Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
DABCO CONSTRUCTION - 1984-07-02
Improvamentknown as Sewer - Coldenweut & Talbert _ (.,"Me wtd oddrejs of profrct or mark of1mpn rrr kw) in t1leCity of Hun tinaton Beach , Coun•y of Orange State of California. _ _Mission Clay Products Corporation w (clalnnt) ,claimant, a (Corporation/Prrtnershlp/Sok troprrrtordtlp) furnished certrin labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by who:n claimant was employed or to whoin claimant furnished labor, servir+e, equipment or materials is Daj�co Qgnstrg rtion _ 1.1'arnrof Subcontractor/Contractor/Or-ner-Buildrr; The kind of labor, service, equipment or materials furnished or agreed to be furnished by claimant was Setter Pipe & Fittings !dcccribe in drwih Total value of tabor. service, equipment ,.,r materials agreed to be furnished... 46t691.06 Total value of iabor, s:rvicc, equipment or materials actually furnished is ...............S 4 6 , 6 91 .0 u Credit for materials returned, if any ................... ...............S 1,240.20 Amount paid on account. if and .................. ......................... ....S 1,358.68 Amount due after deducting all just credits and offsets...............................S—�!W * I a-.—. YOU ARE HEREBY NOTIFIED to withhold sufficient monies held h) you on the above described project to :satisfy claimant's demand in the amount of S _... —, as pro%idcd in Sections 3156 through 3214 of the Civil Code. and in addition thereto sums sufficient to cover interest, court costs and reasonable costs ul litigation, as provided by law. A bond , is not attached. (Bond required on private jobs— not on public jabs.) 10a not1 Date Jury ,a!4 `1985 amcofClaimant _Mission Clay ► Products Mm ATHY #R0TFE7M (official cepad! ) VMIE ICAT1ON 1, the unckrsigrttci, stat,.z ! sin tf.-4.:t ;�Pcretar,— G"wsentor. "prrtrde-ntc+l" "aprt►rnrrof'.**0%Orr ef'.etc.) the claimant named in the foregoing Stop Notice; 1 have read said claim of Step Notice and know the contettts tLcreef. and I certiFy that the same is true of my ow n know kdite. j 1 mtjfv (o(deck,t) andcr i enalt;' of pctjuiy under the laws of the f'tate of California that the fore going is true and corML Executed on _ . 19 . a 1 t tT jr lsi�►r, .,1 !e, �,..��stAnrtrrJ.I�.�,tt MA PSOW+(141". M STOP,1 1T� 9ko 4 ONIficNICAL "'6 w�kmr4 of ar�tr, ctnslrrttite tong or Pi6k rlAcer) o< t�•+ur K co�lractiM tt+�wl 70M MAiLoY CORP. dbe Yotl AK IIEMBY NOTIFIED TMT 90 wnkJusiM cWm M, Trtl!�t:h staft CO. 14520 S. AvAW gam, Ctrdem, CA 90248 prime as w* 70- 6.,v4 shier. tr+vices, 4 wAftri� Id tie! fdowig kw�_..i'�_�'�lrr�i.a-�--fit,._ �H�rYi 1�1� r1�1�D IKXW ("wd dts otim of w w, services, o`/ijiw or Noww t to ar for ..comma • c, . fx the work ienwore+Mrd. kotod at, or Iwro a: IN" of ptnoe to or for abom twe;sw fslikm kpt douiptim, igcriptim of sitt tr pow wwtksiml - Tt+e iitnau I in value of the whole agreed to be done or furnish*d by claaaaat is S Tire arnaant in value of that already done or furnished by claOwnt is S----�----- Ninwt ha; been paid the wm of S__ and there mums due and uto;d the svm of i�..�. � PQ pta intetest thereon at the ratt of 3 6 -per cent per annum frw. YOU ARK_ HEREBY NOTIFIED To WiT.4ftr SUFFICIENT FUNDS To SAII;FY TVIS CLAIM WITH INTEREST. 'TOM MALLOY CARP• dba .mn� ch SWiPg Co• 149MgW&Ojon`131w• G�►rt:ena, CA 90248 .iIM STATE Of CkIF IA OXTY of ..ems �7-- m4---tc` _.... aced my%: TW Jt set pre WOW wfro fk fmW-1 Star ia; tMt --k ks nod tlrt MR end t ftft tk eool SeA ttt+e 9 to k trtrt of It- so Lqwkdg totem is to any softn x twAv ttrtt my ttre om k stthd OR klm Wwashm SW WAO NW aac te cults mom xw ftw Ju Iofiorot than to k trtc J le—t sriad aw Iwo to beh" we Ay of OF rKw uJi • �/ MIDCIRI UYESUGI ►V-AWr Wreak exWO"w N hMie ar rr . PRIftore:, a•Kx m �" t t1s �,wuf 1[ f L�OtMMTY ;. w Ca++we+he Eye Orc !a. IM) 4064 haft w++wr w" �d Mew•+ b to bets tiritr}e.i_ idsft as INon vewk ► *me 0"m p"m summ "m cronva • h+F-.► ■ � aril ice+ IV" w+aa Vbmt amil ra "sl boa hr"W or ka agreed to furrrrdt._.._T1:tapahaaiu Fo_nUAD _ Galt:. le:YKti, epipnwtr ■tittitiij et Ik fdwxirrt kW Ine.tWitti.on, nentat 6 tewvat f (A"trat &SUiptito of 440, sits Les, tgMpwitt of Mtt:iblt) tow fir_Mb .0.. Col'tA4UL�.t[y�rt,, ngne�Rtr� .�'ant�tae#ahb . or t>re crock rru+provrrt ter M, lug it ax.,, — f rerMt bca at (na�t d person to � tw •Ito�s farnist,tdl Cone.tnuction Site, .W/Side og Golden Weal 5 TabeAC, Nrarttingaton 8( h, CaUgoVU4 (Afttn,1*181 dtserip!im. dtseriptfc" of site w t,raitct ik;t:i 404 The amount in value of the. whole agreed to be done or furnished by cia mant is 9 ILL 97 .r The amount in value of that already done of funtishtd by claimant it St 5S°7.97 Claimant has been (Rid the sun of $-29.3.2.40and there rt-ains due and 3"aid tht su•n of s 12935. 57 plus interest theteal at the rate of 19-2____ptr cent per annirn Irorrr. >uty 29 Y(YU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS 10 SATISFY THIS CLAIM WITH INTEREST. Dated__ �' ---• %" �--i } tit air. W-,ass d a,i^wt t, STATE Of CALIFOMIA {,O mTY of LJ .Ky-- be-4 r +f1 sworn,de�3t"� and wjss That 5. k is the persons) wtso sipped the forepq Stop Na!ice; ifrat .k has reu: r�t sane and knove- the conitnts tkttd to be true of b.trt, om ►r+owfi sk tsupt as to any matters or Wis that tray tkertin be stj4d an e•'L infortulion and btki am as to tlrlse matters and things -5 -k bek n theca to k tart. Subtc.��d arc! $worm to kfiKt me 1916 Matt) M*t ad le W for a4 SUM G'titilYl KK agtl/l' FV" • tAt Vomeom �► cs+ i*.t W411. Im tea,► 4%*** i r-M unw. OWN mod e..rrto is s+ &W Ww.a k Po llop r.1 to &r� W"W Ani V*" MV Arm tom" so AW �tr Giw Iits►. up • bwm 9 run A.e41 iihs iiMM t fir. i.� t W"x&W V r+owe iris—+M+. 9•79 CITY OF HUYT I NGTON BEACH RELUSE OF STOP NOTICE To: CITY OF HUNTINGTON BEACH �"` �., %� Attention: City Clerk, 2000 Nain Street • Huntington Beach, California 92648 " r. The undersigned hereby withdraws and releases the Stop Notice filed on June 26, 1985, with the abc,ve-named public entity against DABCG in the amount of $ 11,215.00 for labor, services, equipment and/or material furnished in connection with the original contract, numbered CC-608, for the performance of the public work of i,iporvement described in the contract between the public entitl and DABCO, the prime contractor. A copy of the contract is on file with the City Clerk. The undersigned also hereby releases the CITY OF HUNTINGTON BEACH, and its subdivisions, officers, employees and agents, from any and all duties under Section 3186 of the California Civil Code to withhold money or bonds in response to the abGve--mentioned Stop Notice, and waives any and al: rights of action against them that might accrue thereunder. DATED: X r 20 , 1985. Name of Claimant: Inland Concrete Construction, Inc. Address: 16341 Post Office Box 1463 If a corporation, signature of.- res ent or ee Presid ?--nV ecretary dChief Fin`ancal' Officer Riverside, California 92509 t 1 � CITY OF H'�,�MTiNCTOM r?1.ai.:Ls IL ST IF Paw ofsmW* vfmO fr • YN AN MW I1 TWO T*T Im Al 1101 dlolne, 146 PA- 22502 VAN iM %*ad Mr f d K hu Alrow to fwaiek m. m &Oaf 30m+..wAtArl-Al .._... ...�.11� �__.._.�. 1 i �9A.�Id �'•1rillN�f.f Al ■i��r.r i� .� r Y��w�i�.� M K for the wotk i�nprol*mK bmW at, or know #L �11+G� Is or hr w� hnriMtlq y 1dast 30,> m r 2"'m �...,u. Lrwi i ir� M N . � � I�isgt. K lgtri�tiw� i�1fM �1,111! It F*d ilatii #U* Ik »wW iw 1+We of fire wkk ilftW to bo kne or fvrBi W by Ciaiawt !s $11.211;5 00 ._..,_ The a!lreMlt iA Of tket eklt�.done a turmhed bT► C1aNawnt k i?�.�t5.sx�.._ .� �...� „� cbiaarai Ass boos pt;d the Am of and there ruins due and unpaid the sm of S—L 15 m �...r on iwwat llr m at ev rat= of 10 ...,_pct ant per mm ir._ 4f 10/85 v 19.�,_ VW ARE lE" NOTIFIED TO MTHI MD SUFFICIENT FUNDS TO SATISFY THIS CLAIM AiTH INUREST. Do mk Jima ?41 11Z ,amra t rimat 4nn Yza.- Rm 9f cWWA Mer,e*t 11 em=m �eL pp� Tint .fie k Do WINW wtw *Yad the fortpit Stop IW.ko; that Jibe hu road Im ON mw kwea tka "club tiler. 3( to be tm of k,r. IN k e, oar* as to aq motion v NAP tmt my t W"I be stated on Kr X— MtorMLW aad bekil acid a to a►ewe methn «w 06P _ mm b ft Iss tko to be trod. lli�f�i � titeMtt a ttll�r mt rw%. 10WITS POWN 06••o+. Me . OFFICIAL UAL ipFLAstwck % t liC;s MpTAFiI pMlC•CAI•tFO* jl �ALL�1F4 CO.t art CO SISS10e tit. Otty 4.101 smm& A bm wpm am wwl pobkw++ U •+ " IA+IMs A irA�w }� � :! p. W w an i ON* wow C'Iw/M f 4 m M tsar VANN* rr. Cwwk 0 Ww w if Y" Mnit Mw Ir.� a !we► <<t ~ f+vv+pq. 9 I 'etc `ly ,1. ,.r 1 .,R :,(: ^y.. _ '�i+•r--.T y,.�_- w.r.•,..Fr,.•••��-�1Ri11fr .. ., 04 7 Aeg r. toi f. MM '1'w11GTf4M�: rrlR ir: 11 1 Ale~1 OWM 0 OWO M p a p We Oft or !M OgMotwomy Aw Ci1+p AwWo NAP' d" M ft t 1 err t t +� t�l archer ���" �i1t,��1' -;► �.�. t.�' i ;;. t l l.rtMwlrt t 1 opinion AN wdMb WAM he Ntodwd. cm Ok n mm wIN be ►swrPod so rm. I w E+drii W Am" /S 7—tr t:�......:�r..t... t•;��"c:/r�=j /.%t�r�� �`'"�G,�>� .�'C/.�,�'' �/jj1G-fj�j� lCr'�/t..%'Fr+�`-�'/''�� t`Z�' •�i�/�l�r�G�? ���'ff'� '" �' c�"�': t/.�G:;:';�-'L/�, �,.�" .�'�3=� r t•i%; .t�'C.�.._' /��..e�/i -.sus• Gowme Ago*, po San 10 IV *Mom sod", 490okWM dW + Dabco, Hwtingtovi Beach Q5519. Meet Boundary 'gunk Sever MR W CALF M Ik ter— rrrr�r 11285. 'WM before me, the nndersivw, a Notary Ibabhe in end fa the eeid PA. "Mm ly awaered Mai 7 e� -C%Qa t~ _._.._. _., km" tow to M the T3M'."SXJMMO"nd-- p known to nee to be the_._..._ ._. Sl MMY Of—Tn1 AUd C's+MMite Ganstnte,+1 on, the Caporation tit executed the within rumerit, known to ae to be the peMns h executed the within instriment, on bsbti of the Corpimitkin herein rimed, end ecknowledded to me that such Corporation executed the within ktatrument pxmnt to its byb" or a resolution of its board of dirtctors. WITNESS my hand end official seal Notify st+c�o�rtto�r[KT-.ter,..rtrei & Set—weptettt fern M—ee,. 3 tt r Nov oA1985 *a.row.MWO. C,,a, w.: r 0 P..= .rr. L CMP TO s CITY OF fl"dNTUICr71 S SUCH ZM Main Street Hunti:igton Beach, CL 92648 FROM: %INLLND CONCIM OOMUCTION, ,:NC. 14_V; Rubidous Blvd, Riverside, Cl 92509 JOB: WEST BOMOLff TKMK SEC- R Ellis Avenue & Goldrn West St. R=tington Beach Inland Concrete Construction, Inc. h%-eby releases and relinVi sbec that certsin SWP NOTICE cer red upon you -- organization nn June 26, 1985 against Dabco. DU'M:, October ML1985 . 9Y: Treasurer Marilou Sheets • 6 r� STOP. . L n17 Aw st wMr�-�tl� p�r�er N �lik �rrr! �^ Munvw ri.Aeft Cft,W, Oak" M f>rlft r tt�rrwt4r try M31 AINIMAds ON" Ow ww"11 rl� rl �/ Il�ili � - j fl'r:•. + .1 :.mw .act &) _ ,_■_..,_� Oww. 181,16 flNOWK gawk" M Sh WA t, kw— be ilsilo• }pDIC�� tn..WALI-01� T___t "-Ax s 61PO tw M MM+. tM+kf� "Opp tr mrSt*W operators M 1t IN— „ —. br ft twt bW. bcMN K w W" Iltl: � 14.w��.ilrt d soft to a Ir tam IrwOf4 Ili�i� ltlnuna.�r —+ riw� Ii- MIi B -A. �t Lyast,&to iiir ..n wh biblek 610 6W409% 1•K "M 11 ON o p*tt 11.1W1•if1r� <tM t1�IwM it »IIK N Mlr .MoM tKtftltt N M t11f11 tx btrt�sM�i ly cirMt+M b;��-� ._.. __ Iw O"m b tom! of "I k"01 A" sl Ilmr AW by dowwA k i a i.? IS- 00 Ct kmd on brtell Pw put r~ M ;- ._.._ W4 lkfI (OWN tat Irl W#AW w VA 0( f 13215m 1m watil Omm N IM Alit 10, 1.... �a tt�4 Nw "m hur~._._ 1-/10/85 m #a imw Mom o IR wl om surrav rum ro s y ims am mm mmur. t 26 1 _ 3alt>sod QQSW It rya .,,., :I.^. ; Two, am of t WWO Blvd.. 1 Art" of t 111tw1 stall or Ca{.Iom Li- rd up: t'M4 -Jk is N Pnow I Ik InigaitrM Slop Ne ft Mri —04 kn isw Mrs um W brows Ok 90w4 S I WId M k bra d kot. so ftloft t, two is M a[ wilm a Map Mrs ors VwVm M MOW IM ha~,rt:.. *IitNtrlrfW aW WW M K k Mw wIMn ad &t .&k Wow In Is k bw. ' •y� ��- I._ . "- -`_mow• ftriloqfJ. Shoots — Treasurer r �rlNirhll iNi � M Mlrl w ii ?h rt r 1 Y r'C a„ a ♦ �WIsar fttrKlC t:�lKit�►M pm f1t+••"Ifn ta. M � •.ram~ w t�il+�l� Irf, Kt •.INf wa.r NAM 1110014 PPV*.►* % w i.N 10M#6/. 900-M rw .y.O r.«i 01. M 10 A %oftK •tsa► M��r�y 1� �ii � wfw ft 1m OW"An. r/w^ # b"w IF*w *OmW IM loft I "so 1w fwt w"mft l THIS AGREEMENT, wkk- ,. and centered into on this � elay of 1984, by and between the CITY OF HUNTINGTON BEACH, a municipal corporation of the State of California, hereinafter referred to as "CITY," and DABCO CONSTRUCTION, an unlimited part- nership, hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for P. public works project (hereinafter referred to as PROJECT) more fully described as the construction of Hest boundary trunk sewer, CC 608. work, WHEREAS, CONTRACTOR !, 15 beer. selected and is to perform said NOW, THEREFORE, in consideration of the promises and agree - exerts hereinafter made and exchanged, the parties covenant and agree as follows: 1. ;TA E-MENT O „}d0 K, AMEFT#NCE OF RISK CONTRACTOR 3ha1l furnish, at its own expense, all labor, plant, tools, equipment supplies, transportation, utilities and all other items and facilities necessary to complete and construct, in a good and workmanlike manner, PROJECT. CONTRACTOR agrees to Furnish all said services and mate ial ooatemalated and embraced in this agreement, and assume loss and damage arising out of the nature of they aforesaid work during its progress or prior to acceptance from the: action of the ele- nents, and frog any foreseen or unforeseen difficulties which may -1- f 4.l trine or be encountered in the pr03eOUtiGn 'of work and for all other r13ka of any do3cription coarsected with the work, and to pay all expCn3e3 inourred by or in consequence of, the su3penai.-1n Or di3oontinuance of work, except such as are expressly�i�tipulated to be borne by CITY. CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of the Contract Docu- xents, as hereinafter defined, the location of the jobsite, and the eonditi�ns under which the work is to be performed. CONTRACTOR acknowledges that i* enters ;into this ;ontract based upon investi- gation of all such cutters and is relying in no way upon any opinions or representations of CITY. It is further agreed that the Contract Documents are incorporated in this contract by this reference with the same force and effect as if the same were set fortn at length herein, and that CONTRACTOR and its subcontractors, if any, will be and are bound by any and all of said Cont.-act Documents inso;ar as they relate in any part or in any way, directly or indirectly, to the work covered by this contract. "Contract Documents" as defined herein mean and include: A. This contract agreement; B. Bonds for the work covered by this contract; C. The CITY'S standard plans and specification and special contractual provisions, including those on file in the - 2 - • offioe ' of the - Diroator of Publio Works of CITY and adopted by the City. ':C'i:�unoil of CITY and any revisions, anendmr ats or addenda theretn, the 1982 edition of Ord.,, n�,n ,�n, �i ans, for, Puh, lie Wo�.C,Q2A 'r,CMQtJ0A., published by Builder's Mews, Inn.,, 3055 Over- land Avenue, Los Angeles, CA 90034, and all amenduents thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Assoclated General Contractors of the California Joint Cooperative: Committee; D. Bid documents including the notice Inviting Bibs, the Special Instructions to Bidders, and the Contractors' Proposal; E. The project plans, specifications, special provinions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans, or indicated in the Plans and not mentioned in the Specificationa, shall be of like effect as if indica.ad and mentioned in both. In case of dispute or inconsistency between any plan or specification, the matter shall he iamediately submitted to the Department of Public Works of CITY, hereinafter referred to as "DPW", without whose decision said discrepancy shall not be adjusted by CONTRACTOR, save only at his own risk and expense. Should there be any conflict between the terms of this agreement and the bid or proposal of CONTRACTOR, then this agree- ment shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in conflict herewith. - 3 - 9200 t ■ l t ' I ow t CONTRACTOR agrees to commence the project with 10 working days after notice to proceed is issued and shall diligently prosecute it to the completion within one hundred twenty (120) calendar days from the execution of this contract by CITY, excluding delays provided for in Section 10 herein. Time is of the essence of this contract. CONTRACTOR shall. prepare and obtain approval as required by the Contract Docu- ments for all shop drawings, details, samples, and do all other things necessary and incidental to the prosecution of his work in conformance with the said progress schedule. CONTRACTOR, shall. coordinate the work covered by this contract with that of all. other contractors, subcontractors and of the CITY, in a manner that will facilitate the efficient completion of the project and in accord- ance with Section 3 herein. CITY shall have complete control of the premisoz on which the work is to be performed and shall have the right to deride the time or order in which the various portions of the vork shall be installed or the priority of the work of other subcontractors and, in general, all natters representing the timely and orderly conduct of the work of CONTRACTOR on the premises. 5.CHANGE.