The URL can be used to link to this page

Home My WebLink AboutBuso Constructors Inc - 2001-01-16 (2)RECEIVED BY: (Name) (Date) • CITY CLERK RECEIPT COPY Return DUPLICATE to Jeffrey Hughes (ext. 5260) after signing/dating CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: Shari Freidenrich, City Treasurer ATTN: Jim Sllobojan, Deputy City Treasurer FROM: otk) DATE: 01-14-� SUBJECT: Bond Acceptance I have received the bonds for Mo C005T)tKTOW� I 1R. (Company Name) Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Re: Tract No. CC No. 1131 MSC No. Approved C -18 —JI (Council Approval Date) GK43o27 Agenda Item No. G-� City Clerk Vault No. Q6 6CO- 10 '�, CITY OF .HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: THOSE LI TED HEREON FROM: avid Verone, Contract Manager DATE: September 4, 2001 SUBJECT: RETENTION PAYMENT Intrepid Storm Drain CC-1139 Buso Constructors, Inc. The conformddcopy of the Notice of Completion for the above contracts has been filed. The thirty-five (35) day waiting period has elapsed or will elapse before payment is made. Processing of the retention payment is recommended so long as no stop notices or outstanding invoices are on file with the City. I certify that no stop notices are on file on the subject at this time. Date: ! ¢�aIZ rl OBERT F. BEARDSLEY, Public Works Director I certify that there are no outstanding invoices on file. Date: 10 F 10VENRICH, City Treasurer I certify that no stop notices are on file on the subject contract, and that a guaranty bond has been filed. Date: I /v / / I CONNIE BROCKWAY City Oferk Cc "Progress Payments" G:`%CONSTRUCTION CONTRACTS (CCShM 139\RETENTION RELEASE N 1EPoIO.DOC FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE BALTIMORE, MD. 21203 MAINTENANCE BOND Bond No. 08543027 KNOW ALL MEN BY THESE PRESENTS: 'Appi-�0m 3S To FORYQ(I G IL ..TTCAi, City A orney ray: Deputy City Attorney That BUSO CONSTRUCTORS, INC., as principal, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation organized under the laws of the State of Maryland and authorized to do a surety business in the State of California, as surety, are held and firmly bound unto the CITY OF HUNTINGTON BEACH, CALIFORNIA in the sum of thirteen thousand three hundred sixty three and no/100ths dollars; { $13,363.00 ) ; lawful money of the United States of America, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. Sealed with our seals and dated this .... 23rd.... day of.......May.......................2001. WHEREAS, on the ......... 16th......... day of .........January ........................2001, the said BUSO CONSTRUCTORS, INC., as contractor, entered into a contract for -the "Storm Drain Construction" work required in the construction of the "Intrepid Lane Storm Drain"; CC-1139 ; for the sum of $133,626.00 ; and WHEREAS, under the terms of the specifications for said work, the said principal, BUSO CONSTRUCTORS, INC., is required to give a bond equal to 10% of the total amount of the contract to protect the CITY OF HUNTINGTON BEACH against the result of faulty materials or workmanship for a period of ONE YEAR from and after the date of the completion and acceptance of same, namely until the ..5th..... day of...May ......... 2002. NOW, THEREFORE, if the said Principal, BUSO CONSTRUCTORS, INC., shall for a period of ONE YEAR from and after the date of the completion and acceptance of same by said obligee,CITY OF HUNTINGTON BEACH, replace any and all defects arising in said work whether resulting from defective materials or defective workmanship, then the above obligation to be void; otherwise to remain in full force and effect. Page 1 of 2 "Seal" "Seal' Page 2 of 2 BUSO CONSTRUCTORS, INC. Signed B3 FIDELITY AND DEPOSIT COMPANY OF MARYLAND Surety Signed By: zo",-'so Name: wren M. Brown Title: Attorney -in -fact CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No 5907 State of CALIFORNIA County of ORANGE On May 23rd, 2001 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER • E.O., •JANE DOE, NOTARY PUBLIC' personally appeared OWEN M. BROWN NAMES) OF SIGNER(S) ' ® personally known to me - to be the persor*) whose name(e) is/ subscribed to the within instrument and ac- knowledged to me that heh b q executed the same in his/'knot authorized capacitytkn), and that by his/is signature(N) on the instrument the personN), or the entity upon behalf of which the '"`"'"`"``""�'"" `' person() acted, executed the instrument. BARBARA J. BENDER Commission 12674s' W IV SS hZSITURE ff' ial seal. krc�e�'� * Notay Pubrc - Caitfomia y Orange County 4 My Co^�m.'res Jul 13, 2C3S +' OF NOTARY OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL C9 ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) FTDELTTY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT Maintenance Bond TITLE OR TYPE OF DOCUMENT Two NUMBER OF PAGES May 23rd, 2001 DATE OF DOCUMENT Principal SIGNER(S) OTHER THAN NAMED ABOVE 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 & Canoga Park, CA 91309.7184 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE, MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen M. Brown of Anaheim, California its rue and lawful agent and Attorney -in -Fact, to make, execute, s deliver, �- d on its behalf as surety, and as its act and deed: any and all bonds and undertakings.... .... ................... e execution of such bonds or undertakings in purs Wf these 'o^ , shall be as binding upon said Company, as fully and amply, to all intents and purposes, as if they had been d o uted anwledged by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper The said Assistant Secretary does hereby certi a extrac`u- - rth on the reverse side hereof is a true copy of Article VI, Section 2, of the By -Laws of said Company, and is force. u IN WITNESS WHEREOF, the said Vice- ' ent and staht Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY AN, POSIT CO OF MARYLAND, this_____22nd—_--____day of __, Jul_ , A.D. 19 a�ro, FIDELL*AND IT COMPANY OF MARYLAND ATTEST: ' SEAL �a By Assis etary Vice-PresidAnt STATE OF MARYLAND Q COUNTY OF BALTIMORE �° On this 22nd =___day of __ July_______—, A.D. 192.3—, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed -and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above wr itte . pp a F.qO NOTARY P � AROL J. FADER Notary Public My Commission CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." 2 3 J' d IN TESTIMONY WHEREOF, I have herey8)6sybscribed my name and affixed the corporate seal of the said Company, this _______— day of--____------ May ��----> — Assistant Secretary 1.1428. -012- 4 160 ALAN SLATER, ECEC TrIVE OFFICER AND CLERK OF THE SUPERIOR COURT TY O F ORANGE COUNTY SUPERIOR COURT PROBATE COURT OPERATIONS 341 THE CITY DRIVE P. O. BOX 14171 All G E ORANGE, CA 92613-1571 CLERK OF THE SUPERIOR COURT D= AUGUST 16, 2001 '1 V:r' :A ��tr1 • ' ' M:r• It M :�' •i' �:i" �•11• :r' •.• •• 11'.1 1 It ' •:• :1' •• t! •:' •:' H' V• •1' M• 1` •.'1 1 • :1;�' :+1: M:r'� 1' Y: .�1. V• G` Y' V• 1' •'.'1 I DO FURTHER CERTIFY THAT A COMPLETE LIST OF ALL INSURERS ADMITTED TO TRANSACT SURETY INSURANCE IN THIS SPATE, AS cERr FIED TO THIS DEPArman ' BY THE INSURANCE ammTssictm, Is CN FILE IN THIS OFFICE. FIDELITY & DEPOSIT CO. OF MARYLAND IS CN THE LIST AS ONE OF THE INSURERS ADMITTED TO TRRAM= SURETY INSURANCE IN THE STATE OF CALIFORNIA. t ► I:ti ':Is• J1" :I• :I:Y• :r11 • ► :/• It 11 444001J�Awm*Amo / n-1, • • Cit-.• of Huntington Beach Depar4nent of Public Works Post Office Box 190 Huntington Beach, CA 92648 Subject: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Gentlemen: The undersigned, contractor on C^5 H �opTrts.�i No , 1139 S MTRcs--i O L. A" NI 5-rRP%X 1+1 pMAs n1 Project No. Title hereby certifies that all laborers, mechanics, apprentices, trainees, Nvatchmen and guards employed by him or by any subcontractor performing work under the contract on the project have been paid wages at rates not less than those required by the contract provisions, and that the work performed by each such laborer, mechanic, apprentice or trainee conformed to the classifications set forth in the cortract.or training program provisions applicable to the Nvage rate paid. �`Lcs. Jc.•r i 4SiatO,,ireari�d Title It &:CC :sshtonl • 11 DECLARATION OF SATISFACTION OF CLAIMS [, �Rclo ►JJCJ4AMs."--t , state: I. 1 am the general contractor for the City of Huntington Beach, as to the project more fully described in the public «-orks contract entitled _TN-ri-AaP%j> and dated 6o NOV Z000 2. Ail workers and persons employed, all firms supplying materials, and all subcontractors for the above -mentioned project have been paid in full. 3. Tie following are either disputed claims, or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of Califomia: (if none, state "NONE") I declare under penalty of perjury that the foregoing is true and correct. Executed at L..i..,, on this Z S day of Z,00t (S attire of Contractor) g:cckazhcon2 Recorded in Official Records, County of Orange Gary Granville, Clerk -Recorder WHEN RECORDED MAIL TO: I IIIIII II 11111111111111111111111111111111111111111111II NO FEE fTY OF of the C INCG TON BEACH �20 25 N,2001044908012:38pm 07/05101 P.O. Box 190 — 2000 Main St. 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 Huntington Beach, CA 92648 NOTICE OF COMPLETION NOTICE IS HEREBY GIVEN by the City of Huntington Beach, owner in fee, 2000 Main Street, Huntington Beach, CA 92648, that the contract heretofore awarded by the City Council of the City of Huntington Beach, California to Buso Constructors, Inc. who was the company thereon for doing the following work to -wit: I CC-1139 — INTREPID LANE STORM DRAIN PROJECT I This project includes the construction of a new storm drain involving the modification of the "U" channel running parallel with Intrepid Lane and adding drains. That said work was completed June 18, 2001 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach at a regular meeting thereof held on Monday, June 18, 2001. That upon said contract Fidelity and Deposit Company of Maryland was surety for the bond given by the said company as required by law. This document is solely for the official business of the City of Huntington Beach, as contemplated under Government Code Section 6103 and should be recorded free of charge. Dated at Huntington Beach, California, this 22"d day of June, 2001. 6;�" Zj kOL4"-� City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California STATE OF CALIFORNIA ) County of Orange ) ss: City of Huntington Beach ) I, CONNIE BROCKWAY, the duly elected and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California do hereby certify under penalty of perjury, that the foregoing NOTICE OF COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Orange County by said. City Council. Dated at Huntington Beach, California, this 22"d day of June, 2001. y City Clerk and ex-officio Clerk of the City Council of the City, of Huntington Beach, California WHEN RECORDED MAIL TO: CITY OF HUNTINGTON BEACH Office of the City Clerk P.O. Box 190 — 2000 Main St. Huntington Beach, CA 92648 CITY OF HUNTINGTON BEACH *1Zq*, A MEETING DATE: June 18, 2001 DEPARTMENT ID NUMBER: PW-01 -072 Council/Agency Meeting Held: Deferred/Continued to: WV___ A proved ❑ Conditionally Approved ❑ Denied -- Q—R _ City CI 's Signature Council Meeting Date: June 18, 2001 Department ID Number: PW-01-072 CITY OF HUNTINGTON BEACH REQUEST FOR ACTION SUBMITTED TO: HONORABLE MAYOR AND CITY COUNCIL MEMBERS SUBMITTED BY: RAY SILVER, City AdministratorGv/2J PREPARED BY:� OBERT F. BEARDSLEY, Director of Public Work C� SUBJECT: Accept the Intrepid Lane Storm Drain Project CC-1139 and File the Notice of Completion. Statement of Issue, Funding Source, Recommended Action, Alternative Action(s), Analysis, Environmental Status, Attachment(s) Statement of Issue: Should the City Council accept the Buso Constructors, Incorporated contract as complete for the construction of the Intrepid Lane Storm Drain Project, CC1139? Funding Source: Funds in the amount of $153,675 were authorized from the General Fund, Capital Projects, Intrepid Storm Drain, Account No. 30188006.69365. Recommended Action: Motion To: 1. Accept the Intrepid Lane Storm Drain Project CC-1139 at a final cost of $140,970.02 and authorize the City Clerk to file a notice of Completion with the County Recorder's Office. Alternative Action(s): None. Analysis: On January 16, 2001, the City Council awarded a construction contract to Buso Constructors, Incorporated and authorized a construction budget of $133,626 for the improvements to Intrepid Lane Storm Drain Project, CC-1139. The adopted project budget also included $13,366 to cover potential change orders and $6,683 for supplemental expenses, for a total of $153,675. The improvements have been completed ahead of schedule and under project budget per the approved plans and specifications. The Director of Public -Works recommends acceptance of the project and requests that the City Clerk be authorized to file the Notice of Completion with the County Recorder. M 01-072 June 18 Verone -2- 6/4/01 10:38 A REQUEST FOR ACTION MEETING DATE: June 18, 2001 DEPARTMENT ID NUMBER: PW-01 -072 The following is a summary of the final project costs: Council Approved 1. Contract Amount: $133,626.00 2. Change orders: 13,366.00 Subtotal: $146,992.00 3. Supplemental Expenses: 6,683.00 Total: $153,675.00 Two change orders were issued for this project: Actual Expenditures $137,168.00* 3.784.02 $140, 970.02 0.00 $140, 970.02 * Actual quantities placed during construction were greater than estimated. Public Works Commission Review: On October 18, 2000, the Public Works Commission approved the staff recommendation for the construction of the Intrepid Lane Storm Drain Project, CC-1139 by a vote of 5-0-2 . Environmental Status: This project was categorically exempt pursuant to section 15301, Class 1 of the CEQA Guidelines. Attachment(s): RCA Author: Verone 01-072 June 18 Verone -3- 6/6/01 6:44 PM ;, CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK June 22, 2001 Gary Granville County Clerk -Recorder P.O. Box 238 Santa Ana, CA 92702 Enclosed please find a Notice of Completion to be recorded and returned to the Office of the City Clerk, City of Huntington Beach, P.O. Box 190, Huntington Beach, CA 92648. Also enclosed is a copy of the Notice of Completion to conform and return in the enclosed self- addressed, stamped envelope. Sincerely, Connie Brockway, CMC City Clerk CB:jh Enclosure: ' Notice of Completion — CC-1139 — Intrepid Lane Storm Drain — Buso Constructors, Inc. (Telephone: 714536-5227 ) WHEN RECORDED MAIL TO: CITY OF HUNTINGTON BEACH Office of the City Clerk P.O. Box 190 — 2000 Main St. Huntington Beach, CA 92648 NOTICE OF COMPLETION NOTICE IS HEREBY GIVEN by the City of Huntington Beach, owner in fee, 2000 Main Street, Huntington Beach, CA 92648, that the contract heretofore awarded by the City Council of the City of Huntington Beach, California to Buso Constructors, Inc, who was the company thereon for doing the following work to -wit: CC-1139 — INTREPID LANE STORM DRAIN PROJECT. This project includes the construction of a new storm drain involving the modification of the "U" channel running parallel with Intrepid Lane and adding drains. That said work was completed June 18, 2001 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach at a regular meeting thereof held on Monday, June 18, 2001. That upon said contract Fidelity and Deposit Company of Maryland was surety for the bond given by the said company as required by law. This document is solely for the official business of the City of Huntington Beach, as contemplated under Government Code Section 6103 and should be recorded free of charge. Dated at Huntington Beach, California, this 22"d day of June, 2001. City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California STATE OF CALIFORNIA ) County of Orange ) ss: City of Huntington Beach ) I, CONNIE BROCKWAY, the duly elected and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California do hereby certify under penalty of perjury, that the foregoing NOTICE OF COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Orange County by said City Council. Dated at Huntington Beach, California, this 22"d day of June, 2001. City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California WHEN RECORDED MAIL TO: CITY OF HUNTINGTON BEACH Office of the City Clerk P.O. Box 190 — 2000 Main St. Huntington Beach, CA 92648 ATTACHMENT #1 N %p ti o,F E. �o N AVE. N y~j AVE.p y Ir � a AVE. m z W W V VE. AVE. _ 405 'ALBERT AVE. mri E JAVE. �~ 9 GARFlELD AVE. F. INDIANAPOUS I I AVE. o Ir TLANTA a � a AVE. NZH OCEAN VICINITY MAP \ N.T.S. \ I /I LOCATION MAP N.T.S. RCA ROUTING SHEET INITIATING DEPARTMENT: Public Works SUBJECT: Accept the Intrepid Lane Storm Drain Project CC-1139 and file the notice of completion COUNCIL MEETING DATE: June 18, 2001 ... ... R_ CA ATMT STATUS Ordinance (w/exhibits & legislative draft if applicable) Not Applicable Resolution (w/exhibits & legislative draft if applicable) Not Applicable Tract Map, Location Map and/or other Exhibits Attached Contract/Agreement (w/exhibits if applicable) (Signed in full by the City Attorne) Not Applicable Subleases, Third Party Agreements, etc. (Approved as to form by City Attorne) Not Applicable Certificates of Insurance (Approved by the City Attorney) Not Applicable Financial Impact Statement (Unbudget, over $5,000) Not Applicable Bonds (If applicable) Not Applicable Staff Report (If applicable) Not Applicable Commission, Board or Committee Report (If applicable) Not Applicable Findings/Conditions for Approval and/or Denial Not Applicable EXPLANATION FORMISSING;ATTACHMENTS EXPLANATION FOR RETURN OF ITEM. I RCA Author: Verone �'--- • ' RECEIVED BY: IM S(o�oli (Name) lS�C) (Date: x CITY CLERK RECEIPT COPY Return DUPLICATE to Jeffrey Hughes (ext. 6260) after signing/dating CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: Shari Freidenrich, City Treasurer ATTN: Jim Slobojan, Deputy City Treasurer 1 FROM: U•4-i5 DATE: 0 L 27- 01 SUBJECT: Bond Acceptance I have received the bonds for B650 CON 4t S 'I INC. (Company Name) Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Re: Tract No. CC No. H 3 i MSC No. Approved dl - �b—�� Agenda Item No. F, 5 (Council Approval Date) o 0 City Clerk Vault No. b g:/jah/bondletter.doe ;, CITY OF HUNTINGTON BEACH rqLj 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK LETTER OF TRANSMITTAL OF ITEM APPROVED BY THE CITY COUNCIL/ REDEVELOPMENT AGENCY OF THE CITY OF HUNTINGTON BEACH DATE: February 27, 2001 TO: Buso Constructors, Inc. Name 14700 Firestone Blvd. Street La Mirada, CA 90638 City, State, Zip ATTENTION: Greg Buchanan, Pres . DEPARTMENT: REGARDING: CC No. 1139 - Intrepid Lane Storm Drain Project See Attached Action Agenda Item E-5 Date of Approval 01-16-01 Enclosed For Your Records Is An Executed Copy Of The Above Referenced Agenda Item. Remarks: C&�lrl.G a4w� Connie Brockway City Clerk Attachments: Action Agenda Page X Agreement X RCA CC: D. Verone Name T. Broussard Name S. Freidenrich Name Name C. Mendoza u"w De UV ent Department City Treas. Department Department X Risk Management Dept. RCA X RCA X RCA RCA X Bonds X Insurance X Deed Other X X bonds Agreement Insurance Other X x bonds Agreement Insurance Other bonds Agreement Insurance Other Agreement Insurance Other X Insurance (Telephone: 714-536-5227) CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND BUSO CONSTRUCTORS, INC. FOR CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139) TABLE OF CONTENTS Page No. 1. STATE OF WORK; ACCEPTANCE OF RISK 1 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS 2 3. COMPENSATION 3 4. COMMENCEMENT OF PROJECT 3 5. TIME OF THE ESSENCE 4 6. CHANGES 4 7. NOTICE TO PROCEED 5 8. BONDS 5 9. WARRANTIES 5 10. INDEPENDENT CONTRACTOR 6 11. LIQUIDATED DAMAGES/DELAYS 6 12. DIFFERING SITE CONDITIONS 7 13. VARIATIONS IN ESTIMATED QUANTITIES 8 14. PROGRESS PAYMENTS 9 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES 9 16. AFFIDAVITS OF SATISFACTION OF CLAIMS 10 17. WAIVER OF CLAIMS 10 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS 10 19. WORKERS' COMPENSATION INSURANCE 11 20. INSURANCE 11 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED 12 22. DEFAULT & TERMINATION 13 23. DISPOSITION OF PLANS, ESTIMATES AND OTHER 13 24. NON -ASSIGNABILITY 13 25. CITY EMPLOYEES AND OFFICIALS 13 26. STOP NOTICES 14 27. NOTICES 14 28. CAPTIONS 14 29. IMMIGRATION 14 30. LEGAL SERVICES SUBCONTRACTING PROHIBITED 15 31. ATTORNEY'S FEES 15 32. ENTIRETY 16 01 agree/storm drain/ 1 /30/01 CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND BUSO CONSTRUCTORS, INC. FOR CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139) THIS AGREEMENT, made and entered into this 16th day of January 2001, by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and BUSCO CONSTRUCTORS, INC., a California corporation hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as construction of Intrepid Lane storm drain (CC-1139) in the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall furnish, at its own expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any description connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner 01agree/storm drain/1/30/01 shown and described in this Agreement, and in accordance with the requirements of CITY under them for the compensation set forth in the accepted bid proposal. However the total compensation to be paid is to be computed on the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s). 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS. CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as hereinafter defined), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by said Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council of CITY, and any revisions, amendments or addenda thereto; D. The 2000 edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 3055 Overland Avenue, Los Angeles, CA 90034, and all amendments thereto, written and promulgated by the Southern California 01agree/storm drain/1/30/01 2 chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal (attached hereto as Exhibit "A"); F. The particular plans, specifications, special provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of discrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as "DPW"), without whose decision said discrepancy shall not be adjusted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in conflict herewith. 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed One Hundred Thirty Three Thousand Six Hundred Twenty Six Dollars ($133,626), as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after notice to proceed is issued and shall diligently prosecute PROJECT to completion 01agree/storm drain/1/30/01 3 within forty-five (45) consecutive working days from the day the "Notice to Proceed" is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and. shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6 CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by the DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as the DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the written order of the DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by the DPW. 01agree/storm drain/1/30/01 4 When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the effect of the change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS CONTRACTOR shall, prior to entering upon the performance of this Agreement, furnish the following three bonds approved by the City Attorney: One in the amount of one hundred percent of the contract price to guarantee the CONTRACTOR's faithful performance of the work; one in the amount of one hundred percent of the contract price to warrant such performance for a period of one (1) year after CITY's acceptance thereof; and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. 9. WARRANTIES The CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or 01agree/storm drain/1/30/01 structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten- (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that the CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not and employee of CITY. CONTRACTOR shall secure at its expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of Four Hundred Dollars ($400) per day for each and every working day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable losses CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. 01agree/storm drain/1/30/01 6 CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays or subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of final settlement of the Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of the DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed waiting for materials required by this Agreement to be furnished to CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days the CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of time for completion shall be the sole remedy of CONTRACTOR. 01agree/storm drain/1/30/01 7 12. DIFFERING SITE CONDITIONS (1) Notice: The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) Subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents; or (b) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. The DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly; (2) Time Extension: No claim of the CONTRACTOR under this Section shall be allowed unless the CONTRACTOR has given the notice required hereunder, provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to the CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this section. The DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in 01agree/storm drain/1/30/01 8 price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, the DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its judgment the findings warrant. 14. PROGRESS PAYMENTS Each month the DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY and the remainder, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of the DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if the DPW finds that satisfactory progress has been and is being made, the CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined by DPW, less all previous payments and less all previous retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated int. certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as a acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit 01agree/storm drain/1/30/01 9 therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with the DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PROJECT for either labor or material, except certain items, if any, to be set forth in an affidavit covering disputed claims, or items in connection with Notices to Withhold which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold and save harmless CITY, its officers, and employees against any and all liability, claims, judgments, costs and demands, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, and subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence except where caused by the active negligence, sole negligence, or willful misconduct of CITY. CONTRACTOR will conduct all defense at its sole cost and expense. 01 agree/storm drain/1/30/01 10 19. WORKERS' COMPENSATION INSURANCE Pursuant to California Labor Code section 1861, CONTRACTOR acknowledges awareness of section 3700 et seq. of said Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall maintain workers' compensation insurance in an amount of not less than One Hundred Thousand Dollars ($100,000) bodily injury by accident, each occurrence, One Hundred Thousand Dollars ($100,000) bodily injury by disease, each employee, Two Hundred Fifty Thousand Dollars ($250,000) bodily injury by disease, policy limit. CONTRACTOR shall require all subcontractors to provide such workers' compensation insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 20. INSURANCE In addition to the workers' compensation insurance and CONTRACTOR's covenant to indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. Said policy shall indemnify CONTRACTOR, its officers, agents and employees, while acting within the scope of their duties, against any and all claims of arising out of or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of $1,000,000 per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than $1,000,000. Said policy shall name CITY, its officers, and employees as Additional Insureds, and shall specifically provide that any other insurance coverage which may be 01agree/storm drain/1/30/01 I I applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary. Under no circumstances shall said above -mentioned insurance contain a self -insured retention, or a "deductible" or any other similar form of limitation on the required coverage. 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; said certificates shall: 1. provide the name and policy number of each carrier and policy; 2. shall state that the policy is currently in force; 3. shall promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY; and 4. shall state as follows: "The above -detailed coverage is not subject to any deductible or self -insured retention, or any other form of similar -type limitation." CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this'Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under the Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all said policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. A separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming the CITY, its officers and employees as Additional Insureds shall be provided to the City Attorney for approval prior to any payment hereunder. 01agree/storm drain/1/30/01 12 22. DEFAULT AND TERMINATION If CONTRACTOR fails or refused to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged a bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the contract documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. 23. DISPOSITION OF PLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 24. NON -ASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety. 25. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of California Government Code sections 1090 et seq. 01agree/storm drain/1/30/01 13 26. STOP NOTICES: RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. Said obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100) for every Stop Notice filed in excess of two, regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 27. NOTICES All notices required or permitted hereunder shall be delivered in person or by registered or certified mail to an authorized representative of the party to whom delivery is to be made, at the place of business of such party, or to any other place designated in writing by such party. 28. CAPTIONS Captions of the section of this Agreement are for convenience and reference only, and the words contained therein shall in no way be held to explain, modify, amplify or aid in the interpretation, construction or meaning of the provisions of this Agreement. 29. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of U.S.C. Section 1324a regarding employment verification. 30. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to 01agree/storm drain/1/30/01 14 Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 31. ATTORNEY'S FEES In the event suit is brought by either party to enforce the terms and provisions of this agreement or to secure the performance hereof, each party shall bear its own attorney's fees. 32. ENTIRETY The foregoing, and Exhibit "A," attached hereto, set forth the entire Agreement between the parties. IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized offices the day, month and year first above written. BUSO N T UCT S, INC. By: G g Buchanan, President AND By: ilario Soto, Secretary REVIEWED AND APPROVED: City Adn4ffiistrator CITY OF HUNTINGTON BEACH, a municipal corporation of the State of California ATTEST- C��XGfi City Clerk a%.— APPROVED AS TO FORM: ePAN,pCi;� r3pSyey INITJATED,AND APPROVED: rector of Public Works 01agree/storm drain/1/30/01 15 SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become.the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find D 3oN rin the amount of $ 1 % which said amount, is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert.the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum No. Date Received Bidder's Signature %�27- oti C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S'. ///i2�s'% hka�zs.