Loading...
HomeMy WebLinkAboutEnvironmental Construction, Inc. - 2011-03-07RECEIVED BY: , / , J CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) A CITY OF HUNTINGTON BEACH Y INTERDEPARTMENTAL. COMMUNICATION TO: a:a=Fzeider jch, City Treasurer FEB 2 4 2032 FROM: DATE: SUBJECT: Bond Acceptance I have received the bonds for /1/.A?A )i3'I (Company Name) Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. pp Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. O o MSC No. Approved 13 `l Agenda Item No. /1 (Council Approval Date)_ City Clerk Vault No. #27 gAollowup/bondletter.doc [ 0 OLD HUNTINGTON BEACH TO: THOSE LISTED HEREON FROM: David Verone DATE: 2/15/2012 SUBJECT: Retention Release Payment Company Name: Environmental Construction Inc Address: 21550 Oxnard Street, Suite 1050 City, State and Zip Code: Woodland Hills, CA 91367 Phone Number: (714) 683-471 Business License Number:A273617 Local Address: NA Notice of Completion Date:11/21/11 Contract Purpose: Water Well *10 Rehabilitation The conformed copy of the Notice of Completion for the above contract has been filed. The thirty-five (35) day waiting period has elapsed or will elapse before payment is made. Processing of the retention payment is recommended so long as no stop notices or outstanding invoices are on file with the City. I certify that no stop notices are on file on the subject atfihis z-' Date Travis K. ipin�sPu6`licWo�rks I certify that there are no outstanding invoices on file. �CLI /X D to 6-ti ce_ I Vl I-"-, (c6 Zacks, Pep City Treasurer 1 certify that no stop notices are on file on the subject contract, and that a guaranty bond has been filed with this office. ate Joan lynn, C' y Jerk Retention_Release_Payment.doc 2/15/2012 11:25:00 AM Bond No. 8219-64-20 Premium listed on Performance Bond Executed in Two Originals MAINTENANCE BOND KNOW ALL MEN BY THESE PRESENTS; That: Environmental Construction, Inc. [contractors namel 21550 Oxnard Street Ste 1050 Woodland Hills Ca 91367 [contractors street address, cdy and state and zip =del as Principal (hereinafter called Contractor), and: Vigilant Insurance Com aanY [surety's name] 15 Mountain View Road, Warren, N7 07059 [surety's street address, c dyy and state and z1p codel a corporation organized and existing under the laws of the State of New York with its principal office in the City, of Warren as Surety (hereinafter called Surety), aro held firmly bound unto CITY OF HUNTINGTON BEACH as Obligee (hereinafter called Owner), in the amount of Forty Thousand Twenty Five and 00/100 Dollars ($ 40,025.00 1, for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents, WHEREAS, Contractor has by written agreement dated entered into a contract with Owner for the CC-1380; Water Well No 10 Rehabilitaion Project in accordance with drawings and specifications prepared by which contract is by reference made a part hereof (hereinafter referred to as the Contract); and WHEREAS, the Contract provides that the principal will guarantee, for a period of one year, the work performed as part of the Contract from and against all defects in materials and workmanship; and WHEREAS, the Contract also provides that the Contractor shall secure Contractor's obligations during the one- year period with a bond executed by a surety duly admitted in the state of California; and WHEREAS, the Contract has been completed, and the Owner, Contractor and Surety agree that the commencement date for this Guarantee and Bond shall be , 20_ NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Contractor shall, for a period of one year from and after the date of completion and acceptance of the Contract by Owner, repair and/or replace any and all defects arising in the Work, whether resulting from defective materials or defective workmanship, then this obligation shall be null and void; otherwise it will remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner Whenever Contractor shall be, ,and declared by Owner to be in default under the Contract, the Surety shall, within thirty (30) following Owners written notice of default, either: (a) remedy the default, or (b) shall promptly complete the Contract in accordance with its terms and conditions. Surety shall save the Owner harmless from any claims, judgments, liens or losses arising from the Surety's failure to either remedy the default or to complete the Contract in accordance with its terms and conditions in a tamely manner. Whenever the Principal shall be, and declared by the Owner to be in default under the Contract, which shall include without limitation, any breach or default of the Contract, then, after written notice from the Owner to the Surety, as provided for below, the Surety shall either. (a) remedy the default or breach by the Principal; or (b) shall promptly and faithfully take charge of the Work and complete the Work in accordance with the requirements of the Contract with a contractor other than the Principal, at its own expense, and make available 10-2567/50593 as work progresses`sufficient funds to pay the cost of completion less the unpaid balance of the Contract including other costs and damages for which the surety may be liable hereunder, provided, however, that the _ .-procedure-by. which. the.Surety_.und.ertakes-to discharge its obligations_ under this Bond _shall be subject to the advance written approval of the Owner. Whin thirty (30) days after Surety's receipt of a written notice from Owner of the failure of performance of the Contract by the Principal, it shall be the duty of the Surety to give to the Owner a notice, in writing, of the Surety's election to (a) remedy the default(s) of the Principal promptly, or (b) arrange for performance of the Contract promptly by a contractor other than the Principal, time being of essence to this Bond. In said Notice of Election, the Surety shall state the date of commencement of its cure or remedy of the Principal's default(s) or its performance of the Contract. The Suretys obligations for cure or remedy, include but are not limited to: correction of defective work and completion of the Contract, additional legal, design professional and delay costs arising from Surety's actions or failure to act; and liquidated damages (or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non- performance by the Principal)_ The Surety shall give prompt written notice to the Owner upon completion of the cure or remedy of the Principal's default(s) of its performance of the Contract. If the Surety does issue its Notice of Election and does not proceed to cure or remedy the Principal's default(s) of its performance of the Work within thirty (30) days after receipt of a written notice from Owner, Surety shall be deemed to be in default on this bond, and the Owner shall be entitled to enforce any remedy available to Owner. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the successors of Owner. Signed and sealed this 3rd day of February Principal Raised Corporate Seal (MUST BE AFFIXED) Principal Raised Corporate Seal [MUST BE AFFIXED] NOTES: 1. Adawwledgments must be completed and returned as part of the bond. 2. Raised Corporate Seals are mandatory. 3. Please attach Power of Attomey. t 0-2567/sos83 20 12 Environmental Construction, Inc. (Contractor Name) l ev: (Seal) (Title) Vigilant Insurance Company (Surety Name) �^ B (Seal) Shawn Blume, Attorney -in -Fact VED AS TO FORM f �qc(3RATH, CityAttomoy CALIFORNIA ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT State of California County of TEA Ti ;Pie s On before me, Beverly Parks, Notary Public5". , (Here insert name and title of the officer) personally appeared Farid Soroudi who proved to me on the basis -of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. a d my hand �nl official seal. Signature of Notary Public DESCRIPTION OF THE ATTACHED DOCUMENT (Tltte or description of attached document) (Title or description of attached document continued) Number of Pages - Document Date (Additional information) CAPACITY CLAIMED BY THE SIGNER Cl Individual (s) ❑ Corporate Officer, (Title) Pattner(s) ❑ Attorney -in -Fact ❑ Trtlstee(s) ❑ Other BEVERLY PARKS Commission # 1806841 Notary Public - California a Los Angeles County .. My Comm. Expires Jul 19, 2012 (Notary Seal) ADDITIONAL OPTIONAL I.NF®RMA'TION - INSTRUCTIONS FOR COMPLETING THIS FORM Any acknowledgment completed in California must contain verbiage ewcdy as appears above in the notary section or a separate acknowledgment form must be properly completed and attached to that document. The only exception is if a document is to be recorded outside of California. In such instances, any alternative acknowledgment verbiage as may be printed.on such a document so long as the verbiage does not require the notary to do something that is illegal fur a notary in California ri.e. certifying the authorized capactyo, of the signer). Please check- the document carefullyforpropernotarialwording and attach thisform if required. . State and County information. must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. . Date of notarization must be the date that the signers) po_ og4Ll ppparad which must also be the same date the acknowledgment is completed. . The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). . Print the name(s) of document signers) who personally appear at the time of notarization. . Indicate the correct singular or plural forms by crossidg off inconect fors (i.e. he/she/they; is /we ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection ofdocument recording. . The notary seal. impression must be clear and photographically reproducible. cession must not cover text or lines. If seal. impression smudges, re -seal if a Imp ...' sufficient area permits, otherwise complete a different acknowledgment form.. a Signature of the notary public must match the signature on file with the office of the county cleric. Additional information is not required" but could help to ensure this acknowledgment is not misused or attached to a different document. s Indicate title or type of attached document, number of pages and date. i_ Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). . Securely attach this document to the signed document 2oo8 Version CAPA vl2.10.07 800-873-9865 www.NotaryClasses.com STATE OF CALIFORNIA County of Orange On ZQ- before me, Irene Luong, Notary Public Date Here tnsert.Name and Title of the Officer personally appeared Shawn Blume Name(s) of Signer(s) IRENE LUONG Commission # 1883838 z z i'-es; \ Notary Public - California z Orange County My Comm. Expires Mar 22. 2014 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(e) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/staeA4ey executed the same in his/heFM-reir authorized capacity(ies), and that by his/k e4their signature(&) on the instrument the person(&), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under:PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph istrue and correct. Witness my han and o ici I seal. Signature Signaturv Nola Public OPTIONAL Thoughtheinformation below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this. form to another document. Description of. Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shawn Blume ❑ Individual ❑ Corporate Officer Title(s):_ ❑ Partner —❑ Limited ❑ General ® Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Top of thumb here Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: © 2007 NationalNotaryAssociation • 9350 De Soto Ave.. P.O. Box 2402 • Chatsworth. CA 91313-2402 • www.NationalNotary.orcg Item 415907 Reorder: Call Toll -Free 1-800-876-6827 Chubb POWER Federal Insurance Company Attn: Surety Department OF Vigilant Insurance Company 15 Mountain View Road Surety ATTORNEY Pacific Indemnity Company Warren, NJ 07059 Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana corporation, VIGILANT INSURANCE COMPANY, a New York corporation, and PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Shawn Blume, Eric Lowey, Stephanie Hoang and Mark Richardson of Costa Mesa, California------- --- each as their true and lawful Attorney- in- Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise, bonds and undertakings and other writings obligatory in the nature thereof (other than bail bonds) given or executed in the course of business, and any instruments amending or altering the same, and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof, said FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY have each executed and attested these presents and affixed their corporate seals on this 26th day of August, 2011. Kenneth en I, Assistant SecretaryDavid orris, Jr_, Vice Presid STATE OF NEW JERSEY ss. County of Somerset On this 26th day of August, 2010 before me, a Notary Public of New Jersey, personally came Kenneth C. Wendel, to me known to be Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY, the companies which executed the foregoing Power of Attorney, and the said Kenneth C. Wendel, being by me duty sworn, did depose and say that he is Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY and knows the corporate seals thereof, that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of the By- Laws of said Companies; and that he signed said Power of Attorney as Assistant Secretary of said Companies by like authority, and that he is acquainted with David B. Norris, Jr., and knows him to be Vice President of said Companies; and that the signature of David B. Norris, Jr., subscribed to said Power of Attorney is in the genuine handwriting of David B. Norris, Jr., and was thereto subscribed by authority of said By - Laws and in deponents presence. Notarial Seal KATHERINE J. ADELAAR Q�NE J �F NOTARY PUSUC OF NEW JFRSFI NOTAR Nc,. 2316685 ` PUBLIC Carnmiallion fires July 18, 2014 Notary Public JERg� CERTIFICATION Extract from the By- Laws of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY: 'All powers of attorney for and on behalf of the Company may and shall be executed in the name and on behalf of the Company, either by the Chairman or the President or a Vice President or an Assistant Vice President, jointly with the Secretary or an Assistant Secretary, under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the following officers: Chairman, President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Assistant Secretaries or Attorneys- in- Fad for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." I, Kenneth C. Wendel, Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY (the 'Companies*) do hereby certify that (i) the foregoing extract of the By- Laws of the Companies is true and correct, (1i) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are authorized by the U.S. Treasury Department; further, Federal and Vigilant are licensed in Puerto Rico and the U.S. Virgin Islands, and Federal is licensed in American Samoa, Guam, and each of the Provinces of Canada except Prince Edward Island; and (iii) the foregoing Pcwer of Attorney is true, correct and in full force and effect. Given under my hand and seals 0 said Companies at Warren, NJ this 3rd day of February 2012 ut, `�Su?�NcF t 9 • t v 1 —o-� i+l �i �VDIANP 'S�'t' SEW YOaw — M-1 -�� 9 Lwz Kenneth C. Wendel, Assistant Secretary IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM, VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER, PLEASE CONTACT US AT ADDRESS LISTED ABOVE, OR BY Telephone (908) 903- 3493 Fax (908) 903- 3656 e-mail: surety@chubb.com Form 15-10- M5B- U (Ed. 5- 03) CONSENT RECEIVED BY: (Name) (Date) wW66 CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office after signing/dating CITY OF HUNTINGTON REACH INTERDEPARTMENTAL COMMUNICATION TO: , City Treasurer r- a FROM: ��—� 0 DATE: ' SUBJECT: Bond Acceptance I have received the bonds for Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. aintenance Bond No. c Guarantee and Warranty Bond No. Re: Tract No. CC No. MSC No. Approved (Council Approval Date) (Company Name) C;;, 0 -4-, / 2 - Agenda Item No. City Clerk Vault No. #27 g:/followup/bondletter.doc Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Contract: (z -- /j-2o Project: &q,-bPVt- G4/-� &1 D Pi�l4''Q-l`�r2 7�iOX The undersigned contractor on the above-zeferenced project ("Project") hereby certifies that it has complied with Title VII of the Civil Rights Act, the Equal Opportunity Act of 1972 and Executive Order 11246, and has not discriminated against any employee or applicant for employment because of race, creed, color, sex, national origin, age or disability. The undersigned contractor also certifies that it has not maintained any segregated facilities at its establishments on the basis of race, creed, color, sex, national origin, age or disability (with the exception of access for the disabled). I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this day of 20 / at d� ,California. (Type Contractor Name) Nam e: [Type Name] Title: [Type Title] R A ORNEY P4RID ORovfl) 2459tt.1 Certification of Compliance with Prevailing Wage Laws To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Prevailing Wage Laws Contract: /� gig Project: The undersigned contractor on the above -referenced project ("Project") hereby certifies that all laborers, mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor performing work under the contract for the Project have been paid pursuant to the minimum wage and bona fide fringe benefit requirements specified for each particular classification of work, as set forth in the wage -rate determinations of the State of California, Department of Industrial Relations, and/or the United States Department of Labor. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this 22 day of ��, 20/% at Zo� in , California. IreDN�E.r/�,�°/. (Type Contractor Name) By: ' N [Type N afire] Tit e: [Type Title] A "0 �® �D 2g McGItA - � E ov� CrrY ATro�Y 1 4 247S42.I CONTRACTOR'S CERTIFICATE state and certify that: (Name of Declarant) 1 e4iv�R�is the general contractor to the City of Huntington Beach ("City") on Contract No, C C %. (the "Contract") for the construction of the public work of improvement entitled: (the "Project"). 2. All work to be performed pursuant to the Contract has been completed in accordance with the Contract Documents (as such term is defined in the Contract). 3. Except for the claims listed.below and the disputed claims listed in paragraph five (5), all persons supplying labor, services, materials and equipment to the Project, including all claims against the Contractor arising from the performance of the Contract, have been paid and satisfied (list unpaid debts and claims; if none, write "NONE"): 4. Attached hereto are the lien waivers required by the Contract Documents, which lien waivers have been executed by all persons who performed work on or supplied labor, services, materials, and/or equipment for use at the Project. S. Set forth below is a list of disputed claims or claims that are the subject of a Notice to Withhold filed pursuant to the Civil Code of the State of California (list all disputed claims; if none, write "NONE' ): I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed at on this. day of 201 .100 (Si afore of Declarant) APPROVED AS TO FORM By: 11110 3. Zo ote Name: [Type Name] Title: [Type Title] 144 R /�� J? Pn� 245914.E RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: -�Shari,=Freideneiioh, City Treasurer FROM: LZ V, u< DATE: SUBJECT: Bond Acceptance I have received the bonds for Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. 113 4?D MSC No. Approved (Council Approval Date) (Company Name) Agenda Item No City Clerk Vault No #27 g1followup/bondletter.doc PLEASE COMPLETE THIS INFORMATION This Document was electronically recorded by City of Huntington Beach RECORDING REQUESTED BY: WHEN RECORDED MAIL TO: CITY OF HUNTINGTON BEACH Attn: David Verone P.O. Box 190 — 2000 Main Street Huntington Beach, CA 92648 TITLE OF DOCUMENT Recorded in Official Records, Orange County Tom Daly, Clerk -Recorder 11111111111111111 111111111111111111111111111111111 NO FEE 2011000592008 11:10am 11/21/11 93 401 N12 1 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 THIS SPACE FOR RECORDER'S USE ONLY NOTICE OF COMPLETION NOTICE IS HEREBY GIVEN by the City of Huntington Beach, owner in fee, 2000 Main Street, Huntington Beach, CA 92648, that the contract heretofore awarded to Environmental Construction, Inc. who was the company thereon for doing the following work to -wit: WATER WELL #10 REHABILITATION, CONSTRUCTION CONTRACT-1380 That said work was completed November 14, 2011 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the Director of Public Works on November 14, 2011, per City Council Resolution No. 2003-70 adopted October 6, 2003. That upon said contract Vigilant Insurance Company was surety for the bond given by the said company as required by law. This document is solely for the official business of the City of Huntington Beach, as contemplated under Government Code Section 6103 and should be recorded free of charge. 4oflu Dated at Huntington Beach, California, this November 17, 2011. eectWorks or City Engineer y of Huntington Beach, California STATE OF CALIFORNIA) County of Orange ) ss: City of Huntington Beach ) I, the undersigned, say: I am an Agent of the City of Huntington Beach, owner in fee, in the foregoing NOTICE OF COMPLETION. I have read said NOTICE OF COMPLETION and know the contents thereof; the same is true of my knowledge. I declare under penalty of perjury that the foregoing is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder/of range C nty. Dated at Huntington Beach, California, this November 17, 2011. v ?7.tctor of Public Works or City Engineer This document is solely the official business of Ciy of Huntington Beach, California the City of Huntington Beach, as contemplated under Government code section. 6103 and should be recorded free of charge. THIS PAGE IS ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION (Additional recording fee applies) RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating t4 j (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION 7- TO-' Shari-Freidenrich, City Treasurer FROM: DATE: SUBJECT: Bond Acceptance I have received the bonds for Faithful Performance Bond No Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. /� &—o MSC No. Approved (Council Approval Date) Agenda Item No. City Clerk Vault No. #27 g1followup/bondletter.doc CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND Environmental Construction, Inc. FOR Water Well No.10 Rehabilitation Project TABLE OF CONTENTS Paie No. 1. STATE OF WORK; ACCEPTANCE OF RISK 1 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS 2 3. COMPENSATION 4 4. COMMENCEMENT OF PROJECT 4 5. TIME OF THE ESSENCE 4 6. CHANGES 5 7. NOTICE TO PROCEED 6 8. BONDS 6 9. WARRANTIES 7 10. INDEPENDENT CONTRACTOR 7 11. LIQUIDATED DAMAGES/DELAYS 7 12. DIFFERING SITE CONDITIONS 9 13. VARIATIONS IN ESTIMATED QUANTITIES 10 14. PROGRESS PAYMENTS 11 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES 11 16. AFFIDAVITS OF SATISFACTION OF CLAIMS 12 17. WAIVER OF CLAIMS 12 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS 12 19. WORKERS' COMPENSATION INSURANCE 13 20. INSURANCE 14 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED 14 22. NOTICE OF THIRD PARTY CLAIM 15 23. DEFAULT & TERMINATION 16 24. TERMINATION FOR CONVENIENCE 16 25. DISPOSITION OF PLANS, ESTIMATES AND OTHER 17 26. NON -ASSIGNABILITY 17 27. CITY EMPLOYEES AND OFFICIALS 17 28. STOP NOTICES 17 29. NOTICES 18 30. SECTION HEADINGS 18 31. IMMIGRATION 19 32. LEGAL SERVICES SUBCONTRACTING PROHIBITED 19 33. ATTORNEY'S FEES 19 34 INTERPRETATION OF THIS AGREEMENT 19 35. GOVERNING LAW 20 36. DUPLICATE ORIGINAL 21 37. CONSENT 21 38, SURVIVAL 21 39. MODIFICATION 21 40. SIGNATORIES 21 41. ENTIRETY 21 CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND Environmental Construction, Inc. FOR Water Well No.10 Rehabilitation Project THIS AGREEMENT ("Agreement") made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred .to as "CITY," and Environmental Construction, Inc. , a California Corporation , hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as Water Well No.10 Rehabilitation Pro!ect the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or g/agree/surfnet/citycunst l of 22 5110 be encountered in the prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; g/agree/surfnet/cityconst 2 of 22 5110 C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council, and any revisions, amendments or addenda thereto; D. The current edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 10801 National Boulevard, Los Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as g/agree/surfnet/cityconst 3 of 22 5110 "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum Three Hundred Eighty -Five Thousand not to exceed Nine Hundred Fourteen Dollars ($ 385, 914.00 J, as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within One Hundred ( 1oo ) consecutive working days from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. g/agree/surfnet/cityco"st 4 of 22 5110 CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6 CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the g/agree/surfnet/cityconst 5 of 22 5110 changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final contract price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within ten (10) days of filing of the Notice of Completion. g/agree/surfnedcityconst 6 of 22 5110 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services perfonned hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, g/agree/surfnet/cityconst % of 22 5/l0 the sum of Five Hundred Dollars ($ 500.00 ) per day for each and every working day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless DPW shall grant a further period of time), notify DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting g/agree/surfnet/cityconst 8 of 22 5110 from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors, will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DIFFERING SITE CONDITIONS A. Notice: CONTRACTOR shall promptly, and before such conditions are disturbed, notify DPW in writing of: (1) Subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents; or (2) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as g/agree/surfnet/cityconst 9 of 22 5/10 a result of such conditions, an equitable adjustment shall be made and the agreement modified in writing accordingly. B. Time Extension; No claim of CONTRACTOR under this Section shall be allowed unless CONTRACTOR has given the notice required hereunder provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. g/agree/surfnet/cityconst 10 of 22 5110 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined in its sole discretion by DPW, less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as a acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the g/agree/surfnet/cityconst I I of 22 5/10 substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items, if any, to be set forth in CONTRACTOR's affidavit covering disputed claims, or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all, claims, damages, losses, expenses, judgments, demands defense costs, and consequential damage or liability of any kind or nature, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone g/agree/surfnet/cityconst 12 of 22 5/10 directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 19. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to, City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. g/agree/surfnet/cityconst 13 of 22 5/ 10 20. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend, hold harmless and indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than One Million Dollars ($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees, agents, and volunteers as Additional Insureds, and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary. Under no circumstances shall said above -mentioned insurance contain a self - insured retention without the express written consent of CITY; however an insurance policy "deductible" of $5,000.00 is permitted. 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney g/agree/surfnet/cityconst 14 of 22 5/l0 evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. provide the name and policy number of each carrier and policy; 2. state that the policy is currently in force; and 3. promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 22. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten (10) days of receipt of such claim or claims. g/agree/surfnet/cityconst 15 of 22 5/ 10 23. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 24 and any damages shall be assessed as set forth in Section 24. 24. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause, and whether or not PROJECT is fully complete upon seven (7) calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience, the CONTRACTOR shall be entitled to receive payment for work executed, g/agree/surfneticityconst 16 of 22 5110 and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 25. DISPOSITION OF PLANS ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 26. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety. 27. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 28. STOP NOTICES; RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of g/agree/surfnet/cityconst 17 of 22 5/10 One Hundred Dollars ($100) for every Stop Notice filed in excess of two (2), regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 29. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices, certificates or other communications will be sent by notifying the other party via personal delivery, reputable overnight carrier or U. S. certified mail -return receipt requested: TO CITY: City of Huntington Beach ATTN: Joseph Dale 2000 Main Street Huntington Beach, CA 92648 30. SECTION HEADINGS TO CONTRACTOR: Environmental Construction, Inc. Attn: Mr.Farid Soroudi 21550 Oxnard St., Suit 1050 Woodland Hills, CA 91367 The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions, and do not interpret, g/agree/surfnet/cityconst 18 of 22 5110 define, limit or describe, or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 31. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 32. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 33, ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non -prevailing party. 34. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent g/agree/surfnet/cityconst 19 of 22 5/10 jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 35. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 36. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. g/agree/surfnet/cityconst 20 of 22 5110 37. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 38. SURVIVAL Terms and conditions of this Agreement, which by their sense and context survive the expiration or termination of this Agreement shall so survive. 39. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 40. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact, held by the signatory or is withdrawn. 41. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiation, and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements, promises, agreements or warranties, oral or otherwise, have been made by that party or anyone acting on that patty's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement, g/agree/surfnet/cityconst 21 of 22 5/10 promise, agreement, warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof. IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers on 20If. i CONTRACTOR Environmental icons t., Inc. ,i By: F ia goro i print name ITS: (circle one) Chairma Pre ' ent ice President AND By Fa Sor i print name ITS: (circle on Secr hief Financial Officer/Asst. Secretary - Treasurer CITY OF HUNTINGTON BEACH, a municipal do the State of California 0 ayor City Clerk /- INITIATED AND APPROVED: q�BV6=irector of Public Works g/agree/surfnet/cityconst 22 of 22 5/IU REVIEKEA)YND APPROVED: Administrator APPROVED AS TO FORM: City Attorney SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work, within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. r Accompanying this proposal of bid, fin I- in the amount of $ which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda 1Vo. Date Received Bidder's Signature I t -Zc.p- I C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 1 1 LS Mobilization p� $" -tarot $'`�6 2 1 Temporary sheeting, shoring, and bracing Q 3 1 LS Removal temporary sheeting, shoring, bracing $ Cf $ f 00. 4 1 LS Demolition of existing muffler room, blower shed and paving _ $ $SIT- 5 1 LS Grading and trenching Y� Q j �/&!J 6 1 LS Install gas engine, driveline and appurtenant equipment $ 7 1 LS Construct muffler room and install silencers There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room A' 8 1 LS mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and repainting �, + , f Y ��eP•-� $ % - 9 1 LS Install yard gas piping, yard electrical conduit, and electrical ductbank� gp $oi, Install engine room mechanical piping, relocated existing `2#j 10 1 LPG vaporizer, and install piping and valves associated with LPG vaporizers e.-4 LS $fit $ r 11 1 Install 16-inch flowmeter LS $ w $ 12 1 LS Paving $g 13 1 LS Install catalytic converter and engine exhaust piping There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler 14 1 room roof mounted blower LS $ $ Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation p 15 1 of engine control panels to be conducted by MurCal, Inc 16 1 Install fencing LS"- 17 1 System testing and commissioning =� LS $ 18 1 Clean-up & demobilization GJp �f �^xv LS $ $ 19 1 Provision and implementation of the SWPPP plan L LS $ $ There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 LS Provision of Traffic Control Plan 21 1 LS Provision of implementing traffic control gC -441 g/0l3 Total Amount Bid in Figures Basis of Award): $ S/ `71 Total Amount Bid in Words: Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher ]Lane, Huntington Beach, by the City park Lust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perfonm work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion of Work"` Name and Address of Subcontractor State License Number Class iA)�- i-4 �t of ���/ d rC'jr ®1 F�,440l✓ m,,'L -r l }-S R 5. 