* CONTRACTOR hereby agrees to make any and all r.har.ges, fuvnish materials and perform work as directed in writing by the DPW when such changes are within the scope of work of this agree- ment. Otherwise, CONTRACTOR shall adhere strictly to the Plans and 4 .. Specifications. Under no condition shall CONTRACTOR make any changes, either in additions or deductions, without a written order from the DPW. CITY will not pay any extra charges made by CONTRACTOR unless such charges have bi:en agreed upon in writing the DPW. When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal in reflecting the effect of the change. Should the DPW not agree to such cost proposal, any disputed work shall be performed as ordered in Writing by the DPW and the cost, thereof, shall be negotiated by the parties upon cost and pricing data submitted by the CONTRACTOR. CITY will promptly issue a change: order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. No work, services, material, or equipment shall be performed or furnished under this agreement unlesa and until a notice to proceed has been given to the CONTRACTOR by CITY. CI&Y does not warrant that the work site will be available on the date the Notice to Proceed is issued. In event of a delay in commence - went due to such unavailability, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such avail -- ability. CONTRACTOR shall, prior to entering upon the performance of this contract, furnish bonds approved by the City Attorney: one in the omount of one hundred percent (100%) of the contract prioe to guarantee the CONTRACTOR'S faithful performance of the work and - 5 - to warrant such performance for a period of one (1) year alter CITY'S acceptance thereof; and one in the amount of fifty percent (50%) of the contract price to guarantee payment of all olaiM3 for labor and materials furnished. . Room,15MUDIKER The CONTRACTOR unconditionally guarantees all work done under this agreement, including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CI1i of any defect in the work, shall have the option to cake appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S risk and expense. • ► I , Ili►11�L'11swe1i1 It is further understood and agreed that the CONTRACTOR is, and shall be, acting at all. times as an independent contractor herein and not as an employee of CITY. CONTRACTOR shall secure, at its expense, and be responsible for any and all payment of income tax, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers. agents and employees, and all business linenses, if any, in connection with the services to be performed hereunder. It is agreed by the parties hereto that in case the total work called for hereunder in all parts and requirements is not -b- • finished or completed within the number of calendar days as set forth in paragraph 3 herein, damage will be sustained Uy CITY; and that it is, and will be, impractical and extremely difficult to ascertain and determine the actual damage which CITY will sustain in the event of, and by reason of, such delay; and it is, there- fore, agreed that CONTRACTOR will pay to CITY the sum of one hundred dollars ($100.00) per day for each and every working day's delay in finishing the work in excess of the number of working days prescribed; and CONTRACTOR agrees to pay said damages herein provided for, and further agrees thaw CITY may deduct the amount thereof from any mon-les due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed with damages for any portion of the delay in completion of the work due to unforeseeable causes beyond the control and without the fa«lt or negligence of CONTRACTOR, including, but not restricted to, acts of Cod or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, and unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall within fifteen (15) days from the beginning of any such de!.,a,v ( unless the DPW shall grant a further period of time prior to ::he datf. of final settlement of the contract) notify the DPW in writing of the cause: of the delay, and CITY shall extend the time for completing the work if, in its judgment, the findings of fact; thereon justify the delay and its decision is conclu3ive on the parties hereto. - 7 - • Should CONTRACTOR be delayod in the proseoution or oompletion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed waiting for materials, if said mater- ials are required by this contract to be furnished by CITY, or by damage caused by fire or other casualty for which CONTRACTOR is not responsible, or by the combined action of the workmen, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended Lifie number of days the CONTRACTOR has thus been delayed, bvt no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof and including without limitation the furnishing of material by CITY, or delays by other contractors, subcontractors or CITY, will be allowed and said extension of time for the completion shall be the sole remedy of CONTRACTOR. 1 pjfFEajNG ST_JE _COND''TIQNS (1) Nollsg The contractor shall promptly, and before .such conditions are disturbed, notify the DPW in writing of: (a) subsurface or latent physical conditions at the site differing materially from those indicated in this agreement; or -8- i i :yi__/. _ 0 (b) urknovn physical conditions at the site of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in this agreement. The DPW shall promptly investigate the conditions, and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this agreement, whether or not changed as a result of such conditions an equitable adjustment shall be made and the agreement modified in writing accordingly. (2) lime Extension No claim of the contractor under this clause shall be allowed unless the contractor has given the notice required in this clause, provided, however, the time prescribed therefor may be extended by CITY. CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this contract:, subject to any additions or deductions as provided in the Contract Documents, the sum of three hundred three thousand, five h►indred sixty-eight dollars ($303i768)► as set forth in the Contract Documents and provided for in naragraph 2 herein. Eauh month the DPW will make an estimate in writing o: the work performed and the value thereof. Fco-r each progress estimate ten percent (10%) plus any sums attributable to liquidated damages pursuant to paragraph 10 of this agreement will be deducted and retained by CITY, and the remainder, less the amount of all 9 previous payments since commencement of the work, will be paid to CONTRACTOR. If CONTRACTOR has, in the judgment of the DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if the DPW finds that satisfactory progress has been and is being ma4e, the CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the work, as determined by DPW, less all previous payments and '_ss all previous retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the «anner required by law, accompanied by a certificate signed by the DPW, stating that the work for which payment, is demanded t;as been performed in accordance with the terms of the contract, and that the amount stated in the certificate is due under the terms of the contract. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. After the completion of the work contemplated by this contra(."-,, CONTRACTOR shall file with the DPW its affidavit stating that all workmen and persons employed, all firms supplying materials and all subcontractors upon PROJECT have been paid in full, and that there are no claims outstanding against PROJECT for either labor or material., except certain ,items, if any, to be set 10 - forth in an affidavit covering disputed claims or items in oonoec- tion with Notices to Withhold which have been filed under the provisions of the statutes of the State of California. 15. YAIMER OF.�LAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or ax•ising out of this contract. CONTRACTOR agrees to protect, defend, indemnify and hold and save harmless CITY, its officers, agents and employees against any and all liability, claims, judgments, costs and demands, including death or injury to C'ONTRACTOR'S employees, and damage to property, arising directly or indirectly out of the obligations herein undertaken by CONTRACTOR or out of the operations conducted by CONTRACTOR, regardless of the active or passive negligence of CITY, save and except those which arise out of the sole negligence or sole willful misconduct of CITY. CONTRACTOR will defend any such suits at the sole cost and expense of CONTRACTOR when requested by CITY. and any costs of defense or attorney's fees incurred by CITY in enforcing this obligation will be reimbursed to CITY or may be awarded to CITY by a court of competent juvis- diction. CONTRACTOR acknowledges and undertakes its duty under the provisions of Sectlon 3700 et seq. of the Labor Code to insure against liability for Workers' Compensation and covenants to comply - 11 1# A with such provisions prior to oommencing the performance of the work hereunder. CONTRACTOR shall maintain Workers' Compensation Insurance and otherwise comply with all of the provisions of the Workers' Compensation and Safety Acts of the State of ',.lifornia, the appli- cable provisions of Divisions 4 and 5 of the California Labor Code and all amendments thereto; and all similar State or Federal acts or laws applicable and shall furnish to CITY a certificate of Workers' Compensatio Insurance evidencing s►oh compliance. The insurer shall furnish to CITY a certificate of Workers' Compen- sation Insurance. The provider of insurance shall not cancel or modify any such policy so provided without thirty (30) days prior written notice to CITY. CONTRACTOR shall further require all subcontractors to similarly provide such workers' compensation insurance for all of the subcontractors' employees. CONTRACTOR shall furnish a certificate of waiver of subrogation under the terms of the workers' compensation insurance, and CONTRACTOR shall similarly require all subcontractors to waive subrogation. CONTRACTOR'S Workers' Compensation Insurance shall be in forms and underwritten by insurance companies satisfactory to CITY. Said insu ranoe shall remain in for,,e until the work under this contract is fully completed and accepted by CITY. Said insurance *hall not derogate from the provisions for indemnification of CITY by CONTRACTOR under section lb of this contract. CONTRACTOR shall, notwithstanding nor diminishing the foregoing obligations, 12 subscribe for and maintain in full force and effect during the life of this contract a Workers' Compensation liability policy, in acoordance with the Workers' Compensation Act of the State of California, of not less than one hundred thousand dollars ($100,000). n[JRMEWIMMITIV144 CONTRACTOR ,shall at all times carry on all operations hereunder, bodily injury and property damage liability insurance, including automotive bodily injury and property damage liability insurance, in forras and und.,,rwritten by insurance companies satisfactory to CITY for: all operations, subcontract work, contractual obligations, product or complete' operatics, all ownedvehicles and non -owned vehicles. Said insurance coverage obtained by the CONTRACTOR shall name the CITY, its officers, agents and employees and all public agencies as determined by the CITY as additional insureds on said policies. CONTRACTOR shall require its insurer to waive its subrogation rights against CITY and agrees to provide certificates evidencing the same. Before CONTRACTOR performs any Work at, or prepares or delivers materials to the site of construction, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages and such certificates shall provide the name and policy number of each carrier and policy and that the insurance is in force and will not be cancelled without, thirty (30) days written notice to CITY. CONTRACTOR shall maintain all of the foregoing insurance coverages 13 .. a in force until the wurk under this contract 1s Fully completed and accepted by CITY. The requirement for carrying the foregoing insurance shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under Section 16 of this contract. Notwithstanding or diminishing the obligations of CONTRACTOR with respent Lo the foregoing, CONTRACTOR shall subscribe for and maintain in full force and effect during the life of, this contract the following insurance amounts: mot less than three hundred thousand dollars ($300,000) combined single limit coverage for Items A and B. A. Bodily Injury Liability and Automotive Bodily Injury Liability (including non - ownership and hired cars) B. Property Damage Liability and Automotive Property Damage Liability The City Attorney shall at all times have the right to domand she original or a copy of all said policies of insurance. CONTRACTOR shall pay the premiums on all insurance hereinabove required. • ;.. �� it �:. � If CONTRACTOR fails or refuses to prosecute the work with diligence, or fails to complete the work within the time specified, or is adjudged a bankrupt, or makes an assignment for the benefit of creditors, or becomes insolvent or violates any provision of the Contract Documents, CITY may give notice in writing of its intention to terminate the zontrart. - 14 - Unless the violation is cured within tan (10) days after said notice of iritertion has been seryed on CONTRACTOR, CITY may terminate this agreement Upon the expiration of that time. 20. ,DISEOSITION OE ELAHL E51IMATE3„ M OIBER RQUMU CONTRACTOR agrees that upon completion of the Mork to be performed hereunder or upon earlier termination of this agreement, all original drawings, reports, ealnulations, map. and other documents, pertaining to said contract, shall be delivered to CITY and become its sole property at no further cost. In the event that CITY is dissatisfied with performance of CONTRACT02 and the procedures for terminations set forth in Paragraph 26 are followed, CITY may elect to assume complete control. over PROJECT. 22. l�Qjy,-hc?CNR3ILiTY No assignment or delegation by the CONTRACTOR of this contract or any part hereof, or of funds to be received hereunder, will be recognized by CITY unless such assignment or delegation has had pricy written approval or ecnsent of CITY and the surety. 23. UIY EMPLOYEEa CONTRACTOR shall employ no regular employee of CITY in the work performed pursuant to this contract. 24. ATTORNEY' S FEE: . If any a:tion at law or in equity is necessary to enforce or interpret the terms of this agreema nt, the prevailing party 3hali be entitled to reasonable attorneys fees, costs and ;5 �.a14cs....:...J..,. ..... 'rwwe•r.n I:N1.;, .... .. ... .. ....... ...-:+: R'W�7a"'- -' -� -.+-raTNewl7:': - neoessary disbursements in addition to any other relief to which he may be entitled. If any action is brought against CONTRACTOR or any subcontractor to enforce a Stop Notice or Notice to Withhold, which nam.�-s CITY as a party to said action, or by reason of which CITY inuu.-s expense.. CITY shall be entitled to reasonable adminis- trative and attorney's fees, costs and necessary disbursements arising out of the processing of Stop Notices or Notices to With- hold or any similar legal document arising out of the performance of this agreement. Said obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. LITY may set off any unreimbursed cost or expense so incurred against any sure or sums owed by CITY to CONTRACTOR under this agreement. 25. MRA QQMaEN'SATIOf! CONTRACTOR may submit to CITY a proposal for cost redue-- tion changes in the plans and specifications of PROJECT. If said proposal is accepted by CITY, extra compensation shall be paid to Ca"TRACTOR in an amount equal to fifty percent (50%) of the net savings in construction costs as determined Cy CITY. If said pro- p:isal is not accepted by CITY. CONTRACTOR shall not be required to perform any of the changer contained herein. CITY shall be under no obl.igativn to accept any proposal made under the provisions of this paragraph. 26. MY FM L.OELZ CONTRACTCH shall employ no regular employee of CITY in the work performed pursuant to this contract. - 10 - 27• N9119E9 All notices concerning this agreement shall be in writing and shall be either delivered personally or mailed, postage prepaid, addres3ed to the party concerned as follows: TO CITY: Mr. Paul Cook Director, Public Works City of Huntington Beach 2000 Main Street Huntington Beach, CA 92648 28. parties. TO CONTRACTOR: David Poppin DABCO CONSTRUCTION 5692 Edinger Avenue Huntington BFacth, CA 92649 The foregoing represents the entire agreement between the 1N WITNESS WHEREOF, the partio s hereto have caused this Agreement to be executed by and through their authorized officers the day, month ana year first above written. CONTRACTOR: DABCO CONISTRU^T?ON David POKIn, Partner ATTEST: City Clerk REVIEWED APPROVED• r City Adminxstrato ALL:ps 9/19/84 17 CITY Of HUNTING ON BEACH, A mu. i4pal coPo_rAtiun Lin APPROVED AS TO FORM: S V City Morney INITIATED AND APPROVED: �+ Director, Public: Works •. ..i� .•It 4. ". • t: 1' /1,r, .,,• .. ;.0 '.!'. ,. ..-...o •..•4';:•.:!'.fiy,lN27t11r �._. _ .�.....--...............-.... .._........ ..... St'ATE OF CALIFORNIA f CITY AND COUNTY OF Los Angeles j c 'On thi; 28th day Sept. 19 84. before me. the undersigned Notary Public. in and for the State, pc-sonall . ! William A Sadler y appeared a person known tome (or proved to me nn the basis of satisf�c:ory r�'i ' t to be the persnn who executed the written instrument as Attorney -in -Fact, on behalf of the corporation therein narrr. ' acknowled;ed to me that the corporation executed it. i Given under my hand and Notarial Seal this 28th day of Sept. A.D. 19 89 i• I ' i• i a OFFICIAL SM �• ;: ' My Commission Expires . �.:• BARS. -NOTARY FVBL1 CALIroR.NIA a P'RI11rIPAl OFFICE IN Notary Public. LOS ANGELES COUNTY F0R%I 1161:i1: m, cr)mmissinn Exrores Apr 5. !985 1`�....�';.�,.r+�•,.. _..:�. .r. .. .,,...wn....•..........- - - ..__............«.w+.xWailC'tN�.i4V.lY�'t.t'•t;siiY�•1!k�'rN!'