�•w Dollars Alf Cents 2 1 Traffic Control $2,000 $2,000 L.S. o /ySr,V'n Dollars /tle Cents 3 1 Trench Shoring L.S. ,a,6 f.6, aad o Dollars /✓v Cents /,Soo /Soo 4 889 18" HDPE Storm Drain Pipe L.F. @ Dollars Alp Cents _ 5 238 4" HDPE Storm Drain Pipe L.F. A1,4A Dollars Alb Cents /O q -Z S g 4Z 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each �.yo fi� ••►,o�- IIA1,17y Dollars Alb Cents 2 90 - g4-10 7 20 Concrete Channel Backfill C.Y. @ S,i�r✓ .t�y.✓�rry .�.,�'yi� v�bollars — //o Cents % Z S 4 SeD 8 2 . Tideflex Gate Valve, Series 37G Each @ /�i-/c�vsv�� v.�wj�v Dollars _ /+/o Cents �-SoD q' D OCD 9 3 Junction Structure - Type D Each /tA10 /sSiAvs�swo .fix �v,►�v,,zDollars /i/b Cents 2 DO �SDd 10 2 Abandon Existing Lateral Each Dollars Cents _ svo ODc� 11 30 Sawcut Local Depression L.F. @.z /- y Dollars ,r _ itlo Cents 4-0 I Z.cao 12 30 Reconstruct Concrete U-Channel L.F. @7Z Y Dollars A /o Cents Z O Total Amount Bid in Figures: $ 3 3 4o Z 6 Total Amount Bid in Words: p„�E �- yy�.v.7ozci� /h/i/1TY /NiZe:� �� !>i✓Oi2u� // %STY S%Y ;2ZZ-4.¢/LS -- C-ls LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class Of Number Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOx. LUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California $3. County of Orange GREG BUCHANAN , being first duly sworn, deposes and says that he or she is PRESIDENT of BUSOCCONSTRUCTORS, INC. the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genu} e and not collusive or sham; that the bidder has not directly or indirectly induced or solicited aby other bidder to.put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put In a sham bid, or that anyone shall refrain from bidding, that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. BUSO CONSTRUCTORS, INC. Name o i Signs a of Bidder GREG BUCHANAN, PRESIDENT 14700 FIRESTONE BLVD, #103 LA MIRADA, CA.90638 Address of Bidder Subscribed and sworn to before me this 1s_ tday of DES , 2000. SEE ATTACHED NOTARY ACKNOWL " NOTARY PUBLIC NOTARYSEAL C.a 1. CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No.5907 State of CALIFORNIA County of ORANGE On 12-1-00 before me, BARBARA.J BENDER, NOTARY PUBLIC DATE NAME. TITLE OF OFFICER - E.G.. -JMIE DOE, NOTARY PUBLIC' personally appeared GREG BUCHMAN NAME(S) OF SIGNER(S) ' personally known to me - to be the persortz) whose name((&) is/ subscribed to the within instrument and ac- knowledged to me that heap executed the same in his%kcabbadz authorized capacitypox), and that by his/XVVAX K signature(N) on the instrument the person(), or the entity upon behalf of which the person(t) acted, executed the instrument. BARBARA J. BENDER +* 1267491 Z 2NSLhand-;tn cial seal. Z Notay Public - Califon fa'Cronge county _ My comm. Exphn Jul 3, 2004 610JATURE OF NOTAAY OPTIONAL Though the data below. is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL CORPORATE OFFICER PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR . ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR ENTITY(IES) BUSO CONSTRUCTORS, INC. DESCRIPTION OF ATTACHED DOCUMENT NON —COLLUSION AFFIDAVIT TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 9 Canoga Park, CA 91309.7184 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission_ orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Wte:. �cL Z000 Contractor lz!!!�_ By Title C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yesto If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation onto undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date:,, f% Uc-) S a Co r is 7 (ZQC 1 0 2s �N Contractor By Title \` C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identiftcation Number: Contractor Title Date: Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name Business Address 1--P- F "9 o 03 8 City, State Zip (7 k4) 7 3 -1 E3 t 81 Telephone Number �nd9 g©Z 4-\-, State Contractor's License No. and Class to C>Gi q Original Date Issued --' ► Expiration Date The work site was inspected b�iy�''�' '� of our office on ZS t��•i , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: (fo2teo 13jcr-i^ rjokrJ C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise,- to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. GREG BUCHANAN, 'PRESIDENT Printed or Typed Signature Subscribed and sworn to before me this istday of DECEMBER , 2000, NOTARY PUBLIC SEE ATTACHED -NOTARY ACKNOWLEDGMENT NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. P% \h/ATdZ �oJ2cc3 '.0, ^3i ��c 111 Z- L�+•,•�c•�•s�•t Cs�. �'13584- Name and Address of Public Agency Name and Telephone No. of Project Manager: Cob I c► 4-% 1 o ZA' % S S 7 TJ P)c 19 9 9 Contract Amount Type of Work Date Completed Ili \h/s �c�z 2es",*44es '`O, 3cx 11{-L Name and Address of Public Agency CA 9 3 SS 4- Name and Telephone No. of Project Manager: Po-1 661 o14-�0 102-4- �, pZZ� pvo LoNazei� �as....a.►C� EGG 99 Contract Amount Type of Work Date Completed Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work lute Completed C-10 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No 5907 State of CALIFORNIA County of ORANGE On 12-1-00. before me, BARB`RA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G.,'JANE DOE, NOTARY PUBLIC personally appeared GREG BUCHANAN NAME(S) OF SIGNER(S) ' ® personally known to me - to be the person*;) whose name(e) isAM subscribed to the within instrument and ac- knowledged to me that hey executed the same in his/mac authorized capacity0m), and that by his/XVVAUW signature(g) on the instrument the personN), or the entity upon behalf of which the person(%) acted, executed the instrument. BARBARA J. BENDER Commission # 1267491 -. Notary Public - Carfomia JITSS hand n i 'al seal. Orange County a My Comm. ExPlres Jul 13, 2004 - SIG RE OF NOTARY OPTIONAL Though the data'below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL CORPORATE OFFICER PRESIDENT TITLE(S) ❑ PARTNER($) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR ENTM(IES) BUSO CONSTRUCTORS, INC. DESCRIPTION OF ATTACHED DOCUMENT N/A TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT N/A SIGNER(S) OTHER THAN NAMED ABOVE 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 9 Canoga Park, CA 91309.7184 Bond No ...... 3.0517 19........ Fidelity and Deposit Company HOME OrrrcE OF MARYLAND BALT1M0f2E, MD. 21203 BID BOND KNOW ALL MEN BY THESE PRESENTS: BUSO CONSTRUCTORS, INC. Thatwe, ................................................................................................................................................................................... .................................................................................................................................................................................................. ..................................................................................... as Principal, (hereinafter called the "Principal"), and tale FIDELITY AND DEPOSIT COMPANY OF MARYLAND, of Baltimore, Maryland, a corporation duly organized under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety"), are held and firmly bound unto......... CITY OF..HUNTINGTON..BEACH ............................................................................................................................................................ .................................................................................................................................................................................................. ..................................................................................................................as Obligee, (hereinafter called the "Obligee"), in the sum of ................. TEN PERCENT OF THE TOTAL BID IN------------- Dollars ($..1Q70...af...Bi.d..), ................. ....... ..... ..................................................... for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for................................................................................................... INTREPID LANE STORM DRAIN CASH CONTRACT..N0..1.39 ...................................... NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or contract documents with good and sufficient surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this ................... IS.t.................................. day of ............. DECEKBER.................... A.DX3X..20QO . ... ...... .. . .................. . .. ......... Witness BID DATE: DECEMBER 5, 2000 FIDELITY AND I�Witness CJlsd—ISOM, Approved by The American Institute of Architects, A.I.A. Document No. A•310 February 1970 Edition. USO CO R C ORS, IN..Q............................:.(SEAL' ........... Principal Y: ..... ................................................................ GREG CHANAN, PRESIDENT Title DEPOSIT COMPANY OF MARYLAND S irety B... ....... ..............................(SEAT.) 0 N M. R Title . ATTORNEY -IN -FACT CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 12-1-00 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G., 'JANE DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN NAMES) OF SIGNER(S) ' personally known to me - to be the persortz) whose name(e) isAM subscribed to the within instrument and ac- knowledged to me that heAkwAkzy executed the same in his/"knobbadz authorized capacitytm), and that by his/MmWOM signature(N) on the instrument the personp§), or the entity upon behalf of which the person(t) acted, executed the instrument. Le . _ . � My ..tcry .: _. .,. sidA-ruRr: OF NOTARY OPTIONAL Though the data below• is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL = ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR ENTITY(IES) FIDELITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC- SIGNER(S) OTHER THAN NAMED ABOVE No.b007 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 • Canoga Park, CA 91309.7184 Power of Attorney - FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE. MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen M. Brown of Anaheim, Cal iforn' i rue an lawful agent and Attorney -in -Fact, to make; execute, any and all bonds and undertakings....... on its behalf as surety, and as its act and deed: AMrffe—e`xec_u_tIon of such bonds or undertakings in puts lleZ61f thesed\, shall be as binding upon said Company, as fully and an amply, to all intents and purposes, as if they had been d o cuted wledged by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper tent The said Assistant Secretary does hereby certie extracqrth on the reverse side hereof is a true copy of. Article VI, Section 2, of the By -Laws of said Company, and isce.uIN WITNESS WHEREOF, the said Vice- d is t Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY ANI POSIT CO OF MARYLAND, this _ 22nd day of July A.D. 19 ®RRI FIDELL AND IT COMPANY OF MARYLAND ATTEST: � By Assis etary Vice-Presid a STATE OF MARYLAND Q COUNTY OF BALTIMORE �' �. On this LRd __day of Ju_ 1Y A.D. 192.-L, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first abovew itte . 9 NOTARY ___--� - a PUBLIC AROL J. FADER Notary Public �ECW" My Commission ExpiresAugust 1�1996 _ CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this 1st -- day of_-DECE RE[�ER 2000 Assistant Secretary L142&- -012- 4 16 0 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For INTREPID LANE STORM DRAIN CC- 1139 November 15, 2000 Notice To All Bidders: Please note the following revision to the Project Plans, Specifications, and Technical Provisions: In an effort to compress the work schedule, the attached Alternate Bid Schedule shall be submitted to complete the project utilizing Saturdays as an additional mandatory work day, following a standard 5 day work schedule. The low bid will be based on the primary Bid Schedule. The City reserves the right to utilize the Alternate Bid Schedule upon execution of the contract. This modification does not change the Engineer's Estimate for this project. This is to acknowledge receipt and review of Addendum Number one, vem 15, 2000. Company Name By Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Todd Broussard at (714) 536-5247. SECTION C ALTERNATE PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1' Mobilization $3,000 $3,000 L.S. @- rLZZ �i �-�o�s �w� Dollars A/a Cents 2 1 Traffic Control $2,000 $2,000 L.S. @�i✓o �o✓sA.�o Dollars No Cents 3 1 Trench Shoring L.S. n/o Cents / 5 o /Soo 4 889 18" HDPE Storm Drain Pipe L.F. @ S'cvc•,1TDollars _ Ab Cents % 4 766 5 238 4" HDPE Storm Drain Pipe L.F. @ Gh/,6 %i Dollars iuiv Cents 1,30 30, q +'n 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each Dollars Mo Cents _ 3 0o g 700 7 20 Concrete Channel Backf ll C.Y. @ sctic•� h�v.� c�a�.�/.✓wrYf-idc Dollars 10o Cents %Z 5 8 21, Tideflex Gate Valve, Series 37G Each @/151; c % 4-lw w.zZZ9 Dollars _ Cents 4--5 vo 9 3 Junction Structure - T e D Each l,,cio: ix 1,6mv,1�,o Dollars Al;.,:, Cents 2 600 %goo 10 2 Abandon Existing Lateral Each @ ;;E:,, V.,E- Dollars _ Ivry Cents. 5-�or 1 coo 11 30 Sawcut Local Depression L.F. @ Ty Dollars Z.00 A-v Cents 1 12 30 Reconstruct Concrete U-Channel L.F. @7Z'aFAei y Dollars Zo A/V Cents Total Amount Bid in Figures: $ /4-6 p ZG Total Amount Bid in Words: T►�.�.�,—Y Six Imo ��yzs -Is •1-03-199S 8:SOPM FROM P. 3 AviORO CERTIFICATE OF LIABILITY INSURANCE DATEF B601 PRODUCER lul W R INSURANCE SERVICES THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND 116 N. EL MOUND AVENUE CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE PASADENA CA 91101 POLICIES BELOW. PHONE: 628-795-3000 ' AX: 626-5774940 Agency Lic#: 0893657 COMPANIES AFFORDING COVERAGE INSURED COMPANY A: The Travellers Indemnity Co G;('1i BUSO CONSTRUCTORS, INC. _ OMPANY 8: ICOMPANYC:1d700 FIRESTONE BLVD., #103t `g LA MIRADA CA 90638 COMPANY D: COMPANY E: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, INS- TYPE OF INSURANCE POLICY NUMBER rOLICf EFFECXamaTIVE POLICY ¢x►IRATION LIMITS GENERAL LABILITY C0351Kl90A JAN 100 JAN 101 EACH OCCURRENCE- S 1,000,000 X COMMERCIAL GENERAL LIABILITY CLAIMS MADE 1 x J OCCUR FIRE DAMAGE (Any One File) S 100,000 MED. EXP (Any One Person) S A X OWNER'S CONTRACTORS PROT. ^ _ _5,000 PERSONAL & ADV INJURY S 1,000,000 GENERAL AGGREGATE S 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS.COMPIOP AGO. $ 2,000,000 POLICY PROJECT LOC AUTOMOBILE LIABILITY ANY AUTO 810331K190A JAN 100 JAN 101 COMBINED SINGLE LIMB (Ea aeoidentl S 1,000,000 X ALL OWNED AUTOS BODILY INJURY A SCHEDULED AUTOS (Per person) S „. BODILY INJURY (Per w6denq S X X HIRED AUTOS NON -OWNED AUTOS PROPERTY DAMAGE S GARAOE LIABILITY AUTO ONLY. EA ACCIDENT S ANY AUTO OTHER THAN EA ACC S S AUTO ONLY: AGO EXCESS LIABILITY X OCCUR U CLAIMS MADE CUP331KB739 JAN 100 JAN 101 EACH OCCURRENCE $ 1,000,000 AGGREGATE S 1,000,000 B S ... DEDUCTIBLE -„ RETENTION g S WORKERS COMPENSATION AND EMPLOYERS' LIASILrTY VVC8TATLL dM�R E.L._EACtfCI21 S T —^--- — E.L. DISEASE -EA EMPLOYEE— E.L DISEASE -POLICY LIMIT S~^ OTHER: DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS RE: INTREPED LANE STORM DRAIN; 1139 CONSTRUCTION CONTRACT -THE CERTIFICATE HOLDER IS NAMED AS ADDITIONAL INSURED AS RESPECTS TO LIABILITY ARISING OUT OF THE NAMED INSUREDS' OPERATIONS PER THE ATTACHED CG2010 (11/85). GAIL0� AS TO F'OR�f:</�C� GAI1; 1 City A orney Ey' Deputy City Attorney nvV..�Vr..a�.rv�Vnc , �VVnCn.LGI1CI{ CITY OF HUNTINGTON BEACH ITS AGENTS, OFFICERS AND EMPLOYEES P,O. BOX 180 HUNTINGTON BEACH, CA 92648 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT. Attention: ACORD 25S (7197) Certificate # 10621 ORA9911? .1-03-1995 8:51PM FROM P.A too.. POLICY NUMBER: C0331 K190A COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED -OWNERS, LESSEES OR Bu 60. CONTRACTORS (Form B) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY SCHEDULE Name of Person or Organization; CITY OF HUNTINGTON BEACH ITS AGENTS, OFFICERS AND EMPLOYEES P.O. BOX 190 HUNTINGTON BEACH, CA 92548 (If no entry appears above. information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) WHO IS AN INSURED (Section II) is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of "your work' for that insured by or for you RE: INTREPED LANE STORM DRAIN; 1139 CONSTRUCTION CONTRACT. CG 20 10 1185 Copyright. Insurance Services Office, Inc., 1984 Certificate # 10621 .1-03-1995 8:51PM FROM P. 5 POLICYNUMBER: C0331K190A COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ THIS CAREFULLY ADDITIONAL INSURED PRIMARY COVERAGE 0�UI�(C��{1 i his endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART This insurance is primary for the person or organization shown in the schedule, but only with respect to liability arising out of your work or that insured by or for you. Other insurance afforded to that insured will apply as excess and not contribute as primary to the insurance afforded by this endorsement. All other endorsement provisions, conditions and exclusions of this insurance shall remain unchanged and apply to the additional insured and described below. SCHEDULE .ADDITIONAL INSURED CITY OF HUNTINGTON BEACH ITS AGENTS, OFFICERS AND EMPLOYEES P.O. BOX 190 HUNTINGTON BEACH, CA 92548 NAMED INSURED BUSO CONSTRUCTORS, INC. 14700 FIRESTONE BLVD., #103 �-. LA MIRADA CA 90638 CONTRACT/PROJECT RE: INTREPED LANE STORM DRAIN; 1139 CONSTRUCTION CONTRACT. Certificate # 10621 1—03-199S 8 : 49PM FROM P. 2 co STATE P.O.BOX:420807, SAN FRAIVCI CO,.CA 941.42-0807 I COMPENSATION. , MIS UR.ANC.E FU, N ; : ERTIFIC A►T :PF .W(�?RK, ik ` a MPENS/�T� dla1.:INSUR IN E. >:" r' FEBRUARY } UNI`T 0004944 iPeLICYtq:`:. a:. .�.. CC-2IFICA�E'aXP1RE`S'"::r; CITY OF HUNT DEPARTMENT GF,f' i�;.toJl'if�k`S. i `E:3.Ti.. .. .. .� ..1E°`'•)t: HUNT INGTON HEACK,. ':t 92,648, � LnG JOB; •;+ a."' 2,648 `,a�;�i; �:' ri+i�"<', '':�!' JQlii ` ,. �., DRAIN ,..:�•..� .4:; . L. 1139 Ci)NSTRUCT I ON C¢tJTR Thls,is to.bertify that we have •issued..a valid Workers' Compensation insurance,policy in a form approved. tty. the California: insurance'Coe►missioner to,the.or fooyei nair ed.below.for the'poh' pedod-indicated. —- 30 This policy is not subject.to cancellation by the.Fund except Upon* days' advance written notice to the employer. . We will. also- give you J�N days' advance.notice should this policy be'cancelled prior to its .normal'.expiration. This certificate of insurance is not an .insurance policy and does. not -amend, extend or alter the coverage afforded by the policies listed herein. Nbtwithstanding"r any. requirement, term, or condition of any contract or other document with respect to which :P certificate. of nStlrance ma ^b ,fssaeti`or may pertaih,rtrie ins urarkg!,.a!for:'0ed,,by.the policies.. ;e the•4rmS, ;exct(., ditidns of such3 . i6sdescribedhereinIsSytijttoail t A'M '�' x L•I•' . U.T. OR12ED REPRE$a=lvT',A1"LV'tz'f EMPLOYER'S _I.IaBIt.I. �f ' IMIT TNCL'UbltN �'f1E i,49E% COSTSc 't+>r2 000;0Oq , l (3C i1RRENCE. EMbOR9EMENT 042065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 01/01/.01 IS' ATTACHED 0, AND 'FORMS A, PART OF. 'PHIS POLICY. .w. i ' '1 :: .. a? ,;ram �•,. `,�:,"A "?:a .`,. : •. .. - F^ $•6 .:<:. �r �",;All+`` ": '%.•:: 3,;". $USO CQi�liTR j a. 14700.''FIR'ESTONE. STE 103 LA M.1RADA CA 90638: A STOCK COMPANY — ESTABLISHED 1890 Ll ma a ffil ffl, r1l ru II on) (gym . r I HOME OFFICE O MARYLAND BALTIMORE BOND NO. 085 93 001 Faithful Performance Bond EXECUTED IN THREE (3) PARTS Public Work (The premium charged on this bond is $ 1,269.00 ,being at the rate of $ 10.00-1st $100,00.$er thousand of the contract price) $ 8.00—Remainder KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS, the CITY OF HUNTINGTON BEACH 2Gn 1 State of California, entered into a contract dated with BUSO CONSTRUCTORS, INC. hereinafter designated as toe "Principal," for the work described as follows: CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139 ) IN THE CITY OF HUNTINGTON BEACH, CA. (THIS BOND ALSO GUARANTEES THE WORK ACCEPT;and WHEREAS, the said .Principal is required under the terms of said contract to furnish•a bond for the faithful performance of said contract. Now, THEREFORE, We, the Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation orgainzed and existing under the laws of the State of Maryland, and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH ONE HUNDRED THIRTY TffREE THOUSAND, in the penal sum of SIX HIRMRF.1) TWENTY STX & NO/100ths--- Dollars ($133,626.00 ) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That, if the above bounden Principal, his or its heirs, ex- ecutors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the said contract and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the_ CITY OF HUNTINGTON BEACH its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, altera- tion or addition to the terms of the contract or to the work to be performed thereunder or the specifications accom- panying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to the specifications. IN WITNESS WHEREOF, We have hereunto set our hands and seals this 5th day of FEBRUARY 2001 BUSO CON C RS, INC. t turl:6y ry A.ttornoy BY: Principal FIDELITY AND DEPOSIT COMPANY OF MARYLAND BROWN ^—Attorney-it-ir,-Fact C31731CA-41M. Il.:e 22%S? CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 DATE before me, BARBARA J. BENDER, NOTARY PUBLIC NAArE, TITLE OF OFFICER • E.G.. *jmE DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN . NAAIE(S) OF SIGNERS) , ® personally known to me - to be the person) whose name((S) isARM subscribed to the within instrument and ac- knowledged to me that heAsb y executed the same in his/mac authorized capacitytkxx), and that by his/X*VAXW signature(N) on the instrument the personN), or the entity upon behalf of which the person(t) acted, executed the instrument, BARBARA J. BENDER i a Commission # 1267491 IT ESS my ha an 'o icial seal. Z ` Notary Public - Ca!ifomla y Cronge County My Comm.: x�,:^ss JAI 13, 2004 4P'. TUREOfNOTARY L OPTIONAL Though the data below Is not required by law, It may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(5) ❑ LIMITED ❑ GENERAL CCK ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIANJCONSERVATOR .. ❑ OTHER; SIGNER IS REPRESENTING: NA&A OF PERSONS) OR EWITY(IES) FSDELITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT PERFORMANCE BOND NO. 085 43 001 TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 2-5-01 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE No 5607 01993 NATIONAL NOTARY ASSOCIATION • 8236 Rommel Ave., P.O. Box 7184 a Canoga Park, CA 9i= -7164 A STOCK COMPANY - EBTABLIBHED 1800 5, i ro � ffli ff IT %117, 1 TO, I HOME OFFICE OF MARYL.AND BALTIMORE BOND NO. 085 43 001 Payment Bond EXECUTED IN THREE (3) PARTS Y (Section 3247, Civil Code) (Premium included in faithful performance bond) KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS....... CITY O.F..HUNTINGTON BEACH........................••••••.......................................................................... .... ............ ..... -....... •....................................................................................................................................................................................... has awarded to.....BUSO CONSTRUCTORS, INC. ••---...--•----- ----•- -•................ ......... ....---.....-•.....................................••-•-•----------••--.........---•--.............---------------•----.....-•-•-•---••••----•••-•-•-•----.................._...•--••--------•------- as Contractor, a contract for the work described as follows: ...........CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139) IN THE CITY OF HUNTINGTON BEACH, CA. .......---•...................................•-•-----...----------------...--••-•--••----•-•---.......................-•------••----------..........--•-•-•-----.............-----•---....---------•- ..................................................................................•-•-•-•-•-•--•-•---..................-•---......-•---...----•----•--......................................... ; AND WHEREAS, Said Contractor is required to furnish a bond in connection with said contract, to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law; NOW, THEREFORE, We the undersigned Contractor and Surety are held and firmly bound unto the CITY OF HUNTINGTON BEACH ..... _....... * *ONE HtJ1VD12>;� '1'Nt> 'I''Y 'Y'fIR THOUSAND; SIR' Am"NOV100t hs"-DO LARS in the amount required by law, the sum of..***..Se&.-above,...................................dollars for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That if said Contractor, his or its heirs, executors, administrators, successors or assigns, or subcontractors, shall fail to pay any of the persons named in Civil Code Section 3181, or amounts due under the Unemployment Insurance Act with respect to work or labor performed by any such claimant, that the surety or sureties herein will pay for the same in the amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In case suit is brought upon this bond, the said surety will pay a reasonable attorney's fee to be fixed by the court. This bond shall insure to the benefit of any of the persons named in Civil Code Section 3181 as to give a right of action to such persons or their assigns in any suit brought upon this bond. IN WITNESS WHEREOF, We have hereunto set our hands and seals this ........ --5th................... ,......................... day of..... FEBRUARY 2001 11US0..CON . .0 .. _ R .._..INC'............................................ BY...... ..................•------...---------...--•-•-•-•..._................. ................................................................................................ ..............................................................................................•- Contractor FIDELITY AND DEPOSIT P 1 M R D ..... .. ..... .... ................................................... ROWN Attorney -in -Fact csrnicA�2oo, ls�a �7l 0� M. Farnwly CAL31771 ®1 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER • E.G..'JANE DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN NAME(S) OF SIGNER(S) personally known to me - to be the persolo) whose name(q) is4M subscribed to the within instrument and ac- knowledged to me that hetlzy executed the same in his/mac authorized capacity$i=), and that by his/ = signature(N) on the instrument the person(t), or the entity upon behalf of which the ,+;�*.+�-- +� YR4yh•*u•_r person() acted, executed the instrument. ---- BARBARA J. BENDER ^� i J_� SS han d* cial seal. 11 Commission # 1267491 Z Notary Public California r Orange County a Ai('// My Comm. Expires Jul 13, 20Q4 ' Sr TURE of NOTARY �Y'R'W+MfidFi:L`+ss+i1+r•:Ywl6.i:dd.:li.+ii«acc •l .:-.Rrri+cw.w.._,:,;:: �:. OPTIONAL Though the data below Is not required by law, It may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL DESCRIPTION OF ATTACHED DOCUMENT s Iu101►Y :.� ►D ► / 1 : 11 TITLE OR TYPE OF DOCUMENT ONE (1) ATTORNEY -IN -FACT TRUSTEE(S) GUARDIAWCONSERVATOR OTHER: .2-5-01 SIGNER IS REPRESENTING: NAME OF PERSON 6) OR ENTiTY(IES) FIDELITY AND DEPOSIT COMPANY OF MARYLAND NUMBER OF PAGES DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE NO 6907 01993 NATIONAL NOTARY ASSOCIATION • 8238 Rommel Ave., P.O. Box 7184 • Canoga Park, CA 91309.7184 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE, MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen M. Brown of Anaheim, Californir t s rue an lawful agent and Attorney -in -Fact, to make, execute, seal and ver, for, anis behalf as surety, and as its act and deed: any and all bonds and undertakings.., ......�,.,, ,,,,,,,,,,,,,, e execution of such bonds or undertakings in pursuance amply, to all intents and purposes, as if they had been duly exec at its office in Baltimore, Md., in their own proper persons,( The said Assistant Secretary does hereby certify that 2, of the By -Laws of said Company, and is now in IN WITNESS WHEREOF, the said Vice -Preside Corporate Seal of the said FIDELITY AND DE �------------July A.D. 19-9-3 /1 ATTEST: Assistant STATE OF MARYLAND CotrvrY OF BALTIMORE 1 SS: 1 � 'be as binding upon said Company, as fully and by the regularly elected officers of the Company set foyake reverse side hereof is a true copy of Article VI, Section have hereunto subscribed their names and affixed the ND, this----22nd __-------___day of OF MARYLAND By— 0 Vice -Pr sidettt On this_22na ___day of _July_--�A.D. 1943._, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. 9 aueuc CAROL J. FADER w Notary Public � S My Commission Expires___—_ _ _ August 1 1996 CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the l6th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this 5th day of----- _2Q01 Assistant Secretary LI42& -012- 4 16 0 A STOCK COMPANY — ESTASLISHED 1090 . NO 1011 10 (�� i I (I)111 I) al 1 l�1r HOME OFFICE OF MARYLAND BALTIVORE BOND NO. 085 43 001 Faithful Performance Bond EXECUTED IN THREE (3) PARTS Public Work (The premium charged on this bond is $ 1,269.00 , being at the rate of $ 10.00-1st $100,000per thousand of the contract price) $ 8.00—Remainder KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS, the CITY OF HUNTINGTON BEACH 2001 State of California, entered into a contract dated with BUSO CONSTRUCTORS, INC. hereinafter designated as the "Principal," for the work described as follows: CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139 ) IN THE CITY OF HUNTINGTON BEACH, CA. (THIS BOND ALSO GUARANTEES THE WORK FOR A PERIOD OF ONE (1) YEAR AFTER THE CITY's ACCEPT ; and WHEREAS, the said .Principal is required under the terms of said contract to furnish -a bond for the faithful performance of said contract. Now, THEREFORE, We, the Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation orgainzed and existing under the laws of the State of Maryland, and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH ONE HUNDRED THIRTY , in the penal sum of STX HUNDRED TWENTY SIX & NO/100ths---Dollars ($133,626.00 ) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That, if the above bounden Principal, his or its heirs, ex- ecutors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the said contract and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the_ CITY OF HUNTINGTON BEACH its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, altera- tion or addition to the terms of the contract or to the work to be performed thereunder or the specifications accom- panying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to the specifications. IN WITNESS WHEREOF, We have hereunto set our hands and seals this 5th day of FEBRUARY 2001 BUSO CONST S, INC - x1'FtOl� sD AS TO I OFt ld GA11, 111U'PT0*1, BY: Ey: !)e i;i ty AttoTteo Principal �'�ty City Attornoy FIDELITY AND DEPOS OM NY OF MA AND B _ M. BROWN Atturney-in-Fact C3173(CM--4Ni, !i-W 22Wd? CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 DATE before me, BARBARA J. BENDER, NOTARY PUBLIC NAME. TITLE OF OFFICER - E.G.. -JAW E DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN NAME(S) OF SIGNER(S) ' personally known to me - to be the person*i) whose name(q) is4m subscribed to the within instrument and ac-. knowledged to me that hey executed the same in his/I: authorized capacity0m), and that by his/WrAUM signature(N) on the instrument the personN), or the entity upon behalf of which the person(t) acted, executed the instrument. BARBARA J. BENDER 1: Commission # 1267491 -� Notary Public - Ca;ifa-nia orange County s My Corrnn.,- d:. OPTIONAL TORE OF NOTARY Though the data below is not required by law, It may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER ❑ PARTNER(S) TITLE(S) ❑ LIMITED ❑ GENERAL = ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIANJCONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAYS OF PERSONS) OR EhIr Y(IES) FIDELITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT PERFORMANCE BOND NO. 085 43 001 ONE (1) 2-5-01 TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE No.5907 01993 NATIONAL NOTARY ASSOCIATION @ 8236 Rommel Ave., P.O. Box 7184 * Canoga Park, CA 91309.7164 A STOCK COMPANY —ESTABLISHED 1890 ' "At i I , "M141111"I,lp �; l HOME OFFICE OF MARYLAND BALTIMORE BOND NO. 085 43 001 EXECUTED IN THREE (3) PARTS Payment Bond (Section 3247, Civil Code) (Premium included in faithful performance bond) KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS ........ CITY__OF HUNTINGTON BEACH ------••----•----•-•--•............................................................................•-----.................................--... .....---.........-•--------------------••-•-•----•--•-•--.................................................----••---••-•-•---•--........-----••--••-•-•---.............---.....--••--................. has awarded to.....BUSO CONSTRUCTORS, INC.............................. ••---•--•---.....--• • ........ ...__.................................•----........---•--....-----••----••----.........---..............................----•--•-•-------......---•--•---..............-•---........