4-4 H t^' a 4c✓ % S Y y e--/n By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange Ahh�i� O1 J)-). f i , being first duly sworn, de oses nd says that he or &k-is of t e party making the foregoing bid that the bid is not made in the interest of, or on the e a f of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Name of Bidder SignaturepKidder atsSoLgn 4 Address of Bidder Subscribed and sworn to before me this day of 11a BEVERLY PARKS Commission # 1806841 Notary Public -California Los Angeles County My Comm. Expires Jul 19, 2012 NOTARY PUBLIC C-1 NOTARY SEAL State of California County of LOS ANGELES On _Z - 4 -- 11 before me, BEVERLY PARKS, NOTARY PUBLIC , Date Here Insert Name and Title of the Officer personally appeared FARID SOROUDI BEVERLY PARKS Commission # 180684, -- Notary Public -California Los Angeles County My Comm. Expires Jul 19, 91 who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and offic' al. Signature Q� 51_y� — Place Notary Seal Above Sig a of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by SIgner(s) Number of Pages: Signer's Name: Signer's Name:' ❑' Individual ❑ Individual ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Partner — ❑ Umited ❑ General _ O Attorney in Fact ' . ❑ Attorney in Fact ' ❑ Trustee Top of thurrib here ❑ Trustee Top of thumb here ❑ 'Guardian or Conservator ❑ Guardianor Conservator ❑ Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02007 National Notary Association • 9350 De Soto Ave., P.O. Box 2402 • Chatsworth, CA 91313-2402 • www.NafionalNotary.org ftem f15907 Reorder. Can Toll -Free 1-800 876.6827 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: C-t Contractor y Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes al o If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. Date: I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. C-1 Contractor y Title BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name Business Address City, Telephone Contractor's License `No. and Class Original Date Issued Expiration Date State Zip The work site was inspected b Q Q�aL of our office on , 201b. The following are persons, firms, and corporations having a principal interest in this proposal: S S C-1 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Company Name ignature of der -N,aftICL L Printed or Typed Signature Subscribed and sworn to before me this _+_ day of , 201 BEVERLY PARKS Commission # 1806841 z. Notary Public - Ga!ifornia Los Angeles County My Comm. Expires Jul 19, 2012 NOTARY PUBLIC NOTARY SEAL Listed below are the names, address and telephone numbers'for three public agencies for which the bidder has performed similar work within the past two years: 1. 3. Name and Telephone No. of Project Manager: (r�ZA0 Z O'ipiA5� Contract Amount Type of Work Date Completed to Name and Telephone No. of Project Manager: Z -Z3iO l r� zoo C) Contract Amount Type of Work Date Completed Name 4nd Address of Public Agency `' r Name and Telephone No. of Project Manager: 62() L-- zapnz Contract Amount Type of Work Date Completed 4) VI�JGQ�, 3�-c t1.()�2JYhQ.lil� . C-1 `mt�G �. State of California County of LOS ANGELES On Z^ 4 " 11 before me, BEVERLY PARKS,NOTARY PUBLIC , Date Here Insert Name and title of the Officer personally appeared FARID SOROUDName(a) of Signer(s) BEVERLY PARKS Commission # 1806841 Notary Public - California Los Angeles County My Comm. Expires Jul 19, 2012 Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNES nd and official s al. Signature �v Sipatum,61 otary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑' Individual ❑ Corporate Officer — Title(s): _ ❑ Partner — ❑ Limited ❑ General 0 Attorney in Fact ❑ Trustee ❑ 'Guardian or Conservator ❑ Other: Signer is Representing: RIGHTTHUMBPRINT. OF SIGNER' Signer's Name: ❑ Individual ❑ Corporate Officer—Title(s): _ ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: RIGHTTHUMBPRINT OF SIGNER''`Top of thumb here :�s�s�c.;�c�s�s�:.�s�s-.�s�c�.v�s�ss✓c��c�.✓c�cv.vc�a�c�c�c�c�c�c�c�.�cc-�c�-� ��s�c�c�s�c�c�c�c�s:�r�c�s:�ci�c TIDE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A310. Bond No. N/A KNOW ALL MEN BY THESE PRESENTS, that we Environmental Construction, Inc. 21550 Oxnard St., Ste. 1050 Woodland Hills, CA 91367 (Here insert full name ,and address or legal title of Contractor) as Principal, hereinafter called the Principal, and Vigilant Insurance Company a corporation duly organized under the laws of the State of NEW YORK as Surety, hereinafter called the Surety, are held and firmly bound unto City of Huntington Beach 2000 Main St. Huntington Beach, CA 92648 (Here insert full name and address or legal tide of Owner) as Obligee, hereinafter called the Obligee, in the sum of (10%) Ten percent of the attached bid amount ( 10% of bid amount ) for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for Water Well #10 Rehabilitation Project (Here insert full name, address and description of project) NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed on February 2, 2011 Environmental Con truction Inc. - (Principal (Sea rtness) e) (Witness) Irene ilant nsu nc Company (Seat) (Tit e) St pha a Pham Attorney -in -Fact AAA DOCUMENT A310 BID BOND ALA V FEBRUARY 1970 ED THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 N.Y. AVE., N.W. WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT STATE OF CALIFORNIA County of Orange 'On before me, Irene Luong, Notary Public DaA Here:. insert Name and Title of the Officer personally appeared Stephanie Pham Namefs}.of"Signer(s) who proved to: me on the; basis of satisfactory evidence to be the person(e) Whose.names) is/afe subscribed to the: within instrument and' acknowledged to me that he/she/thQy executed the sarne.,in his/herAheirauth- orized capacrty("#es):, And that by his/her/thiegf,signature(&) on the instrument the person(s), or the entity upon behalf of which the person#,$) IRENE LUONG acted, executed the instrument. Commission # 1883838 z -a: s Notary Public - California D I certify under PENALTY OF PERJURY under the laws of z Orange County the State of California that the foregoing paragraph is true My Comm. Expires Mar 22, 2014 and correct: Witness my hand and. fi " l seal. Signature Place Notary Seal Above Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to: persons relying on the document and could prevent fraudulent removal and reattachment of this formto another document. Description of Attached Document Title. or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Stephanie Pham ❑ Individual ❑ Corporate Officer— Title(s): ❑ Partner — ❑ Limited ❑ General ® Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Signer's Name: Individual ❑ Corporate Officer— Title(s)-. ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: P_ 2007 National Notary Association - 9350 Do Soto Ave.. P.O. Box 2402 -Chatsworth. CA 91313-2402 - www.NationatNotary.org Item 45907 Reorder Call Toll -Free 1-800-876-6827 Chubb POWER Federal Insurance Company Attn: Surety Department OF Vigilant Insurance Company 15Mountain View Road Surety ATTORNEY Pacific Indemnity Company Warren, NJ.07050 Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana corporation, VIGILANT INSURANCE COMPANY, a New York corporation, and PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Shawn Blume, Eric Lowey, Stephanie Pham and Mark Richardson of Costa Mesa, California each as their true and lawful Attorney- in- Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf assurely thereon or otherwise, bonds and undertakings and other writings obligatory in the nature thereof (other than bail bonds) given or executed in the course of business, and any Instruments amending or altering the same and consents to the modification or alteration of any instrument referred to in said bonds or obligations. in Witness Whereef,.said FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY have each executed, and attested these presents and affixed their' corporate seals on this 15th day of January, .2010. enneth G. ends ,isOfflintseoretary Da ' Norris, Jr_, Vfce Pre ' STATE OF NEW JERSEY ss. County of Somerset On this 15th . day of, January, 201.0 before me, a Notary Public of New Jersey, personally came Kenneth C. Wendei, to me known to be Assistant. Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY, the companies which executed the foregoing Power: of Attorney; and the said Kenneth C. Wendel, being by me duly swum, did depose and say that he is Assistant Secretary. of FEDERAL INSURANCE COMPANY,. VIGILANT INSURANCE COMPANY; and PACIFIC INDEMNITY COMPANY and knows the corporate seals thereof, that the seals affixed. to the foregoing Power,ot Attorney are such corporate seals and were thereto affixed by authority of the By- Laws of said Companies; and that he signed said Power of Attorney as Assistant Secretary of.said Companies by.like authority, and that he is.acquainted with David B. Norris, Jr., and knows him tots Vice President of said Companies; and.that the signature of David B. Norris, Jr., subscribed to said Power of Attorney is in the genuine handwriting of David B. Norris, Jr., and was thereto subscribed by authority of said By - Laws and in deponant's presence_ Notarial Seal tip M1HE41NE J. AUElAAR G� �,/ �lJ� I r,s NOTE iVil C OF NEW AMSEY '!•"` No 131.085 Notary Public q'cmflimiam bPtrtt►s July 16, 2014 :CERTIFICATION Extract from the By- Laws of FEDERAL INSURANCE COMPANY, VIGILANT, INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY: "AIL powers of attorney for and. on behalf of the Company.may and shall be executed in the name and on behalf of the Company; either by the Chairman or the President or a Vice President or an: Assistant Vice President, jointly with the Secretary or an Assistant Secretary, under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the following officers: Chairman, President, any Vice President, any Assistant Vice President, any. Secretary, any Assistant Secretary and the seat of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto' appointing Assistant Secretaries or Attorneys- in- Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in nature thereof, and any such pourer of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and;any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." 1, Kenneth C. Wendel, Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY (the "Companies' do hereby.ceR'rfy that (i) the foregoing extract of the By- Laws of the Companies is true and correct, (k) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are authorized by the U.S. Treasury Department; further, Federal and Vigilant are licensed in Puerto Rico and the U.S- Virgin islands, and Federal is licensed in American Samoa, Guam, and each of the Provinces of Canada except Prince Edward Island; and (;ii) the foregoing Power of Attorney is true, correct and in full force and effect. Given under my hsnd and seals of said Companies at Warren. NJ this February 2, 2011 3 Kenneth C. WeAssistant Secretary iN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM, VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER, PLEASE CONTACT US AT ADDRESS LISTED ABOVE, OR BY Telephone (908) 903- 3493 Fax (908) 903- 3656 e-mail: surety0chubb.corn Form 15-10- 0225B- U (Ed_ 5- 03) CONSENT 04/01/2011 07:05 FAX STRNTON ASSOC . hak 190b3194196 Mar Al 1U11 11; AC®RD CERTIFICATE OF LIABILITY INSURANCE TM 'ROMER 819. 880. 2155 FAX 805. 379.4198 THIS CE01FICATIE IS 1331JIWAS A MATTER [ LSU Insurance Service$ LiGenSe #0050569 ONLY AND CONFERS NO RIGHTS UPON THE ( Stanton Assoe9dCers HOLDER, THIS CERTIFICATE DOES NOTAMEI ALTER THE COVERAGE AFFORDED BY THE P 3625 Thousand Oaks Blvd f319 Westlake Village, CA 91362 WSUR IRS AFFORDING COVERAGE MRm f n-vironmanta Construction Inc. INSUMA., Great American Assurance t—M 21550 Oxnard street INEU;9 F(9; Imo- HaWl 9L9 company 01050 IN$URM 0: Scottsdale Ins o any Woodland Hills, CA 91367 INSUREI( D: Fail : 618 , 703.9072 INSURER E: THE POLICIES OF M60ANC,? LISTED DELOW HAvE BEEN ISSUED TO THE INSURED NAMLM ABOVE FOR THE w ANY REOUIRr-MENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT" WITH RESPECT TO WHI( MAY PERTAIN, THE INSURANCE AFFORPED BY THE POUGf:B PEWRI8150 HEREIN IS SUBJECT To ALL THE TER KX ICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. U TYPE OF INSURANCE GEHEW LJAUSaY X COMILICROIALGENERAL UA13 JTY CLAIMS MADE FX] Q-QV9 GUM AGGREGATE LWGTAPPUB$FIM'' /r f MXY M JECT M = AUTgAOOfl.IS UA91Ury ANT AUTO ALL. OWNED AUTOS OCHWULED AUTOS h1PZQ AUTOS NON-00MMA1T08 OAPME LLMIL T I MY A= QCW I MaRnI A LL ou" X OGCUR CLAW RM55 A I DEDVGTWLQ X RhlFJdfION a 10,00 MMMOGUIPIRMW AND RMPI DV 1 W UABB.[T7 ANY PRDPRI ffl, I0 CIfiVEr In NIQ jAffm� i � SI�ON9 balo.r PR Pollution B iability 0 j City rro EXGESS LrAam-yl 01n2/1011 i 03/31/2011 POUTCY : XLS0069268 I II City, its ottledrs, elected or tional insureds per form CG2037 act. " HOLDER raM UY r OU MZW 1ar� PR0'r4IONR ted offticIals, employees, agents, and volunteers are 112M as /04) and M2010 (10/93). Primary A Non-CUntributory Wordily 2 002/003 - upam , ND OR BELOW, NAIL 0 IUCY PERIOD INDICATED_ NOTWITHSTANDING H THIS GERTLI°ICATE MAY 9E IMED OR dB. EXCLusioNs AND CONDITIONS OF SUCH uNin6 EACA occURRBNC 2 s 1,000,000 Peo�renes 6 S010001 W -D EXP ( oroe • Excl ud PFI430KAL LADV iwLW $ 10000.00 GEWJ AL A13OREGATZ ' S 2 000. P(iPDLICT�J • ewloP AGG . 3 2 000 00 CA6eDINEG 6LNCU LIM" 5 (� acNnenq . BODILYINJURY a (PWDWWI BODLY INJURY s (Pat owdam) PROPERTYVAMMe s MAC ONLY-EAA00IDENT B EAACO S 6 AGO PACK 000URRENVE t s o 000 000 AQW MAlt s 5 000 0 Occurrence % 3.1000 0 Aggregate t 1,000. B EL 611Cii ACOIDEW i R.LDIMPJI$P-.EAW?WLO t E.LDU A6E-POLICYLIMrr 9 Limits S2,000,000 Ea Pollution Liab SZ,000,000 Aggregate sh0uto AM/ OF nee Alcove Dcar�eeD rCa-ldEs BEg4►lCFL>I�D aq-aRts TnE R+�►nvN DATE TNERWF, THH MU Na B191 pok WILL WOMW WIIL f30 DAW riRiI M City of Huntington Beach 2000 Main Street HUPtin9ton Beach, CA 92648 7LVE ?$ (2009101) ' i 81=9 ACORD CORPORA-nDWL Aq rlgG I'e>Ia$RQ. The ACORG nama 04 Toga are ra2istarod marks of AaORD w Clapy j, CERTIFICATE OF LIABILITY INSURANCE 03DATE(M111D�) PRODUCER Baumann Insurance Agency, Inc. License # OF13003 22019 Vanowen Street, Ste G Canoga Park CA 91303-2558 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIC # INSURED Environmental Construction, Inc 21550 Oxnard St Suite 1050 Woodland Hills, CA 91367 INSURERA: National Union Fire Insurance Co. 19445 A XV INSURER B: INSURER C: INSURER D: INSURER E: COVFRAnFR THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR DDT POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS GENERAL LIABILITY EACH OCCURRENCE $ RE ,DAMAGE TO RENTEDr. $ OMMERCIAL GENERAL LIABILITY Cnce CLAIMS MADE OCCUR MED EXP (Any oneperson) $ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ GENT AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP/OP AGG $ POLICY 77 PRO LOC AUTOMOBILE LIABILITY ANY AUTO COMBINED SINGLE LIMIT (Ea accident) $ BODILY INJURY (Per person) $ ALL OWNED AUTOS SCHEDULED AUTOS BODILY INJURY (Per accident) $ HIRED AUTOS NON -OWNED AUTOS PROPERTY DAMAGE (Per accident) $ APB AS' 0 _ GARAGE LIABILITY Jl' jvC Nl 'I' C'+1 ( AUTO ONLY - EA ACCIDENT $ ANY AUTO ( ( OTHER THAN EA ACC $ $ CCC AUTO ONLY: AGG EXCESS/UMBRELLA LIABILITY EACH OCCURRENCE $ OCCUR CLAIMS MADE AGGREGATE $ $ DEDUCTIBLE RETENTION $ WORKERS COMPENSATION AND OTH- X WC STATU- I FIR E.L. EACH ACCIDENT $ 1,000,000 A EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? WC20634912 03/01/2011 03/01/2012 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE - POLICY LIMIT $ 1,000,000 If yes, describe under SPECIAL PROVISIONS below OTHER DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS Waiver of Subrogation to: City of Huntington Beach its officers, elected or appointed officials, employees, agents and volunteers per waiver of subrogation. t RECEIVED MAR 14 2011 10 Day Notice of Cancellation for Non -Payment of Premium UtKIIVIGAIt HVLUtK LAN L,CLLAIIVIV City of Huntington Beach 2000 Main St. Huntington Beach, CA 92648 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL KNEM X0060CA MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BU BDGXXX Ilaea= AGVKU ZO (ZUUI/U5) raoo Insured: Environmental Construction, Inc. Policy Number: WC20634912 Insurance Company: National Union Fire Insurance Company IT IS AGREED THAT WE WAIVE ANY RIGHT OF RECOVERY WE MAY HAVE AGAINST THE PERSON OR ORGANIZATION SHOWN IN THE SCHEDULE BECAUSE OF PAYMENT WE MAKE FOR INJURY OR DAMAGE ARISING OUT OF "YOUR WORK" DONE UNDER A CONTRACT WITH THAT PERSON OR ORGANIZATION. At 0 lop , 1I Project , CERTIFICATE HOLDER'S NAME City of Huntington Beach 2000 Main Street Huntington Beach, CA 92648 Waiver of Subrogation; to the City of Huntington Beach, its officers, employees, agents, representatives, its elective and appointive boards and volunteers for work performed under this contract and work done on behalf of the City of Huntington Beach, subject to the terms of the Worker's Compensation Laws of the State of California. 30 Day Notice Cancellation to the City of Huntington Beach, except for non- payment of premium which is 10 day notice of cancellation. Date: 03/10/2011 U3/11/2011 11:b7 323-yb4-12(ib Jonatnan Glabman Image 1/1 DATE (MMIDDIYYYY) ACC-RD- CERTIFICATE JF LIABILITY INSURANCE; 3/11/2011 RODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE GLABMAN INSURANCE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 5455 Wilshire Blvd Ste 1000 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Los Angeles, CA 90036 tonm A CZ')_�49')4 Environmental Construction, Inc. 21550 Oxnard St., Ste 1050 Woodland Hills, CA 91367 41 Q—A A 0_007n :OVERAGES INSURERS AFFORDING COVERAGE NAIC # INSURER A: Mid Century Insurance Company 216E INSURER B: INSURER C: INSURER D: INSURER E: THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALLTHE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BYPAID CLAIMS. rR rR kOD'L NSRD TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE DATE AMIDDfYY POLICY EXPIRATION DATE (PAMIDDIYY) - LIMITS GENERAL LIABILITY EACH OCCURRENCE $ PREMISES (Ea uwuwlce) $ COMMERCIAL GENERAL LIABILITY CLAIMS MADE CI OCCUR MED EXP (Any tme person) $ PERSONAL & ADV INJURY $ GENERAL AGGREGATE $ GEN'L AGGREGATE LIMIT APPLIESPER: PRODUCTS - COMPIOP AGG $ PR6 POLICY JECT LOG AUTOMOBILE LIABILITY ANYAUTO COMBINED SINGLE LIMIT (Ea awident) $ 2,000,001 BODILY INJURY (Per person) $ ALLOWNED AUTOS X SCHEDULED AUTOS X Y - HIRED AUTOS NON -OWNED AUTOS 600996856 01/22/11 01/22/12 BODILY INJURY (Per accident) $ PROPERTY DAMAGE (Per accident) $ X $0 Deductable GARAGE LIABILITY AUTO ONLY- EA ACCIDENT $ OTHER THAN E.AACC $ ANYAUTO $ AUTO ONLY: AGG EXCESS/UMBRELLA LIABILITY - OCCUR 1A CLAIMS MADE AP y �f',D AS 1 0 ��lYl RM EACH OCCURRENCE $ AGGREGATE $ DEDUCTIBLE RETENTION $ �E I 1 M GRAT \ City �� I $ $ $ WORKERS COMPENSATION AND TORY LIPAtiS I Ili -ER EMPLOYERS' LIABILITY - E.L. EACH ACCIDENT $ .4NY PROPRIETOR/P.ARTNERIEXECUTNE E.L. DISEASE-E.A EMPLOYEE $ OFFICERIPAEPABER EXCLUDED? Ifyes%desuibemda E.L. DISEASE- POLICY LIMIT $ SPECIAL PROVISIONS Wow OTHER t6UhtVk1UN OF UPtKAI1UNb /LLYL;A11UNS 1VtH1CLt5 ItAULU51UN5 AUUEU BYtNUORSEPAtN1 ISHLUALPROV161ONS Additional Insured: City of Huntington Beach, its officers, elected or appointed officials, employees, agents and volunteers. :ERTIFICATE HOLDER CANCELLATION City of Huntington Beach 200 Main St. Huntington Beach, CA 92648 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL MaXXXX0 MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE, INSURER, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE % A _ 4 1CORD 25 (2001108) @ ACORD CORPORATION 1988 04/01/2011 07:05 FAX 12 003/003 oinnivn noow, rbx INDS( IJU Mar j1 ZU11 11:4Uam FUU2/UU'L Policy Number: GLP 1679612 COMIMIERCUL GENERAL LIABILITY - CO 2010 (10-93) THIS ENDORSEMENT CHANGES TfM POLICY, PLEASE READ r AREF'ULLY. ,ADDITIONA,L INSURED - OWNERS, LESSEES OR CONTRACTORS (FORM R) This, endouewent modifies imurance provided uader the following: COMMERCIAL GENERAL LWBILiTY COVERAGB PAKT SCHEDULE Name of Persona or Organization: City of Huntington Beach, the city, Its officers, elected or appointed officials, employees, agents, and volunteers (If no wfty appem above, information mquired to compim this endorsement will be shown in th@ Declandjow as applicable to this endormmMt.) WHO IS AN INSURED (Section II) is amended to include as an lasured the person or orpulmdon shown in the schedule, but amly with inspect to liability arisiog out of your ongoing operations performed for that insured. It is flu her mod dW such insurance w Is a&rded by tlb PoUcy for the benefit of the addidond immured shown above shall bo primary insuance, subject to all policy provisions, including the deductible clause, but only with respect tQ the 11411W arising otn of "yo x woW flex the additional iusut+ad by'or for you within the above described job, Any Insurance poiauitaihed by the additional insured as rospecb to the liability arLing out of "your work" shall bo non-contnbuting. 11 A, o ' Sig�xature 31 I I D Foam #: CG 2010 (10-93) CMTigh% Insurance Services Qffice, Inc., 1992 03/30/2011 08:10 FAX Ia003/004 insured: Environmental Construction Inc. P01icy: GLP 1679612 CG 20 37 (Ed. 07 041 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE HEAD IT CAREFULLY, ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL ,GENERAL LIAEILITY COVERAGE PART Name of Addition®l Insured Person(s) or Or!3anization(s): Any person or organization that ..you" and such person or organiza- L(on have agreed in writing in a conlratt or agreement that Suoh person or organization be added as an additional insured on "your" policy, but only for "your work" performed during this policy period. Additional Premium: Included Schedule Location and Description of Completed Operations: Only per Certificatels) or Insurance accepted by and on file with "us", "Your work" performed during this policy period. Information required to complete this Schedule, if not shown above, will be shown in the Declarations, SECTION 11 - WHO IS AN INSURED is amended to include as an AddidQnal Insured the person(s) or organizations) shown in the Schadula, but only with respect to liability for "bodily injury" or "property damage" caused. in whole or in part, by "your work" at the location designated and described in me Schedule of this endorsement performed for that Additional Insured and included in the "products -completed operations hazard." The city, its officers, elected or appointed officials, employees agents, and volunteers Copyright, ISO Properties, Inc.. 2004 C(3 2c 37 (Ed. 07iO4) PRO Ipoge 1 of 1) 03/30/2011 08:11 FAX IM 004/004 GAC 3E49CG (Ed. 1 i 06) THIS ENDORSEMENT CHANGES THE POLICY. PLLASE READ IT CAREFULLY. PRIMARY NUN -CONTRIBUTORY INSURANCE ENDORSEMENT This endorsement modifies insurance provided under 1he following COMMERCIAL GENERAL LIABILITY COVERAGE FORM OWNERS ANO CONTRACTORS PROTECTIVE LIABILITY COVERAGE FORM This insurance is primary to any other insurance held by third parties with respect to work performed by you under written contractual agreements wiih such third parties and any other insurance which may be available to such third parties shall be non-contributory. GAC 3349CG (Ed 11;06) XS CONTRACTOR'S SWORN STATEMENT AND WARRANTY REGARDING CONTINUING INSURANCE OBLIGATIONS FROM:y 11� � 1.6M C P OXCT:�2ELA D _� (Contractor Name) (street Addres ) (City, State and Zip) TO: CITY OF HUNTINGTON BEACH 47 X . t-OR Attached hereto is a true and correct copy of the current Certificate of Insurance and Additional Insured Endorsement CG 2010 1185, which Certificate complies with the insurance requirements of the Contract by and between the City of Huntington Beach ("City) and the above -named Contractor ("Contractor) for the above -described project ( Project"). I declare under penalty of perjury under the laws of the SZ of California that the above statement is true and correct. Signed on _ _.._. �'5 — � � �, 20! I , at JTZT (Date) (City, State) Who is Making Declaration) Lfti>/=,k Mm Contractor hereby warrants and agrees to maintain Products and Completed Operations Insurance in compliance with the Insurance requirements of the Contract for the Project. Said insurance shall be maintained through and until the expiration of all Warranties provided by Contractor. Said insurance shall contain Additional Insured Endorsement CG 2010 1185, naming City as an additional insured. Contractor shall supply to City, on at least an annual basis, a Certificate of Insurance and the aforementioned Endorsement evidencing continuedcoveragewhich meets the Contra requirements. Signed on _! -- l l , 20! t , aty ut& t� t�- (Date) (City, State) CONTRACTOR: Name: LAC +t ,> 1Iq" znazi.z RECEIVED BY: (Name). (Date) CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office after signing/dating CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: Shari Froielenri h, City Treasurer FROM: DATE: SUBJECT: Bond Acceptance i have received the bonds for Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. to MSC No. Approved J (Council Approval Date) Agenda Item No City Clerk Vault No. #27 g1followup/bondletter.doc Bond No. 8219-64-20 Premium listed on Performance Bond PAYMENT BOND , Executed in Two Originals KNOW ALL PERSONS BY THESE PRESENTS that: V41HEREAS, the City of Huntington Beach (hereinafter relented to as "City*) has awarded to Environmental Construction Inc. 21550 Oxnard Street, Ste 1050, Woodland Hills, CA 91367 (none anG address of Canlractor) (hereinafter referred to as "Pnindpal7, a contract ("Contracn for the work dascrlbed as fbbovrs: Water Well No. 10 Rehabilitation Project (prow) WHEREAS, Principal is required under the term of the Contract and the California Civil Code to secure the payment of Balms of laborers, mechanics, materiabnen, and other persons as provided by law. NOW THEREFORE, we, the undersigned Principal. and Vigilant Insurance Company 15 Mountain View Road, Warren, NJ 07059 (noM8 and address of Suzy) (a duly admitted surety Insurer under the laws of the State of Cafrfomia and hemir+afW r+ef rred to as *Su"'), as Surety, are held and firmly bound unto City in the penal sum of Three Hundred Eighty Five Thousand Nine Hundred Fourteen & 00/100 dollars, ($ 1 385}914.00 ), this amount being not less than one hundred percent (100%) of the total pri a set forth in the Contract, In lawful money of the United Strain. of Arnerica. for the payment of which sum, well and truly to be made, we bind otaselves, and each of our heirs, executors, administrators, successors, and assigns, Jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH Tt-iA7, it the Principal, his, her, or its heirs, executors, administrators, sucrosscre or assigns, or subcontractors shall fail to pay any of the persons reamed in Section 3181 of the onhle Chid Code (AClabnante) for all labor, materials or services used or reasonably required flan use in performance of the work described In the Conbwt, or any amounts due under the Unemployment Insurance. Code with respect to work or labor performed by arty such Claimant, -or prevailing wages due and penalties incurred pursuant to Sections 1774, 1775, 1 S13 or 1815 of the. Labor Code, or any amounts required to be deducted. withheld and paid over to the Employment Development Department from the wages of empbyess of the Principal and Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to the worts or hd w performed under the Contract, Surety will pay for the same. in an amount not exceeding the penal sum specifod in this bond; otherwise, this obligation shalt be null and void. This bond shall inure to the benefit of arry of the persons named in Section 3181 of the California Civil Code so as to give a right of action to such persons or their assigns. In case any action is brought upon this bond. Surest hirther agrees to pay all court costa and a reasonable attorney°s fee In an amount fried by the court Surety stipulates and agrees, for value received, that no change, extension of time, alteration, addition or modification to the terms of the Contract, or any contract document or any wo* to be performed thereunder, whether made after notice or not, shall in any way affect. impair or release the obligations of Surety under this bond. Surety hereby waives note of any such change, mu4.3 PAYMENT BOND Page I of 2 Bond No_ 8219-64-20 tbalm of time, alteration. a"on. or modWeAm to the terms or the Contacct, the cofted decutnents or the work aweunder. Surety also wakes the provisions of Caftrnfa Civil Code§� 2845 and 2W. IN WITNESS IiV HEROF, each party represents and warrants that this Insturnent has been duly executed by Principal and Surely, , on the daft set forth below, that the name of each corporate party being affixed hereto is such party's proFw lager name and that the individuals Ming this ins6ru vmt have been duly authorized pursuant to the authority of its governing . body. Surety. by execWon of this bond. walves any defense which Surety has or may have by mason of any falfure of the Principal to execute or. property execute this bond. Dated March 11, 2011 ATTEST Environmental Construction, Inc. (Com Arete Seat) (Principal i &OW) A Vi it I Ace Company (Corporate Seal] urea ) (Attach Ati rney4n-Fact Certlt ) By. Nam ep ame am, orney-m- act (Signature of Atttxney in -Fact for Surety) (.Li j2 612-4000 (Area Code 5 Telephone Numb of Surety) APPROVER AS TO FORM: CITY OF HUNTINGTON BEACH 4 niter ANC th sIA S18L ify Attorney Nab 7M bored mist be executed in dW*eta and as ed, am atqattees most be ncearkwd, and ego of ft WOW* a►&Vaoraon a as afoam)%IR-tad awd be attach aMal PAYMENT BOND Page 2 of 2 1il ;—.alc- -.-!— C- I s.��v v!�fiAsaC�$f.R�.^;5..•, �S<' State of California County of LOS ANGELES On �,5 — 11 - ZU ( ( before me, BEVERLY PARKS. NOTARY PUBLIC , Date Here Insert Name and Title of the Officer personally appeared FARID SOROUDName(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/sheAhey executed the same in his/her/their authorized BEVERLY PARKS capacity(ies), and that by his/her/their signature(s) on the Commission # 1806841 instrument the person(s), or the entity upon behalf of Notary Public - California Z which the person(s) acted, executed the instrument. Los Angeles County My Comm.. Expires Jul tg, 2012 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNES hand and official fea Signature . Place Notary Seal Above Signatur Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Or Individual Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General _ ❑ Partner — ❑ Umited ❑ General _ ❑ Attorney in Fact ❑ Attorney in Fact ❑ Trustee Top of thumb here ❑ Trustee Top of thumb here ❑ Guardian or Conservator ❑ Guardian or Conservator ❑ Other. ❑ Other: Signer Is Representing: Signer Is Representing: 02007 National Notary Association- 9350 De Soto Ave.. P.O.6m 2402 •ChatsworA CA 91313-2402 • www.NagonaMotaryorg item N5907 Reorder: Cell Toll -Free 1-800876-W27 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT 'STATE OF CALIFORNIA County of Orange On 1 ZI I before me, Irene Luong, Notary Public , Dell Here. Insert Name and Title .of the Officer personally appeared Stephanie Pham Name,(s)-of Signer(s) 111lilENE LUONG Commission # 1883838 Notary Public - z z - � y California Orange County D My Comm. Expires Mar 22, 2014 Place Notary Seal Above who proved to me :on the basis of satisfactory evidence to be the person(4) whose name(s) is/are subscribed to the within instrumentanI :a . powledg.ed to me that he/she/.tfaay executed the -same 'in his/her/their:authorized capacity(iss), and that by Ibis/her/their signature.(&) on the :instrument the person(&), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand d fficial . eai:. Signature Signature cJ Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Stephanie Pham ❑ Individual ❑ Corporate Officer Title(s): ❑ Partner ❑ Limited ❑ General ® Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: Signer's Name: ❑ Individual ❑ Corporate Officer — Title(s)- ❑ Partner ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: (0 2007 National Notary Association • 9350 De Soto Ave.. P.O. Box 2402 • Chatsworth. CA 91313-2402 • www-NM,onalNotary.org Item a5907 Reorder: Call Tou-Free 1-800-876-6827 PREMIUMS SUWECT I TO AD USTMENT BASED ON FINAL CONTRACT PRICE Bond No. 8219-64-20 Premium: $5,557.00 PERFORMNCE BOND Executed in Two Originals KNOW ALL PERSONS BY THESE PRESENTS. VV REREAS. City of Huntington Beach (Fereinafter referred to as "City') has, by wren agreemeritd . 20,_,_, entered Into a contract with Environmental Construction Inc. 21550 Oxnard Street, Ste 1050, Woodland Hills, CA 91367 (name and addrem of Canhat" (Imelrratter referred b as "Principal', for performance of the work described as follows: Water Well No. 10 Rehabilitation Project (Proloat Ttge) WHEREAS, said contract, and all docurnma referenced therein (hereinafter colleaWvely "Contract), are inoorporeted herein by this refarenoe made a part hereof as though set forth herein in fuM_ WHEREAS, said Principal Is required under the terms of the Contrad to furnish a bond guaranteeing the prompt full and faithftil performance of said Contract NOW THEREFORE, we, the understgned, as Principar, and Vigilant Insurance Company 15 Mountain View Road, Warren, NJ 07059 (narnn and address of surety) (a duly admitted surety insurer under the laws of the State of California and herWnefier referred to as "Surety"), as Surety, am held and IMy bound unto City In the penal sum of Three Hundred Eighty Five Thousand Nine Hundred Fourteen & 00/100 DOWWWs � ), this amount being not lass than one hundred percent of the price set forth In the Contract, In bwfU money of the United States, for the payment of which surn, well and truly to be made, we bind oumehres, our heirs, executors, administrators and successom, jointly and severally. 