.i.fiiYAa""" �,..r�..r�.,...zv'rrnw�-n'xnc*v.rcza-.1............ ,: n�.....+d.w..an...,. ,. .. .. , nix\-v.YM'ATR': •t•.t.•: �: A.�Rrt .... ..... .�• Bond #B213530 ' FREkv'DNY INDEMNITY COMPAN Tti= /RCMtomT •uiLoosta 4 LOS Atv4ELES, CALtroRMiA CALIFORNIA PENFORVANCit BOND KNOW ALL OMEN 81' THESE PRESENTS: PUBLIC WORKS BOND ND. B213530 That we. Dabco Construction r as Principal, hereinafter called the Principal, and FREMONT INDEMNITY COMPANY , a California corporation, duly arthorited r to Dane -act a surely business in the State of California, as Surety, hereinafter called Surety. are held and firmly bound unto City of Huntington Beach, CA as Obligee, hereinafter called ObiiQee, ; in the sum of Three Hundred and Three 'Thousand Five Hundred Ss.xty—Eight & N0/100--•Dollars, 1 ($303,568.00) for the payment whereof the Principal and Surety bins themselves. their heirs, executors, administrators, successors and assigns.. jointly and severally, by these presents. WHEREAS, the Principal and Obligee have entered into a certain contract in *citing, hereinafter called the contract, dated for The Construction of West Boundary Trunk Sewer 4CC-608 1. AS TO rOFY: C! ty Attorney .;eputy 16'i ty Attorney 7'z� t a copy of which is or may to attached hereto, an9 which is hereby referred to, NOW, THEREFORE, The condition Of this Obligation is .hit it the Principal shall welt and truly perform the work Coit- tracted to be peiletrittO under said contract, then this cblig3tion shall be voiJ, otheiwise to remain in `ull torte and effect. This bond shall inure to the benefit of the perscris herinabove specified only so as to give a rirtit of action fir such persons of their or their assigns in any suit brought upon 'his Cond Th s bond is effective on the date of the contract. Any notice M Surety shall be addressed to or stived upon, it at c/o Robert C. Sellers & Co., P.O. Box 17220 Los Angeles, CA 90017 SIGNED. SEALED AND BATED :his _ 28th day of SePtetrber . 14 8A Dabro Construction PREMIUM $3643.00 H I ��• • PRINCI AL 0 FREMONT iNnEIMINITY COMPANY By William A. SAile r vrnn.try oa t• &rt STATE OF CALIFORNIA : j Angeles a ss•; .' ctrY AND colltvrj• of Los An g� On this 28th Sept. �.._,,,,_ day..1984 ),,.tore me. the undersigned Notary public, in and for tl:: State Wearied —_ William A. Nadler- � . personally to be the person who executed ihr written instrument Person known tscy in Fa (or rproved r bee slf of tilto ffle on e acknowledged to me tilat the corporation executed it. Po on therein named and Given under my .'sand al Seal this 28th day of OFFICIAL SEAL . hty Commission f. Ercpires ''7r`� � ARB BRAUN ;;.. •nornRy Pp t'iCIPAL Crr,r E I)p>r1A L05-4NQLE3 COUNT. i M • y Comm,SSIon �tArr3 Apr. 5 a F()Rt1 11e IZrF2 . 1- N j Sept:. 84 A.D. 19 Gi.0 �j'L HOW)- Public. U - _..,-...,.....«n.r..w.'^uJWN � . r � f .+ter • �aui�Nw.:at..vusr. e��,. ww,..•... ' 0 bond 0213530 •r FRE -x': NT INDEMNITY COMPAN a, Tme rottMomr nuii.vi110 LOS AMOtL[S, CALIFORNIA GALIFORNIA PAYMENT MONO KNOW ALL MEN 6Y ~HEST: PRESENTS: PUBLIC WORKS (C•C•=241) NON N0. b213530 That we Dabco Construction . as Principal. hereinalter called the Principal, and F9EMONT INDEMNITY COMPANY , a California corooralion, duty authorized to transact a surety business in the State of California, as Surety, heteinafter called Surety, are held aid firmly bound unto City of iiuntingwon Beach, CA , as Obligee, hereinafter called Obligee, in the sum of ore hundred fifty-one thousand seven hundred eighty-four & N0/100-- Dollars. _I5151,7134.0p� for the payment whereat the Principal and Surety bind themselves, their heirs. executors, administrators, successors and assigns, jointly and severalty, by these presents. WHEREAS, the Principal and Obligee have entered into a certain contract in eating, herematter called the contract, dated lore The Construction of west Boundary Trunk Sewer #CC-608 APPROV0 rl.S TO FOR-Mo. rJ 1L HUTTON, Clty Attorney e- : Dopni`y CC! ty AQtto::rry a copy of which is or may ►:e attached hereio,a,id which is hereby :ete(red to, NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS that if the Principal or his subcontractor fails to pay any of the persons naned in California Civil Code, Section 3181. vvho are directly employed by the Principal or his subcontractor or wN) furnish labor, natertals, previsions, provender or supolies directly to the Pimcipa! or his submitracto► or it the PrrnC!pal or his subcont i,aor fail to pay amounts du: under the llnernploynent InsuianceCode with respect to work or labor performed by any such 11 Claimant ", then the Surety hvieonwill pay lot the sate in an aggregate amount not exceeding the sun herin specs• lied; olhtiwise, this obligation shall be null and void. In case suit is bought upon this bond the Surety v+ill pay i reasonable at'oir+ey fee to be fixed by the court. This bond shah inure to the benefit of the persons hermaboYe specified only so as to give a right of action to such persons or their or their assigns in any suit brought upon this bond ThLs bond i s effective+ on the date of the contract. Any notice to Sute,y shall be adoresssd to or served upo,i it at c/o Robert C. Sellers & Co., P.O. Box 17220 Los Angeles, CA 90017 SIGNED, SEALED AND DATED this '8th day of September 19. 84 potEmium included- in performance bond Mmb4o Construction 13�• . PRINCIPk FREMO�t'�i�T�INDE1MNiTY COMPANY 0GG' . / X 'ot 40r—.n&""./ By —J r William A. Sadler a. .-,P%ns'r0 *astthr^r t� M t�. 17� �j�i•� .�?1 CSs• .I�4'v ,'a.rT •�7 .�-t.rj?Tyre . , rC t FReMONTINDEMNITY COMPANY HOME OFFICE -- LOS ANGELES, CALIFORNIA POWER OF ATTORNEY KNOW :1,1,1.1 EN IIY 'I•IW 'F PRESENTS: 71at. 1+ REMONT INDEMNITY COMPANY. lty WILLIAM JONMI ,7R. as< Vice F'rr>idrltt, in leur<uant:r of authority ;;ranted by Rmfutinn eef it.- Eloaftl of Direclon; at a mcrling Caned and field tilt the ISth day of February. I372, which raid ftr.o{utiun lea, ru,1 horn amended or resrindrd alit] of which tier fi,lat,wing is a true, full and complete copy: " U.- OLVE D: That the Pre,idcnt or any Vice-Prr,idct►t may from time to time. aplx►int :llturne t•-in•Fact to rrprerre:nt and act for and oil behalf of the Coutpany, and either tilt- or any YirwPtr.iden►, the Board of Dirrctnrs or Executive Committee may at any tittle rrmove t:►tch Atturneyae-in•Fact and rcvttkt!. tilt- {'ueerr of .Attornry given him or her. and he it further "RFsoi.%,E 1): That tier :lttornry,-in-Fact ntay he }.i%,-n full l►uwer to exe cult, for and in tilt. nanw of ant) on behalf of tilt: Cumpany ►eny and all howl, atul unt.t dt-rl.enoT a, tier of tile l:urtepany may rr'rluirc, still illy -ucll lionds or undr• takitims Cxcctttcd Lc any such Atturnev•in-1'•ar1 ahal{ lie a� hintling ul►un tilt! Cumj,any as if Agned fly tits Ptt.-ident and sealcS and attested! by :he .'ecrrtary does hrreby nontittate, constitute and appoint WII,T.17pd•1 A. S,ADIM itf tru.r and lawful :Attorney-in.Fact. to male, e:texute, brat Will tICIM r flit and on its lerhalf, as surety, and as its act alit] deed: ANY XM AU BONDS AND MJD~-TttWMS IN WITNESS W11FRE:OF the said Vice Pre•itle•nt his he•rcunto ,ulrcriLrd; lei; manic anti affi%ctl the curporWtc seal of tht: aid FREMONT INDEMNITY COMPANY. this , 6th d.ey o April :te AD.. IY79 FREMON T' INDEMNITY COMPANY t , . III• _.. STATE OF CALIFORNIA Vice Presidre,r illiam J s, Jr. COUNTY OF LOS AN(;EIX.S `--�"""""'�"' 1 Or, thif. 6th slay of AIX"d A.D., 1974, before the sulefcribcr, a Notary� Public of the State. of California, in Wnd for tilt:Count• of Um Angelc,, duly carantissiuttcd and t ualifirdl, came thr. a1mve ttatned V ce I'reAdertt, of FaE mt3:YT INU MNITY COMPANY , to ntr prummally LntiNn to lie the inditidual and otfierr dcicribed in and who r.,.rrtttrtl the prrredit+� inttrumcnt, and {e,' ackmst.lydr,ed Inc eYrculimi of 11ec s,renr, and Icing by me duly bwort►, defx,seth J711i siitlt, tl►at he i• the paid officer of the Unporation aforr!-aiel, and Heat the 4r;1 af(isrJ to Ile: IvretrJinr i•estnrntrnt iK :lie Corporate Still of the Said Corporation, and that the staid Corfr wmr Sral and his siZnalurr as such uffircr were duly affixed and etthscril►td to they said instrurr:cnt 1►y lite authority and direction of the said Corporalinn. IN WITNESS 11'1]l:f FOR I have. Itrtruttto t4•t my hand and affixed my Official S ealatt the City of I.a+ �+,ries, the .lay an;] yrar first allege written, F"wa�� — , / Orf1CIAL SEAL M / / ::::,) " 1+ .. r+►t-wr . t,Ntn. t,1�t(oxlaetd (,.F.A.) M, mil-Alls coutrltt """' ,otar� uGlir 1*1 tArIftlizwn Wues Aur.13, IM2 / I, the unJrrsignrd. Assistant Secretary if FRESIONT INDEMNITY COMPANY , fit', hcteby cr.ttify that lhr original POWER OF ATTGUNCY, of vthich thr foregoing is a fell. true and turrets coley, is in full force and effect. IN WITNI.SS %Vl{1:111 OF, I Ww herrunto -ule.eiibrdl try nat.tr at t1S51St',Mt secretary, and afGted tile, l r►tarat(! Seal of tltc rA)!jhlratiurt, slat 28L11 day of September I() BA IF � If fir. IL •� �".)lc :� Artitsfunt 5ecretar,v I VIr't S. SCei:1 pr %.wl :a/:T,1t it IA! 1t,N I11: CERTIFICATE OF INSURANCE I'll,. tot 1111111111 •I4111 lira► 11 r G lis•.& CITY OF HUNTINGTON BEACH. CALIFORNIA I'. I {. 11„, I ul t 111111tilwt,nt Itr .tr I►, I.1 rl;'r, III A MUNICIPAL CORPORATION APsK" as to Fa.m: Coil F,lutto+r, City Att�rte�• 1 till is to cer!tly that the policies of insurance as described below have been issued to the Insured Iry the undersigned 4i d ere in force at thv- time. If these pot)icies are cancelled or changed in such~ss manner that will affect this certificate, the insurance'compalry agr#ts to dress 10 days prior written notice, by mail, to City of Huntington Beach, P. 0. Box 711. Huntington Beach, talifarnia 92648. ALL ITEMS MUST BE COMPLETED, ANY DELETION OH CHANGE IN THIS FORM SHALL BE SIGNED AND DATED BY AN AUTHORIZED REPRESENTATIVE OF THE IN§UFIANCE COMPANY AND MUST BE APPROVED IN WRITING BY THE CITY ATTORNEY. Dabco Construct Ion Name of Insured Addtess,of insured 5692 Edinger Avenue, Huntington Beach, CA 92649 ---'-----r-.---•-----•.-.-• .._.,....�..._...._�._„_.... Locatinn of Work or Operations to be performed West boundary trunk sewer Itcc-608 Detcription of Work or Operations_ �.�,..._....._... LIMITS OF LIABILITY NAME OF COMPANY POLICIES IN FORCE POLICY NO. kl'eteive Expiration In Thousands (0001 (INSJ GENERAL, LIA131LITY {?Q COMPREHENSIVE FOAM CL 20-435- 10-1-84 10-1-85 3 50___..Q ._._. -csL Argonaut Ins. Co. I x PnEVISES - OPERATIONS 111383 i Each Occurance 14 EXPLOSION AND COLLAPSE HAZARD ► X UNDERGROUND HAZARD I PRODUCTS COMPLETED OPERATIONS HAZARD a I CONTRACTUAL., INSURANCE XI BROAD FORM PROPERTY DAMAGE r` I INDEPENDENT CONTRACTORS F I PERSONAL INJURY AUTOMOBILE LIABILITY I COMPREHENSIVE FORM CA 2C-.435- 10-1-84 10-1-85 III.-. ArgQr K I ONNED 111.3A4 „lute ."u. Each Occurance X HIRED K 1 NON•01,VNED EXCESS LIABILITY (•x r UMBRELLA FORM CTU 55-17-- S 1,500 Cravens Dargan/ i 1 OTHER THAN 96 10`1-q4 0-1.-85 C'entttry Indemnity UMBRELLA FONIA company WORKERS'COMPENSATION ;trd r;CC 20-1135- lri(1 2d. �iCCI. �C•tlt `r)tL'1Ut; Lrlt'. �-O. EMPLOYEW LIABILITY 1f,1774i(.1 1 l iJ• 1 - ,) I r_ 1-il`,i ..•..:�.;-�.,._••reresr.ar^•.s .•.-er.: �cc-:•i.:._•-:..; .. .: ..:: _.!.-�. .. ... .. rt-. ._ -.. .--. ..a::r.: r...c-.. .. -_-•. .. ., .,_ Adoitiunal fnst,, ;() Endoisesncni The insurer ag'cc. 10ml the City Or HIJ- r.r;rton ,1rst1 its Crt'r t:vUtlCil, lt:,! t.N all City (..owicii a111)o+"TO cf,",1+5, C,)rtsn '+'r,•� comnhS:in,is, I?.%,irdl and any o0-t!r City C'Jorlfli •i br„ay, and,'or cil'cove di-d , I)polntj►e t)lltct'rs. svi%atio ur City of Hunlinytan Heach. vOicn ,:c irn as each instilk.0t beftundcr. for tfrr .+r rs :'t y2r ry r fib r' `,: `�x rr p -11 be printary to any nismance cl t're'. C;ty r)' Huntn;utcrt i;-�zvn, ac Ih it inierr -st may appear. Date -..•--•------.--.. AUtHORITED IIC•Plir-GENTATI OF INSURANCE COMPANY ByM,� •� '"f ?� �l.�t.'s'�,�-�,i Lo t !� , 44010 ..._.....�... Atttlrt Li,)!)rlrtqule:t C�� 90067 il• .............. Cityr.Morxxre 1213) 553-: 1.1 9/28/ 114 srr,\•s+eras'a'..'...x,::Sistsssr.�rust�:2-*,•»�•�-rrr^irr.er•r-!'.rit:ir_�.. .•cr',:K,•c-.r.•:.••a_,:^'r.•:t�:r:ts:-sr'snarsX�_Israel:nra�sta.^�urz�rr.Yxwtttstaez+s�rsr.^,aaacr•:-,rt.s'e� HOLD IfARMLESS AGRE MENT (to In exccutei! by insuretf) The inswrrd agrees to prctect. defend, indemnify, save. and Hold harmless the City of Huntington Bench at otfiCers. a"rits, and emplayeas against stiv liability, loss, d+lrnape. cost. or expens" by reason of Any end ail liability. w►ts, claimj, dettiandt, ludgmilnts and chases Of Cavan caused Ivy in,.ured, his errlooytes. agents or any subconitpctitt or by any third party at►trng out of at in conle-quone" of the pet;-;rm*nca of •)I Of snY ORO,.ts it air activity for which tail Cell6cate of Insurance is lurnishtd. 'III Sot: Plop?101oyshtp (7) Partrurtshrp (3) C .,gtaa tin 1141 Other (1r lie) "01.0 14ARW SS IIGNrO. Br ttvwf*d; :11t• asm" shoot lift w►nrwj w rrvsd ,•� /9 inMw wr:A wt�u+a.l (tY twtrr+r+1; � •,,�/r(��y,�ca'��r.G:.....'itM �l �'' l�'.��='�:a....,.,.....-........_._ .,._.... it Cro"tt,an, IWO (01k etv m,r,r ken, a .yirwa+t rrridemc• of %VjhKrretrnn ra *oint t:nrw4r„t►c,1j. I City of Huntington Beach Zrw. fir 13en. Office P. 0. Box 190 11unlinxton Beach, CA 92(A8 CENTIF!CATE OF INSURANCE TO CITY OF HUNTINGTON BEACH, CALIFORNIA A MUNICIPAL CORPORATION Ap'rawrl is to Funs: (WI Horton. City Anermy 'This Is to owify that the polici" of insurance as described below have boom iwwd to the Imurod by the unders;Vwtt stud are in foray at this time. If them policies are cancelled ar chawod in such a manner t,'`+t will affect this : If3�,atr, the insurwoo Ir4mparty aws" to give 10 days prior written notk*, by entail, to City of Huntin wri Beach, P. 0. Box 711, Hurltinoon Bow*, California tuft. ALL ITEMS MUST BE COMPLETED, ANY DELETION OR CHANGE IN THIS FORM SHALL 8F SIGNED AND DATED BY AN AUTIIOfiIZED REPRESENTATIVE OF THE INSURANCE COMPANY AND MUST BE APPROVED IN WRITING BY THE CITY ATTORNEY. Name of Inwrod __._..D_abco ConstructiO,x Addew of Inured 56 2 Edinger Avenue± Huntington Beach, CA 92649 Location of Work or Operations to be performed West boundarlr gunk sewer ##cc-608 Description of Work or Operations ---- ^".1%'1r `'^' C' LIMITS OF LIA510TY NAME OF COWANY POLICIES 114 FORCE POLICY NO. 1 Effea6v I EWkvtion I In Thotraer(INIJ GENERAL LIABILITY IX) COMPREHENSIVE FORM Da PREMISES -- OPERATIONS I)d EXPLOSION AND COLLAPSE HAZARD Iq UNDERGROUND HAZARD I)d PRODUCTS COMPLETED OPERATIONS HAZARD 1 ); CONTRACTUAL INSURANCE IN BROAD FORM PROPERTY DAMAGE 00 INDEPENDENT CONTRACTORS I)j PERSONAL INJURY AUTOMOBILE LIABILITY I)9 COMPREHENSIVE FORM (XI OWNED DO HIPED I}O NOMOWNED U43276585 1 10-1-83 110-1-84 500 S_.�....�_........CSL Efth Oveww w Fireman's Fund Insurance Company IF YOU SHOULD HAVE ANY QUESTIONS REGARDING r THIS CERTIFICATE OF INSURANCE OR CORRESPONDENCE, PLEASE CONTACT AT EMETT & CHANDLER, (2131 553-2711. THANK YOU. 1800 AVENUE OF THE STARS. SU17E 400 LOS ANGELES, CALIFORNIA 90057 LA3276585 110-1-83 `10-1-84 I S 500 CSL ! Firemart's Fund I Each Ott urtrrce I Insv; ance Company IEXCE3S LIABILITY I (xl UM3RELLAFORM CIU549919 10-1-b3 10-1-84 It, 1,5p0 Craveris Dargan/ (I O'rHFR THAN Century Indemnity UMBRELLA FORM Company WORKERS' C0NVENSATION WWI 20-422•-107 10-1-83 10-1-84 100 ea. Argonaut Insurance + EMPLOYERS* LIABILITY 740 accident Company �i:Si:ta7.Tts1 G]:2:Y"'s-t.-�.�=C�JYii�'�S'.it«:SxS1STJLT..:3'1i3S"[iRJ.SEi��t^�t'4LFiSi1�T7�.RA�Si1'M"IJ.9GLtA'L'�: L"'31831 L19'.�TL'�L.�' I"""' Additional Insured Endorsement: The insurer agrees that the City of Huntington Beach and its City Council, and/or all City Council appointed groups, cornm•%.. 4s. commissions, boards and any other Citv Council appointed body, and/or elective and appointive officers, servants or employers of the City of Huntington Beach, when acting as such are additional insureds hereunder, for the acts of the insured, and ♦uch insurance shall be primary to any insurance of the City of Huntington Beach, as their interest may appear. EMETT AND CHAIIIIE$_ 11416 ..........._.. t11SURANCE COMPANY �.. /rarrwr AUTHORIZED REPRESENTATIVE By BY .�.- Addrw 180Q Ave. a:` t City Las Angeles, 9 RANCE ##400 (213) 553 City • .-�--.-.+.-�------ T�e1M �..�..�....» HOLD HARMLESS AGRE!cMENT (to be executed by insured) The intiwrd anew to protect. defend, find* unify, Wt, wW rlald hern0ol the City of Huntington deah its off e". ogsnit, and employees strAnst any liability, lass, dttrtlge. cast, or expo nrt by .*awn of any sort oil liability, suits, claims, Jeasands, juc%-rtenls std al►um a-f action comovd by Inured, hit arIlploysts, aWts or ar,Y sukorlttactor W by any third pony wising Rut of or in ctmqegW"" of the performartte of all w any ratlals air aMlIvity For which this certificate of insurance is furnhlled. '01 Sole Prcrettirttmsmy (2) Pwthonhip 31 aflan (4) 00wr bite) HVt V "AfWV-119 SIGNED; lay ir+wrad:.rnM.- In.'.s nefow r+"two p;riwlsd e+ t"Wd it b.iew stet wn.l "*� gr lnotrr+ti: _�a& .�:% Title X411169 4' .._. 11 C.»pw+rt}arr, jVfa OMivrtr, mwt IhM. w p000nt vo lopi a *4 wrfrwlt llom to birnl ra+porNtun. IF-s p 1367.43 cc ` or SUMMONS (CiTACION JUDICIAL) NOTICE TO DEFENDANT: (Avilro a Acu"do) i DABCO CONSTRUCTION COMPANi, a Corporation; PREMONT � INDEMNITY COMPANY, a Corporation; CITY OF HUNTINGTONi BEACH, COUNTY OF ORANGE, a Political Subdivision of � the State of California, STEVE LEWIS as Auditor of the County of Orange, State of California, and ROBERT L. CITRON as Treasurer of the County of Orange, State of California and DOES 1 through 50, inclusive YOU ARE BEING SITED BY PLAINTIFF: (A Ud. k estJ derrlandando) + X40• Y, 4-40 / -•--•- .wMeer tag « 44 ,l.M++r,.