------.......... as Contractor, a contract for the work described as follows: ----- _---- CONSTRUCTI................. N OF INTREPID LANE --••- ....... •................. STORM DRAIN (CC-1139) IN THE CITY OF HUNTINGTON BEACH, CA. ..---................•-•-...................................-•-------••-•---...........---•--.......----•----•---•---.....--•--•-----•--...................--•--.......................-----•...... .........................................................................................................................••----.....................----............---.........---......•-•---..... ; AND WHEREAS, Said Contractor is required to furnish a bond in connection with said contract, to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law; NOW, THEREFORE, We the undersigned Contractor and Surety are held and firmly bound unto the CITY.OF_ HUNTINGTON BEACH HiJNDRE�•'1�`Ht}�`I'Y-'I7�EE-THOIISAND..... SIX..HUNDRED..,PWENTY..STX..AM7•'[J(Y I til'ts"»OI;LAR in the amount required by law, the sum of..*.*.*..see.-above----------------------------------- dollars for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That if said Contractor, his or its heirs, executors, administrators, successors or assigns, or subcontractors, shall fail to pay any of the persons named in Civil Code Section 3181, or amounts due under the Unemployment Insurance Act with respect to work or labor performed by any such claimant, that the surety or sureties herein will pay for the same in the amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In case suit is brought upon this bond, the said surety will pay a reasonable attorney's fee to be fixed by the court. This bond shall insure to the benefit of any of the persons named in Civil Code Section 3181 as to give a right of action to such persons or their assigns in any suit brought upon this bond. IN WITNESS WHEREOF, We have hereunto set our hands and seals this...........5th......................I..................... day of..... FEBRUARY 2001 ---------------•-------------.---••• 13USQ..CON S1 C'........................................... BY....... .......... .......................•-----...........................---.....----•-••--•-••--•----•--....--•- ....--••--•........................•-•----•--...............................----................ Contractor FIDELITY AND DEPOSIT ND 0 Attorney -in -Fact 01771cA1-200. 1z-88 229471 M. Famaly CALJ177J CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G..'JANE DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN , NAMES) OF SIGNER(S) ' E2 personally known to me - to be the persortz) whose name(q) is/M subscribed to the within instrument and ac- knowledged to me that hekbsAkzy executed fir the same in his/authorized capacity0m), and that by hIs1ne0VW signature(N) on the instrument the person(), or the entity upon behalf of which the person(t) acted, executed the instrument. BA.R5ARA J. BENDER Commission 1# 1267491 IT ESS ha n ff' ial seal. -� Notary Public - Califomia Orange County My Comm. 50res Jul 13, 2 O4 f. SIdNATURE OF NOTARY OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form, CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL Ca ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAVE OF PER80N 61 OR ENM(*$) FIDELITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT /ul�l►Ya : • ►IB ► • • • TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 2-5-01 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE NO 5907 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 - Canoga Park, CA 91309.7164 Power of Attomey FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE, MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen M. Brown of Anaheim, California its rue and lawful agent and Attorney -in -Fact, to make, execute, seal and,,x�kver, for, anditts behalf as surety, and as its act and deed: any and all bonds and undertakings..........'� .. Affd-ffFe—e—x_e_cu_tI5n of such bonds or undertakings in pursuance amply, to all intents and purposes, as if they had been duly exec at its office in Baltimore, Md., in their own proper personslc The said Assistant Secretary does hereby certify that 2, of the By -Laws of said Company, and is now in IN WITNESS WHEREOF, the said Vice-Presid Corporate Seal of the said FIDELITY AND DE —_—__ Jul , A.D. 19� ATTEST: STATE OF MARYLAND COUNITY OF BALTIMORE be as binding upon said Company, as fully and by the regularly elected officers of the Company 1 v set foyElloirt}te reverse side hereof is a true copy of Article VI, Section have hereunto subscribed their names and affixed the vD, this _ _ 22nd--------day of ANY OF MARYLAND By Vice-N sident On this 22nd ___day of July _ A.D. 199-3—, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. CAROL J. FADER Notary Public My Commission CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate: and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this day of ------- FEBRUARY__—_ _ 2001 Assistant Secretary LI428c -012- 4 16 0 A STOCK COMPANY — ESTABLISHED 1800 =I - l EI 01 HOME OFFICE OF MARYLAND BAI-TIMORE BOND NO. 085 43 001 Faithful Performance Bond EXECUTED IN THREE (3) PARTS Public Work (The premium charged on this bond is $ 1,269.00 being at the rate of $ 10.0(J-1st $100,00i$er thousand of the contract price) $ 8.00—Remainder KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS, the CITY OF HUNTINGTON BEACH 2001 State of California, entered into a contract dated Feb 5. tq_ , with BUSO CONSTRUCTORS, INC. hereinafter designated as the "Principal," for the work described as follows: CONSTRUCTION OF INTREPID LANE STORM DRAIN (CC-1139) IN THE CITY OF HUNTINGTON BEACH, CA. (THIS BOND ALSO GUARANTEES THE WORK ACCE�) ;and WHEREAS, the said ,Principal is required under the terms of said contract to furnish•a bond for the faithful performance of said contract. Now, THEREFORE, We, the Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation orgainzed and existing under the laws of the State of Maryland, and duly authorized to transact business under the laws of the State of California, as Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH ONE HUNDRED THIRTY THREE TROUSAND, in the penal sum of SIX HIItMFn TWENTY SIX & NO/100ths---Dollars ($133,626.00 ) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS Sucii, That, if the above bounden Principal, his or its heirs, ex- ecutors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the said contract and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the_ CITY OF HUNTINGTON BEACH its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, altera- tion or addition to the terms of the contract or to the work to be performed thereunder or the specifications accom- panying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to the specifications. IN WITNESS WHEREOF, We have hereunto set our hands and seals this 5th day of FEBRUARY 2001 BUSO CONST ('f S , INC. BY: Principal FIDELITY AND DEPOSIT,00MY P LAND WEN M. BROWN Attorney -in -Fact 01721CA1-41%1. 1148 229-41 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER • E.O.,',IM1E DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN • NAME(S) OF SIGNER(S) ' ® personally known to me - to be the persorXx) whose name((s) is/M subscribed to the within instrument and ac- knowledged to me that hekblsr6ti ny executed the same in his/ authorized capacity0m), and that by his/XVVAWW signature(l) on the instrument the personN), or the entity upon behalf of which the person(t) acted, executed the instrument. OPTIONAL Though the data below is not required by law, It may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER ❑ PARTNER(S) TITLES) ❑ LIMITED ❑ GENERAL Ca ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAWCONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR EIITITY(IES) FIDELITY_AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT PERFORMANCE BOND NO. 085 43 001 ONE (1) TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES 2-5-01 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE No 5607 01993 NATIONAL NOTARY ASSOCIATION • 8236 Rommel Ave., P.O. Box 7184 9 Canoga Park, CA 91309.7164 A STOCK COMPANY - ESTABLISHED 1800 �1 .�: of "s-almi(I (!'. I(.1MOTU � n) I I I) ail t f HOME OFFICE O MARYLAN D SAI.TIMORE BOND NO. 085 43 001 EXECUTED IN THREE (3) PARTS Payment Bond (Section 3247, Civil Code) (Premium included in faithful performance bond) KNOW ALL MEN BY THESE PRESENTS: THAT, WHEREAS....... CITY OF..HUNTINGTON..BEACH .... ........................................ ----------------------------- -....................................................................................................................................................................... has awarded to.....BUSO CONSTRUCTORS, INC.. ......................•--......----......... ...... .............................................•-----...------•---------.....------....-•-------•----•---•---..............................................--•--•--....------..................-- as Contractor, a contract for the work described as follows: ........... CONSTRUCTION OF INTREPID LANE ............................................... STORM DRAIN (CC-1139) IN THE CITY OF HUNTINGTON BEACH, CA. ....._.......---•..............................••----•-••-----•--............................-•-•-•----....---...............................---•-••--•-••-------•------•--....................------ ..............................••---....................-•----.............---•--...........-•-•••---...........•--•----................_.....--••------••-•---.....-•------•--•-••---------........ ; AND WHEREAS, Said Contractor is required to furnish a bond in connection with said contract, to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law; NOW, THEREFORE, We the undersigned Contractor and Surety are held and firmly bound unto the CITY OF HUNTINGTON BEACH •----•--....•* * *ONE HUNDRED Tff R'' Y •TMnE THOUSAND-1 SIR H[JNDRED `PWENTY STX"'ANII'TTO IOflti�ts"�I;LARS in the amount required by law, the sum**..e�..av�......................:............dollars ($..a..r.6�?.00--), for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That if said Contractor, his or its heirs, executors, administrators, successors or assigns, or subcontractors, shall fail to pay any of the persons named in Civil Code Section 3181, or amounts due under the Unemployment Insurance Act with respect to work or labor performed by any such claimant, that the surety or sureties herein will pay for the same in the amount not exceeding the sum specified in this bond, otherwise the above obligation shall be void. In case suit is brought upon this bond, the said surety will pay a reasonable attorney's fee to be fixed by the court. This bond shall insure to the benefit of any of the persons named in Civil Code Section 3181 as to give a right of action to such persons or their assigns in any suit brought upon this bond. IN WITNESS WHEREOF, We have hereunto set our hands and seals this ............ 5th............................................. day of..... FEBRUARY 2001 ..................................... ........... BUSQ..CON C S C •............................... .......-- BY.:..---- --- ...... •-- ............................................................ ......----•-••------------------•-••--•--•--.........---•-••-•---.....................---------- ................................•----...------.................................---••--•--....... Contractor FIDELITY AND DEPOSIT OF M AND ... ... .... ...... .... .................................................... OWN A.lorne -in-Fact cai771c�►—zoo. 1s�a zr9an M. ' Formerly CAL3177J CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 2-5-01 before me, BARB'RA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G., 'JME DOE, NOTARY PUBLIC personally appeared OWEN M. BROWN NAME(S) OF SIGNER(S) ' ® personally known to me - to be the persor*) whose name(s) is4m subscribed to the within instrument and ac- knowledged to me that hekbzddM executed the same in his/ftobbadz authorized capacity$im), and that by hls/)WVAXM signature(g) on the instrument the personN), or the entity upon behalf of which the ` --�---,------.---_. _ personO acted, executed the instrument, BARBARA J. BENDER < COn' MLSSion -- 1267491 z NOfcay Pub lit; - Colifom)o ? `✓ /� �j �/� LI�/y MYCCM �mngeCounty 50--eS Jul 13, 2004 ,. SIC ATURE OF NOTARY OPTIONAL Though the data below Is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER ❑ PARTNER(S) TITLES) ❑ LIMITED ❑ GENERAL Ca ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAWCONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAtQ OF PEPWKS) OR ENM(IES) FIDEIIITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT ONE (1) TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES 2-5-01 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE No.6007 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 - Canoga Pent, CA 91309.7154 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE, MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen M. Brown of Anaheim, Californi, its rue and lawful agent and Attorney -in -Fact, to make, execute, seal andl4tkver, for, and h behalf as surety, and as its act and deed: any and all bonds and undertakings..........,'1.... .�.............. AnTER.- execution of such bonds or undertakings in pursuance amply, to all intents and purposes, as if they had been duly exec at its office in Baltimore, Md., in their own proper persons,` The said Assistant Secretary does hereby certify that 2, of the By -Laws of said Company, and is now in IN WITNESS WHEREOF, the said Vice-Presid Corporate Seal of the said FIDELITY AND DEPI July , A.D. 19_93 e ATTEST: . Assistant STATE OF MARYLAND COuN-ry OF BALTIMORE �' be as binding upon said Company, as fully and by the regularly elected officers of the Company set foyAoe reverse side hereof is a true copy of Article VI, Section have hereunto subscribed their names and affixed the VD, this_ — 22nd _-__-day of OF MARYLAND By Vice -Pr silent On this 22nd _day of July—_ ; A.D. 199-L, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. rueuc �. CAROL L FADER Notary Public My Commission CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto ubscribed my name and affixed the corporate seal of the said Company, this ____5th day of____ FEBRUARY _ 20�1 Assistant Secretary 1I42k -012- 4 160 CITY OF HUNTINGTON BE T. �NU5-!rA�)O/ MEETING DATE: January 16, 2001 DEPARTMENT ID NUMBER: PW 01-002 Council/Agency Meeting Held: Deferred/Continued to: Approved ❑ Conditi ally Approved El Denied - C ty CI rk's Signature Co ncil Meeting Date: January 16, 2001 Department ID Number: PW 01-002 CITY OF HUNTINGTON BEACH REQUEST FOR ACTION SUBMITTED TO: HONORABLE MAYOR AND CITY COUNCIL SUBMITTED BY: VPREPARED BY: SUBJECT: RAY SILVER CITY ADMINISTRATOR �R N C= f ROBERT F. BEARDSLEY, DIRECTOR OF PUBLIC WORK i I ACCEPT LOW BID FOR THE INTREPID LANE STORM DRAIN PROJECT, CC-1139. Statement of Issue, Funding Source, Recommended Action, Alternative Action(s), Analysis, Environmental Status, Attachments) Statement of Issue: Should the City Council accept the low bid for the construction of the Intrepid Lane Storm Drain Project, CC-1139? Funding Source: Funds in the amount of $116,950 were budgeted from the General Fund to the Capital Projects Fund Account, Intrepid Storm Drain, No. 30188006.69365. An additional $50,981 is available from the Unappropriated, Undesignated, General Fund Balance. Recommended Action: Motion to: 1. Approve the lowest responsive / responsible bid submitted by Buso Constructors, Inc. for the Intrepid Lane Storm Drain Project, CC-1139. 2. Authorize the Mayor and City Clerk to execute the Construction Contract in the amount of $133,626. 3. Authorize the Finance Director to appropriate $36,761 from the General Fund balance to the Intrepid Lane Storm Drain Account. 4. Authorize the Director of Public Works to expend a total of $153,711, to cover the contract amount of $133,626, estimated construction contingency of $13,366, and supplemental expenditures of $6,683. 01-002 jan 16 broussard -2- 1/5/01 3:24 PM REQUEST FOR ACTION MEETING DATE: January 16, 2001 DEPARTMENT ID NUMBER: PW 01-002 Alternative Action(s): Authorize the Director of Public Works to expend a total of $167,930, to cover the alternate Contract amount of $146,026 which includes Saturday as a mandatory workday, estimated construction contingency of $14,603, and supplemental expenditures of $7,301. This action would reduce the work schedule from 6 weeks to 5 weeks at a cost of $14,219. Authorize the Mayor and City Clerk to execute the Construction Contract in the amount of $146,026, the alternate bid to include Saturday as a mandatory work day. 2. Authorize the Finance Director to appropriate $50,981from the General Fund balance to the Intrepid Lane Storm Drain Account. 3. Deny award of the contract to Buso Constructors, Inc. and select one of the other responsive / responsible bidders. 4. Reject all 8 bids and direct staff on how to pursue project, i.e. 1) Wait a year or two and then rebid; 2) Cease all work on project and return funds to General Fund. Analysis: A new storm drain has been recommended by residents on Bayview Lane and City maintenance staff to correct odor and maintenance problems associated with the current system. The project was included on the City unfunded needs list and was funded in Fiscal Year 99/00. On November 6, 2000, the Council authorized the Director of Public Works to solicit bids, including an alternate bid to include Saturday as a mandatory workday, and approved the sample contract for the Intrepid Lane Storm Drain Project, CC-1139. Bids were received on December 5, 2000 and publicly opened by the City Clerk. The engineer's estimate was $100,415. A total of 8 bids were received and are summarized below by order of least dollar amount. Bidding Contractor Bid Amount 1. Buso Constructors, Inc. $133,626 2. 4-Con Engineering $137,520 3. KEC Engineering $153,705 4. Atlas -Allied, Inc. $173,592 5. R&L Sewer, Inc. $206,905 6. GMC Engineering, Inc. $260,000 7. GCI Construction, Inc. $273,279 8. Belczak & Sons, Inc. $329,800 Staff has checked the low bidder references and recommends award of the contract to Buso Constructors, Inc. 01-002 jan 16 broussard -3- 01/05/01 4:18 PM REQUEST FOR ACTION MEETING DATE: January 16, 2001 DEPARTMENT ID NUMBER: PW 01-002 Per Council action, a new appropriation must meet one of the following three criteria: 1) It is an unanticipated emergency, 2) It is required to implement labor negotiations, or 3) It is a new expense that is offset by related new revenues. This new appropriation meets criteria #1, an unanticipated emergency. Public Works Commission Review: On October 18, 2000, the Public Works Commission approved the staff recommendation to request that City Council authorize the Director of Public Works to request bids for the construction of the Intrepid Lane Storm Drain Project, CC-1139 by a vote of 5-0-2 (Commissioners Snyder and Johnson were absent). Environmental Status: This project is categorically exempt pursuant to Class 1, Section 15301 of CEQA. Attachment(s): RCA Author: Todd Broussard:jm, ext. 5247 01-002 Jan 16 broussard -4- 1/5/01 3:22 PM ATTACHMENT #1 LOCATION MAP N.T.S. ATTACHMENT #2 CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICA TION To: Ray Silver, City Administrator From: Clay Martin, Acting Director of Administrative Services Subject: FIS 2001-12 Accept Bid for the Intrepid Lane Storm Drain Project CC 1139 PW 01-002 Date: December 8, 2000 As required by Resolution 4832, this Fiscal Impact Statement has been prepared for "Accept Bid for the Intrepid Lane Storm Drain Project CC 1139 PW 01-002." If the City Council approves this request (additional appropriation required of $50,981), the estimated unappropriated, undesignated General Fund balance at September 30, 2001 will be reduced to $8,373,813. Clay k1aftin, Actin Director of Administrative Services Fund Balance - General Fund Adopted Budget Current Estimate Beginning Fund Balance 10/1/2000 (unaudited) $ 9,540,000 $ 9,540,000 Plus: Estimated Revenue 127,313,303 127,313,303 Less: Estimated Expenditures (127,313,303) (127,313,303) Pending/Approved FIS's: (1,115,207) Less: FIS 2001-12 - (50,980) Estimated 9/30/2001 Balance (with econmic reserve) $ 9,540,000 $ 8,373,813 ESTIMATED GENERAL FUND BALANCE - SEPTEMBER 30, 2001 $10,000,000 $990009000 $890009000 $790009000 $6,0009000 $6,000,000 ADOPTED BUDGET CURRENT ESTIMATE RCA ROUTING SHEET INITIATING DEPARTMENT: Public Works SUBJECT: Accept Bid for the Construction of the Intrepid Lane Storm Drain Project, CC-1139. COUNCIL MEETING DATE: January 16, 2001 RCA ATTACHMENTS STATUS Ordinance (w/exhibits & legislative draft if applicable) Not Applicable Resolution (w/exhibits & legislative draft if applicable) Not Applicable Tract Map, Location Map and/or other Exhibits Attached Contract/Agreement (w/exhibits if applicable) (Signed in full by the City Attorney) Not Applicable Subleases, Third Party Agreements, etc. (Approved as to form by City Attorney) Not Applicable Certificates of Insurance (Approved by the City Attorney) Not Applicable Financial Impact Statement (Unbudget, over $5,000) Attached Bonds (If applicable) Not Applicable Staff Report (If applicable) Not Applicable Commission, Board or Committee Report (If applicable) Not Applicable Findings/Conditions for Approval and/or Denial Not Applicable EXPLANATION FOR MISSING ATTACHMENTS EXPLANATION FOR RETURN OF ITEM: �A1�-.+� /wi4 T7� a!'�G JICO:I► I� � Q . GII"�� %L CITY OF HUNTINGTON BEACH REQUEST FOR LEGAL SERVICES Gail Hutton, City Attorney RLS No. Assn To Date i Date: Request made by: Telephone: Department: 2/09/01 David Verone 8471 Public Works INSTRUCTIONS: File request in the City Attorney's Office. Outline reasons for this request and state facts necessary for City Attorney to respond. Please attach all pertinent information and exhibits. TYPE OF LEGAL SERVICES REQUESTED: ❑ Ordinance ❑ Opinion ❑ Stop Notice ❑ Resolution ❑ Lease ® Bond ❑ Meeting ® Contract/Agreement ❑ Deed ❑ Court Appearance ® Insurance ❑ Other: Is Request for Preparation of Contract form attached? ❑ Yes ® No Are exhibits attached? ® Yes ❑ No If not for Council action, Unless otherwise specified herein, I consent to the disclosure of the If for City Council action, desired completion date: information contained)—Rthis RLS tddall memderso!,,t e,city cauncil.�_ " Agenda Deadline Council Meeting 2/16/01 Signature of Departmen Head COMMENTS: Routing: Please review and approve "As to Form" the following contract documents furnished by Buso Constructors, Inc., GCH . contractor for the I+Rtrapdi-Lane Storm Drain Project: CC 1139. PDA 1. Certificate of Insurance SIL 2. Payment Bond # 08543001 (3 COPIES) WSA ❑. 3. Performance Bond #08543001 ( 3 COPIES) ADL' 4. Agreement - for signature only( with attachment A) SF ❑:. JM ❑' 0: a REFERENCE R.L.S. # 2000-979 - a This Request for Legal Services has been assigned to attorney. , extension His/her secretaryis , .extension Notes: File Name:- Date Completed: WP No.: Shaded areas for City Attorney's Office use only. "-�, IN - , "% COPIES TO: Front Desk Engineer City Clerk INTREPID LANE STORM DRAIN INTREPID LANE, HUNTINGTON BEACH BID DATE: DEC. 5, @2:OOPM (Engineer's Estimate: $100,415.00) BID LIST BIDDER'S NAME RANK TOTAL BID AMOUNT 1. ATLAS -ALLIED $ I � 3 / 5 q 1 . , 2. BALCZAK & SONS $ 3 L ql not 3. BUSO CONSTRUCTION $ I �� 4. CODY ENGINEERING $ 5. DECON ENVIRONMENTAL, INC. $ 6. ELSER CONSTRUCTION $ 7. G.C.I. CONSTRUCTION $ 8. G.M.C. $ Z to) 000. 9. J.A. SALAZAR CONSTRUCTION $ 10. KEC ENGINEERING $ I J J 11. LONG BEACH IRON WORKS $ 12. MIKE PRLICH $ 13. PIPELINE EQUIPMENT $ 14. R. & L. SEWERS $ D I q 05, -- 15. SAVALA CONSTRUCTION $ 16. SO. CAL UNDERGROUND $ G\BID LIST w 17. STEVE CASADA $ 18. 4-CON ENGINEERING n $ 10, � 0 5zol 19. $ 20. $ G\BID LIST COPIES TO: Front Desk Engineer City Clerk INTREPID LANE STORM DRAIN INTREPID LANE, HUNTINGTON BEACH BID DATE: DEC. 5, @2:0013M (Engineer's Estimate: $100,415.00) BID LIST BIDDER'S NAME RANK TOTAL BID AMOUNT 1. ATLAS -ALLIED $ 1731,312 - 00 2. BALCZAK & SONS $ 3,21 800, 00 3. BUSO CONSTRUCTION $ [33) 6 26. 00 4. CODY ENGINEERING $ 5. DECON ENVIRONMENTAL, INC. $ 6. ELSER CONSTRUCTION $ 7. G.C.I. CONSTRUCTION -7 $ 27 7) 1 27 A. QQ 8. G.M.C. 6 $ 2;0) Mo . 00 9. J.A. SALAZAR CONSTRUCTION $ 10. KEC ENGINEERING 3 $ 15.00 11. LONG BEACH IRON WORKS $ 12. MIKE PRLICH $ 13. PIPELINE EQUIPMENT $ 14. R. & L. SEWERS $ 2d6 OQ 5. I 15. SAVALA CONSTRUCTION $ 16. SO. CAL UNDERGROUND $ G\BID LIST 17. STEVE CASADA $ 18. 4-CON ENGINEERING 19. $ 20. $ G\BID LIST zu L, CA Z060 Vo iNMBER: �� - A�IIOSL� PPO CITY OF HUNTINGTON BEACH '(_ Oo1�ISSAK � � MEETING DATE: November 6, 2000 DEPARTMENT ID PW 00-101 1 k /,\ Council/Agency Meeting Held: Deferred/Continued to: X Approved ❑ Conditio ally Approved Denied — N Jerk' Signature Council Meeting Date: November 6, 2000 Department ID ber: PV\F, 0-1 oil CITY OF HUNTINGTON BEACH REQUEST FOR ACTION SUBMITTED TO: HONORABLE MAYOR AND CITY COUNCIL SUBMITTED BY: �i )'PREPARED BY: SUBJECT: ,J RAY SILVER, CITY ADMINISTRATOR�s' ROBERT F. BEARDSLEY DIRECTORF O PUBLIC WOR f K� AUTHORIZE ADVERTISEMENT OF THE INTREPID LANE STORM DRAIN PROJECT, CC-1139. Statement of Issue, Funding Source, Recommended Action, Alternative Action(s), Analysis, Environmental Status, Attachments)1 Statement of Issue: Should the City Council authorize the Director of Public Works to request bids for the Intrepid Lane Storm Drain Project, CC-1139? Funding Source: Funds in the amount of $116,950 are budgeted in the General Fund, Capital Projects, Intrepid Storm Drain, Account No. 30188006.69365. Engineer's cost estimate is $100,415. Recommended Action: Motion to: 1. Approve the project plans and specifications and authorize the Director of Public Works to request bids for the Intrepid Lane Storm Drain Project, CC-1139. 2. Approve the attached Sample Contract subject to award of the contract to the lowest responsive/responsible bidder. Alternative Action(s): Forego approval at this time and direct staff on how to proceed with the project. / 0 RCA1139Bid.doc -2- 10/23/00 11:08 AM REQUEST FOR ACTION MEETING DATE: November 6, 2000 DEPARTMENT ID NUMBER: PW 00-101 Analysis: An existing "U" channel running parallel with Intrepid Lane collects runoff and provides drainage for the adjacent residential area, just south of Intrepid Lane. The "U" channel is located within the City right of way on the property side of an existing screen wall adjacent to Intrepid Lane. Due to the channel's shallow slope, debris washed into the "U" channel from one property tends to be deposited down the "U" channel along the adjacent property. This situation has resulted in blockage of the channel, which leads to odors and nuisance ponding. Because of its location relative to the street and wall, the "U" channel cannot be routinely maintained by traditional means such as street sweeping and must be cleaned by means of a vacuum truck. This project will modify the "U" channel and add drains in an effort to allow each property to drain onto itself. Public Works staff has prepared Contract Documents and Specifications for this project and now requires permission to advertise for bid. Public Works Commission Review: On October 18, 2000, the Public Works Commission approved the staff recommendation to request that City Council authorize the Director of Public Works to request bids for the construction of the Intrepid Lane Storm Drain Project, CC-1139 by a vote of 5-0-2 (Commissioners Snyder and Johnson were absent). Environmental Status: This project is categorically exempt pursuant to Class 1, Section 15301 of CEQA. Attachment(s): RCA Author: Todd Broussard:jm, ext. 5247 RCA1139B1d.doc -3- 10/24/00 4:46 PM ATTACHMENT #1 HUNTNGTON WMURK LOCATION MAP N. T. S. ATTACHMENT #2 SAMPLE CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND . FOR CONSTRUCTION OF INTREPID LANE STORM DRAIN IMPROVEMENTS (CC 1139) THIS AGREEMENT, made and entered into this day of 2000, by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and , a California hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as construction of Intrepid Lane storm drain improvements (CC-1139) in the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall furnish, at its own expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any description connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as -are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner jmp/k/agree/form/con-sam/10/18/00 1 " SAMPLE shown and described in this Agreement, and in accordance with the requirements of CITY under them for the compensation set forth in the accepted bid proposal. However the total compensation to be paid is to be computed on the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s). 2. ACCEPTANCE OF CONDITIONS OF WORK' PLANS AND SPECIFICATIONS. CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as hereinafter defined), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by said Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council of CITY, and any revisions, amendments or addenda thereto; D. The 2000 edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 3055 Overland Avenue, Los Angeles, CA 90034, and all amendments thereto, written and promulgated by the Southern California jmp/k/agree/form/con-sam/10/18/00 2 1 SAMPLE chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal (attached hereto as Exhibit "A"); F. The particular plans, specifications, special provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of discrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as "DPW"), without whose decision said discrepancy shall not be adjusted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in conflict herewith. 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed Dollars ($ ), as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after notice to proceed is issued and shall diligently prosecute PROJECT to completion jmp/k/agree/form/con-sam/10/18/00 3 1 SAMPLE within ) consecutive from the day the "Notice to Proceed" is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6 CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by the DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as the DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the written order of the DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by the DPW. jmp/k/agree/form/con-sam/l0/18/00 4 1 SAMPLE When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the effect of the change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS CONTRACTOR shall, prior to entering upon the performance of this Agreement, furnish the following three bonds approved by the City Attorney: One in the amount of one hundred percent of the contract price to guarantee the CONTRACTOR's faithful performance of the work; one in the amount of one hundred percent of the contract price to warrant such performance for a period of one (1) year after CITY's acceptance thereof; and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. 9. WARRANTIES The CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or imp/k/agree/form/con-sam/10/18/00 5 1 SAMPLE structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten- (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that the CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not and employee of CITY. CONTRACTOR shall secure at its expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of Dollars ($ ) per day for each and every working day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable losses CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. jmp/k/agree/form/con-sam/10/18/00 6 1 SAMPLE CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays or subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of final settlement of the Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of the DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed waiting for materials required by this Agreement to be furnished to CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days the CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of time for completion shall be the sole remedy of CONTRACTOR. jmp/k/agree/form/con-sam/10/18100 7 1 SAMPLE 12. DIFFERING SITE CONDITIONS (1) Notice: The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) Subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents; or (b) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. The DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly; (2) Time Extension: No claim of the CONTRACTOR under this Section shall be allowed unless the CONTRACTOR has given the notice required hereunder, provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to the CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this section. The DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in jmp/k/agree/form/con-sam/10/18/00 8 1SAMPLE price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, the DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its judgment the findings warrant. 