4rn* by these prmnts. THE COtVDMON O1= THIS OBUGATION IS SUCH THAT if the Principal shag promptly, fully and faift*lly pertorm each and all of the covenants, obligations and things to W done and performed by the Princii* in shirt accordance wfth the terms of the Contract as said eontrad may be altered. amended or modified from time to time. and N the Principal shag indemnify and save harmless City and all of City's officers, agents and employees (hereinafter collectively referred to as "Obligees') from any and all losses,_ PabAy and damages, Balms. judgments. stop notices, fees and costs of every description, whether imposed by lawor in equity, which may be incurred by the Obligees by reason of the failure or default an the part of the Prfncipal in the perkwmance of any or all of the terms or the obligate of the Contract, Including all alterations, amendments and modifications thereto, and any warranties or guarantm required tiwreunder. then this obligation shalt be void. otherwise, ft shelf be and shall remain in fug farce and effect. Surety stipulates and agrees, for value received, that no adjustment of the time or price in the Contract or any alWatlon, change. deletton. addition or other modlflcallon to the Contract, or the work to be performed thereunder, shall In any way affect, knit, restrict, impair or release the obligations of this Surety under this Bond. Surety waives notice of any adjustment of contract time or contract prig, and srtss►_r PERFORMANCE BOND Page l of 2 Bond NO 8219-64-20 any other sherwon, change, deWon. addiaon or other rw%xWIcadon to the Contract, or the worts to be performed thereunder. and agrees to aulomeffcally adjust the penal sum of this Bond to reflect such adjustments, allleraWrt6, changes. deloWns, additions oredter moditafions. Surety agrees to provide wrkton confrontation of such adjustments In the penal sum to City on not less than a quarterly basis. Surety also wolves the provisions of Ctvii Code §§ 2845 and 2849- The 01098tiOns of this Bond shah survive the completion of the work described in the Contract as to aff obligOwns and liabilities of the Principal which 8urVNe cornpletion of the work. IN WITNESS WiEREOF, each party represents and warrants that this instrument has been duly executed by Prtrtgipal and Surety. on the date set forth below. that the nacre of eao corporate party being affixed hereto is such pariy's proper legal name anti that the individuals signing then ststrunrant have been dulyeuthofted pursuant to the auttwity of Its governing body. Surety, by exea,teon of this bond, waives any defense which Surety has or may have by reason of any fallure of the principal to execute or properly execute this bond, Dstet. March 11, 2011 ATTEST Environmental Construction, Inc. (Corporate Beau (principal Name) By: Nam 'Fide: ATTEST Vigilant Insurance Company (Corporate Seal) (Su Name) BY' . 1 ot9l Name' to h tt me -in-Fact (Slgttature oll A ney-in-Fact for Surely) (Attach Attorney -in -Fact Certificate) 2( 12 ) 6124000 (Area Code & Telephone Number of Surety) APPROVED AS TO FORM: CITY O ItJ[+tTINGTON BEACH � e By Y fer M Wlsla6 Attorney Note: 7rds rxa�d mustbe ereotA9Q ht Oup9 � dated, s!<s lrrfi5t 8e noteraeQ and evidence ar flle 6t1!/r0/iQ/ Or enypes�oat somas a+�mu�be eP�d►ed PERFORMANCE BOND Page 2 of 2 CAL IFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of LOS ANGELES On V - 1-1 before me, BEVERLY PARKS, NOTARY PUBLIC , Date Here Insert Name and Title of the Officer personally appeared FARID SOROUDI Names) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/sheAhey executed the same in his/her/their authorized .� BEVERLY PARKS capacity(ies), and that by his/herAheir signature(s) on the Commission # 1806841 -m Notary Public - California instrument the person(s), or the entity upon behalf of Los Angeles County = which the person(s) acted, executed the instrument. My Comm. Expires Jul 19, 2012 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. .WITNE hand and official e . Signature Place Notary Seal Above Signa t Notary Public OPTIONAL e Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑' Individual ❑ Individual ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General _ _ ❑ Partner — ❑ Limited ❑ General O Attorney in Fact lnffel ❑Attorney in Fact '- ❑ Trustee Top of thumb here ❑ Trustee Top of thumb here ❑ Guardian or Conservator ❑ Guardian or Conservator ❑ Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02007 National Notary Association- 9M De Soto Ave., P.O. Box 2402 • Chatsworth, CA 91313-2402 • www.Natona[Notary.org Item #5907 Reorder. Cal Toll -Free 1-e00-e76.6e27 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT lou; STATE OF CALIFORNIA County of Orange On ? < < i' before me, Irene Luong, Notary Public Dat Here insert Name and Tifle:of the:Offiber personally appeared Stephanie Pham Name(s):of Signer(s) who proved to: me: on the basis of satisfactory evidence to be the person(o) whose name(s) is./afe subscribed to the within instrument and`acknowtedged to me that he/sheithay executed the:same in #risiherltKimr alltborized capacity(ies), and that Wy Utter%their sign atiure($} on the instrument the persan(s), or the entity upon behalf of which the person(s) IRENE LUONG acted, executed the instrument. Commission # 1883838 a --� Notary Public -California z 1:certify under PENALTY OF PERJURY under the laws of z ' orange County D the State of California that the foregoing paragraph is true My Comm. Expires Mar 22, 2014 and correct. Witness my hand an ffid I s al Signature Place Notary Seat Above Signature of Notary Public OPTIONAL Though the information below is not required by taw, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to andther.document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Stephanie Pham ❑ Individual ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ® Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer is Representing: Signer's.. Name.- ❑ Individual ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer, is Representing: * 2007 National Notary Association - 9350 De Soto Ave_ P_O. Box 2402 -Chatsworth, CA 91313-2402 - www.NahonalNotary.orq Item #5907 Reorder: Call Toll -Free 1-800-876-6827 Chubb POWER Federal Insurance Company Attn: Surety Department OF Vigilant Insurance. Company 15 Mountain View Roar! Surety ATTORNEY pacificIndemnity Company Warren, NJ 07059. Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana corporation, VIGILANT INSURANCE COMPANY, a New York corporabon,.and PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Shawn Blume, Eric Lowey, Stephanie Pham and Mark Richardson of Costa Mesa; California each as thefrtrue and lawful Attorney- in- Fad to.execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise, bonds and undertakings and other writings obligatory in the nature thereof (other than bail bonds) given or executed in the course of buslness,:and any Instruments amending or at ering the same; and consents to this mcdfication or alteration of any instrument referred to in said bonds cr obligations. In Witness Whereof; said FEDERAL INSURANCE COMPANY, VIGILANT.INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY have each executed and.attested these presents and affixed their corporate seals on this 15th day of January, 2010. ne h C:: _; : ntSecretary Da . Norris,:Jr;lfke Pr STATE OF NEW JERSEY ss" County of Somerset On this 15th . day of January, 2010.before me, a Notary Public of New Jersey, personally came Kenneth:C.-W.endel, to me known to be Assistant Secretary of;FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY -and PACIFIC INDEMNITY COMPANY, the companies which executed the foregoing Power: of Attorney, and the said Kenneth C. Wendel, being by ma duly swom; did -depose and say that: he Is Assistant Secretary of FEDERAL INSURANCE COMPANY. VIGILANT.NSURANCE COMPANY, and.PACIFiC INDEMNITY COMPANY and knows:,the corporate ssaWthered, that the seals:affixed to the foregofng`Power of Attomey:are such corporate seals and were thereto affixed by authority of the By- Laws of said Companres;;and that he signed said Powerbf Attorney as Assistant Secretary of,said Companies by like authodty; and that he is acquainted with David B. Norris, Jr.: and knows hum to be Vice. President of said Companies: and#hat the signature of David 8. Norris, Jr., subscribed to said Power of.Attomey is in the genuine handwriting of David B. Nords, Jr., and: was thereto subscribed by authority of said By- laws and in deponents presence_ Notarial Seal NOT ENNE J. ADELAAR rr `� pUBUC OF NEW JERSEY ptfs No 2316685 Notary Public q'�q*rf'On bPh111116 JUIY lb, 2014 CERTIFICATION Extract from the By- Laws of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY; and PACIFIC INDEMNITY COMPANY: "Ali powers of attorney for and on behalf of the Company may and shall be executed in thie name and on behalf of the Company; either by the Chairman or the President or a Vice President or an Assistant Vice President, jointly with the Secretary or an Assistant Secretary; tinder their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the following officers: Chairman, President, any Vice. President, any Assistant Vice President, any Secretary, any Assistant Secretary and lire seal of the Company may be affixed by facsimile to any power of attorney or to.any certificate relating thereto appointing Assistant Secretaries or Attorneys- in- Fact for purposes only of executing and attesting bonds. and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile:seai shall be valid and binding upon the Company and any such pourer so executed and certified by such facsimile signature and facsimile seal shag be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." 1, Kenneth C. Wendel, Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY (the "Companies) do hemby certify that (i) the foregoing extract of the By- Laws of the Companies is true and correct, (it) the Companies are duty licensed and authorized to transact surety business in all 50 of the United States of America and the District of.Columbia and are authorized by the U.S. Treasury Department; further, Federal and Vigilant are licensed in Puerto Rico and the U.S. Virgin islands, and Federal is licensed in American Samoa, Guam, and each of fie Provinces of Canada except Prince Edward Island; and. (Iid) the foregoing Power of Attorney is true, correct and in full force and effect. Given under my hand and seals of said Companies at Warren. NJ this March 11, 2011 " Jn RCO is ° Y Kenneth C. , Assistant Secretary IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM, VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER, PLEASE CONTACT US AT ADDRESS LISTED ABOVE, OR BY Telephone.(908) 903- 3493 Fax (908) 903- 3666 e-mail: surety Ochubb.com Form 15-10- 0225B- U (Ed. 5- 03) CONSENT City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachea.gov Office of the City Clerk Joan L. Flynn, City Clerk April 12, 2011 Environmental Construction, Inc. Attn: Mar. Farid Soroudi 21550 Oxnard St., Ste. 1050 Woodland Hills, CA 91367 Re: Water Well No. 10 Rehabilitation Project — CC-1380 The City Council awarded the bid to your company for the above referenced project. Enclosed is a copy of the executed contract with the City of Huntington Beach. A Certification of Compliance with Title VII of the Civil Rights Act, Certification of Compliance with Prevailing Wage Laws and Contractor's Certificate form must be returned to this office after the proiect is completed but prior to the release of retention funds. In addition, the following item must also be on file, with this office before the City can release any retention funds: A warranty bond guaranteeing the final amount of work and materials for one year. If your performance bond does not include specific wording for a one-year warranty, then a rider or separate bond must be submitted. Should you have any questions or concerns regarding the enclosures or items that must be on file in this office prior to release of retention funds, please call the Public Works Department at 536-5437. Sincerely, y a4� y Clerk JF:pe Enclosures: Copy of Contract including Proposal Copies of insurance/bonds Contractor's Certificate Certificate of Compliances Bid Bond (original) gSOt,oupeint\omjogrjlatago,♦ Waitakere, New Zealand Certification of Compliance with Title VH of the Civil Rights Act and Equal Employment Opportunity Act of 1972 To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Contract: Project: The undersigned contractor on the above -referenced project ("Project") hereby certifies that it has complied with.Title VU of the Civil Rights Act, the Equal Opportunity Act of 1972 and Executive Order 11246, and has not discriminated against any employee or applicant for employment because of race, creed, color, sex, national origin, age or disability. The undersigned contractor also certifies that it has not maintained any segregated facilities at its establishments on the basis of race, creed, color, sex, national origin, age or disability (with the exception of access for the disabled). I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this day of ; 20_, at , California. (Type Contractor Name) By: Name: [Type Name] c�R�► Title: [Type Title] E , IF g t� 'Y_ A L�RNEY _IL) 3--1)6-UP 1 245911.1 1, i CONTRACTOR'S CERTIFICATE state and certify that: (Name of Declarant) is the general contractor to the City of Huntington Beach ("City') on Contract No. (the "Contract") for the'construction of the public work of improvement entitled: (the "Project"). 2. All work to be performed pursuant to the Contract has been completed in accordance with the Contract Documents (as such term is defined in the Contract). 3. Except for the claims listed.below and the disputed claims listed in paragraph five (5), all persons supplying labor, services, materials and equipment to the Project, including all claims against the Contractor arising from the performance of the Contract, have been paid and satisfied (list .unpaid debts and claims; if none, write "NONE"): 4. Attached hereto are the lien waivers required by the Contract Documents, which lien ,waivers have been executed by all persons who performed work on or supplied labor, services, materials, and/or equipment for use at the Project. 5. Set forth below is a list of disputed claims or claims that are the subject of a Notice to Withhold filed pursuant to the Civil Code of the State of California (list all disputed claims; if none, write "NONE"): I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed at on this _ day of , 20 (Signature of Declarant) APPROVED AS TO FORM By: s1 TL) 3 . Zo ot,o Name: [Type Name] Title: [Type Title] 245914 1 Certification of Compliance with Prevailing Wage Laws To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Prevailing Wage Laws Contract: Project: The undersigned contractor on the above -referenced project ("Project") hereby certifies that all laborers, mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor performing work under the contract for the Project have been paid pursuant to the minimum wage and bona fide fringe benefit -requirements specified for each particular classification of work, as set forth in the wage -rate determinations of the State of California, Department of Industrial Relations, and/or the United States Department of Labor. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this day of 20 , at (Type Contractor Name) By: Name: [Type Name] Title: [Type Title] California. _T S 03 '(TIP 247542! TT Council/Agency Meeting Held:_ A0 Deferred/Continued to: l*pp ved ❑ Conditionally Approved ❑ Denied � C y Cler s Sig ure Council Meeting Date: March 7, 2011 Department ID Number: PW 11-011 CITY OF. HUNTINGTON BEACH REQUEST FOR CITY COUNCIL ACTION SUBMITTED TO: Honorable Mayor and City Council Members SUBMITTED BY: Fred A. Wilson, City Manager PREPARED BY: Travis K. Hopkins, PE, Director of Public Works SUBJECT: Approve project plans and specifications and award Construction Contract in the amount of $385,914 to Environmental Construction, Inc. for the Water Well No. 10 Rehabilitation Project, CC-1380; and, authorize the Mayor and City Clerk to execute a contract in a form approved by the City Attorney Statement of Issue: On February 8, 2011, bids were opened for the Water Well No. 10 Rehabilitation Project, CC-1380. Staff requests City Council award the contract to Environmental Construction, Inc., the lowest responsive and responsible bidder. Financial Impact: Funds in the amount of $590,000 are available in the Water Fund, Well 10, Account No. 50691026.82100. Recommended Action: Motion to: A) Approve the project plans and specifications for the Water Well No. 10 Rehabilitation Project, CC-1380; and, B) Accept the lowest responsive and responsible bid submitted by Environmental Construction, Inc., in the amount of $385,914; and, C) Authorize the Mayor and City Clerk to execute a construction contract in a form approved by the City Attorney. Alternative Action(s): Reject all bids, and provide staff with alternative direction. HB -275- Item 8. - 1 REQUEST FOR COUNCIL ACTION MEETING DATE: 3/7/2011 DEPARTMENT ID NUMBER: PW 11-011 Analysis: Water Well No. 10 is located at 16192 Sher Lane at the northwest corner of Sun View Park. The facility, originally constructed in 1982, is used to extract groundwater to meet City's annual water use. On September 21, 2009, Water Well No. 10 sustained significant fire damage. It is believed that the pressurized ventilation/cooling system caused the fire. After evaluation, City staff decided to revise the ventilation system design to reduce the fire potential and also included other design changes in the revised plans and specifications to further improve the operation and maintenance of the water well. The scope of work consists of replacing the damaged engine room roof, replacing the muffler and catalytic converter, and constructing a new detached muffler room. It will also include converting the adjacent former chlorine room into a separate control room, installing new controls and telemetry system, and other repair/upgrades necessary for the proper operation of the well pump station. A complete set of plans and specifications are available for review at the Public Works counter during normal business hours. Bids were opened publicly on February 8, 2011, and are listed in ascending order: BIDDING CONTRACTOR BID AMOUNT BID AMOUNT CORRECTED Environmental Construction, Inc. $385,714.00 $385,914.00 Falcon General Engineering, Inc $398,303.00 $399,317.00 Olsson Construction, Inc. $431,000.00 $431,000.00 Sepulveda Construction $432,439.00 $432,439.00 Pointer Enterprise, Inc. $433,950.00 $433,950.00 SCW Contracting Corporation $449,826.00 $449,826.00 ATOM Engineering Construction $455,979.00 $455,979.00 United Engineering & Construction $471,600.00 $471,600.00 4-Con Engineering, Inc. $497,750.00 $497,750.00 Bid amounts were verified and the lowest responsive bidder was determined to be Environmental Construction, Inc. The reference check for Environmental Construction, Inc. provided acceptable responses from past clients. Due to favorable construction climate, the low bid came in under the engineer's cost estimate of $500,000. With contingency (10%), supplemental expenses, and expected staff costs, the full project cost is estimated to be $502,000. Supplemental expenses are estimated at approximately twenty (20) percent for soils and materials testing, construction management and inspection support services by consultant, and additional engineering support. Environmental Status: The project consists of rehabilitation of existing City -owned facilities, with little or no negligible expansion of an existing use. The project is, therefore, categorically exempt from CEQA per Article 19, Section 15301. Public Works Commission Action: The Public Works Commission reviewed and approved CC-1380 on July 21, 2010, with a vote of 6-0-1 (Herbel absent). Item 8. - 2 HB -276- REQUEST FOR COUNCIL ACTION MEETING ®ATE: 3/7/2011 DEPARTMENT I® NUMBER: Pal 11-011 Strategic Plan Goal: Maintain, improve and obtain funding for infrastructure and equipment Attachment(s): HB -77- Item 8. - 3 ATTACHMENT Item 8. - 4 NB -27 - 9 Well No. 10 �.. Edinger Avenue ! North AP PROJECT LOCATION o U c WATER WELL NO. 10 REHABILITATION PROJECT CC1380 i I HB -279- Item 8. - 5 Water Well NO.10 Rehabilitation Project, CC1380 Bid Opening February 8, 2011 2:00 PM Huntington Beach Council Chambers Bidder Bid Amount Bid Amount Corrected 1 4-Con Engineering, Inc. OD --- 2 Adams/Mallory Construction Co. Inc. 3 Alfa Electric 4 ATLAS ALLIED, INC. 5 ATOM ENGINEERING CONSTRUCTIN --- 6 Beard Electric Cora Constructors 8 Dave Shultz 9 Environmental Construction 10 Falcon General Engineering, Inc 7 11 FLEMING ENVIRONMENTAL INC. 12 G2 Construction, Inc. 13 Leed Electric, Inc. 14 MCI General Building 15 Metro Builders & Engineers Group Ltd. 16 Olsson Construcion, Inc. 17 Palm Springs Pump West 18 1pima Corporation 19 Pointer Enterprise, Inc. %50 -- 20 R.Y. Engineering Works, Inc 21 Rick Hamm Construction, Inc. 22 S.S. Mechanical Corp. 23 SCW Contracting Corporation 24 Sepulveda Construction 25 Shultz Electric 26 Tamang Electric 27 United Engineering & Construction 28 29 30 31 32 33 2011 FEB -8 Pi"I 2., 00 71 6:-/1r4/L - / /3 // / SECTION A )1i-3//1 NOTICE INVITING SEALED BIDS for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated projects and will receive such bids in the office of the City Clerk, Second Floor, 2000 Main Street, Huntington Beach,. California 92648, up to the hour of 2:00 PM on February 8, 2011. Bids will be publicly open in the Council Chambers unless otherwise posted. Copies of the Plans, Specifications, and contract documents are available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $90.00 nonrefundable fee if picked up, or payment of a $110 nonrefundable fee if mailed via U.S. Postal Service, FedEx, UPS or any other delivery service. Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000. Main Street, Huntington Beach, CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders as determined by the AGENCY. The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State A-1 Contractor's License Class A at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. Project Description: The Work generally includes: demolishing and constructing a new muffler room, replace existing walls, construct a new concrete roof on the existing pump room, pave and grade well site, rehabilitate or rearrangement various above ground and underground piping and conduits, relocate pump control to adjacent room, install various new and AGENCY furnished equipment, including and not limited to engine control panels, instrumentation equipment, chemical equipment, and associated equipment. Install new and rehabilitate lighting system, install replacement pump engine, replace existing underground natural gas feed line, and related appurtenant work not mentioned above but required in accordance with the Contract Documents. The Work is located at Sher Lane and Amazon Drive in Huntington Beach, CA. The project schedule is 100 working days. The engineer's estimate for the work is $500,000. There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park lust north of Sun View Elementary School. From there, every attendee of the mandatory Job walk will proceed to the Well #10 site. Installation of natural gas Waukesha engine shall be by AGENCY approved sub - consultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall ONLY be sub -contracted to MurCal, Inc. The AGENCY reserves the right to reject any or all bids, to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH, CALIFORNIA,- the 20th day of September 2010, by Resolution No. 2010-69. Attest: Joan L. Flynn CITY CLERK OF THE CITY OF HUNTINGTON BEACH A-2 PROOF OF PUBLICATION STATE OF CALIFORNIA) ) SS. COUNTY OF ORANGE ) I am a citizen of the United States and a resident of the County aforesaid; I am over the age of eighteen years, and not a party to or interested in the notice published. I am a principal clerk of the HUNTINGTON BEACH INDEPENDENT, which was adjudged a newspaper of general circulation on August 24, 1994, case A50479, for the City of Huntington Beach, County of Orange, and the State of. California. Attached to this Affidavit is a true and complete copy- as was printed and published :on the following date(s) : January 6, 13, 20, 2011 I certify (or declare) under penalty of perjury that the foregoing is true and correct. Executed on January 25, 2011 at Costa Mesa, California C77, Signajwfe .: NOTICE INVITING SEALED BIDS for the WATER WELL NO. 10 REHABILITATION PROJECT ' `CC No. 1380 " in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above statedprojects And will receive such bids in the office.of the City Clerk, Second Floor, 2000 Main Street, Huntington. Beach, California 92648, up to'the hour of 2:00 PM on February 8, 2011. Bids will be.publicly open in the Council Chambers unless,otherwise posted. Copies of the Plans, Specifications, and contract documents are available from the Office of the Director of Public Works,, 2000 Main Street, Huntington Beach, CA 92648, upon payment,of a $90.00 nonrefundable fee if picked up, or payment of a`$110 nonrefundable fee if mailed via U.S. Postal Service, FedEx, UPS or any other delivery service. Any contract entered into pursuant, to this notice will incorporate the provisions of the State Labor Code. .,Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of, workman needed to execute the contract shall be those determined by the Director of Industrial Relations, of the State of California, -which are on file 'at the Office of the Director 'of Public Works; 2000 Main Street,' Huntington Beach, CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor. may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. " The AGENCY hereby affirmatively ensures that minority business enterprises will be' afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry; sex, or religion in. any consideration leading to the award of contract. No bid shall be considered unless it is prepared on -the' approved Proposal forms in conformance with the Instructions to'Bidders as determined by the AGENCY. The bid must be accompanied by .a certified check,. cashier's check, or bidder's bond madepayableto the, AGENCY for an.amount no less than 10%•of the amount bid'. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a -State Contractor's License Class A at the time of the bid opening. The successful Contractor and his subcontractors -will be required to possess business licenses from the AGENCY.. Project Description: The Work generally .includes:, demolishing and constructing a new, muffler room, replace existing walls, construct a new concrete roof on the existing pump room, pave and grade. well site, rehabilitate or rearrangement various above ground. and underground piping and, conduits, relocate ;pump control to adjacent room," install various new and AGENCY furnished equipment, including and not limited to engine cbntrol panels, instrumentation equipment, chemical equipment, and associated equipment. Install"new and rehabilitate lighting system, install replacement pump engine, replace existing underground natural gas feed line, and related appurtenant work not mentioned above but required An accordance with the Contract Documents. The Work is located at Sher. Lane and'Amazon Drive in Huntington Beach, CA. The project schedule is 100 working days. The engineer's estimate for the work is $500 000. There' will be a mandatory job walk for bidders on Wednesday, January 26th of 9:00 o.m: The location to meet will be near 16192 Sher Lane, Huntington Beach; by the City, park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to The Well # 10 site.. Installation of, natural gas Waukesha engine. shall be by AGENCY approved sub-consultcint as a. sub -contract to the .contractor as defined by the, contract documents and Specifications. All construction sequencing and coordination between all trades 'shall' remain the responsibility of the.contractor including but not limited to systems testing, start-up and commissioning. Installation of engine control panels; instrumentation equipment, chemical equipment, and associated equipment shall ONLY _ be sub -contracted to MurCal, Inc. The AGENCY reserves the right to reject any or all ,bids, .to waive any irregularity and" to take all bids.under advisement_ for a maximum period of 60 days. . BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH, CALIFORNIA, the 20th day of September 2010, by Resolution No. 2010-69. Attest: Joan L. Flynn CITY, CLERK OF THE CITY,OF HUNTINGTON BEACH P.ublified Huntington Beach Independent January 6, 13, '20, 2011 UNSUCCESSFUL BIDS Water Well # 10 Rehabilitation Project City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 Atom, Inc. 40410 Vista Rd. Hemet, CA 92544 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, I � - jrA) Joan L. Flynn, CMC City Clerk JF:pe Enclosure gSi9bW0itS6wmtL%jmPd"0r41o♦ Waitakere, New Zealand AToM; Inc. '40410 Vista Rd, HeM EA ` 92544 '. !7; 2011 Frl - 0 pi -I 4 SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find & ed 6,M4 in the amount of $ 10 61J 6�which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda go i i '!,P i i ie"Received"nature',,"" C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 1 1 Mobilization LS $ $3592 9 2 1 Temporary sheeting, shoring, and bracing LS $ C90® ev $ 010� 00 ` 3 1 Removal temporary sheeting, shoring, bracing � LS $mod a $/S''90 . 4 1 Demolition of existing muffler room, blower shed and paving LS $/S��® Z% y $/ 5 1 Grading and trenching LS $ d ao. V' $ rJ OG 6 1 LS Install gas engine, driveline and appurtenant equipment 2 Lrt-© $E� 7 1 Construct muffler room and install silencers LS $ ®d �O q $ ad sVd There will -be a mandatory iob walk for bidders on- Wednesday-, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers a• LS $ / $ l da 11 1 Install 16-inch flowmeter LS $ Oao $ dad 12 1 Paving LS 13 1 Install catalytic converter and engine exhaust piping LS $ [® 0 $ ' cad There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler 14 1 LS room roof mounted blower $ 0®�1 $.ti (?UU Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation 15 1 of engine control panels to be conducted by MurCal, Inc LS $ 16 1 Install fencing LS 0g-O q � 'aC) 17 1 LS System testing and commissioning a $ �Dv $�,Sod 18 1 Clean-up & demobilization LS $X� �v CP $/f� 19 1 Provision and implementation of the SWPPP plan LS y P GU 116 There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington- Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 LS Provision of Traffic Control Plan $� $ /©G ®� 21 1 LS Provision of implementing traffic control f $��/ — $ 9 d Total Amount Bid in Figures 0S Basis of Award : $ Sjj' - 9127 �.- Total Amount Bid in Words:/ �OV A � u ri top lei Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. 'Portion of, W k N,same _and Address- of Subcontractor :fir ; ..;:,.;.;<.. State L,rcense ,,1Vumber<;;. ;, Class A. J .per ke,A , ©wJV M5 vlfG A �.�� ��� � c-20 C5� fN�/ Goy CJ' d0 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County ofjUmngp, f���°�� being first duly sworn, deposes and says that he or.sle.is of J'IT(� ( . 7VI C d _ the party making the foregoing bid that the bid is not made in the interest A, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. A�)ffl WpC Name of Bidder Signature of Bidder k4c)'Alo J s Address of Bidder Subscribed and sworn to before me this day of , 201_ . NOTARY PUBLIC (' �f1 f'l.'� dc� (-6+ 1 NOTARY SEAL C-1 State or California County of :R j ver5; .e_ Subscribed and sworn to (or affirmed) before me on this by L--G_(A-1 ,atisfactory evidence to be the re me. mature <&< UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: C-1 _aTocn�-a Contractor a Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes �No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: C-1 &aourn Contractor By CA Chi 64) ��� {��PsjrdM�- Title L' BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name L-�bL,\jb V Business Address City, I State Zip A's] ) `+- �R i'-.::PCb L e Telephone Number State Contractor's License No. and Class -tcl—lo Original Date Issued � -31— d,�a— Expiration Date The work site was inspected by &�oeil+ of our office on 201L. The following are persons, firms, and corporations having a principal interest in this proposal: C-1 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. -tom (" Company Name Signature of Bidder Printed or Typed Signature Subscribed and sworn to before me this _ day of , 201_ NOTARY PUBLIC ; exe 4-4 ArL V ea) i" NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 2. 3 Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Date Completed Date Completed Contract Amount Type of Work Date Completed 1031 State of California County of 'I �.le�s;c�'� Subscribed and sworn to (or affirmed) before me on this�� day of . 