-- ---- CITY OF H'JNT1N4`:ON BEACH OFFtCF OF TPE CITY CLERK MEMORAND.;hl OF S_ RVICE -- SERYEO ON: TOM MALLOY CORPORATION dba TRENCH SHOEING COMPANY, i [DAM Ytw have 30 CALENDAR DAYS Mist this sum. morns Is sewed on you to file a typewritten re- spomN at this court. A letter or phone call will not protect you; your typewritten response must be in proper lege*, foren If you went the court to hear your case. If yt-J do not fiM your response on time, you may lose the case, and your wages. money and pro- perty may be taken without further warning from the court. ft /ROCE5: srawcp Dejpue4 de que !r „nimb Cgj . T fiene un plaza de 30 D S CALENMAR10E pars prrwnur una respucsta e4crita a m iquina ern esta come. Una carta o una 114mada 'teW6nica nu k ofrttwcrrii proteccivn; su rrspuesta escrifo a mJgvins tip que cumplir can /as formai dades kpiles aprgpssdW si mard quiere que la come muche su cis& Si usted no prewrrta su mpuesta r tiempa pu * prrttkr el casa s le purdert quitar w saUtia su dines y afts comas de su propie dad sin a►,so adicional par parte de 4 torte. There are other legal requirements. You may fasten otrai rrquisitos iegaks. Pamnk q&w usted qukm want to aril an attorney ngh! away. If you do not llamar a un abnpdo inmcdiatanwnte. 5i no conoce a un know an mwney, you rt'say call an anorne:y refer- abocado. puede Ilamar a un serrido de refewxia de rat ser#*A or a Mega) wd office (listed in the phone abaFados a a una oiicina de ayuda kjW fwa e4 ditreforio book). telrlanicol. 1 - - LAl w� I Tne namt and ag0ress Of tit Court is cEI nonrbrt, . dtrt"(ctan de l,e carte Grange County Superior Court � 700 Civic Center Drive West f Santa JZ,na, Cr 92701 ` �w TM name, aodttss, and telephone number of p.amtlff's atto►ne%. or p+aln;Iff ►%ithout an attorney. W (FI norltur, la din CClon t el numrro Or trlefOrit, V0. ;fJU}'dtl0 av' at -ma nc;,-rie v dr•' oe mandar+tr que no t►entr Jb'o�i✓Oref�. r" •C PLOTKIT: & RAPOPORT ii;633 Ventura Blvd. Sixth Floor Enc1no, CA 91436 {618' 906-1600 Cr � • �,+�WiYE DATE: t . t �``, `fIL. �rri' Clerk. br (fechat ru 15 149F G A4��1 L. .4cr"IrIo NOTICE TO THE PERSON SEINED. You wo served I as an inklrvrdual clefenasnt. as the person su!tl u"er trit f,ctntous name of Istpecrt y/: 3. tl .on behact Of Isaac,64.� undttr: �:.a l CCP 416.10 lcorporaten) CCP 416.60 Itnhnorl i I L:CP 41fi.20 loetunct curporotton) CCP 416.70 lc~rvatee) I CCP alb 40 (rstwctatwn or portnershlol CCP 41E.90 lw*v+dual) other. 4. by personal eletty .Ty an l9210l: •• • ftsm A00~ r 040 012 tsar( mverov for Prose ur SO M "l 1604 + • R - e- s s... . Ast"O. Cetwe+ ter CdpM•w 1� 2 3 A 5 6 7 8 9 10 11 1It-, 13 14 15i 16 17� I 18� i 19 20 21 22 23 24 ! 25 26 4 21 281 �GARY A.'PLOTKIN, RUSSELL H. RAPOPORT► CREIGHTON A. STEPHENS, STEPHEN L. SURTC14: . JOHN D. MONTE► . MEMBERS OF � L F. PLOTKIN i RAPOPORT, A.I.P.C. 16633 VENTURA OLVD., 6TH FLOOR ' ENCINO►.CALIFORNIA 91436-1861 MW (818) 906-1600 ATTORNEYS FOR PLAINTIFF 021186/65.4 CAS/SVP 1367.43 SUPERIOR COURT OF THE STATE OF CALIFORNIA FOR THE COUNTY OF ORANGE TOM MALLOY CORPORATION dba ) CASE N04 8 3 7 5 2 TRENCH SHORING COMPANY, ) COMPLAINT ON BOND AND STOP Plaintiff, ) NOTICE (PUBLIC WORK) } V. ) ) DhBCO CONSTRUCTION COMPANY, ) A CORPORATION; FREMONT ) INDEMNITY COMPANY , A } CORPORATION; CITY OF ) HUNTINGTON BEACH, COUNTY" OF ) ORANGE, a Political Sub- ) division of the State of ) California, STEVE LEWIS as ) Auditor of the County of ) Orange, State of California, } and ROBERT L. CITRON as ) Treasurer of the County of ) Orange, State of California, ) and DOES 1 through 50, ) inclusive, ) pefenuants. ) PLAINTIFF complains and alleges: FIRST CAUSE OF r.C1 ::ON (STOP NOTICE) 1. Pia;tntiff is now, at all of the times herein mentioned was a corpo•tation duly organized and existing under and by virtue 1 1367.43 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 1fi 19 20 21 22 2a 24 25 26 27 28 of the lags of the State of California, doing business in the State of California, pursuant to and as authorized by the laws of the State of California. 2. Plaintiff is informed and believes, and thereon alleges that all times herein mentioned, Defendant, DABCO CONSTRUCTION COMPANY, (herei:,after "DABCO"), was, and now is, a corporation duly organized and existing under and by virtue of the laws of the State of California, and engaged in business in th,, State of I Ca] ifornia. 3. Plaintiff is informed and believes and thereon alleges that at all times hrein mentioned, Defendant, THE CITY OF ' HUNTINGTON BEACH, COUNTY OF ORANGE? ChLIFOR.NIA (hereinafter "HUNTINGTON BEACH"), was, and now is a political subdivision of the State o; California. 4. Plaintiff is ignorant of the true names of Defendants, DOE 1 through DOE 50, inclusive, and has therefor sued them by the foregoing names which are fictitious names, and asks :hat (when their `rue names are discovered, this Complaint may be I I amended by inserting their true names in lieu of said ficttious inames, together with apt and proper w•nrds to charge them. 5. Plaintiff is informed and believes and thereon alleges that on or about September 28, 1964, Defendant PURTINGTON BEACH made, executed, and entere-d into a certain contract with Defendant VASCOv whereby DAACO agreed to do and perform the following work, to wit: the construction of the hEat Boundary 1Trunk Sewer No. CC-605. G. During the course of said work and the construction of said public work, and under and ny virtue of the contract between. 2 136?.43 11 2 3 4 6 a 10 11 12 13 14 f 15 16 17'' i$j 'i 9 20 e1 22 23 24 i •' 25 26 27 4 a Defendant DABCO and HUNT11.1GTON BEACH between October 24, 1984 and June 27, 1985, Plaintiff furnished certain materials consisting of trench shoring, trench boxes, cable, and other equipment and materials as more specifically set forth in Plaintiff's invoices, true and correct copies of which are attached hereto as Exhibit "I" and incorporated herein by reference as though fully set forth. At its special insistence and request, materials were furnished to Defendant DABCO to be used and ::he same were actually used, in, upon, for, and about, the construction of said public work, to wit: No. CC-608. . 7. The labor, materials and equipment so furnishes to Defendant DABCO as aforesaid were and are reasonably worth the sum o; $19,496.00. 8. There remains due, ewing, and unpaid to Plaintiff at the time of the filino of Plaintiff's verified Stop Notice and Claim of Lien, after deducting all just credits ana offsets, the sun o: $19,496.00, and the sane has not been paid, neither the whole or any pa.'t thereof. 9. Within the period of 20 days after Plaintiff first furnished labor, services, equipment, or materials to the ;lob site as hereinbefore alleged, and on or about October lb, 1964, Plaintiff gate to Defendant DABCO, the origins: contractor, and to HUNTINGTON BEACH, a written Preliminary Notice as prescribed by and in accordance with the requirements of Section 3098 of the Civil Code of the State of California, a true and correct copy of which is attached hereto as Exhibit '2" and incorporated herein by this reference as though fully set forth. 10. Plaintiff performed his last work and furnished the 3 1367.43 7 last of his materials on June 27, .1.985, and thereafter and prior 2 to the expiration of the period within which a Stop Notice must 3be served as prescribed by Section 3184 of the Civil Code of the 411 of California. on the 29th of August, 1985, plaintiff filed with Defendant HUNTINGTON BEACHr its Stop Notice and verified 5 Statement of its claim herein as aforesaid, pursuant to the 5 provisions of Section 3103 and 3181 to 3214 of the Civil Code of 8 t.ie State of Ca?ifornia, a true and correct copy of sai6 Stop Notice and verified Statement and claim of Plaintiff is attached a hereto marked Exhibit "3" and incorporated herein by this 10 reference as trough fully set forth. 11 12 11. Said Stop Notice and verified Statement of Claim. of Plaintiff gave notice to the Defendant HUNTINGTON BEACH, that 1311 14j 15 16 i 17 Plaintiff had furnished labor and materials to the contractor, DhBCO, statinc in general terms the kind of labor and materials furnished and the amours and value of same and the whole agreed to be done or furnished and reouirina Defendant HUNTINGTON BEACH to withhold sufficient money due to Defendant DABCO, to answer 181. I Plaintiff's claim. 191' 1 12. Plaintiff is informed and believes, and thereon 2011 alleces that the time and times of the filing and service of said 21 22 23 24 25 26 Stop Notice and verified Statement and Claim of Plaintiff (Exhibit 030) as aforesaid, there was a sufficient amount of rioney due from said put,lic Defendants to Defendant UABCO, under the contract hereinbefor.e mentioned, to answer and pay Plaintiff's claim vind the reasonablo coats of litigation ' thereunder:. 27 13. Said public work was completed and a Notice of ; 28 4 1367.43 r 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 i$ 19 20f 21 22 23 t 24 215 I 26 27 28 Completion duly recorded on January 10, 1986. 14. :`although demand has been made therefor, said Defendant DABCO has failed, neglected and refused to pay said sum of $19,498.00 or any part thereof and there is now duct owing and unpaid to Plaintiff by said Defendant, the said sum of $19,498.00. 15. Plaintiff's claim has been filed and all proceedings in connection therewith have been had and done as required by the provisions of the statutes of the State ,,f California. 16. In the preparation and presentation of said Stop Notice and verified Statement and Claim of Pla-intiff in the Institution of these proceedings, Plaintiff has employ.:d the law offices of Plotkin & Rapaport, An Association Including Professional Corporations, as his attorneys and will seek a reasonable fAe to be allowed and awarded Plaintiff for and on account of said attornuy's fees herein. SECOND CAUSE OF ACTION (PAYMENT BOND) 17. Plaintiff repeats and realleges paragraphs 1 through 16 of its First Cause of Action. 18. Plaintift is informed and bc^lieves and thereon alleges that Defendant FREMONT 'INDEMNITY COMPANY (hereinafter "FREMONT")t was at all times herein mentioned and now is, a corporation duly orcanized and existing under and by virtue of the laws of the State of California acid authorized to transact business as a surety upon bonds or undertakings in the State of California. 19. Bei;ore entering upon thQ construction of said West Boundary Trunk Sewer# No. CC--608, and performance of the work contracted to be done thereunder, and in accordance with the 5 1367.43 1 2 3 4 r a 6 7 8 9 10 11 12 13 14 15 15 11 18� 19 20 ► 21 f 22 terms of said contract, said Vetendant DABCO, as principaal, and Defendant FREMONT, as surety, duly made, executed an(' filed, with said Defendant HUNTINGTON BEACH, a certain surety bond bearing the date of September 28, 1984, which bond was made, issued and executed as aforesaid in accordance with the pro visions of Division 3, Title 15, Chapter 7, Sections 3247 to 3252 inclusive of the Civil Code cf the State of California, which bond so given and filed, referring to thtl contract above mentioned, provides that if the above principal, contractor, person, company, or corporation, or 'iis or its subcontractor, fail to nay any of the persons named in sail Civil Code Section 3161, furnishing labor, materials, or services, etc., ;or or about the performance of the work contracted to be done, of for any work or labor done thereon of any kind, then said surety will pay the E ame in an arroant not exceeding the sums specified in the bond, and will also pay in case suit is brought upon such bond, such reasonable attorney Is fees as shall be awarded by the Court to the prevailing party in said suit, such attorn+;y's fee to be taxed as cost in said suit, and to be included in the judgment therein rendered; as in said bond and in the above --mentioned statute provided. Said bond was and is in the sum of $151,784.00 and contains all the stipulations and agreements required by said act to be contained 2311 therein. 24 25 26 27 28 20. Said bond was duly filed with Defendant HUNT'INGTON BEACH, and approved by the regularly constituted authorities thereof. 21. A true! copy of said Bond is attached hereto and incorporated herein by reference as though fully se: forth and 6 1367.43 i 1 2 3 4 51 6` 7 A 9 10 1) 12 1:) 14 16 161, 171 16 I- 20 21 22 2; 24 2! 2E 2i 21 !marked Exhibit "40. 22. Although demand has been made 4hereforr Defendant FREMONT has failed, neglected, and refused to pay under and pursuant to the terms and conditions of said Surety Bond heritofora referred to as Exhibit "4111 the amount due Plaintiff for said ;labor and mati�rials furnished, to wit: the sum of $19,496.00. WHEREFORE, Plaintiff prays judgment against the Defendants, DABCO CONSTRUCTION COMPANY, a corpo r e tion j and F;?rHO::T INDEMNITY COMPANY, a corporation, jointly and severally,, in the sum of $l9,498.00 together with interest thereon at the rate of ten percent (10% ) from the 28th day of August, 1985 until paid, t►cether with the costs of suit incurred herein, and for reasonable attor.ney's fees in a sum accordire to proof at trial and further prays judgment against Defendant, CITE' OF HUNTINGTON PEACH, COUNTY OF ORANGE, CALIFORNIA, decreeing that any monies withheld by said Defendant under and pursuant by the verified Statement anJ C1446ra of notice herein mentioned be paid to Plainti�'i- be applied in paymen. and satis action of this iudgmern; hatJ For such other and further relief as the Court may deem just and ecuitahle. Dated: 34k PLOTKIN i RIPOPORT An association including Professional.. Corpor �r.s 7 n . la 4 "r"irl. 47 , for PLAINTIFF 1367.4*1 1 In 13v?.w.. prMr3*4"D INVOICE N0.42480 i. 1. _. • wrrwrd � .'l�p�'fl ti �•i+:f%• l 'w r(Jl/�1/�.r��, i4 :�;r'y y 11ElMIr'-•�;;;,... t '�..I f•+ � w. ram- ,� • / �1 %..• f. �. / >✓riA� /",•r �' I ( I„r'•T r.. /" �Ib•.'I•r.'1/'w•'• �%/l�t"Iij/•Vl�..+•,. ���y. PaNTAL• Q SAi.E �} �i�wa •�Iw,ll•ten D col.Tlwvcn �o '� ✓ /� j Cd� 7 Ri`� �...,,...� ` tc -� a w. pft •//�� 4. c , ` A Y // G M/ rI1 jF• IMY 1 MAW dTt ZYI.IICR MF I 1 D'14a ( I •� I 1. +�/• /� C7K.(,ri I I�L�/Y'Li.r- �i':� �./' t r• r �_ 11 •�! I..�r, rwr..r• r�rr. I..i w rr V o 0 i 1 i r.'v- I •� .• .. /!' ...f:.i: I rrr, ! rl1l. `IL, 1 / I � j t ( � ..w........w..... `�q,..• S (+-illy. I l--L%•'t'^•� � � �I L-..• i ��. 1 � �' ♦ % � L1 �.1,••! t �� K" . M''' r �; �i 1 =?- tot In ' i �.. ' ► f'�'.' L.r '.w'.' � �'`' 4w �I+.S.,' �✓' r � � 1 M• . �i t ' i.. t ,�(, • w+'Y t rr c�,�-rt>�r..... }• 1 +.1. . Qv i t=-w 19E- �'� . 1•�.�.:.u�••A•�w.' yL_ /'••1 r't ._��. 1 r • �riw�r � Sr I] r.w7i.i i•. Y ij _> ter. 1L� 1� 4+ �r � ,,.•„_ :. I i w...,....... tN� iwrl MIMft LATT !A!#Wt t'twlli� 1�" ai�wlis PM/� Mtk IAi7 qua. ' r'Ult'Ii �SC3 ''A � �1 � •• Rl�tafWT Of TOW aIJrpv�F K aGx+M0lws+fANU AND PROVIS VISORS fiALii TA7i SUM Of NE !t!M[1$t SIX A40rM. #1 !i PjWtAL 09 L.ASOM ' &AIX ►.t ir![LIM[RY t•Ntt►1��r1�. w lwhl RT � 'fir/..rr, • '�' PICK -Lop CM%IRGC RENTAL i1C�J►LA WT •' w EXHTEIT "I" �. i t q I It till 1460 WXnh AVA&M 06VO 'VOICE NO.42133 ' Rtfl it74dH+ . pt+t1 la+••+iio ' �, �_ -F c'_r_. �,. � .rr..�^. .r rr.rrrr ya�„� 1�+D 't'•�� +fir ��rr.�Yi.. ��rr .rr�...�unr...�Y•��♦ �� Z��N�� ,��+�• ,ter---- SA c On I 0014 SNVID" we? If" pool �- -4-' 411 I ., Vi. air �,� , • „ ' �; s marts acs�lls►tsOt. ,� ,,+wit poses i t , ,_ --Pit I It I &LVES 1 �r�.ii.% I hit- 1 iz�T'✓ .y�'l••�1r' 'D I I 1 i � w M i A rrM�•. } { I A .- ;,,,��=--,,.;_. emu_ , J= L � �"' logy '�^ _•>' i 1 � c _ x I � f 1 I I f 1 - � r � � ram• • - �.. "J11016 wwvm LAT1 FAVW"T 11140" l 6% DA6moc '1 ova* w IO VI ►A" AVi RECO#PT Of TW AIOVf 1S ACKJVCWLLOGfA AND AROVISiOMS STATf-DON riyd RrVtltSt SfW ACCEPTED, at IT PENUL DA SAIL PCLIVEA'Y C , MCK-W c"Aprol my ......�.i....... PU"CNASZS " ! SALE$ TAX Ito I LANOR Lit ' �RtN?AL RT r R [SALE fMr • . N1 ' rV-,< A. �.=•:.tl+s:.%irti�.i:'�ti4+tt�.•'4►•Y.'.:•';, t •, 1roww'R•-or�rVC ►wa 006m' OWALM.lttr�.•_... a�;�,�WIVIALS INVOICE NcAim .rnYr. r irr"...rrrwirii..r.. rYrrw ty{ M►t1i r'f { AMIa A7'k iJ ii � rMOM Qua wV000 RNT Is" NATS tip, vf• � "» f�'�-'! , fwvcr• - / !�'" 6�IiMTiTT � DtiCwMTK7A uMN FAIY.i � t• Tt;Zw; • f l rrrr.._r i ! I ' 1 f. '�( �Ij��r f ;... I .•.rr�l.V•• ti.f 5 I �f" .. .r.: ✓ , it r..�`I i `'"�I (..•�7'%.►•.rc:•,.,,,,i �, _*32t ° ; •.. �.,_. .ww�.A I _ w-+•w �...+ Vim. r .r....� l �..~ ( r .��1 i.... M•'� ...• r f 4 � ' Yrr wYrwwrr+Ywwr i I h+ pea OWN TM LATt W404" e1+oAm w ""MOM t' "0 to MT1 P"7 nut• I r�....—...... "` RECfN7 Of tME AROW IS ACKaI'6+t► .l0GEG AND fAgIVISPOW SALES TAX W •� „y:. SlAfEC O+v Twf REWASf JIM ACCfsTEO, st iT item AL Oft LAi►r.�R 61 $ALI. DEL►VERV SMit*1�111G SM ~ '••� .; 1=i PICK-Uf C►1AMRSE j RC?fTAL f4t • � 1 � 11CSAL[ Ir"Y elf i ...■ fir. ' •�nl . - .• ` A Gli )ia,.z• � • A1rt�y,a..trluls . -� :�.a�s`s4�t,';. -•,,. ,.,,�,��,. ',E T-w .AZK &ac *7 lop �y r •.. r. 41, IttMTA1L .`ASALt Q w!A►pp w OTr •1r�a �' `=Pon o"a i.4t\-. yt to s.� T+sw, Ova prvoom" w. IN ALAIMO elf:— ..+. • . •11 `111 Y•..- .. ww,www•Y., fM1%p,W 91 . TV twil ftoqt Ps AS Ai 1 Ilan(ww+..ar I ,• .r.raGl.. � ( L.:. Lr,:�.` :• :..,..� ; � T ! CJL' t`:'7'�t"�:._ U.J2.'�, r • j ` i N.'S t> � i.;' , � I 1 fwe'J ►J I I J tr'L � i � M; - ir..+iuiMl'a `^ _ �- 1 ;i•i-- _... ' �`-'..,r �,C: ... � . wrI.I.Yr � 1 a ►rl. u r r. - - _ _ _ - � ( - - -W •Y••W •rr.••/� ' 1 rr•+.rU w�wwA Yr.O "n ftO 4rtr VW &AYS FOWWO" C*AAW ON 6.I600= o+n0 34 WS PAW" %A- PURCHASES rp � _- AfgLrA* ' of TW MOVE IS ACtrI OWLtOW AND 1JROV.PDW 3K%LCS TAX iD � STATED Q* Twt Atut*st S+O[ ACCf+7fo. at tT AINTAL CI! LAVOR Lot s4LL r. 7 ""INC llii Q QCLIVLRY � fi:, G(r� .''