14. PROGRESS PAYMENTS Each month the DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY and the remainder, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of the DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if the DPW finds that satisfactory progress has been and is being made, the CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined by DPW, less all previous payments and less all previous retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as a acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit jmp/k/agree/form/con-sam/10/18/00 9 1SAMPLE therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with the DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PROJECT for either labor or material, except certain items, if any, to be set forth in an affidavit covering disputed claims, or items in connection with Notices to Withhold which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold and save harmless CITY, its officers, and employees against any and all liability, claims, judgments, costs and demands, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, and subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence except where caused by the active negligence, sole negligence, or willful misconduct of CITY. CONTRACTOR will conduct all defense at its sole cost and expense. jmp/k/agree/form/con-sam/10/18/00 10 1 SAMPLE 19. WORKERS' COMPENSATION INSURANCE Pursuant to California Labor Code section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of said Code, which requires every employer to be insured against liability for workers' compensation;. CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall maintain workers' compensation insurance in an amount of not less than One Hundred Thousand Dollars ($100,000) bodily injury by accident, each occurrence, One Hundred Thousand Dollars ($100,000) bodily injury by disease, each employee, Two Hundred Fifty Thousand Dollars ($250,000) bodily injury by disease, policy limit. CONTRACTOR shall require all subcontractors to provide such workers' compensation insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 20. INSURANCE In addition to the workers' compensation insurance and CONTRACTOR's covenant to indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. Said policy shall indemnify CONTRACTOR, its officers, agents and employees, while acting within the scope of their duties, against any and all claims of arising out of or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of $1,000,000 per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than $1,000,000. Said policy shall name CITY, its officers, and employees as Additional Insureds, and shall specifically provide that any other insurance coverage which may be jmp/k/agree/form/con-sam/10/18/00 11 1SAMPLE applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary. Under no circumstances shall said above -mentioned insurance contain a self -insured retention, or a "deductible" or any other similar form of limitation on the required coverage. 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; said certificates shall: provide the name and policy number of each carrier and policy; 2. shall state that the policy is currently in force; 3. shall promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY; and 4. shall state as follows: "The above -detailed coverage is not subject to any deductible or self -insured retention, or any other form of similar -type limitation." CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under the Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all said policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. A separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming the CITY, its officers and employees as Additional Insureds shall be provided to the City Attorney for approval prior to any payment hereunder. imp/k/agree/form/con-sam/10/18/00 12 1 SAMPLE 22. DEFAULT AND TERMINATION If CONTRACTOR fails or refused to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the contract documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. 23. DISPOSITION OF PLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 24. NON -ASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety 25. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of California Government Code sections 1090 et seq. jmp/k/agree/form/con-sam/10/18/00 13 1 SAMPLE 26. STOP NOTICES; RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. Said obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100) for every Stop Notice filed in excess of two, regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 27. NOTICES All notices required or permitted hereunder shall be delivered in person or by registered or certified mail to an authorized representative of the party to whom delivery is to be made, at the place of business of such party, or to any other place designated in writing by such party. 28. CAPTIONS Captions of the section of this Agreement are for convenience and reference only, and the words contained therein shall in no way be held to explain, modify, amplify or aid in the interpretation, construction or meaning of the provisions of this Agreement. 29. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of U.S.C. Section 1324a regarding employment verification. 30. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to jmp/k/agree/form/con-sam/10/18/00 14 1 SAMPLE Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 31. ATTORNEY'S FEES In the event suit is brought by either party to enforce the terms and provisions of this agreement or to secure the performance hereof, each party shall bear its own attorney's fees. 32. ENTIRETY The foregoing, and Exhibit "A," attached hereto, set forth the entire Agreement between the parties. IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized offices the day, month and year first above written. CONTRACTOR By: print name ITS: (circle one) Chairman/President/Vice President AND By: print name ITS: (circle one) Secretary/Chief Financial Officer/Asst. Secretary - Treasurer REVIEWED AND APPROVED: City Administrator CITY OF HUNTINGTON BEACH, a municipal corporation of the State of California Mayor ATTEST: City Clerk APPROVED AS TO FORM: ooCity Attorney D AND APP, OVED: Director of Public Works jmp/k/agree/form/con-sa m/l 0/ 18/00 15 SAMPLE RCA ROUTING SHEET INITIATING DEPARTMENT: Public Works SUBJECT: Authorize Advertisement for the construction of the Intrepid Lane Storm Drain Project, CC-1139. COUNCIL MEETING DATE: November 6, 2000 RCA ATTACHMENTS = STATUS Ordinance (w/exhibits & legislative draft if applicable) Not Applicable Resolution (w/exhibits & legislative draft if applicable) Not Applicable Tract Map, Location Map and/or other Exhibits Attached Contract/Agreement (w/exhibits if applicable) (Signed in full by the City Attorney) Attached Subleases, Third Party Agreements, etc. (Approved as to form by City Attorney) Not Applicable Certificates of Insurance (Approved by the City Attorney) Not Applicable Financial Impact Statement (Unbudget, over $5,000) Not Applicable Bonds (If applicable) Not Applicable Staff Report (If applicable) Not Applicable Commission, Board or Committee Report (If applicable) Not Applicable Findings/Conditions for Approval and/or Denial Not Applicable EXPLANATION FOR MISSING ATTACHMENTS REVIEWED RETURNED W: 'FORWARDED, Administrative Staff u ( ) (" ) Assistant City Administrator (Initial) ( ) ( ) City Administrator (Initial) ( ) ( a4V ) City Clerk ( ) EXPLANATION FOR RETURN OF ITEM: SECTION A NOTICE INVITING SEALED BIDS for the INTREPID LANE STORM DRAIN CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated project and will receive such bids in the office of the City Cleric, Second Floor, 2000 Main Street, Huntington Beach, California 92648, up to the hour of 2:00 P.M. on DECEMBER 5, 2000. Bids will be publicly opened in Room B-6, Lower Level of City Hall unless otherwise posted. Copies of the Plans, Specifications, and contract documents are available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $15.00 nonrefundable fee if picked up, or payment of a $25.00 nonrefundable fee if mailed. Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders. A-1 The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount not less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State Contractor's License of the appropriate Class at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. The AGENCY reserves the right to reject any or all bids, to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH, CALIFORNIA, the 6TH day of NOVEMBER 20.00. Attest: Connie Brockway CITY CLERK OF THE CITY OF HUNTINGTON BEACH A-2 PROOF OF PUBLICATION STATE OF CALIFORNIA) ) SS. County of Orange ) 1 am a Citizen of the United States and a resident of the County aforesaid; I am over the age of eighteen years, and not a party to or interested in the below entitled matter. I am a principal clerk of the HUNTINGTON BEACH INDEPENDENT, a newspaper of general circulation, printed and published in..the City of Huntington Beach, County of Orange, State of California, and that attached Notice is a true and complete copy as was printed and published in the Huntington Beach and Fountain Valley issues of said newspaper to wit the issue(s) of: November 16, 2000 November 23, 2000 November 30, 2000 I declare, under penalty of perjury, that the foregoing is true and correct. Executed on November 30 20o0 at Costa Mesa, California. �r i i fSignature NOTICE INVITING SEALED BIDS - for the INTREPID LANE STORM DRAIN CASH CONTRACT No. 1139 In the CITY OF HUNTINGTON BEACH PUBLIC NOTICE- IS HEREBY GIVEN that the CITY OF HUNT- INGTON BEACH, as, AGENCY, invites sealed bids for the above stated project and will receive ! such bids in the office of the City Clerk, :Second Floor, 2000 Main Street, Huntington Beach, Cali- fornia 02648, up to the hour of 2:00 P.M. on DECEMBER 5, 2000.- Bids will be publicly opened- in. Room- B-6, Lower Levey of City Hall, unless otherwise posted. Copies of the plans, Specifications, and con' I tract documents are!, available from the Office, of the Director of Public! Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $15.00 nonrefundable fee if picked up, or payment of a $25.00 nonrefundable fee if mailed. Any contract entered into pursuant to this no - lice will incorporate the trovisions of the State abor Code. Pursuant to the provisions of the La- bor Code of the State of California; the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those de- termined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA- 92648. The AGENCY will -de- duct a 10% retention from all progress pay- ments. The Contractor may substitute an escrow holder surety of equal value to the n ten- tion , in accordance with the provisions of the Cal- ifornia Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive Warty terest thereon. AGENCY hereby affirmatively , ensures that minority "business enterprises will be af- forded full opportunity to submit bids in response to this notice and will not be discriminated against, on the —basis of race, color, national origin, ancestry, sex, or reNgxrn in any consideration spading to the award of No bid shail be con- sidered unless it is prepared on the ap proved Proposal forms In conformance with the Instructions to Bidders. The bid must be ac- oompanied by a certified check, cashier's check, or bidder's bond made re to the AGENCY Vanamount not less than 10% of the amount bid. The successful bid - Ow, shah tie licensed In accordance with provisions of the Busi- ness and Professions Code and shall possess a State Contractor's License of the ap- propriate Class at the time of the bid opening. The successful Contrac- tor and his subcon- tractors will be required,' to possess business licenses from the AGENCY. The AGENCY re- serves the right to reject any or all bids, to waive any irregularity and to. take all bids under advisement for a maximum period of 60 days.• BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON ,BEACH;--CALIFORNIA, the. 6Ti_ day_ _ of_ NOV- EMBER 2000. Attest: Connie Brockway CITY CLERK OF THE CITY OF HUNTINGTON 'BEACH PubAretied Huntington Beach -Fountain Valley Independent November 16, 2% 30, 2000 113-161 - - � . i. ... - V"�r'�-- _ � .. -k. - .- - -y . �,4.. Q -- - - --- - - -- .- - , , _.. , "I' ,-M.�", ,-,-��,,-�.�"..'.�-!�,--.'.--.---��,- if_... — _1 i, :. , . . - -�.'�`.?' "f!. - go �-;��-.-._. ... -;v- � -7 r.j:c- -.-_.��-_',� -.-.j`L,--..-5 :.,... , - �., -�- ��" ;-::. . - "..i _6 .i , , ".. . .. . . , ,- ..:4 ". .. !_ - � -, . . . . , .. , .�.7 . . .� .,..,. - . . . . . , W�,. �_ � "', . . . _... � ... . _ . ..., . ..: . . ;0 - .11,; , . V.',�. ,p:j-,t. - , . " . .. ........ �. . , . _, -, , �. v.: --- -. ,; ; , - -., .- - . - . .. - __ ... ---.. . .. ... - . ., . �- " :. ., � , , Z.r, , " - i'X�., . - .., - .1.. i ,.-l-.- .i....,; .... .. w- I ,iii. - 'I" ,•" , . , .7� , - .. .. . . . I � 1'� 4 - �;- .. '.. "..., "��.i, :.-..i.;'-'. ; L.�.!;.:Z,'. � , " " e_ . � - !� 7 . .. . v. �,2 &,� ,-,..,11_.__, .-. ! :7 .`n :L,�'-.� -,�!��;.--. ,- . c —, 7 . ..� i . ;., - - ` .. ...... -.-�-..y�.:-v -.'4.!a..i:. ..'..�.; :..!..; ii, -�'_:i;. ,..'�,�-.4. ...'; � .m ,I . ��!:- �-i.. � ve,, " .:...-z I.."...-.... ._.... ��-4'�.'..,.'..-,�.--i-�'..'tt.n,�,.,'.-'i.,"�",;,. . '75a. . .. _. .._... :, i - .7 ' . . . , , . . . . . . - - . - ,- - _. .. .1 . .. - - . . . '. . - . . : .. . . � ii . , . - . , . 1. - , - . :.ri.� , , ,2 ... . .... il . � ,:1.f%.;;.4, x.-. � �'. . :� ,:!,�o. `,.��..` :.41'-� i j , �.�.: ,. ... . - I -��. . . , ,,- :, - .; . . . .: I - '!� .- .1 - '... ,t ,.,� ':,'-Zi: .i.. n , � I.., . a -..-.,.; " 1 ,� z7 r-, " r. .,V, ,tvj�;� " ��....-; _�. 1-:1.1i., . . . . . %_. . ,.� . ,� �. . ', . I i ;; , " , , '. . , -, ; : , : - .; . � . 4. : - a ; '. , , . t . ,% �. - . . ... ; , I, - . , , ,.--A- '. . . '. . _.. . . . -.,.��.',��.-"k.,.�'�.-. : , " .. . i N �z. . . - , 1i _. . . .? . . . . . . . . _. . , - '- :!,.! ., . P-!!k .. M .:_ .'�. -_'. &M. " !..� � , - � 4F.V , �cX..,.�i;W.--_ . - - %--,,!,' 'r.-,� !:. , - � I . i �-_.;�i:, �- .;,' �.; f i. ,� w; - :. - . , , -j. . , . , y w4r. ..,.- 5.miY;.;�,,.`,Vfi ,..,,'I , ".."` .-`;:z ". -�,.,�_. :.,� .-" , 1. . �. " I . 7� , %! " v i,---;,i_".,o�,A� 'C%.-' ,--,�. . � .. , .� .... - ,..;i ,,zli, 11:. I .--I. , ` -i - i� ..:ii � ...,.,�, :-? 4 .. . -1, '; ". '. - -5, t, �km-t _,,�, ,.- 'tY:. .." .,.. -,...��;� _..�-.,;-..... - . Xz.'�. ';,,' , '".. .. � .: -� - - y w 1� �.#Au! 4 , ;:`�- :'_� : - , , , - .1 . . .. . �4 42 .., - !�-, -, - I - . - , , .1 . . .. ..... '.; - .,z . !": ` - .,-.'..1�: .. I , I p �: .. :. , _�.:ii ;...; ...... -j: - :,:. .! . , - - - - . ::.: -S. .- �', 11..'t .. :.- '�.: 4-�, .., I - z: . ..�, - - ..c ,. , - , ,. ,:..! ,. ,:..! . A�121�`N�ItA�, ,��: � �- : -, " ! , ,�.r, ,;' ; �. '�: _.;�:�.; , -.� - ., - �` 4C k-_�� . - , .:. . ,... _� .. 4 � "t I V E ; _;, : -4-. � " " - ; '. 'i. ��:, . - . o" . . . . � . � . . ;Y.._"_ i!_,;i;4. . f-.�t: , :2 -.,� ...., . I �, ail - "t . . b . . F. r� . - � 1� . , . ,:, . - , � i. , . )-'�.- ., i, 7 , -.,., ". ". I , - -c-,, . . . . - . . i , ; ..� .. , � � I ...... ;p - - i: ...'�� i,.�z � . ... , . . . I .. - , - 7 - - _,:_�,_ _ _..;... .- � . , ". -4;!-,r- '. , - -.' ,- , � - � ,�; � ; -Z, ;-,-" - i�. . , , - " , 7., :-.,:� % - . .. 4 . ..'. � " 0i :., . � - 1. :.... - ; . .. .. . :�i, ;, .. . I � � . : , ,� _,� A .,'..�� .. , . - , LERK-�: �,.%��.-,'.?�. . '. - -, . .. . i;, � --,,i�:.,.,�c,,�.�'�- U "....". ...-- � 11 't. -.'.. '. - . . ;1; , ... - . I-v _' — i ,;1.1' - ... ; ., ..._ . _;" . . ;d". �i,, , - — C, �:. .,t f ."... , . �, " f, me . - �. .t..14...�. L.";, . . ., � I �, L .... ". r .,-,�,',.�`if ,�!,;.�?'.. ;__ . .. � " . .. - - v,. '-.-. I � "'. , ,�,., . A ",., `� . " . . I-'.. 1� 1��; � - " 1; - � , , ;."; .. - W-r,q��i�`,.`�i�,-`: : ...i.. � ,�lz-�,�; jf.�� :-'�S. - �! �- ".; ;7., �. - - . ,; - ... mw .! .. _.. . , ..� , . , . � � ta. .- , - . . , , �. I i ...i ' . - - . '.. , i. "'.. , :..7;,-:�l,.-,.k,-"!,!..'.�:,4.:r, . - . .1 . - . I . . ! .r . -.- , __' �.:.- , , :.. ,,;... 1.1 :. - - . . . - - ,',;'� 7,.�,-t:; -- -1..". " - , , , m.,:,`:_'�� :_ �!.:..,!.,.-....._' 2"... ;,.,.,: �-- T. U "' -� . .. . . , . - , . V, i �-;��'.-__-. :.! .: .. % - .. ;-��f. .._7 , ! . . ..... I ,.Li�.� -,;..7�1 , - . � �, z - .. . . - . . . � t. , , a�r,,- ;; L _r ,t. . ..., 4 - , , .'i- �-.--t:� :� - - I . 'I.s. , � - '.� & - , . .. " .%�-ejg,x�,, kLqiei;',_��.�%� ..,-.' �. ;;. , , .. - , .. . .1 . tO.1; . L " I , � IV I I ., L 1_� IF .!." . I .� . A" .; . - 4 - : -; - .1. U. t.. ;. -,..-.:.., - � , ;. 1. .. ; q- j;, : , ., , , . � - - - . �.. - 1. i...`K;��""; .. .1— i.., -,. - ..", ,.,!.. �_. .: .. . . . I . .1. - �.-4r. il,z t:A - w, . 1..�.,. . ..',:.; - . ., . .- , �,. 1, . , '. � '...", , - ; -, ;11�il�,;%�'. -, -.'� . _." ,,, . . . , .. " i ..;. , -i ., , � 1_ L 'I.: � ... . ;I .1. .. . . - . . � . . ` � " - i j!�.._:.!, j . �..J,iu 1-1 - , ." , 1 . . - " c l-, . IN-- .. - . �. . .. . �..;.- ,"LZ`.`.` ',- e 111.:il ., : �"� � 5 � � - r'�., '-,.'; " -, A: ; " I -) L _.; 3k "": .�. ..i i�:*a N V .., e,m �_ - I - .1 - 1, :' , -,�;- -I, , '4' " " , , , �� - . .. : `., .- :. ,-.�.:�-:::!...'- - 1 . I.: ; u.!�. , 'j j . .. .��, ., - . ..., .. " .. . ...... . ...zi..%, ... - . . - m . . � `,• In , , , .. 1, : .. - � .. I; - - I.. - . - � ..-. I .. . . . � , . It .�A_<.R1L.V'2r1111KY:;d_1 N&`_.j,_ 7� .,� ..._� , .. ., Q; ��&��p;-y,:;- ... - . . � -:. .. �.4 .l.", - . " ., _. . z , . � . - , ;� ,,, 1 f, ;-i � z 6ft; , - - .. , , �- 4 .-Il".0 . Vz.,z .,��., . , . . � . ...... 1 , . . . - .; U. ...'b." 1: ,,�i 7, 2 . ... - . , �? - ..-..- . It .".) . ,�t . . .: � - .;... '. :: �_ - -� rn�; . . . . `;.�..; . . ... . . , . . _..� ", , ;--A ,". -'... i;_. � . �.. : .. . .. . .... .� -, ... I ..;,. .. .1.; _ - - - iv;. i .1 , . r . . .-,, ! .. �' , 1 . ,1 . .....'... . 1--iii I � I ,,, " �,'. , , _� 1 A. . I -m - .'.. .. . i .�411; , ., --6:,,� .- ... _-.1.: . - , I I . . : .�. . - - � � - ,". I., . . .. V%xxu . I 1'� 11 , . � r--,- , �� - .... 0: ,.,.., - ,� ;Z,". ". "I . - �V�-.r.,� I..., __ , dt� " , , -- 11 - - - ... '. iNO�-".`.!.. I....", -i.. ..,'�� ..�,.i., , " - - t`.--_-_t..-,._ - ,.: , . " '. ; :: .-'.....-'.' :*. �"_' 1�';.-,,.L.,� .!;i,C,-`!4 :-.','.. i "'..".. _ . _�. . , - 9 , .. I- .., I-, '?, -,;,... -- - �� -, . `4:!... !.1 !.,. . . ., , ..;; .� . .i�.-� ov,-,;t;§Z� t` ii - - ..- On, - ;'� n .q'.j".1 - ;p , 'ir -" " ; �,.%.-.im;�; . .. i� . - � .. � � - ;.1 ." _', �".-,',r."'-_� - n,.,. � .. , . ., i; .; . ! 1 : � 1: .. - ,.; , - .." "."o, - L �. * -. 4 G_,;.� -� "..'r, � N-,_�, , .. ,." , � � -...,.:4 L . , ?. . . . - .. .. .. g i - k .: �_I;� -� i 4t,L !';.;'i f:" :i , , , t ,,, :,�L t �.� , I- 1, R...'N . , i -i �..`:_ kA ;.'_;_.`P.�i. . --,-;,- �, , .. I " * ,V, ..." , .. . . , ..I _`�,__41., j,";1�.I.;--7. ";.. _� , - i'-,.'- - . -, . �.��:,4"4,.,.�.-;!,, .:�7;.. _; .�;-.., .�','..-a.;� 3: , . 2., -..�. _,,�ii4', � i:4 �! . . I , " .. � - t,.C:';,:- , , ... - .. . - - . - fm-,..;;.',j�:,- - .- 'rt:,;--n: - `�:,��,'-�,.- -.; ..;' I , . - .,,;-� ,;t- .,... - I t . . `�..,!,Rzll � . ., " . �1 , .... % , - ., - .41 ,,,�S�l � I j. .. -_,.;,A, - ---, _:.,V�� ','�'.�. lb.-..4, -1511 .t _� � _.,_.p. i_.;!,!1.-..,..� ... _-,;-,� .. , N . M N. , . , �',':.:. �'i ", �tii-!f��v,�AE T.S,,-Vi, -.?.�V.,; "'."., ..�. � .1-.;_��,:- .� m ..I I allm ..,-� - 'j� -f, 1, , ...: - '.�,%.w " �', �.' �, . � .ij;!,.-. , - -- ; .,;':i.' , ;� N ."'. i�i..-,:.,i`.`.�-' - . .. " , ..".. , - -, r i!,.i'� . 1�!,.,-.;, ;�.'� :, -i �,,.' , 1, , '. . " , � . I -.;.. . , �!,.,. I I'll., i: .- . ..... .,�....�.,.�'..',�;��,.'�-.1"".il."�.,4�!-.��,.,�-.�f��t-, I . - 1 - •1 - W .. � �M�11' _., ., ... � I __ - A . . . . . . 4 !s ;- ;." ";...,:-.,.,.,. "... " . , , .. ..". I , %.,.- L;;� �; , - - - . .:, ".. � - , - - . t: i,., e .. iia-z:- - -, '. Z.,-5- ,, ,. �.�. ;` - ..,... .. ,v'� , - _.T.'.....".Z., . Jr� � ....3". -, - 1 I. r"'. ..., .., .... d." --- - - " I I... 1.1 . ... ... �:,j r - , .- I.. ...... ......, ..j5 �, � � . : , , - ,..' , - , .. , �. _. ', , :� . .7'.", �'k . . . ? , -v. - - � - .'O .*m�L�_.. �. - ,.;. ... 1 � - . ;� ... .. . .._...'.:.. , �: - _4-,� A;-'.'--,.,%... � I L . . �. � ;- -!�, .._.':-.,f �`�;, , , , , ,f. ,?, _� ,.� .11i'd, .,.";,"�..�;a.'�.-..,-.,.'.�,.�.,..:, �_�- � , . t_ ... �� ;.P,'V�,_ �, .... 11 . .. - � - . .14 _-t w.... .� .-I . -..m . J�,-t.-,--,%�, - - - .. . I , j,;�,�7. , " �` , - '9 , . _-M -� '.t, , . - - V, .: - - - i;�'�,,�%-_ � .�,Iyt��: O.: �_ . - I...'-- -- - , ..' , - ;� - -";.�-,, -:, . '. . .�,.JiaN.,`,47-1,p �.,,,::.�i;ln""-I".",�!,%;,. .;::�,`, . - . . - , - - .." - 4c, � I: . - 4; �-C.'-,, P",�:�,' Al�..".'*,., -"`i;W ,��. ., _� � , I .1� - . -, .c � .. ... .., � �vj.,._,�Y,.-�' ",:i!� - .-Yfz��,�,-,.�%!-,. ... .. . J:�i - � . . - , - i _,1.L ... 6 ; . �. ... ;T - - :. , - 4- , � . " � - ,�,ii ! 4 1. �`-,i�m �:n 1.,; ,�;. IF.',�:.::r,.-',,,�.-.,��.r.*.,.�y..'��,��;,�..L,t,I -.---- - - A. .,-,5-' , �y-�-.i�I �, . � � -. - . .. :',,-� . : '2 5, �, - . . . . .. . .. - � I .�, 11 L, t, , , — , �, T .1. .1.. tw Q." :. ; , ..0 011 , ;F �, ;!.... .J!'- ;� ;.,,..,",,."1:7,....�-j..,,. 114�1,1001 ,11........;p.1 - .- -0- " nii. - " ", 1,4� �i�.,�- - - - - � . - - . - -;..;.L. . - _ . .� r7\ - .. , I . 1 - � .'Q `� - V. - " .�-�-w ..!. � , I ." tk:. d� 11. ". .7 ...... " . I .1 _- L " . . : - ,�� , '�""',Z.`i�',. •K.%' .. E__1_;_1.w; �-i-;4'.;�,,; " , -- . - .,:,cm ,::�-,�_-, - " . . - 2 �N,. _. r --f.-. ".. " , . ,- � ,% -4 , , :., '..14��N . . ,.,-, !.,, -'.., z .`,.-"�: ','.,'77 --,,`,��.!c,:k ;�, ';�.- V 7�1, -.'�, ! 1 "I.., , , -, - - -..,- .. � ..,.. ..'L' r i . , - . . ... - , , ` , , , ��; ...'. �,.,..-_� - ,;.t �;' i ..,�. .- - ,� , ,�*- �`, S.- ... .. . � . , 7;�i!' ",:� :. ii" -�i .. : - - - . . I . . . . . . -�.Y;"-".7.f��-�,.-,��,�.".,4--.��'.-. , - ". ,?.. 1 : . �-71, .. -_, '. - , - �r, i" -.4. -, -,F i.,', . .;",. . " t ; g ,;" •" ,�, . . J , �,,, '. !,� �; .". ..,-�'? v ", , -1, - f, . �,, %-Z� -7; '� ,; ; ....... "I'll, �, . . i i . , ", 7;�i�', :�, I cil;,. ✓. ..',' , '.�.i,' . U. , . a,- ... , � :-1:�Xi, �:-�� - 1., - .'� ` � z., -L. .., �� ,_,,;� """; jjr'�- �---V,.L�1, ,;:"!."�w_��;-�_U.*;�',. iy N � r ,�"4 % -,,�;n ,;.""A : ... ... �:.;if.i.�.'."%..: �4 � �,� �_-...,;-p ; A Ljl ,'?�. i',?% �.�'�i�*,� ��,,..�. - .!;" . � f�T;�-,-,_-.�k,�, 012;, -,;-'�'. ; "' , .- , .- .- i,r_,!,.j-5-m'�1'j-,' .�i,A 4;. , -,-�.,;�� !":,"..".�. --, . , .y ��r.:�-; ..;..!.v . i..,.'-; . "..:- , ;.1-,F �Q-;;. .!�.% Z _,'z, . . �. .. . ... .. . - -' - - -.1--r,2 11 ..... � , .. ,f,v .._N: "�.'Li;�,I�;-�- . '�V., - . ..z . ., .. . . �,,. • " - _!�' ` _�..:"j�4.i - - , .. W: - �'.. ,,�,, �-,.,�--.T.A -"-.i�..,_;,;K , , '!� .�, � . _ . .. ii. � �-' " .,.,_....!f,.,I��l;.".,;��,'�;.� I " 1 21; IV, L . - % 4, _, � _ " '. -,;. , 41,f5;,?1'' , ,!, )�, ., Tr�'x il�l 1, .. il�, - - - -.,'. -C , ,.;;! ..;,,,.�11 �-;, "I I v I -A`11; , k! - 5. 7. - .... L. '. ..... I .- .. W.h ., _. . "- - ,;-�.; :�!_,.";,-i, .. ... .. .- .. . . . ,;. - . I-, -vC:;�; . -...... !L" 1 ..5 , ? ' i'_Im �1' ��' 0 Yor,�'L.L.- �.,,.,.r�%.!!;�,.�,,� Z,%-',��'.".��'.�.:7.,4.--'.'i�!', " O -- , , �i4i.L..,.�_!-� �,.;,.,.-,,,��.i.'I',��",�..�..,P,.'Pi.'..-..�� ....... t� " ) �i-, :-� , ;�� -�' ,.n ii��. _1� ,17, .,*;zs'1.Z,.,1A, � ".. ... F.. �;'.',;Y •.. :.,_�.;;�',,,� ;"..;�.Fj�;�,tl..'�, . i., _trl, . �Z.lj '.. � c"r ,�: k -,.?0,'.-.-7.,-vL4,. -, . . . �z,��".�,�,;�,�.'.-�F,!,,'.-��.�,.�;'��.L�.'.�:.,w ."'.... w ...... ; I ..I-. . - I. ,2 1 , , , - . .1. "'. ,; i . - . ., . "'; -- i -, ,i-� ..5 F-I.. - 0 41 ,..�-,,, !,.':W�_' , - 11� " I ,2: . -1 2'.. . L, - - - -?15 , " i.,�-, _._.;:::,; 1.;o, :. ,::.�v'��!.',.I�,�-11'..�--h,��.i,.'. _�. , " _ J%s �z --!-'.�4.�'.. L:_j�-..'��?, �3' - .." _., ? '. ��` ,,'.�,',.�i, i.,7 - -.':,�. . X . J ✓� . .., - , �,* ;; . . " , .. � ."., . . , �. �. j, � . �: �;,�;) " :; , . - :i . '... � I - - I. T1, " `6?..�.t,.�; . `):;i,.-: k i , i � ., " .-I's- �, - ," ,:�.,.. �� i.? , - . .. I.. - ... . %, , .,�. . "'i�,"-I.Wi L .; DA ; . ',,;j..%.;.�,--,. .1 �•". ,�U . . I - ., .' ;�...��.'.-,'.-"��,.i�L:".,-�--i�.-f:�..,��,-.� '. -xn�,- _ , � I _wz" ,.,�,: .. l'._L,'!��;.;Id �,:.,..ial�,�;j:;_ . , , .4. ' . ' q ""'. � - - 0. " ' ; :�� __ . - �., .-W ,i_,_��.;` ..-- .... . ... ... - . " .. , Aii , - ' " . )' - ' 'N "T " �' " ' 2 � . .! �. � r -,. -�.�. i Y, ��., � "'. " ir'. V,X "I ..... ... ,; I ,�C' ,# N k m. '. , f - .k. �, " , . . ..,; . - " L. - I , 'Q;al. , � I � . ..,7:1: ,- -1 "t . L - , , N _. 1. ,�,. - ,..-. , , 'g. "t�i ". OR " ,.t�:'I�-' ?;L7 " 1 tm j'q S,'.'.,P.-,`)�� t,:.� -f 4). . * , � . . 1 . , � 1�� ,� I ; . � .3 ., , & % X, ��:. " L.,!��,� � —, - � , � :,!4�1� , I r�;,. ." . �. , - 1!V,.Z-;7W�.. ,�7.,�;;��lj� .JL* � 4"t. 1 , - , . � __., I,. %. . --;-��";,,-,��.r-,W..-.,,:,.KL,: 6, �;-,.Jj.�, .. ,� .q,' `Ifl"_�`, ,� --� -;�.`il,l"",P, ..'� , , , '", , " ,�X. '. __ ,,; - . ..:. . " r� ., - , �. �, ,C I , , - - N I -��.--- .% -',Y�. ,t,r"�j.-A.,�, . " .! , . . . . U , - 5, ;,.2, -,��'4.T-,.. - I,•, - , ...., ... m " - V c "I '. �i.".- . -1.%i...!�T1!1? , - `,7, `1 �i��.',�',.'-�L!F.!!-, ��.4 Y, "'ai, ,;, ..� ��, ... ., . • . R.i . . . . � ii6. � � . I-, - ., . I.- ' .. Itio.. _� . . er. .._.1:f;:- .. , . - . I - .: � . " , "?" -, " j� ;J� ,- , . , � I � j. I .... , . � � , " - '4;: _ '. . ....., . .. . . " , L I..- � ." �4 . . .. ,� , ,� - . . � ,�. � .1. , I o... 4 ........ . I ." ., _ill k -...., " I . - - �Q .- 6 1 _,�.:. .. - . _ ... a � , " t, !,;�_ 5's- ,-zr, , , . . V I'MV � ,, y.�,. -, I. . . 11�� i� `,4"' ""... . 5..,Z,-;�,;�,, . '.4..�O;�&��, -�'�,�!,.-,�f,�,��....:i�9k.., %� f..t...m y,�.� -, ,V'm .:;i." .. "._4' � � �: 4,� il..X,,�-.W.!�t. Ji; ;. _ ,; I - --�i,;z._- --�i.�.- -.,. , I . m .. U.' - .. J. zi-0, ;.,��.; , . , .1.: .:,.�..i -�r. 'It.., .tF .1 .4 , , ".- ?...'T. - .. ,.-z � -7., . :-�.,,:,! �0.;,%�,- . _. P L . - __ .. , ... '. " . .. , . I .',";� ' M'j� ' .1 - - I I ;.". ,�.' '�� -�P ,j7�,-,,�j�i'.t�'-. -,.-.,�?j '.�_,�-,fi�;, . A N , * '), , -..,. , ", � ,;.��'wm,. ,,:, .- .. . ,e�.�t,,fi%;_ 1! :�� i . �� , ,:,: .�. �i �; i. '�!�,�,�:,� ;,.,S� , ��'._ . . .. .. I . ,,�i�,.,.� �k�. ..,��.. -�i.-T .. - . . . � 'I I - . .Ei�; r. :..., . , - . . ;.�. � b - �- % �., � , ',;,� �.',i��".'. ,� ,.',-,'!' ,1�, � ;.",;k74 -'A_ .*�D;4,al;7illp,&.�C. - - ,�, v - %4�1..�..'W,xZ - ,,,� . . f, . - r, •. �.. . ;,;�_,;'-711. - 6z. � . ,.7, .. , .. - .: - - . " i. .�.Ik i __.— "-A- --F-j;�,-, .�'�� 1,'.a,!A 'ip_..W.� — .�. -,%� Al �7 ',,1,4.1,��._ "v . tim, - '. - .,-, - .�7� - - . .�' M ". t"; ii ff � iiig� t, '. .t 4 :r M, 114, �,,11�.j?":, . . �w _... . �_ .. - -, -.�,4f,'� - 'r��,, . ,� - - --I.- . , . ,�C, -i�c,�'.�P,4,&. .:.,. � .. ..., ...1. 1� �_ , ; , " 'Tk 'iil — —O.—N .;:1t"V;1'a!,� jL:,4<.,��.', . I ., � . ii,, -- - ,,---,- . '. ", 0-1, -,�Lx�.�'.41'.�l4�,,.'�r.l....,- P, - 'JjZ-,'� , . " I - - ��Ii._ . �� . . " . , ,, -T --h I,,-- .- .,t M, 7,��'vz�-'�",L7�;:�'�'4';4�i��';:-�, --'�� -K�`414 -i .: ., "" V 51 !4 ...... .. , I... ...0 , ", t �j , . . . . .... 4 '.�'��;"A""��"':'-'-."��.' �7,.%:��,�.._'_� I - -U , E-1i,in'! I ';,� , ;� ii -- - ", ��;?..;*N i'f,'?� �11 , ":W,T`.Dj��.�6 , a ;;;-'., 11� ,�F,, .'�t4 , r .r " , " "-,..,.A, 50 �� ..'� . ,; - � '� _' 1. I I. " %,:,�Izll��"il.,_,,�_ 1� , , , .$� . . , �, _- � '� �Mx ZN: �'.i,�,- 'L..:. . 41 _,'. $ . ..,. ., - . , v ��7-. 7 � N ...'. ,�� - I.h! .i.. upU1:_1. .. 1, � . , .,�.,""q"4�,, N " . - % "I.-g ".., _ , . i , , , �� _ . _ ,_ , . . . ., i - _ . . ,.!W .4. ��,��,',',-"`R.-,--,, 1",P... � r, . ,-,.. .K. i-.�Wl ,,A,", 17,,f� ,1--1A-,,_ � '.. - x � . ,-....' '_-_ �� - .. . . �vh! . , . I .. - -4 -.I- A - i� J ' " RN ,4`77,., - iw..�!;:�. --��i!�L-�.11 . , . k ,'.r� It, �'. -, '�. y -�i ". •�.... � . .".,-" " r...-,. .,..- - .. . 'IF" .. - ; pn; " - 'i -t lym! , .�, 1101,,x,kc " , , ?,;-- ".';, "i ,.Z1": - ,;.. �.w�s �--,1,7Atz-:.;U,� - �, . .... - . . " " , ; , " -. , .1. . - Z'X�,,:' 4!."?�, -g� , , ". " .... . . ... 11 - .1.1. ., - ; i. ." _.. ..'�..."�.�..,----gj�-y�l-.-...- W-j".. "',�,.,!A, ., . - � ... . .. __.... — ... 11. . .ke". ;.,.� .i t�iIi�k�(j;�,'l�..:7�,..;- ,�m .ia .... m - 1 ,..4. 'i. 7.. z�. "i" � , " ., Ei��. �..,; ', . ii. -Q,gli".!�Y 4�. ?'aQ'. .•� �� '. , I -,�Ii . . .. .,.i ✓ - F., .7.4. , I � I 1_..1 -, � i , . 4ip, 'W"T(" , .: A ,Z..., .;�, I , " , ,N".4,..,:�;�'.�z*�'L.T.,.;:"��i;!�!il?-!,�.'..�.-, -, - -.1-1. . !. .ji " - , --��r? .., " , .1 i. , .! � ;� A � ...j r _.: ,� . - . .-, - .q K - - .- ;g. --6,�L .. ." ., , . �1. .&.-I - - � i,., ....;, .'.-.-, "..?", k ". Z. -.1-C. - 111. 1. "Ill 41'_!..-.�. "014-7 � ., � - . "i , .7. 1 �".;�_ �;..,;,.,..-�.7,.-..O:,,��.,7:",�,.�."".;,k""�?�i.;;� '>&V-�.. 11!77 .11.v . .. , ,, - - .. rj',;��,,j,�� , 'P , - " —, 1,19 --- �- .. .: .:�. -,�AA d.,t.. _,;,M�1! ;,..... , �, , , R;�,�..�-,,�� '.`,.�`. .�O',qp "W-1 "; . . '� _1�1_ .. - � , ""'.1 , I ,Am �$ - , .� '11-0 " L. ., , .i., .. ,� 'r "A", i,-*,�.;',,11A_ .. , :K!'..-..S_%,.,.,t .;i5 ,5��, _3 ....;.i,,,.t�.,,.�.,.,��,, 01 L1. ... r I � - 4w , _�. , , . ;4) k � - .11k,��.W: :,� Mi' — . ",.r I . -, L 4;!" �.q -z; , W ;z ,--- .. nt�,�.,�. f W'. 4 ,14", �,, z - . . , .Z, , , , %. : �� . . ri. � , . . — . z :::, . - '. - ..r. .. , , N .��,,,:".r'h_ . . , . i, ;�� , ;,,; -�.4'4 - - ; 1 .;k— �. � �.� .U. in , , -. ---,. ;i .�4 , r r � I. o'� '- t - - � . - I .,-,. �-_. - , ---- - - - . , Y. . -�','&t .;�I. 'ell "'.'.Zk�.:,fy, :. .-., �_ 1 ; - ,...L.-�',7..t',",'�::�7;';-4-i.'-.;�I - ,a� � .. j . .. ,,..-t .e.'N'....._�.i:.�r.- im2"",;:.r1 .i47,�.;,.',.�;,�iA�'..v�t�:',i-,-�l-�'-�.t-��-2"��,,�i I -Pi. .... r.,1,1,,. . .. �,; :, � � , . . . . � ,,, . .Q, �!i Ur - L , - .._j ,� . �];;� . . , Rq..., P��7 �j.i�?""Y,.-.mk. k., ;I- ,., j I - __ , , %�?.,, -,-,-- * , " -4")'-�, - 0. m -� T .'. ",!q ': " I . , �! '. . 4.,. U6'. 4Y,K',- T'q' - . �; ,,-,-,-�. �:-;�, . .. •- �.'.- T" fit� �" --t,�,-f'-'��.;IM4;�.. 1, ��t .\ -�.�,', v .N� �S! ?�, 41 " " 11�, .�� .V4,�!� " - i�'.'�#,; -�! egk�,4k - u. .'. I _'Ijk'� - .'.� - , - - - - 2 I .. . iv�ni;il ,K.,;:--`;'�.�Z6' - " ,�:�..�,A' ,.'i'Vg'. ,,, - _��_4L��,,�; 7 ' . . - - " , �,;; -1 , '.��v�i-""T",i,,�t,� " - - ,�% t,'Q .;".. . - "", , , - - I. ��,;, ,1f,;-.'R, :.:., . - 5 - - '%�, ."t -,--'i' ,�'a -,7.", 1',ilz�'.�� , . , ,.�.';_ I . f�,.,.;; i, -. ,.', - " - . ,�4...:.,�..";,wz,.:"t,,.,:,..��'. - ; � 0 k� - �. ,�, - - , . ., , ... ,� _;• . .. I �1;�,L - -A;?".�,;`,!I,'�v',, ` * ,;,,,,.?;;�,..�,.,;� � ."i ,Q ;.!, , Q��?�- .�. .,'!. ,.�4�,-',S,� !"r_ r!t- - ZC. ni�t��,� W'. ., j,;L, '.A . &.-,.; � - .. .. - . , g�- I , .!�. 1, %. J ," '1&t,Me'r. . " 1,�.�V'i . ." . - L .1.3 �. � 'i ,jy, "t "' t�' ;Oi- i, .-�.�'j�.!A',��'.,� J.; , I.i. I 1.1 .. ., ""M!_.,1�P1j'(%-K-.,- ,�,%,-�,; __,4`r .1 , ,A - - � ii 1,.. - V - - "'.'... 1 -11'.... k , .1 , -I.V .. - � � ...... . . 'T. 4.1-ii.ij A �114!f .;:,L- I V ',,i"_ Ej "3;P....-'�,-'.. - . , - - , " . . '.. I 111� � %--.'�', ,.,�. - ,.,- -� L; . I., . .tL,,,.,.. .I; !-..�� .� ,v, - ::., , � "': 1.t,R),'...-1�L- �� ', 'Nfl �_.� h;" ,)� . . . .., . ......... `,Ili 1.1-p, .�P .;��,--,,��':vs�,,�i` ; . � i.!1.-.P!;,i .51 P � c . -.1. ,. ,)", ....: , , , , , �-- -;�' '�;. -i4 -� L'. "�'.';'.-'A�.'...T'."'.'?t".a'.;..""If��l,'��l�� - -- y., . 3 T. � , - I ..... . . . , - . . N.. .1 . .1. I - - i ,�!z - 2 .�� ,;� , ;.r , �., � �, . . . %, .. , ; " .' I - "' _..'JL". ' 1�5"? ."ji � g, -t :11? 4i!" Ar-'l. c:�� .%..1;.,1; 1'�,iy - .% ,�j ,�. - kl'";- -�- -yi-.,.'�,;`�'.,�,�, �, ,,i, �t., �� 1 ." .s. , . ". ". 9� il 1.* ,'��t:4�.,,,-.'�,,��el-.:,.;�-li:-, .- � .,.,;. ,�., I , �'. � U, . ". ..;� . - �.-., , . .. . ir -j"'i , - ;, �. !"'..".�- . ,i1t.;i-*1-N..�i. .;, , ;7,."j �-,-., ,�.,-. - - A..'- % .i.n. � , . .1 ,,� - m. ..'... , ;, - 1, .. .. " . '. � . `i�_,tL V!," �1�. �.R 'q X � 1 %�7 .� . . r .,:." ", -, , . - ", .. - . . , . .�,' ' I' - - 11 I' 4 - , , ) - i",," - U;�., ,xai�'i_.-4,_L �, .11.:4.. .. ... ,L, . - . - . , - . . k ., �f_. 0, L. i�. � �.,;-,'-, P ". '� . Z�_"..il,�,,.%,�! - , � .�,�,'. � -, � � -, , r, .. - ;,�, , . , , IN , - .. ., - r!_. -:i, __ _._ , �. '�- 10 hxt.��:!j� �;,�,.L,�.F,�-i,,'��,,.�,.",-i,-.�,?'�, . T., .,Mf, ?� r 1_0 i� • Y-,4-i'�,`.',�i-,-_A."1_ �._;,�,4ri"",."!4` , - - ,, .�,�.,5.e..i..,.,i,i-;��...,-..,i�,,�l.��.4r4. � i_.111,%.._ .r, - - ii.