20LL—, by c., n11 proved to me on the basis of satisfactory evidence to be the person(-- who appeared before me. TERRA J. COX Commission * 1892519 Notary Public - California Riverside County rSeal) Signature ATOM, Inc. DATE OWNER/JOB ATTACHMENT "A" TOTAL CONTRACT 9/10-12/10 Metropolitan Water District 201 Rio Hondo Power Plant Seal Water Discharge $ 700 N. Alameda Ave. Los Angeles, CA. 90012 213-217-6000 Harout Kassabian 10/10-3/11 City of Norco 202 Auger/Grinder Wastewater System $ 2870 Clark Ave. Norco, CA. 92860 951-735-3900 Bill Thompson 11/10-12/10 Orange County Sanitation District $ 203 Plant 2 Ocean Outfall Seal Repairs 10844 Ellis Ave. Fountain Valley, CA. 92708 714-720-6967 Markopolo Valasco 11/10-2/11 City of Seal Beach $ 204 Firestation 48 Fuel Island Cover 211 8th St. Seal Beach, CA. 90740 562-431-2527 Michael Hoe 12/10-4/11 Olivenhain Municipal Water District $ 205 Septage Dump Station & Catwalk at 4S WWTF 1966 Olivenhain Rd. Encinitas, CA. 92024 760-753-6466 Dan Badalucco 1/11-2/11 City of Moreno Valley $ 206 Sunnymead Blvd. Intersection Enhancements 14177 Frederick St. Moreno Valley, CA. 92552 951-413-3000 Chris Vogt 35,428.00 281,095.00 4,289.00 65,359.00 72, 573.00 13, 979.00 $ 472,723.00 ATOM Engineering Construction 8/09-2/10 County of Orange 101 Yorba Park Group Shelter #4 333 W. Santa Ana Blvd. Santa Ana, CA. 92701 714-227-3992 Frank Cristaldi 9/09-10/09 City of Irwindale 102 Storm Drain Catch Basin Inserts 5050 N. Irwindale Ave. Irwindale, CA. 91706 626-430-2200 Edgar Rojas 9/09-5/10 Metropolitan Water District 103 CUF Shade Structure 700 N. Alameda Ave. Los Angeles, CA. 90012 213-217-6000 Dave Farmer 10/09-3/10 Orange County Sanitation District 105 Digester 7,8 & 10 Stair repairs 10844 Ellis Ave. Fountain Valley, CA. 92708 714-720-6967 Markopolo Valasco 10/09-10/09 Hemet Adventist Christian School 106 Front Entrance Landscape 26312 Hemet St. Hemet, CA. 92544 951-927-3972 Gary Brown 10/09-2/10 Metropolitan Water District 107 Coyote Creek Seal water discharge 700 N. Alameda Ave. Los Angeles, CA. 90012 213-217-6000 Everett Mundkowski 10/09-5/10 City of Manhattan Beach 108 City Yard Fuel Island Cover 1400 Highland Ave. Manhattan Beach, CA. 90266 310-802-5000 Ish Madrano 10/09-10/09 Pine Springs Ranch 109 PSR Fence 58000 Apple Canyon Rd. Mountain Center, CA. 92561 951-659-4131 Fritz Wutke $ 105, 979.00 $ 39,374.00 $ 35, 979.00 $ 44,935.00 $ 1,000.00 $ 33,935.00 $ 93,729.93 $ 4,485.00 ATTACHMENT "A" 3/10-5/10 City of La Palma $ 80,772.00 121 Community Center Remodel 7822 Walker St. La Palma, CA. 90623 714-690-3300 Jeff Moneda 11/09-2/10 Chino Valley Unified School District $ 182,503.40 111 Irrigation at various sites 5130 Riverside Dr. Chino, CA. 91710 909-628-1201 Martin Silveria 12/09-3/10 Orange County Sanitation District $ 59,114.00 114 Plant 2 Ocean Outfall Bulkheads Repair 10844 Ellis Ave. Fountain Valley, CA. 92708 714-720-6967 Markopolo Valasco 12/09-7/10 Joshua Basin Water District $ 510,441.44 115 E1,D2 Booster Pump Station Replacement 61750 Chollita Rd. Joshua Tree, CA. 92252 760-366-8438 Randy Little 2/10-2/10 Chino Valley Unified School District $ 14,500.00 116 Chino hills High Scoreboard 5130 Riverside Dr. Chino, CA. 91710 909-628-1201 Martin Silveria 3/10-4/10 City of Laguna Beach $ 41,444.53 117 Bon Drive Terrace Drain 505 Forest Ave. Laguna Beach, CA. 92651 949-497-3311 Lisa Penna 3/10-4/10 Palm Springs Unified School District $ 71,514.26 118 Two Bunch Elem Wind Screens & Site Work 980 E. Tahquitz Canyon Palm Springs, CA. 92262 760-416-6126 Joel Sorenson 3/10-5/10 OC Waste & Recycling $ 65,312.58 119 HB Hazardous Waste Recycle Site Work 300 N. Flower St. Santa Ana, CA. 92703 714-834-4000 Jared Kemp 3/10-4/10 City of Palm Springs $ 39,010.20 120 PS Stadium Re -Roof 3200 E. Tahquitz Canyon, CA. 92262 Michael Mott 760-323-8255 11 3/10-4/10 Palm Springs Unified School District 121 Cathedral City High Roll up Doors 980 E. Tahquitz Canyon Palm Springs, CA. 92262 760-416-6126 Joel Sorenson 4/10-11/10 City of Carlsbad 124 La Costa Ave Sub Drains 1200 Carlsbad Village Dr. Carlsbad, CA. 92008 760-434-2830 Constantine Avalos 4/10-11/10 County of Riverside Parks & Recreation 125 San Timoteo Schoolhouse Improvements 4080 Lemon St. Riverside, CA. 92501 951-955-1000 Steve Lech 4/10-7/10 City of Manhattan Beach 126 Strand & Live Oak Erosion Control 1400 Highland Ave. Manhattan Beach, CA. 90266 310-802-5000 Ish Madrano 5/10-6/10 Housing Authority of Riverside County 127 Aladdin Apartments Landscaping 5555 Arlington Ave. Riverside, CA. 92504 951-351-0700 Anita Rhodes 6/10-9/10 City of Temecula 132 Road & Storm Drain Damage 43200 Business Park Dr. Temecula, CA. 92590 951-694-6444 John Salazar 6/10-12/10 City of Carrsbad 133 Calle Barcelona Ped Bridge Repair & Veneer 1200 Carlsbad Village Dr. Carlsbad, CA. 92008 760-434-2830 6/10-7/10 Carlsbad Unified School District 134 Carlsbad High Baseball Scoreboard 6225 El Camino Real Carlsbad, CA. 92009 760-331-5000 Deon Harrington 27,935.00 158, 969.43 348,214.14 99, 339.82 83,647.20 $ 45,359.00 $ 121, 979.00 $ 64,928.00 $ 2,374,400.93 The following shall be deleted from the Specifications, page 16 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, d ed January 26, 2011. Company Namd By L-4c&"t6 . 8-ni' ,"'tfi Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 28, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The attached new SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be added to the Specifications, within "PART 4 — TECHNICAL SPECIFICATIONS". All references to "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be considered as exposed piping and/or equipment insulation as per Section 15250, para. 2.2. The following shall be added to the Specifications, page viii in the "Table of Sections": 15250 — Insulation for Exposed Piping and Equipment This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number two, dated January 28, 2011. C—V—�� 4TC.>>M Company Name By #— �C2�Il� 4er, 0rPSP'/1 I Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -1- SUIRETY FIRST NATIONAL 1NSURANCECO. OF AMERICA 4333 Brooklyn Avenue N.E. Seattle, W A 98105 BID BOND KNOW ALL BY THESE PRESENTS, That we, ATOM, INC. of 40410 VISTA RD. , HEMET CA 92544 (hereinafter called the Principal), as Principal, and FIRST NATIONAL INSURANCE COMPANY OF AMERICA, of Seattle, Washington, a corporation duly organized under the laws of the State of Washington as Surety, hereinafter called the Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH (hereinafter called the Obligee) in the penal sum of TEN PERCENT OF THE AMT. BID Dollars ($ 10% OF BID AMT. ) for the payment of which the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, That Whereas, the Principal has submitted or is about to submit a proposal to the Obligee on a contract for WATER WELL NO. 10 REHABILITATION PROJECT NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within such time as may be specified, enter into the contract in writing, and give bond, if bond is required, with surety acceptable to the Obligee for the faithful performance of the said Contract, then this obligation shall be void; otherwise to remain in full force and effect. Signed and sealed this 27th day of JANUARY 2011. ATOM, INC. (Seal) Principal — I Witness Pf'+eS;destfi Title FIRST NATIONAL INSURANCE COMPANY OF AMERICA By M"D.STONG P to; ney-in-Fact S-9208/Ev 7/94 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT G�t,.GLt vai! 1S!'•1i!',><!.):/ )>!.)t! )i! ))/ ). !G\S/.G\ / i!GTt!.�?i - . _r1>! \t ).. 1�, .)tom " +ai" )..fir ".J>_ 1�, r\ . )<:'.!�{.'s)C/'n</ C/ /- / / J• /• State of California County of Riverside On l' �J j-' 1 before me, Terra Cox,_ Notary Public Date Here Insert me andTitle 01 ft ofter ' personally appeared Larry Boyer Nam(s) of SWtei(s) - > who proved to me on the basis of satisfactory evidence to be the person(&). -whose nameW is/are-subscribed to the within instrument and acknowledged to me that TERRA J. COX he/sb�ey�executed the same in hisJherAheir-authorized Commission 1892519 capacity(ies); and that by hisfied"r signatures} -on the = Notary Public - California Z instrument the person(e); or the entity upon behalf of Riverside County which the person("cted, executed the instrument. My Comm. Ex Tres Jul 10, 2014 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Place Notary Seal Above Signature of Notary Pudic OP77ONAL Though the information below is not required by law, it may prove valuable to persons retying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document 8,z (c),ad Title or Type of Document: Document Date: } -off - (.� Number of Pages: Signer(s) Other Than Named Above: P_ JJ�� Capacity(ies) Claimed by Signer(s) Signer's Name: Larry Boyer Signer's Name: ❑ Individual ❑ Individual ® Corporate Officer — Title(s): President ❑ Corporate Officer — Tdle(s): ❑ Partner — ❑ Umited ❑ General ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Attorney in Fact ❑ Trustee Top of thumb here ❑ Trustee Top of thumb here ❑ Guardian or Conservator ❑ Guardian or Conservator ❑ Other: ❑ Other: Signer Is Representing: Signer Is Representing: C 2007 National Notary Assodedon- QM De Soto Ave., P.O. Boot 2402-Chaftworlb.CA 91313.2402• www.NationelNotwyorg ham p5907 PWorder.Cal1 Tdl-Froe 1-800$7e-eW7 CALIFORNIA ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT State of California County of RIVERSIDE On �� f 1� before me, R. NAPPI "NOTARY PUBLIC" (Here insert name and title of the officer) personally appeared MICRAEL D. STONG who proved to me on the basis of satisfactory evidence to be the person(.g'f whose name(W�is/are subscribed to the within instrument and acknowledged to me that he/sheMwy executed the same in his4ionk tek authorized capacity{ie4 and that by his/hodtlwir signaturewon the instrument the person faj or the entity upon behalf of which the person(Kacted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. R. P µ COnqM. #97g6996 NOT Kttm„ (Notary scat) (NyCa.SXpM juice 7. 2012 Signature of Notary Public ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT (Title or description of attached document) (Title or description of attached document continued) Number of Pages Document Date (Additional information) CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer (Title) ❑ Partner(s) ❑ Attorney -in -Fact O Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM Any acknowledgment completed in l altfornta must contain verbiage exacthy as appears above in dw notary section or a separate arimmdedgment fornr must be properly completed and attached to that document. The only exception is if a document is to be recorded outside of California. In such instances. any alternative acknowledgment verbiage as may be primed on such a document so long as the verbiage does not require the notary to do something that is illegal for a notary in California (Le. certng the authorized capacity of the signer). Please check she document carefully jar proper notarial wording and attach this farm if required. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Dateof notarization must be the date that the signers) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Prim the name(s) of document signers) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/*ey, is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection ofdocument recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on rile with the office of the county clerk. • Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. • Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. if the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary)_ • Securely attach this document to the signed document 2008 Version CAPA v I2.10.07 800-873-9865 tismv.NotaryClasses.com THIS -POWER 6FATTO_ RNEY IS NOT VALID UNLESS1T.IS PRINTED'ON:RED BACKGROUND bjs 06*4iof Att6rne'y limits the acts of thosenamed hereln,':and they ha4e:no Autticirity to'bihidl the, Oompanyvxioept 10 the marinei and to theextent herein stated. FIRST N ONAL iNsuRANCCOMPANY ATI E_.,DF AMERICA SEATTL E,,WASHINGTON, POWER OlF, ATTO RNE Y', KNOW,ALL PERSONS BY THESE PRESENTS: That First National InWrance "Company of America -he 'bornpany.- j'A-W.6shiington stock insurance in -pg- pany, nt't6.and.'by�iu-thorityoft,h'e,-By-i-awl,andALithoriz,�borih,�r6inaftei�6tforthI does b, -pursuai 'here, y name, constittitean '-appoini :.-_�66EMARYNPLPPj JEREMY PENDERGAST; MIb FGRhIA..:.­ ... . .... HAELD'S TONGALL W THE CITY�:0117 RIVERSIDE ALI ..... . .............. ................. ....... .......... .... ........ ..................... ...... ..................... ............. ;:each individually if there be more than one named, fts�trueair:id tawful'attomeylin-facti6make-i execute, ',seal ,-ackh6vviedge�and -d6iiVer,'f(�r and dh:-ft-6`i*AIjas _ surety and. as -:its it! aci--and ,deed, .arty"and all. undertakings,"bonds, �reco'gnizAri6es`and- othersurety obfigaY.-ji the'- -penal -sum, -not -exc�jlng -FIFTY f4It_Lj64-AND,60/100"******** ($ and .,the '666utl ;of, S each,, . on. ��sijcf� yance , these pr �in _on e as: jnp presents - �yp th asiftheyhadlap'e- undertakings, bonds, rec'ognizances and other surety obligationspursuance of th shall -b-dift -POT by the president and -attested by the secretary of the'Compa"ny intlieir -own proper persons.- That "this Power is made and executed pursuant to and by authority bfthe fb A h ization: Itowing By-law and ut ori -ARTICLE IV, . Execution of. Cbritracts..Section A 2. -Surety Bonds and,Underiakings. 0 Anyofficer or other, official of the qQrporakion, authorlied forthiat, purpose I in.writingb -subject to such y, and h limit is the -Chairman or the President may orescribe, shall appoint 'attorneys -in Corporation'to -sd�h attorneys -in -fact, necessarytoaciir�, t4kbfthe,C - execute -seal, I , acknowledge and: deliver as , surety - any and all -undertakings, bonds, �ie6ognizAnbes And other Such aItpjrh6ys- I"II"acknowledge -1 1 , - - - I I I - - -_ - - _ , :. - , ,in - --' ' - .-fact-, - subiect to the lirnitations�, set forth I wers�o attorney, ave w&-t6_b1hd1tb6 C-orporatio I r, .1 - --- theiir-tesipeclliv�_po' f "1-'h 6--ih and qy ej signature d C :atn e I xecuted, such instrumerits,shall Lie as binding as if signed by the president and attested by_,thp secretary ox:', J By the -following'instrument the chairman, orthe president has authorized the officer orother official named thereinto appoiiit-.att6rneys-in-fact.- Pursuant to Article kV, Section 12 of the -By-laws, Garnet W. Elliott- AssistantSecretary First America, of IF t`N4ti"I Insurance Company of A ric6, is Authorized In to appoint such attorneys in -fact as may be,necessary to act in behalf of the Corporation to make, execute, seat, acknowledge and--,( e iver assuretyQ 0— Any and all undertakings,,bonds, recbgnizandes And other surety -obligations. (D->- r That the Bylaw and the Authorization set forth above are true copies thereof and are now in full force and effect. LD A IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer-or.-6ffi6Ar of'the,,Company,and the,_6or06rate..,se_aI' of Fir st , National Insurance Company of America has been Affixed thereto in Plymouth Meeting, P6nnsylva , i 11a this , 6th day of j , U pl I o , I I I I affixed , -_ Pennsylvania y ly' 2010- -C FI RST NATI �L INSURANCE. OMPANY OF AMERtCA- ONA 1�� Garnet et W. Elliott, A ssi' Assistant retary COMMONWEALTH OF PENNSYLVANIA ss COUNTY OF MONTGOMERY On this 6th' day of July 2010 before me, a Notary Public, personalty came,, Qamet W Elliott, " to me known, -and acknowledged that he is an Assistant Secretary,of First National Insurance Company of Ame I a, -that he-kh6ws 'the sea- d ric corporation; aid tfiafh6_ executed the above Power of Attorney and affixed the corporate seal of First National. Insurance Con' arty of Americailverei6 with the Authority and.at the - direction of said corporation. IN TESTIMONY WHEREOF vto subscribed my: name and affixed my notarial. seal at Plym outh Meetin ;l,.. Pennsylvania, on, the.:day and year first above written. WNW& B v nre,n pazs�ei a. Ic x G. Tere& Pastelld; Notar Publ CERTIFICATE t My C:vmS8 on Exp " _ . - __y nf 1, the undersigned, Ass st,Nabon al Insurance Company of 'America, do hereby c-ertify,1hat.the original power of attorney of Mich the foregoing. is a full,A r y, is in full force and effect on the date of this certificate- And I do further certify that the officer or officialwho executed the said power of, a it, an Assistant Secretary specially, authorized by:the chairman 6r--the fiiotidenflor - point attorneys4in-'lact, as appoint provided in Article IV, Section 12 of the By-laws of First National Insurance Company of America. This . certificate and', the above power of attorney may be signed by facsimile or mechanically'reptoduced �signatures under and by, authority of the followihg:vbte of the board of directors'of First National Insurance Company o I f America it a -meeting dutycalled.Andheld, on the 18th clay ofSeplember, 2009. VOTED that the facsimile or mechanically reproduced signature of any assistant secretaryof the company, wherever appearing upon a certified cop y y,of an power of attorney issued by the company in connection with surety bonds, shall be valid and binding upon thecompany with the same force and effect as though manually affixed. IN ESTIMONY WHEREOF, Ihave hereunto subscribed my ria xed the corporate seal of the said company, this' day Of 192a By David M. Carey', Agz-1stant'Secretary 0 City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachea.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 Falcon General Engineering, Inc. 572 Collyn St. Vista, CA 92083 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CMC City Clerk JF:pe Enclosure Waitakere, New Zealand FALCON GENERAL ENGINEERING, INC 572 COLLYN STREET VISTA, CALIFORNIA 92083 7 6 0 / 6 3 0 - 9 5 7 0 S C"�►� �\ cad K�. In \�s'x 2. )Ogl\ SECTION C PROPOSAL for the WATER WELL NO.10 REHABILITATION PROJECT CC No.1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. - BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and - all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find i O 9 &,JO in the amount of $ 20 — which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: rugF':.:�; :Ai1!deida,,lVo ��. �2 •, �,-- ,>��� s y'�:''i �'s� �'�»��?rg{., `����„ :-"r's�'f�'y�'c�Lj'�� i z C-1 PRO F,CT RM SCHMULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 1 1 Mobilization LS $ i5 Doo.� $1,DQ0�' 2 1 Temporary sheeting, shoring, and bracing LS $ ACO, $ 100, r 3 1 Removal temporary sheeting, shoring, bracing LS $ IOO.� $ ta0,' 4 1 LS Demolition of existing muffler room, blower shed and paving 6�90 $?)6.32 L 5 1 LS Grading and trenching $ 1 60 51 / $ 6 1 Install gas engine, driveline and appurtenant equipment LS $ $ 3,b. 7 1 Construct muffler room and install silencers LS $ sl8d 35-- There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City Park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will Proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting LS q $ 1 %, Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $ )5. ®i . $ i5i-qv: Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $ 14, $ y_4. 11 1 Install 16-inch flowmeter LS $ $7, �39. 12 1 Paving LS $15'ig $ 13 1 Install catalytic converter and engine exhaust piping U97• Cat.. 97, LS $ $ There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City nark iust north of Sun View Elementary School. From there. every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 197II1OTaI11 1.11 17MM1101flIIMd Item No. Estimated 2uantity Item with unit price written in words Unit Price Extended Amount 14 1 LS Install engine room roof mounted exhaust fan and muffler room roof mounted blower r $ 15 1 LS Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation of engine control panels to be conducted by MurCal, Inc i s 70, 3R• 16 1 LS Install fencing $ $�,�I�, 17 1 LS System testing and commissioning $3a(oa,` $ 3�- 18 1 LS Clean-up & demobilization 1 $ 97. $ $ $ 19 1 LS Provision and implementation of the SWPPP plan There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City hark just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 Pl2 (LiF.f T RM 'WHEDITI .R Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 LS Provision of Traffic Control Plan $Spr7, $5c; I. 21 1 LS Provision of implementing traffic control $ 5brl . ` s5u Total Amount Bid in Figures (Basis of Award): $ -M5? ` 03 Total Amount Bid in Words: I-h f 2.e. 0 u nd feA n; neiy e. is M `V-hCQSr Y c� . �('Qe. hon'lre6 e�v,�'Thc�ee Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday. January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City nark lust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. U Pvrtton Name andddress<o jSubcantractor State License ° Numberh Class 57nSit, ( e'n '?e+e(-.c) n Cw +rqQ i'19 ab c . 133. 'D-, s .4 S m , "� 8L1.?7g6 A rno`Cgt nCe Econz) RenceXnc 5 ? le,ve ; de qo!im 3377,3q C 3 �2�b�r An,berStee f C. 9 a(o 5 b(o C 5 FIedri Neal eke-c}ric /3 Sao �0�5 C'IQ Ana3cint- Y .51't'_v e Lynch Masonry '�c - �i45 Le, HG `lDl 3 r j � 5IF DP005 64-r I i e -DH1'A+/\g4znk6`l 14 oc)69L) � yc�;n};nc� K� +--T-nd rigl Lon ac i p tl �jD9bC`P C�J3 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California SS. County of Orange �� • `►.l Z , being first duly sworn, deposes and says that he or she is of the parry making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, nr to anv mPmhPr nr acrent thPrPnf tn-PffanfiratP a nnllrra;va nr-cham_h;14 CALOFORMOA ALL-PURPOSE AC KHOWLEDGMENT -- No.5193 State of California County of SAN DIEGO On 2/4/2011 before me, MICHELLE M. BASUIL, NOTARY PUBLIC personally appeared DALE E . WINTERQUIST who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/ their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. MICHELLE M. BASUIL tTHPJ Nn COMM. #1862575 NOTARY PUBLIC-CALIFORNIA ccn SAN DIEGO COUNTY ~ F My Comm. Exp AUG 24, 2013 THIS CERTIFICATE MUST BE ATTACHED TO THE DOCUMENT DESCRIBED AT RIGHT: I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. 4`7. s� Signature of Notary OPTIONAL SECTION TITLE OR TYPE OF DOCUMENT OPTIONAL SECTION I CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL ® CORPORATE OFFICER(S) PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED [:]GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(ES) Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. NUMBER OF PAGES DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROTECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: 2-N1 \ 1 C-1 N Qb�'N(2n EtJ 0 �t �SCr rS c Contractor =2 By Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes �No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 21-) I,,k C-1 Contractor By Title ;19cr'i - BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name r�-1 Z Nkll41--- SA., Business Address 2. City, State Zip Telephone Number State Contractor's License No. and Class Original Date Issued G 3 b 1 i"z- Expiration Date The work site was inspected by G6ZC1r. -- 6a h v% R of our office on I t ?-- t , 201 i . The following are persons, firms, and corporations having a principal interest in this proposal: dkr:sl y fL C-1 CALDFOO RMOA ALL-PURPOSE ACKNOWLEDGMENT GMENT No. 5193 sI State of California f„ounty of SAN DIEGO On-✓/K/1gI1 personally appeared _ before me, DEBORAH D. DAVIS, NOTARY PUBLIC DALE E. WINTERQUIST who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/ their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the sE"Fl°KA ADooRa ©. t�Avls instrument. ww E. Via, COMM. ##1737411 � I certify under PENALTY OF PERJURY under the laws of OPTIONAL SECTION � CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL ® CORPORATE OFFICER(S) PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED [:]GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: :�i r No NOTARY PUBLIC-CALIFORNIA cn ° SAN DIEGO COUNTY N the State of California that the foregoing paragraph is My Comm. Exp APf I� 21, 201� true and correct. l SIGNER IS REPRESENTING: WITNESS my hand and official seal. NAME OF PERSON(S) OR ENTITY(IES) Signature of Notary OPTIONAL SECTION THIS CERTIFICATE MUST BE ATTACHED TO TITLE OR TYPE OF DOCUMENT THE DOCUMENT DESCRIBED AT RIGHT: NUMBER OF PAGES DATE OF DOCUMENT Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. SIGNER(S) OTHER THAN NAMED ABOVE The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Company Name Signature of Bidder tu N - &' W 1 n�� t1 titer Printed or Typed Signature • Subscribed and sworn to before me this LL day of , 201 . NOTARY PUBLIC NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1.ECAi(1)QQ'V4 i C 1 c c(--D-iAs; `7 ()--A5 Name and Address of Public Xgency i 1 be a pK , CA Name and Telephone No. of Project Manager: T,)r t a n C-, i_ e e- rho Q - % a 3 - I l f 1 R 169 1 k a \Ak5 \rJC AeT 9 10 -1 D Contract Amount Type of Work Date Completed 2. a &e t ;> 6 i� V URN Gunter R Name anAddress of Public Agency Va t Iey Ce n - -2 r, CA Name and Telephone No. of Project Manager: FeCn G nd c,, C- (-rl l 1 o '760 -7yq -1Gt 3 Contract Amount Type of Work Date Completed 3. EO►5t2rn % v opr Ci pal , 1J O I 0 Trum Oe -Rd. Name and Address of Public Agency her f i S , CA q z -7o Name and Telephone No. of Project Manager: \t� dk1Cam, nO Che-) Contract Amount Type of Work Date Completed C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX 1K) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a quote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this project. The following shall be amended from the Specifications, page 4 in SECTION 13005: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 2724700. Attention to Mr. John Murphy, ihmurphyna,murcal.com 4- The following shall be deleted from the Specifications, page 15 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for thi roject. This is to acknowledge receipt and review of Addendum Number one, dated January 2 , 011. FALb)0 (Ort-r\tozAL CrxJG-6v,,A V*'-C- Company Name By 0(-11 t, Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO.10 REHABILITATION PROJECT, CC1380 January 28, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The attached new SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be added to the Specifications, within "PART 4 — TECHNICAL SPECIFICATIONS". All references to "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be considered as exposed piping and/or equipment insulation as per Section 15250, para. 2.2. The following shall be added to the Specifications, page viii in the "Table of Sections": 15250 — Insulation for Exposed Piping and Equipment This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number two, dated January 28, 2011. Company Name Date By All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. BID BOND Conforms with The American Institute of Architects, A.I.A. Document No. A-310 KNOW ALL BY THESE PRESENTS, That we, FALCON GENERAL ENGINEERING INC. as Principal, hereinafter called the Principal, and the SURETEC INSURANCE COMPANY of 3033 FIFTH AVENUE, SUITE 300, SAN DIEGO, CA 92103 , a corporation duly organized under the laws of the State of TEXAS , as Surety, hereinafter called the Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH as Obligee, hereinafter called the Obligee, in the sum of TEN PERCENT OF GREATER AMOUNT BID ---------------------------------------- Dollars ($ 10% of Bid Amount ) , for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for WATER WELL NO. 10 REHABILITATION PROJECT, CC NO. 1380 NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then, this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 3RD day of February 2011 Witness FALCON GENERAL ENGINEERI G, INC. (Seai) Principal DALE E. WINTERbVIIT, PRESIDENT Title SURETEC INSURANCE COJAPANY vy '�-A Witness { By v MATTHEVVC, GAYNO Attorney. -in -Fact FRP f ! . - POA #: 510021 SureTec Insurance Company LIMITED POWER OF ATTORNEY Know All Men by These Presents, That SURETEC INSURANCE COMPANY (the "Company"), a corporation duly organized and existing under the laws of the State of Texas, and having its principal office in Houston, Harris County, Texas, does by these presents make, constitute and appoint Helen Maloney, Matthew C. Gaynor, Mark D. latarola. John G. Maloney its true and lawful Attorney -in -fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings or other instruments or contracts of suretyship to include waivers to the conditions of contracts and consents of surety for - Five Million and 00/100 Dollars ($5,000,000.00) and to bind the Company thereby as fully and to the same extent as if such bond were signed by the President, sealed with the corporate seal of the Company and duly attested by its Secretary, hereby ratifying and confirming all that the said Attorney -in -Fact may do in the premises. Said appointment shall continue in force -until 10/3112012 and is made under and by authority of the following resolutions of the Board of Directors of the SureTec Insurance Company: Be it Resolved that the President, any Vice -President, any Assistant Vice -President, any Secretary or any Assistant Secretary shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attomey(s)-in-Fact to represent and act for and on behalf of the Company subject to the following provisions: Attorney -in -Fact may be given full power and authority for and in the name of and of behalf of the Company, to execute, acknowledge and deliver, any and all bonds, recognizances, contracts, agreements or indemnity and other conditional or obligatory undertakings and any and all notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -in -Fact shall be binding upon the Company as if signed by the President and sealed and effected by the Corporate Secretary. Be it Resolved that the signature of any authorized officer and seat of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signature or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached. (Adopted at a meeting held on 2e of April, 1999.) In Witness Whereof, SURETEC INSURANCE COMPANY has caused these presents to be signed by its President, and its corporate seal to be hereto affixed this 3rd day of September, A.D. 2010. AatvFc SURETEC INS E C PANY i1 X 9 . By: u,1 ut ; > � John o Jr., resident State of Texas ss: County of Harris `A •- . •-' �° On this 3rd day of September, A.D. 2010 before me personally came John Knox Jr., to me known, who, being by me duly sworn, did depose and say, that he resides in Houston, Texas, that he is President of SURETEC INSURANCE COMPANY, the company described in and which executed the above instrument; that he knows the seal of said Company; that the seal affixed to said instrument is such corporate seal; that it was so affixed by order of the Board of Directors of said Company; and that he signed his name thereto by like order. WMy JAC9UflYN MALQONADO Notary Public, State of Texasacq ely aldo ado, Notary Public Commission Expires May 18, 2013 Wy comm sion ex s May 18, 2013 I, M. Brent Beaty, Assistant Secretary of SURETEC INSURANCE COMPANY, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Company, which is still in full force and effect; and furthermore, the resolutions of the Board of Directors, set out in the Power of Attorney are in full force and effect. Given under my hand and the seal of said Company at Houston, Texas this 3RD day of FEBRUARY 2011 , A.D. M. Brent Beaty, Assistant Secretary Any instrument issued in excess of the penalty stated above is totally void and without any validity. For verification of the authority of this power you may call (713) 812-0800 any business day between 8:00 am and 6:00 pm CST. w .0. � ■ . we CwwAA� Y A./6\A\®Ye a-w A�Re—�BT %PA`nra✓nr► ruse--rvn■ _ _ IVO.OIiM State of California County of SAN DIEGO On/ ? before me, DEBORAH D . DAVIS, NOTARY PUBLIC personally appeared DALE E. WINTERQUIST who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/ their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of SQL OFJ pEBORAH D. C)AVI the State of California that the foregoing paragraph is COMM. #1cli 737411 true and correct. r > o NOTARY PUBLIC-CALIFORNIA rn Cq< FOAKP My Comm Exp. APRIL COUNTY 2011 N WITNESS my hand and official seal. Signature of Notary OPTIONAL SECTION THIS CERTIFICATE MUST BE ATTACHED TO TITLE OR TYPE OF DOCUMENT THE DOCUMENT DESCRIBED AT RIGHT: Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. ® OPTIONAL SECTION CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL ❑X CORPORATE OFFICER(S) PRESIDENT TITLE(S) ❑ PARTNER(S) ❑ LIMITED [:]GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) ❑ GUARDIAN/CONSERVATOR ❑ OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) NUMBER OF PAGES DATE OF DOCUMENT SIGNER(S) OTHER THAN NAMED ABOVE CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No.5193 State of California County of SAN DIEGO On 02/03/2011 personally appeared before me, DEBORAH D. DAVIS, NOTARY PUBLIC MATTHEW C. GAYNOR who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/ their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. DEBORAH D. DAVIS COMM. #1737411 I certify under PENALTY OF PERJURY under the laws of r= rl NOTARY PUBLIC-CALIFORNIA the State of California that the foregoing paragraph is SAN DIEGO COUNTY CgQF00 My Comm. Exp. APRIL 21, 20t1 true and correct. ® OPTIONAL SECTION CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL CORPORATE OFFICER(S) TITLE(S) PARTNER(S) ❑ LIMITED GENERAL [� ATTORNEY -IN -FACT ❑ TRUSTEE(S) GUARDIAN/CONSERVATOR OTHER: SIGNER IS REPRESENTING: WITNESS my hand and official seal. NAME OF PERSON(S) OR ENTITY(IES) Signature of Notary OPTIONAL SECTION THIS CERTIFICATE MUST BE ATTACHED TO TITLE OR TYPE OF DOCUMENT THE DOCUMENT DESCRIBED AT RIGHT: NUMBER OF PAGES DATE OF DOCUMENT Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. SIGNER(S) OTHER THAN NAMED ABOVE City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 4-Con Engineering, Inc. 2751 Avalon St. Riverside, CA 92509 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CIVIC City Clerk JF:pe Enclosure 9v ► t? 9°" r3pjjh °# Waitakere, New Zealand Y :._8.`P 517, CITY CLERK, CITY OF HUNTINGTON BEACH SECOND FLOOR, CITY HALL 2000 MAIN STREET HUNTINGTON BEACH, CA 92648 "SEALED BID FOR" WATER WELL NO. 10 REHABILITA'TION PROJECT, IN THE CITY OF HUNTINGTON BEACH - DO NOT OPEN WITH REGULAR MAIL SECTION C PROPOSAL for the WATER WELL NO. 10 REIIABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date_ If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary- bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find 8;JJc#4s&jj in the amount of $ 607bai hich said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be)_ Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature as' o C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER TWO For WATER WELL NO. 10 REHABILITATION PROJECT, CCI380 January 28, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The attached new SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be added to the Specifications, within "PART 4 — TECHNICAL SPECIFICATIONS". All references to "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be considered as exposed piping and/or equipment insulation as per Section 15250, para. 2.2. The following shall be added to the Specifications, page viii in the "Table of Sections": 15250 — Insulation for Exposed Piping and Equipment This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number two, dated January 28, 2011. 4f e Company Name RiC�ta f e�. ,�aylOec�lI �dZSep�yb"� Fe6rr�aH�/T o2011 Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -11- City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX K) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a quote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this proiect. The following shall be amended from the Specifications, page 4 in SECTION 13005: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Attention to Mr. John Murphy, ihmurphy(&murcal.com -1- The following shall be deleted from the Specifications, page 15 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, dated January 26, 2011. It - Co Px F—Ka; Keering2ptc. Company Name R char T. C.