`. t1CR•U�' CKARG� 14t�7yTAL ItT R4TSALt my TOTAL H VP Ird -90 (A PC 1064i; 6 FAN"ALM sum "an Sam AWL*N 64APBOM ,QM T._V � Tw d5U' pop* •100 SALE kii P "C& all .06 lovia"t. —1-� •E18 — TZ I 1TV I L1141'T P#IiLt nttI IW I "'t Vj%"QWj Cv"b= MW *ALA P.W4 VVIP 30 JKTS PA" PUL. PURCHASCS NfCf so,,. or rNf.WVt IS ACKKOKUDGEP A)VP PM0VI$F0#d SALES TAX oc :TAff jo oh, THE AtWIRSE V" ACCIFTED. Of #?'RtNrAl 010 SALE. LA60P LID ,n DELIVERY 5"IPPING 1 S" i rjCrL GMARGE RENTAL IRT NY I ; L; L -WIll fi • �.' ���rk•. w� �,•+'i �' JOWA .Sy,•/y iyUlw�� •/ySGF'tVyKV ,' tyr- �..'r _.,a p • i;,, �•l. % •� • ti••+..N ia11,�p RW.n AVAtow �t.vvi. ..: r•- •: ♦. a.. IMICE�ttA►�t7•�Mut Z 9 7 6 4 ,. _ ♦ p1,t►Ts , .. 01, TE JOG --� i ,X.�t4 !,/r:.yTivr1-7/ . c.lG�r fr. w...�. .. '.: :i:�.lw "'\F, .a�4'�•�.'�.r��ti:.. '. wr..�4+ ... r �.� .. i. ��tiri� .�.�.... wry � • .t✓ A .. , "-�• SALE r�r«wc ' . teftir.rrwna 'to nrwa _ - , •... /#Jr' •� _ f I lb 0%* W V OrCI *C. �,,.+.�--.w 0* 1 f rP, V 00 * . • .. :.. _ . _� _ - _ 51x- �r++..rw.��i�r..�rr.raw .._ z.:.,__. { n cam, .' .• . ,: •,- �; ';. , .� 1 otsca�rr�trw uric pact 0116 . odti►i 1 �, ;" '� • . 1120 NOW 1 / f ✓-- I --- rr 1�?I.+ / ✓Ll•l L.ti='%LG� I• I, lil��... ��r...s:•..y;�•�r:s..;..lzsr.r ::::.. { wrA•Y�Yrr•�•w.Y• 1 1 rti4.�y� (. . ..r .. r li• •. � •1'•SL'.1 ��r�1Nw/r r.� •• 1 .r• � { • I i i � j%%VCR no ff„ ukll ►A"AGWt Ck^#M a. "ti AWAS CW11k 76 oars rwtc art. � P1J1tGMtAS�f }'R � REC&P7 OF TMf t#0VE IS ACKAlOWLEDGEG AND PADWSIOH' y SALES TAX 00 StA7W_D Ow TI/E AEYERU 501 AC+:FtTEC. it 17I.EMTA; GA (LAS4it 411 SALE. v L1[LIYCRY SHIPPING sH ` ( Pi K-UP.C"ARCC r RCSA6E NT 1 � my m M*?ALS &W.M * MOAVW umm IW(iq AVAUM DAM INVOICE NO. M03 A - .-AVO-9 AP— of --60/M.26.4- rwb T, ~4"rw �.- -1. .77, off" C) coal wwo D .1 a wa owwoom wt- op" too "t*x AC 6 JWV W. Oftbis P.Ar115 17 vo^ ."WOME wooll rovirl plot, .4M= 10 e. -.7 ij w- (Ab S02" xrc, #,I i-f4-pet wav- va Ir" PIIV "NY" LATI VAlfsaw CM*m 0^ ""Wt" avg n PAXT wt.. 1PURCHASrs Mir l a AfCEOP7 Ot 704f APOV." IS ACKMIDA-LOGID AND I SAUS TAX stArep orb' rNr stiviotetvot occenra oi ir ottmTAL op Lb SALL M DELIVERY TICK-00 CHARGE 11 v - SHIPPING SH jt WENTAL "T dp � � t arn�u►�'iati��i�► ���r�.at :.... ...... ''"�'''�' 3�t�t+R'•�+�it+�i'�r�`:+i:w.+�• rn,a�. • F"' 'may �1 •• •� ����•' 62 Y • w • • � .. tom. ,//��.// //'1 j#/�.�,1�r�:/r`r"�►� • •wn+ r 1l�i'I`J SAI.0 G n na wrM.r,..nc `_ "- _ n► r /• • jj OMAN 1 t>t a;, l,ln lQM WWII FROM Ft► tLi)j/It!'F./K. fwa ol �v ;....., ...... _ . [/`.- .» r^ a 1 1 i i I i I%%ofN WONT" ►urt ►av"dwt CxwtlC[ Cpk &ALAP+Ctt Cfta% PC G-ATY OW Wt AECF"1►T Of Tf46 AROvt IS ALKhOMwi EPOU AND PAOvJSJOVS { SaLG� T Ax ►►: STAr4rD cw THf. !vEVEAS1 SfDE ACCEITIC f !T AFMTAL 00 1.ABJW LE SALE / J DELIVERV � 1'!CK•UI' LHARGE� /• 1� t REh'A& RT o� J RESh:.i NT — �-- ✓ w .7,Y_. N { t ' •„� ` `.. •1s�� >/L14RM Ar#LOM �iY�1. O"Oe+K CAL so" fir«,. . _ R 1 �! itT�e♦ • i� •�.' t�r..re�a "no No. 41721 • � � +�/ ....,,.y� .1,+�/ •I �~fit ev 'i1L� Rpl'fAL - • • ,' F'1 r(iAL[ © �.toriCl� ti.TrrrltlAt�O rt�'t �'' ?won Gi co+rtrryip TO W+� ►�+r{trW MO.,�...�. �N t t N� ►MI t + r� • �. � : ra .. T IMWDirg DATL f scnNtlG•, %mv, 0*14:1 F 101Ai • " I I i k � ,r Iin � �� �" �� L f.• Cti�i. �� �� I 1 , 1 . .•-------� I I t lrl { 1 it% Ftli aAct •A,#bw"T cStAsict ce» aA..wttt twe ft cars ►Ai' twt I'URCHASCS PR Arr_suT pr 7'r4t Alf)Vf IS A:x1VCYN•..f&:;FL. A$v✓ ►A6vrS1DK: SSA -CS IA,X PQ STASfD aA THE Af►rE1tSE $IL! ACCit 94, dC I' RENTAL U0. I LADOR t.8 • SMtQ'►r{NG 5� Ft OtL1 CY PICK-Ut CMARGE' I FLNTAL R7 I PrSALE h'? •• Y S ft r>t; Mri tlMrr � � hel1U�Ia f NO., PO4 R !b N&MM" t"rIL • ,........ . t Ujdl Nofiice Prere i to Ia Fi1ia� Cloin� f a Aod/p r Stop Nofie�- '�4�C� `ay PrermGt iry Totten ' tt0: tt ttJr Kea 1 � "W"'tm itiMw Gi JMT71 .f ` g n • ftleatlS w V r rr er M F h 4 ..+ elww. It t1�a d Yrllt w net r.rrr p* wq wY+QTrM w' Wore. "iJ�TM�T►Oit Lfi�Q' •• Mr lt+r «....u.. r.,...re.. .www .errrl• �.,.� f"rw._ w..r ...a..► .we". our... �i �.� ..��... Lemnos ins• bat WO, calif CM1 sae. {11 Taa w"Waw It a" tmmcoS r t1""It is Q 1�lXil"fl tDr xttnttetl Owner Pour "I"I:T . eafrf fe an w10I9 tarn coc000 is me - too PpI1I-C r ru .r. w /a.. e1I00 errwtf"Al I% }*tote tilt e' er GSS.wrwr.*w Ua.Ia ^� CT" or =a'1�1! 1 � r w"c wa=� � u ' � w Suet: �- rMORMAMOM � n urea M derwe of 9two V" It an xw tinx Ast+Iw= MISS be tl7rer►tetlll SIParowat sate rnK {1a�o rtwa it ea•tr nectar to wWISP,% tw sowfeeallpfetl bw wart' '•ti.rliW, to %tv Mae Y pMav No "" ' Its tllt7tlftV{i � ~: COttlltfM•IVII mor Re .ec contrano., tti Ml, er' xiftllM COMT. c t h N t 502 �..� Y XAM AV" at• r `. v StrOtr: n.` Ill 111:1 C"ix 11110 co w «� 1r w r+�• .a Itlot f• tIw►+tl of *Seer a*tt7 be wit t e.t Am SM AOOCM me, w reaat•Iaae to, tar+'ef tee Owl�«+ ta.tta " M rtnwr r .%item Ieelarww I1 Sow Uevl rr* tire ataetttlrp !•+ wa"w •'KIft1tJ1: CWT11tslCTur w two •aa, jnU term 1n HOT L. A7Laciwtnit's List►--JAtMY t, Lara: toltuirwmer.1 Is pretest litre{ Riots$ Tat wire it rAe Lr" cplg;l 6.4 PSIS IrWblrw►1r trrttt "w" ea►•wIStsa+r+' era. CLMrT1AMS fa' wo' © l9111.MAX ♦ 9" lepat. awwaeet Irn.asw • *1I'retll; w 'X 'tour ea (efGIVA. CCKTX .106 te.•rs rISlew. Syr, a.tw etI Ielal arrwrfw ~ ww Yof�ietrM.wditt be artac• Iwwwm 1 ►doltWoo-IN r+w ,tt rE...rs ~vowwiva. aH MrtIS' IM d*ete a�f ~ Ica" AM .tarU M.i Or MOU attar PkA. TO p rtMUt dna DAL. .._._._. Trench $t►ortnr' G3. fwlet 7L)Z zrfr- STTOt!,r_._...�.---••��-trot{.: v'w-•� - -- ._.. cm • trf?: �V�CitJI�.Q,M./ r• � �,�__.112 �' •- � .�«r.0 ��..��-ter .... ..�...r.� /............_...----,•--...�_�.... „ .. ttJloate*I tY /oaM.r►ISet �frt'' arts Iel+!' The tlateete/ ar f+t acne' tf+++I r how trlee sew rxraaree « erewnr+I . 7 -�'- 1 Q kogmow W „ fry ter $**v "410.44 OW" ale a" MMw7111a►I bras • �"' it*r to wnimlrl'a" Its ►ate rtlr w a" ft w-woea oft? to Li]M R W CtI1R TOWT atA1 T'YTIOf M n►sI/ltlbielgrae Ae*1e�eat� 1 Kr►N on t i Kaaa►T1 au rn nw su. Paz. uumm cfu m n", "Ir►i"Mawl XPOW Iertow to fell wooftl" vowits wttl« ISa"Of Ifloo a rll/atehl row to 0-woo" WOW M IIIe wcaee.et td 11 moveA -I :ear wlt O"w N I►r ►Itlt� it r row into*, errc t► OWN oil eI dr woo" wider oft Ia1wWW4 ettgt+ eleftec to t"Gol "It ~ i.rec, """am ar+lr ltlt twat r oft wou- lelle' tit womot", t r taNwt IftV tenet eaen+lrrr of them 3111, vw" ►►ow Seth* twownch 1\rY. Mhia. lin.V*Wnt. IS, V~MtIK F Ow h�f w6 Wim e Ooswt„ar td w tbo-tow t/nldl tatorce It Ir MOMIc ter sel000wm be /See► char• I t.i fifet, ~I, w a eaceaaan Owomm111111♦ K low vo-wry i e►tT Suer a' I.or.. IW4 a, I IM1491 Its wltlerelC. Comm K aM etch" It low !tree• e• rte►anw idle'•, to Ire ptttlyl tar'• e ftter. w twevoot towifeKltt, one Sol"0 eartsfewovolp eaten►•, If spot. of It tfr teilvw carrorlltltftet' M o. a tnrw trl..w Mlr.e►f OW1144 to twlltfl1_ Its ; tacaa/ fh► cprtretta', er awI WAN Sip Verne blow iIt• Medal, a M tlerow "WI have wiee"We I, }Ilciler :111, as trrw/t Wft t.ara a e,rlit• cbp"v'f arTt 1`114F arrfM• atd W-x trrnllr fapr'. Mna.co, OWIV"Wftt, a• or11'fitrye! ►11011100 t 1.11r a1MraHr te' w cbewoic Iewee• 111411 ISM. a- Ito W%.CF f .Ante to 111,'t~1t1olic U efq „ribot vqv e wKW INS IOU. beat'. M t ♦e•tNrt to On, tlrfw W We ItM1t r1 t .aitt► It WOPOSelc tr.rlt it Ire r.1"t It "Soo trwtrrvcirat lent*!, If O"'v. w It lit rrWtut Cert•ttKtllp let lea,, I' P't1, or .ftrirr 4'9, I,fq,l.r,t t.f'.tl In d-fltnawr I" f►'1I Ittttb. It It* fTffw.,wgr. .thee tr-tfSK It •• ►Madn'eMrn 1wr O"t rt Ka1 ►r e'vI• n^1- ivr 1ar t1is ten �rr1.1r�' ttw/ , ttw ford tvw..►tit IferISr►K , tl, eatNea't*'f'•. IS, Pt01If41 h the tret/1t. Some a{' tv "ll"t "IS fO71C•,erlie 0/ eonvot• eru11v tar v Sow howl IMKa teMlat•Ier" r rttartn.clt tu'tllsttet r If be tyrw.tne:, twf[ IS Short tI t Iw11vewv er ►Ayer• tot Nye{ ee two+otrtot atlt r totlr„t11 91 lots rose -r•to IV Oft -two it Ierlt�atflt t wf Wan* ewt aal•r l : t/ fteP eerwf lot--*f'••'R W r Web- ertr.tl IIItn I""fnt. *1 twQtr-WL OT1.e went. r' rho r.trlfr .,hf te"tre ive la• e.trc%ml f• tor• Iorw. II•tiatl felm"11 t'• r -10 0t SOIL iJ tagw. if bill, Ore Slat void it fvti for the laloar, sere- ices" T%%liprt►eml, et r.1ateritis turtished a• to 1►t Wr'"Wit1e. a ► ov smic•r fire 194drrft tC ttw Will, through hurt f*ntwtare tr corwinyt, rt Ott of }tart of you, prspel•ty Itwint k impteorse fi yoy o{emi Oveintl the Propo"T e on havil POilt your cr-rttrOtter M tul.. Tot; rtltry with, to prowl younalf r>tointt fttis cofuequehct by tit rrVeir>x„s tav• t+ntttcty' is fur"6-- r t4wf! n1eaas bT the P/r►IIt1 or fin+' /ivint yea tW1 Itotlu btfert rmkins ►rl'Tt"l to ysur tar"mt- ►pr er tT, tslfr OtA1rt rnrthk Or d"kv IMISh clt it d'rerve►ette vrtMr "It tirrowornt'incet. O to UKI, e►1ttl to crow ►, t SWISS It rp 4NO,rw wvlo "' It I ed rYtttLter9tl ".nC Irr" O". It ►r- bvw.r•"w►te 1n.0t g1/ w1tI lift at ftT•r11 ltyf 11"'f aractfr.rt .f WISsow yi i t. 1.4r Iw'f.tt S%W! eta. cc -tip. Rt IY /Mr1,l. r►t O1Yt•4ru I" KKr Irer• 1.w.1 it' h•f' hoe:, , le 11'/Ka1rC e't1'•1 K' 1rt,IfMe entttr*•, a" IK1t'frt llrt[ ty�I+e• ...< wa. OW"wrr a•^rnel its, ►ht Nt/r r' few -WI 01 t.t".e.tr.Iyn• Ilfyt W" 1.7ts a d/ttwtwla". .1e/lact a r4lWort I,► itvl omr OW SWISS, "W'it 04" IS" v"I- won to, If►Some $ Pltel' Slef trRwr. IC W IM1f to taerttlC 11 %owl tarllUtat w1w tlllergttatll it' gone It .,rt ►ISTOC• 1t erTh'19t'1tl'♦ It,tr'1*+I•t04 fY 1.."RI"tri tere,..rt Ivfa Hl.rt r it b tw—%* 4 It 1' leleaf Ir"Kl M.t.fntewl •• otletl'•'rou ltrrrt (leer IV-.tPrt It I rat•rltt ►. c t*fuw croft atcllf ty' Ia f� f efa'et,-e.a •• /M114111 M ►1I'f1eeC Y I.aII,e114dw to a1 so. r v VaMor d'Ir' ter M+ e"KrMnt M1rr t'.IIIS a { trr'Iw PNWy t.t1.Ie ►a' Wv ISM, X VIM r'+t' owm.okle•r •rwI• la►t' wn<e eatwlw i M *W"Mefl It ISM Oven c ItAMIt i,R• erttrw I'M FNM•. to af1111MC I/ /beer t 1'wr am I nelSS.t It .,thtwo 04ty I" het iwwa Irrr•Itf orw.Ieya": r' rwo'Irrlc 11wrwlryw meta• tw at" "IV to low *mate a1 Iat'I aelre. tell or ewe ►r.rr ►1lrretrhlt. It &a. W•p rltw•' OVMF tr awllrK tw/T It. r pS•wft, W-w-re. Now rw w tyrw.t it I O." I1a rtt"Il e• a/1e10a1trs trwfr,"O Steel low H Iw't owiter *Hone' iM re.e PHIS o- ft etNt.• , for twl tot tew.ter' «sae it 111 e'*'•e to a,r M11r. w I•tt.Sr er t ea•*ttrw tr.trl to P0e"4e7"•II"' 's"St'rl *We 11wIII'10't aM tan MAUO, f^r is oast it, ►ASS+ (8,.0,W49• 6w.r w.. **ter• {ltar•1r I ttrwtlr'.ISwtion r'•• bttf'r► )CW I• G•t.tw } r' t... t.n•1y11• ut1' trlSSttrtwt (eM fI M r N t •tw.e t wee J ' r "• • to e.et. e'w.. O"'I'.e Ste+ ♦err 1 "_ . r _ ..- : >. f ..l S 3 7 i Arked WIN '�1►1\ti1�'�� .�'iJI'1'1 STOP NOTICE "m n f111 I f Y 11f m of FM ( IMb r ~ fpsuo"ar I♦h' t e oot t uv: . �'Y"' �A\ � 1�oR+4t(y. tl 1QQCi tlt fUt': --- — WAWttl r MN• or RMu,icsr• wwi TW µALLOY CORD t:u+ TrtnCn Sraint Cc you Akr Kim 43104C 10A, bt s+"ttnut+ct chant'; 14.20 S. Avalon lilvC. Go+rdena• CA 4024 anv tut meZ# j1 7 Gp /i9 ,♦ It31trlldelet In I�tlfL if ItMkv �" f'r_7"_f* '.� 574.,%t.0 C r t 4'd406*r- t1aV#"n tatrltt Iru,ww tttJ jx-=t�'A T It""s 10:1064a♦ 11 Now w•rcll t104Mtl to ftwIIK it r W Pik i�f .r' =, (_" W I t w► Ap0101IRL" %CJ?rt 1: s LAM t! Now a' 14110 Is Y to, ~ tovo"" uwv:. IH' att!•t+N MK�Nw P SII ♦ hwM MorMt♦tIr ' Ito orrA ' r Cato! t' Im ••oaf felt, !: to We 6, IvImo?: to Vag.'r.' C let ealQa!' r Imp r ttu a"ft:• cart V. I,r". tr• cart', [italJ R' U. t+.'r a'! tfar ttsT L' i a'i '•`r'! •fu r "1 4% tmas IM W. t• i�Ci �•!�♦J+--r •rT hu enter trrror r t+e rrt e' _i_? cr. tr• Imr "cr 1 t ; r ► ill, h5ttil;: l: N'lhti' : 1. WT. 1. �^rtlr N'1• +o'jc: cry t;.a•.r�, ;,,s a�74E sop fa_". I' ".awr S1Ar, D CA I%ttr.► r CUT, Or �!�, y•__ .' L`w_ f { ,+. _N C' Ittt►...L`, r _. _ I in Or, trvf. 1t$me! or uw. our —it is to ammo *V. t.t'ftt IN frepAj I'm 4-0 IY —to W +tr: I" W.4 era •+test toot tw1w-. rwev IC IN t}af t' Lr, VW aft♦rejff juts' r. It OF- n"j'% a NIft tau' w. twe- Do tom v tJ'— nr+n.rar eat IeW' tK a tt "ftv Wir. lot trigs _.!e It♦tvt: tort f: to VIC -- _ • y-' 1 � �+� � � i< Imo. r,,..,,�'''��`. $aflaG+lf m re Hutft* L. ort rf to tt:._.rs.C"tr_._.fa+ r t �'. • _,war L ♦j'. L.,,r;.;l.- % Ir' i a . - . r , t M-'-»"'�-....�, ' i � M l rjijR . (tY c $ U; A•" y.. .".�..,- c.. ,. -" ' r.+%` -- '.. .. •e„rrn A. tow. 4,r.r �.,,.a...1''� tMV ta i bm" elr Ott It, trl Up I M .ri'•t��t ;,..wn♦.,.. S 4.` f. wi',. •M+K Yw. to" eY W ` V� w �• •++r.Irt♦ lot t1w to lu. "W arwt.f In♦r iw.wr low, sw r-sam W Dw b"I Iwbe" t+.%. rw tr+ omme a f: to 04 I•.nI► r"IO•' wM�tl `" Is"4. frw►oo wq*A a. ►w+ Ir.wwr► Cntrw. .wrww • ♦ru Done• h /wwt Wow. rww OWWMr •r'e+:.s�x.'r'�"�Niii"*.�ii1i it �s1�"'r • rr .rw.wJ. . XML £XAY.11BTT "3" '" Iht6.0 tort ►t.trbwt 111LIOLDING ►OS AF1a=116[S. cALIF011"A � r CAL14AMIA PERFORM-ANCE BOND tKMOtti ALL yEH BY THESE PRESENTS: PUSLIC WORKS gqN D R0. 2213530 .. Twat wt Dabco Construction as Principal, hereinafter calla: tht Ptincipal, alit FREMONT INDEMNITY COMPANY , I California corporation, duty autt,artted it tarlsaet a surely business in the Stitt of C111101nrt, as Surety, herernatler tatted Surety, are htlt ant firmly bounC unit City of Huntington Beach. CA as Obtllee, hereinafter called Obllret, In the sure of '=hree Hundred and Three Thousand Y'ive Hunt: ed Sixty, -Sight t n0/ i00--'r)ollars, ($303, 56P..00) bt the payrent whereof tnt Prrnc+pa' Inc Surety bind thtf�selves.:hev hells. etecuiors, azmrnistrators, succ:Ssors and ISsrfns„ jorrrlly and severall).:y Ihcse ptesenit. WHr-RrAS, tht Printipa' ant! 4blrjet have entered lnit a cenarr, conitt:; rr 1vrrtrnt, heternatter caitec Inc contract. Cited log: The Construction o. West Boundary 7ru.nk Sever 011-C-602 1 . 6C!.,' l.ttcr my I Copy 01 which is or car be attached he etc. art whla:t. is hereby Itle►►et It. NOIM, THEFr.FDl?E, Tht condition o! Inrs Millatron is Ilia it tht F1rn;rpal s' oi: well and truly reriorr the wor►, cor- lretled It be ottloln�et unoet cart contract. leer Wi obllldlror wall bt voie, oineiw-. ►t:air it, lull latce air etlec; i hri bond Stilt Inuit It tilt btnettl Gt Slit persvmS htt+habovt S1 ti:let W) St IS It 11vt 1 rrjht of aurae It Slott perser.s or then o' their Iss,yns it, any slit bsouiht upor lhrs bond Thiz bond -I & ef,ective on the date c. the nontf act Any notice It Surety wall bt arcrtsset it o! server ua9or 1'. at c/v hobtr: C. Sp A1.lerts x Co., P.C. box. :72: Los i nae:es , CA 90017 S:GN EL. SE A_EC, ANC OA,' EC this 3E'.1 ca) of 5e �terr.�e: — , .. 6 PP%MrUW $364:s.00 °m a�wr0 mr .» EXHIBIT "4" 0abce Gann trur't + er. FREMONT INDEMNITY COMPANY VERIFICATIO14 STATE OF ChLIFORNIA 2 COUNTY OF LOS ANGELES 3 I have read the foregoing C.'MPLAINT ON BOND AND STOP :NOTICE 4 (PUBLIC WORK) and know its contents. I am an Officer of TOM MALLOi CORPORATION dba TRENCH SHORING COMPA2NY# a party to this action, and are, authorized to 6 make this verification for and on its behalf, and I make the s verification for that reason. I have read the foregoing document i and know its contents. The matters stated in it are true of my own knowledge except as to those matters which are stated on 8 :information and belief, and as to those matters I believe them to be true. 9 Executed on February a-� , 1966, at Gardena, California. 10 12 TOM MALLOY 13► 1i4 � 16{ 161 17j i 18i 19� 201 l 211 �2 f 23 24 l 251 ti 26 2 s " 2b 8 1367.43 I CC,(A if A L SUMMONS (CITAClON JUDICIAL) NOTICE TO DEFENDANT: (Aviso a Acusado) DAVID POPPIN and BRUCE POPPIN :individually and doing business as DABCO CONSTRUCTION ar:d DABCO CONSTRUCTION; FREMONT 114DEMNITY COMPANY; CITY OF HUNTINGTON BEACH; ONE DOE, TWO :30E and JOHN DOE COMPANY, YOU ARE BEING SUED BY PLAINTIFF: (A Ud. le esta dernandando) MISS1014 CLAY PRODUCTS CORPORATION, a California corporation You have 30 CALENDAR DAYS aster this sum. rnotts is served on you to file a typewritten re- sponse at this court. A letter or phone call will not protect you; your typewritten response must be in proper legal form if you avant the court to hear your case,. If you do not file your response on time, you may lose the case, and your wages. money and pro- perty may be taken without further warning from the court. `rc-9os - b - Ps' /7 AM comor v" arcr iJ&O A404 CITY OF HUNTItIr VI" ; OFFICE OF TIE CITY CLERK . MEMORANDUM OF SSRVICE .,.. _.�.._................ SERVED ON; 1C£FS :t9'JER IMLI j1► • Despues de que le ent c, anon to tcratr I! tiene un vlato de 30 DIAS CALENDARIOS pare presentar una n'spuesta escrita a maquina en esta carte. Una carts o una Ilamada tcalefdnica no lr ofreceri pra!eccidn; su respuesta escrita a rrtaquina tiene que cumplir con las forrnalidades kpiiles apropi,idas Si usted quierr que la code escuche su cam 5i usted vn prewnta su n-spuesta a liempa purde perder el cwa p ie purden guitar su salark su dine•ry y otras cows des su propiedad sin asisv adicional nor parte des to torte. There are other legal requirements. You may ExAten oteas requisites /(VIM. Puede que usted quiera t,.int to call an attorney right away. If you do not Ilamar a utl abopido inrnediatamente. Si no conoce a un know an attorney, you may call an attorney refer- abagada puede llafnar a un sen•icio do mferxnciai de ral service or a legal ,aid office (listed in the phone ahocados o a una oficina de jilvda legal (rlea el directoria book). te4eal6niraj. Zhe ra-T;:• and aduress of the GG.1!1 it, i; nit nhrt ti d,-'r`C1 ion fir la (fine e-%, Cast NuvNI K 1%**%"* •a 4 Ate, SUPERIOR COURT OF CALIFOR2:.A, COUNTY OF 700 Civic Center Dr_tve West Santa Ana, C.:ii`.orn:'.707 Th., r!;Jtllf. d1:;'e"s Ono 1t.r;it1or.e rj",ver os v,ai'lt.fl s atto,nvy o' t1ainuff Mi!IIUUi aft 811(11n" 1;,` r.. u4.io a• 1 1 r )!r a , , „, ri,r• 1 t• •!,•, 1r :1N 1t f'' 1 tlt, ,1 '.