`,�,� I L, - , W, � '�,`.' `4 24- - r;`,j."."��' g,ii, -��:,.4.��Nf;-.';,,..'R s "Ap"ZIvii i.;v - � 4t�jjkll, .- i�; - �,; . . j;1 pt d , - - �., , �.� , . - If .. . - - '! - " . - " , �_ il ,'- r';� . I.' (,.',� ;�,g�,-a;,it- .---.7;%g' I" .� r . .2 - - � "". _. � ,�� ... ,. .ir: .� . mi:y��7�-,r,.I�!,�,L�.i3: i4,-�."`i�4 :.�F; �_ -�l,'�'r',',-T.%:,,�-.�.!,C�,-4"-�j - -: :. .." i. .. ,! ;,� � :! . - r: . . . . . ... .j� - I . '. . . " . .`e,�.�,.';!. -�;�.�.��r �:� , . .., Q,-Fa..)N�'1--� .,.- �, , .% - .�. - -, " ..._�,'.;j:.".i.f%.. .,�_., ,.jz. r�,'?��_.711",A'� Iff", It �VO " "i - " ��._' " . - -1 - , - , , �,f A- . *56; -7. . I _fl��'. ,;..a :; S ': Z " - , , . - , . t -,, - .., ".. -j. ..'�;q, I O." . � .. ... ... . . � - -. " .;;�V`xf% r V_ - '. - " p '-, M- 4� 116_1 40� !-"�,,��,,,;,,�":.,:-"�",f.""', '; , . . '. 4�L;Zi : , ..", WP��',_,. g I -�-", 17_�it. L�' , '. _n-x"J.;,Z,;i' , -. . �, ., i. -,,, , ;.-�: : : �Iv. .,� .,-, "t. �,.,., �.' .Pr--,;,T ?, .. .. , . '�� 'i�;!" "' �� ,, - i,i� -, , . V, K . �; � T. , -� K�,� .Sad:. . " `�,,-�� L��!7"it�.� ��-.,-v."q,.:-1,._ ... .,;- L.-c � 7�.Q; " '.it I -,!' - " ILL --. �, `i��, -.;; - j, �: -.,;" _!`.�__, _.,g .", '. "Vi ". . . 'P.:14) . �.% �t�`.��!- �,�,. . .4'.. . :. , ;7 ,., .i.t;; i, . . , I . %N_ - ,�- ., , , �.'.-.��11'.!', ". -1 -, , �?",z,;��,Cm? , Z 1k - ;-". .. , ,4;: . �;. � " . , . I . . I I . , , 11�4y ;, 1 . , .'�-:' - --4;.T.',' C. _ 4yt'A,' � ;0Z kv'- ", . _. . _..; .. . I '. - - , jt',.'!�v � :.,.�;',- � -, , , . .. .f, , ,,N% ,:7- "-,,-- --.nr.6: , " . ; .. .. - '. ...", ' .., .2, �'. ,:��` :,!:. .. - I '. , '..., --_ .-I. . _ ,:��Pj Z C. I 0 . : 'L',�,� I .� �k. .. - - �6. i .. . . . I _,. .. .. . a , . , � . , , 31;�QML,'."; ��;� . , - i:: v , , , .1 _� . - 7._ ft . _� � I ,, . . , .q4'4.zl� . ,� : !',�; V.: - _--� ;, I " . �.. . , ...% --.7 r - - : . — , , .. _-, .... . .. '. ..." , .-I --.-� ! , - -, " . I . . - e�...`... a,;, :.. , _ " t; �._ -_ . I . . . . �Y. - 1. .. -...i .1 ; I r, , " �.-,.. _. .1 i...:: :,:-, .,., �.. i -:: - - .... . . .. - i -:: - - . , .. � � M, , . . .;t.,-.. .;;�-; .... .. . , , , , i - -, .. - - I -, . - :: . . : I - - -. m: : - .- � - , .? — - 1�.. :.-Z� ... . I I ). . .; , � I - - � ...1. - ., . - .. . � , - ! � .. . . . .. ... I .1 ...... . - — .! :,. � . ., __ 41. ; . . � . - . , , . . . . . . .'- . . I b) . . . . .,' ' -�; . . . .. . - - . . . . P. _.- . . . . .. ;. �4, ';'.. . :. . . -11 . . I -, . . .. _.... . . . i , ; .. . . - -t 00 � t , - ^ . . .. . . : . . . :i E E E i.;:. ; _. . : . 5-.`:,,!i....! 1.j. i j U. I , . � - (� � ..V . . ... . I . .. ..... ,:- ... 8 . . . . . . . . .... - . . . . . . . . . .. ... , e . . . Z. . . . I ,;. ... . .�_ . . . . . . ; '. . 6 brd�— .iq-�J- . ", ...11411444 . . . .. ... . ... . >_...._ tj o ;',nn.. .. 1� 1- — " Mus -4 . . A . .. . ; . ,:- - � __ . � T� D — e . . I . . i 0 ..J rt�_Nl . 1 �7.1..N_ _.. . ,�'�_ . 7 m I !:-Q . ., . .. C, -'.'�.!...'..j,7-,:j . I k�:. , 4.1 .! 0...;,;�._T� . . - . . . . . . . . . . . . . . . J . _,j . . - . ... , b ,�Z� :: . c=- I . ..; - .. . . 'T. !�` . i - . - - i , - . .��Ak . . ��,, 1 r ",Fl-v�� c; ` . . s ( _. . a, CITC , V.4 . - L, - - �q i. .. C*�_ .. Lie , � ..,j - !�..- 'i . ,�� --� , - '. �� .1 . . . .. ..., .. . . ! . - ., M� - ," � ) pgi _��-",N,' 'm . -4y:� . . _-) 4 1 . .. c 3 () 0 x, - - . 1. . . . . . " �',�.� M . .._p:'�t.'_4 . i.�. . . ? .. . . . I , CA. - I . . .- _. . . - ". " . I . I ,�* " :i ." �- Z�ri . . ; I on, . .. . .. . . I . _., ... - - I....m. i .,�' '. '... '��.04 � I � , . 5. .-�: - , im. .',Z..�. - . . - T 5-41. , , �_, I - -, - - .-!.:..,: I . ....'.., J r . p. . _. . - . ....i. __ ..... . �! .. . . I' � �i, i D --r- p. . - ." . . . . . .. '_ , - - �� ", ... . . . ; . g , .: � ,"�: i.: _..... - . . . . . . � ,;,,;.'. . . ; :,.I�.' . p _-� . G .; , .. . . . . . . . :�.I�.,..4-;�,�,,, - .3, . . , . I ;j . , . � .w ... . . . - '. : . - il. 17.,c - . . . -- - - I 'j, - . . . - I I Li ,E�� . . . ...f. . . - i - .. . . .. - 1�. . . : ... - .. - ... . It. ;_11_11 . . — . . ! � � - P2 I N_ffl �! �,;.�:,f,'.. L . '11. - . I .. - . . . - — . . . - . .- � - . . ! I , - - .I..- __ . . . _�..,..'.., . . ....r- . V, Ln -_ I ;"_P..'�� . =4 1 . . : ,_� Q-�; -,X-141" .W.4 r.- . � i r -1 j, -1 . . . 11�;�V 21444:�`? - - N. ZWO . , F . . I I . . . . . . . . . . . . . . . . . I . .. . . . . � '.�.,',',?' - . .. . . � " . " .. . . . - . ,.-.. -Ir t'.-.',t-.'-.. �. - . A� :11. �. r.,;T. ,�;...., , . . . . . . . . . . i .. I , - . r ;( ., .C., - I.-S., I ... . . . o -..,. N. .U�.,. . I k), . I . . . . I �.. ...., ..j J..; . . . . . � ,�... . . . .1 . . . . . . . .. w, _` , '.. . . . . . . I , . . . h. . . . . . I ...... . . . - . . . . . . 1! - A , I _. . .. . . " .. . . .z - : , . - ;1j:. - P.. � , , ,�:. ,�:. 'j:. ,�:. 'j:. I ,�:. . ..- .�t . .. .. .. - . . il& � . .. . � : ..., t, � , .1 " . gw. , 11 .;. - LL. - A . '4 ? i. . "I . . . . . .. ill . .. I. V.. . , : -;; . � . I _. % t I : . . pvfp., . .... % ".. . : . . , .� . , ;. .. ... .. N.. - 1. . . . . % T p . ; ITUIZZI .j- , . . . '751111- "..... . . ... . . . .1. . . . i I , . . - •. ; 11 .... Z.. . .. . .. .. ... . . . . ., �. . . . . . :* , .". . .. . . . I . . . . .:.. -.' !.m .: . . . . .. . . . . 1 4-m ..... . .. . . . . . . . . - . .... . . . I . . . . . - . u . P I P 'I . . - . , , , , , , . . . ., ,_ . . �-, , - " I , I -,-"�,1111 d, X, I C_ - . .. .. . - I . . I . . . . . . . . . . . I . . . . I . , . . . � . . . . . . I . . . . . . . . . . . . . SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find C3 i o 3o N r-) in the amount of $ 10 X which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum No. Date Received Bidder's Signature �1/27- o0 C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. /H. % aysa^10 Dollars A/a Cents 2 1 Traffic Control $2,000 $2,000 L.S.o Dollars ltly Cents 3 1 Trench Shoring L.S. @ O,c% % �S�s i .�� A�wva:co Dollars _,A c Cents _ 4 889 18" HDPE Storm Drain Pipe L.F. @ Si,�ry S'iX Dollars Al,:::) Cents 5 238 4" HDPE Storm Drain Pipe L.F. A114A Dollars /O cl Z S q 4-Z Alb Cents 6 29 5"x 20" NDS Channel Drain #810 with 4816 Grate Each /t A/.0 11412-7-Y Dollars r -z 90 _ /tfa Cents 7 20 C.Y. Concrete Channel Backfill A%v-y/-�,,ollars %ZS - 4, So'r /410 Cents 8 2 Tideflex Gate Valve, Series 37G Each .,o /7ver A1v.&wcre_> Dollars /%/o Cents 4/'-Soo f 0 DC� 9 3 Junction Structure - Type D Each /o11u,,wwcno Dollars l 2 (, 00 %84d A4;) Cents 10 2 Abandon Existing Lateral Each Dollars ► 000 Alc- Cents 11 30 Sawcut Local Depression L.F. @ �o z7-y Dollars 4-0 Zao Cents 12 30 Reconstruct Concrete U-Channel L.F. / �-�%NT Y Dollars A 16 Cents Total Amount Bid in Figures: $ 1 3 3 6), Z 6 Total Amount Bid in Words: _ ©/✓E yd.�oiz u.9 /zTY __tG /tYG�v.;;I",4 C-Is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. PortionName and Address:.of Subcontractor State License Class Of Number Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY'BDJDER AND SUBMITTED WITH BID State of California S3. County of Orange GREG BUCHMAN , being first duly sworn, deposes and says that he or she is PRESIDENT of BUSOC,CONSTRUCTORS, INC . the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genu' e and not collusive or sham; that the bidder has not directly or indirectly induced or solicited a y other bidder to put in a false or sham bid, and has not directly or indirectly co)ludod, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the, proposed contract; that all statements contained In the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. BUSO CONSTRUCTORS, INC. Name o i Signs a of Bidder GREG BUCHANAN, PRESIDENT 14700 FIRESTONE BLVD, #103 LA MIRADA, CA.90638 Address of Bidder Subscribed and sworn to before me this 1st day of DECEMBER , 2000. SEE ATTACHED NOTARY ACKNOWLE ;�OTpRY pUgLIC NOTARYSEAL C•4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE No 5907 On 12-1-00 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G..'JANE DOE, NOTARY PUBLIC' personally appeared GREG BUCHMAN NAME(S) OF SIGNERS) personally known to me - to be the persona() whose name((&) is/ subscribed to the within instrument and ac- knowledged to me that heiebsAfty executed the same in his/kNx) t authorized capacity$iox), and that by his/XQK signature(l) on the instrument the personft or the entity upon behalf of which the person(%) acted, executed the instrument. BARBARA J. BENDER Commbdon # 1267491 IN jShanUnacial seal. Nolcay h bk - Colijk ila county MyC0m. EI0%Ju1 3.2M4 S140ATURE OF NOTA Y OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL CORPORATE OFFICER PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR ENTITY(IES) BUSO CONSTRUCTORS, INC. DESCRIPTION OF ATTACHED DOCUMENT NON —COLLUSION AFFIDAVIT TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE 01993 NATIONAL NOTARY ASSOCIATION • 8236 Rommel Ave.. P.O. Box 7184 • Canoga Park, CA 91300.7184 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: S� Oc� Z000 _—ZJ5 a Contractor By Title C-s DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes �To If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: ,!�-- fDe-c Uc� Contractor By Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Contractor Title Date: Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: I Jy s o cl—* n r a s, Zy e 1 a i -S C-- Bidder Name -Xt:- I 4--70 + 2z s a.�� ►�� I o3 Business Address L-1--.. Imo% i ►= GG o(o3 8 City, State Zip (7k4) `739 E3tei Telephone Number State Contractor's License No. and Class Original Date Issued Expiration Date The work site was inspected b�y�''�'*'�'� of our office on Ze rNo-/ 52000. The following are persons, firms, and corporations having a principal interest in this proposal: C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise,- to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. GREG BUCHANAN, PRESIDENT Printed or Typed Signature Subscribed and sworn to before me this 1stday of DECEMBER 2000, NOTARY PUBLIC SEE- ATTACHED NOTARY ACKNOWLEDGMENT NOTARY SEAT, Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. ►�% �ti/p ��z 1�-��oa.z s ? O. �i ��c 111 Z L�.,.�c.�.sr-z,t �� =1-3 6 Name and Address of Public Agency 3. Name and Telephone No. of Project Manager: F—►' k71,crJS2-J 661 q 46 1 O z-'6— s S 7 l�oa GH.oi.wcv ��.. 4 T1oyo ..E in aE 1999 Contract Amount Type of Work Date Completed .�E.'z Zes"pc2S PO. --Ijoic 1 11Z l�ar�cn.srtn Cak,, 9 3 SS 41 Name and Address of Public Agency Name and Telephone No. of Project Manager: art►a.,u ID F. i�oy �� 1 �t 4!0 ► oZ-4' ¢-, G�ZZ� ovo CONutgi� �sG..•d..�a—c— ,/�—� 99 Contract Amount Type of Work Date Completed Name and Address of Public Agency Name and Telephone No. of Project Manager; Contract Amount Type of Work Date Completed C.10 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORAWGE No.5907 On 12-1-00 before me, BARBARA J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G., -JANE DOE, NOTARY PUBLIC' personally appeared GREG BUCHANAN NAME(S) OF SIGNER(S) personally known to me - to be the persono) whose name(a) is/ subscribed to the within instrument and ac- knowledged to me that heAsbsAhW executed the same in his/knodbmix authorized capacity0m), and that by his/XVVAUW signature(l) on the instrument the person(t), or the entity upon behalf of which the person() acted, executed the instrument. BARBARA I BENDER Commission # 1267491 ' Z Notary PuNTc - California JITSS han=i* Orange County My COmm. Expires Jul 13, 2004 Q, SIGNV RE OF NOTARY OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL CORPORATE OFFICER PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSONS) OR ENTITY(IES) BUSO CONSTRUCTORS, INC. DESCRIPTION OF ATTACHED DOCUMENT N/A TITLE OR TYPE OF DOCUMENT .ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT N/A SIGNER(S) OTHER THAN NAMED ABOVE 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Rommel Ave., P.O. Box 7184 a Canoga Park, CA 91309.7184 Bond \'o...... ,3.0.17.1.19 fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 BID BOND KNOW ALL MEN BY THESE PRESENTS: BUSO CONSTRUCTORS, INC. Thatwe....................................................................................................... .................................................................................................................................................................................................. .............................................................I as Principal, (hereinafter called the "Principal"), and the FIDELITY AND Di;POSIT COMPANY OF MARYLAND, of Baltimore, Maryland, a corporation duly organized under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety"), are held and firmly bound unto......... CITY OF...............................HUNTINGTON BEACH ................................................................................................................................. .................................................................................................................................................................................................. ..................................................................................................................as Obligee, (hereinafter called the "Obligee"), in the sum of..................T.EN PERCENT OF THE TOTAL BID. IN------------- Dollars ($..1R%..af...Bicl..), ........................................................................................... for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for..........:....................................................................................... INTREPID LANE STORM DRAIN ..................................... :............................................................................................................................................................ .................CASH CONTRA4�?'..N..4.1155....................................................................................................... ................... ................ ..... .................................................................................................................................................................................................. NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or contract documents with good and sufficient. surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter into such contract and give such -bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof .between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void,otherwise to remain in full force and effect. Signed and sealed this ................... Ist.................................. day of ............. DECEHRER.................... A.DXXK..20.00 .......... .. . ............... . .. ......... Wilncss BID DATE: DECEMBER 5, 2000 F FIDELITY AN Witness C325d-1 SOM, ADDroved by The American Institute of Architects, A.I.A. Document No. A•310 February 1970 Edition. USO CO R C ORS IN s ....fir...... :(SF.AI.i . ... ... .. .. . .. ................ .. Principal Y.- ..... _ ....................................................., ................... GREG CHANAN, PRESIDENT Till. DEPOSIT COMPANY OF MARYLAND S trely ....... (SEAL) 0 N M. R 1'ille ATTORNEY -IN -FACT CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On 12-1-00 before m@, ��A J. BENDER, NOTARY PUBLIC DATE NAME, TITLE OF OFFICER - E.G..'JANE DOE, NOTARY PUBLIC' personally appeared OWEN M. BROWN NAME(S) OF SIGNERS) personally known to me - to be the person*o) whose name((s) is/M subscribed to the within instrument and ac- knowledged to me that hekba tfty executed the same in his/bl authorized capacity0m), and that by his/XGVAXM signature(g) on the instrument the personft), or the entity upon behalf of which the person(t) acted, executed the instrument. BARBMA J. BENDR IT S Zh an ial seal. OMY 1 X X , i ,r -UIRM OF NOTARY OPTIONAL Though the data below is not required by law, It may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ATTORNEY -IN -FACT TRUSTEE(S) GUARDIAN/CONSERVATOR OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(8) OR ENTMJIES) FIDELITY AND DEPOSIT COMPANY OF MARYLAND DESCRIPTION OF ATTACHED DOCUMENT BID BOND TITLE OR TYPE OF DOCUMENT ONE (1) NUMBER OF PAGES 12-1-00 DATE OF DOCUMENT BUSO CONSTRUCTORS, INC. SIGNER(S) OTHER THAN NAMED ABOVE N0.6907 01993 NATIONAL NOTARY ASSOCIATION 9 8236 Remmet Ave., P.O. Box 7184 a Canoga Park, CA 913W7184 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BALTIMORE, MD KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by C. M. PECOT, JR., Vice -President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Owen- M. Brown of Anaheim, Cal iforn' irs true and lawful agent and Attorney -in -Fact, to make; execute, s deliver, on its behalf as surety, and as its act and deed: any and all bonds and undertakings.... .. .... e execution of such bonds or undertakings in purs f these shall be as binding upon said Company, as fully and amply, to all intents and purposes, as if they had been d cuted an�wledged by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper The said Assistant Secretary does hereby certi a extracrth on the reverse side hereof is a true copy of Article VI, Section 2, of the By -Laws of said Company, and is force. IN WITNESS WHEREOF, the said Vice- nt and s t Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY AN, POSIT CO OF MARYLAND, this22na______--____day of - ------ -- JulYL--------- A. D. 19 _ FIDELAND IT COMPANY OF MARYLAND ATTEST: a SEAL � � By 01— Assis tary Vice-Presid rt STATE OF MARYLAND _ Q COUNTY OF BALTIMORE { �'\�/ On this 22nd ---- day A.D. 1923__, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came C. M. PECOT, JR., Vice -President and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the sea] affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above: wr itte . ,apl d. Fq�_ NOTARY_ ___------ PUBLIC K AROL J. FADER Notary Public My Commission CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attorney -in -Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this day of_-DFP_EDdEkU------------- ---- ------ 2DDO q_ --- —---- ----- ----------------- --------- - - - ---------------------------------- Assistant Secretary - Llaisc -012- 4 16 0 EXTRACT FROM BY-LAWS OF FIDELITY AND DEPOSIT COMPANY OF MARYLAND "Article VI, Section 2. The Chairman of the Board, or the President, or any Executive Vice -President, or any of the Senior Vice - Presidents or Vice -Presidents specially authorized so to do by the Board of Directors or by the Executive Committee, shall have power, by and with the concurrence of the Secretary or any one of the Assistant Secretaries, to appoint Resident Vice -Presidents, Assistant Vice -Presidents and Attorneys -in -Fact as the business of the Company may require, or to authorize any person or persons to execute on behalf of the Company any bonds, undertakings, recognizances, stipulations, policies, contracts, agreements, deeds, and releases and assignments of judgements, decrees, mortgages and instruments in the nature of mortgages, ... and to affix the seal of the Company thereto. " City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For INTREPID LANE STORM DRAIN CC- 1139 November 15, 2000 Notice To All Bidders: Please note the following revision to the Project Plans, Specifications, and Technical Provisions: In an effort to compress the work schedule, the attached Alternate Bid Schedule shall be submitted to complete the project utilizing Saturdays as an additional mandatory work day, following a standard 5 day work schedule. The low bid will be based on the primary Bid Schedule. The City reserves the right to utilize the Alternate Bid Schedule upon execution of the contract. This modification does not change the Engineer's Estimate for this project: This is to acknowledge receipt and review of Addendum Number one, vem 15, 2000. —1-30S c C_p.•3 S i Ry cMo2S, 1r►` Company Name By t7c'� OQ Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Todd Broussard at (714) 536-5247. SECTION C ALTERNATE PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @—i 44rL -;:- Dollars Cents 2 1 Traffic Control $2,000 $2,000 L.S. @�iio %�oysA.�n Dollars nio Cents 3 1 Trench Shoring L.S. ,Vo Cents / Soo /,Soa 4 889 18" HDPE Storm Drain Pipe L.F. @ S'cyc'NTY �v2 Dollars ,A,b Cents % 44- (o S 786 5 238 4" HDPE Storm Drain Pipe L.F. @ OeV, y0^1,0,26P i 7 i Dollars my Cents 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each Dollars n10 Cents _ 3.00 g 7ov 7 20 Concrete Channel Backf ll C.Y. @ �y�.v yv.� aZ�.%,✓' Dollars � It& Cents %Z s � 4- Soo 8 2 Tideflex Gate Valve, Series 37G Each ollars i(,,b Cents 4--5 vo Dvo 9 3 Junction Structure — Type D Each /,,cycDollars Al-, Cents 2C000 % goo 10 2 Abandon Existing Lateral Each @vim 1/0.-.2c> Dollars mc, Cents _ �-�0 1 000 _ 11 30 Sawcut Local Depression L.F. @ X�;,e-ry Dollars 4� _ Ata Cents 12 30 Reconstruct Concrete U-Channel L.F. @��,,. -,y Dollars AoV Cents Total Amount Bid in Figures: $ Total Amount Bid in Words: O�vs ,UvNo zar� ,.LrY �x %cos-f-W C-1s , CITY OF HUNTINGTON BEACH 2000 MAIN STREET OFFICE OF THE CITY CLERK CONNIE BROCKWAY CRY CLERK February 27 ,2001 To: 4-Con Engineering, Inc. P.O. Box 2217 Fontana, CA 92334-2217 CALIFORNIA 92648 Enclosed please find your original bid bond issued by Great American Insurance Company for Intrepid Lane Storm Drain cc no. 1139 G�� ow-14vy- Connie Brockway, CIVIC City Clerk Enclosure g Nollowup/cashcon/returnbidbond.doc (Telephone:714-536-5227) 4-Con Engineering, Inc. Bond No. N/A GMU M ERICAN INSURANCE COMP® OHIO BID BOND Approved by The American Institute of Architects, A.I.A. Document No. A310 February 1970 Edition KNOW ALL MEN BY THESE PRESENTS, that we 4—CON ENGINEERING, INC. as Principal, hereinafter called the Principal, and the GREAT AMERICAN INSURANCE COMPANY, a corporation duly organized under the laws of the State of Ohio, with Administrative Offices at 580 Walnut Street, Cincinnati, Ohio 45202, as Surety, hereinafter called the Surety, are held firmly bound unto CITY OF HUNTINGTON BEACH. as Obligee, hereinafter called the Obligee, in the sum of TEN PERCENT OF AMOUNT BID—,— Dollars (S10% OF -BID"" ), for the payment of which sum well and truly to be made, and the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for INTREPID LANE STM DRAIN 41139_ NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obli, ation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 4TH_ day of DECDIBER 2000 F-9630B 4-Con Engineering.,, Inc. CALIFORNIA ALL PURPOSE ACKNOWLEDGEMENT STATE OF CALIFORNIA COUNTY OF SAN BERNARDINO On DECEMBER 4, 2000 before me, Janet L. Miller, Notary Public personally appeared Kelly A. Saitman personally known to me; X or proved to me on the basis of satisfactory evidence to be the person whose name (.ai-. is/ate subscribed to the within instrument and acknowledged to me that (sae-/she/thy) executed the same in b.i- /her/tbe� authorized capacityLi-e-st, and. that the entity upon behalf of which the person(.a3- acted, executed the instrument. WITNESS my hand and official seal. (SEAL)':,, -� JANET L. MILLER COMM. #1147631 < �r0_ oiir�' NOTARY PUBLIC - CALIFORNIA N Fr"8 »F i SAN BERNARDINO COUNTY MA Comm. Expires July 20, 2001 Y Y 3c+ Sig ure of Notary Ptiblic CAPACITY CLAIMED BY SIGNER: Though statute does not require the notary to fill in the data below, doing so may prove invaluable to persons relying on the document. Individual( s ) Corporate 0=ficer(s) Titles Partner(s) X Attorney -in -Fact Trustee(s) Guardian/Conservator Other: and _ Limited General Signer is representing: ATTENTION NOTARY: Although the information requested below is optional, it could prevent fraudulent attachment of this certificate to unauthorized document. Title of type of document: Number of pages: Date of document: Signer(s) other than named above: THIS CERTIFICATE MUST BE ATTACHED TO THE DOCUMENT DESCRIBED ABOVE. KAS/189637 4-Con Engineering, Inc. CUM AMERICAN INSURANCE COMPANY® 580 WALNUT STREET • CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than No. 0 13970 FOUR POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and existing under and by virtue of the laws of the State of Ohio, does hereby nominate, constitute and appoint the person or persons named below its true and lawful attorney -in -fact, for it and in its name, place and stead to execute in behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name JAY P. FREEMAN KELLY A. SAITMAN Address ALL OF ONTARIO, DONALD R. DES COMBES CALIFORNIA J4NET MILLER This rower of Attorney revokes all previous powers issued in behalf of the attorney(s)-in-fact named above. Limit of Power ALL UNLIMITED IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 26TH day of JULY 2000 Attest STATE OF OHIO, COUNTY OF HAMILTON — ss: GREAT AMERICAN INSURANCE COMPANY On this 26TH day of JULY, 2000 , before me personally appeared DOUGLAS R. BOWEN, to me known, being duly sworn, deposes and says that he resided in Cincinnati, Ohio, that he is the Vice President of the Bond Division of Great American Insurance Company, the Company described in and which executed the above instrument; that he knows the seal; that it was so affixed by authority of his office under the By -Laws of said Company, and that he signed his name thereto by like authority. This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated March 1, 1993. RESOLVED: That the Division President, the several Division Vice Presidents and Assistant Vice Presidents, or any one of them, be and hereby is authorized, from time to time, to appoint one ormore Attorneys -In -Fact to execute on behalf of the Company, assurety, anyand all bonds, undertakings anti contracts of suretyship, or other written obligations in the nature thereof, to prescribe their respective duties and the respective limits of their authority; and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and the .signature of any of the aforesaid officers and any Secretary or Assistant Secretary of the Company may be affixed by facsimile to any power of attorney or certificate of either given for the execution of an), bond, undertaking, contractor suretyship, or other written obligation in the nature thereof, such signature and seal when soused being hereby adopted by the Company as the original signature of such officer and the original seal of the: Company, to be valid and binding upon the Company with the same force and effect as though manually affixed. CERTIFICATION 1, RONALD C. HAYES, Assistant Secretary of Great American Insurance Company, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of March I, 1993 have not been revoked and are now in full force and effect. Signed and sealed this 4TH day of DECEMBER 1 2000 S1029S H 1, 97) FORNIA ALL-PURPOSE ACKN State of California County of San Bernardino On December 5 2000 before me' 'T Cruz R. Borrero Notary Public ' Date Name an T t efor Officer e.g., " ane WOO, Notary Public") Personally appeared Richard J. Garabedian Name(s) of Signer(s) ® personally known to me ❑ proved to me on the basis of satisfactory evidence to be the person(} whose name(e) isle subscribed to the within. instrument and acknowledged to me that CRUZ R. BORRERO he executed the same in hisey r Commission # 11699m authorized capacity(, and that by hisk&eAPey •� No-ary Puck - CalNamdo signature(e) on the instrument the person(, or the Los Angeles County entity upon behalf of which the person(e) acted, MY Comm.E)phn Jan 18.2002 executed the instrument. WITNESS my hand and official seal. gna ure OT NOtarY FUVIIC OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Bid Bond Document Date: December 4. 2000 Number of Pages: 1 Signer(s) Other Than Named Above: Kelly A. Saitman Capacity(ies) Claimed by Signer(s) Signer's Name: Richard J. Garabedian ■ ►4 100 Individual Corporate Officer Title(s): President Partner -- ❑ Limited ❑ General Attorney -in -Fact Trustee Guardian or Conservator OF SIGNER Other: Top of thumb here Signer is Representing: 4-Con Engineering, Inc. Signer's Name: N/A Individual Corporate Officer Title(s): Partner -- ❑ Limited ❑ General Attorney -in -Fact Trustee Guardian or Conservator Other: Signer is Representing: 4-Con Engineering, Inc. P.O. Box 2217 Fontana, CA 92334-2217 CITY OF HUNTINGTON BEACH INTREPID LANE STORM DRAIN From ^- REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 BID DATE: 12/05/00 BID TIME: 2:00 PM r ax xt (� ! t W� k +n A Yi•2�'i 1. f z .. SECTION C � Cali �n�inaerin>> Inc: PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and .all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 4-Con Engineering, Inc. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. 0 Accompanying this proposal of bid, find j30N b in the amount of $ 10 70 which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum Date Received Bidder's Signature f No. C-2 4-Con Engineering, Inc. SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ �i><� oysA Dollars Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ Dollars Cents 3 1 Trench Shoring L.S. @ IC1'rC Dollars Cents 4 889 18" HDPE Storm Drain Pipe L.F. @ Qiy��/n�OiLe d �/✓� Dollars D� Cents 5 238 4" HDPE Storm Drain Pipe L.F. @ — Dollars Cents 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each @ 0-"/ 4V47- y /�� ✓E Dollars Cents 7 20 Concrete Channel Backfill C.Y. @ %!•� f�y.�JDrtF� Fi fTc�'�4/ Dollars l /-� 3DU f Cents 8 2 Tideflex Gate Valve, Series 37G Each @ Dollars 10000 Cents 9 3 Junction Structure — Type D Each @ ?te a 7//V 0sA4A _::rr x AoA.,b/1�� Dollars ;Z 6,9 Cents 10 2 Abandon Existing Lateral Each @ Ti,.D f-r vaDdt7 Dollars Zs�D ' 6 Cents 11 30 Sawcut Local Depression L.F. @ 15, v Dollars Cents 12 30 L.F. Reconstruct Concrete U-Channel @ Dollars Cents Total Amount Bid in Figures: $ % ,� 7 .2,9, 0 Total Amount Bid in WWords: d)N�-/-fvn��Jr�e7> %�ti� sev6✓ fiV--, C-Is ` 4-Con Engi meri ng. Inc. LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor Stat License Class Of umber. Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 4-Con Engineering, Inc; NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange K10-0.20 T. 6-AkAe�tA^► , being first duly sworn, deposes and says that he or she is g65I IN e,-1- of y -co" Ls--N& jaw4 w6- ZiuL . the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Name of Bidder tIc B' gnature of der �D AA," EcxgP3 1477 (k)A%W P&Tb a b&_ FQA/t PdJA- 0 A- . Z39 .. Address of Bidder Subscribed and sworn to before me this j' day of 2000 . CRUZ R. BORRERO Commission* 116"3S Norm A' aBc . Calft"a My Comm. ER�ies bn la �2 NOTARY PUBLIC NOTARY SEAL C-4 4-Con Engineering, Inc. UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: 12 - L( - ov q -eO&) QU&tNitAl& 1206 Contractor By c.► oozo j 2►a4t�Dt� % Title C-5 4-Con Engineering, Inc., DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes KNo If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 4-Con Engineering, Inc. COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 12-- 4-DO q - (2ou &X)t-A nJ&- Tl t Contractor C-7 4-('on Engineering, fMCO UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: q - C.©N &Q61nJ6jE21P16r . Contractor Title Date: [ Z A — D0 Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 4-Con Engineering, Inc. BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name 1 411 l PASt}-+ w ( -Mk) �XZ . Business Address FbnjTP4WH CA 14 Z3 3 y City, State Zip (9.b9 ) 42.-) - L(1-i Telephone Number State Contractor's License No. and Class -LA- 30-tq97 Original Date Issued L� — 3 Z> - 2-00 -'— Expiration Date The work site was inspected by&j�4jb_T ;�tdpf our office on I-?-- 1 — , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: q -(°OV-) 1✓A)61 N6QLt-) r C-9 4-Con Engineering, Inc. The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Company Name Signa of Bidder Printed or Typed Signature �r Subscribed and sworn to before me this ,� day of �� e , 2000. R• CwM*don ♦ I ti99Ss Z Norary Pyyft • Cdb►Mo UX VPAycornm. sow im M 2002 9 NOTARY PUBLIC NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has, performed similar work within the past two years: 5Ez--- 1. 2. 