�be , &J%)1 es;deA f' F-e6radw,( Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- PROJECT DID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 1 1 LS Mobilization $ 000 $h 2 1 LS Temporary sheeting, shoring, and bracing $ ZYO'& off{ $ 2-S—O 3 1 LS Removal temporary sheeting, shoring, bracing $ 2S-D $ 2,SD 4 1 LS Demolition of existing muffler room, blower shed and paving $ '-;S,00O $ 3,';-no 5 1 LS Grading and trenching $ S OoO $ �ap3 6 1 LS Install gas engine, driveline and appurtenant equipment $ LIo,��� 7 1 LS Construct muffler room and install silencers $ There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and S 1 repainting LS Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $ IS, Doo $ 15-4 o'az� Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $ /O,Doco $ P3� 003 11 1 Install 16-inch flowmeter LS $ i 3� $ 130 12 1 Paving LS $ Z- 5 Cs 0 1 $ 'Z .i 1 n or) 13 1 Install catalytic converter and engine exhaust piping LS $ $ There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City nark lust north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BIID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler 14 1 room roof mounted blower LS $ 9,0.00 $ 9' 000 Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation 15 1 of engine control panels to be conducted by MurCal, Inc LS $ t-1 of $ l 16 1 Install fencing LS $ 3 $ 17 1 System testing and commissioning LS $ 03'a i $ J—,T Ocfl is 1 Clean-up & demobilization LS $ 2,yp $5 4� 19 1 Provision and implementation of the SWPPP plan LS $ There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 LS Provision of Traffic Control Plan $ 2-SO $ '25-Z? 21 1 LS Provision of implementing traffic control $ S 00 a 0-zo Total Amount Bid in Figures (Basis of Award): $ 4-7 1, -750 ,, c,o Total Amount Bid in Words: joj K�.c✓Q? o ._ n/t c.� S�Vc.� __ µam 0 Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion of Work Name and Address of Subcontractor State License Number Class DDc�?-s 7 L10o Got `i CA Li -'�-"3C' q `i CA 4 1 is I Z15 1 A.) a t,jv,_9AL CA (� . �i �✓ �"O C �c u b c/ i - G Qa�N L0,VQ, ZA HNV�Ci CNRkS-TkP' ' l"Ray . It % `10 (KJ4LSroY L" r�,[cA l o�nPt CPC 9 9 514 7 ^N50 kR- y 5 fcu� �Y ✓cri ro F-)V '14 ,� CA, 33 5-5 1 .s -957 1 3"Z-7,F 4 EGG, sr- --o.. y . C cpg 3 3 1 1 I\cyOsT.cC r_F Q1(X'Jd' 1-Ixq 3t to ep-SS G� C-P, co y 1 (D S 13 By submission of this proposal, the Bidder certifies: That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing- 2- That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDEN AND SUBMITTED WITH BID State of California ss. County of Orange RicAotr-cj U. Garmwio-*v being first duly sworn, deposes and says that&eF-&k.e­is Pre .5 deny' of q-Con En9ineen nsiXetc. the party making the foregoing bid that the bid is not made in the interest of, or on tfie behalf of, any undisclosed person, partnership, company, association, organization, or corporation', that the bid is genuine and not collusive or sham, that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. H - Con E ngAeer* v�9. c. Name of Bidder 1 re ffBidder c ha rJ T. &^v%&k ;0Aj P�cs:de#%+ ;L7S*1 Aro lon 5+eeef}R%crerside. C9a5OQ Address of Bidder Subscribed and sworn to before me this day of �� , 201/ r­. =_CARRIE D. GARABEDImission # 1873445 U Ya NotaryPublic - California z�San Bernardino County D NOTARY PUBLIC J -., I My rnmm Fwaireq Jan 6, 2014 C-1 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROTECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to he performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: Felryaul'y 7 C-1 q-Ceo En9iheeriA,4.Zne_. Contractor �tcha J Gav►w6e yaK FreSi deKf Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes UY No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract_ Date: a 01 C-1 Ai, C o n E A 1 n eeri v►yr�Ac. Contractor Title / BIDDER'S INF'ORMA'TION BIDDER certifies that the following information is true and correct: I- Coy Bidder Name A7s-t Ayp o n St re e't Business Address Il iyees; de C4 u6-0 City, State Zip (mil ) aa9• �z Telephone Number 7y8'2V/ A.L -1 State Contractor's License No_ and Class a0, Original Date Issued 4prr 1 30, aa1a. Expiration Date The work site was inspected by of our office on i�QirWa►ry 2 (0 201_L. The following are persons, firms, and corporations having a principal interest in this proposal: I C-1 rile" W. The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. N-�o � F+�9iheeNTr�9-�h�. Printed or Typed Signature ,r Subscribed and sworn to before me this � 4ay of r�-'G' , 201 c NOTARY PUBLIC CARRIE D. GARABEDIAN Commission # 1873445 a llotary Public - CaliforniaSan Bernardino County My Comm. Expires Jan 6, 2014 NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1 c1fv oIPI —01 .11('00 4 r ekul o rA TZ Name and ddress of Public Agency Name and Telephone No. of Project Manager: �[( $Q P,t� �i1�y aemM&A0 $� �e 2-0— Masi—, t�A*rRec1oV71 1JV0l PaLp;1;4u/ a (��qA0� ontract Amount Type of Work I Date Completed 2. CT� , 302Oo. �'y, f Canyoyr waw Palms Syr<24 l�2a6.Z Name and Address of Public Agency . oiQo� Name and Telephone No. of Project Manager: LLO PAi lli�V201;A (/iia Ga 'Y3D- 8"3.3 3. Amount Name and Addr&ss of Public I 14LYZIaf .'9AM—Fin Type of W leted Name and Telephone No. of Project Manager: -"—" Con mount C-t C Completed -Con Engineering, Inc. WATER FACILITY PROJECTS PROJECT: Phase 2-A Wastewater Reclamation Facility Expansion DESCRIPTION: Construct wastewater treatment structures and install pumping & Process equipment PROJECT LOCATION: Adelanto, CA COMPLETION DATE: 04/24/09 DOLLAR VALUE: $5,526,414.00 PROJECT OWNER: City of Adelanto OWNER ADDRESS: 11600 Air Expressway, Adelanto, CA 92301 CONTACT & PHONE NO.: Wilson F. So, P.E., City Engineer, (760) 242-2365 PROJECT ARCHITECT: So & Associates Engineers, Inc. ARCHITECT INFORMATION: 16209 Kamana Rd., Apple Valley, CA 92307, Wilson F. So, P.E., (760) 242-2365 PROJECT: Gravity Thickeners Upgrade CP No. 09-02, Project No. 3305500 DESCRIPTION: Modification / Expansion of Water Treatment Facility Gravity Thickeners PROJECT LOCATION: Palm Springs, CA COMPLETION DATE: 12/17/10 DOLLAR VALUE: $304,869.00 PROJECT OWNER: City of Palm Springs OWNER ADDRESS: 3200 E. Tahquitz Canyon Way, Palm Springs, CA 92262 CONTACT & PHONE NO.: Jeff Phillips (Veolia Water) (562) 430-8133, Ext. 202 PROJECT ARCHITECT: Carollo Engineers, P.C. ARCHITECT INFORMATION: 3033 N. 441h St., Suite 101, Phoenix, AZ 85018, (602) 263-9500 PROJECT: SCLA Industrial Wastewater Treatment Facility — Site Development DESCRIPTION: Site Development, Site Utilities, Concrete Process Tank Structures & Lift Station PROJECT LOCATION: Victorville, CA COMPLETION DATE: 07/31/10 DOLLAR VALUE: $4,991,000.00 PROJECT OWNER: City of Victorville OWNER ADDRESS: 14343 Civic Dr., Victorville, CA 92345 CONTACT & PHONE NO.: H. Lauson Kostka, Project Director (Benham Constructors, LLC) (314) 456-9887 PROJECT ARCHITECT: Benham Constructors, LLC ARCHITECT INFORMATION: 622 Emerson Road, Suite 600, St. Louis, MO 63141-6728, (314) 477-8387 PROJECT: Phase 2-B Wastewater Reclamation Facility Head Works DESCRIPTION: Construct wastewater treatment head works structure and install piping & equipment PROJECT LOCATION: Adelanto, CA COMPLETION DATE: 03/11/10 DOLLAR VALUE: $1,192,200.00 PROJECT OWNER: City of Adelanto OWNER ADDRESS: 11600 Air Expressway, Adelanto, CA 92301 CONTACT & PHONE NO.: Wilson F. So, P.E., City Engineer, (760) 242-2365 PROJECT ARCHITECT: So & Associates Engineers, Inc. ARCHITECT INFORMATION: 16209 Kamana Rd., Apple Valley, CA 92307, Wilson F. So, P.E., (760) 242-2365 (951) 222-2241 Fax: General (951) 222-2248 • Estimating (951) 222-2285 2751 Avalon St. Riverside, California 92509 • License No. 748284, A & B PROJECT: Monitoring Well SAR-5 Rehabilitation DESCRIPTION: Well Facility Rehabilitation PROJECT LOCATION: Fountain Valley, CA COMPLETION DATE: 07/07/10 DOLLAR VALUE: $177,771.00 PROJECT OWNER: Orange County Water District OWNER ADDRESS: 18700 Ward St., Fountain Valley, CA 92708 CONTACT & PHONE NO.: Chuck Steinbergs, (714) 378-3230 PROJECT ARCHITECT: Tetra Tech, Inc. ARCHITECT INFORMATION: 162.41 Laguna Canyon Rd., Ste. 200, Irvine, CA 92618, Tom Epperson, (949) 727-7099 PROJECT: DESCRIPTION: PROJECT LOCATION: COMPLETION DATE: DOLLAR VALUE: $ PROJECT OWNER: OWNER ADDRESS: CONTACT & PHONE NO.: PROJECT ARCHITECT: ARCHITECT INFORMATION: (951) 222-2241 • Fax: General (951) 222-2248 • Estimating (951) 222-2285 2751 Avalon St. • Riverside, California 92509 • License No. 748284, A & B -Con Aff Engineering, Inc. WATER FACILITY PROJECTS UNDER CONSTRUCTION PROJECT: 1486 Zone Booster Pump Station (LLWD CFD No. 1) Sycamore Creek Non -Potable Water Project DESCRIPTION: Construct filter and booster pumping system PROJECT LOCATION: Corona, CA DOLLAR VALUE: $299,900.00 PROJECT OWNER: Lee Lake Water District OWNER ADDRESS: 22646 Temescal Canyon Road, Corona, CA 92883 CONTACT & PHONE NO.: Jeff R. Pape, (951) 277-1414 PROJECT ARCHITECT: Hunsaker & Associates ARCHITECT INFORMATION: 3 Hughes, Irvine, CA 92618, John Gass, (949) 583-1010 PROJECT: Green Acres Project Backwash Flow Meter DESCRIPTION: Replace flow meter, piping & electrical PROJECT LOCATION: Fountain Valley, CA DOLLAR VALUE: $46,000.00 PROJECT OWNER: Orange County Water District OWNER ADDRESS: 18700 Ward Street, Fountain Valley, CA 92708 CONTACT & PHONE NO.: Charles Z. Steinbergs, (714) 378-3229 PROJECT ARCHITECT: Bureau Veritas North America, Inc. ARCHITECT INFORMATION: 1565 MacArthur Blvd., Costa Mesa, CA 92626, Joseph 1. Gutierrez, (714) 431-4100 PROJECT: Project No. FE05-41 — P1 Baker -Gisler Siphon Access and Air -Jumper Improvements DESCRIPTION: Pipe liner, concrete access ramps, siphon vault improvements PROJECT LOCATION: Fountain Valley, CA DOLLAR VALUE: $279,950.00 PROJECT OWNER: Orange County Sanitation District OWNER ADDRESS: 10844 Ellis Ave., Fountain Valley, CA 92708 CONTACT & PHONE NO.: Ludwig R. Lapus, (714) 593-7543 PROJECT ARCHITECT: DUDEK ARCHITECT INFORMATION: 605 Third Street, Encinitos, CA 92024, Jerod Coleman, (760) 942-5147 PROJECT: Plant 1 — Facility Upgrades JSCD P.N. 2879 DESCRIPTION: Modify vactor dump station, piping, valves, electrical & security PROJECT LOCATION: Mira Loma, CA DOLLAR VALUE: $1,118,590.00 PROJECT OWNER: Jurupa Community Services District OWNER ADDRESS: 11201 Harrel Street, Mira Loma, CA 91752 CONTACT & PHONE NO.: Keith Backus, (951) 685-7434 PROJECT ARCHITECT: Albert A. Webb Associates ARCHITECT INFORMATION: 3788 McCray Street, Riverside, CA 92506, Shane Bloomfield, (951) 686-1070 (951) 222-2241 • Fax: General (951) 222-2248 • Estimating (951) 222-2285 2751 Avalon St. Riverside, California 92509 • License No. 748284, A & B 2751 Avalon St., Phone (951) 222-2241 4-Con Engineering, Inc. Riverside, CA 92509 -- Project List -- Fax (951) 222-2248 JOB 'PERCENT CONTRACT VALUES DATES No. NAME AGENCY CONTACT 1 PHONE i coMPLETED ORIGINAL FINAL START FINISH PC001 Lincoln Ave. Coyote Creek Bridge City of Cypress Kamren Dadbeh (714) 229-6456 100.00% 175,576 196,755 09/03/98 11/04/98 Retrofit PC002 Edmondson Alley Reconstruction City of Pasadena George Martinez (626) 744-3842 �100.00% _ _ 198,862 211,222410/02/98 12/12/98 PC003 Valencia Park Picnic Area City of Fullerton Eliseo Bravo f (714) 738-5348 100.00% 61,993 63,101 11/02/98 12/15/9_8_ PC004 Alley No. 77 Storm Drain Repair & City of Costa Mesa Tom Banks j (714) 758-5222 100.00% 99,860 106,913 12/07/98 12/21/98 _ PC005 Iowa Street Drain Improvements_ Street Improvements Spruce & City of Riverside Karl Mosby (909) 782-5346 100.00% 55,734 67,201 j 11/30/98 01/22/99 _ PC006 . Blaine (Schedule A) On -Site and Off -Site City of El Monte Kev Tcharkhoutian (626) 580-2056 100.00%F 173,205 209,460 12/07/98 02/01/99 PC007 � Improvements on Ramona Blvd. and Cogswell Rd. San Jose Creek Water Reclamation Plant - East Stoplog Los Angeles County Sanitation District Samuel Espinoza I (323) 283-0881 100.00% 121,850� 122,450 01/12/99 05/20/99 Storage Structure _ _ _ _ PC008 Construction of 43 Curb Ramps at Various Locations Throughout the City of Fountain Valley Bob Kellison (714) 593-4517 100.00%1 30,837 34,527 02/23/99 03/16/99 'i 9 city PC009 Pepper Street San Bernardino County Jerry Ivy (909) 387-2800 100.00% 83,583 _ 84,797 03/15/99 04/12/99 PC010 Del Amo Blvd. Over Compton L.A. County Dept. of Neil Menuwaria (818) 458-4953 100.00% 45,260 41,076 03/25/99 04/07/99 Creek Public Works PC011 Wash Water Recycling Facility City of Ontario Dennis N. Watson (909) 391-2507 100.00% 124,969 134,529 04/05/99 05/21/99 PC012 Mechanical Ventalation and Los Angeles Community Hickman Mechanical, (626) 442-5626 100.00% 66,500 83,558 05/14/99 j 02/11/00 Substation Replacement Phase I College District Inc. (Prime Contractor) & II, L.A.Valley College; Contract I No. 98-1045 PC013 PC014 Ronald Regan & Heritage Park Garvey Park Pool Renovation City of Diamond Bar City of Rosemead _ Bob Rose Ron Bravo (909) 860-3195 (310) 370-6724 100.00% 100.00% 373,378 204,153 386,511 226,157 04/09/99 04/08/99 07/15/99 07/09/99 PC015 City Park Skate Park Facility; City of Corona Jonathan Jones (909) 279-2241 1 100.00% 196,000 223,976 06/08/99 08/20/99 PC016 Project No. 431-8062 Hook -East & West Debris Basin L.A. County Dept. of 1. Primo Candia (626) 447-5362 100.00% 229,195 241,174 07/12/99 09/24/99 PC017 Enlargement in Glendora Franklin Ave. Drain in the City of Public Works L.A. County Dept. of Primo Candia _ (626) 447-5362 100.00% 155,815 186,687 09/20/9_9 12/ 0 9/2 9 PC018 PC019 Rehabilitation of the Nature Trail Two Bridge Seismic Retrofit City of Fountain Valley San Bernardino County Bob Kellison Jerry Ivy (714) 593-4517 (909) 387-2800 100.00% I 100.00% 245,664 112,158 302,805 118,249 08/16/99 08/31/99 03/24/00 10/25/99 PCO20 Indian Ave. Overhead Seismic City of Palm Springs Marcus Fuller (760) 323-5253 1 100.00% 186,462 212,898 10/26/99 01/26/00 PCO21 PCO22 Retrofit Terry Road Storm Drain Construction of Skatepark at City of Laguna Beach City of Irvine Lisa Penna Douglas Davidson _ �949) 497-0711 (949) 724-6675 100.00% 1 100.00% _ 145,208 642,068 _ 180,521 670,761 i 11/29/99 01/03/00 02/08/00_ 06/02/00 Harvard Athletic Park; CIP 8110 City of Pico Rivera Juan Balanay (562) 801-4415 100.00% 82,400 100,077 06/12/0 07/25/00 PCO23 Rio Hondo Park Rehabilitation Site Work File: Project List Page 1 of 9 2751 Avalon St., Phone (951) 222-2241 4-Con Engineering, Inc. Riverside, CA 92509 -- Project List -- Fax (951) 222-2248 JOB I PERCENT CONTRACT VALUES DATES No. NAME AGENCY CONTACT PHONE COMPLETED ORIGINAL FINAL START FINISH PCO24 Jaboneria/Shull Park City of Bell Gardens Bill Pagett (562) 806-7770 100.00% 587,047 620,686 03/06/00 08/22/00 Improvements PCO25 Skate Park at Peterson Park City of Diamond Bar Bob Rose (909) 860860� 100.00% 282,8 44 311,162 04/10/00 07/15/00 PCO26 Heritage Trail Bikeway Project City of Palm Springs Marcus Fuller P.E. (760) 323-5253 100.00% 873,781 879,416 05/22/00 11/09/00 PCO27 Beverly Blvd. Over San Gabriel L.A. County Dept. of Jolene Guerrero (626) 458-3137 100.00% 669,423 707,272 07/07/00 02/07/01 River; Cash Contract 8344 Public Works PCO28 Seismic Retrofit of Brea Blvd. Orange County PF&R Gerald Shubert (714) 567-7795 100,00% 411,210 431,606 10/04/00 03/21/01 Bridges 1 & 2 (Nos. 55C-0123 & Department 55C-0122) Over Brea Creek PCO29 Hermosa Ave. Storm Drain and City of Rancho Jerry Dyer (909) 427-2740 100.00% 61,326 1 62,559 10/16/00 11/17/00 Street Improvements Cucamonga i I PC030 Dale Page Park Improvements, City of Redondo Beach Thomas Baldwin (310) 318-0661 100.00% 151,800 155,657 12/13/00 01/19/01 and Ford and Sneary Parkettes Improvements PC031 Storm Drain Improvements at Holt City of Ontario Fe M. Rama (909) 395-2025 100.00% 151,157 165,579 01/16/01 03/23/01 Blvd. I I_ PC032 Construction of Storm Drain and City of La Habra Eduardo L. Lanuza (562) 905-9700 100.00% 319,134 320,892 01/17/01 10/04/01 Parkway Improvements - Project No. 4-R-00 PC033 Public Works Central Maint. Yard City of Palmdale Mr. Tim Hughes (661) 267-5300 100.00% 469,668 468,316 02/19/01 06/07/01 Perimeter Wall Improvements - Cash Contract No. 415A PC034 Canada Blvd. & Verdugo Rd. L.A. County Dept. of Mr. Ricardo Gordillo (626) 458-3142 100.00%1 247,481 286,570 04/02/01 06/26/01 POC at Glendale Community Public Works College - Project ID No. RDC0011407 PC035 Carmelitos Storm Drain City of Long Beach Mr. Jose M. Rosas (323) 890-7086 100.00% 159,700 159,700 07/06/01 08/15/01 Improvement PC036 McDermott West Park, Village of City of Fontana Mr. Harry Foley (909) 350-7661 100.00% 1,199,768 1,299,783 05/14/01 01/10/02 Heritage, Fontana; Bid No. SB-43- 24/01 PC037 Hurless Barton Park City of Yorba Linda Mr. Steve Campbell (714) 961-7168 100.00% 222,223 226,841 0 /4 08/17/01 PC038 Whites Channel Invert Access L.A. County Dept. of Mr. Sumitha Shival (626) 458-3137 100.00% 251,550 252,530 08/20/01 11/02/01 Ramps & Medea Creek Invert Repair - Project No. FCC0000764 Public Works PC039 Gene Autry Trail Bikeway, CP99- City of Palm Springs Marcus Fuller P.E. (760) 323-5253 1 100.00% 230,604 230,423 08/23/01 09/26/01 14, A4371-- -- — ---- -- ------ ----- --- �— File: Project List Page 2 of 9 4-Con Engineering, Inc. 2751 Avalon St., Riverside, CA 92509 -- Project List -- Phone (951) 222-2241 Fax (951) 222-2248 JOB PERCENT CONTRACT VALUES DATES No. NAME i AGENCY CONTACT PHONE COMPLETED ORIGINAL _i j FINAL START FINISH PC040 State Street Sidewalk and City of San Jacinto Habib Motlagh j (909) 654-7337 100.00%1 413,000 398,676 09/24/01 01/09/02 _ PC041 Miscellaneous Improvements Lemon Park Improvements City of Fullerton +Mike Pickens (7 14) 738-6391 100.00% 816,951 914,847 09/24/01 07/11/02 PC042 Parking Lot / Landscape Corona -Norco Unified Greg Chapman, PCH (909) 792-7397 121,121 144,754 11/08/01�0_3/07/0_2_ Revisions at Anthony Elementary School (Project No. F0002-002) School District Architects, LLP, Project Manager F�06-000/0 PC043 Eastbluff Park Walkway City of Newport Beach Fong Tse (949) 644-3340 100.00% 113,015 113,815 12/1�01/24/02 Reconstruction, Phase II - Contract No. 3334 PC044 — Flintridge Drive Slope City of Glendale Kevin Carter (818) 548-3945 100.00% 85,460 92,405 02/11/02 04/01/02 _ Rehabilitation y PC045 Subsurface Drainage Project At City of Corona Nadeem Syed (909) 279-3515 100.00% 57,180 67,525 01/03/02 01/22/02 Various Locations; Project No. 31- 1001 — PC046 East Rialto Storm Drain San Bernardino County Gary Landry (909) 387-7920 100.00% 240,226 260,210 02/08/02 04/26/02 i Flood Control District _ PC047 The Club at Big Bear Village, Phase 1 B (Site Work); Detention The Bergman Companies Dale Colosi, Project Manager (909) 627-3651 100.00% 249,000 281,262 i 01/24/02 05/02/02 Basin PC048 Rialto Street Improvements City of Rialto Bruce L. Cluff (909) 820-2530 100.00% 32,932 30,356 04/29/02 05/29/02 PC049 Parking Lots Improvement at _ Lake Esinore Unified Grand J. Hamel (909) 296-0776 100.00% 282,107 306,578 04/02/02 06/03/02 Elsinore & Wilomar School District PC050 Azusa Skatepark at Memorial City of Azusa Joe Jacobson (626) 812-5280 100.00% 379,752 _ 429,933 _ 03/18/02 07/12/02 Park PC051 Montebello Skate Park City of Montebello, c/o Mr. Bill Torres, (323) 726-0734 100.00% 232,000 270,512 05/28/02 _ 10/17/02 TELACU Construction TELACU Construction PC052 Independence Skate Park City Downey Mr. Lea Sharp 904-7118 and of (562) 100.00% 981,435 1,062,127 05/20/02 10/25/02 PC053 Tennis Center, Cash Contract No. 623, City of Downey Bridge Repairs; City Project No. City of Palm Springs _ Marcus Fuller P.E. (760) 323-5253 100.00% 97,610 98,636 09/20/02 _ 11/01/02 __ PC054 97-20 ,San Sevaine Creek Bike and City of Fontana �Mr. Harry Foley (909) 350-7661 100.007% 256,214 I 360,389 07/29/02 11/30/02 Recreational Trail, Project No. SB- i PC055 41_02 -- — Montclair Station Improvements; - - — - Cityof Montclair - Morteza Ghandehari --� 714 814-4513 -- 100.00%' -�- 845 060 - -�- 903 879 - 09/30/02 - -- - 03/12/03 Federal Project No. RPSTPL- 5326 (005)-- File: Project List Page 3 of 9 4-Con Engineering, Inc. 2751 Avalon St., Riverside, CA 92509 -- Project List -- Phone (951) 222-2241 Fax (951) 222-2248 JOB I PERCENT! CONTRACT VALUES DATES No. NAME AGENCY CONTACT PHONE COMPLETED ORIGINAL FINAL START FINISH PC056 Carnelian Street Underpass SANBAG - San ,Joe Poirot, PE, (909) 884-8276 100.00% 186,896 200,697 10/30/02 03/10/03 Earthquake Retrofit; Contract No. Bernardino Associated Resident Engineer 03-018 Governments _ PC057 South Gate Skateboard Park; City Project No. 284-ARC City of South Gate IAbdulla Ahmed - Senior Engineer (323) 357-9657 100.00% 326,623 392,057 12/02/02 03/19/03 PC058 Loynes Drive over Los Cerritos L.A. County Dept. of Salaman Khan, (626) 458-4956 100.00% 647,870 653,787 02/24/03 06/04/03 Channel, Et Al. - Project No. Public Works Construction Liaison PC059 RDC0014210 Arcadia Skate Park; Project No. City of Arcadia Mr. Ken Herman, (626) 256-6654 100.00% 540,256 546,076 02/10/03 06/25/03 2255022 Associate Civil tMr. Engineer _ PC060 Construction of Brea Skatepark City of Brea John Hogan (714) 671-4450 100.00%1 174,950 174,950 02/24/03 05/16/03 Soundwall; Project No. 7848 PC061 North Phase - Civic Center City of Palm Desert Mr. Martin Alvarez (760) 346-0611 100.00% 417,501 412,802 _ 04/21/03 07/24/03 Carport Structures; Project No. 2225.00 _ PC062 Artesia -Norwalk Drain Project No. L.A. County Dept. of Mr. Paul Keizer (626) 458-3122 100.00% 284,941 324,842 05/22/03 1I 08/04/03 21 Line "C" Backslope Repair; Public Works Project ID No. FCC0000617 PC063 Bluebird Park Renovation City of Laguna Beach Mr. Mark Trestik P-(949) 497-0300 100.00% 1,005,128 1,148,978 09/15/03 06/23/04 _ F-(949) 497-0771 PC064 Memorial Park Restrooms City of Azusa Mr. Randy Noriega (626) 812-5266 100.00% 318,000 342,743 07/08/03 01/10/04 PC065 Santa Clara River Invert Access L.A. County Dept. of Ms. Stringer (626) 458-5100 100.00% 263,866 347,087 09/24/03 �__12_/03_/03 Ramps at PD T832, PD T771, and Public Works PD T911 - Project No. FCC0000744 PC066 Sierra Avenue Street City of Fontana Anthony Salam, P.E. (909) 350-7632 100.00% 267,025 388,593 08/12/03 01/16/04 (Improvements; Bid No. SB-39-03 P C067 Grace Yokle Middle School y Mountain View School Jeff Miller Sr. Project � 909 476-6005 ( ) 1 0.00° 0 /o 172 07 ,8 182,655 07/07/03 09/22/03 Retaining Wall & Storage Bid.; Project No. 02513A.40 District Manager, WLC Construction Services, Inc. PC068 Widen Northbound Portola, from _ City of Palm Desert Jeremy Vela (762) 346-0611 100.00% 129,950 109,800 _ 08/04/03 09/02/03 San Marino to El Cortez - Block Wall; Project No. 630-99 B; i f Contract No. C20920B- PC069 Valley Drive Storm Drain at City of Villa Park Kamran Saber, P.E. (714) 973-2230 i 100.00%I 88,748 94,866 i 09/29/03T11/05/03 Aubrey Circle Project Manager - (Norris= Repke) -- ----- - —� �— - — - File: Project List Page 4 of 9 2751 Avalon St., Phone (951) 222-2241 4-Con Engineering, Inc. Riverside, CA 92509 -- Project List -- Fax (951) 222-2248 JOB PERCENT CONTRACT VALUES DATES No. NAME AGENCY CONTACT PHONE COMPLETED ORIGINAL FINAL START _ FINISH PC070 Aurantia Park; Project No. 010318, Bid No. 2003-05 City of Highland Terry Vernon, EDGE Development Inc. P-(951) 296-07761 F-(951) 296-0775 100.00% 1,069,700 1,161,023 11/17/03 05/21/04 1 PC071 Irwindale Skate Park City of Irwindale Ron Hallquist L.A. P-(626) 454-5222 100.00% 433,000 428,773 01/19/04 05/07/04 (Subcontract) Engineering, Inc. F-(626) 454-5226 (Prime Contactor) PC072 Blair Skate Park; Plans and City of San Bernardino Robert Sepulveda, (909) 384-5167 100.00% 229,361 229,547 01/12/04 03/12/04 Special Provisions No. 10667 Associate Engineer PC073 WRDM000008 - Thompson Creek _ L.A. County Dept. of Ms. Chandra McLoud (626) 458-4967 100.00% 286,850 288,350 01/05/04 02/16/04 @ Sycamore Cyn Park & Webb Public Works Cyn Site Fire Emergency Protective Meas. PC074 Laguna Niguel Elementary School City of Laguna Niguel Randy Trinkaus, P.M. (949) 362-4337 100.00% 231,000 282,879 06/16/04 12/03/04 Restroom PC075 CSA 9 Phelan Park; Project No. County of San Bernardino, Mr. Greg Bacon (909) 387-6076 100,00% 343,000 356,208 05/10/04 10/08/04 20030001 County Service Area 9 (Phelan) PC076 Centennial Regional Park, Dan City of Santa Ana William Albright, P.E. P-(714) 647-5029 100.00% 1,274,672 1,297,868 05/05/04 03/11/05 Young Youth Soccer Field; F-(714) 647-5058 Project No. 6369 PC077 Construction Of Mesa Linda Park; City of Victorville Celeste Calderon P-(760) 355-5085 100.00% 1,715,024 1,790,522 06/03/04 03/16/05 Project No. CC04-035 F-(760) 269-0045 PC078 Santa Fe Reservoir Spreading L.A. County Dept. of Ali Dana P-(626) 458-3110 100.00% 344,535 442,325 08/30/04 04/13/05 Grounds and Horse Trail Public Works F-(626) 458-2197 Modifications - FCC 0000627 PC079 New Restroom and Utilities; California Department Of Mr. Carl Rose P-(916) 263-0358 100.00% 448,900 458,131 10/22/04 06/03/05 Ramp 6 & 7 Boat Launch Area, Boating And Waterways F-(916) 263-1852 Lake Perris SRA, Riverside PC080 Engineering Laboratory Facility University of California, Omar Nabahani, P.M. (949) 824-7145 100.00% 897,332 _ 919,690 10/05/04 04/06/05 (E.L.F.) Strongwall Irvine Campus Enhancements; Project No. 990081 PC081 Construction of Canada Vista City of Rancho Santa JacqueLynn Niemi, P-(949) 635-1800 100.00% 588,200L 691,933 12/06/04 08/26/05 Skate Park Margarita P.E. F-(949) 635-1667 PC082 Relocatables at Various Sites, Adelanto School District _ _ David Brown, Project P-(760) 955-2446 100.00% 648,258 622,075 10/28/04 04/11/05 Adelanto School District Architect Ext. 12 F-(760) 955-2446 PC083 El Cerrito - Kayne Street Storm Drain; Project No. 2-0-0112 Pelona Vista Park, Phase 3 _ Riverside County Flood Control and Water Conservation District City of Palmdale Dale Anderson, Construction Engineer _ Mr. Tim Hughes P-(951) 955-1345 F-(951) 788-9965 (661) 267-5300 100.00% 100.00% 645,679 I 107,450 737,086 119,027 06/14/05 04/15/05 12/23/05 09/26/05 _ PC084 Stairway - - — - 1- -- File: Project List Page 5 of 9 2751 Avalon St., 4-Con Engineering, Inc. Phone (951) 222-2241 Riverside, CA 92509 -- Project List -- Fax (951) 222-2248 JOB 'i I PERCENT CONTRACT VALUES DATES No. NAME AGENCY CONTACT PHONE ! coMPLETEo ORIGINAL FINAL START FINISH PC085 Amargosa Creek Trailhead and City of Landcaster Mike Slayton, P-(661) 510-4320 100.00% 634,719 653,142 03/10/05 10/22/05 Pathway - Cash Contract No. 628 P.E./P.M. F-(661) 723-5873 PC087 Sycamore Canyon Park Phase II Improvements, Diamond Bar; City of Diamond Bar Ryan Wright (909) 860-3195 100.00% 184,925 202,178 05/16/05 08/29/05 _ C_DBG_Pr_oject No. 600400-99 _ _ _ _ PC088 Civic Center ADA Accessibility City of Huntington Beach Robert A. Martinez (714) 536-5423 -1M00% 233,905 260,555 06/28/05 03/02/06 Improvements; CC-1245 PC089 The Adelanto Marketplace Road City of Adelanto Wilson F. So, P.E. P-(760) 242-2365 100.00% 1,796,669 2,300,235 06/24/05 03/26/06 Improvement; EDA Award No. F-(760) 242-3083 074905428 PC090 Phase II, Flatwork, Landscape, Herperia Recreation and Cal Camara, General P-(760) 244-5488 _ 100.00% 1,415,020 1,453,629 07/19/05 04/07/06 Electrical & Other for 4 Fields @ Park District Manager F-(760) 244-2513 Hesperia Community Park; Bid No. 2005-04-01 PC091 Orange Coast College Baseball Coast Community College Tere Meredith, PM (c/o P-(714) 731-4687 100.00% 1,099,000 1,099,000 07/05/05 ! 03/16/06 jPackage Field Renovations; Bid No. 1888; No. 2 District Douglas E. Barnhart) F-(714) 731-4691 PC092 Riverside County Flood Ed Lotz, Construction P-(951) 955-1266 100.00% 1,293,176 1,567,786 12/05/05 08/11/06 �GarageAddition Control and Water Engineer F-(951) 788-9965 Conservation District _ PC093 Project ID No. WMD0000099 - L.A. County Dept. of Ali Dana P-(626) 458-3110 100.00% 2,281,691 2,415,724 01/10/06 12/05/06 Paseo del Rio at Rio Hondo & Public Works F-(626) 458-2197 San Gabriel Coastal Basin Spreading Grounds _ PC094 Santiago Creek Bike Trail - Bridge City of Orange Alan Truong, Assistant P-(714) 744-5568 100.00% 447,007 475,766 01/23/06 06/20/06 Project from 75' Down Stream to Engineer F-(714) 744-5573 850' Upstream of Glassell Street Overcrossing along Santiago Creek PC095 Park Avenue Sidewalk City of Laguna Beach Bob Koch / Mark P-(949) 497-0300 100.00% 527,454 526,613 04/12/06 07/14/06 Construction Project (from Wendt Trestik F-(949) 497-0771 Terrace to Hidden Valley Canyon Road) PC096 Beach Blvd. Parkway Landscape City of Huntington Beach Dwayne Wentworth _ P-(714) 536-5431 100.00% 999,893 1,042,398 07/17/06 01/29/07 Enhancement Project - Cash F-(714) 374-1573 Contract No. 1229 PC097 Eastern Ave. Drain Channel L.A. County Dept. of I !Ali Dana P-(626) 458-3110 100.00% 1,912,332 1,871,483 06/22/06 03/02/07 Replacement - Project No. 64; Public Works F-(626) 458-2197 Project ID No. FCC0000835 File: Project List Page 6 of 9 4-Con Engineering, Inc. 2751 Avalon St., Riverside, CA 92509 -- Project List -- Phone (951) 222-2241 Fax (951) 222-2248 JOB PERCENT CONTRACT VALUES DATES ORIGINAL FINAL START FINISH No. NAME AGENCY CONTACT PHONE COMPLETED PCO98 Project No. 50745 -Lake Gregory County of San Bernardino, lArcie Cummings P-(909) 387-5227 100.000/6 1,095,000 1,139,471 06/26/06 Regional Park -Playground, lArchitecture and F-(909) 387-5050 104/26/07 Shelter and Skate Park Addition Engineering Department PC099 Puesta Del Sol Elementary Victor Elementary School Wayne Johnson P-(909) 476-6005 100.009/6 578,773 615,749 10/02/06 ��/l/07 School Additions and Site District F-(909) 476-6055 Renovations; Project No. 052800 (David PC100 City Park Restaurant/Restroom City of Lake Elsinore S. Solomon, P-(951) 674-3124 100.00% 496,032— 541,305 12/04/06 06/29/07 PC101 Building Bid No. 06P121, Maintenance Chaffey Community Ext. 242 Mark Logan F-(951) 674-8761 (909) 692-6703 100.00% 329,397 339,462 12/07/06 0510 1007 Drainage College District j PC102 Bid No. 071329, Community Trail - Chaffey Community Mark Logan (909) 652-6703 100.00% 206,020 216,870 12/08/06 l 03/06/07 Phase I College District PC103 New Multipurpose Building - The Victor Elementary School Wayne Johnson P-(909) 476-6005 100.00% 1,224,000 1,293,562 12/06/06 01/03/08 Academy Elementary School. District F-(909) 476-6055 _ PC104 Seville & Tamarind Parks City of Fontana Tom Hallgh (909) 322-4707 100.00% 157,500 157,500 01/18/07 03/20/07 Restroom Replacements _ PC105 Renovation of the Dominquez and City of Indio Mark Hodnick P-(760) 391-4005 100.00% 1,759,500 1,859,225 03/25/07 10/19/07 Indian Terrace Parks F-(760) 391-4008 PC107 The Village Plaza; C.I.P. No. 2007. City of Claremont Kirk Phillips P-(909) 399-5478 100.00% 830,000 846,000 05/21/07 _ 12/04/07 01 F-(909) 399-5327 PC108 Cactus Channel Wall; City Project City of Rialto John Wheatley Ext. P-(909) 820-2525 100.00% 1,242,406 1,364,965 05/14/07 _ 10/05/07 No. 060212; City of Rialto Bid No. 2101 F-(909) 421-7210 07-073 PC109 Community Center/John Swisher Herperia Recreation and Cal Camara, General P-(760) 244-5488 100.00% 919,000 1,211,208 07/23/07 11/25/08 Museum Park District Manager F-(760) 244-2513 PC110 Victor Jr. High School Growth Victor Valley Union High Keith B. Coon, CAL K- P-(909) 795-9169 100.00% 729,000 773,732 07/11/07 10/01/07 Portables 2006 - 2007, Bid School District 12, Construction F-(909) 795-9432 Package 01 General Construction Management PC111 Memorial Park Restroom City of Upland, Public Annette Guthrie P-(909) 291-2962 100.00% 479,825 484,152 10/16/07 03/18/08 Improvements; Project No. 8205 & Works Department F-(909) 795-9432 PC112 9635; Bid No. 2007-13 Jurupa Area Recreation and Park Riverside County Erik Sydow P-(951) 218-8552 100.00% 4,066,000 4,450,545 09/05/07 07/29/08 District- Harvey Field and Economic Development F-(951) 955-6686 _ PC113 Knowles Field Chaffey Community College Agency Chaffey Community _ Mark Logan (909) 652-6703 100.00%� 366,470 _ 371,565 09/18/07 01/03/08 District - Accessibility Upgrades College District and Fire Lane Extension; Contract No. 07P113 - - --------J ---- -- -— - — -- -- ---- -- — L—--- --- File: Project List Page 7 of 9 4-Con Engineering, Inc. 2751 Avalon St., Riverside, CA 92509 -- Project List -- Phone (951) 222-2241 Fax (951) 222-2248 JOB I I 'PERCENT CONTRACT VALUES DATES No. NAME i AGENCY CONTACT PHONE COMPLETED ORIGINAL FINAL START _ FINISH PC114 Rancho Verde Elememtary (Apple Valley Unified Lynette Kachelmeyer I P-(760) 403-4503 100.00% 1,760,000 1,818,602 12/03/07 10/15/08 School Kindergarten Building School District F-(760) 247-8907 Replacement; Bid No. 08-02; NTDS Proj. No. 2005-0130 _ _ _ PC115 Village Park, Restroom & Snack City of Fontana Thomas M. Haugh I P-(909) 322-4707 100.00% 456,000 470,400 03/03/08 08/27/08 Bar Replacement Project, SB-64- F-(909) 350-6755 PW-08; AAI #05-874 PC116 Phase 2-A Wastewater City of Adelanto Wilson F. So, P.E. P-(760) 242-2365 100.00% 5,286,000 5,526,414 03/31/08 04/24/09 (a) Reclamation Facility Expansion _ F-(760) 242-3083 PC116 Phase 2-A Wastewater City of Adelanto Wilson F. So, P.E. P-(760) 242-2365 100.00% 1,192,200 1,276,093 06/18/09 03/11/10 (b) Reclamation Facility Expansion F-(760) 242-3083 (Head Works & Piping) _ PC117 Sandburg Middle School New Glendora Unified School Mr. Robert Jole, PM P-(714) 262-3530 100.00% 1,649,000 1,937,213 06/13/08 01/02/09 Canopy District (Douglas E. Barnhart, F-(626) 963-8459 _ PC118 Gilman Historic Ranch and Riverside County Regional Inc.) Steve Lech, Park P-(951) 955-4318 100.00% 1,032,600 _ 1,080,437 10/20/08 05/04/09 Wagon Museum Site Park & Open Space Planner F-(951) 955-1383 PC119 Improvement Project Garey Avenue under Union District L.A. County Dept. of Robert Eisenhamer i P-(626) 458-3155 100.00% 385,705 409,848 _ _ 12/02/08 04/10/09 Pacific Railroad, ET AL: Project Public Works F-(626) 458-2197 PC120 No. RDC0014375 Sturtevant Debris Basin: Project L.A. County Dept. of Robert Eisenhamer P-(626) 458-3155 100.00% 1,015,005 963,506 10/15/08 1 02/24/09 _ PC121 No. WRDM000025 SCLA Industrial Wastewater Public Works City of Victorville H. Lauson Kostka, F-(626) 458-2197 P-(314) 456-9887 94.86% 4,991,000 06/01/09 Pending Treatment Facility - Site Benham Constructors, Development, Site Utilities, LLC Construction of Process Tank Structures and Lift Station PC122 Monitoring Well SAR-5 Orange County Water Chuck Steinbergs P-(714) 378-3230 100.00% 177,771 195,194 05/03/10 07/07/10 Rehabilitation; Contract No. SAR- District F-(714) 378-3373 2009-1 — _ PC123 Project ID No. RDC0015308 L.A. County Dept. of Colin McCarter P-(626) 458-3116 100.00% 239,500 236,957 12/02/09 01/11/10 Station Fire - Angeles Forest Public Works F-(626) 458-2197 Highway Culvert Improvement _ PC124 Gravity Thickener Feed Veolia Water, City of Palm Jeff Phillips P-(562) 430-8133: 97.97% 304,869 02/22/10 Pending Modification Project; Project No. 3304100 Springs Ext. 202 F- (562)430-8132 _ PC125 Rancho Jurupa Park Splash Pad I Riverside County Regional _ Steve Lech, Park P-(951) 955-4318 100.00% 289,900 309,239 1 06/07/10 07/22/10 Improvement Project: PKARC-0881 Park & Open Space Planner i F-(951) 955-1383 District - ----I -- --�-- - --- --- File: Project List Page 8 of 9 4-Con Engineering, Inc. 2751 Avalon St., Riverside, CA 92509 -- Project List -- Phone (951) 222-2241 Fax (951) 222-2248 JOB PERCENT1 CONTRACT VALUES DATES No. NAME AGENCY CONTACT PHONE ICOMPLETED ORIGINAL FINAL START FINISH PC126 Project ID No. FCC0001186 L.A. County Dept. of Mario Rodriguez P-(626) 458-3147 100.37% 565,091 07/27/10 Pending Bigriar, Mullally, Pinelawn, Starfall Public Works F-(626) 458-2197 Debris Basin Enlargements PC127 Santiago Creek Bike Trial - Tustin City of Orange Paul Tran P-(714) 744-5544 1 47.27% 2,014,702 10/01/10 Pending Street to Collins Avenue, Federal Project No. ESPLE - 5073 (065) F-(714) 744-5573 1 PC128 Santiago Creek Bike Trail North - City of Orange Christian Saxe P-(714) 744-5544 3.59% 2,654,452 01/03/11 Pending Hewes Street from Bond Ave. to F-(714) 744-5573 Villa Park Road (SP-3683) & Villa Park Road from Hewes Street to Santiago Blvd. (SP-3741) (Bid No. 090-22) PC129 1486 Zone Booster Station Lee Lake Water District Jeff R. Pape P-(951) 277-1414 299,900 02/21/11 Pending (LLWD CFD No. 1) Sycamore F-(951) 277-1419 Creek Non -Potable Water Project PC130 Green Acres Project Backwash Orange County Water Charles Z. Steinbergs (714) 378-3229 46,000 02/14/11 Pending Flow Meter District PC131 Project No. FE05-41 — P1 Baker- Orange County Sanitation Ludwig R. Lapus (714) 593-7543 279,950 01/25/11 Pending Gisler Siphon Access and Air- District Jumper Improvements PC132 Plant 1 — Facility Upgrades JSCD Jurupa Community Keith Backus (951) 685-7434 1,118,590 01/10/11 Pending P.N. 2879 Services District j I _ File: Project List Page 9 of 9 GREAT AMERICAN INSURANCE COMPANY ©HI© Bond No. N/A Approved by The Amclicun Institute of Architects, A.I.A. Document No. A310 February, 1970 Edition KNOW ALL MEN BY THESE PRESENTS: that we 4 - C011 Ent jiDeering, Inc. as Principal, hereinafter called Principal, and GREAT AMERICAN INSURANCE CQMPANY, a corporation duly organized under the laws ofthe State of 0hiu, with Administrative OCflees at 580 Walnut Street, Cincinnati, Ohio 45202, as Surety, hereinafter called the Surety, are hold firmly bound unto City of Huntington Beach as Obligee, hereinafter called Obliac% in the sum of Tian pagg tat of A== bid Dollars if 10 % 1 For the payment afwhieh sum well and truly to be made, and the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, Jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid(ot Water Well No. 10 Rehabilitation Project NOW, THEREFORE, if the Ohligeo shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance ot'such Contract and for the pronil't payment of labor and material litrishod in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, iftho Principal shall pay to the Obligee the difference not to exceed the penalty hereof tpetween the amount specified in said bid and such larger amount for which the Obligeo may in good faith contract with another Patty to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and scaled this 3rd day of February 2011 In the presence of: 4-Con En-ineeri Inc. tpal) (Se41) By: itic • �- a ian.l es; 2n.