�1 Jrlf1 �1••. (b r11.1r/fl.lnit' C. (le (1t•1•j.0-,'.1,'1:v (joc no 10ellf' J�r:Ir.la�1 f'1r n l M CLEMONS & CRANDi>,'" Attorneys at Law 11*417 South Broadway Street Santa Anal California 9 707 DATE 1...� 4 (I �C? J �f..4Clerk. tlti - .i.�i►�•.L.1.._'.Lfr! a_�—L'1Lrl. .t .�.. Deputy rJOTICE TO THE PERSON SERVED:Yau are served - 1 1 as an mjividual cefendant. as the ne►son saved uncel itiv f1^mious none of ttsorcify1 1 1 / r /''' � t 7 ir•'j� v ram, f r 3 _ /� ' On trihp. O. /See C lYl. i 1`11� under: I CCP 41610 Icwporatl(1•n) C :P 416 50 lmtnorl 1 *CCF 416 2t7 Idefutntt cotravat1t1n1 �T CCP 416.7.` lconservateel CCF 416 dt; lrassa�.tartltsn o► part le,sru;�1 �� CCP 41t3 SO Imdrvtdu(r11 1 4 L-_..-! try pdr: I diltvery on Idefel: Xn.m AdoOrid M ALM oat IS+e1 rtllYOfve lot hunt erl sory o, tGkou,N as CM1tM'►o� o;al.,.>: 1w., .Nvft 'v 1 19A• SUMMONS ccr 41! 1'. 1 2 3 4 5' 61 7 I $I 9 10 CLEMONS & CRANDALL Attorneys at Law 1417 South Broadway Street P.O. Box 2396 Santa Ana, California 92707 (714) 542-4757 Attorneys for Plaintiff IN THE SUPERIOR COURT OF ORANGE JUDICIAL DISTRICT COUNTY OF ORANGE, STATE OF CALIFORNIA i 111i11 MISSION CLA:: PRODUCTS COR.PORATION, ) CASE NO. a California corporation, ) 12 } COMPLAINT FOR MONEY PUR— Pl aintif f , } EUANT TO NOTICE TO VtI'rH- 13 j HOLD; TO ENFORCE PAYMENT vs, ) rOP 1J-. OR AND MATERIALS 14� ) FURNISHED UNDER SURETY r DAVID POPPIN and BRUCE POPPIN } F3l.-)ND; AND COMM0N COUNTS 15 individually and doing business } 161, as DABCO CONSTRUCTION and Ur1k CONSTRUCTION; FREM-DNT ?NDEMN,; TY } ) ;R COMPANY; CITY Or' HUNTINGTON } 17 BEACH; GNiE DOE C)OE and -IOHN: } 1 DOE COMPANY, 181? } Defend<�nt:s. } 191! i• 201; Plaintiff allcr,es: 21 22 23 That plaintiA f does not know the `.rue names of the de- fendants sued herein as O-:e Doe, Two Toe and J,)hn Doe Company and 24 that when the true narne:3 rf sold defendants are ascertained, r fx } will as}: lc�e�e o� this r:�urfi to emend this complaint. 25l1 pluxntiL.. a p 2b y' x I 21 That at all. times herein mc:.,ntioned, plaintiff was and 2811 now is, a corporation ::u3y organiZed and (27.istirig under and by �I c��.ucr�:. ti eA►e�a+��� �� � yp�7►. �c,�wr,�r l40A APO CA.* 1 virtue of the laws of the State of California. 2 111 3 That at all times herein mentioned, defendant, City of 4 Huntington Beach, was, and now is, a political subdivision of 5 the State of California. 6 Iv 7� That on or about the 6th day of October, 1984, said de- 8T1 fendant City of Huntington Beach made executed and entered cl 9into a certain contract with defendant DABCO CONSTRUCTION, 10 whereby said DABCO CONSTRUCTION agreed to do and perform the 11 12 13 221 231 241 25 1 26 27 281 Gc i V0915 6-PANDALL t'*3+sat+R s' Vw ;allowing work, to wit: construction of improvements to the construction of West Boundry Truck Sewer tCC-608. A That during the course of said work and the construction az said improvements as aforesaid, and under any by virtue of the said contract between the said defendant, DABCO CONSTRUCTION}� i and the said defendant, City of Bunt inaton Beach, and between } i the 12th day of November, 10841, and the 5th day of May, 1985, � I both inclusive, plaintiff furnished certain materials consisting! i of pipe and miscellaneous building materials to said contractor, DABCO CONSTRUCTION, at their special instance and request, which, said materials were furnished to the said defendant DABCO CON- i STRUCTIOi., to be used, and the sane wf-re actually used, in, i upon, for and about the construction of said improvement and pudic work as afore -,aid. VI That said materials so furnished to said defendant, DABCO CONSTRUCTION as aforesaid, were and are reasonably worth —2— 1 2 3 4 5 6 7 8 gi 101 i1 121 • the sum of $46,691.06 . That before the filing of plaintiff's stop notice, hereinafter alleged and mentioned, there was not paid or credited any part of said amount, except for $10,358.68 paid and credit granted of $1,240.20, leaving a balance due, owing and unpaid to plaintiff at the time of the said filing of said stop notice, the sum of $35,092.18, and there is now due, owing and unpaid to plaintiff, for and on account thereof, the said sum of $35,092.1E, no part of which has been paid. viz ?'hat plaintiff furnished the last of his materials on i the 5th day of May, 1965, and thereafter and prior to the expira- tion of the period within wl�ich claims of lien must be filed, and, I 13on or about the 31st day of July, 1985, plaintiff filed with )� 14 � i ,i the defendant, City of Huntington Beach, his stop notice and 15�(� verified statement and claim of plaintiff is annexed hereto and ) 16 M l is hereby referred to and made a part hereof, marked Exhibit � , 71' ff (Except that the amount of payment was $10,358.68 instead of j 1a(; SA,358.68 as erroneously recited in said stop notice) . That said i 1�11 stop notice and verified statement and clairr of plaintiff gave I i� 20 21 22 23 2411 I 25 26 27 28 CU MONS a CAANDALL AV,'OV%E'M ►1 LA* 1w r4"k. p- W#00*Ar I.ANT/ A%* 4CALK notice defendant; City of Huntington Bench, that plaintiff! had furnished materials to the contractor, DABCO CONSTRUCTION, � stating in general terms the kind of labor and materials furnish- ed and the amount in value of the same, and of the whole agreed to be done or furnished, and requiring them to withhold money due or that might become due, to said defendant, DAECO CONSTRUCTION, to answer said claim of plaintiff. Plaintiff is informed and believes, and thereon alleges, that at the time of the filing and: service of said stop notice and verified statement and claim of plaintiff, as aforeszid, there was sufficient amount of honey due -3- t 2 3 4 5 6 7j 9' 10 11 12 13 141 L7 from said public defendants to said contractor, uncle= the con- tract hereinbefore mentioned, to answer any pay said claim of plaintiff and the reasonable costs of litigation thereunder. Vill That prior to the expiration of the period within which claims of liens must be filed, and on or about the 31st day of July*, 1985, plaintiff gave written notice of his said claim to the public defendants above named,and to the defendant, DABCO CONSTRUCTION, in accc,_d with the provisions of Sections 3103 and 3181 to 3214 of the -•il Code, and on or about October 29, 1984, provided preliminary i. ce to said defendants in accord with Section 3098 of the Civil C: , nf' the State of California. IX That the improvement hereinbefol -cubed and rren- 15�1 tinned, and the owner, City of Huntington Beaci,, -e received 1 16! full value and consideration for the said materials ;shed by 17!' plaintiff to said defendant, DABCO CONSTRUCTION, and used the 18 19 20 21 22 23 24 1 251 26 27 28 CtA MONS A iCAANOAII 4%T0ft% rb At UAW �e t Saul" #^DADVNAY SA%'SA AkA W&+A 1• t., !.A) 4!1P construction of said improvements, and said City of Huntington Beach now enjoys the benefits and value of said mater%al.s fur- nished and used in the construction thereof, as aforesaid. X That the peril.d within which claims of lien must be filed for record has expired; and that ninety days has not elapsed since the expiration of said period. XI That although demand has been made therefor, said defen-- dant, Dj%BC0 CONS"..RUCTION, has failed, neglected and refused to pay said sum of $35,092.18, or any part thereof, and there is now due, owing and unpiiid to plaintiff by said defendant, DABCO — 4 .. I 2 i 3' 4 5 B 7 �I 9 I 10' 11 i 12 131 14 1 151 t CONSTRUCTION, the said sum of $351092.16. xil That in the preparation and presentation of 3 atop notice and verified statement and claim, and in the institLLtion of these proceedings, plaintiff has employed coup: el., and tha' the sum of $8,000.00 is reasonable fee to be allowed anri awarded plaintiff for and on account of legal fees herein. SECOND CAUSE OF ACTION Repeats all the allegations contained in Paragraphs I. II, III, IV, V, ►ri, Vill VIII, IX, X, ?:I and X11. of the First Cause of. Action and makes them a part of this Ithe Secgnd Cause of Action witY out repeating the same herein. ii That prior to the commencement of the construction here - VW in, and in accordance •:vith the terms of the construction con- 17,! tracts between the other uefandants herein, said defendant, f 18 DABCv CONSTRUCT70K, as gricipal, and defendant FRMNIONT I14"'EM ITY i {j ; 19c11 CC>•:PMZY, as surety, executed a certain performance and payment i I� i 1 201 bond, �B,213530 for the purpose of compl;•ing with the laws of the 1 i 21 State of California] which said bond refers to said construction 221 c•.)nt Tact above mentioned, and provides, among other things; that 2311 it shall inure to the benefit of any and ail persons furnin-ping 24' 15 I 261 27 materials to be used :in the work described in said contract, so as to give such persons right of action to recover apon said bond in any suit: brought to foreclosure the liens pro%rided for by the iaws of the 5aate of California, or in a rcparAte suit 26IJ brought on said bond, end further provides that in case 5ait. is C►f.FACAA <Ait !j -5- t 2 3 4 5 i 6� 7 8 9 1Q t1l i 121 13� 141 15', 16 17 18 19 20 21 22 23 24 25' 26 27 28 %%Z MQ"S • casino+ LL SIMOWW VS AT 00 j a t t &0W ►+ 1r0*VWV $""A AIK to".M. rI01 swsrii a brought upon said surety will pay a reasonable att"orney's fie to be fixed by the Court, and plaintiff alleges that a reasonabxej sum for the prosecution of this action is $8,000.00, III T:.at on or about August 5, 1985, plaintiff gave defen- dant, FREMONT INDEP+ITY COMPANY, written notice in accord with Section 3240 and 3241 of the Civil Code of the State of Califor- nia. THIRD CAUSE OF ACTION I Repeats all the allegations contained in paragraphs I and II of the First: Cause of Action and makes them a part of this the Third Cause of Action without repeating the same herein. II That within four years last cast defendants became indebted to Plaintiff for a balance due on an open book account for goods, wares, merchandise and services furnishers to defen- dants at: their special instance and regaest in the sum of $35,092.1E; that no part of said sum has been paid although duly demanded and the same is now wholly due, owing and unpaid. FOURTH CAUSE OF ACTION I Repeats all the allegations contained in paragraphs I and 12 of the First Cause of Action and makes them a part Ur" this the Fourth Cause of Ar..tion without repeating that same herein. 1I That within two years last past plaintiff sold and de- liveied to defendanto goods, wares, services and merchandise of ..6— 16! 19 20 21 22 23 24 25 26 �T 28 LImc+rs IL CAPADALL At'7("YZ A' LAW t e t ` SOUTH MRYDOA I !wll & AMA OftV i 2' 3 4 51 61 7� a �I I gl 10 11 12 11 14 12 • the reasonable value of $35 0 092.18 for which defendants agreed tc pay pl&intiffl no part of said sum has been paid and the *an* is now due, owing and unpaid. WHEPEFORE, plaintiff prays judgment against the defen - darts, and each of them, jointly and severally, in the sum of $35,092.18, together with interest thereon at the rate of seven percent (.71) per annum from the 5th day of May, 1985, until paid, together with costs of suit herein incurred, and for a reasonable' ji attorney s fee in the sum of $8,000.00; and further pray; judg- ment against the defendants, City of H!intington Beach, State of j California, decreeing that any monies withheld by said defendants', of any of them, *anc:er and pursuant to the verified statement anU claim and notice herein mentioned, be paid to plaintiff, and le applied in payment and satisfaction of this judgrx nts and for 15j such other and further relief as the Court may deem just and 16' squitable. i 171i DATED: October , 1985 CLEMONS L CRMDALL Attorneys for Plaintiff BY: HUGH L. WRIGHT -7- PY Stop Notice -� NOT ICIE TO _.....rTTX--nZ..HVIITIS N „"BEACH PMBLIC , i�QM§ DES ..._...._ 2000 Main StrAirefflInklieftaftVach, California 92647 (Addivu) (if Job i file with oftix of conitolkr, auditor, or other public disbursing ofl+rcer whose duty it is to make. payroants Under provisions of the contract.) (if Private Job — fik with mponsibk ofrxv or person at office or branch of construction lender administering the construction funds.) Prime Contractor. Dabco Construction SabCoatractor(1fAny) Noma Ow,-worpublicl1wr. Cite of Huntington Beach 1mprovmwt known — Gol.denwest i Taibert (NaarW d &are" oj'rojfet or *#rk ojiTVroWMM) to theCity Yf ..-rr�HotiYVw{L Beach , Count) ore Oran State orCalifornia. Mission Clay Products Corporation _�. ._�., ,claimant, a (tie Mend (CorpWation/1'ariff"Af "Ir Proprkrorsiripl furnished certain labor, service, equipment or materials used in the above described worl. or;mprovement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment or materials is — DAbr-Q Con s t uc tion, (h'arnr ojSrbrortracror% Cowr►a;roe/Orrner•Swidrr) The kind of tabor, bervica, equipment or materials furnished or agreed to be furnished by claimant was Sewer Pipe t sittings fdeirribe M detain - ,. T.. I . of . WILLIS J. CLAANC " ! CLEMONS & CRANDALL ARCA COOS 7;4 9TCP14KN 4. CdANDALL A'ITa"W" AT LAW 049-4757 1417 SOUTH SAOADWAY 1".0. box 2396 SAWA ANA, CALi!"MnA UM July 26, 1985 City of Huntington Beach Public Works Departmen•i: 2000 Main Street Huntington Beach, California 92647 Re: Mission Clay v. Dabco Construction Gentlemen; Enclosed is a S;:op Notice in which Dabeo Construction is prime contractor for $35,092.18 Yours truly, CLEMONS & CFtANDALL 03., V)� . WILLIS J. CLEMONS WJC : sh encl ._... _ ...... — ._. — -y _i ,_ .._._.. _. .. .-.w-«�+PRC=..:��S s!�54�'Y ..Z.-.%c;Z.Z f� 1 *11V CW M IM01 INNER —DEPARTMENT COMMUNICATION To ; Wayltie Lee From : Lee G. Evam Aocau Ling officer/ Mwkoe City &qit er sublat: 1?AB M/F7M P * 'ITY ..-_ -, [ate : Sepbeemr 22, 1987 MET HOME TFtW , 0C-60g Pl&.irae prqpam. a cfi+.ac in the awmtr of $22,683.25 to Ftem it Irdamity Company as final par rent .for Cash Contract M rher 608. In addition $5, 225.53 in proj-,�t fua-*.-is should be train fered to reinbvrse City Acmunt 415445 for Ironies spent to re)air a traffic signal d mWd by DK9M Construction. the remaining project Rinds should return to the Mty's sewer fund as liquated dmrages assessed against DABCD tbnstruction. 7he che(*.should be sent to the attorney representing Frer=t Indnaniity: Mr. Brian Case Lanak and Hanna 170 South Main Street #20.) Orange CA 92666-2890 Fe: l?f' BM, Claim 857385, Bond 213530 LCyE:,7M: i}: CC: yCi ty Clerk c:r%� - Gr WOTOW W&W INT&I-DEPARTMENT COMMUNICATION M TO JACK 'NILLER Principal Engineer Dabco Construction SUWWt [CC-6081 From TSD ENDRES I Deputy City Attorney Date September. 8, 1987 All of the Stop Notice claims on the above referenced project have been resolved and we have now received all of the necessary legal documentation. My understanding is that the city is presently retaining $43,308.76 from which $15,400 and $5,225.53 should be deducted for liquidated damages and traffic signal repair respectively. Thus, the sinal payment on :he project may now be made to the surety, Fremont Indemnity Company, in the amount of twenty-two thousand, six hundred eighty-three -and twenty-five hundredths dollars ($22,683.25). If you have any questions, please do not hesitate to contact .me. Thank you for your help in this case. GAIL HUTTON City Attorney By lr'� ga"-J� TED ENDRES Deputy City Attorney 37451 ' WHEN RECORD p MAIL TO: CC.' REeoMa IN 09Fruc. laiY UI: HUI+c riNUTON BEACH OF ORANGE COUNTY CIA Office of "!ha Uy CWk ����� ;1. 0. em y D -4 ! PM l 10 To ,Hunti�►+�ta� 8e�th. Ca!ii, .,92f�F' . , 301 COMPLETION cam. . . .LOW V NOTICE IS HEREBY GIVEN that the contract heretofore awarded by the City Council :f the City. of Huntington Beach, California to 1§22-Edinver Menu, Huntington Beach. CA 92649 Who' was the company thereon for doing the following work to -wit: construction of the West Boundary Trunk Sewer, Project CC-608, in the City of Hunti rMtoir Beach, California That said work was completed by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach at a regular meeting thereof held on January 6, 1986 That upon said contract the FREMONT INDEMNITY COMPANY was surety for the bond given by the said company as required by law. Dated at Huntington Beach, California, this 7th day of January , 19 86. City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California STATE OF CALIFORNIA ) County of Orange ) ss: City of Huntington Beach ) I, ALICIA M. WENTWORTH. the duly elected and qualified City Clerk and ex•officio Clerk of the City Council of the City of Huntington Beach, California do hereby certify under penalty of perjury, that the foregoing NOTICE OF COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the OfficE of the County Recorder of Orange County by said City Council. !bated at Huntington Beach, California, this 7th day of January -, 1986 This• &oouomt is seloly for the arriaiai bustross or the city of Nuotinttoo Eoacy, as contwr- vieted under CoYrrrMmt Code See. $103 and SWUM U McOried /wry of cberso. ., �.tty erk and ex-officio Clerk of the City Council of the City of Huntington Beach, "nraia WILN RECORDED lNll : Un 11F HLlNIPGTON U ALH COWL' (4 tier! CRY rAAk f.0.fk%196. ihP4wwiu) air- di. CAM. 92AA? r,0NE0R0 COpI ► Not pied with a EXEMPT i - C 1 NOTICE tf COWLETION PO CC•fy08 • 'Itwo NOTICE IS N€'REBY GIVEN that the contract heretofore awardad by .