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Date Completed Date Completed C-10 4-Con Engineering, Inc. P.O. Box 2217 Fontana, CA 92334-2217 -- Project List -- Phone (909) 427-1177 ... Fax (909) 427-1562 JOB No. NAME AGENCY CONTACT PHONE PERCENT COMPLETED1 I CONTRACT VALUES DATES ' ORIGINAL FINAL START FINISH PCO01 Lincoln Ave. Coyote Creek Bridge Retrofit City of Cypress Kamren Dadbeh (714) 229-6456 100.0% 175,576 196,755 09/03/98 11/04/98 PCO02 Edmondson Alley Reconstruction City of Pasadena George Martinez (626) 744-3842 100.0% 198,862 211,224 10/02/98 12/1.2/98 PCO03 Valencia Park Picnic Area City of Fullerton Eliseo Bravo (714) 738-5348 100.0% 61,993 63,101 11/02/98 12/15/98 PCO04 Alley No. 77 Storm Drain Repair & Iowa Street Drain Improvements City of Costa Mesa Tom Banks (714) 758-5222 100.0% 99,860 106,913 12/07/98 12/21/98 PCO05 Street Improvements Spruce & Blaine (Schedule A) City of Riverside Karl Mosby (909) 782-5346 100.0% 55,734 67,201 11/30/98 01/22/99 PCO06 On -Site and Off -Site Improvements on Ramona Blvd. and Cogswell Rd. City of El Monte Kev Tcharkhoutian (626) 580-2056 100.0% 173,205 209,460 12/07/98 02/01/99 PCO07 San Jose Creek Water Reclamation Plant - East Stoplog Storage Structure Los Angeles County Sanitation District Samuel Espinoza (323) 283-0881 100.0% 121,850 122,450 01/12/99 05/20/99 PCO08 Construction of 43 Curb Ramps at Various Locations Throughout the City City of Fountain Valley Bob Kellison (714) 593-4517 100.0% 30,837 34,527 02/23/99 03/16/99 PCO09 Pepper Street San Bernardino County Jerry Ivy (909) 387-2800 100.0% 83,583 84,797 03/15/99 04/12/99 PCO10 Del Amo Blvd. Over Compton Creek L.A. County Dept. of Public Works Neil Menuwaria (818) 458-4953 100.0% 45,260 41,076 03/25/99 04/07/99 PC011 Wash Water Recycling Facility City of Ontario Dennis N. Watson (909) 391-2507 100.0% 124,969 134,529 04/05/99 05/21/99 PCO13 Ronald Regan & Heritage Park City of Diamond Bar Bob Rose (909) 860-3195 100.0% 373,378 386,511 04/09/99 07/15/99 PCO14 Garvey Park Pool Renovation City of Rosemead Ron Bravo (310) 370-6724 100.0% 204,153 226,157 04/08/99 07/09/99 PCO15 Corona Skate Paris City of Corona Jonathan Jones (909) 279-2241 100.0% 196,000 223,976 06/08/99 08/20/99 PCO16 Hook -East & West Debris Basin Enlargement in Glendora L.A. County Dept. of Public Works Primo Candia (626) 447-5362 100.0% 229,195 241,174 07/12/99 09/24/99 PCO17 Franklin Ave. Drian in the City of Pomona L.A. County Dept. of Public Works Primo Candia (626) 447-5362 100.0% 155,815 186,687 09/20/99 12/20/99 PCO18 Rehabilitation of the Nature Trail City of Fountain Valley Bob Kellison (714) 593-4517 100.0% 245,664 302,805 08/16/99 _ 03/24/00 PCO19 Two Bridge Seismic Retrofit San Bernardino County Transportation Dept. Jerry Ivy (909) 387-2800 100.0% 112,158 118,249 08/31/99 10/25/99 PCO20 Indian Ave. Overhead Seismic City of Palm Springs Marcus Fuller (760) 323-5253 100.0% 186,462 212,898 10/26/99 01/26/00 PCO21 Terry Road Storm Drain City of Laguna Beach Lisa Penna (949) 497-0711 100.0% 145,208 180,521 11/29/99 02/08/00 PCO22 Skate Park at Harvard Athletic Park City of Irvine Douglas Davidson (949) 724-6675 100.0% 642,068 670,761 01/03/00 06/15/00 PCO23 Rio Hondo Park Rehabilitation Site Work City of Pico Rivera Juan Balanay (562) 801-4415 100.0% 82,400 100,077 06/12/00 07/25/00 PCO24 Jaboneria/Shull Park Improvements City of Bell Gardens Bill Pagett (562) 806-7770 99.9% 587,047 620,868 03/06/00 PCO25 Skate Park at Peterson Park City of Diamond Bar Bob Rose (909) 860-3195 100.0% 282,884 311,162 04/10/00 10/04/00 PCO26 THeritage Trail Bikeway Project I City of Palm Springs Marcus Fuller P.E. (760) 323-5253 1 990%1 873,781 1 05/22/00 File: Project List.xls Page 1 of 2 4-Con Engineering, Inc. P.O. Box 2217 Fontana, CA 92334-2217 -- Project List -- Phone (909) 427-1177 . Fax (909) 427-1562 JOB No. NAME AGENCY CONTACT PHONE PERCENT COMPLETED CONTRACT VALUES DATES ORIGINAL FINAL START FINISH PCO27 Beverly Blvd. Over San gabriel River; Cash Contract 8344 L.A. County Dept. of Public Works Jolene Guerrero (626) 458-3137 66.0% 669,423 07/07/00 PCO28 Seismic Retrofit of Brea Blvd. Bridges 1 & 2 (Nos. 55C-0123 & 55C-0122) Over Brea Creek Orange County PF&R Department Gerald Shubert (714) 567-7795 22.0% 411,210 10/04/00 PCO29 Hermosa Ave. Storm Drain and Street Improvements City of Rancho Cucamonga Jerry Dyer (909) 427-2740 100.0% 61,326 61,326 10/16/00 11/17/00 PC030 Dale Page Park Improvements, and Ford and Sneary Parkettes Improvements City of Redondo Beach Thomas Baldwin (310) 318-0661 Award Pending 151,800 PC031 Storm Drain Improvements at Holt Blvd. City of Ontario (909) 395-2025 Award Pending 151,157 File: Project List.xls Page 2 of 2 I (CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK February 27 ,2001 To: KEC Engineering P.O. Box 909 Corona, CA 92878-0909 Enclosed please find your original bid bond issued by Safeco Insurance Co. of America for Intrepid Lane Storm Drain - cc no. 1139 L� OW411 7- Connie Brockway, CIVIC City Clerk Enclosure g:/followup/cashcon/retumbidbond.doc ( Telephone: 714-536.5227 ) Ea SA+ECO` BID BOND KNOW ALL BY THESE PRESENTS, That we, KEC ENGINEERING of P.O. BOX 909, CORONA, CA 92878-0909 as Principal, and SAFECO INSURANCE COMPANY OF AMERICA MILLENNIUM CORPORATE PARK BLDG. C 18400 NE UNION HILL ROAD REDMOND, WA 98052 (hereinafter called the Principal), (hereinafter called the Surety), as Surety are held and firmly bound unto CITY OF HUNTINGTON BEACH (hereinafter called the Obligee) in the penal sum of Ten Percent of Bid Amount ---------------------------------- ----------------------------------------------------- Dollars($ 10%of Bid Amount ) for the payment of which the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That WHEREAS, the Principal has submitted or is about to submit a proposal to the Obligee on a contract for INTREPID LANE STORM DRAIN FROM REMORA DRIVE TO BROADWAY CASH CONTRACT NO. 1139 NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within such time as may be specified, enter into the Contract in writing, and give bond, if bond is required, with surety acceptable to the Obligee for the faithful performance of the said Contract, then this obligation shall be void; otherwise to remain in full force and effect. Signed and sealed this day of December , 2000 Witness Witness KEC ENGINEERING (Seal) Principal Vle� (JSe51C-Title SAFECO INSURANCE COMPANY OF AMERICA By SE BE "NE TAttorney-in-Fact S-0053/SAEF 10/99 0 Registered trademark of SAFECO Corporation. State of California NOTARY ACKNOWLEDGMENT County of Orange On December 1, 2000 before me, Erika A. Nicholas , Notary (Date) (Name/Title - Notary Public) personally appeared Denise Bennett ® personally known to me - OR - ❑ OFFICIAL SEAL pNy ERIKA A. NICHOLAS NOTARY PUBLIC -CALIFORMA COMMISSION COUN � lIq►CNIMOSWO EV. M&Tk tt.10" CAPACITY CLAIMED BY SIGNERS) ❑ INDIVIDUAL ❑ CORPORATE ❑ OFFICER(S) _ (Title) ❑ PARTNERS(S) LIMITED GENERAL ® ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/tee subscribed to the within instrument and acknowledged to me that he/she%he} executed the same in hi-s/her4he4 authorized capacity(ies), and that by hi-Aer/4teif signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. OPTIONAL INFORMATION Witness my hand and official seal. (Signature of Notary) �'�,� S A f E C O" POWER � u. OF ATTORNEY KNOW ALL BY THESE PRESENTS: SAFECO INSURANCE COMPANY OF AMERICA GENERAL INSURANCE COMPANY OF AMERICA HOME OFFICE: SAFECO PLAZA SEATTLE, WASHINGTON 98185 No. 10031 That SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA, each a Washington corporation, does each hereby appoint ********+***********DENISE BENNETT; Tustin, its true and lawful attorney(s)-in-fact, with full authority to execute on its behalf fidelity and surety bonds or undertakings and other documents of a similar character issued in the course of its businesg, and to bind the respective company thereby. IN WITNESS WHEREOF, SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA have each executed and attested these presents this 10th R.A. PIERSON, SECRETARY CERTIFICATE day of June k), 4MO4&49� W. RANDALL STODDARD, PRESIDENT Extract from the By -Laws of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA: 1999 "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attomeys-in-fad or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 13 of the By -Laws, and (ii) A copy of the power-of-attomey appointment, executed pursuant thereto, and (iii) Certifying that said power-of-attomey appointment is in full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, R.A. Pierson, Secretary of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By -Laws and of a Resolution of the Board of Directors of these corporations, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both the By -Laws, the Resolution and the Power of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation this 1st ffli-�F (WRM SEAL w SEAL 1953 W i day of December . 2000 R.A. PIERSON, SECRETARY S-0974/SAEF 7/98 0 Registered trademark of SAFECO Corporation. 6/10/99 PDF KEO ENNNEERING UJ" TO: City of Huntington Beach City Clerk 2000 Main Street, 2nd Floor Huntington Beach, Calif. 92648 1 Project: " Intrepid Lane Storm Drain Cash Contract # 113911 Bid Date: 12/5/00 2:00pm UJ" TO: City of Huntington Beach City Clerk 2000 Main Street, 2nd Floor Huntington Beach, Calif. 92648 1 Project: " Intrepid Lane Storm Drain Cash Contract # 113911 Bid Date: 12/5/00 2:00pm SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. a Accompanying this proposal of bid, find & A,"5 �j in the amount of $ toryd which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum Date Received Bidder's Signature. No. C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ Dollars k1 a --------Gents 2 1 Traffic Control $2,000 $2,000 L.S. @ 1 w o 'T'-�6o� �,.� o —Dollars M d -gents 3 1 Trench Shoring L.S. @ F7 —Dollars �lC,�p 05 SoOCS --- k/,, Cents 4 889 18" HDPE Storm Drain Pipe L.F. @ 6-t(.H�'rIt �� v c ----------Dollars Ad ents t 5 238 4" HDPE Storm Drain Pipe L.F. @ -' Dollars 70 -2- 1). tit d Cents 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each �sLEc 14%_9&EpszcD �cv�=��%Y-Dollars �© -3 70 lD -73v�o !% a -Cents ' 7 20 Concrete Channel Backfill C.Y. E(GH- -e— Dollars 56- AJ c ---Cents 8 2 Tideflex Gate Valve, Series 37G Each Dollars bC�,_ j �/ OOp bo Cents 9 3 Junction Structure - Type D CZ� ISO Each @ Fo rL' -T --`Dollars ��! p oo` l Z/Dog — ti10 rents 10 2 Abandon Existing Lateral Each @ ota&tcco-1ZjE--vr-e—Dollars G2� ZYv ^o 11 30 Sawcut Local Depression CX> L.F. @ —_7Z e,.r r e Fi ,,--Dollars ZSr�`' -7 9c h10 Cents 12 30 Reconstruct Concrete U-Channel L.F. @ r�H Y -Dollars oc � ti(n----Eents Total Amount Bid in Figures: $ / S 3 . 7d 5' _ Total Amount Bid in Words:,�� C-Is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontrdctor -State License Cass Of " Number. Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange �_ i , Nz , bein first duly sworn, deposes and says that®or she is 60 s 1 d aAc ,+ of C J�((',- l N �� (' / N(�- the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. t�F,C F I1 G-1 A/E ck21 Al e- Name of Bidder Si nature of Bidder �It' e- Pies i d e4L: Address of Bidder Subscribed and sworn to before me this 0 'day of ,E�, , , 2000 . CLAUDETTE MARIE NEICE COMM. #1233440 cr NOTARY pV®i_�C , CALIFORNIA p!%;rrjg;�r. COUNTY My Comm.. UDirw August 99, 2003 NOTARY PUBLIC (LL�1��= NOTARY SEAL C-4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Riverside ss. On December 4, 2000 before me, Claudette Marie Neice, Notary Public Date Name and Title of Officer (e.g., "Jane Doe, Notary Public") personally appeared Leslie R. Card CLAUDETTE MARIE NEICE in : COMM. #1233440 m NOTARY PUBLIC -CALIFORNIA N RIVERSIDE COUNTY My Comm. Expires August 29, 2003 Place Notary Seal Above Names) of Signer(s) . 7f� personally known to me ❑ proved to me on the basis of satisfactory evidence to be the persons) whose name(s) is/are subscribed to the within instrument and acknowledged tome that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. S my hannd official seal. 1 Signature of OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: ❑ Individual Top of thumb here ❑ Corporate Officer — Title(s): C Partner — ❑ Limited C General C Attorney in Fact Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 0 1997 National Notary Association - 9350 De Soto Ave., P.O. Box 2402 - Chatsworth, CA 91313-2402 Prod. No. 5907 Reorder: Call Toll -Free 1-800-876-6827 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned fiu-ther promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: `ZI 41 Da L 6 ►VG- I NQ_k e- i ffa- Contractor V► � e_ ��e� 1 d Title C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes R�No If the answer is yes, explain the circumstances in the space provided. N 6 Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 1114 /00 k-E C- E A/P, I A/C E P— I A/0, Contractor P�e-sj d le4L.+ Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Contractor go Title Date: Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: ,AFC E-/VG- I IVl- , k I ff Bidder Name Business Address 0 City, State Zip 467) 17.34-31)J6 Telephone Number 1v1 /1 n If State Contractor's License No. and Class /at, ME Original Date Issued )]z161 Expiration Date The work site was inspected by c/—Gg of our office on / / — 30 , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: C-9 KEC ENGINEERING CERTIFICATION STATE OF CALIFORNIA ) SS: COUNTY OF RIVERSIDE ) I HEREBY CERTIFY that at a meeting of the Board of Directors of KEC Engineering, a corporation existing under the laws of the State of California, held of June 16, 2000, the following resolution was duly passed and adopted: "RESOLVED, that the following officers: James Elfring, President Leslie R. Card, Vice -President Matthew Card, Vice -President Scott Pfeiffer, Vice -President Timothy J. Stephens, Secretary & C.F.O. of the Corporation are hereby authorized to execute bid documents submitted by this corporation, and any such execution shall be an official act and deed of this Corporation". I further certify that said resolution is now in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the official seal of the corporation this 16th day of June, 2000. orpora ecretary The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. KCf E N0l /AI -=E MG Company Name Signature"of Bidder /e,s /i e- � . Oa,,� d - Via e. Om d &4 Printed or Typed Signature Subscribed and sworn to before me this4' 'day of , 2000 . NOTARY PUBLIC • CLAUDETTE MAR" N"" COR4M.#1233440 ® NOTARY'UBLIC - CALIFORNIA I"�'�RSIUE COUNTY My Comm. _.'i s August 29, 2003 NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. ''do, J----1 I Name and Address of Public Agency 2. 0 Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Date Completed Date Completed C-I 0 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Riverside ss. On December 4, 2000 before me, Claudette Marie Neice, Notary Public Date - Name and Title of Officer (e.g., "Jane Doe, Notary Public") personally appeared Lie g i i P R Cn rd Name(s) of Signer(s) • , CLAUDETTE MARIE NEICE cC COMM. #1233440 �o Ix NOTARY PUBLIC - CALIFORNIA RIVERSIDE COUNTY My Comm. Expiros August 29, 2003 Place Notary Seal Above ftpersonally known to me ❑ proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. N,�SS my h5nd and official seal. of Notary OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: ❑ Individual Top of thumb here ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee Guardian or Conservator ❑ Other: Signer Is Representing: 0 1997 National Notary Association • 9350 De Soto Ave., P.O. Box 2402 • Chatsworth, CA 91313-2402 Prod. No. 5907 Reorder: Call Toll -Free 1-800-876-6827 200 N. SHERMAN AVENUE CORONA, CALIFORNIA 91720 -MAILING: P.O. BOX 909 CORONA. CALIFORNIA 91718 CORONA (909) 734-3010 - LOS ANGELES (323) 774-2282 - ORANGE COUNTY (949) 768-4411 FAX (909) 735-2041 - ESTIMATING FAX (909) 734-7987 . . . general engineering contractors REFERENCE LIST List of at least five Construction Projects similar in size, scope and cost to the project defined in the specifications: Irvine Community Development Co. (Proj. No: 1895-02) Peters Cyn between Jamboree & Culver Irvine Project No: 98-020 Lower Peters Cyn, Sectors 8 & 11 Norm Burch (949) 654-2608, Keith Silhaugh (949) 654-2604 Industry Urban Development Agency Old Ranch Road & Grand Avenue. Industry Project No: 98-005 Old Ranch Road Job. Gerry Perez 626-333-0336 Riverside County Flood Control District San Sevaine Channel Between Etiwanda & Country Village, Riverside, County Project No: 98-035 San Sevaine Job Clyde Johnson (909) 955-1288 Los Angeles County Sanitation District JOD Sepulveda & Figueroa, JOJ Senator St. & Lomita, JOH Downey Between Bandini & Washington Project No: JOD-97-090, JOJ-99-010, JOH-99-025 John Joyce- (323) 775-2351, Walter Ackerman Pager (562) 602-9761 Los Angeles County Department of Public Works Crenshaw -Western Gardena Project No: 99-020 Byron Rexwinkle (626) 458-3125 REFERENCE JOB LIST YEAR DESCRIPTION 1998 Old Ranch Rd./G 1998 Marshburn Retarding Basin 1998 Rattlesnake Reservoir Spillway 1998 Lower Peters Canyon-Sec.8111 1998 Joint Pollution Plant/Venturi Pits 1998 Portola Parkway 1998 San Sevain Channel 1998 Barranca/Valley Oak Bridge 1998 L.A.River Improvements 1998 Imperial Highway 1998 Hemet Line "B" 1999 Carlsburg Ranch 1999 Joint Outfall J 1999 Katella Ave., Phase II 1999 HollyPark Storm Drain 1999 Joint Outfall "H" 2H 1999 San Jose Creek Access Ramp 1999 Morrow Reservoir 1999 Santa Monia/Ocean Ave. Sewer 1999 South Gate Storm Drain 1999 Fallbrook Golf Course 2000 Foothill Blvd. 2000 Alameda Corridor 2000 Ball Road Corridor Improvements 2000 Costco Wholesale Plaza 2000 Central Avenue Bridge 2000 No. Norco Channel Invert Repair CONTRACTS LOCATION OWNER/AGENCY 8,348,583 Industry 1,800,000 Tustin 115,600 Irvine 3,499,972 Irvine 126,000 Carson 180,080 Irvine 2,272,860 Riverside/Fontana 2,095,636 Irvine 6,118,036 Los Angeles 197,520 Anaheim 98,080 Hemet 430,000 Moorpark 2,848,550 Lomita 5,189,320 Anaheim 5,930,427 Gardina 844,100 Vernon 561767 49840 Rainbow 6766440 Santa Monica 75000 South Gate 47000 Rainbow 7036520 R-Cucamonga 3,687,378 Los Angeles 2,040,930 Anaheim 606,200 Hawthorne 2,052,140 Chino 63,906 Riverside City of Industry Silverado Constr'n Irvine Ranch Water Irvine Comm. Deve. LACSD Griffith Co. Rvsd Co. Flood Co. C.A. Rasmussen Ortiz Enterprises Hillcrest Contracting Gueno Development Simi-Conejo Constr'n LACSD City of Anaheim Army Corps of Engineers LACSD LACDPW Rainbow Municipal W. D. City of Santa Monica City of South Gate Rainbow Municipal W. D. City of Rancho Cucamonga Tutor -Saliba Corporation City of Anaheim Ferguson Construction Sukut Construction, Inc. Riverside Cnty. Flood Control REFERENCE JOB LIST YEAR DESCRIPTION CONTRACTS LOCATION OWNER/AGENCY 1994 Renforced Concrete Box 710,000 Norwalk C.K. Construction 1994 Channel Invert Repair 2,177,587 San Dimas LACPW 1994 Channel Improvements 539,880 Irvine Foothill Ranch 1994 Structural Concrete 5,000,000 Santa Ana C.R. Rasmussen 1994 PCC/LBC Pavement 1,314,000 91 Fwy/55Fwy Granite Construction 1994 Open Channel 1,317,433 Brea OCEMA 1994 Sewer Slip/Lining 2,768,010 Long Beach LACSO 1994 Effluent Treatment/Wetlands 1,472,992 Riverside City of Riverside 1994 Storm Drain/RCP 49,294 Laguna Niguel El Niguel C.C. 1995 Storm Drain/Open Channel 3,235,555 Rancho Cucamonga RCDA 1995 Backland Improvements 2,878,758 San Pedro Shawnan Corp. 1995 Storm Drain 3,592,415 Carson LACPW 1995 Bldg. Expansion/Parking Lot 333,168 Costa Mesa Snyder Langston 1995 Bridge Retrofit 100,000 Santa Ana CBPO 1995 Monterey Ave./Cook St. 580,000 Palm Desert E.L. Yeager 1995 Inglewood Truck Sewer 409,433 Inglewood LACSD 1,995 Anaheim St. Trunk Sewer 2,189,660 Long Beach LACSD 1995 Desilting Basin Cleanout 150,096 Yorba Linda City of Yorba Linda 1995 Trench Restoration 147,930 Carson So. Ca Gas Co. 1996 Hicks/E.Hicks Canyon Ret. Bas. 2,559,000 Irvine C.A. Rasmussen 1996 105 Fwy Emergency S.D. Repair 5,000,000 Downey CALTRANS 1996 San Joaquin Hill Transp. Corridor 79,378 Irvine CA Corridor Cons't 1996 Palm Springs Storm Drain 800,000 Pam Springs Rvsd Co. Flood Con 1996 Ontario Airport RCB 356,420 Ontario E.L. Yeager 1996 Joint Outfall H, Unit 1 B 582,010 Paramount LACSD 1996 Rossmoor Channel 570,459 Orange County OCEMA 1996 Concrete Barriers, Railing 179,360 Santa Fe Springs LACPW 1996 Harbor Blvd. Improvements 848,670 Anaheim Sequel Contractors 1997 Front Street Improvements 4,098,840 Burbank City of Burbank 1997 Route 91 Box Culvert 6,000,000 Placentia E.L. Yeager 1997 Rivo Alto Channel Sewer 211,000 Long Beach LB Water Comm. 1997 Washington Blvd. Streetscape 320,000 Culver City Sequel Contractors 1997 Pier A Misc. Concrete 1,000,000 Port of LA Kiewitt Pacific 1997 Talbert Channel 3,909,148 Huntington Beach OCFC 1997 Ball Road Sewer Relocation 3,786,574 Anaheim City of Anaheim 1997 Lower Peters Canyon-RCB 2,249,403 Irvine Irvine Co. 1997 Peters Canyon Wash 2,171,000 Irvine Griffith Co. 1997 "1" Ave. Rd. Reconstruction 591,000 Hesperia Cooley Cons't 1997 Upper Peters Canyon-RCB 302,781 Irvine Silverado Cons't 1997 OSO Segment 1 - RCB 501,737 Irvine Silverado Cons't 1997 Whites Point Pumping Plant 162,010 Palos Verdes LACSD 1997 Bear Creek Golf Course 99,298 Murrieta Bear Cr. Golf Course 1997 San Gabriel River Cleanout 844,000 Pico Rivera LACPW 1997 Katella Ave. Street Improvements 2,796,540 Anaheim Sequel Contractors 1997 Joint Outfall "D" Sewer 2,910,305 Carson LACSD CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK FEbruary 27 ,2001 To: Atlas -Allied, Inc. 1210 N. Las Brisas Anaheim, CA 92806-1823 Enclosed please find your original bid bond issued by Fidelity and Deposit Co. of Maryland Connie Brockway, CIVIC City Clerk Enclosure for Intrepid Lane Storm Drain cc no. 1139 g Jfollowup/cashcon/returnbidbond.doc ___ (Telephone: 714536-5227) THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, that we Atlas -Allied, Inc. 1210 N. Las Brisas Anaheim, CA 92806 as Principal, hereinafter called the Principal, and Fidelity and Deposit Company of Maryland 225 S. Lake Ave., Ste. 700 Pasadena, CA 91101 a corporation duly organized under the laws of the State of Maryland as Surety, hereinafter called the Surety, are held and firmly bound unto City of Huntington Beach as Obligee, hereinafter called the Obligee, in the sum of Ten Percent of the Total Amount Bid Dollars ($10%), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for Intrepid Lane Storm Drain From Remora Drive to Broadway - Cash Contract No. 1139 NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the Prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specked in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 1st day of December, 2000 1 RACC AIA DOCUMER7"A310 . BID BOND • AIA • FEBRUARY 1970 ED . THE AMERICAt INSTITUTE OF ARCHITECTS, 1735, N.Y. AVE., N.W., WASHINGTON, D.C. 20006 Atlas -Allied, Inc. J.W. Johnson, Attorney -in -fact CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California SS. County of Orange On _ DECEMBER 1, 2000 , before me, BRAD L. SETTGAST, NOTARY PUBLIC Date Name and Tine of Officer (e.g., 'Jane Doe, Notary Public') personally appeared J.W. Johnson Name(s) of Signer(s) IN personally known to me ❑ proved to me on the basis of satisfactory evidence a BRAD L.SGAST COMMISSION#125358a VotaryPublic-CaliforniA ORANGECOUNTY 4 Comm"onExpires FEaRUARY14, 2W4 Place Notary Seal Above to be the person) whose name(§0 is/XMK subscribed to the within instrument and acknowledged to me that he/ )M executed the same in hiS11t%UUM authorized capacity , and that by his/KKKN & signature(go on the instrument the person", or the entity upon behalf of which the person(C acted, executed kie inslument. TN Public Though the information below is not required by law, it may prove valuable persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Bond Document Date: DECEMBER 1, 20000 Number of Pages: 1 Signer(s) Other Than Named Above: ATLAS -ALLIED, INC. Capacity(ies) Claimed by Signer Signer's Name: J.W. JOHNSON VIEW_ ❑ Individual Top of thumb here. ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General (N Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Fidelity and Deposit Company of Maryland 0 1999 National Notary Association - 9350 De Soto Ave.. P.O. Box 2402 - Chatsworth, CA 91313.2402 - www naticnalnotary.ofg Prod. No. 5907 Reorder. Call Toll -Free 1.800-876-6827 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE: P.O. BOX 1227, BALTIMORE, MD 21203-1227 Know ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by W. B. WALBRECHER, Vice -President, and T. E. SMITH, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full a and effe the date hereof, does hereby nominate, constitute and appoint J. W. Johnson, of Fullerton, Cali , its true wful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and on its behalf as sure as its a deed: any and all bonds and undertakings and the execution of such bonds or undertakings in pu a of the ents, shall be as binding upon said Company, as fully and amply, to all intents and purposes, as if th been d cuted and acknowledged by the regularly elected officers of the Company at its office in Baltimor �., in their proper persons. This power of attorney revokes that issued on behalf of J. W. Johnson, dated Janu998. The said Assistant Secretary does hereb ify that tfact set forth on the reverse side hereof is a true copy of Article VI, Section 2, of the By -Laws of s mpany, now in force. IN WITNESS WHEREOF, the said eside Assistant Secretary have hereunto subscribed their names and affixed the Corporate Seal of the s�F DELIT DEPOSIT COMPANY OF MARYLAND, this 19th day of November, A.D. 1999.. �Q ATTEST: FIDELIT SIT COMPANY OF MARYLAND a� SF Q Q Lt�I�CC� �.,... �;�. By. T. E. Smith Assistant Secretary W. B. Walbrecher Vice -President State of Maryland SS: County of Baltimore On this 19th day of November, A.D. 1999, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came W. B. Walbrecher, Vice -President and T. E. Smith, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. c� Carol J. FapVr Notary Public My Commissi Expires: August 1, 2000 L1428-012-4152 A INC. Atlas -Allied, Inc. 1210 N. Las Brisas Anaheim, Ca 92806-1823 L PROJECT:- -Intrepid Lane Cash Contract No 1139 BID DATE: 12/5/00 BID TIME: 2:00 PM CITY OF HUNTINGTON BEACH CITY CLERK, Second Floor 2000 Main Street Huntington Beach, CA 92648 714 536-5431 (-n 13 SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days .from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ -rkp °e TMoWb A N p Dollars NO Cents 2 1 L.S. Traffic Control @ -TWo T'IOUSAN ID Dollars $2,000 $2,000 o G Cents 3 1 L.S. Trench Shoring @ M.EveN Tb 0USANp F(v a Dollars 1 11500, cc S ob N-44DW17 ' * No Cents 4 889 L.F. 18" HDPE Storm Drain Pipe @ ONE'' 140DAOD Zigk+eeN Dollars a•00 0%� 9 02 L.F. NC Cents 5 238 L.F. 4" HOPE Storm Drain Pipe @ 571, )L+- Fi y B Dollars �L:F° 15, 470.00 11 c Cents 6 29 Each 5"x 20" NDS Channel Drain #810 with #816 Grate @ 'Two lrlur4Pa4?0 51,Xt Dollars Z�oO• co A` ' `75ya00 A N o Cents 7 20 C.Y. Concrete Channel Backfill @ '('wo TWA p 2ep Fi•Fty Dollars *ZS0• 0 0 5, 000. 00 NO I Cents G •y 8 2 Each Tideflex Gate Valve, Series 37G @ Fi 0 LTk0VSA Np 9f1hI NVOMP Dollars y� A oC 91000. 00 f No Cents 9 3 Each Junction Structure — Type D @ Tviaee Th04AWP-r4jo HyN0RE0 Dollars 3ZO0' oc q�0� • Go A . $ No Cents 10 2 Each Abandon Existing Lateral @ 542YLEIN R VNDR.CO Fi F+ Dollars %5a• 00 j SOO . CO EA• ! IJ o Cents 11 30 L.F. Sawcut Local Depression @ f i Ft f i �Vr Dollars L,F it 1040 Cents 12 30 L.F. Reconstruct Concrete U-Channel @ i F+- V Wr Dollars ' S8• CC 1..F• ii yip • O 0 o Cents 'A tic) C-1 s If awarded, the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. BIDDERS 10% OF THE TOTAL Accompanying this proposal of bid, find BOND in the amount of $ BID AMOUNT which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum - No. Date Received Bidder's Signature NONE C-2 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class Of ;1Vumber Work NONE By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange Eva Siciliani , being first duly sworn, deposes and says that he or she is Secretary/Treasurer of Atlas --Allied, Inc. the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Eva Siciliani - Secretary / Treasuer Name of Bidder Signature of Bidder 1210 N. Las Brisas, Anaheim, CA., 92806 Address of Bidder Subscribed and sworn to before me this day of 52000 . **SEE ATTACHED NOTARY ACKNOWLEDGEMENT NOTARY PUBLIC NOTARY SEAL C-4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Orange On December 5, 2000 before me, Nile R. Sensabaug_h — Notary Public , DATE NAME, TITLE OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC" personally appeared Eva Siciliani -- Secreatry/Treasurer , NAME(S) OF SIGNER(S) personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence to be the person*) whose namets) is/ subscribed to the within instrument and ac- knowledged to me that ±mVshe&n executed the same in hjWher&mk authorized capacity(), and. that by /her/tx signature(s) on the instrument the person(W, or the entity upon behalf of which the person(a) acted, executed the instrument. NILE R. SENSABAUGH WITNESS m hand and official seal. CommA 1283M5 y �q NOTARY PUBLIC - CALIFORNIA j - - ORANGE COUNTY My Comm. EXW- Mara h G. soon SIGNATURE OF NOTARY OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL EX CORPORATE OFFICER Sec.— Trea . TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) Atlas —Allied, Inc. DESCRIPTION OF ATTACHED DOCUMENT NONCOLLUSION AFFIDAVIT TITLE OR TYPE OF DOCUMENT —1— NUMBER OF PAGES December 5, 2000 DATE OF DOCUMENT N.A. SIGNER(S) OTHER THAN NAMED ABOVE UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: 12-05-00 ATLAS ALLIED, INC. Contractor EVA SICILIANI , SECRETARY./ TREASURER Title C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes J No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 I COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 12/05/00 ATLAS -ALLIED, INC. Contractor EVA SICILIANI By SECRETARY / TREASURER Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Date: 11-05-00 TO BE ASSIGNED WHEN PROJECT IS AWARDED ALTAS-ALLIED, INC. Contractor EVA SICILIANI < By SECRETARY / TREASURER Title Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: ATLAS -ALLIED, INC. Bidder Name 1210 N. LAS BRISAS Business Address ANAHEIM, CA 92806 City, State Zip ( 714 ) 630 - 3633 Office Telephone Number 437235 A, B, C34, C36, and C42 State Contractor's License No. and Class April 7, 1983 Original Date Issued April 30, 2001 Expiration Date The work site was inspected by GEORGE SICILIANI of our office on 12/04/00 32000. The following are persons, firms, and corporations having a principal interest in this proposal: ALIAS -ALLIED, INC. GEORGE L_ STCTLTANT - PRESTDENT EVA SICILIAN - SECRETARY/TREASURER C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. ATLAS -ALLIED, INC. Company Name UISz`., December 5, 2000 Signature of Bidder Eva Siciliani Secretary / Treasurer Printed or Typed Signature Subscribed and sworn to before me this _ day of 52000. **SEE ATTACHED NOTARY ACKNOWLEDGEMENT NOTARY PUBLIC NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1 ** SEE ATTACHED REFERENCE SHEET ** 2. 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work C-10 Date Completed Date Completed Date Completed CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Orange On December 5, 2000 before me, Nile R. Sensabaugh - Notary Public , DATE NAME, TITLE OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC' personally appeared Eva Siciliani -- Secreatry/Treasurer , NAME(S) OF SIGNER(S) 93 personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence to be the person) whose names) is/ subscribed to the within instrument and ac- knowledged to me that±H3Vshe/AM executed the same in his/hers authorized capacity(), and. that by /her/fix signature(s) on the instrument the person(, or the entity upon behalf of which the person(g) acted, executed the instrument. NILE R. SENSABAUGH T Comm.#1253NS WITNESS my hand and official seal. CD NOTARY PUBLIC - CALIFORNIA j Q '++i ORANGE COUNTY My Comm. Expires march 8, 2004 SIGNATURE OF NOTARY OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL NX CORPORATE OFFICER Sec.