�-' GREAT AMERICAN INSURANCE COMPANY___(Scalj- (Surety) ---- — R Cyntwia XO (AtW ey-in•l act) Bid Bond 179630a CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT State of California SS. County of San Bernardino On February 3, 2011 before me, Pamela McCarthy, Notary Public Name and Title of Officer (e.g., "Jane Doe, Notary Public") personally appeared Cynthia J. Young Name(,}) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, PAMELA MCCARTHY and that by her signature on the instrument the person, or the entity upon behalf of which the person CJMM. # i 885009 acted, executed the instrument. NOTARY PUBLIC - CALIFORNIA T °C SAN BERN.4RDIN�,2014 My Comm. Expires I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official sea]. Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: a Individual O Corporate Officer Title i7 Partner -- O Limited 0 General 0 Attorney -in -Fact O Trustee O Guardian or Conservator Other: Signer is Representing: IA ALL-PURPOSE ACKNOWLEDGMENT State of California ss. County of San Bernardino On February 7, 2011 before me, _Carrie D. Garabedian, Notary Public , —Date V — 'Name awn TiiTe of umce (e.g., jane1>oe -iary Pu6iic )-� personally appeared Richard J. Garabedian , ame s of SWUM who proved to me on the basis of satisfactory evidence to be the person(e) whose name(e) isAwe subscribed to the within instrument and acknowledged to me that heisheAhey executed the same in hiss authorized capacity(ie ), and that by hisA *W#iei#; signature(s) on the instrument the person(), or the entity upon behalf of which the person(s) acted, executed the instrument. CABBIE D. GARABE.144 1 certify under PENALTY OF PERJURY under the laws of Commission # 1873445 Z fy Notary Public - California j the State of California that the foregoing paragraph is true z San Bernardino County and correct. My Comm. Expires Jan 6, 2014 WITNESS my hand and official seal. 1� � ure ary ublic OPTIONAL a Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Bid Bond Document Date: Signer(s) Other Than Named Above: Cynthia Young Capacity(ies) Claimed by Signer(s) Signer's Name: Richard J. Garabedian I Individual Corporate Officer Title(s): President Partner — ❑ Limited ❑ General Attomey-in-Fact Trustee Guardian or Conservator Other: Signer is Representing: 4-Con Engineering, Inc. Number of Pages: 1 Signer's Name: N/A Individual Corporate Officer Title(s): Partner — ❑ Limited ❑ General Attomey-in-Fact Trustee Guardian or Conservator Other. Signer is Representing: GREAT AMERICAN INSURANCE COMPANY® Administrative Office: 580 WALNUT STREET* CINCINNATI, OHIO 45202 • 513-369-5000 • FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than FOUR No. 014652 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and existing under and by virtue of the laws of the State of Ohio, does hereby nominate, constitute and appoint the person or persons named below, each individually if more than one is named, its true and lawful attorney -in -fact, for it and in its name, place and stead to execute on behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name JAY P. FREEMAN PAMELA McCARTHY CYNTHIA J. YOUNG LAURIE B. DRUCK Address ALL OF SAN BERNARDINO, CALIFORNIA Limit of Power ALL $75,000,000.00 This Power of Attorney revokes all previous powers issued in behalf of the attomey(s)-in-fact named above. REoF-thee—GREAT-AmERiCAN-fNsuRp,-NC); rOMP71IIY- a} cause ese presen sign and-atteesteed yliy its appropna2e -- officers and its corporate seal hereunto affixed this 27th day of, JULY, 2010. Attest s, - GREAT AMERICAN�II.SURANCE COMPANY yH ryUg4 ){ F IA �I A.c.ciuuet Secreterrc Dnvisinncd Senior Vice Prenrlent STATE OF OHIO, COUNTY OF HAMILTON - ss: DAVID C. KITCr-IIN (513-41214602) On this 27u' day of JULY, 2010, before me personally appeared DAVID C. KITCHIN, to me known, being duly sworn, deposes and says that he resides in Cincinnati, Ohio, that he is a Divisional Senior Vice President of the Bond Division of Great American Insurance Company, the Company described in and which executed the above instrument; that he knows the seal of the said Company; that the seal affixed to the said instrument is such corporate seal; that it was so affixed by authority of his office under the By -Laws of said Company, and that he signed his name thereto by like authority. KAREN L. BROSHEIM 00., NOTARY PUBLIC, STATE OF 01*0 MY COMMISSION EXPIRES 02-20-11 This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated June 9, 2008. RESOLVED: That the Divisional President, the several Divisional Senior Vice Presidents, Divisional Vice Presidents and Divisional Assistant Vice Presidents, or any one of them, be and hereby is authorized, from time to time, to appoint one or more Attorneys -in -Fact to execute on behalf of the Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof to prescribe their respective duties and the respective limits of their authority, and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and the signature of any of the aforesaid ofjicers and any Secretary or Assistant Secretary of the Company may be affixed by facsimile to any power of attorney or certificate of either given for the execution of any bond, undertaking, contract of suretyship, or other written obligation in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with the same force and effect as though manually affixed. CERTIFICATION 1, STEPHEN C. BERAHA, Assistant Secretary of Great American Insurance Company, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of June 9, 2008 have not been revoked and are now in full force and effect. Signed and sealed this lz:5 day of a�,��y :« j -W { �� rl i.Vum Se<retur_i S1029Y (10t08) City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 Olsson Construction, Inc. 326 W. Katella Ave., Ste. 4-J Orange, CA 92867 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, � 0)"1191490) Joan L. Flynn, CIVIC City Clerk JF:pe Enclosure 98iMWaM9%0nt,/"r0b6"A0* Waitakere, New Zealand SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find 130"A in the amount of $ which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda No.' Date Received, Bidder's Si nature C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 1 1 Mobilization LS $ $ 2 1 Temporary sheeting, shoring, and bracing LS $ $ 3 1 Removal temporary sheeting, shoring, bracing LS $)O� $ _ 4 1 Demolition of existing muffler room, blower shed and paving LS $1� DW $Coo 5 1 Grading and trenching LS O $(0co 6 1 Install gas engine, driveline and appurtenant equipment LS 7 1 Construct muffler room and install silencers LS ��,// � $J $� There will be a mandatory Job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park Just north of Sun View Elementary School. From there, every attendee of the mandatory Job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting LS n Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $ $_�'Ji lt1� Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $ate $ 11 1 Install 16-inch flowmeter LS $.1.IL $ 51O 12 1 Paving LS $ $ 13 1 Install catalytic converter and engine exhaust piping LS $ $�Vtt There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended - No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler 14 1 room roof mounted blower LS $ $'1 ` Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation 15 1 of engine control panels to be conducted by MurCal, Inc LS swjO $ (DEi UYD 16 1 Install fencing LS $ $ 17 1 LS System testing and commissioning $ $ 18 1 Clean-up & demobilization LS $ $_ 19 1 Provision and implementation of the SWPPP plan LS $71iM-0 $1 CM_ There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park Just north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 Provision of Traffic Control Plan LS $_'' }�� $T� 21 1 Provision of implementing traffic control Total Amount Bid in Figures Basis of Award): $ 45M.DDO Total Amount Bid in Words: ft uyz �71.L Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. from there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. .Portion- ,of Work - - 'Name. and Address of Subcontractor '__ ._ .'_Number ;.StateLicense -_ Class t16 lgGll r .So�•l GO N -C -t �.1 S 1 "' C-10 By submission of this proposal, the Bidder certifies: That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange NA&yy\ 0166wl , being first duly sworn, deposes and says that he or she is -Vrtz t dla-n A- of qo r Q. DWy, Q)rAweXi an fuw the party making the foregoing bid that the bid is not made in the interest of, or on the belialf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any - other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Name of Bidder Bidder govuA OlS!�nyl cam. ICE., a,�. 5L4?'/4' -J- Address of Bidder Subscribed and sworn to before me this day of , 201L ---- MAGGIE STEWART Commission #E 1857991 i Notary Public - California D Orange County My Comm. Expires Jul 16, 2013 NOTARY PUBLIC �c�QL�, S 4,A,0 � NOTARY SEAL C-1 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: Z — �% — 11 Contractor C-1 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: Z ( -7 ( It Contractor C-1 DIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name 6 z co 0, K+s, ad- me.. `;6(� 4 - 3- Business Address e3A,96 City, v State Zip (J)�) allo-a40tto Telephone Number State Contractor's License No. and Class Original Date Issued Tj2DI I Expiration Date The work site was inspected byShX. N, N"� of our office on !ZU12011 L. The following are persons, firms, and corporations having a principal interest in this proposal: I 1 1 l i 1 ' lot 1111 I ¢L J l C-1 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. -Na MAA A, . O l� C6ytis-f -rvc l ne, Company Name Printed or Typed Subscribed and sworn to before me this - day of VOR6. , 2011. MAGGIE 5TEWART Commission #t 1857991 Notary Public - California a Orange County Mg Comm. Expires Jul 16, 2013 NOTARY PUBLIC M o-p NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: Name and Address of Public Agency 2. 0 Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Date Completed Date Completed C-1 Job History Log Projects Over $100,000 Original Final Start Job# Project Name Project Location Owner I Contractor Engineer Description of Work Contr. $ Corl $ Date End Date 1099 RP-5 Gas Storage 6075 "C" Kimball Ave Inland Empire Utilities Agency Parsons 4,389,300 5,969,683 Oct-07 Oct-08 1 Chino CA 91710 6075 "B" Kimball Pasadena Ca. Furnish and install ping -Storage & 240 cal days 710 NOC Chino, CA 91710 Voytek Muszynski Compressor systems, associated piping a NTP- 10/31/06 106 Cos for $1,580,383.49 909 993-1600 related site work due to numerous eng. design mods. 1101 Well Site Crawford 5 Elsinore Valley Municipal WD MWH Americas 3,695,766 3,935,646 1 Jun-07 Aug-09 Wellfield Construction Parcel #371270005 31315 Chaney St 301 N. Lake Ave Suite 600 construction of a new dual propose wen facilhy 270-sa6days 413 cal days - Back Basin Groundwater Well Site A-2 Lake Elsinore CA 92531 Pasadena CA 91101 ng, control system, including piping' 326 cal s days 4 COS = 239,880 Storage Chloramination Disinf. System & site NOA: 6/01/07 Parcel#371270019 951/674-3146 David Bouck 626/796-9141 improvements NTP: 6/19/07 1102 Midway City Sanitary District PRP Engineering Rehabilitation of four existing pump stations, 4,776,002 4,842,406 Jul-07 Jun-09 Westminster, Hammon, 4locations all 14451 Cedarwood St Mike Palzes including replacement of pumps, motors, . 450 wkg days Willow & Brookhurst in Westminster CA Westminster Ca 92683 714/ 374-0048 MCC/Control Panel, new SCADA system, new wet wells, valve vaults, new valves, meters, piping and NOA: 06/20/07 Pump Stations Facility emergency back up power generators e Improvements Ken Robbins 714/893-3553 NTP 07/27/07 1103 Cactus Ave Well Site Crawford 5 Eastern Municipal Water District Field Engineering Construction of a potable water pumping facility 9,598,410 9,750,745 Jul-07 Aug-09 Pump Station Parcel #371270005 2270 Trumble Road - Christy Hagen including steel framed, precast concrete paneled 430 cal days Well Site A-2 Perris Ca 92570 951/928-3777 ext. 4341 buinal turbine pumps, surge tanks, piping, additional mechanical equipment and related site NOA: 6/27/07 Parcel #371270019 951/928-3777 work NTP: 07/05/07 1104 Rehab. of College 3190 College Ave OCSD Alberto Acevedo, PM - 5,792,000 6,120,332 Feb-08 Feb-10 Ave. Pump Station Costa Mesa CA 10844 Ellis Ave 714/593-7846 Structural and mechanical modifications to an epslmg pump station. construction of concrete 540 cal days 992 cal days Fountain Valley, CA 92708 stairwell and piping vault, Replacement of a acting NOA 11/28/07 4 Cos = 328,332 wage pumps, Aping associated electrical work and site improvements. NTP 2/l/08 1105 Creek WTP... Mission Viejo CA Santa Margarita Water District Bart Lantz 2,341,000 2,466,736 Apr-08 Oct-09 10so Finisterra PS Mission Viejo CA 2611 Antonio Parkway Suite A - 949/459-6504 Modifications to the electrical and instrumentation along with associated concrete and site work to the 1 CO=125,736 Trabuco Pump/ Las Flores CA 92683 Trabuco Pump a Lift station s Finiaterra Pump NOA: 12/19/07 Lift Station Rancho Santa Mang. CA station, Also includes electrical, piping and sitework mods. To oso Creek WRP. NTP: 01/30/08 1106 Terminal Island TP 445 Ferry St. City of LA, Dept of Public Works Sinh Pham, Constr. Mgr. 3,130,000 2,779,882 May -OS May-10 Centrifuge Improvements San Pedro CA 90731 200 N. Spring St Rm 355, City Hall 3101732-4726 Structural, mechanical an.d electrical Modifications w me c tdfuge facility. PrPecf includes demolition 553 cal. days Cos ($330,118) Project Los Angeles Ca 90012 of the existing facility and installation of 3 new centrifuges and 3 new screw conveyors includingall NOA: 4/2/08 mechanical appurtenances and associated electric. work. Modify centrifuge No. 4 ana associatecd electrical a controls NTP: 05/01/08 1107 Rehabilitation of Westside OCSD Chris Maher, Contracts 5,885,000 6,487,763 Aug-08 Dec-10 Pump Station 3112 Yellow Tail 10844 Ellis Ave (714) 593-7582 Structural and mechanical modifications to an 600 cal days Contract No. 3-52 Los Alamitos Ca Fountain Valley, CA 92708 e.isting pump station. construction of concrete NOA: 06/25/08 stairwell and piping vault. Replacement ofexisting wage pumps, piping associated electrical work and site Improvements. NTP: 08/26/08 1108 RP-2 Solids Handling Inland Empire Utilities Agency - Nasrin Maleki, S.E. 2,943,000 3,199,772 Sept. 08 Oct-10 Facility Improvements Chino CA 6075 "B" Kimball 909/993-1696conveyors; Demolition of old and installation of new screvr retroau;ng the mechanical mechanism of 310 cal days 31 Cos= $256,772 2 Gravity Thickeners: installation of a chemical Phase 1 Chino, CA 91710 containment structure and associated tanks, NOA: 07/17/08 pumps,and piping. Also construction of new SARI 909 993-1600 dump site and associated subareas, piping for IFUA NTP: 09/10/08 RAProject Logs\project logs\_Project History Log -over $100,000 - last 10 yrs-2011.xls City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX K) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a quote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this proiect. The following shall be amended from the Specifications, page 4 in SECTION 13005: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Attention to Mr. John Murphy, ihmurphy(dinurcal.com -1- The following shall be deleted from the Specifications,. page 15 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, dated January 26, 2011. 11 Company Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER TWO For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 28, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The attached new SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be added to the Specifications, within "PART 4 - TECHNICAL SPECIFICATIONS". All references to "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be considered as exposed piping and/or equipment insulation as per Section 15250, para. 2.2. The following shall be added to the Specifications, page viii in the "Table of Sections": 15250 — Insulation for Exposed Piping and Equipment This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number two, dated January 28, 2011. 0 1,%M On stn)a-m Company Name �,I,7'I 11 Dates Z - 055un By All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -1- �- CERTIFICATE OF LIABILITY INSURANCEDATE (MMIDDIYYYY) 12/30/ 010 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Garrett/hosier/Griffith/Sistrunk Iris. Services 12 Truman Irvine, CA 92620 www.garraf-mosier.com OB84519 -CONTACT NAME: - PHONE o 949 559-6700 F AIC No): 949 559 fi703 E-MAIL ADDRESS: INSURE S AFFORDING COVERAGE " "C # INSURERA : Travelers Propegy CasuaLty Co. of America INSURED Norman A. Olsson Construction, Inc. 326 West Katella Ave, #4J Orange CA 92867 INSURERB: Travelers IndemnilyCompan of Connecticut INSURERC: RSUI Indemnit Company - INSURER D INSURER E : INSURER F : - - r`nvRRAPri=c CFRTIi:ICATE N1IfMRER- 01474.4n REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR OF INSURANCE ADDLSUBRTYPE INSR WVD POLICY NUMBER MWDDN'rYY PMf DN-YYY OLICY EXP LIMITS A - GENERAL LIABILITY f COMMERCIAL GENERAL LIABILITY - CLAIMS -MADE a OCCUR y BFPD: Contract DTE-CO-8265L609-TIC-11 $5,000 Prop Damage Bed, per Occurrence - 1/1/2011 1/1/2012 - EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED PREMISES (Ea occurrence) $ 300,000 INED EXP (Arty one Per50n) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 ,/I Llab: XCU: IQ,P GENERAL AGGREGATE $ 2,000,000 GEN'LAGGREGATE LIMIT APPL{ESPER: POLICY y PE Q 171 LOG PRODUCTS - COMP/OP AGG $ 2,000,000 $ B AUTOMOBILE LIABILITY _ ANYAUTO _ ALLOWNED SCHEDULED AUTOS AUTOS HIRED AUTOS NON -OWNED AUTOS DT-810-8265L609-TCT-11 - 1/112011 1/1/2012 (Ea aaid22!) INGLELkMCr $ 1 ODO000 . BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ ?eOraxitleMDAMAGE $ A UMBRELLA LIAB EXCESS LIAB ✓ OCCUR CLAIMS -MADE DTSM-CUP8265L609-TIL UIL: GL, Auto, EL 1/1/2011 111/2012 EACHOCCURRENCE $ 1,000,000 AGGREGATE $ 1,000,000 DED f RETENTION $ $ $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOPJPARTNERIEXEcu nVE Y! N OFFICERNEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below NIA DTJ-UB-8265L609-11 - 1/1/2011 1/1/2012 wcsTATu- oFH- TORY LIMITS ER EL EACH ACCIDENT $ 1 000 000 E.L. DISEASE -EA EMPLOYEE $ 1 00 OJ.i.. E.L. DISEASE- POLICY LIMIT $ 1,000,000 C Excess Liability Follow Form NHA227363 UIL: Umbrella r7T/2011 1/1/2012 $4,000,000 Occ/Aggregate DESCRIPTION OF OPERATIONS I LOCATIONS r VEHICLES (Attach ACORD 101, Additional Remarks Schedule, if more space is required) Cert holder is included as additional insured under general liability with respect work performed by or on behalf of named insured per attached form CGD246 08 05, including primary wording, subject to policy terms and conditions. Waiver of subrogation applies to the general liability per attached CG D316 07 04. Auto additional insured applies per attached CAT437 0808. Per project aggregate applies per attached CG 02 11' 01 04. Waiver of subrogation applies to the work comp per attached WC 99 03 76 (00). CERTIFICATE HOLDER CANCELLATION Sample - For Bidding Purposes Only SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE - Calvin Sistrunk U 19t3S-ZU1 U ALUKL) L;VKYUKA I Ivry, Au ngnrs reseF VCu. ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD CERT NO.: 9147430 Blanca Rogue 12/30/2010 10:55:34 AM page 1 of 8 Norman A. Olsson Construction, Inc. COMMERCIAL GENERAL LIABILITY DTE-CO-82651-609-TUIC100 Prop Damage THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART 1. WHO IS AN INSURED — (Section 11) is amended to include any person or organization that you agree in a "written contract requiring insurance" to include as an additional insured on this Cover- age Part, but: a) Only with respect to liability for "bodily injury", "property damage," or "personal injury"; and b) If, and only to the extent that, the injury or damage is caused by acts or omissions of you or your subcontractor in the performance of "your work" to which the "written contract requiring insurance" applies. The person or organization does not qualify as an additional insured with respect to the independent acts or omissions of such person or organization. 2. The insurance provided to the additional insured by this endorsement is limited as follows: a) In the event that the Limits of Insurance of this Coverage Part shown in the Declarations exceed the limits of liability required by the "written contract requiring insurance", the in- surance provided to the additional insured shall be limited to the limits of liability re- quired by that "written contract requiring in- surance". This endorsement shall not in- crease the limits of insurance described in Section III — Limits Of Insurance. b) The insurance provided to the additional in- sured does not apply to "bodily injury", "prop- erty damage" or "personal injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or sur- veying services, including: i. The preparing, approving, or failing to prepare or approve, maps, shop draw- ings, opinions, reports, surveys, field or- ders or change orders, or the preparing, approving, or failing to prepare or ap- prove, drawings and specifications; and ii. Supervisory, inspection, architectural or engineering activities. c) The insurance provided to the additional in- sured does not apply to "bodily injury" or "property damage" caused by "your work" and included in the "products -completed op- erations hazard" unless the "written contract requiring insurance" specifically requires you to provide such coverage for that additional insured, and then the insurance provided to the additional insured applies only to such "bodily injury" or "property damage" that oc- curs before the end of the period of time for which the "written contract requiring insur- ance" requires you to provide such coverage or the end of the policy period, whichever is earlier. 3. The insurance provided to the additional insured by this endorsement is excess over any valid and collectible "other insurance", whether primary, excess, contingent or on any other basis, that is available to the additional insured for a loss we cover under this endorsement. However, if the "written contract requiring insurance" specifically requires that this insurance apply on a primary basis or a primary and non-contributory basis, this insurance is primary to "other insurance" available to the additional insured which covers that person or organization as a named insured for such loss, and we will not share with that "other insurance". But the insurance provided to the additional insured by this endorsement still is excess over any valid and collectible "other in- surance", whether primary, excess, contingent or on any other basis, that is available to the addi- tional insured when that person or organization is an additional insured under such "other insur- ance". . 4. As a condition of coverage provided to the additional insured by this endorsement: a) The additional insured must give us written notice as soon as practicable of an "occur- rence" or an offense which may result in a claim. To the extent possible, such notice should include: CG D2 46 08 05 © 2005 The St. Paul Travelers Companies, Inc. CERT NO.: 9147430 Blanca Roque 12/30/2010 10:55:34 Ant Page 2 of 8 Page 1 of 2 COMMERCIAL GENERAL LIABILITY I. How, when _and where the "occurrence" or offense took place; ii. The names and addresses of any injured persons and witnesses; and iiii. The nature and location of any injury or damage arising out of the "occurrence" or offense. b) If a claim is made or "suit" is brought against the additional insured, the additional insured must: f. Immediately record the specifics of the claim or "suit" and the date received; and ill. Notify us'as soon as practicable. The additional insured must see to it that we receive written notice of the claim or "suit" as soon as practicable. cy The additional insured must immediately send us copies of all legal papers received in connection with the claim or "suit", cooperate with us in the investigation or settlement of the claim or defense against the "suit", and otherwise comply with all policy conditions. dj The additional insured must tender the de- fense and indemnity of any claim or "suit" to any provider of "other insurance" which would cover the additional insured for a loss we cover under this endorsement. However, this condition does not affect whether the insur- ance provided to the additional insured by this endorsement is primary to "other insur- ance" available to the additional insured which covers that person or organization as a named insured as described in paragraph 3. above. 5. The following definition is added to SECTION V. — DEFINITIONS: "Written contract requiring insurance" means that part of any written contract or agreement under which you are- required to include a person or organization as an additional in- sured on this Coverage Part, provided that the "bodily injury" and "property damage" oc- curs and the "personal injury" is caused by an offense committed: a. After the signing and execution of the contract or agreement by you; b. While that part of the contract or agreement is in effect; and c. Before the end of the policy period. Page 2 of 2 © 2005 The St. Paul Travelers Companies, Inc. CG D2 46 08 05 CENT NO.: 9147430 Blanca Roque 12/30/2010 10:55:34 AM Page 3 of 8 DT-810-8265L609-TCT-11 Norman A. Olsson Construction, Inc. COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modi- fled by the endorsement. GENERAL DESCRIPTION OF COVERAGE — This endorsement hroadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to the Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general cover- age description only. Limitations and exclusions may apply to these coverages. Read all the provisions of this en- dorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered. A. BROAD FORM NAMED INSURED B. BLANKET ADDITIONAL INSURED C. EMPLOYEE HIRED AUTO D. EMPLOYEES AS INSURED E.. SUPPLEMENTARY PAYMENTS — INCREASED LIMITS F. HIRED AUTO — LIMITED WORLDVADE COVERAGE— INDEMNITY BASIS G. WAIVER OF DEDUCTIBLE — GLASS PROVISIONS A. BROAD FORM NAMED INSURED The following is added to Paragraph A.1., Who Is An Insured, of SECTION 11 — LIABILITY COV- ERAGE: Any organization you newly acquire or form dur- ing the policy period over which you maintain 50% or more ownership interest and that is not separately insured for Business Auto Coverage. Coverage under this provision is afforded only un- til the .180th day after you acquire or form the or- ganization or the end of the policy period, which- ever is earlier. B. BLANKET ADDITIONAL INSURED The following is added to Paragraph C. in A.1., Who Is An Insured, of SECTION it — LIABILITY COVERAGE: Any person or organization who is required under a written contract or agreement between you and that person or organization, that is signed and H. HIRED AUTO PHYSICAL DAMAGE — LOSS OF USE —INCREASED LIMIT 1. PHYSICAL DAMAGE — TRANSPORTATION EXPENSES — INCREASED LIMIT J. PERSONAL EFFECTS K. AIRBAGS L. NOTICE AND KNOWLEDGE OF ACCIDENT OR LOSS M. BLANKET WAIVER OF SUBROGATION N. UNINTENTIONAL ERRORS OR OMISSIONS executed by you before ' the "bodily injury" or "property damage" occurs and that is in effect during the policy period, to be named as an addi- tional insured is an "insured" for Liability Cover- age, but only for damages to which this insurance applies and only to the extent that person or or- ganization qualifies as an "insured" under the Who Is An Insured provision contained in Section 11. C. EMPLOYEE HIRED AUTO 1. The following is added to Paragraph A.1., Who Is An Insured, of SECTION 11 — LI- ABILITY COVERAGE An "employee" of yours is an "insured" while operating an "auto" hired or rented under a contract or agreement in that "employee's" name, with your permission, while performing duties related to the: conduct of your busi- ness. CA T3 53 03 10 ® 2010The Travelers Indemnity Company. Includes copyrighted matedal of Insurance Services office, Inc. with Its pennisslon. Page 1 of 4 CERT NO.: 9147430 Blanca Roque I2/30/2010 20.55:34 AN Page a of 8 DTE-CO-8265L609-TI L-11 Norman A. Olsson Construction, Inc. COMMERCIAL GENERAL LIABILITY 2. This insurance does not apply to damage to premises while rented to you, or temporarily occupied by you with permission of the owner, caused by: a. Rupture, bursting, or operation of pres sure relief devices; b. Rupture or bursting due to expansion. or swelling of the contents of any building or structure, caused by or resulting from water; c. Explosion of steam boilers, steam pipes, steam engines, or steam turbines. 3. Paragraph 6. of LIMITS OF INSURANCE (Section 111) is deleted and replaced by the following: Subject to 5. above, the Damage To Prem- ises Rented To You Limit is the most we will pay under COVERAGE A. for the sum of all damages because of "property damage" to anyone premises while rented to you, or temporarily occupied by you with permission of the owner, caused by: fire; explosion; light- ning; smoke resulting from such fire, explo- sion; or lightning; or water. The Damage To Premises Rented To You Limit will apply to all "property damage" proximately caused by the same. "occurrence", whether such damage results from: fire; explosion-, lightning; smoke resulting from such fire, explosion, or lightning; or water; or any combination of any of these causes_ The Damage To Premises Rented To You Limit will be the higher of: a. $300,000; or b. The amount shown on the Declarations for Damage To Premises Rented To You Limit. 