-e City Council of the. City of Huntington Beach, California to , UL[dimpr Avenue. Huntin tor► Beach, -CA 92649 who was the company thereon for doing the following work to -wit: construction of the West Boundary Trunk Sewer, Projecc CC-608, in the City of Huntington Beac;,. California 3931 f 8dX1 o 99 OFFICtAL REC OFM OF OAANGE Coulm CAMMIA "4 Q0 Pt:; jAN 101% COATV Frccnotn That said work was completed by said company according to plans and specifications and to the satisfaction of the City Engincer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach it a regular meeting thereof held on January 66. 1986 That upon said contract the FRFMON1 IN _Will Y QVPAHY was surety for the bind given by the said company as required by ;aer. Dated at Huntington Beach, Californit. this � 7th _ d,y ,,: January ly 86. 9—tv4;tT— c o erk aneo Cerk of the City Council of the Ci:y vt Huntington Beach, California STATE OF CALIFORNIA ) County of Orange r City of Ifuntirgton Peach ) 1, ALICIA V.. WENTWORTH. the duly elt4tec and qualified City Clerk and ex-officto Clerk of the City Council of the City of Huntington Beach, California do hereby certity under penalty of perjury, that the foregoing NOTICE Of COWLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Dranse County by said City Council. Dated at Huntington Beach, California, this 7th day of January __, ig 86 Tula das~t It oololT fsr tht official ►"Inoaa of the City of "tln!toa hang. as •eateer- plat04 wr.lor c4vorrrwl ce" So*. 4103 arnt r1Mwld h meor 44 P"a oP cMryse. �It4ytrk i ex-o C 0 C !rk of tht, City Council of the City of Huntington Beach, California Ur*F *IAL L POINT PEN ONLY — PRESS FIRMLY ,! C"m RECEIPT i • CITY OF HUNTINGTON BEACH A4' ►O sox i:i HUNTINGTON BEACH. CALIFOI.NIA 92644 I71 �) sus sst>t m- 4792 47 >r+:aG MD. CITY TREASURER -- WA1RREW, kALL vig 25J '2*00 TL' wile. r� O: p DEFT ISSUING _� S.c ..J 1..t.._..� DATE i �'"'r' .yam RECEIVED FROM Jt/ A D D FI E SS _ _ % Yj J y.2 >• `" - -- F O Ft AMOUNT FlFC0Vf O CASH[] CIIECI[ yt i ACiAn *ftkRfCF#VEU fi.' TOTAL No. 3 2 5 5 9 6 CusTOMER COPY USE SALL POINT PEN ONLY - PAM FIRMLY. CAM RECWT • 'CITY OF HUNTINGTON%dftN 14i HUN10#WDN BEACH, CAUFOVNtA 9Xd& '1141 M5511 Woopmom MAIN CITY TAEASLWCA - WARREN 0 HALL /Lnr__ (*MIVED FROkA--- 0140 -0 A ADDAEM del 1�4�9 FOR A AMOUNT REa(VEO CASH V-ECK K 0% BAN f.rE.IVTD BY AMOUNT AWMW TOTAL a2- N ?).3) 4 0 2 3 0 CUSTMIER COPY p t 4i t � '/ r .. •r,�r ; tt .. Is... r `+ J AY 'r1. ,i �,1`i?G1Mi1'i4'iM�l��,�,+,����� i; c 3 , y ', r �, t •3LLV�ls�:��r :1� �,. it •i J� �'. t• tS t 1�RiF P 543 158 391 RECEIPT FOR CERTIFIES MAIL 10 " eSURANCE CGYiAAGE PPOVICED NOT FCR INTEPNATICo SAL MAIL (Seep Re►•eae) � rjFR t0 Clemons 8 Crandall, att s t s .0 ` llld�3 Broadway,P 59�� 6 O r P p , state and LIP Code c Santa Ana CA 92 707 4 o i nostne I 1 N a Cert+t�e4 Fee Sret,ai N:`.erl Fee Fia-!tr`Lte�] De:rr!ry Fee Return FReti.e`Pt shr.e+nF, to annm 3-4 Lite Veilver•.,� eV Ret•x'+ rece`rt s•'w•r•rq to oh.)m Cale. aryQ AddreS% ce Ge!l+.e7 TOTAL P: sta„e Ord Fees S u a 03."•'�73J 1 CLEMONS & CRANDALL ATTOR7+ E" AT L&W WILM.1. rtm*s 1417 !'70 IK OFIDAMAY AMA U(NIZ t:4 r. ter.:. R LZMWAtL F. ii F1 X am A"4757 S&Mx U CAUF[?liNL, KW '1 August 9, 1985 City Clerk City of Huntington Beach 2000 Main Huntington Bcach, California Re: Mission Cl.ay Products Corp. v. Dabco Construction Stop Notice Gentlemen: Enclosed is my check for $2.00. In accordance with California Civil. Code Section 3195, please furnish this office with the date of the Notice of Acceptance of the City of the sewer pipe lire on Goldenwest and Talbert Stree':s. Fours truly, CLEMONS & CRANDALL WILLIS J. CLEMONS WJC!gcr Enclosures .e—V�l f, of 10, law 7 - 47 f/x1u.�.i u M l Sabtnitted to: Submitted by: Prepared by: Subject: R C U ' FOR CITY CC)UNC Date '2� ACTION December 5, 198 Honorable Mayor and City Council Oar �rL Charles W. Thompson, City Administratorc.L4 ��,.t�S 'o r Paul E. Cook, DJ.rector of Public Works � WEST BOUNDARY TRUNK SEWER - CC-608 - Consistent with Council Policy? ( X) Yes [ ) New Policy of Statement of Issue, RecommeMation, Analysis, Funding Source, Alternative fions, Attrachnwnts: Stateme.it of Issue: Dabco Construction has completed the construction of the server main for the west boundary trunk sewer.. Recommendation: Accept the improvements for the west boundary trunk sewer as completed by Dabco Construction, cash contract 608 and authorize the City Clerk to file the Notice of Completion. Analysis: �)n September 4, 1984, the City Council awarded a contract to Dabco Construc- tion for the construction of the west boundary trunk sewer from Ellis Avenue west of Goldenwest: Street, to Goldenwest Street, north of Talbert Avenue. The construction of the sewer improvements are now complete, per the approved plans and specifications. The Department or Public Works recommends acceptance of the project and requests that the Notice of Completion be filed by the City Clerk. Construction of the project started on October. 9, 1984. A ninety-two (92) day extension of the contract time was granted by the Department cf Public Works for weather and change order work, establishing a contract completion date of May 9, 1985. Dabco completed the main line installation on April 24, 1985; however, the main line did not pass the final pressure testi nq . A number of joint failures were located and repaired by Dabc.�. Pinal acceptance of the line, restora- tion of the project site and the start of landscape maintenance period was not completed until October 11, 1985. The contract was completed one hundred fifty --four (154) days beyond the allowed contract time. I'rovi.sions in the contract call for a change to the contractor of $100 per day for liquidated damages for each day the contract runs beyond the contract completion date, an amount of 515,400.00. A difnute and litigation has arisen between Dabco Construction and their pipe supplier as Dabco claims the failures are due to the pipe provided by their stipplier. The reluctance of either to take responsibility, delayed repai.* of the lino and completion of the project. Dabco has requested relief from the city on the numL of repairs needed and their the related work to complete the project. Works has reviewed the request and found were not. city caused nor weather related time. for liquidated damages based effect on the scheduling for. The Department of Public that the cause of the delays and has not granted additional Request for Citv Council Action West Boundary Trunk Sewez - CC-608 December 5, 1985 Page 2 Change orders in the amount of $54,026.78, less related contract items deductions of $4,507.02, for a net increase of $33,519.76 were issued on this project. Change order work included pipe realignment in two areas to clear existing underground facilities, additional work due to unknown subsurface conditions and utility protection. The following is a summary of the contract costs: Contract Amount Contingencies Change Order Work Subtotal Liquidated Damages Total Council Approved Actual Expenditures $303,568.00 46,432.00 $350,O00-00 $350,000.00 Funding Source: City sewer funds account 606080. $239,060.00 54,026.78 $343,087.76 [ .1.5, 400. 001 $327,687.76 Attachments: Ci.rculat.ion Plan of Arterial Street and Highways Map. CWT:PEC:JM:lw mw . -,Iowpgrs pt hown WIT 71 •� - -I �- CIRCULATION PLAN OF ARTERIAL STREETS AND HIGHWAYS umm By ary coullix RESaXMI NO 4 %8 - CSC 12.19?6 LEGEND ;!BEET CAMITY FREEWAY MAJCR 454, X PROIARY 50DW SECOND,4RY 20M t4TE SCL 10 L P*i 3 NOCZt t USTOW WWI CW M" OCT VUV2Al*lLV tA.TA14Tt RIGWAT 90 SO Lv%o %0"?[ AKLS ove.ft ft3 % kv CITY OF HUNTINGTON BEACH WAKE CW,'TY CAL If CRIVA STYM1EY K ClLMIALL CLEMONS & CRANDALL ATTOI NIM AT LAW 14: Y SOUTH F.ItO.U)WAY nabox a n S&NTA AIwA. CAI.IPORNLA OV07 August 26, 1985 City Clerk City of Huntington Beach 2000 Main Huntington Beach, CA Re: Mission Clay Products Corp. v. Dabco ^onstruction Stop Notice Gentlemen: Enclosed is my check for $2.00. AMA CO{Id ?li 1iAX-MT In accordance with California Civil Code Section 3185, please furnish this office with the date of the Notice of Acceptance of the City of the sewer pipe line on Goldenwest and Ta::bert Streets. Yours truly, CLEMONS & CRANDALL WILLIS j. CLEMONS WJC/gcr Enclosures CXRTIPM RZOUESTRO, C EMONS i CRAMALL ATTOFMYS AT LAW S►lCIAL AccouMT IAIT S ltAOAf MIA`/ 7T1-ItA2-ATS7 3532 • 11rid/tZ't0 SAWA AM, CA 02M 819 �PAY 1� M T"t w+rrlrw n+w M•r�w oftora Of City Clerk CP-tington Ae.arch 1 a 2.00 jTWOand-nal-UMw�-----------i--Y-A-Iw--------------------wi-M==-- "VOLLARS BMKCfAMER1C1'1""" &WT4 of* M""J= wry is "" qr 4f1?R 00035320 4 1 2 200066 0: 009t19m0? 3?6,' F�- ,,, ITY OF 1�-�1U�"'1�Ti�' GTON EACH 20�00 MAIN STREET CALIFORNIA 926Q OFFICE OF THE CITY CLERK October 8, 1984 Dabco Construction 5692 Edinger Avenue Huntington Beach, CA 92649 RE: Construction of West Boundary Trunk Sewer through portions of Central Park, CC-608 Enclosed is your bid bond, a copy of the executed contract with the City of Huntington Beach and a Certificate of Compliance form. The Cortpliance Form must be signed at the completion of work and returned to this office. In addition, the following itens must also be on file, with this office, before the City can release any retention funds. 1. A warranty bond guaranteeing the fir:al amount of work and materials for one year. If your performance bond does not include specific; wording for a one year warranty, then a rider or separate bond must be submitted. 2. An affidavit stating that all workmen and persons employed, all firms supplying materials, and all subcontractors have been paid in full and that there are no outstanding claims &gainst this project. Should you have any questions or concerns regarding the enclosures or items that must be on file in this office prior to release of retention funds, please call Don Noble, Contract Administrator, 536-5441. Alicia M. Wentworth City Clerk AMWW: bt CC: Don Noble, Public Works Dept. Enclosures: Bid Bond Cash Contract Certificate of Compliance I ITolgNs %:714f1"2271 6 CITY OF HUNTIN ON BEACH 2= MAIN STREET CALIFORNIA 92648 OFFICE of THE CITY CLERK October 8, 1984 Steve Bubalo Construction Company P. 0. Box 1067 Reseda, CA 91364 We are returp ng your Bid Bond which was submitted with your proposal for the construction of the 'West Boundary Trunk Sewer through portions of the Central City Park, Project CC-608, in the City of Huntington Beach. The contract was awarded to Dabco Construct;or. of Huntington Brach. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk AMW:bt Enclosure 1T : 144304 'f) ITT OF HUN TINGTON BE H 2000 MAIN STnEET CALIFORNIA 92�18 OFFICE OF THE CITY CLERK October 8. 1984 Loant Construction P. 0. Box 6796 Buena Park, CA 90622 We are returning your Bid Bond which was submitted with your proposal for the construction of the West Boundary Trunk Sewer through portions of the Central City Park, Project CC-608, in the City of Huntington Beach. The contract was award-,d to Gabco Construction of Huntington 8�ch. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk Aft bt Enclosure Ir.w how:7943"Wl sm}� PF40PWMRL ric1�.�.�.�i�f.+�.�r/ii���frw� Firm NOMM 7b the 11m n rable Nkyiaar and City Cow il, city of Hmtiraton reach, Ca mmiia s with tine notice inviting mal.ed pcupo gals for the eons wrxrtitxt of the Wwt Bmrdary Trunk Sewer through portions of the Central City Park. CC-608 I heraby propose and agree to enter into a rxntract to perform the work herein described and to furnish the mtesrials th--arefore ac - arding to the plans, speci- ficatians and special parovi aionp. for tt* said work wul to the satisfaction of and under the v pervision of t:ie Director of Public Works of said City of Montirgton Beach, California. The urdersigned has not accepted any bid from any subcontractor or materia],mn th rougn any bid depository, tie by-1 mm, rules or regulations of which prohibit or prevent the contractor fran considering eery bid fran any xubavntracbar or nateiialmazi which is not processed through said bird depocitory, or which prevent any suba.)ntract r or n aterialman from bidding to any contractor who does not use the facilities of or accept bids from or through such bid depository. For the furnishing of all labor, rateri.als and eTiipnwt, and or all incidental nark neaessary to deliver all the iaprovffmts cmplete in place in strict axr f'ormity with the platw, specifications and special provisions, on file in the office of the Director of Public Works, City of Huntington Beach, California, I p nFoee and agree to take full payment therefore at the following unit prices; to wit. ITEK APPFKxamA= ITEM WM UNIT PRICE UNIT HC). CITY WRITTEN IN WOES PRICE IMAL Install taVoraxy 6' chin link fencing ixicludinrg gate at spa 1. 2800 L.F. T bd.. ,. � ]�sl�"_ w.� �..,� ► -Q Me IIdr AX er linear foot &vr Farove ex s trees at - 2& Q 2. 21 Fa. f y.,c�r AAA g.�. per earn dv. . Furnish and install 15" extra 3. 2147 L.F. stresngth vitrified clay sewer pipe- W tt A Case 1 bedding at k W I CV), IT "PROXIMATE WITH UNIT PRICE UNIT PRICE �106 QUANTITY WRITTEN WRITTEN IN WORDS PRICE Furnish and install 15" extra 4. 29' L.P. stremith vitrified clay tamer pipe - Case IA be&1ing at :1 wjcQ dP; ,,.._... �-�ftA&# . 2 U4 peer linear foo A?2: `A Mr -ash aw aRea- strength vitrified clay sewer pipe•- 5. 290 L.F. Case 2 bedding at T W ., 2A 2%col c r.yd. linmr f 7 �i � or Furnish and install 1 extra 6 strength vitrified clay ,r pipe - Case ld. betiding at U x 5.�s.4 i2A 2."r l o„Aml lzvt ! - " V linear f • Furnish anti install 15" extra 7. 1031 L.F. stxexqrh vitrified clay sewer pipe - Case 3 bedding at 2' V Furnish and install 1511 extra strength vitrified clay newer pipe- B. 65 L.F. Cage 3A bedding at ' Furnish and install trench ex-- cavatiun sheeting, shoring and 9. Dmp Swm bracing at EA ;.24.c 7 . - 4 x %I . 0 o a" m C7 Z k y..wu!.m.:.. lump SM Fia mish & install 4 " I.D. precast aHate s�anhnles, including n n-. *Ham* & 10. 72 V.F. covers s cmctete bases at x % per vertical footu• ""'.... FUMM & insI.D. pare as o�ol7te manholes, including man- 1l. 118 V.F. hole frames & covers & concrete glg�'�...ir A-Cd'� did Mi..Ids Al ram Vic - per veitical foot Furnish and install drop stI'uc.`ture (manhole No. 7 j at Z; A Z:.A4"iAaW l.2 • 1 Ea. 1 06, '1 Z. L. .r ..d s:.A it am d....... — mr each wcxU and'imconstruct existim s raaae per detail on suet 2 of plans 13. 1 Ea. at .0 k2 Ar a LP�f A7 UA �. ilk . 34 X P-2-1 IT NO. 14. 15. "PROXIMATE QUANTITY Lump Sum 7000 S.P. WITH UNIT PRICE: WRITTEN IN WORDS WRITTEN Install sod at mm Jeri d U?11T p�tICN PRICE 0 000• X �t�#' r�eri.rA& d m cJ _pes lump sm Ruuow and replace 6" thick POC ro&%my in kind at itgemav 4 y-A� Teti �.• J E," , C _ v.. ja d • • 4J&U4V5 AwJ F_,�=r P�wriamfoot P-- 2 - 2 k b rworwaad mad spW dot the oprrximu Moon** dwm is in f14 Mroproel IAWWo on No* fa do p Ir of boilitq so "W"rbm of bk mw *4 the wroewoWS " a be a N"m W5 do Moir of IN Md 4"xw o i* dw oo+*10 w work, whodw J* he w*on or No � draw Iowa we * at 1Mo r* pica w i* do prrrrwl m6wvlo. TIN *W MWEI o 6 the oorN M liar link ollrt W for do imahmt k...,._..12.,.��.r*...,�, If •+ortdW do , as woiaeilm i W* apm tl " aowat ooi famm On o eawy Ma6 vov" try (1116" of the of aw fit, ad to boa W" r� VQ tifi &" frown #4 6% Of ApprwW •J *M ft& met by 1f a" of lldotiwawos boob, Crlifaaie. ra wWiri�M twt *xowow arnfolry tM ** of dw work eroawrplrww, tw >� ad K, elfin W. alw dM Mr"OW W arw t forwr tlwrdor. lu rbaiaia* of a bw AMI be a**elwiw Vf *W toot dw WW lha iw+ 00*4W w d r orWed a to 1% oowiit om to be suvA �r�ri, a w two ci -r 18 4awitll, &d mp of work is be porf*rwwW, dM *mOlin of nmi * to be trroieM*i, OW a wa d» mq uiaoAft of dw p P I NI, llesKiplim"liNr► awf * or et. Nord Mao t word: Caok, y "CwtK'oi Mock," or "lWdor' %W," a Ow oor�my M in a wmim m owl to at� lost 1A pnm of do tool bw brio*, poyobllto tm City of HwrtlwMtow bm*. r" M"w*r I�ror1� Z% ww" awd Drafty a o PMPOW pwmy •w1 DPW00 k dambr fe fAw to OR City d llw�ti�1M � r oWtw dawn in am thk MropmW it kWood by dw City owd do mWo-elgai N M W ra a l"18 o 1811h c for wm wwk iww to ivrom food atw wthoiw beak iw o* tone wt fo* io *o wowed eel iaOp"U of tlro Chy' wide Way O*bduy to the City witlrio 1i 6m ofwrr dN Mel& ha raoiow Wt+.ao son of too Oworr of t%$ I I m Iet; odwnwiro OW Boon* WON be ntoraw 10 tm wwwoiai. ./ Ar li0000rd Is s ee ithwoo with ro ad MrooWFoq for to nMirtr*ti*w of oe►rrft ! Lkwa No. .Z z t:+ --., Isomm "WIN IMoiiowoi Ow tltbr, l* of t.? �. r.,...r 11.. Nid& *A sip ft mWO of oM Ad aw k Mir*, :f say: Add*Wm No. oft Aoo*iww foe P-.a WWI betm Av v"yl' i OP050- 0►- r r°AMSLQ INFORMATION REWIRED OF BIDDERS rrrl.Y� rrw�lY.r.YV M Tl r bWWR Is r+*si W in U40y do foNowkq iMr# mwift. AddilWW *mft my be i I Mal If rwarrwry. 1. fiirs� 1lsrtr�: �'.`? ..cam r �� r Q .{r -j �� � j/ / 7 ri .A Ad*ma i.� ii��wi.r �..wr..r...� J. 1rN.wir�rw�rw� �. Type d t M -- 1049ldurie pstTWIMN, or a poro%ion: S. CwpwNfon opsised under the laws of the State of s. CwArsaw't Lkwm Number: ,.%... _ of ee Qis�tifiootion of Comse w's Uamse 7. Upt the ►� ��/Md �wa otof all membeis of the firm or names and tit;m of all off'kws of tto wpontion: l% c►( 4 ly—�s ��i t '�J`. /�-arC�dytc �yor s c' �•. irL �.1�ir:�L. �X f� ��r./ai� rr+lfw��r SI ,� C E" �O r �r4. - L� cam!✓ct� k� .i rirc 't�-L �r �-�" & Numiwr of yam wcpa kmx at n oowrtctor in corwtruction work: % 't/Jj �.w11� 1 MY•r111YYY�wi arrwwrr S. List at ;$W six Projects ami0rted is of r*vW. date: (Contract amt.) (Ckm of wwk) (I is Qoeq*#%d) (Nom wW of Owrnr ) rev, �11�,�►f 1,..�/ ' /�-�t = /'}v _ �L G'�,� 7 0,ca'�Cov- •—� Ir�lr r +.+r r r W f.,,,�.rc,...,..._,�IT ,c � �.f �r�-- � •- •�� ] � � - �.�' rs�.,,. C'' �,ct.-ram I Ust tfw nrwm of ft pvwm who inspected fie sits of the propoW wont for your fifrn: -� Y..