- Trea. TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) Atlas -Allied, Inc. DESCRIPTION OF ATTACHED DOCUMENT BIDDER'S INFORMATION TITLE OR TYPE OF DOCUMENT - 2 - NUMBER OF PAGES December 5, 2000 DATE OF DOCUMENT N.A. SIGNER(S) OTHER THAN NAMED ABOVE (JIATLAS-ALLIED., INC. Pipeline General Piping 7 Engineering SINCE 1969 REFERENCE SHEET April 2000, City of Fullerton 303 W. commonwealth Ave Fullerton, Ca 92832 Eric Nunez 714-738-6845 Large Meter Upgrades $18,564.00 May 2000 Three Arch Bay District 5 Bay Drive Laguna Beach, Ca 92651 Greg Cohen 949-499-4567 Callecita Storm Drain Improvements $50,736.00 July 2000 City of Anaheim P O Box 322 Anaheim, Ca 92806 Dale MacIntosch 714-765-7156 Orange Ave 16" & 6" Main Relocation $35,948.00 October 2000 Whittier Union High School District 9401 S. Painter Ave. Whittier, CA 90605 Karl Schrader 562-698-8121 #1541 Main Water Pump Replacement @ Sierra Education Center $76,213.00 Julv 2000 County of Los Angeles 9001 S. Fremont Ave Alhambra, Ca 91803 Paul Keizer 626-458-3122 Ocean Outlet Modifications $406,773.99 Project No. 507, 513 & 7401 August 2000 State of California Dept Park & Recreation 3030 Avenida del Presidente San Clemente, CA 92672 Donna Renner 949-492-0802 Rehabilitate Water & Sewer System @ San Clemente State Park $909,022.57 June 2000 County of L. A. Dept P.W. 900 S. Freemont Ave Alhambra, CA 91803 Linda Tacconelli 626-458-3147 Alamitos Bay Pump Station $88,274.00 November 2000 Burbank Union High School District 1900 W. Olive Ave Burbank, CA 91506 Michael Maurizo 818-729-4461 #205 Sewer Relocation & Burbank H. S. $245,991.00 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE # 437235 ---An. k ATLAS ALLIED, INC. Pipeline General Piping Engineering SMCE 1964 REFERENCE SHEET July 1999 El Camino College 16007 Crenshaw Blvd. Torrance, CA. 90506 Bob Gann (310) 660-3693 Water Distribution System Contract Amount: $166,940.00 July 1999 Long Beach Transit District Steve Watt 562-591-8753 1963 E. Anaheim Street Long Beach, CA. 90801-0731 Project NO. LBT 99003 Stormwater/Wastewater Treatment Contract Amount $260,000.00 June1999 Barstow College The Addington Partnership Bob Varner 661-327-1690 Fire Loop System Contract Amount $230,000.00 September 1999 Rialto Unified School District 182 E. Walnut Ave Rialto, Ca 92376 John Boatman 909-684-4664 C/o Ruhmau Ruhmau Associates New Fire Hydrant at Eisenhower HS Contract Amount $13,774.00 September 1999 City of 303 W. Commonwealth Ave Fullerton, Ca 92832 Eric Nunez 714-738-6845 Storm Drain Improvements Contract Amount $ 26,025.00 September 1999 Mt. San Antonio College 1100 N. Grand Ave. Walnut, CA 91789 John Beckton 909-594-5611 C/o Bovis Construction Corp. Water main Replacement at Farm Area Contract Amount $187,565.00 December 1999 City of Seal Beach 211 Eighty Street 2°d Floor Seal Beach, Ca 90740-6379 Gary Tomasetti 562-799-4492 C/o CRSS Constructors Pier Water Line Improvements Contract Amount $61,091.94 October 1999 Coast Community College District 1370 Adams Avenue Costa Mesa, Ca 92626 Terry Craig 714-432-5990 Water Valve Replacement Contract Amount $98,624.00 1210 N. LAS BRISAS, ANAHEIM, CA92806 . TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE t# 437235 (fiATLAS-ALLIED, INC. Pipeline Generat Piping Engineering S/NC , 1969 REFERENCE SHEET March 1998 Orange County Sanitation District 10844 Ellis Avenue Fountain Valley, CA 92708 Dave Erdkamp (714) 962-2411 x6315 Reclaimed Water Extension to . Headworks "C" Plant No. 2 Contract Amount: $139,680.00 March 1998 California State University, Fullerton 800 N. State College Blvd Fullerton, CA Mr. Hyun Lim (714) 278-2349 T-Building Drainage Contract Amount: $27,037.00 March 1998 Coast Community College District 1370 Ad* Avenue Costa Mega, CA 92626 Ardith Ritchey Sidewalk Improvement at Parking Lot F At Oranges Coast College Contract mount: $10,965.00 June 199> Long Beach City College 4901 E. Carson Street Long Beach CA 90808 Oscar Trejo (562) 938-4072 Drain Improvements Contract Amount: $7,200.00 July 1998 City of Laguna Beach 505 Forest Avenue Laguna Beach, CA 92651 Steve May (949) 497-3311 *351 Lower Park Ave. Storm Drain Contract Amount: $455,497.00 August 1998 City of Cerritos 18125 Bloomfield Avenue Cerritos, CA. 90703-3130 Joe Holden (562) 860-0311 *2665 Design and Installation of Existing Sewer Lift. Station from Ejector Type To pump Lift Station, Project #1805 Contract Amount: $139,680.00 August 1998 Orange Coast College 2701 Fairview RD Costa Mesa, CA. 92626 Terry Craig (714) 438-4646 Sewer Line Replacement & Various other Projects Contract Amount: $113,455.00 September 1998 Midway City Eastside Water Association 14882 Jefferson Street Midway City, CA. 92655 Jim Curry (714) 893-7346 Distribution System Replacement Program, Phase V Contract Amount: $36,682.36 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE # 437235 ATLAS ALLIED, INC. PipelineIT General Piping Engineering SINCE 1969 REFERENCE SHEET August 1997 City of Irvine P.O. Box 19575 Irvine, CA 92623 Doug Davidson (714) 724-6000 Rehabilitation Heritage Community Park Lagoon Contract Amount: $89,470.39 August 1997 Santa Ana Unified School District 1601 E. Chestnut Ave Santa Ana, CA 92701 Richard Murray (714) 558-5501 Repl. of Storm & Sewage 54" & 48" System @ Wilson Elementary School Contract Amount: $53,065.30 August 1997 Los Angeles Metro Transit Authority One Gateway Plaza. Los Angeles, CA 90012 Paras Sharma (213) 922-6000 Fire Hydrant Replacement @ Division 16 Venice, CA Contract Amount: $21,160.00 September 1997 Los Angeles Metro Transit Authority One Gateway Plaza. Los Angeles, CA 90012 Paras Sharma (213) 922-6000 Motor Oil Supply System @ Division 18 Carson, CA Contract Amount: $114,376.00 September 1997 Orange County Transit Authority 550 S. Main Street Orange, CA 92863 Steve Levine (714) 560-6282 On -Site Gas Piping Relocation Contract Amount: $21,274.15 November 1997 City of Newport Beach 3300 Newport Blvd. Newport Beach, CA 92663 Pete Antista (714) 718-3400 Big Canyon Reservoir 48" & 54" Piping Modifications & Valve Replacements Contract Amount: $174,600.00 November 1997 City of La Habra Heights 1245 N. Hacienda Blvd La Habra, CA 90631 In Care of RKA Engineering Dave Gilbertson (626) 331-8323 Drainage Improvements @ Locations Various Contract Amount: $110,975.06 December 1997 City of San Clemente 1 Avenida Presidio San Clemente, CA 92673 Gary Vorborsky (949) 361-6132 Calle Vallarta Storm Drain Contract Amount: $46,219.00 1210 N: LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE # 437235 A". ATLAS ALLIED, INC. Pipeline General Piping Engineering SINCE 1969 REFERENCE SHEET December 1996 California State University, Fullerton 800 N. State College Blvd. Fullerton, CA 92634 Mr. Hyun K. Lim (714) 278-2349 Sewerline Construction Contract Amount: $31,411.00 February 1997 Long Beach City College District 4901 E. Carson Street Long Beach, CA 90808 Ali Izadian (562) 938-4111 Water Main Replacement Contract Amount: $54,449.00 April 1997 Capistrano Valley Water District 32450 Paseo Adelanto San Juan Capistrano, CA 92670 Eric Bauman (714) 493-1515 Glenfed Main Supply Line Contract Amount: $13,559.00 April 1997 La Habra Fire Protection 941 Macy Street La Habra, CA 90631 Terry Kennedy (310) 694-2948 6" Fire Protection Upgrade Hacienda Country Club Contract Amount: $13,403.00 April 1997 Frame-N-Lens 4201 Bonita Avenue Fullerton, CA 92835 Brent Saul Water Line Improvements Contract Amount: $34,756.00 May 1997 Long Beach City College 4901 E. Carson Street Long Beach, CA 90808 Ali Izadian (562) 938-4111 Installation of Secondary Containment Barrier @ Liberal Arts Campus Contract Amount: $23,029.00 May 1997 Tavaglione Construction 3405 Arlington Avenuek Riverside, CA 92504 Ray Tavaglione (909) 684-8870 Piping @ Boston Market Contract Amount: $9,900.00 .Tune 1997 County of Los Angeles Department of Public Works 1000 S. Freemont Avenue 5t' Floor Alhambra, CA 91803-4737 Nicholas Kozma. (626) 458-2523 South Campus Utility Reroute Project Rancho Los Amigos Medical Center Contract Amount: $ 481,175.00 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE # 437235 ATLAS ALLIED, INC. Pipeline General Piping Engineering SINCE 1969 REFERENCE SHEET January 1996 El Monte Union High School District C/O G&A Engineering Atta Alsaleh (818) 852-4779 Storm Drain Pump Station & 16" Discharge Pipeline Contract Amount: $275,000.00 February 1996 Burbank/Glendale/Pasadena Airport 2627 Hollywood Way Burbank, Ca 91505 Dan Feger (818) 840-9456 Sewer Replacement @ Terminal B Contract Amount: $95,806.00 February 1996 Coast Community College District 1370 Adams Avenue Costa Mesa, CA 92626 Terry Craig (714) 432-S990 Track Drainage System Contract Amount: $74,717.81 March 1996 City of Laguna Beach 505 Forest Avenue Laguna Beach, CA 92651 Steve May (949) 497-3311 *351 Storm Drain & Street Improvements @ Forest Avenue Contract Amount: $60,000.00 April 1996 State of California Div. of State Arch Los Alamitos Army Reserve Center George Lai (619) 674-5440 Installation of 300HP Pump & Pipeline Modifications Contract Amount: $155,000.00 August 1996 City of La Habra Heights 1245 N. Hacienda Blvd. La Habra Heights, CA 90631 David Gilbertson (310) 694-6302 Misc. Storm Drain Repairs Contract Amount: $113,100.00 October 1996 City of Dana Point 33282 Golden Lantern Dana Point, Ca 92629 Gerry Anderson (714) 248-3506 36" Storm Drain Improvements Contract Amount: $160,000.00 October 1996 J.D. Diffenbaugh Paul Ramsey (909) 684-2820 Price Club, Fullerton Fire Protection/City Water System Improvements Contract Amount: $38,000.00 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 ^ FAX (714) 630-0445 LICENSE # 437235 ATLAS ALLIED, INC. Pipeline General Piping Engineering SINCE 19(") REFERENCE SHEET November 1994 City of Monterey Park 320 W. Newmark Ave. Monterey Park, Ca 91754 Tony Hiroka (818) 307-1322 24" SCCP Water Transmission Main Contract Amount: $16,980.00 Emergency Waterline Repair $10,485.00 March 1995 City of Glendora 116 E. Foothill Blvd Glendora, CA 91740 Jerius Williams (818) 914-8254 10" Waterline Replacement @ Baseline Road Contract Amount: $59,576.05 July 1995 Corona -Norco Unified School District 2820 Clark Avenue Norco, Ca 91760 Linda Jankel (909) 736-5045 Site Plumbing @ Susan B. Anthony Elementary School Contract Amount: $43,035.37 Auggst 1995 Laguna Beach Unified School District 550 Blumont Street Laguna Beach, Ca 92651 Jim Xanthos (714) 497-8379 Relocate Utilities & Pump Station Contract Amount: $98,223.00 September 1995 City of Garden Grove 11391 Acacia Parkway Garden Grove, CA 92642 Ben Yamada (714) 741-5186 Install Recirculation Pump Pipeline @ Twin Lakes Park Contract Amount: $43,817.36 November 1995 City of Laguna Beach 505 Forest Avenue Laguna Beach, CA 92651 Wade Brown (714) 497-3311 Drainage Structure Improvements @ Sunset Drive Contract Amount: $38,480.00 December 1995 City of San Juan Capistrano 32400 Paseo Adelanto San Juan Capistrano, CA 92675 Brian Perry (714) 493-1171 Drainage Improvements @ Spring Street Contract Amount: $23,565.00 December 1995 City of West Covina 1444 W. Garvey Avenue West Covina, Ca 91793 Miguel Hernandez (818) 817-8425 Storm Drain Improvements @ Amar Road Contract Amount: $14,160.50 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 • FAX (714) 630-0445 LICENSE # 437235 ATLAS ALLIED, INC. Pipeline Ix —General Piping Engineering `SINCE 1969 June 1993 U.S. Department of Labor C/O KDG Architect 3600 Wilshire Blvd. #1820, Los Angeles, CA 90010 Mohammad (213) 381-3311 Sewer System Installation Contract Amount: $179,800.00 November 1993 Mt. San Antonio College 1100 N. Grand Avenue Walnut, CA 91789 Gungor Dolic (909) 594-5611 Fire & Water System Rehabilitation & Replacement Contract Amount: $886,160.00 Peccmber 1993 Cal State Dominquez Hills 1000 E. Victoria Street Carson, CA 90747 Dominic Del Re (310) 516-3 799 Sewer Line Construction & Repair Contract Amount: $77,300.00 April 1994 John Wayne Airport County of Orange — GSA 1143 E. Fruit Street Tony Nevarez ( 714) 567-7709 Dump Station , Contract Amount: $43,097.90 REFERENCE SHEET May 1994 City of Loma Linda 25541 Barton Road, Loma. Linda, CA 92354 Brian Gengler (909) 799-2800 Relocate PRV Valves & Vaults Contract Amount: $44,560.00 June 1994 LA County Sanitation District 1955 Workman Mill Road Whittier, CA 90601 Rick Caulkins (310) 699-7315 Landfill Gas Collection Wells Contract Amount: $121,250.46 August 1994 Marine Corps Base Camp Pendleton P.O. BOX 209 Oceanside, CA 92049-0209 Nate Cervantes (619) 725-3923 41 Potable Water Sampling Stations Contract Amount: $70,876.90 November 1994 LA County Sanitation District 1955 Workman Mill Road Whittier, CA 90601 Rene Provoost (310) 283-0881 Landfill Storm Drain @ Puente Hills Contract Amount: $73,680.00 1210 N. LAS BRISAS, ANAHEIM, CA 92806 TEL (714) 630-3633 - FAX (714) 630-0445 LICENSE # 437235 ;, I& CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK February 27 ,2001 To: R & L Sewer, Inc. 8815 E. Somerset Blvd. Paramount, CA 90723 Enclosed please find your original bid bond issued by Fidelity and Deposit Co. of Maryland for Intrepid Lane Storm Drain:- cc no. 1139 Connie Brockway, CIVIC City Clerk Enclosure g •lfollowup/cashcon/retumbidbond. doc (Telephone: 714-536.5227 ) Bond N,O..N�A...08081876 Fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 BID BOND KNOW ALL MEN BY THESE PRESENTS: That we R & L SEWERS, INC. ,. _................................................................................................................................................................._..--.------ ......................................................................•--..........................................---•---•---•------....------...._....._...._.._.._.....---------------- --- ........ :....... ...:... :......................................................................... as Principal, (hereinafter called the "Principal"), and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, of Baltimore, Maryland, a corporation duly organized under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety"), are held and firmly bound unto ..... ...CITY..OF HUNTINGTON BEACH ......... .. ... - ...._.. ......_.._....:................. ........................................................•.......... ....................................................................._.._---................----•-..............as Obligee, (hereinafter called the "Obligee"), in. the sum of. TEN_. PERCENT OF THE AMOUNT OF THE ACCOMPANYING BID— Dollars ($.10% OF BID ), ...... ...._.------......................................_...... ............._........... ...... for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for ...___.................................................................. "INTREPID LANE STORM DRAIN" .............................................................................................._.. _..........------.............---................................. NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall :enter into a contract with the Obligee in accordance with the terms of such bid and give such -bond or bonds as may be specified in the bidding or contract documents with good and sufficient surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty her. -.:of between the amount specified in said bid and such larger amount for which the Obligee may in- good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this ........... 30TH y NOVEMBER yy 2000 ..........................--...-----..da of.....-••---.- O.....................................A.D. R & L SEWERS, C. (SEAT) Witness FIDELITY AND D Witness Title COMPANY OF MARYLAND Surety B ------ •- . ...... -........ (SEAL) MICHAEL � Y Title ATTORNEY —IN —FACT 02Sd-150 M, Approved by The American Institute of Architects. A.I.A. Document No. A-310 February 1970 Edition. CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of ORANGE ss. On NOVEMBER 30, 2000 before me, M. TREDINNICK, NOTARY PUBLIC Date Name and Tille of Officer (e.g.. 'Jane Doe. Notary Public) personally appeared MICHAEL A. QUIGLEY Name(s) of Signer(s) M. TREDihtiiCK Commission # 121305A z 4Mm��y NO'ary Puo!iC — Coiitornia >_Orange County Comm. Expires Mar 26, 2003 IK3 personally known to me ❑ proved to me on the basis of _satisfactory evidence to be the person(g) whose name(i4 is/ subscribed to the within instrument and acknowledged to me that he/zbWjtW executed the same in hiss authorized capacityW, and that by hiMUMMMIK signaturep on the instrument the person(i ), or the entity upon behalf of which the person(It) acted, executed the instrument. WITNESS my band and offigaf s-6 1. - '. &M Place Notary seat Above gnature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document_ Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: ❑ Individual Top of thumb here ❑ Corporate Officer — Titlefs): ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 0 1997 National Notary Association • 9350 De Soto Ave., P.O. Box 2402 • Chatsworth, CA 91313.2402 Prod. No. 5907 Reorder. Call Toll -Free 1-800-876-6827 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE: P.O. BOX 1227, BALTIMORE, MD 21203-1227 Know ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by W. B. WALBRECHER, Vice -President, and T. E. SMITH, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint Michael A. Quigley, of Aliso Viejo, California, its true and lawful agent and Attomey-in-Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings and the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said Company, as fully and amply, to all intents and purposes, as if they had been duly executed and ack�y edged by thearly elected officers of the Company at its office in Baltimore, Md., in their own proper persons.. o The said Assistant Secretary does hereby certify that the extract seoFn the rev hereof is. a true copy of Article VI, Section 2, of the By -Laws of said Company, and is now in force. IN WITNESS WHEREOF, the said Vice -President and Assis etary hav o subscribed their names and affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYL 0 s 25th day, ust, A.D. 1997. e ATTEST: FIDELITY AND#OSIT C Y OF MARYLAND gSEAL .�. � By: QLdce� •• T. E. Smith ssfstant Spare W. B. Walbrecher Vice -President State of Maryland SS: ^� � County of Baltimore �` J 0 On this 25th day of August, A.D. 1997, before the s r, a Notary Public of the State of Maryland, duly commissioned and qualified, came W. B. WALBRECHER, Vice -President and T. E. SMI rstant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and offs scribed in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly s erally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the pr� c instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed °1 scribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. �+�tcvr Car l J. Fader Notary Public My C missi Expires: August 1, 2000 CERTIFICATE I, the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the original Power of Attorney of which the foregoing is a full, we and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -President who executed the said Power of Attorney was one of the additional Vice -Presidents specially authorized by the Board of Directors to appoint any Attomey-in-Fact as provided in Article VI, Section 2, of the By -Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed." IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this 30TH day of NOVEMBER 2000 Assistant Secretary L1428-012-0626 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of 4 • -ES ss. On -:vIn-7 Date personally appeared DEBRA STOKLEY ICommbdon 01269490 Notary public - California Los knoes County My Comm. Expires Jul 1, 2004 Place Notary Seal Above 'personally known to me ❑ proved to me on the basis of satisfactory evidence to be the person() whose name() subscribed to the within instrument and acknowledged to me that he/sh executed the same in hisAer/their authorized capacity(iesr, and that by hi-sAie444e+r signature(*'on the instrument the person(•sr; or the entity upon behalf of which the person(it acted, executed the instrument. WITNESS hand and official seal. Signature of otary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: ❑ Individual ❑ Corporate Officer — El Partner — ❑ Limited ❑Attorney in Fact Title(s): El General ❑ Trustee ❑ Guardian or Conservator Other: Signer Is Representing: Number of Pages: RIGHT THUMBPRINT OF SIGNER 0 1999 National Notary Association • 9350 De Soto Ave., P.O. Box 2402 • Chatsworth, CA 91313-2402 • www.nationalnotary.org Prod. No. 5907 Reorder: Call Toll -Free 1-800-876-6827 RfG r 74c his £. S�,n�t 8��d J2 4row%conA, eel... qo?23. I) A fze:7 0 lops �Pcl (oc>o goo -woo 5)morni SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 ♦ y If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find said amount is not less than 10% of the aggregate of the Inviting Sealed Bids, payable to the AGE 1 Check", or "Bidder's Bond", as th may be). Bidder shall signify receipt of all Addenda here, if any: in the amount which t price, as required by the Notice ease insert the words "Cash", "Certified Addendum Date Received Bidder's Signature No. C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @'y/�� iT�/y Dollars Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ �Gdl��/� Dollars Cents 3 1 Trench Shoring L.S. Dollars Cents 4 889 8" HDPE Storm Drain Pipe L.F. @ _ Dollars Cents -, 5 238 L.F. 4" FWPE Storm r n pipe @ _ AIIA"r Dollars �J Cents �� D 6 29 595x 20" NDS Channel Drain #810 with #816 Grate Each @ 0Ailti�'i+LC�=-Dollars Cents 7 20 Conytete Channe BacVZd C.Y. @ vow Dollars Centsfl 8 2 Each TidPx Gate Valve, Seri s 37G @ Dollars ,/��pl/5y� _ O Cents 9 3 Each Junct'. n Structure - Type D Dollars Cents 10 2 Abandon Existig Lateral Each @ 91yi `�2t��0y/�r!/� Dollars 9p Cents 11 30 Sa c texiDepression L.F. @ Dollars Cents�- 12 30 Reconstruct Conc to U ha el L.F. @ lke- Dollars Cents C-Is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Of Work Name and Address of Subcontractor State License Number. Class �s By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange bein 7/- st duly sworn, deposes and says that he —ghe is of - Gs' the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. of Bidder Address of Bidder Subscribed and sworn to before me this Sfh day of 2000. DEBRA STOKLEY VoCommission # 1269490 Notary R bik . Colifomio Los Angeles County My Comm. Expires Jul 1, 2004 NOTARY PUBLIC IL,6(.43 NOTARY SEAL C-4-4 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: Title C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes X No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 4- 4l Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Contractor Title Date: Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: idder Name pBsiness Address City, State Zip (J4�) 93/--fo,3 a 5' Telephone Number ,�z9 '1141- State Contractor's License No. and Class Original Date Issued Expiration Date The work site was inspected by4d 9&of our office on %�� , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Printed or Typed Signature Subscribed and sworn to before me thisday of DEBR/► STOKIEY Cam*slon 01269490 Notcy public - Collfomla Los Angeles County 00my Comm. Expires Jul 1.2004 NOTARY PUBLIC NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. ame and is Agency Name and Telephone No. of Project Manager Amount �A � avewlsel K3/Oj ��3 yia Type of Work 2. �'// N and Address of Public Agency -/g --e;o Date Completed Name and Telephone No. of Project Manager: Contrast Amount 3. Name and Address of Public Agency of Work Date Completed Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed C-10 CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK February 27 To: GMC Engineering, Inc. 1401 Warner Avenue, Suite B Tustin, CA 92780 Enclosed please find your original bid bond issued by First National Insurance Company of America for Intrpid Lane Storm Drain - cc no. 1139 Connie Brockway, CIVIC City Clerk Enclosure g Jfollowuplcashcon/return bid bond.doc (Telephone: 714.536.5227 ) FIM NATIONAL INSURANCEGO. OF 4313 Onlyn A10eue NA Saauls,WA 9I105 BID BOND KNOW ALL BY THESE PRESENTS, That we, GMC Engineering. Inc. of 1401 Warner Avenue, Suite B, Tustin, CA 92780 (hereinafter called the Principal), as riacipa and FIRST XATION= INSUWME COMANY OF AMERICA, a Seattle, Washington, a corporation duly organized under the laws at the State of Washington as Surety, hereinafter called the Surety, are bald and firmly bound unto the City of Huntington Beach (hefileaitor nailed We Obligee) In the penal sum of Ten Percent of the Total Amount Bid --------------------------- ---------------------------------------------------------------------------------------- Dollars (S-------- 10%-------------- ) for the payment of which the Principal and the Surety bind themselves, their heirs. executors, administrators, euacessors and assigns, jointly and aevarally, firmly by thraa praaoata. THE CONDITION OF THIS OBLICATION IS SUCH, That Whereas, the Principal has submitted or is about to submit a proposal to tho Obligee on a contraot for Intrepid Lane Storm Drain, Cash Contract No. 1139 NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within Inch time aI may be specified, enter into the contract in writing, sad give bond, if bond is required, with surety acceptable to the Obligor for the faithful performance of the said Contract, then this obligation shall ba void; otherwise to remain in full force and effect. Signed and sealed this 1 st day of 34206/FP 7104 December , 2000. GMC Engineering, Inc. (Seal) Principal Title FIRST NATIONAL INSURANCE COMPANY OF AMERICA By F� rey . Gryd Attorney-ia- act POWER 1900JOHN OF ATTORNEY 4333 Brooklyn Avenue N.E. Seattle, NVA 98105 KNOW ALL BY THESE PRESENTS: FIRST NATIONAL INSURANCE COMPANY OF AMERICA 4333 BROOKLYN AVE NE SEATTLE, WASHINGTON 98105 No. 9392 That FIRST NATIONAL INSURANCE COMPANY OF AMERICA, a Washington corporation, .does hereby appoint Oq;;Oq;i;qq;;GO##iggi;+Mq;i#qq;t�Fgq;;qqq;#4q#;{qqi#QOJLI;I:KL'Y K. GRYDE, San Clemente, CLL11C�n)li)+#tqq;f4q;q►qq;;�R#;##Yvggilq 6#\i#;qF;q};;R#gi�F#q;#;O;i�F4q#;q#q; its true and lawful attomey(s)-in-fact, with full authority to execute on behalf of the company fidelity and surety bonds or undertakings and other documents of a similar character issued by the company in the course of its business, and to bind FIRST NATIONAL INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its regularly elected officers at its home office. IN WITNESS WHEREOF, FIRST NATIONAL INSURANCE COMPANY OF AMERICA has executed and attested these presents this 25th R.A. PIERSON, SECRETARY CERTIFICATE day of March 1999 r), 4y&6W W. RANDALL STODDARD, PRESIDENT Extract from the By -Laws of FIRST NATIONAL INSURANCE COMPANY OF AMERICA: "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attorneys -in -fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of FIRST NATIONAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 13 of the By -Laws. and (ii) A copy of the power-of-attomey appointment, executed pursuant thereto, and (iii) Certifying that said power-of-attomey appointment is in full force and effect; the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, R.A. Pierson, Secretary of FIRST NATIONAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By -Laws and of a Resolution of the Board of Directors of this corporation, and of a Power of Attomey issued pursuant thereto, are true and correct, and that both the By -Laws, the Resolution and the Power of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation this SEAL 1928 ?off ♦ • lst day of December , 2000 R.A. PIERSON, SECRETARY S-10491FNEF 7/98 3/25/99 PDF ALL-PURPOSE ACKNOWLEDGEMENT State of California County of 'LOS ANGELES On December 1, 2000 before me, CHRISTINE JANE FENDERSON—NOTARY—PUBLI DATE, , NOTARY I personally appeared JEFFREY R . GRYDE SIGNERISi ® personally known to me - OR - CHRISTINE JANE FENDERSON d Comm.11205912 a NOTARY PUBLIC-CALIFORNIA 'Y Los Angeles County MT Comm. Expires Doe.24,2002 ®xp[xmldxooxmxx=mvx)fxNx&f S RaXm,Aj odidm xto be the person(N) whose name(X) is/aix subscribed to the within instrument and acknowledged to me that he/ ftWcexecuted the same in his/k! lR4ct' authorized capacity(, and that by his/hxxktl>sxbf signatures(x on the instrument the person(x), or the entity upon behalf of which the person(30 acted, executed the instrument. WITNESS my and official seal. NOTARY'S SIGNATURE - OPTIONAL INFORMATION The information below is not required by law. However. it could prevent fraudulent attachment of this acknowl- edgement to an unauthorized document. CAPACITY CLAIMED BY SIGNER (PRINCIPAL) DESCRIPTION OF ATTACHED DOCUMENT 17 I,NDIVIDUAL 1-1 CORPORATE OFFICER BOND TITLE OR TYPE OF DOCUMENT TITLE, S . I PARTNER(S) I ATTORNEY -IN -FACT TRUSTEE(S) Gt;ARDIAN/CONSERVATOR OTHER: SIGNER IS REPRESENTING: NAME OF PERSONIS, OR ENTITY,IES, NUMBER OF PAGES DATE OF DOCUMENT OTHER d RIGHT THUMBPRINT OF L SIGNER a APA =-99 VALLEY -SIERRA. 800-362-3369 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On /f5Z—` '( ICD- before me, SANDRA JO WINBERRY. NOTARY PUBLIC , Date Name and Title of Officer (e.g., 'Jane Doe, Notary Public') personally appeared GENNADY CHIZHIK Names) of Signer(s) ersonally known to me — OR — ❑ proved to me on the basis of satisfactory•evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the SANDRAJO WINBERRY same in his/her/their authorized capacity(ies), and that by Commission # 1153985 his/her/their signature(s) on the instrument the person(s), Notary Public - Califomia or the entity upon behalf of which the person(s) acted, Los Angeles County 9 executed the instrument. My Comm. Expires Sep 10, 2001 WITNESS my hand and official seal. gnature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual Corporate Officer Title(s): PRESIDENT ❑ Partner — ❑ Limited ❑ General ❑ Attorney -in -Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Top of thumb here Signer Is Representing: GKC ENGINEERING INC 1401 Warner AVe Ste B Tustin, CA 92780 Signer's Name: s 70 El El El El Number of Pages: Individual Corporate Officer Title(s): Partner — ❑ Limited ❑ General Attorney -in -Fact Trustee Guardian or Conservator Other: Signer Is Representing: 0 1994 National Notary Association • 11236 P.emmet Ave., P.O. Box 7184 • Canoga Park, CA 91309.7184 Prod. No. 5907 Reorder. Call Toll -Free 1.800,878 6817 GMC ENGINEERING INC. 1401 WARNER AVE STE S 690-JUM CA MM L ui q �111, CA SEALED BID FOR: CITY OF HUNTINGTON BEACH INTREPID LAND STROM DRAIN from Remora Dr to Braodway CC# 1.1-39rV Bid Date:1.2/5/00 Time 2:00 Pm SECTION C . PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find b; j jjh ,,j in the amount of $ 7_0% which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum: Dafe Received Bidder's Signature :No ]. 1.1/30/00 C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ 7/ OV-5A0-/ D Dollars Ql Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ 7k- JO 7110U Dollars Cents 3 1 L.S. Trenc4 &gg�{f% S Dollars @ f/ynFa a rD27Y 1K Cents-- 4 889 18" HDPE Storm Drain Pipe L.F. @ CYYE 1-&VVQrc�CJ Dollars Cents /3D //SS 70 -- 5 238 4" HDPE Storm Drain Pipe L.F. @7~- A6#vNGYI6a Af7Y I -vat Dollars 0 Cents 35 Y— $yZ5 Z-- 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate Each @ fiVW fidND/I61D Dollars Cents 113 8 — /Zj 7OZ-- 7 20 Concrete Channel Backfill C.Y. @/6/rLAND/Lf� /64Ti/ 6y4 Dollars p1 Cents y65— q 700 — 8 2 Each @dec�te V13aZ60 �' Z Dollars 0 Cents 6 1 L10 9 3 Junction Structure - Type D Each @ %#/97Y S'/X { NDf1ED Dollars 9 Cents 3 6 — L04 goo — 10 2 Abandon Existing Lateral Each @ YyH=60 Dollars Cents 35 o _ %OD -- 11 30 Sawcut Local Depression L.F. @ 714//Z7Y' FiyZ- Dollars Cents 35, l DSD- 12 30 Reconstruct Concrete U-Channel L.F. @ 0,-4,0/260 /7`7Dollars Cents 1 SD — Total Amount Bid in Figures: $ Z(2(� DDD Total Amount Bid in Words: 77?,(,0 r�%tJn(D/1.�,0 SI xTY 7h'vu-&fV,0 004444S C-is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract iri an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. 0 Portion. _ Name and Address:of Subcontractor State License Class Of Number Work pcKwON PACIFIC STRUCTURES OfT�`f 6611 ARLINGTON AVE #L y�IG�I 909-687-6861 f%/zvelk fe, 655717 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the .above subcontractors listing. 2. That the AGENCY .will .be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. • C-3 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For INTREPID LANE STORM DRAIN CC- 1139 November 15, 2000 Notice To All Bidders: Please note the following revision to the Project Plans, Specifications, and Technical Provisions: In an effort to compress the work schedule, the attached Alternate Bid Schedule shall be submitted to complete the project utilizing Saturdays as an additional mandatory work day, following a standard 5 day work schedule. The low bid will be based on the primary Bid Schedule. The City reserves the right to utilize the Alternate Bid Schedule upon execution of the contract. This modification does not change the Engineer's Estimate for this project. This is to acknowledge receipt and review of Addendum Number one, dated November 15, 2000. By All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Todd Broussard at (714) 536-5247. SECTION C ALTERNATE PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 , Mobilization $3,000 $3,000 L.S. @ 7�fiL 7ff0� Dollars Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ -Z&,Q 7,ypv.44V!Q Dollars Cents 3 1 Tren S L.S. us�tn10 @ iy�,r� it�y 37Q4 Dollars Cents- 4 889 18" HDPE Storm Drain Pipe L.F. @ CWE f/dA-W,,62 /O/ZW Dollars Cents l t/0 12-q YbD — 5 238 4" HDPE Storm Drain Pipe L.F. @ 77'&d4!5 #zl VnZ60 Si Kam/ Dollars Cents 36 O— $✓� w — 6 29 5"x 20" NDS Channel Drain #810 with #816 Grate , Each @ /�L& 4kWppf0 7is*,aw h-t6i/lDollars 1 Cents L 3 8— /Zj 70Z- 7 20 Concrete Channel Backfill C.Y. @ Vt& A kVOAW 6i 6#W h V4 Dollars Cents 9, 700- 8 2 Each Tid ex Gale Valve Series 3 @ � 7X0�� vK1 NDiWDollazs Cents 6 / —- 9 3 Junction Structure - Type D Each @ 7#47y Sry wygAVAO Dollars 92 Cents 3 A? Oc- 10 2 Abandon Existing Lateral Each @ 7#flk�-� AQ1% &40 K<l,/ Dollars Cents 35V %a -- 11 30 Sawcut Local Depression L.F. @ 17yf/z7y Dollars Cents ,jS — /0 S0 —' 12 30 Reconstruct Concrete U-Channel L.F. @ ox,�, Aympnw h/-Ty Dollars Cents /SOS -5-00 — Total Amount Bid in Figures: $ Z70,51g Total Amount Bid -in Words: ,fir/ 7 7lff�c.