4. Paragraph a. of the definition of "insured con- tract" (DEFINITIONS - Section V) is deleted and replaced by the following. a. A contract for a lease of premises. How ever, that portion of the contract for a lease of premises that indemnifies any person or organization for damage to premises while rented to you,, or tempo- rarily occupied by you with permission of the owner, caused by: fire; explosion; lightning; smoke resulting from such fire, explosion, or lightning; or water, is not an "insured contract"; 5. This Provision B. does not apply if coverage for Damage To Premises Rented To You of COVERAGE A. BODILY INJURY AND PROPERTY DAMAGE LIABILITY (Section 1- Coverages) is excluded by endorsement. C. BLANKET WAIVER OF SUBROGATION We waive any right of recovery , we may have against any person or organization because of payments we make for injury or damage arising out of. premises owned or occupied by or rented or loaned to you; ongoing operations performed by you or on your behalf, done under a contract with that person or organization; "your work'; or "your products". We waive this right where you have agreed to do so as part of a written contract, executed by you before the "bodily injury" or "property damage" occurs or the "personal injury" or "advertising,injury" offense is -committed. D. BLANKET ADDITIONAL INSURED- MANAG- ERS OR LESSORS OF PREMISES WHO IS AN INSURED (Section II) is amended to include as an insured any person or organization (referred to below as "additional insured") with whom you have agreed in a written contract, exe- cuted before the "bodily injury' or "property dam- age" occurs or the "personal injury" or "advertis- ing injury" offense is committed, to name as an additional insured, but only with respect to liability arising out of the ownership, maintenance or use of that part of any premises. ]eased to you, subject to the following provisions: 1. Limits of Insurance. The limits of insurance afforded to the additional insured shall be the limits which you agreed to provide in the writ- ten contract, or the limits shown on the Declarations, whichever are less. 2. The insurance afforded to the additional in- sured does not apply to: a. Any "bodily injury" or "property damage" that occurs, or "personal injury" or "adver- tising injury" caused by an offense which is committed, after you cease to be a ten- ant in that premises; b. Any premises for which coverage is ex cluded by endorsement; or c. Structural alterations, new construction or demolition operations performed by or on behalf of such additional insured. 3.. The insurance afforded to the additional in- sured is excess over any valid and collectible Page 2 of 6 Copyright, The Travelers Indemnity Company, 2004 CERT NO.: 9147430 Blanca Roque 12/30/2010 10:55:34 AM Page 5 of 8 CG D3 16 07 04 Norman A. Olsson Construction, Inc. COMMERCIAL GENERAL LIABILITY POLICY NUMBER: DTE-CO-8265L609-TIL-11 ISSUE'DATE: 1/1/2011 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Project(s): EACH "PROJECT" FOR WHICH YOU HAVE AGREED. IN A WRITTEN CONTRACT WHICH IS IN EFFECT DURING THIS POLICY PERIOD, TO PROVIDE A SEPARATE GENERAL AGGREGATE LIMIT; PROVIDED THAT, THE CONTRACT IS - SIGNED AND EXECUTED PRIOR TO ANY LOSS FOR WHICH COVERAGE IS SOUGHT. A. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under COVERAGE A. (SECTION 1), and for all medical expenses caused, by accidents under COVERAGE C (SECTION 1), which can be attributed only to operations at a single designated "project" shown in the Schedule above: 1. A separate Designated Project General Ag gregate Limit applies to each designated "project", and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations, unless separate Designated Project General Aggregate(s) are scheduled above. 2. The Designated Project General Aggregate Umit is the most we will pay for the sum of all damages under COVERAGE A., except damages because of "bodily injury" or "property damage" included in the "productscompleted operations hazard", and for medical expenses under COVERAGE C, regardless of the number of: a. Insureds-, b. Claims made or "suits" brought-, or c. Persons or organizations making claims or bringing "suits". Designated Project General Aggregate(s): GENERAL AGGREGATE LIMIT SHOWN ON THE DECLARATIONS 3. Any payments made under COVERAGE A. for damages or under COVERAGE. C. for medical expenses shall reduce the Designated Project General Aggregate Limit for that designated "proj'ect". Such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Designated Project General Aggregate Limit for any other designated "project" shown in the Schedule above. 4. The limits shown in the Declarations for Each Occurrence, Damage To Premises Rented To You and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Designated Project General Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under COVERAGE A. (SECTION 1), and for all medical expenses caused by accidents under COVERAGE C. (SECTION 1), which cannot be attributed only to operations at a single designated "project" shown in the Schedule above: CG D2 1101 04 Copyright, The Travelers Indemnity Company, 2004 Page 1 of 2 CERT NO.: 9147430 Blanca Roque 12/30/2010 10:55:34 AM Page 6 of 13 COMMERCIAL GENERAL LIABILITY 1. Any payments made under COVERAGE A. for vided, any payments for damages because of "bodily damages or under COVERAGE C. for medical injury" or "property damage" included in the "products - expenses shall reduce the amount available under completed operations hazard" will reduce the Products - the General Aggregate Limit or the Products- Completed Operations Aggregate Limit, and not reduce Completed Operations Aggregate - Limit, the General Aggregate 'Limit nor the Designated 'whichever is applicable.- and Project General Aggregate Limit. 2. Such payments shall not reduce any Desig nated Project General Aggregate Limit. C. Part 2. of SECTION 111= LIMITS OF INSURANCE -is deleted and replaced by the following: 2. The General Aggregate Limit is the most we Will pay for the sum of a. Damages under Coverage B; and b. Damages from "occurrences" under COVERAGE A (SECTION I) and for all medical expenses caused by accidents under COVERAGE C (SECTION I) which cannot be attributed only to operations at a single designated "project' . shown in the SCHEDULE above. D. When coverage for liability arising out of the "products -completed operations hazard" is pro E. For the purposes of this endorsement the Definitions Section is amended by the addition of the following definition: "Project" means an area away from premises owned by or rented to you at which you are performing operations pursuant to a' contract or agreement For the purposes of determining the applicable aggregate limit of insurance, each "project" that includes premises involving the same or connecting lots, or premises whose connection is interrupted only by a street, roadway, waterway or right-of-way of a railroad shall be considered a single "project". F. The provisions of SECTION III - LIMITS OF INSURANCE not otherwise modified by this en- dorsement shall continue to apply as stipulated. Page 2 of 2 Copyright, The Travelers Indemnity Company, 2004 - CG D2 1101 04 CERT NO.: 9147430 Blanca Roque 12/30/201D 10:55:34 AM page 7 of 8 Norman A. Olsson Construction, Inc. WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY ENDORSEMENT WC 99 03 76 ( A) — 001 POLICY MLIii SER: DTJ-UB-8265L609-11 WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT W CALIFORNIA (BLANKET ,AIVEiR) We have the right to recover our payments from anyone liable for an injury covered by Us policy. We will not enforce our right against the person or organization named in d're Schedule. The additional premium for this endorsement shall be % of thtt California Workers' compensation pre- mium. Schedule Person or Organization Job Description: ANY PE'WOX OR ORGANIZATION FOR WHIM = NAMM XXSURLYD am AGRSSA BY WRITTEN CONTRACT 9X'SCOTED PRIOR TO LOSS TO FUMXXSH THIS WAIVER_ This endorsement changes the policy to which it is attar had and is sf active on the date issued unless otherwise stated. (Tho information below is required only when this endorsement Is issued subsequent to preparation of the policy.) ` Endorsemeni Effective polity No. Endorsement No. Insured Premium lnSurance Company DATrz OF ISSUE.: ST A8SIGN: Countersigned by Page t of 1 CERT NO.: 9147430 Blanca Roque 12J30%2010 10155:34 AM Page a of E 8739437 Bond No._._______�------- NIL Fidelityand Deposit companyx POST OFFICE BOX 1227 OF MARYLAND BALRUORE MD 21203 RID BOND KNOW ALL MEN BY THESE PRESENTS: That we, ---- Norman A.Olsson Construction, Inc. — -- -- -- ---- - ---------------------�---- as Principal, (hereinafter called the "Principal-), and the FtDEUTY AND DEPosrr COMPANY OF MARYLAND, P.O- Box 1227, Baltimore, Maryland 21203, a corporation duly organized under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety"), are held and fumfiy bound unto The City of Huntington Beach as Obligee, (hereinafter called the "Obligee"), in the sum of__T --n Percent of Amount Bid for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. Water Well No. 10 WHEREAS, the Principal has submitted a bid Rehabilitation Project CC No. 1380 NOW, THEREFORE, if the Obligee shall accept the bid- of the Principal and the Principal shall enter into a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or contract documents with good and sufficient surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this_18th day of — _January ---____----A-D.,2011- Norman A. Olsson Construction, Inc. (SEAL) ' Principal Witness BY: S t7 C� 7V T T[le FIDELITY AND DE IT CO PANY OF ARYLAND _ _-_ _----- — Surety -- By_.-- -------___--- SEAL witness ATTORNEY -IN -FACT Ttte C320-50M-7'92 Richard A. Coon Conforms n Aareicln Instisutc of Arsift= oon,,,wnt A 310. , - Fcbw=cy 1470 Edition. - - - - - - CALIFORNIA ALL-PURPOSE �`�" ,N" !T - �' v' N' d' � - .•Yy" y - a7r ,•➢' JY"t)' e'd:'✓" ,•J - 'ty STATE OF CALIFORNIA County of Orange } On 1-18-11 before me, Lexie Sherwood, Notary Public Date Here Insert Name and Title of the Officer personally appeared Richard A. Coon Name(s) of Signer(s) LEXIE SHERWOOD COMM. #1856389 3 NOTARY PUBLIC • CALIFORNIA n 1 ORANGE COUNTY -+ W'Y (000mm. Exp. JULY 27, 2013 who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand and official seal. Signature Place Notary Seal Above Signature o`f`N6t6ry Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Individual ❑ Corporate Officer — Title(s):_ ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Number of Pages: Signer's Nacre: ❑ Individual ❑ Corporate Officer —Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: © 2007 National Notary Association • 9350 De Soto Ave., PO. Box 2402 -Chatsworth, CA 91313-2402 • www.NationalNotaryorg Item #5907 Reorder: Call Ton -Free 1-800-876-6827 Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by WILLIAM J. MILLS, Vice President, and ERIC D. BARNES, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date a dds y nominate, constitute and appoint Richard A. COON, Charles L. FLAKE, David L. CULB n e OOD, all of Anaheim, California, EACH its true and lawful agent and a a >d deliver, for, and on its behalf as surety, and as its act and deed: any an o n xecution of such bonds or undertakings in pursuance of these prese in as fully and amply, to all intents and purposes, as if they had been d VS t ac gularly elected officers of the Company at its office in Baltimore, Md., iP Per attorney revokes that issued on behalf of Richard A. COON, Charles L. FLAKE, C ew P. FLAKE, Lexie SHERWOOD, dated November 7, 2005. The said Assistant a s by certify that the extract set forth on the reverse side hereof is a true copy of Article VI, Section 2, of the By- s said Company, and is now in force. IN 'WITNESS WHEREOF, the said Vice -President and Assistant Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 15th day of November, A.D. 2006. ATTEST: '�� 9fPps�i W � "V rJ State of Maryland City of Baltimore ss: FIDELITY AND DEPOSIT COMPANY OF MARYLAND Eric D. Barnes Assistant Secretary By: William J. Mills Vice President On this 15th day of November, A.D. 2006, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came WILLIAM J. MILLS, Vice President, and ERIC D. BARNES, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, 1 have hereunto set my hand and affixed my Official Seal the day and year first above written. �tt�ttA't .:d;..... lip " (, xt 777/ll if tl�t\`\ Constance A. Dunn Notary Public My Commission Expires: July 14, 2011 POA-F 012-4150H City of Huntington Beach 2000 Main Street ® Huntington Beach, CA 92648 (714) 536-5227 ® www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 Pointer Enterprises 9121 Atlanta Ave., Ste. 410 Huntington Beach, CA 92646 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CIVIC City Clerk J F: pe Enclosure gMtw0WI3sunt mPJIxVd1v0* Waitakere,.New Zealand 2011 FEB . 8 PM 1: 44 IV meNo.lo - R�abili� kvvhPf6je6 for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within G1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. o' Accompanying this proposal of bid, find 0 /6 in the amount of $'� which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 Provision of Traffic Control Plan LS �(�4Z $ ►}a4�� 21 1 Provision of implementing traffic control LS $5�A- $ S 54-7:- Total Amount Bid in Figures Basis of Award : $ Total Amount Bid in Words -�rf • r.� iqni'i ,A` -- _ _.. ry e 3'JC� `l.� 1 Yi2 -444 nl ted r„n e , }_ V _----- Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there: every attendee of the mandatory job walk will proceed to the Well #10 site. G1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler . 14 1 room roof mounted blower LS $ $ Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation 15 1 of engine control panels to be conducted by MurCal, Inc LS $ 3Q��T8® $ . 16 1 Install fencing LS $ ( 22q si— 2Z9 17 1 LS System testing and commissioning 18 1 Clean-up & demobilization LS 4Jq 0 $ 19 1 Provision and implementation of the SWPPP plan LS There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quanti - written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting LS $ o4 ? $90,47�= Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $ 22,76 s 22,76Sf Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $� g��?1419 11 1 Install 16-inch flowmeter LS $�ji �C $ta�S.= 12 1 Paving , LS 13 1 Install catalytic converter and engine exhaust piping LS There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quanti Item with unit price written in words Unit Price Extended Amount 1 1 LS Mobilization $ " j 51-A = S �5 2 1 LS Temporary sheeting, shoring, and bracing 3 1 LS Removal temporary sheeting, shoring, bracing S S= $ -2 ci -3 F 4 l LS Demolition of existing muffler room, blower shed and paving s"3i. I- s 14 1 5 1 LS Grading and trenching 0 �= 0 6 1 LS Install gas engine, driveline and appurtenant equipment s2-4,-�73- s 2-4,373 7 1 LS � Construct muffler room and install silencers $� // $�-T��--77� There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 FIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion of Work Name and Address of Subcontractor State License Number Class Murr 1 nc.. 41 VR2 Vrh S� . Wmacag , C_Aot�r51 M �bD2® �nJ .tQ;4&,Q'r a Oyx ' nd burr ` 4'� 1 dWe8lr POOR CD •JVIC l Lk) . IDS• c rr o- "7 Vb1Gnlayf 0 CPr t is UyyXW q Spa-- (,r G5W COOr By submission of this proposal, the Bidder certifies: That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange being first duly sworn, deposes and says that he or she is �_�\afn� of "M42g- 'En{,the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. 0'�&, lcwi Fnnka, 1C7, i• Address of Bidder Subscribed and sworn to before me this day ofa� 201� . CHRISTINE WASFI LPCOMM. # 1751215 NOTARY PUBLIC - CALWORN1AE RIVERSIDE COUNTY MY �mm. Expires June 16, 2011 NOTARY PUBLIC C-1 NOTARY SEAL UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned, also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: —r2 1 (6 1,9cm C-1 Title DISQUALIF'IC'A'TION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes WNo If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: c'-). It?> I c9m C-1 ,C�inec Tf\k Inc. Cnntrnrtnr R-�.g=,rya- Title BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name OI �&l AWRY) 4 -41t) Business Address City, Telephone Number State Contractor's License No. and Class to--(aCX:)& Original Date Issued b I Expiration Date State Zip p y---�- -11, . T'he work site was inspected b � 1 V1(VlC�6� of our office on 201 The following are persons, firms, and corporations having a principal interest in this proposal: ��, � Imo. �� ', �� � 1 ■ � �i�.� �.� ��� � ti � �� Rt C-1 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Company N Signature gfBi a v eYA Printed or Type Signature Subscribed and sworn to before me this 43day of 2011 NOTARY PUBLIC CHRISTINE WASFI COMM. # 1751215 ® , NOTARY PUBLIC - CALIFORNIA RIVERSIDE COUNTY My Comm. Expires June 16, 2011 NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: A Nam(Yand Address of public Agency Name and Telephone No. of Project Manager: -b Gi 15 f ?146.11 MnnmunNA QeM�tr Imo. njEnk 1 )9011 Contract Amount Type of Work Date Completed 2. 1L->T3M o new th �1cy�� � �-v��a 1e�®, CA Name and Address of Public Agency Name and Telephone No. of Project Manager:, 't-9-11 Iq 1q.-1 ELM Path cal6lettCJ Il 9C� Contract Amount Type of WorkeA AsT1dLSCAJ?en%- Date Completed Name and Address of Public Agency Name and Telephone No. of Project Manager: LOTTA CXS Tf l t4J %(00 -���� Contract Amount Type of Work �—Cy to -�' Date Completed C-1 AIA Document A31 OTM -2010 Bond No.: 20-SUR-210613 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR: (Name, legal status and address) T A POINTER ENTERPRISES, INC. DBA POINTER ENTERPRISES 9121 ATLANTA AVE. HUNTINGTON BEACH, CA 92646 SURETY: (Name, legal status and principal place of business) AMERICAN SAFETY CASUALTY INSURANCE COMPANY 23901 CALABASAS ROAD SUITE 1085 CALABASAS, CA 91302 OWNER: (Name, legal status and address) CITY OF HUNTINGTON BEACH 2000 MAIN STREET HUNTINGTON BEACH, CA 92648 BOND AMOUNT: 10%, ( TEN AND 00/100 PERCENT) OF BID AMOUNT BID BOND PENALTY NOT TO EXCEED $ 43,395.00 ( FORTY THREE THOUSAND THREE HUNDRED NINETY FIVE AND 00/100 PROJECT: (Name, location or address and Project number, if any) WATER WELL #10 REHABILITATION PROJECT CC#1380 The Contractor and Surety are bound to the Owner in the amount set forth above, for the payment of which the Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, as provided herein. The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the time specified in the bid documents, or within such time period as may be agreed to by the Owner and Contractor, and the Contractor either (1) enters into a contract with the Owner in accordance with the terms of such bid, and gives such bond or bonds as may be specified in the bidding or Contract Documents, with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner, for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof; or (2) pays to the Owner the difference, not to exceed the amount of this Bond, between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid. Waiver of notice by the Surety shall not apply to any extension exceeding sixty (60) days in the aggregate beyond the time for acceptance of bids specified in the bid documents, and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty (60) days. If this Bond is issued in connection with a subcontractor's bid to a Contractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law b Signed and eal this 7th day of February, 2011. T A POI R ENT�RPAI�, INS. DBA POINTER AMERICA"AFETY SUALTY INSaCE (Surety) (Seal) (Title) (Title) YU . MULLICK, attomey-in-fact CAUTION: You should sign an original AIA Contract Decumant, on wl-.:ch this text pears in RED. An original assures thatchanges will not be obscured. AIA Document A31OTM — 2010. Copyright ©1963, 1970 and 2010 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. Purchasers are permitted to reproduce ten (10) copies of this document when completed. To report copyright violations of AIA Contract Documents, e- mail 4-- ACKNOWLEDGMENT State of California County of Orange ) . On February 7, 2011 before me, Peter Austin Neff, Notary Public (insert name and title of the officer) personally appeared Yuny, T. Mullick who proved to me on the basis of satisfactory evidence to be the person(l) whose name(*) is/ate; subscribed to the within instrument and acknowledged to me that hebsbvbM executed the same in hisGben&je r authorized capacity(a*, and that by hisHmwL#I Wk signature(s) on the instrument the person(), or the entity upon behalf of which the person(x) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. N �� 'LOFT"R. PETERA►uS 11h NEFF n" t COMM. 1 M389 � o IOTARYPUB#C L•C{�90 ;D ORANGE COUNTY CC Signature (Seal) M'CWM E*=1AY27,m2" RESOLVED FURi ZlBR, that the signature of any aufflotized officer and the seat of the Company maybe affixed by facsimile to any power of ammey or certification thereof' aat6o—g tfrt, execubm and delivery of any bond andmukin& recognizan e, or other suretyship obligations of the Company. and such signature and seal when soused shall bane the same force and affects as though wasamiy affixed IN yV7IMM 9VEMWJMF. Amencan Safety Casually insurance Company has camed its official seat to be hereunto afiuccd, anti these prasenCs to be signed by its President and. attested by its Secretary this Highth day of September, 2t)03. r—® Attest® Stephen R. Ctim. President Randolph L Hutto. Secretary STATE OF GEORGIA POU1477 OF COBB , On this Eighth day of September, 2W3; before me pe-mily came Stephen R. Crim. to the known, who. being by duly sworn. did depose and say that be is thtficsidetit of Amerwan Safety Casualty Insurance Coatpany, the corporation described in and wind[ executed the above iastntme" Oat he knows the seal of the said corporation, that the seal affixed to the said instrument is such corporate seal; that it was so affixed by order of ft Board of Directors of said corporation and that he signed his name therein by like order. i Tna/� Rath Baakslo4 NOtary PabIK of J. the atrdersigped, Secretary of American Safety Casualty lasuraam Company - , Oklahoma. corporation. DO . HEREBY CERTIFY that;'the foregoing and aueched Power of Attomey remains in full force and has not been revoked-, and furthermore that die Resolution of the' Board of Directors, set forth in the said Power of Attorney, it now in fa= Signed and Sealed at the Cry of Atlanta. in the State of Georgia.''., Dated the 07 day Of February, 2-011 ,v. x 4 : tGt71d ht_ Fttat4,f ORIGC�:?LSOF[HCSf'OYY'£KGi,9L;'OUVE7"AI{£1'KLVTEl7la7ZHK£L';NGadE7{Ci:d;_,vL.t1[tEKS. lJUPLI(-_i7E:)i7i-2.'.Li�•i�?,IH.`_),�,bll:rGRC./!,t'U£rlC:iiS.i�'URIi;C;ti'.a!_C>,11.Ybt'H£HISS'U£1)1�<U�'.ilbrti;)3'V6t7'✓71CL:(.RICL��)?.. City ®f Huntington Beach 2000 Main Street s Huntington Beach, CA 92648 (714) 536-5227 o www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 SCW Contracting 2525 N. Old Hwy 395 Fallbrook, CA 92028 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed. please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CIVIC City Clerk JF:pe Enclosure s�v�tAjc�piiwf� Waitakere, New Zealand SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find in the amount of ;QKp.,.- -which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: C-1 PROJECT DID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 1 1 LS Mobilization $114 t�S $ H 2 1 LS Temporary sheeting, shoring, and bracing $ $ gZq.Ua 3 1 LS Removal temporary sheeting, shoring, bracing $ 270CYj $ Z?.3.C)0 4 1 Ls Demolition of existing muffler room, blower shed and paving 5 1 LS Grading and trenching $ 3� 2-30 $ 3, z250 6 1 LS Install gas engine, driveline and appurtenant equipment $ ZZj% 7 1 Ls Construct muffler room and install silencers $ 516-�15-� There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. LOW PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 LS repainting $ $1C�9 1y Install yard gas piping, yard electrical conduit, and electrical 9 LS ductbank $ $ J/ -I , Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LS LPG vaporizers $ s,033 $ s, 63 11 1 Install 16-inch flowmeter LS $ � ,yea $ (D 12 1 Paving LS $Zs-jSr6 $ ZSJ57 13 1 Install catalytic converter and engine exhaust piping LS $ %O $ %i CX�Q There will be a mandatory iob walk for bidders on Wednesday. January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item No. Estimated Quantity price written in words Unit Price Extended Amount 14 1 LSs71 Install engine room roof mounted exhaust fan and muffler room roof mounted blower $� 15 1 LS Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation of engine control panels to be conducted by MurCal, Inc $ 7��30� $-7�3' 16 1 LS Install fencing $ J� oT1 $ %d�7 17 1 LS System testing and commissioning $Z, (�2 1 $ 2 �OZ- 18 1 LS Clean-up & demobilization $ZJZ-2IF7 $2032 $ $ Z,o3Z 19 1 LS Provision and implementation of the SWPPP plan There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PR0.1FCT Bin SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 20 1 Provision of Traffic Control Plan LS $ I J o C_C_ $ t-) 21 1 LS Provision of implementing traffic control Total Amount Bid in Figures (Basis of Award): $ y q i, a Total Amount Bid in Words: Q r- H u 1 id re d �L`✓ 7"Gcc�uS 14wrclrcc% Tw t,1 �- I— S Notes: All extensions of unit prices will be subject to verification by Owner. In .case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School From there; every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 i LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. St`Pv'i I\(nc,kJ ff1',5a/1k.J ' �9 �I 4, - Z-� l��r�• Gvf 903 55/ 5'�� ti'eC" t '7ZOG EL�c-T 132=p i4� r Klrt4� `��y uy �i9 6S C- t� cr-&6=Q J_o�n A -� �&" /bj�3 Dim s T 5�,� ��os rf9 7-6- Ak -rz- �,` 3 -1 17 — s T rc�s %JM , Pat» CA A 1400 tflit5npit S ( 7-il /`J . V-2cf I � s t Co C-14 92J� -76?D S O reb -31ZS. w; i (OW b4u� (�+��� fo Z377 2 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 State of California County of San Diego Subscribed and sworn to (or affirmed) before me on this 8th day of February , 2011 , by Jeffrey Scrape proved to me on the basis of satisfactory evidence to be the person(s) who appeared before me. S. L. COLENIAN Commission # 1913434 Notary Public - California San Diego County My Comm. Expires Dec 15.2014 (Seal) _ Signature LE NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange being first duly sworn, deposes and says that he or she is of5e--%-6 the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. .s c., I cC 1h.4-T r%j%6--T Z S4 L- CQfrecl' . Z s Z s t4v-a 71' -15b -1 ---131 r ��t��votG cok q Z AZ-$ Address of Bidder Subscribed and sworn to before me this day of , 201_ . NOTARY PUBLIC C-1 NOTARY SEAL UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL. CITY OF HUNTINGTON BEACH CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL, NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: -VEM . ? N C-1 Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes O No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. r Date: FF—P,. $z- Zcv1 k C-1 1�— --- — Title BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name 7-5 2sEi� r`1 . -3-9S Business Address FA L-L-- C A 9 ZO Z& City, State Zip ( 16o) -1 Z-B - 1 3 c� g Telephone Number G3C> "-s' 4�:- State Contractor's License No. and Class % o , `i 'I 1 4 `i Original Date Issued 10 1-&1 IZo1 1 Expiration Date The work site was inspected by PerTE-KoGLMAX, of our office on ZYAw"4. � , 201L. The following are persons, firms, and corporations having a principal interest in this proposal: C-1 State of California County of _San Diego Subscribed and sworn to (or affirmed) before me on this 8th day of February , 2011 , by_ Jeffrey Scrape proved to me on the basis of satisfactory evidence to be the person(s) who appeared before me. S. L. COLEMAN Commission #t 1913434 1. ja Notary Public -California San Diego County My Comm. Expires Dec 15, 2014 _ (Seal) Signature The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. .----C%"J Cc» e-r Company Nam a , Signature Printed or Typed Signature Subscribed and sworn to before me this _ day of NOTARY PUBLIC C6rz-F-care- A-r�� , 201_ NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: I. TT--c t=--z e> \3A-r r--K % -&- l o Name and Address of Public Agency 4 S -1" Name and Telephone No. of Project Manager: 7Ay, zc> A) E{Zm L!_ 41 SSA ®n "�+ELLNE1I> f1'spSZT�.I 1PI�aM XF-147S t I -cm Contract Amount Type of Work Date Completed 2. C)-TA,!,( WA--%ErZ ZSs�y Swf mLyb-. Name nd Address of Public Agency's `r°` "'F-%' Name and Telephone No. of Project Manager: {�o,�� d�loc�E� ��"��� 44L1 - GI�OLP Contract Amount Type of Work Date Completed 3. L,qV-'P%o, ISoK -1 cx:> Name and Address of Public Agency cA. 42'3 sZ Name and Telephone No. of Project Manager: IKU o,-a C�r�`ti ss �`i� 16 -- -113-1 `T LA l f L491 Contract Amount Type of Work Date Completed C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to:. Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All -construction -sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX I) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a guote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this proiect. The following shall be amended from the Specifications, page 4 in SECTION 13006: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Attention to Mr. John Murphy, ihmurphynmurcal.com -1- The following shall be deleted from the Specifications, page 15 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, dated January 26, 2011. Company Name z--7— 7_­k l Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- January 26, 2011, 9 am Mandatory Job Walk - Well 10 Project (CC1380) - Sign -in Sheet No. OrBanixatlen Contact Address Address2 City State Postal Coda Fax Phone Em.11 Type Prizd Name of Attendee Si acute of Attend. 1 Ace CA In. D—y Daher 1199 En 1ev41d or Glendora CA 91741 626 $52-0258 1626 852-0257 .mcd99 —;].cam General Contractor 2 A66 1-aA... Lwelyw-4ASHinee sonDiegoC4 9}123 (8b8)-834-6569 _ _ _ _ Waq-Ream {defvlee 3 Bakersfield Well &Pump Company 0sor Macias 7212 FrvfMleAvt Bakersfield CA 93308 (661) 393-9661 amad c@bvrpumps.mm Generd Contractor 4 Beard ElenMc Richard Beard 13924 Ma on Ave Santa F.Springs CA 90670 562)802-0700 562)832-1800 rwbeard@bexdelect6acom Subcontractor N 7"O]% b gid-IMaerka Plan -Ream 4}BBSSm-Spee! Mwriesa CA y2552 fq&44499- 5 (95.})g72.337g P - 5Bldnet 20A Railroad Awn- Albany NY 12205 (8001677-1997 gbs@bfdnet.mm Other 7 fe ke( etwerk _ _ _ _ 5an.glaga G4 w4w (Gig) se&8b% PlanRacswKarc/ae 8 Cora Constructors Lynn. cat eault 75140 St Charles Place Wee A Palm Desert CA 92211 (760) 674-8648 (760)674-3201 lynne@ceraconstructors.com Generd Connector 9 Envlranmentel Construction Arash Bekheirnie 21550 anard SIR 1050 W..dland Hflls C4 1 91367 818) 703-9073 618 449-8920x112 &whb@enWo— General Contractor ,1gr W. Do dge CA 1928DG- k WogJie.m�-Sen4ae 11 Falcon menorah Engineering, lnc Davld Pitts 572 Collyn Stf Vista CA 99083 (760) 630-3648 (760)630-9570 dpitts@f4cc Inccom General Contractor 12 PIS Electrical Service Fred Snith 12456Ramon.Awnne Chfno CA 91710 9D9)628-3096 909)721-0006 Qsdecnlc@ver net Subcontractor 13 FLEMING ENVIRONMENTAL INC. PATTY FLEMING 1372 E VALENCIA DRIVE FULLERTON C4 92831 (714) 871-2801 (714) B71-2800 pflemf aeflem ngenvironm¢ntd.mm General Contractor G 14 Fluld[Qs LLC 0,60,e6erry, 2650 nap. Valley Corp Dr Napa CA W559(707)258.8465 (707)258-8400 merry@Buldigi Not Specified i649e-walnuF h, he9sarlo 64 924" 964948-WIS �«.a kgk Md{ew$s8gs Suk.N44 Sonotega CA 921&3 (8661 PQ Sig 7 (ttDG 7464-2ebb9-x8964 F. c•_ ___ plan-Raem-fb.rviae d-7KgF- 1066 WA;versleyh .*ue ban-Dleg. CA 4240(866)-67g Big i ;gftcom WanAeerwf be,•vice 18 Metro Bulidr- &Engineers G­p Ltd. Ran Schultz 2610 Awn Street Newpor,a... h CA 92663 949 515-435t (949) 51543S0 n@metrobullders.mm General Contractor 1901sson Constmdon, Inc Rachel 01sson 326 W Katella Ave Ste 4J Orange CA 92857 (714) 516-9596 (714)516-9496.327 radhel@olsmnconstmcdon.mm Generd Cantracmr 20 Palm Springs Pump West lennlfer 5245 Cadbury Road VJhltder C4 90601(562)699-9845 (562)695-5081 OTT Not Specified 2� Reed-4' .twaq.�nta Rradudlew bnite•6p0 NeraeK 6A "p��, doepro—ol pl.nAapm{gervka 22 S.S.Medhanlcal Corp. Steven Stump 17631 Metzler Lane Hun Ing—Bnarh CA 92647(714) 847-6907 (714)847.1317 myna@ssmechenl-Lblt Generd Contractor 23 SON C—trocdng Corporation Peter K.O., 2525 NOld Hwy395 Fdlbrook CA 92028 (760)72e-130Bx15 pkogler@scvvmmpanles.mm General Can [rector 24 Shultz Electrfc David shultt 1H411 Gohard Street Unit D Huntington Beach CA 92648 714847-7433 dishbca@ewthlfnk.net General Connector 25 Sauthem Contracting Co. Philp Waterman 559 N. Twin Oaks Valley Rd. San Marcos CA 92069 (760) 744-6475 (760) 744-0760 pv termon@southermmntractwg.mrn subcontractor 26 Tennyson Mpellne Co. 7819 KerryonMo Hesperfs CA 92345 (760) 948-2487 (760954-3544 grymnysn@eol.mm General Contractor 27 TPCJPdnt uare 2100 Wharton Street Sufle310 PIttsburgh PA 15203 (800 837-8303 k'einer@paln tsquare.mm Other 28 Watson Medhanfwl, I— Larry Wet— 564 West Bateman Cycle Corona CA 92BEO (951) 738-0404 (951)738.0408 Not S .dfied 29 West& Slywster Electrical 4597Aknond Ave Is..I Beach CA 90740 (562) 430-3 18S (562)430-9173 mike@wselecvfcnet Not5ped6ad O n a N 1 B0 J� 4* I aYd- 1- 27 1 e - b?- wz577Zt7[Tlo7� Nam, o AGve 33 I Wd Brty 7 - /4' S'8- 0 41 ts.4y2eD O e /tv i C- AMN LSi17X S. aF9r- St+c. R cboR- Ye S.I(Asl Ge4c r 9dd-7o ,I d TR Ti-3oN/IrI,oLA7M4WRYQAC CCVA It\ 0 uevo 00evv NUHVO "� 2 linen edhw «1. ate 1h o ah n---- Skkist T aF 3 Generated on: 1/25/2011 8:21 AM January 26, 2011, 9 am Mandatory Job Walk -Well 10 Project (CC1380) - Sign -in Sheet No. Oraenl.V_ Carted Address Address2 CI State P,, t [Code Fax Phone Email Type Prim Name.f Aaerdee Signature of Attendee 1 Ace Cd Inc Day Daher 1199 En l—Aid Dr Glendora CA " 91741(626) 8524256 62G) 852-0257 acecd99 mafl.mm General contractor A66p1a.R.ew. "' 4-Qkg. CA 9212a w&%47d-8669 (858�874-gd60:riF P{en_Pee /_Scr4ce 3 Bakersfield Well &Pump CompanyOscar Mad., 7212 Fwltvale Ave Bakersfield CA 93309 (661)393-95B1 omados@b General Contractor 4 Bead Electric Richard Beard 13924 Ma ton Ave Smt.F.Spri s CA 90670(562802-0700 562802-1800 rwb,wd@beadeleddcmm Submntractor Bid/lraerlea f4a.Raes. 4 M5 w" R Muwieta C A 92662 (! 6&Q 600-0646 WawAaem{.Sx-we 6 Bldne[ 20A Railroad Avenue Albert NI 12205 (BOOT 677-1997 bs@bidneLmm Other San9kg. 65 Pam (614)6w.;R3 PbrMeesa-EScr'rice Cora Constructors Lynne Cazeault 75140 5t Charles Place Sufw A Palm Desert CA 92211 (760)674-8648 (7601674-3201 Iynne@cc aco strucwa m General Contractor f O 9 Environmental Construction Arash Bekhalmfa 21550 Oxnard StR 1050 Woodland Hills CA 91367(818)703-9073 (818)449-8920 x112 General Gnbector i9 F+-WbbdBa Adeiana6ue 3n ke-WB A-s— CA 92806-6}26 (744)424-42M Wan-Ream}5en/ee 11 F,Imn General Engineering, Inc David Pitts 572 allyn Stl Vista CA 92083 (760) 630-3648 (760)630-9570 dpilts@fdconganergincmm General(bntrwtor e!