•.1. � Vi c� :.•; '`ci; Dos of kvpovd" ..,.."" N rwprw,-I by the City, ow bidder 0911 furnish t nowizsd fin&*W sutwnw. finwcW dell, ar olfMr WonMtion and rlfer-r , `may O w4wshwalws /0 pwn* an aWatol of his sw-trrt fkwrl W too-WWWa P-d DESIGNATION OF SUBCONTRACTORS In araMibam wi6 the 'Ubkttinq and Subcontrnrtirhp Fair pra6cm Art" brim Swim 41M4113 of 1k G*mnmW CW i of the We of California, and any anwrhdrrmau thereto, each bidder sWI wt forth below tk Mm •od kmegon of dw pkwe of hwimm of each subcorhusaar who will perform wwk w lobar or rrndarr eervfoe to 0o prim am trrotnr is er obwt the U Mtrwetiom of tfhe work w improwahent in an ootooRt is exam of aMrlhrM 1%) of on psi ml (11%) of OW prim nftUW'a tWI bii, and tiMl! fwfiter act forth the portion of the wwk w" wilt to dW hV oork s 6WW ftWW. MY an ai for for cah ptrrr:ao do" be listed. If the urtrM w %& to spo+4fy a wbccatromw for any portion of Ow work to be performed Wer the aorro►s>r.'t, he d oM be deminiel to tm equal ts perform "4 portion hirnaalf, aid Me *A nct be pumittm! to wboWm tMat portion of do work attoaMR rNaior for c*Whjom hweinttter tot forth. SWWotting of Mbaerrtr bal of any portion of the work to which Pq x6contmtor haw do*PaRW in the orillimm bid dog ealy bo pwmftted in am of public emergency or nocneity, and then only after a finding WNW to Wftirp as e pod k ismil of *A Looftfive Body of the owna. PORTION STATE L(CKWPC OF WORK CONTRACTOR'S NAW ANO AOORESS Wjvmr1 CLAif Iky wbWia&W of fhis propam, fQ c6mnew mow. t. Thet he is We to nod wAl rAdwm the Imkow of sit work voiah k cowered in tW **ve wboont w or !sating. 2. TM ft City will be fW111 he+l copier of ON 01711-69nt OM ehrterld ieto eid bonds farNi" by tab�wvv otwr for tm iw*at. r --6 �; dl"'is: w,.. , ......•Lr't l... r ... ._.._......�,.»....,N.,.... ..ai' i . I'�? �'�t, . t 1 �:. �f C/�� ,i � ... - - - ._.._.��. T"'-' ` i ,.: i � l ` :: '�, „ CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFORNIA 92648 Paul E. Cook Director West Boundary Trunk Sewer CC-608 Addendum Number 1 June 18, 1984 Notice to All Bidders: Public Work: Dapartment (714) 535-5431 The following revisions and additions shall -)e made to the bid documents: Between manhole nos. 8 and 9, within the equestrian center, approximately 280 linear feet of 6" thick concrete roadway has boon constructed. This work was undertaken after the plans for the subject sewer project were finalized. The portion of this roadway which interfers with the proposed sewer construction must be removed and replaced in kind. This work has been noted on Hid Item Number 15 of the Bid Proposal form. You are requested to acknowledge the receipt of this addendum below and return a copy of this addendum with your bid proposal. `,�ery truly yours;, .tS v Paul B. Cook Director of Public Works PBC:ML:1w This is to aoknow receipt and review of Addendum Number / dated f _� 19 "t is understood that the revision of new 6oc en s s gall be Inclu.ied in the bid documents. c',iro of Company Dated By rM REQUES1•` FOR CITY COUN IL C 'ION Dater Augmst 22, 1964 Submitted to: Honorable Mayor and City Council Submitted try: Charles W. ThoWson, City Administrator- C rD�'` L c. Prepwod by: Paul E. Cook, Director Public Works . O�,yn i�Y , _...t •" ►T SubjM: WEST BOUNDARY TRI,ITIIC SESqER; CC 608 ...r Statement of Issuer, Rw*mnmdation, Analysis, Funding Sour _ stive Acdons, Anwhmmts: O ST,17EMENT OF ISSUE: Pursuant to City Council approval of July 2, 1984, bids were received on August 16, 1984, for the construction of sewer improvemnts in the Central Park area, north of Ellis and West of Goldenwest. RIXM�UMATION: Approve the low bid submitted by DabCo Construction of Huntington Heath, and authorize the City Clerk to execute an appropriate contract in the arm mt of $303, 568.00. ANALYSIS: On July 2, 1984, the City Council. approved the plans and spr-cificati.ons struction of sec rrr imprcr-vnents in the Central Park area- north of Ellis Goldenwest, and authoriw-d the staff to advertise for construction bids. sun mrized below, were received and o}->--nod on August 1.6, 1984. Contractor Bid 7btal Dabc+o C =x.trrct..i.on $ 303, 568. 00 loant Construction $ 3740752.00 Steve Bubalo Construction Co. $ 3717, 900.00 ►lixi.bodo Construction $ 385, 726. 00 Robert G. Castongia, Inc. $ 397e 057. n0 Vicco Construction $ 409,282.00 Albert W. Davies, Trig. $ 412, 868.00 Ivan Bacham Constructicx.� Co. $ 499,186. 00 Doty Smther s FY.Tuipttent Cb. $ 519, 000.00 Risto Construction Cn. $ 549,245.00 for the con - and west of aids, as Staff has reviewed die bid proposals and r cores-nds the acceptance of the Dkab o Con- struction bid. FCVDING SUIRLX : Construction Costs: Contract Amount: $ 103,568.00 Construction Ccmtinqenciea: 46, 432.00 Stxurces of Reventn: $ 350, 000.00 Funds are available in the 1984-1985 fim-i1 bL6rt, as outlined below: Acccxmt 806080 No 4 I L��Lion Oast Doemdacy Trunk I mount Available $ 878,596.00 RCVWest Boundary Tnink Sewer; CC-608 -2- 71jgust22, 1984 WFWarIVE ACrICN: 1. Peject the low bid and select another bidder. 2. Reject all bids and forgo improvements. AMACHMEMS: None PE)C:DN:ik a Ittellyto CITY CLERK CrTy OF MUNTINGIOM 5941f.CALIF. Auuo% 16 10 01 AM 'P;l N� HV 0-101 9154 INTyll Nols)OUNAN NUI*�13 imaili 0 IN "IF Superior Court OF TIM. STATF:OFCALIFOIiNIA In and for the County of Orange a CITY OF HUNTINGTON BEACH CITY CLERK State fit Califutnia 1 Mount}• (If OrAner APRIL L. ELLIOTT That I nm and nt all tinwt hereto mentioned w'tt+ A rairen of the United State, over the Art- of twenty one veArs, enL that I mm nut A party ht. rvir intrrr•ted in the atht,%r entitlyd rnAtter, that I am the principal rlrrk of the printer fit the HUNTINSTGN BEACH IND. REV. a nrw'spalrrr of aenrrAl cirr ulatwn, puhit+h+'d in the r--tv of HUNTINGTON BEACH County of Orange and which nem,%rim w•r l+ puhrt+hf4l ftir the dl•eminacn n fit ItrAl new" And mtelltgrnt a of o ,;rttrral charac ter, and which nru%palter at all tune•+ herrtn rrientittnt-� had and still ha+ a Nina fide •ulr+ctipttun It+t (if pavrrtjZ i«ulrcrtltets, and Mhich oeis-paper h,+ f-en eItahlt+hrd• pnnteli And Puh liithed at reguler Internals in the 4AM County of OrnnKr for it I)etim! r>c"Amlc fine year: thmt the notice. of which the a•inried it, a pr►nird ntpv, ha+ 11—n puhh+lled In thr reFiular tend entity I* ve of said newspalxrr, and nett in Inv supPlrment therrrzf, cin the fnllimm—t date++, to wit. JULY 26 t AUG. 2+ 1984 I rerUfv t(Ir drrlarr) under penalty td twrlunv that the f0t"It ing I• trim and cnrlrrt GARDEN GROVE DAmyl At 3rd AUG. , 8t4 t'AlrfnrmA, thl• +lay ttf IJ ,.� Aori I L. El I iott :'+gnat rim. trrt BIDS CC-608 grow m '�t 60 wlpff r r t►rratrtMgw �trA. CV�1kaeN■ it .( :' �"I.to 1 ,1t'11f11�I1�M� "1!(: t i�•'.t ? ,tt` t,l;ti, :i'`%.: f pp�11II�( ,t. 1 sj!'watyr�iv�3Lu,.M�i�ii`S"�'17'lrtniA 'r.%.r',: , 1 POP* ltw �lptt� l+w � aw t . � • .,• '', l `: � 1 f (i � 1 iSt -{ , ` �++� d tirt+trtirarit�ntlrt t5elt�; .tatal�k'.}5,_.F: �f �` 11 �r�1M� w i;7#IIt111M tttl"D i r Mtud+M 1rlll tw�t tiuq► t+rrr+nw irn `• � � t t tttk rrrrk MIIMw' ' t. Ill natrrMwrA t., t o i 't1 ' , ki'.111iPfU'�'fall�'� 3' • '' t• •Ia: ,': l'f' t; ;: tP � 'a11w+M1Mnq tl �Yw7. Ws11� lAII I14Iq Ims "a IlrM i ' i 's Mitre 6i4m, II' 1W1I1116 Form No FKP 2l 0 NOTICE INVITING SEALED BIDS CC- 608 Notice is hereby given that the City Council of the city of Huntington Beach, California will receive sealed bids for the West Bch Trunk sewer in the City of Huntington Beach, California in accordance with the plans and, specifications and special provisions on file in the office of the Director of Public Works. Documents will be available on JU1Y 19 , 196, A charge of S 10.00 , not refundable, will be required for'eacFi sec. of aped cations and accompanying drawings. DIRECTOR OF PUBLIC WORKS ESTIMATE Work Item Quantity 1 Install txnporary fencing 2800 L.F. 2 Pwam existing trees 21 EA 3 Furnish and install 15" VCP case 1 bedding 2147 L.F. 4 Furnish and install 15" 41Cp case lA beading 291 L.F. 5 Flirni,sh aid install 15" 11CP ase 2 bedding '290 L.F. 6 Furnish and install 15" VU case 2A bedding 145 L.F. 7 Furnish and install 15" VC? case 3 beading 1031 L.F. 8 Furnish and install 15" VCP case 3A hredding 65 L.F. . 9 Sheeting, shoring and bracing L.S. 10 Furnish and install 48" I.D. M.H. 72 V.F. 11 Furnish and install 60" I.D. M.N. U8 V.F. 12 Furrash and install drop structure (KI 47) 1 EA 13 Modify and reconstruct existing mmihole base 1 EA 14 Install Sod L.S. 15 Amme and replace existing, 6" thick PM ron&my in kind 7000 S.F. In accordance with the provisions of Section 1771. of the Labor Code, the Mate of California+ Director of the Department o; Industrial Relations shall determine the ge:ieral prevailing rate of wages, applicable to the wor to be done; copies of the latest general wage rate determinations are on file at the office of the City Clerk and the office of the DirecU r of Public Works of the city of Hunti:if ton Beach, California. PlaAs and specifications, together with proposal form, may be obtained at the office of the Director of Public Works, City Hall, Huntington Beach, California. No bid will be received unless it is made. on a blank form furnished by the Director of Public Works. The special attention of prospective bidders is called to the proposal requirements, setfort:h in the specificatic for full dir;actions as to the bidding. 7.;ie foregoing quantities are approximate only, being given as a basis for the comparison of bids, and the vita of Huntington Beach dote not expresb or by implications agree that the actual, amount of work will corres- pond therewith but reserves the right to increase or decrease the amount of any class or portion of the work, as may be deemed necessary or expedient by the Director of Public Works. i A All bids will be compared estimate of the quantities of • on the basis of the Director of Public works work to be done. Substitution of securities for any moneys withheld by the City to the to insure performance shall be permitted in accordance with provisions of the California Government Code, Section 4S90. No bid will be accepted from a contractor who is not licensed in accord- ance. with the law, under the provisions of Chapter 791, Statutes of 1929, as amended or Chapter 17, Statutes of 1939, as amended, or to whom a proposa: form his not beck issued by the city of Huntington Beach. Each bid shall be made out on a form to be obtained at the office of thu Director of public Works, Development Wing, 2000 Main Street, Huntington leach, California; shall be sealed and filed with the City Clerk at the Civic Center, Second Floor Administration Building, 2000 Main Street, Huntington Beach, California, on or before 10:00 A.M. of A=st_ 1.l6 , 1984 , ar. shall be opened by a committee composed of the City Clerk, the City Attc rney and Director of Public Works or their authorized representative and the results of said bidding will be reported to tho City Council of s id :ity of Huntington Beach at their regular meeting to be held on 4Wm 4th of Sept. , 19 S4 , at the hour of 7 : 3 0 P.M. in the City Council Chambe in Civic Center of said city of Huntington Beach, and shall be acted upon by said City Council at the regular meeting of Sept. 4 1 r 19 84. The city of Huntington Beach, California reserves the right to reject any or all bids, and to accept the bid deemed for the best interest of the city of Huntington Beach, California. By order of the City Council of the city of Huntington Beach, Californi. this July 2 , 19840 ATTEST: Alicia Wentworth City. Clerk tr_2 A CITY OF HUNTINGTON BEACH Floe al 2000 MAIN STREET ' . P. 0. BOX 190CALIFORNIA � 92648 Paul E. (.uok Director -Ve-x� -- To City Clerk: Six"`--E a otice Inviting Sealed Bids Public Works Dvortm6it (714) 636-5431 d &V'u' blieation in Huntington Beach News on c,%//y , IW4 Aywy 4 ,r i /'Af.t} Remarks: Authorization from City Council to advertise Bid Opening Date• /�'►',�.'+ '/G, ,VA?0 Time /O.00 A!o . Engineer's Estimate AWO,000-00 APa1 y yruly ur , E. Cook Director of Public Works PEC:uFM:lw Submitted to: Submitted by: Prepared by: Subject: REQUEST FOR CITY COUNCIl. ACTtON Honorable Mayor and City Council Charles W. Thompson, City Administra Paul E. Cook, Director of Public Works West Boundary Trunk Sewer; CC-608 June I Be Statement of Issue, Recommendation,, Analysis, Funding Source, Alternative Actions, Attachments: STATEMENT OF ISSUE: Plana and specifications for the construction of the West Boundary Trunk Sewer are complete. RECOMMENDATION: I. Approve the plans and specifications for the construction of the West Boundary Trunk Sewer and authorize staff to solicit construction bids. 2. Approve Negative Declaration Number 83-23. ANALYSIS: On June 6, 1983; i-*ouncil approved the selection of Boyle Engineering to prepare plans and specifications for the construction of the West Boundary Trunk Sewer. Plans and specifications were completed several months ago; however the City had to acquire additional properties before construction could begin. On April 18, 1984, the Council approved Resolution Number 5370, thereby initiating condemnation proceedings to acquire the final five lots which couldn't be obtained by other means. The condemnation proceedings are complete and the City now has possession of the property essential for construction. Therefore, tho Director of Public Works recommends approval of the plane/specifications and requests authorization to solicit construction bids. On July 7, 1983, draft Negative Declaration 83-23 was pcsted for a 10 day publin review ending July 18, ;983. No comments, either written or .,erbal, were received; therefore, the Deve:upment Services Department recommends Council approval of Negative. Declaration 83-23. FUNDING SOURCE: Construction Costs imated Coat of Project: %pproxii-notely 15:+G for Construction Contingencies: Total Estimated Cost: Fundinq Funds budgeted in Account N8060PU (i.e. "West Boundary Trunk I") ALTERNATIVE '.!!ONS: Deny approval to solicit bids and forego improvements. ATTACHMENTS: l ocetT'on Map CWT:PEC;URN:Iw Mo Atli $314,592.00 45,400.00 360,000.00 w► . S � WEST BOUNDARY TRUNK SF. N'ER cc -sae P.Po iro r L o A rIoN s mA p 777.i, 7: - Wst !�Rmdr. y Tr,mk Sewer 110 U. .1.11161-10ER - '608 -AL MVW,ce Construction Incorip6r-ated ti Ivan Baclkmn Construction Cmpany 1% 1 C K Punr., rind -and Da -watering Corporation California Es LjLm-Lt�Limited ibbert G. CastonciLa- Eca= Cbnstruct cn __ _.. __ ..� _.'`._ _ _ _. Doty Brothers - - -____ ___ ___---__. _ ____. _.: ....�! .!' .. �4.� t,.� - - _____ _ _..�.. Albert W. Davies Incorporatiod Inland (bncrete Rnte*rises Incoporated Loant O:;;ist.-ur.- u-on 16C G. R. MaKervey Inocm.rated John T. Ma In rpo rate-fl. Mike Prllch and Son Prakacin Oonpmy Pi.ow Cbnstrvction Onpany suuy-mule-r W!ft4 Smc; lr==rated Wo 1395,o 0 Stop Notice 0 NOTICE: TO CITY O_F_HUNTINGTON BEACH (Name of Public Body or Lender) P Q BOX 190 HUNTINGTON BEACH, CA. 92648 (Address) (if Public Job — file with office of controller, auditor, or other public disbursing officer whose duty it is to make payments under provisions of the contract.) (1 f Private Job file with responsible offic-.r or person at office or branch of con WE ction lender administering the construction funds.) CE r V E D Prime Contractor. _ DABCO CONSTRUCTION W Sub Contractor(IfAny) JAN 171986 Owner or Public Body: CITY OF HUNTi INGTON BEACH Improvement known as Goldenwest & Talbert (Name and addreJs of project or work ofiinprowment) in the Cityol• Huntington Beach ,County of Orange State of California. LIVINGSTON—GRAHAM, A DIVISION OF ! ybInNs C'ORPORATIOU ,claimant a (claimant) CORPORATION (Corporation/ Partnerahfp/Sole Proprietashipl furnished certain tabor, service, equipment or materials used in the above describcd work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment or materials is __.___.__.QABrQ COI'1STRUCTIQN (Nance of Subrontractorl ConiractorlOkt ner• Builder) The kind of labor, service, equipment or materials furnished ov agreed to be furnished by claimant was MINERhL AGGREGATES (delydbe in derail) Total value of labor, scrvicc, equipment or materials agreed to be furnished .............S 4..SEfi . 5_6 __ Total value of labor, service, equipment or materials actually furnished is ...............S 4, 062.56 Credit for materials returned, if any..............................................S 0 Amour: paid on account, if any ...................... .......................... .S 3,, 199, , 46 Amount due after dcducting 01 just credits and offscts...............................S 863.10 YOU ARE HEREBY NOTIFIED tr; withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of S 863. 10as provided in Sections 3136 through 3214 of the Civil Code, and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond _.3, i n9 . attrched. (Bond required on private jobs— not on public jobs.) (itlij nut) Date JANUARY 14, 1996 LIVINGSTON-GRAHAM, . A DIVISION Name of Clnimsnt By H. A. MOPE•: _ASSISTANT TREASURER OW icsw cowcay) . VERIFICATION I, the undersiEned, :tale: I rim the ASSISTANT TREASURER � ( "age"I or. " !►IYaAw of 1. 1•0 PUrt#e► of ', "0%we of '. et0 the claimant namt;d in the ioregoing Stop Notice; I have read said claim of Stop Notice and know the contents thereof, and I certify that the torte is trio of My owr, knowledge. I certify (or declare) under penalty of perjury under the is*s of the State ofl:alifornia that the foregoing is true and correct. EtircuttJ on JANUAPY 1.4 14 6 at IRWINDALE �. a (Sieft" reafd; AuAwiseWAgM1 Irr�t fo�rtr+ttr.� al �r S. A. COOPER, ASST. TREASURER