�r0 #04PR460 7-1-ey�( DOLC�4�LS C-ls , NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange Gennady Chizhik , being first duly sworn, deposes and says that he or she is President of aMC Rnginaaring Tnr_ the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. GMC ENGINEERING INC. Name of Bidder Signature of Bidder Gennady Chizhik 1.401. Warner Avenue Ste B, Tustin, CA 92780 Address of Bidder Subscribed and sworn to before me this Ist day of December , 2000 . NOTARY SAN mis ft WI115398 ' CommlSSlon #� 1153985 Z Notary PUb11C - COlifomlC Z LOS Angeles County My Comm. Expires Sep 10, 2001 NOTARY SEAL C-4 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified -Person"' is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar wik.th the operation to be performed and the hazards• involved. " • " ' , The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. GMC Engineering Inc. Contractor By Gennadi Chizhik President Title \C-5 v� CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On ahka before me, SANDRA JO WINBERRY. NOTARY PUBLIC Date Name and Title of Officer (e.g.. 'Jane Doe. Notary Publicl personally appeared GENNADY CHIZHIK Name(s) of Signer(s) a(Versonally known to me — OR — ❑ proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by - , — — , y _ _ _ __ _ _ his/her/their signature(s) on the instrument the person(s), SANDRAJO WINBERRY or the entity upon behalf of which the person(s) acted, '�, Commission # 1153985 Z executed the instrument. ry Notary Public , -California Los Angeles County a f. MyComm. ExpiresSep 10,2o0t WITNESS my nd an official seal. ,C of Notary Public OPTIONAL' Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual Corporate Officer Title(s): PRESIDENT ❑ Partner — ❑ Limited ❑ General ❑ Attorney -in -Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Top of thumb here Signer Is Representing: GMC ENGINEERING INC 1401 Warner AVe Ste B Tustin, CA 92780 Number of Pages: Signer's Name: Individual Corporate Officer Title(s): Partner — ❑ Limited ❑ General Attorney -in -Fact Trustee Guardian or Conservator Other: Signer Is Representing: RIGHT THUMBPRINT OF SIGNER 0 1994 National Notary Association - 5236 Remmet Ave., P.O. Box 7164 - Canoga Park, CA 91309.7164 Prod. No. 5907 Reorder. Call Toll -Free 1-e00.876.6a17 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has,the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes )(No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 1-2/j/00 GMC ENGINEERING INC. Contractor BY Gennady Chizhik PRESIDENT Title C-7 - UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: (TBA) GMC ENGINEERING INC. Contractor By Gennady Chi ik President Title Date: 1.2/2/00 Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: GMC ENGINEERING INC Bidder Name 1.401. Warner Ave Ste B, Tustin, CA 92780 Business Address City, State Zip 71.4 ) .247-].040 'Telephone Number 739091. A, B State Contractor's License No. and Class 8/1.1/97 Original Date Issued `t8/31/01, Expiration Date The work site was inspected by Gennady Chizhik of our office on 7.1/30 , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: Gennady Chizhik / President, GMC Engineering C-9 .;I The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. ftRRRAAXXRkiKkftXX GMC Engineering Iric. Company Name Signature of Bidder Gennady Chizhik Gennady Chizhik - President Printed or Typed Signature Subscribed and swornto before me this ].slay of December , 2000 SANDRA JO WINBERRY Commission # 11w985 z^ad Notary Public -California Los Angeles County NOTARY PUBLX:,- MyComm. Expires Sep 10 2001 NOTARY SEAL Listed below are tIe'1 times, address and telephone numbers for three public agencies for which the bidder has performed similar. work within the past two years: 1 SEE ATTACHED 2. 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Type of Work C-10 Date Completed Date Completed Date Completed J CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of CALIFORNIA County of ORANGE On _alb too- before me, SANDRA JO WINBERRY. NOTARY PUBLIC , Date Name and Title of Officer (e.g.. 'Jane Doe. Notary Public] personally appeared GENNADY CHIZHIK Name(s) of Signer(s) ;kersonally known to me — OR — ❑ proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), SANDRA JO WINBERRY 11 or the entity upon behalf of which the person(s) acted, Commission # 1153985 z executed the instrument. Z r _� - Notary Public - California z '¢ Los Angeles County My Comm. Exgkes Sep 10, 2001 WITNESS my hand and official seal. Signature of Notary Public OP Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual Corporate Officer Title(s): PRESIDENT ❑ Partner — ❑ Limited ❑ General ❑ Attorney -in -Fact ❑ Trustee ❑ Guardian or Conservator ❑ other: Top of thumb here Signer Is Representing: GMC ENGINEERING INC 1401 Warner AVe Ste B Tustin, CA 92780 Signer's Name: a i Number of Pages: Individual Corporate Officer Title(s): Partner — ❑ Limited ❑ General Attorney -in -Fact Trustee Guardian or Conservator Other: Signer Is Representing RIGHT THUMBPRINT OF SIGNER Too of thumb her 0 1994 National Notary Association - 8236 Remmel Ave., P.O. Box 7184 - Canoga Park, CA 91309-7184 Prod. No. 5907 Reorder.. Call Toll -Free 1.800.876-M7 : GMC Engineering Inc. CONTRACTORS PROPOSAL REFERENCE LIST ADDRESS 3900 Main Street Riverside, Ca 92522 Our Job # 137-00 CONTACT Dick Clelland PHONE (909) 826-5671 DESCRIPTION Fairmount Blvd. from Mission Inn to University Avenue CONTRACT AMOUNT $ 472,549.38 OWNER City of San Juan Capistrano ADDRESS 32400 Paseo Adelanto San Juan Capistrano, CA 92675 Our Job # 132-99 CONTACT Jerome Ruddins PHONE (949) 855-3634 DESCRIPTION Camino Capistrano Street Widening CONTRACT AMOUNT $ 677,706.39 OWNER City of Mission Viejo ADDRESS 25909 Pala Suite #200 Mission Viejo, CA 92691 Our Job # 117-98 CONTACT Marc Chagnon PHONE (949) 470-3091 DESCRIPTION. La Paz Widening CONTRACT AMOUNT $ 317,375.00 OWNER City of Huntington Beach PWA ADDRESS 2000 Main Street Huntington Beach, CA Our Job # 128-99 CONTACT Larry J. Taite or Eric Charlonne PHONE (714) 536-5590 / (714) 536-5430 DESCRIPTION Glencoe Avenue Street Improvements CONTRACT AMOUNT $ 319,691.00 ADDRESS 300 Centenninal Way Tustin, CA 92780 Our Job # 112-97 CONTACT Fred Page or Jerry Otterson PHONE (714) 573-3167 / (714) 573-3162 DESCRIPTION "A" Street & Mountain View Drive CONTRACT AMOUNT $ 467,632.42 OWNER City of Irvine ADDRESS One Civic Center Plaza Irvine, CA 92623-9575 Our Job # 118-98 CONTACT Ed Rozok PHONE (949) 724-7554 DESCRIPTION Michelson Ave Median CONTRACT AMOUNT $ 537,973.22 OWNER City of Chino ADDRESS 13220 Central Avenue Chino, CA 91710 Our Job # 123-99 CONTACT Raja Edirisuriya PHONE (909) 627-7577 x253 DESCRIPTION Pipeline, Eucalyptus, & Grand Ave CONTRACT AMOUNT $ 414,932.81 ENG N� GE GENERAL ENGINEERING CONTRACTOR Lic. No. 739091 CONTRACTORS DESIGNATION OF SURETIES Bonding: JRG Surety & Insurance Agency, Inc. 104 Calle Patricia Unit B San Clemente, CA 92672 (949) 498-7384 (949) 498-1467 Fax Attention: Jeffery R. Gryde Insurance• Armstrong Robitaille 680 Langsdorf Dr. #100 Fullerton, CA 92831 (714) 578-7268 (714) 578-7487 Fax Attention: Paula Thibodeau 1401 Warner Avenue, Suite B, Tustin, California 92780 • (714) 247-1040 • Fax (714) 247-1041 4 CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK February 27 12001 To: GCI Construction, Inc. 245 Fischer Avenue, Suite B-3 Costa Mesa, CA 92626 Enclosed please find your original bid bond issued by Travelers Casualty and Surety Company of America for Intrepid Lane Storm Drain - CC No. 1139 e�� O"r Connie Brockway, CIVIC City.Clerk Enclosure g:/followup/cashcon/returnbidbond.doc (Telephone: 714-536-5227 ) Bic BOND TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA Hartford, Connecticut 06183 Bond No. N/A KNOW ALL MEN BY THESE PRESENTS, That we, GCI CONSTRUCTION, INC. as Principal, hereinafter called the Principal, and TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, of Hartford, Connecticut, a corporation duly organized under the laws of the State of Connecticut, as Surety, hereinafter called the Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH as ODI!r An hnnninafter Caiierd the Ob!"gee in the -,,um of TEN PERCENT OF THE AiNfOUNT BID Dollars ($ 10% ), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for INTREPID LANE STORM DRAIN —CASH CONTRACT NO. 1139, CITY OF HUNTINGTON BEACH NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shalt enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract .Ath another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 30THday of NOVEMBER CNitness) (Witness) 2000 GCI CONSTRUCTION, INC. TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA B C SUSAN C. MONTEON (Aft miaf•.-IFactJ Printed in cooperation with the American Institute of Architects (AIA) by Travelers Casualty and Surety Company of America, The language in this. document conforms exactly to the language used in AIA Document A310, February 1970 edition. S.1 g6ar (07-97) CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California. County of Orange On�, .� before me, Janet L. Russell - Notary Public DATE I , , a , _ , NAME. TITLE OF OFFICER • E.G..'JANE DOE. NOTARY PUBLIC personally appeared `J NAME(S) OF SIGNERS) Ei personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and ac- knowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. JANET L. RUSSELL WITNESS my hand and afficial seal. Comm. # 1166123 (( - 4�4 NOTARY PUBLIC • CALIFORNIA Orange County My Comm. Expires Dec.21, 2M 4vi��f L. Russell sIGNA RE OF NOTARY Nota OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUAROIAWCONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTTTY(IES) DESCRIPTION OF ATTACHED DOCUMENT TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE 60-1133 3J94 01993 NATIONAL NOTARY ASSOCIATION - 8236 Remmet Ave., P.O. Box 7184 - Canoga Park. CA 91309-7164 STATE OF _ COUNTY OF CALIFORNIA RIVERSIDE On I i /30/00 , before me, SS. R. STANDL EY PERSONALLY APPEARED-----SUSAN C. MONTEON--------- personally known to me to be the person4s3-whose name{.&} isAara.subscribed to the within instrument and acknowl- edged to me that.h4a-Ashe/,the*. executed the same in .-ni her/;,immix. authorized capacity(4es3, and that by la4r.-.,/her/ 4heir signature cs n the instrument the person4, or the entity upon behalf of which the person4;Lacted, executed the instrument. WITNESS my hand and official seal. Signature OPTIONAL R. STANDLEY COMM. #1263272 NOTARY PUBLIC -CALIFORNIA RIVERSIDE COUNTY My Comm. Expires Juno 7, 2004 This area for Official Nlotarial Seal Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) ❑ LIMITED ❑ GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) DESCRIPTION OF ATTACHED DOCUMENT TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE ID-osl Rev.6/94 ALL-PURPOSE ACKNOWLEDGEMENT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY Hartford, Connecticut 06183-9062 TRAVELERS CASUALTY AND SURETY COMPANY OF ILLINOIS Naperville, Illinois 60563-8458 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S)-LV-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, and TRAVELERS CASUALTY AND SURETY COMPANY OF ILLINOIS, a corporation duly organized under the laws of the State of Illinois, and having its principal office in the City of Naperville, County of DuPage, State of Illinois, (hereinafter the "Companies") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Michael D. Stong, Shawn Blume or Susan C. Monteon * * of Riverside, CA, their true and lawful Attorney(s)-in-Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, or, if the following line be filled in, within the area there designated the following instrument(s): by his/her sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duly authorized officers of the Companies, and all the acts of said Attorney(s)-in-Fact, pursuant to the authority herein given, are hereby ratified and confirmed. This appointment is rnade under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking,- and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that_each such delegation is in writing and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Power of Attorney and Certificate of Authority is signed and sealed by facsimile under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY, FARMINGTON CASUALTY COMPANY and TRAVELERS CASUALTY AND SURETY COMPANY OF ILLINOIS, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (8-97) GCI CONSTRUCTION, INC. 245 FISCHER AVENUE, WE. B-3 COSTA MESA, CA 9'16 CITY OF HUNTINGTON BEACH OFFICE OF THE CITY CLERK Second Floor 2000 Main Street Huntington Beach, CA 92648 2 "SEALED BID FOR": INTREPID LANE STORM DRAIN CASH CONTRACT NO. 1139 r SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find S L'in the amount of $ 16 which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum Date Received Bidder's Signature No C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ Dollars (� p Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ TLOCaha 1Sc12(.i Dollars %lQ Cents 3 1 L.S. Trench Shoring @ ahnw_�twQszy p Dollars 3pnp °6 3 Q6O C ' Cents 4 889 L.F. 18" HDPE Storm Drain Pipe @ 19 d�� Dollars 67 as -7-7` 3@00 Yl0 Cents 5 238 L.F. 4" HDPE Storm Drain Pipe y @QU hundred 6061U ►�- jVC, Dollars ta'5.0o tEE� p as (Zy Cents 6 29 Each 5"x 20" NDS Channel Drain #810 with #816 Grate @ TtL-10ku n�EN_ Dollars .2svco _7j2-5D (la Cents 7 20 C.Y. Concrete Channel Backfill @: fXjjjQAD " CI C� Dollars 2� I UO as 42-/ OCJQ o c (9Cents 8 2 Each Tideflex Gate Valve, Series 37G @ Six Dollars b`GOU a �COV 11 Cents 9 3 Each Junction Structure - Type D @T__0 t,,Tim FkAAdred Dollars o0 oa /La Cents 10 2 Each Abandon Existing Lateral @0l'laWVldfi9J r: %- T.�� Dollars o 0 �� 0 0 6 Cents 11 30 L.F. Sawcut Local Depression @ _ Dollars 0' Z5' do %J� i� Cents 12 30 L.F. Reconstruct Concrete U-Channel @-ZL1,{ ma)Eea Ek Ll Dollars ,2-50U. 0,0 (OR OQo * [] t� Cents • • : • rMirl-r • C-Is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class Of Number Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange oqG! 8wo I , being first duly sworn, deposes and says that he or she is E0 y e:tz3r �j' Ls() f�" of GCl (��1,� the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. 90-1(3zn s4rveA'o6 Name of Bidder 245 �--cse lt_Qr P4�r j 0-=3 QaS sa,C4 9 Address of Bidder Subscribed and sworn to before me this day of aumbe, 2000. NOTARY PUBLIC JANET L. RUSSELL N Comm. # 1166123 NOTARY PUBLIC-CALIFORNIA Orange County qPMY Comm. Expires Dec. 21,1001 NOTARY SEAL C-4 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: 1- . 4 2XQ GC 102 nos-[rrudi&n,�rlc . Contractor �smLv= ru Treoc� r-e� Title C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes eN0 If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 00 GC( owns cAor).:Fhc. Contractor Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Pe,► eoos4ve,46e) .Inc . Contractor �' . M .;sia�� i Title Date: tva. Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name Business Address Q2sfa I Ln3 Cg2o219 City, State Zip C71+) g5-7 -Q z�3 Telephone Number -7 55 ,1 A /i State Contractor's License No. and Class (c) - ICO - Original Date Issued to-:5I- oz Expiration Date The work site was inspected by 0 Vl of our office on j (- �jQ , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. GCI �a ��e�-c'o►� , �.ne . Company Name Typed Signature Subscribed and sworn to before me this?day of , 2000. ------------------------ ` JANET L. RUSSEII Comm. A 1166123 N �� NOTARY PUBLIC • CALIFORNIA NOTARY PUBLIC �1�0 orange County^ Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 2. 0 I I 31y� iffirf, a Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed C-10 • G C I CONSTRUCTION, INC. FORMERLY: GILLESPIE CONSTRUCTION INC. COMPLETED PROJECTS As of May 31, 2000 CONTRACT CUSTOMER NAME & ADDRESS JOB #/ LOCATION AMOUNT CITY OF FOUNTAIN VALLEY 017 Park & Ride Lot at the Fountain Valley 166,669 10200 Slater Avenue ' Recreation Center Fountain Valley, CA 92708 (714)593-4400 j CITY OF LAGUNA BEACH 025 Virginia Park Drive, Skyline Drive &Vista Lane 315,315 505 Forest Avenue Storm Drain Laguna Beach, CA 92651 I j (949) 497-0351 _._............__...._.. ---._.__...._......._..__...._._...._._....__..._.._.._.. -----..._......_.........._. I _ ...... . CITY OF NEWPORT BEACH 009 Water Line Replacements &Alley 26,243 3300 Newport Blvd. Reconstruction Marcus Newport Beach, CA 92658-8915 012 Jamboree Road Sewer Improvement 139,730 (949) 644-3311 , 018 Central Balboa Water, Sewer & Alley 495,804 Improvements & West Newport Beach Main Replacement, Phase II CITY OF ROSEMEAD 013 Storm Drain Improvements 330,031 8838 East Valley Blvd. Rosemead, CA 91770 (626) 288-6671 j CITY OF TORRANCE 1016 Construction of CMP Replacement Program 1,021,000 3031 Torrance Blvd. ! 1998-199 i Torrance, CA 90509-2970 1 026 Construction of Arnie Avenue Retention Basin 423,078 (310) 618-2820 Force Main C.W. DRIVER 035 "Perilous Plunge" - Utilities 215,583 7442 North Figueroa Street Los Angeles, CA 90041-1710 (323) 259-8600 ---------._.._.. i ----........__..__...._......_.-.._..._.- .............__........ ---- IRVINE RANCH WATER DISTRICT -- ----- -- 001 ...._..__.._..r.— - - ........_.._..__....—_... -- -- ....._..._.._.... - -' Bonita Creek Park Trunk Sewer Relocation 621,100 15600 Sand Canyon Avenue j Irvine, CA 92618 (949) 453-5585 JOHN LAING HOMES 037 Laing Homes Meadowlark Utilities- Tract 15472 99,981 19600 Fairchild, Suite 150 Irvine, CA 92612 (949) 476-9090 Ext. 230 GAJanet\GCI\JOBLIST\GCI REFERENCE SHT.doc Page 1 of 3 G C I CONSTRUCTION, INC. FORMERLY: GILLESPIE CONSTRUCTION INC. COMPLETED PROJECTS As of May 31, 2000 CONTRACT CUSTOMER NAME & ADDRESS JOB #/ LOCATION AMOUNT KNOTT'S BERRY FARM 010 Coasters Restaurant Knott's Berry Farm 12,820 8039 Beach Blvd. 023 "Wipe Out" & "Scrambler" 71,031 Buena Park, CA 90620 027 "Soak City" Demo 123,882 (714) 220-5227 028 Parking Lot Rehab for Restriping 51,309 029 Employee Parking Lot 29,418 030 "Soak City" -Water Lines 13,000 031 Mechanical Pump Buildings - "Soak City" 899,999 032 "Soak City" - Grading 572,073 033 "Soak City" - Utilities 498,067 034 "Perilous Plunge" -Demo 159,750 039 Cross Town Sewer 210,708 041 "Soak City" -Asphalt Paving 170,394 j 043 "Soak City" - Concrete Flatwork 753,828 044 "Soak City" -Wall #1 for Ramp to Bridge 94,590 046 Grand Avenue Drop Off - Knott's Berry Farm 102,136 054 Stanton Avenue Phase - 1 136,071 055 Housekeeping Pads - "Soak City" 9,812 LOYOLA MARYMOUNT UNIVERSITY 002 L.M.U. Export -Playa Vista 716,502 7900 Loyola Blvd. Los Angeles, CA 90045-8370 (310) 338-7762 MISSION VIEJO CHRISTIAN CHURCH O11 Mission Viejo Christian Church 11,222 27405 Puerta Real Suite 360 Mission Viejo, CA 92691 (714) 768-0209 _..__...-----._.._...__...__....._.._.._.._......._........_... _.._._................. --—..._.... _._..................-- MR. JOHN THORSELL _.._............ . 006 - -- ............. _ Water Line Relocation - Dana Point 13,709 1 Santa Lucia Dana Point, CA 92629 (949) 448-8722 PACIFIC BUILDING INDUSTRIES 024 Bayside Restaurant -Newport Beach 2,700 3190-K Airport Loop Drive Costa Mesa, CA 92626 (714) 755-0299 PERDOMO BLT ENTERPRISES, LLC 1 003 East L.A. Recycling and Transfer Station 313,144 511 Spectrum Avenue Oxnard CA 93030 (805) 278-8220 GAJanet\GCI\JOBLIST\GCI REFERENCE SHT.doc Page 2 of 3 G C I CONSTRUCTION, INC. FORMERLY: GILLESPIE CONSTRUCTION INC. COMPLETED PROJECTS As of May 31, 2000 CONTRACT CUSTOMER NAME & ADDRESS JOB #/ LOCATION AMOUNT PLAYA CAPITAL COMPANY, LLC 12555 West Jefferson Blvd., Suite 300 Los Angeles, CA 90066 (310) 822-0074 '1 004 Placement of LMU Import Material 132,470 PORT OF LONG BEACH 925 Harbor Plaza Drive, 4' Floor Long Beach, CA 90801 (562) 437-0041 ................... . . . . . — . . . . . . . ............ ......... . .............. . . .... ------ SOUTH COAST WATER DISTRICT 31592 West Street Laguna Beach, CA 92607 (949) 499-4555 022 --- 007 i 1 015 Removal of Nicholson Avenue Ramp ......... . ................ . .... -C- -o-a- sa -a- I Treatment -- --- Plant - - ------ -E- - x-- p- o- r-t----Sludge Force Main Phase III Camino De Estrella Sewer Main 128,153 .......... . ... . . .......... .. .. . .............. 93,109 110,767 SOUTHERN CA WATER COMPANY. 17140 South Avalon Blvd., Suite 100 Carson, CA 90746 (310) 767-8205 045 Albertoni Blvd., East of Avalon Blvd. - 12 DI I142,229 Pipe Watermain Installation WALNUT VALLEY UNIFIED SCHOOL DISTRICT 880 South Lemon Avenue Walnut, CA 91789 (909) 595-1261 Ext. 1378 1008 Morning Sun Landslide Site - Walnut 25,392 . . ....... .... . . . .... . ..... . ... ................ . ..................... . . . . ........ . . .......... .. ............. . . ............................... . . . --- --- ......................... . . ........ ... . ............ .... ......................... . ... . . ......... ........ - -------- . .. . . ..... ............... . .................. . . ........... ...... . .... . ............... . .............. . ....... .... ........ . .. . . .... ... . ...... . .. . . .................... . .... . . . ............................. ......... - --------------- - ----- - ----------------- ..................... ........ . . ... . . . .... . .. . .. ................................. . .... . ...... . . ....... ............ . ..................... .. . ... . .... . . ................. . ............ . . ... . . ... . ....... ........ ... . . . ........................................ .... ..... ...... ... . .. . ......... ................ . ..... . ... . . ...... . ... ... . ................ ... . ......... ....... . . ............. . . ....................... ..... . . . ...... ...... . . . . . ........................... - -------- - ......... ........... . . . . .......... .... ... .......... . ........ ...... ... . . .......... . .... ... . . .. .. . ............ GAJanet\GC1\J0BL1S'nGC1 REFERENCE SHT.doc Page 3 of 3 CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE OF THE CITY CLERK CONNIE BROCKWAY CITY CLERK February 27 12001 To: Belczak & Sons, Inc. P.O. Box 3196 Orange, CA 92857-3196 Enclosed please find your original bid bond issued by Safeco Insurance Company of America for Intrepid Lane Storm Drain cc no. 1139 4�� a"r Connie Brockway, CIVIC City Clerk Enclosure g:Kollowup/cashcon/returnbidbond.doc (Telephone: 714-536-5227 ) KNOW ALL BY THESE PRESENTS, That we, BELCZAK & SONS, INC. of ANAHEIM. CALIFORNIA as Principal, and SAFECO INSURANCE COMPANY OF AMERICA MILLENNIUM CORPORATE PARK BLDG. C 18400 NE UNION HILL ROAD REDMOND, WA 98052 (hereinafter called the Principal), (hereinafter called the Surety), as Surety are held and firmly bound unto CITY OF HUNTINGTON BEACH (hereinafter called the Obligee) in the penal sum of TEN PERCENT OF TOTAL AMOUNT BID - - - - - - - - - - - - - - - - - - - - - - ------------------------------------------------------------- Dollars($ 10%OFAMOUNTBID ) for the payment of which the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firnily by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That WHEREAS, the Principal has submitted or is about to submit a proposal to the Obligee on a contract for INTREPID LANE STORM DRAIN - CASH CONTRACT NO. 1139 NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within such time as may be specified, enter into the Contract in writing, and give bond, if bond is required, with surety acceptable to the Obligee for the faithful performance of the said Contract, then this obligation shall be void; otherwise to remain in full force and effect. Signed and sealed this 30th day of Witness L e62'Ll Rhon b C. A el Witness November , 2000 BELCZ N C (Seal) Principal elf Title SAFECO INSURANCE COMPANY OF AMERICA By J e Kepner Attorney -in -Fact S-0053/SAEF 10/99 8 Registered trademark of SAFECO Corporation. CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No. 5907 State of California County of Orange On ///3p��--� before me, Nanette Mariella-Myers , DAIrE NAME, TITLE OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC - personally appeared Jane Kepner NAME(S) OF SIGNER(S) ® personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. , �; n _-fJ,YERS nti Corrmis- n 1159222 - I:�ta^I/P. -Cc:rcrnia57 WITNESS my hand and official seal. � i •t� - i�y7fN�zJ SIGNATURE OF NOTA OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER ❑ INDIVIDUAL ❑ CORPORATE OFFICER TITLE(S) ❑ PARTNER(S) H LIMITED GENERAL ® ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) DESCRIPTION OF ATTACHED DOCUMENT TITLE OR TYPE OF DOCUMENT NUMBER OF PAGES DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE S-A097/f;FFF 9/AA O 1993 NATIONAL NOTARY ASSOCIATION - 8236 Remmet Ave.. P.O. Box 7184 - Canoaa Park. CA 91309-7184 �+ POWER SAFECO INSURANCE COMPANY OF AMERICA J A F E C O" GENERAL INSURANCE COMPANY OF AMERICA OF ATTORNEY HOME OFFICE: SAFECO PLAZA SEATTLE, WASHINGTON 98185 No. 10081 NOW ALL BY THESE PRESENTS: iat SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA, each a Washington corporation, does each hereby )point .■.:■..■■■....■■■:■•••JANE KEPNER, STANLEY C. LYNN; NANETTE MARIELLA-MEYERS; JAMES A. SCHALLER; Costa Mesa, California■....■■..■■.■■.■.......■ true and lawful attomey(s)-in-fad, with full authority to execute on its behalf fidelity and surety bonds or undertakings and other documents of a similar character sued in the course of its business, and to bind the respective company thereby. J WITNESS WHEREOF, SAFECO INSURANCE COMPANY OF AMERICA and GENERAL INSURANCE COMPANY OF AMERICA have each executed and tested these presents this 31st day of March , 1999 RA. PIERSON, SECRETARY W. RANDALL STODDARD, PRESIDENT CERTIFICATE Extract from the By -Laws of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA: Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that )urpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attomeys-in-fact or under other appropriate titles with authority to :xecute on behalf of the company fidelity and surety bands and other documents of similar character issued by the company in the course of its business... On any nstrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or mdertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not )e necessary, to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. 'On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 13 of the By -Laws, and (ii) A copy of the power -of --attorney appointment, executed pursuant thereto, and (III) Certifying that said power-of-attomey appointment is in full force and effect, :he signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, R.A. Pierson, Secretary of SAFECO INSURANCE COMPANY OF AMERICA and of GENERAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By -Laws and of a Resolution of the Board of Directors of these corporations, and of a Power of Attorney issued pursuant thereto, are true and orred, and that both the By -Laws, the Resolution and the Power of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation this day ofc��(1/�%i��L� o2L2'L'J POR�T�`p.� CORPORATE SEAL SEAL a z x .rj 1953 ArFOf WASt��o �f�0iWd5��R.A. PIERSON, SECRETARY 5-09741SAEF 7/98 0 Registered trademark of SAFECO Corporation. 3/31/99 POF BELCZAK & 3014g, INC. ORANGE, A 92857 3196 City of Huntington Beach City Clerk, Second Floor 2000 Main Street Huntington Beach, CA 92648 Bid: Intrepid Lane Storm Drain Cash Contract No. 1139 12-5-00 @ 2:00pm SECTION C PROPOSAL for the INTREPID LANE STORM DRAIN from REMORA DRIVE TO BROADWAY CASH CONTRACT No. 1139 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 45 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. "Bidder's Bond" Accompanying this proposal of bid, find in the amount of $ 10% which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addendum Date Received Bidder's Signature No C-2 SECTION C PROJECT BID SCHEDULE ITEM ESTIMATED ITEM WITH UNIT PRICE WRITTEN IN UNIT PRICE EXTENDED NO. QUANTITY WORDS AMOUNT 1 1 Mobilization $3,000 $3,000 L.S. @ Dollars Cents 2 1 Traffic Control $2,000 $2,000 L.S. @ Dollars Cents 3 1 Trench Shoring S L.S. @ —V'W!5' Dollars 000 n^ W, Cents 1 4 889 18" HDPE Storm Drain Pipe L.F. @ Dollars eco Cents 5 238 4" HDPE Storm Drain Pipe L.F. @ 1-6-4,cc, 00-)0 trA Dollars S 2 3 0 �, ►`�ov Cents 6 29 5"x 20" NDS Channel Drain #810 with 4816 Grate Each @ 50c, Dollars Cents 7 20 Concrete Channel Backfill C.Y. @ TA,LG 00_)�-o d." Dollars ��(� ~ Cents to OCR L) 8 2 Tideflex Gate Valve, Series 37G Each @ -L� Na-m Dollars — Cents QO v o iL) 9 3 Junction Structure - Type D Each Dollars -' Cents 00 vZ ()C'il 10 2 Abandon Existing Lateral Each @ <F'J& V\">�'p wG) Dollars 5 Ou Cents Q D 11 30 Sawcut Local Depression L.F. @ t,J Dollars Cents C� 12 30 Reconstruct Concrete U-Channel L.F. @ oo-u- %�wCA Dollars Cents - .. Total Amount Bid in Figures: $ v Total Amount Bid in Words: JSWV'A `mot, a U_kw C-Is LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor :State License Class Of Number Work By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange Tim S. Belczak , being first duly sworn, deposes and says that he or she is President of Belczak & sons, Tnc. the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Belczak & Sons, Name o of Bi 3510 E. Enterprise Drive Anaheim, CA 92807 Address of Bidder Subscribed and sworn to before me this 5th day of December , 2000 . NOTARY PATH KAE BARMOWSKI �°. COMM. #1203266 NOTARY PUBLIC • CALIPORNIA m ORANGE COUNTY My Comm. E*rN Dre. II6. 20M i NOTARY SEAL C-a UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the INTREPID LANE STORM DRAIN, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: 12-5-00 8elc7ak & Scns► IAe Contractor Tim S. Belczak By Title President C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes LJ No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 12-5-00 Belczak & Sons, Inc. President Title C-7 UNDERGROUND SERVICE ALERT IDENTIFICATION NUMBER (To be completed only by the awarded Contractor prior to excavation) No excavation will be permitted until this form is completed and returned to the AGENCY. Section 4216/4217 of the Government Code requires a Dig Alert Identification Number be issued before a Permit to Excavate will be valid. To obtain a Dig Alert Identification Number, call Underground Service Alert at 1-800-422-4133 a minimum of two working days before scheduled excavation. Dig Alert Identification Number: Belczak & Sons, Inc. Contrac BYO"' Tim S. Belcz President Title Date: 12-5-00 Note: This form is required for every Dig Alert Identification Number issued by U.S.A. during the course of the Work. Additional forms may be obtained from the AGENCY upon request. C-8 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Belczak & Sons, Inc. Bidder Name 3510 E. Enterprise Drive, Anaheim, CA 92807 Business Address City, State Zip ( 714 ) 998-5920 Telephone Number 291101 A State Contractor's License No. and Class 10-23-73 Original Date Issued 5-31-02 Expiration Date The work site was inspected by John Belczak of our office on 11-28 , 2000. The following are persons, firms, and corporations having a principal interest in this proposal: Tim S. Belczak, Pres.,Sec./Treas. John J. Belczak, Vice President C-9 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Belczak & s, Inc. Company J X a/ Signature of Bidder Tim S. Belczak Printed or Typed Signature Subscribed and sworn to before me this 5th day of December_, 2000 Im PATnKAEBARMOWN COMM. #1203266 NOTARY PUBLIC • CAUPORNIA m ORANOE COUNTY My Cann. Exph" Dw. U, I= NOTARY PUBLI NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. Orange County PF&RD P.O. Box 4048, Santa Ana, CA 92802 Name and Address of Public Agency Name and Telephone No. of Project Manager: Dave Marshall 714-56767800 31477,822. Open Channel & RC Box 11/00 Contract Amount Type of Work Date Completed 2. Catellus Residential Group 4000 Westerly Place, Newport Beach, CA 92660 Name and Address of Public Agency Name and Telephone No. of Project Manager: Jim Brockman 949-251-6100 1,413,405. RC Box & Pipe 3/00 Contract Amount Type of Work Date Completed 3. Orange County PF&RD P.O. Box 4048, Santa Ana, CA 92702 Name and Address of Public Agency Name and Telephone No. of Project Manager: Dave Marshall 714-567-7800 7,464,361. Open Channel & RC Box 5/00 Contract Amount Type of Work Date Completed C-10