� K dihs�iw`A'G 12 FIS Ela fcai 5arvfm Fred Smith 12456 Ramon.Avenue lChin. CA 91710909)52B-3096 (909721-0006 sdactric@w,fzon.net Subcontractor 13 FLEMING EN'ViRONMENTAL INC. PATTYFLEMING 1372 E VALENOA DRIVE IFULLERTON CA 978.31 (714) 871-2801' (714)871-2800 pFleming@flemingenvironmental.com General Con Vactar 14 FluidlQ,, 1LC ChdstineBeny 2650 nap, Valley Carp Dr INw. CA 945S9(707)258-8465 (707)258-MOO d,erry@fluidigsmm Not Spedfled N+R.dslu i6490wa1..t-4khespe CA 424" i.lineblue dot@«ene..ares ib Fsg4 MeuyaBeggs Su4a2244 8-Wega CA 44N (866) in 219 891s4 sendiege@Isg7beer. P18 1 ROOM / Scr+�m 4i 49rt, 4966-IW -.--• • '- _ gan9leY. CA 92W7 (wb) sn$3'B7 (egg)464-2069 Wa.-Rea.F/�erMea 18 Metro Builders & Engine— Group Ltd. Ran Schultz 2610 Awn Street New art Bead, CA 92663 (949) S15,4351 949) 5154350 @metr.1,01ders.mm General Contractor 1901sson Gonstmdon, Inc Rachel CNsson 326 W KatelleAw Ste 41 Orange CA 92867 (714) 516-9596 QW)516-9496.327 ian.com General Contractor 20 Palm SprrnS5Pump West lennffar 5246 Cadbury Road Whittier CA 90601(.562)699-9845 (562)695.5081 Nat SpecfRed 2+ kaeNen9ata preduetbn 6.4e, W NerustYr. GA dB092-29i7 2-M37 (1470f876.4045 Wa.ile.m{-6ar5iea 22 S.S. Medr Fol Corp. St —Stump 17631 Metzler Lane Hune'retan Beach CA 92647 (714) 847-6907 (714)847-1317 nrym@_achanical.b1t Generd Contractor - LA a... 23 SCW Contracting Co oration Peter K ogler 2525 N Old Hwy 395 Fe116raa1, CA 92028 (760)728-1309.15 pkogler@scwm mpanles.wm Generd Contractor 24 Shuitr Ela.nlc D,vld Shultz 18411 Gohard Street, UnitD 111—tIngton Beach CA 92646 714) 847-7433 dlshbca esthlink.net General Contractor 25 Southern contracting Ca. Philip Waterman 559 N.Twin Oaks Valley Rd. is. Marcos CA 92069(7607444475 (760)744-0750 pwaterman@southemmntradhg.mm Subcontractor 26Tennyson Plpeline Co. 7819 KenyonAm Hespeda CA 92345 (760) 948-2487 (760)954.3S44 grytnnysn@aol.mm General contractor 27 TPC/Pant^ uare 2100 Whartnn Street Suite310 Pfttsbu h PA 15293 800)837-8303 krelner@ ai uare.com Other 28 Watson Mrciartkd, Inc. Lary Watson 564 West Bateman Circle Comma CA 92880(951)738-0404 (951)738-0408 Not Sped Red 29 West& Slyvester Electrical 4597 Almond Ave Seel Beach CA 90740 (562)430-3185 (562)430.9173 mike@wselectric.net Not SpedBed N '71r - e 'k tJ 'iMc C, rE s-7 :-aq•s bove 0 IL 2 r -7 '7 i P.,„ na1 i� �4� d 722 r nb r FRer81 3 b 9. 1 6 Sc-�--7 Z O i= 3 Generated on;1/25/2011 8:21 AM f January 26, 2011, 9 am Mandatory Job Walk - Well 10 Project (CC1380) - Sign -in Sheet No. 0rgerdatlen Comsat Address Address2 City Starts Poatal Cade Fa. Phone Email Tvp, Prim N am of Attendee Signature of Attandw 1 Ace Cal Inc Donny Daher 1199 En lewild Or Glendora CA 91741(626) 952-0258 626SS2-0257 acecd99@gmaiLcorn General Con tractor 2 AGQPlaa-Roem _ __ __ gsr.pago G4 4� (869)_87"569 (858)8748660 wi0 PkwRaem-/SerM 3 Bakersfield Well & Pump Comps 0s Macias 7212 Fen1tvale Ave Bakersfield CA 93308 (661) 393-9661 omadas@bwpum s. Genre( Contractor 4 Bead Electdc Rlch.edfl—d 13924 Ma an Ave Son to Fe Spring, CA 90670 .562)8024700 (562) 802-IMO rwbeard@beardele-iroarn Subcontractor b Bid-Amerlea 81on8aem 44QW9r,Street Mywlets CA 42664 (961) E;j 44; 6 Bidnet 20A Railroad Avenue Albany NY 12205 (800) 577-1997 tibstMbidnet.ron, Other s CA 42588 (6{g}6gg.O6g6 _ __— _ top 8 Cora Constructors Lynne Cazeault 75140 St Otaies Place Suite A Palm Desert CA 92211 (760) 674-8648 (760)674-3201 nea@mraronstructon.eam General Contractor 9Environmental Con—effon Arash Bekhaimia 215500xnard St81050 Woodland Hills CA 91367818)703-9073 (819449-8920.112 aashb@oeVrommn.com General Contatcor 49 FW. P,ege AdriepeL'uz _ __ __ -_ 6eNe-100 Anahekw CA 92M-15426 (714) 634-4519 (7}4V6d4-42BG plasAasw{-Wruc¢ 11 F.Imn General Engineerin&In, David Pitts 572 Collyn Stf Vista CA 92083 (760) 630-3648 (760)630-9570 dpitts@felcorgenengincmm General Cont—tar 12 FIS Eleariml Servtm Fred Smith 12456 Ramon.Avenue China CA 91710(909628-3096 90972100015 fJselectric(LD ,lzon.net Subcontractor 13 FLEMING ENVIRONMENTAL INC. PATTY FI. E61ING 1372 E VALEN CA DRIVE FULLERI ON CA '92831(714)871-2801 (714)871-2800 pfleming@flemGtgenvironmental.wen General Contrrctor 14 FIu1dIQ%LLC Chd,dneBe,ry 2650 nape Valley Corp Dr Napa CA 94559(707)258-8465 (707)258S400 dserry@0uditt—re Not Spedfied 35 falir-neprate ibA90-welnnl-41 CA 9:!s4 plan Reaml3ar Ass i6 lartt4 Melisa;P9gs ..-12Q 6-mega, CA 92108(866) 6748187 (ago) 49a-2959«eB59 saAd{ego@kRtt.aom Plait gseml-6erMee 43 9q&6 - 406 lWenue sat Diego CA 42m (866)-sm fit7 (8B0)364 M em@k4tt,aem Rlen-Resmi daMee 18 Metro Bullders&ErGnears Group Ltd. Ryan Sehultz 2G1O Avon Street Newport Bead, CA 1 92663 949 51S 4351 (949)5154350 an@metrobuilder—, General Can tractor 19 Olsson Construcion, Ina Rachel Olsson 326 W Katella Ave Ste 4J Orange CA 1 92867 (714) 516-9596 (714) SIG-9496 w327 rschel@oissanoonstmcdon.mm General Contractor 20 Palm Springs Pump West Jennifer 5245 Cadbury Road Whittler CA 1 90601(562)699-9845 (562)695-5081 Not Spedfied 2} �en8— - _ _ 283echnolo iiw a -SOB No —to GA 3QGp_,g4 (804}874AB4b d pl�ae 22 an S.S. Mechical Corp. Steven Slump 17631 Metzlar Lane Hun tlrgton Bead, CA 92647(714) 847-6907 (714)847-1317 myra@ssmechanieal.biz General contractor 23 Scow Cor,tractlrg Corporation Peter Kugler 2525 NOld Hwy 395 Fdibmok CA 92028 (760)728-1308.15 pkogler@sewcompwie—re General contractor 24 Shultz Electric David Shultz 1B411 Goherd Streat, Unit D Hurt tan Bead, CA 92648 (714) 8d7.7433 dlshbo@earthlinknet General Contractor 25 Southern Contradhgc. Philip Waterman 559 N.Twln Oaks Valley Rd. San Marcos CA 92069(760) 744b175 (760744-0760 p_terman@southemmntrading.mm Subcontractor 26 Tenryson Pipeline Co. 7819 KenyonAve Hespeda G 92345(760)948-2487 (760)954-3544 grytnny.@soil.... General Contractor 27 TPCIPalet u 2100 Wharton Ste. Su Ita310 Pittsbu h PA 15203 (800) 837-8303 kreiner@ sin[ uam-mm Other 28 Watson Merhadcal, Inc Lary Watson 564 West gateman Ord. Corona CA 928M (951) 738-0404 (951) 738- 10R Not Specified 29 West& Sly—ba, Elaetri®I 4597 Almond Ave Seal Beach CA 90740(562)430-3185 (S62)430-9173 mike@wsal cvic.net Not Spedfied i N K n • a G, !4 r z w •r• doe Z . r9 10 0 /, `t/ ✓Pal tl eL dr1• 852 or 31 f •C @ C L Lim a44 ( &n N"f L CA- O d 86 W SL1-•- I 8 i l - r- e m `m ML T'Q.f G V I tkc-12_ t�r1 c ar M Y A ``1 �f 4— ei 20 , CA cniz c- lvtA lrnar SKe4 7 3 ,-T 3 Generated on: 1/25/2011 8:21 AM A City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER TWO For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 28, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The attached new SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be added to the Specifications, within "PART 4 — TECHNICAL SPECIFICATIONS". All references to "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be considered as exposed piping and/or equipment insulation as per Section 15250, para. 2.2. The following shall be added to the Specifications, page viii in the "Table of Sections": 15250 — Insulation for Exposed Piping and Equipment This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number two, dated January 28, 2011. S C �-a Cm n.4—T r&,,csc--r Company Name 2-7—Zsa� Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -1- SECTION 15250 INSULATION FOR EXPOSED PIPING AND EQUIPMENT PART 1 - GENERAL 1.1 DESCRIPTION A. Scope: This Section specifies insulation for exposed piping and related equipment and appurtenant surfaces. B. Temperature Classes 1. Insulation for exposed piping and equipment is classified for the following temperature ranges: medium, high, and very high. 2. Medium temperature class insulation shall be suitable for an operating temperature range of 100 to 800 degrees F. 3. High temperature class insulation shall be suitable for an operating temperature range of 800 to 1000 degrees F. 4. Very high temperature class insulation shall be suitable for an operating temperature range of 1000 to 1800 degrees F. 1.2 REFERENCES A. This Section contains references to the following documents. They are a part of this Section as specified and modified. In case of conflict between the requirements of this Section and those of the listed documents, the requirements of this Section shall prevail. ASTM B209 Aluminum and Aluminum -Alloy Sheet and Plate ASTM C533 Calcium Silicate Block and Pipe Thermal Insulation ASTM C534 Preformed Flexible Elastomeric Cellular Thermal Insulation in Sheet and Tubular Form ASTM C552 Cellular Glass Thermal Insulation ASTM E96 Water Vapor Transmission of Materials FEDSPEC P-535E Plastic Sheet (Sheeting) "Plastic Strip" Poly (Vinyl Chloride) and Poly (Vinyl Chloride -Vinyl Acetate), Rigid HH-1-558B Insulation Blocks, Boards, Blankets, Felts, Sleeving (Pipe and Tube Covering), and Pipe Fitting Covering, Thermal (Mineral Fiber, Industrial Type) PART 2 - PRODUCTS 2.1 GENERAL A. Piping insulation shall be tubular type or the flexible blanket type. Insulation for valves, strainers, fittings, expansion joints, flanges and other connections shall be segmented sections, molded, or blanket type coverings of the specified type and thickness of pipe insulation, or the flexible blanket type. Equipment insulation shall be flexible blanket type or rigid board type cut to fit the surface. CITY OF HUNTINGTON BEACH INSULATION FOR EXPOSED PIPING WATER WELL NO. 10 REHABILITATION PROJECT AND EQUIPMENT C.C. No. 1380 15250-1 JANUARY 2011 2.2 INSULATION A. General 1. Medium temperature class insulation shall be of the cellular glass or fiberglass type. 2. High temperature class and very high temperature class insulation shall be of the calcium silicate type or the flexible blanket type. Piping and equipment subjected to vibration (such as engine exhaust) shall be insulated with flexible blanket type. B. Unicellular Elastomeric Thermal Type: Unicellular elastomeric thermal type insulation shall conform to the requirements of ASTM C534, Type I. C. Cellular Glass Type: Cellular glass type insulation shall conform to the requirements of ASTM C552, Type 11. D. Fiberglass Type: Fiberglass type insulation shall conform to the requirements of FEDSPEC HH-1-55813. E. Calcium Silicate Type: Calcium silicate type insulation shall conform to the requirements of ASTM C533, Type 11, Class C. F. Flexible Blanket Type 1. High Temperature Class: High temperature insulation shall be removable 1-inch or 2- inch thick blanket -type insulation designed for continuous 1000 degree F service. The blanket shall be a custom sewn, flexible, reusable jacket, custom designed to closely fit the piping or the equipment housing. Blanket shall be custom fitted to not restrict access to any instrumentation or equipment. Insulation shall not compact or shake down in vibrating service. Blanket insulation shall consist of a noncombustible silica cloth jacket and nonasbestos white ceramic fiber insulation. Insulating blanket shall be Thermazip Hi -Temp blanket Style 2000-60-3000 by Accessible Products Company, Hitco AIM, Advanced Thermal Products, SEI Temp -Set 1200, Owens Corning Fiberglas TIW Types I and 11, or equal. 2. Very High Temperature Class: Very high temperature insulation shall be removable 1-inch or 2-inch thick blanket -type insulation designed for continuous 1800 degree F service. The blanket shall be a custom sewn, flexible, reusable jacket, custom designed to closely fit the piping or the equipment housing. Blanket shall be custom - fitted to not restrict access to any instrumentation or equipment. Insulation shall not compact or shake down in vibrating service. Blanket insulation shall consist of a noncombustible silica cloth jacket and high purity alumina and silica nonasbestos white ceramic fiber insulation. Insulating blanket shall be Thermazip Hi -Temp blanket Style 2000-61-3000 by Accessible Products Company, Hitco AIM, Advanced Thermal Products, or equal. 2.3 INSULATION JACKETS CITY OF HUNTINGTON BEACH WATER WELL NO. 10 REHABILITATION PROJECT C.C. No. 1380 JANUARY 2011 INSULATION FOR EXPOSED PIPING AND EQUIPMENT 15250-2 1 1 P A. Laminated Jackets: Laminated jackets shall consist of aluminum and white kraft paper. Jackets shall have a perm rating for water vapor transmission of not more than 0.02 in accordance with procedure A of ASTM E96. B. Aluminum Jackets 1. Aluminum jackets shall be constructed of smooth finish aluminum sheet conforming to ASTM 6209, alloy 5005, temper H16, with integral vapor barrier. Jackets shall be 0.016 inch thick. 2. Sheet metal screws shall be aluminum or stainless steel. 3. Jackets shall be secured with 0.020 by 3/4 inch type 304 stainless steel expansion bands. 2.4 INSULATION COVERS A. Polyvinylchloride (PVC) Covers: Polyvinylchloride covers shall be one piece, premolded polyvinylchloride conforming to FEDSPEC L-P-535E, Composition A, Type ll, Grade E4. B. Aluminum Covers: Aluminum covers shall be constructed of smooth finish aluminum sheet conforming to ASTM 6209, alloy 5005, temper H16, with integral vapor barrier. Covers shall be 0.016 inch thick. 2.5 SHIELDS A. Unless otherwise specified, thermal pipe hanger shields shall be provided at pipe supports. 2.6 FLASHING A. Flashing shall include aluminum caps, sealant and reinforcing. Aluminum caps shall be 20 gage thick and shall be cut to completely cover the insulation. Sealants shall be as recommended by the insulation manufacturer. B. Reinforcement in flashing heated up to 370 degrees F shall be nylon fabric. Reinforcement in flashing for hotter surfaces shall be wire mesh or as recommended by the insulation manufacturer. 2.7 PRODUCT DATA A. The following information shall be provided in accordance with Section 01300: 1. Manufacturer and manufacturer's type designation. 2. Samples, for each insulation material type, of typical jacket and closures for fittings, valves and appurtenances. 3. Descriptive literature and catalog data for materials to be used showing methods of installation. 4. Certification of ratings for water vapor transmission and puncture and stiffness as specified in Paragraph 15250-2.3 A. CITY OF HUNTINGTON BEACH WATER WELL NO. 10 REHABILITATION PROJECT C.C. No. 1380 JANUARY 2011 INSULATION FOR EXPOSED PIPING AND EQUIPMENT 15250-3 PART 3 - EXECUTION 3.1 INSTALLATION A. General: Insulation shall be applied over clean, dry surfaces. Double layer insulation, where specified or required to achieve the specified surface temperature, shall be provided with staggered section joints. B. Pipe Supports and Shields: Unless otherwise specified, thermal pipe hanger shields shall be provided by the CONTRACTOR and installed during pipe support installation. Where thermal pipe hanger shields are used, apply the following to all butt joints: 1. On hot pipe systems, the CONTRACTOR shall apply 3-inch wide vapor barrier tape or band over the butt joints. C. Protection: Insulation and jackets shall be protected from crushing, denting, and similar damage during construction. Vapor barriers shall not be penetrated or otherwise damaged. Insulation, jacket, and vapor barriers damaged during construction shall be removed and new material shall be installed. D. Piping Insulation 1. General a. Pipe: Piping shall be continuously insulated along its entire length including all in -line devices such as valves, fittings, flanges, couplings, strainers and other piping appurtenances. Unless otherwise specified, piping insulation shall be provided with laminated jackets specified in Paragraph 15250-2.3 A. Insulation shall be butted firmly together and jacket laps and joint strips provided with lap adhesive. Jackets shall be provided with their seams located on the underside of pipe. PVC covers specified in Paragraph 15250-2.4 A shall not be used with medium- or high -temperature class insulation. Removable flexible blanket -type insulation need not be jacketed. b. Fittings, Connections, Flanges and Valves: Fitting, connection, flange and valve insulation shall be provided with covers specified in Paragraph 15250-2.4. Insulation shall be secured in place with 20-gage wire and a coat of insulating cement. Covers shall overlap the adjoining pipe insulation and jackets. Covers shall be provided with their seams located on the underside of fittings and valves. 2. Medium, High, and Very High Temperature Class a. Pipe: Except for flexible blanket type, insulation shall have ends sealed with end joint strips and held in place by waterproof adhesive. b. Fittings, Connections, Flanges and Valves: Except where soft covers are specified, rigid insulation shall be provided with rigid aluminum covers specified in paragraph 15250-2.4 B. Covers shall be mechanically secured by corrosion - resistant tacks pushed into the overlapping throat joint. CITY OF HUNTINGTON BEACH WATER WELL NO. 10 REHABILITATION PROJECT C.C. No. 1380 JANUARY 2011 INSULATION FOR EXPOSED PIPING AND EQUIPMENT 15250-4 3. Outdoor Piping a. Pipe: Rigid insulation shall be provided with aluminum jackets specified in Paragraph 15250-2.3 B. Flexible blanket -type insulation shall be designed for outdoor, weather -exposed service. b. Fittings, Connections, Flanges and Valves: Rigid insulation shall be provided with rigid aluminum covers specified in Paragraph 15250-2.4 B. Flexible blanket type insulation shall be designed for outdoor, weather -exposed service. E. Flashing 1. Flashing shall be provided at jacket penetrations and terminations. Clearance for flashing shall be provided between insulation system and piping supports. 2. A heavy tack coat of sealant shall be troweled over the insulation, extending over the jacket edge 1 inch and over the pipe or protrusion 2 inches. Reinforcement shall be stretched over the tack coat after clipping to fit over pipe and jacket. Clipped reinforcing shall be strapped with a continuous band of reinforcing to prevent curling. Sealant shall be troweled over reinforcement to a minimum thickness of 1 /8 inch. 3. Aluminum caps shall be formed to fit over the adjacent jacketing and to completely cover coated insulation. Cap shall be held in place with a jacket strap. 3.2 INSULATION THICKNESS SCHEDULE A. The insulation dimensional tolerances shall comply with the specified standards. Equipment insulation shall match thickness of attached piping. The minimum insulation thicknesses, exclusive of jacket, shall be as follows: 5, 6, and Fluid Temp. Runouts 8 inches Piping Service (a) range, up to 1 inch 1.25 to _2.50 to and 8 inches degrees F 2 inches and less 2 inches 4 inches larger and larger b Engine Exhaust c 350- 1500 - - - 4 4 4 Hot Water 105-300 0.5 1.0 1.0 1.5 1.5 1.5 Supply/Return (vaporizer) Starting Air d 150-250 1.0 1.0 1.5 1.5 - (a) See specification Sections 15000, 15010, and 15066. (b) Runouts to individual terminal units (not exceeding 12 feet in length). (c) Engine exhaust from the engine to the Muffler Room. Catalytic converters, where used, shall be insulated with very high temperature insulating blankets. Additional insulation blankets shall be provided, if required, to limit the external surface temperature to a maximum of 200 degrees F or to achieve the required minimum thickness. (d) Insulate piping for personnel protection between catalytic converter after exhaust piping. Include catalytic supports. (e) For condensation control, see specification Sections 15000, 15010, and 15066. Unless otherwise specified, connected equipment shall be uninsulated. CITY OF HUNTINGTON BEACH WATER WELL NO. 10 REHABILITATION PROJECT C.C. No. 1380 JANUARY 2011 INSULATION FOR EXPOSED PIPING AND EQUIPMENT 15250-5 ** END OF SECTION ** CITY OF HUNTINGTON BEACH WATER WELL NO. 10 REHABILITATION PROJECT C.C. No. 1380 JANUARY 2011 INSULATION FOR EXPOSED PIPING AND EQUIPMENT 15250-6 SAFECO Insurance Company PO Box 34526 Seattle, WA 95124-1526 BID BOND Conforms with The American Institute of Architects, A.I.A. Document No. A-310 KNOW ALL BY THESE PRESENTS, That we, SCW CONTRACTING CORPORATION as Principal, hereinafter called the Principal, and the SAFECO INSURANCE COMPANY OF AMERICA 9 ATTN: SURETY CLAIMS DEPARTMENT of 1001 4TH AVENUE, SUITE 1700, SEATTLE, WA 98154 a corporation duly organized under the laws of the State of Washington , as Surety, hereinafter called the Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH as Obligee, hereinafter called the Obligee, in the sum of TEN PERCENT OF GREATER AMOUNT BID -------------------------------------------- Dollars ($ 10% of Bid Amount ) , for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for WATER WELL NO. 10 REHABILITATION PROJECT, CC NO. 1380 NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 7TH day of February 2011 SCW C ACTI C ORATIO (Seal) ( Principal Witness {` JEFF S , PRESIDENT Title SAFECO INSURANCE COMPANY OF AMERICA Witness { B y MARK D. IATAROLA, Attorney -in -Fact S-0054/SAEF 12100 v M ieyiaicicu uaucnlaln vi FRP THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED OWRED BACKGROUND. 4260377 :This Power of:Attorney limits the acts of those named:herein' and they, have: no,authori[yto bindthe Company except in the manner:and to the, extent . herein stated: SAFECO INSURANCE COMPANY OF AMERICA SEATTLE.WASHINGTON POWER ' OFATTORNEY KNOW ALCPERSONS, BY,THESE PRESENTS: That Safeco insurance Company of, America (the 'Company),a Washington, stock insurance company, pursuant to and by authority"of the By-law,and Authorization hereinafter set -forth, 'does _hereby name, constitute and appoint JOHN G.'MALOi11EY,. HELEN MALONEY MARK=D: IATAROLA,::DEBORAH D 'DAVIS;'AAATTHEW.C: GAYNOR, ALL OF, THE -CITY OF ESCONDIDO, STATE OF "CALIF.,ORN1A ..:: ........ .......................................... , each individually if there be more man,one named; its true and lawful attorney-m fact to.make, execute, seal, acknowledgeand'.deliver, for and on its behalf.as surety and as its Act; and deed any":and all., -undertakings ,bonds recognizance) and .other 'surety. obligations: in the .penal sum not. exceeding TWENTY FIVE MILLION=AND 00/100'!*'****: ******'DOLLARS ($ 25;000;000:00******"*""**"* ******),each and the execution of such - undertalungs;!fonds recogmzarices and other suretyobligat!ons in pursuance of_these presents; shall be as binding upon the Company,as if they had been duty signed by the president and attested by file secretary of the Com- _1 V in their own properpersons: - That this power is made and executed pursuant to and by authority of the following By-law "and Authorization', 4 ARTICLE IV -":Execution of Contracts Section 12.:84rety Bonds and Undertakings. t G Any officer or other,official of the Corporation authorized for that purpose in:writing by the Chairman or the President, and subject to such limitations - m as the Chairman orthe President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Corporation to make,- _ .. execute seal,-acknowled a and deliver: as sure and all:undertakin s bonds;. reco nizances and other sure obligations. Such attorneys -in -- an a. 9, tyY 9" 9. surety. 9 ' C fact;`sublectto the limitations set forth in their respective powersof"attorney shall !lave full power to bind the Corporation by their signature 'and 3 +; executed; such instruments:shall be as tiinding as if signed bythe.president and attested by the secretary: i By the following instrument thechairman or the president has authorized the officer or other official named thereinto appoint attorneys -in -fact: acc Pursuantto:Article IV, Section 12 of the By-laws, Garnet W. Elliott, Assistant Secretary of Safeco Insurance Company of. America, is authorized to 7Bo-iw. w appoint such attorneys -in -fact as maybe necessary to act in behalf of. the Corporation to make, execute, seal, acknowledge and deliver as surety 0any And all ,undertakings, bonds, recognizances and other surety obligations. c � d > �:t R: That the By-law and the Authorization set forth above are true copies thereof and: are now in full force and effect. 0 e C IN WITNESS WHEREOF, this Power .of Attorney. has been subscribed by an authorized officer or official of the Company and the corporate seal of_� O; d Safeco Insurance Company.of America has-been affixed thereto in -Plymouth Meeting, Pennsylvania this 30th day of November Us2010` 3 c m `o a SAFECO INSURANCE COMPANY OF AMERICA a a C 10 By v— t d rss a Garnet W. Elliott, Assistant Secretary a C-_ COMMONWEALTH OF.PENNSYLVANIA ss h P '`' a ,E COUNTY OF MONTGOMERY: c y+„ cc On this 30th day of November 2010 before me, a Notary Public, personally came Garnet W. Elliott, to me known, and C 'a v acknowledged that he is an Assistanf Secretary of Safeco.Insurance Company of America; that he knows the seal of said corporation; and that he c _ executed the above Power of Attorney and affixed the corporate seal of Safeco Insurance Company of America thereto with the authority and at the a «, L direction of said corporation. p a Z v IN TESTIMONY WHEREO ,*vd' o subscribed my name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year O first above written. � ✓ NW °���• G it (% � 12 r 9 C3 r aP tea hoayF 3 B OF �'E;<rr u h ay, � h�cntr� �me �r U ssiz t y My cor m, ss ffn .Virs Mar 282 3 ; Tereta Pastella, Notary Public CERTIFICATE® M5mbor, -PwmsyPmnda Asstytat,;0r. of'Notarias Py�°IF�Ck 1, the undersigned, As r Safeco Insurance Company of America, do hereby certify that the original power of attorney of which the foregoing is a full, true and c py, is in full force and effect on -the date ofthiscertificate; and I do further certify that the officer or official who executed the said power of attorney is an Assistant Secretary: specially authorized by the chairman or the president to appoint attorneys -in -fact as provided in Article IV, Section 12 of the By-laws of Safeco Insurance Company of America. This certificate and the above power of attorney may be signed by facsimile or mechanically reproduced signatures under and by authority of the following vote of the board of directors of Safeco Insurance Company of America at a meeting duly called. and held on the 18th day of September, 2009. VOTED that the facsimile or mechanically reproduced signature of any assistant secretary .of t),* company, wherever appearing upon a certified copy of any power of attorney issued by the company in connection with surety bonds, shal! be v&lid. and binding upon the company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed myna xed the corporate seal of the said company, this 7TH day of FEBRUARY 2011 Dav'i, M. Carey, A istant Secretary CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT No.5193 State of California ) County of San Diego ) On F4)- R, 2011 before me, S.L. Coleman, Notary Public , personally appeared Jeffrey Scrape who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/ their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the S. L. COLEMAN instrument. Commission # 1913434 a . Notary PubBc - California 1 certify under PENALTY OF PERJURY under the laws of San Diego County the State of California that the foregoing paragraph is My Comm. Expires Dec 15,201 - true and correct. WITNESS my hand and official seal. Signa u e of —Notary �3t�� _ OPTIONAL SECTION ® OPTIONAL SECTION a>� CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL CORPORATE OFFICER(S) TITLE(S) PARTNER(S) LIMITED GENERAL ❑ ATTORNEY -IN -FACT ❑ TRUSTEE(S) GUARDIAN/CONSERVATOR OTHER: SIGNER IS REPRESENTING: NAME OF PERSON(S) OR ENTITY(IES) THIS CERTIFICATE MUST BE ATTACHED TO TITLE OR TYPE OF DOCUMENT THE DOCUMENT DESCRIBED AT RIGHT: NUMBER OF PAGES DATE OF.DOCUMENT Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. SIGNER(S) OTHER THAN NAMED ABOVE AAI A2Tf%nk11A Al 0 MR 1MM^d%-1= A^Wk9^1AIi 1=Md%RA�ILR'r vnaau■ vo as �r�+ �srr a ve se. v�.vr r��,rsvw®�rr,es �Ae�sr�� a rvo. wy3 State of California County of SAN DIEGO On 02/07/2011 before me, personally appeared DEBORAH D. DAVIS, NOTARY PUBLIC MARK D. IATAROLA ® OPTIONAL SECTION CAPACITY CLAIMED BY SIGNER Though statute does not require the Notary to fill in the data below, doing so may prove invaluable to persons relying on the document. ❑ INDIVIDUAL ❑ CORPORATE OFFICER(S) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are TITLES) []PARTNER (S) ❑ LIMITED subscribed to the within instrument and acknowledged [—]GENERAL to me that he/she/they executed the same in his/her/ E] ATTORNEY -IN -FACT their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity ❑ TRUSTEE(S) upon behalf of which the person(s) acted, executed the ❑ GUARDIAN/CONSERVATOR ..� instrument. �Psa°FrtiF� DEBORAH D. DAVIS I certify under PENALTY OF PERJURY under the laws of ❑OTHER: Cn o > COMM. #1737411 R the State of California that the foregoing paragraph is Cl) NOTSAN D EGO COUNTYPUBLIC-CALIFORNIA true and correct. CqFpRNP Nly Comm. Exp. APRIL 21, 2011 SIGNER IS REPRESENTING: ^ WITNESS my hand and official seal. NAME OF PERSON(S) OR ENTITY(IES) Signature of Notary OPTIONAL SECTION THIS CERTIFICATE MUST BE ATTACHED TO TITLE OR TYPE OF DOCUMENT THE DOCUMENT DESCRIBED AT RIGHT: NUMBER OF PAGES DATE OF DOCUMENT Though the data requested here is not required by law, it could prevent fraudulent reattachment of this form. SIGNER(S) OTHER THAN NAMED ABOVE City Of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 Sepulveda Construction, Inc. 233 W. Cerritos Ave. Anaheim, CA 92805 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CIVIC City Clerk JF:pe Enclosure g5PJ l%qnq"@bl1kTMrgoA Waitakere; New Zealand CITN,! C IT Y L ER, K CITY OF T Y H U 7 1 N'G T O."-J 6 EACH HU SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find '91t] MDND in the amount of $ y3. Zy3 y2. which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bid erXftwoture 51 C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 1 1 LS Mobilization $ IS'ODD` ° $ l �—i ffV," 2 1 LS Temporary sheeting, shoring, and bracing $ CZSV'F� —T $ �OI�SU°s 3 1 LS Removal temporary sheeting, shoring, bracing $ v� l l � '` $ v/lO 4 1 LS Demolition of existing muffler room, blower shed and paving $ :76, _T = $ 5 1 LS Grading and trenching $ Z --T YD $ 2-,TYD C'' 6 1 LS Install gas engine, driveline and appurtenant equipment $ $ 7 1 LS Construct muffler room and install silencers $ C//, /OV `% $ W, / OD There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting LS $ -?Ccq;7 ,r $ -7�c E� GL °= Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $ 34 ZTU ''' $ 3� `" Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $ i3' ° $ ! Lam' 11 1 Install 16-inch flowmeter LS $ 6S3D`= $ 0.xf-D ®; T 12 1 Paving LS $-S;� 1 qi�,S-° ` $ 3=, 13 1 Install catalytic converter and engine exhaust piping LS $ 1,6 YLft? $ !L --rvv There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park lust north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 14 1 LS Install engine room roof mounted exhaust fan and muffler room roof mounted blower $ $ —�-- —� 15 1 LS Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation of engine control panels to be conducted by MurCal, Inc $ (/l /W $ r//_ l� VP 16 1 LS Install fencing $ L//10 =' $ V/ID19 '-' 17 1 LS System testing and commissioning $ 6 Z�_ $ E 18 1 LS Clean-up & demobilization $ L/_ //G $ $ $ 19 1 L S Provision and implementation of the SWPPP plan There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. Gl PROJECT BID SCHEDULE Item No. Estimated Quantity Item with unit price written in words Unit Price Extended Amount 20 1 LS Provision of Traffic Control Plan /� y $ L7 V� l�� $ 2�O 21 1 LS Provision of implementing traffic control $ Z.� '!O $YD� Total Amount Bid in Figures Basis of Award): $ Total Amount Bid in Words: r-Qf/L 14L)A)odzey `7zaary Two )tisA)Nn FUME 11dtJ.0rLEPT41 L1-Y IYJ{1J�: Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park iust north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion of Work Name and Address of Subcontractor State License Number, Class DE A40 FAVNO[vWnUC� 1M �7,32D i afvv�c rw uKr n zg r sii (sv A_73:C (Z 9 D S'TE0C. /J-W .-;,, , SL)AffX FE CCAI(T N CO 3 J O�iO CiMl1 NO 1Z.7LT_fVV115T7UQL /y(( ILI6UNLDILv 5T' L73 c,4 8:30957 G-37 a�711 at NEA L Ei.L cnzic nz., Jt'LPICtIL1A( eiY F oviaya) dCL 5n C_ to 141MVIRF ARUI U L rPLA.((DID QJ ' EM P .i 13),M51iV 11ECHM I a L SSA/ 0, Oa'TLAW N Ufai 6))Mo 7-0-5-DIC7 A. By submission of this proposal, the Bidder certifies: That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDEN AND SUBMITTED WITH BID State of California ss. County of Orange (�W �• �--� `� , being first duly sworn, deposes and says that he ore is of Y.c" CiusIoethe party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Name of Bidder _ J Ad re"ss of Bidder Subscribed and sworn to before me thisl*' day of _ , 201 1 �++ HARESH LACHMANOAS SAKHRANI CoMM.# 1752370 ,,^^ NOTARY PUBLIC-CALIFORNIA Yt v ORANGE COUNTY MY COMM. EXP. JUNE 21, 2011 NOTARY PUBLIC�LS NOTARY SEAL C-1 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date::- —a - /1 C-1 SEFULtIWA C0A1_31'7ZUCT7CA1 1111C. Contractor By res ; J1e4,7 Title DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes 4 No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: Z--2-- It C-1 SEPULVEDA Cfff17-ILUCn11N INC. Contractor By Title BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: SAEPUL1160A 667W77ZL/6Y-7O12/ /NC Bidder Name -W-33 0. C-E ZXI7TS ill E Business Address AA/Alh -/M G.4. q�z City, State Zip ( /-Iq ) E,'3 DY`7-1 Telephone Number c-JS� CLL4SS rq /r State Contractor's License No. and Class -7- —3D —LO Original Date Issued Expiration Date The work site was inspected by Ozk✓- L; LA of our office on / .16 , 201/ . The following are persons, firms, and corporations having a principal interest in this proposal: C-1 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. I NIC. Company Name of Bidder Printed or Typed Signature Subscribed and sworn to before me this - day of , 201 f HARESH LACHMANOAS SAKHRANI LOW Comm.# 1752370NOTARYY P�UNBB CO NTYORNIA COMM. ExP. JUNE 21, 2011'� NOTARY PUBLICAQ�S� NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: L. fJ AN6EL.ES C'01JAJ rY -6-1V 1-r-n 77CA/ f 11SiTILiCT. /C/S-i- &JO/LKMpA/ MILL /ZO Name and Address of Public Agency Lt)MV t&K G:A. gCCO/ Name and Telephone No. of Project Manager: 0-5C41L UO/LALf 3/O - Z30- XD S -V ups - OW ` EPMCE FOkCC.; VN 11" EIF FEn.. zDI o Contract Amount Type of Work Date Completed 2. u-IOTVAL.LEV LIAT&Z 01Sr1Z1C.7- ASS lU. 7SI-1SCLIAIL- 4U4L7U !_/1. Name and Address of Public Agency Name and Telephone No. of Project Manager: IM/L/L Y CQin/ ClVe7- ../3 - C/27Y' l,d 60,01D[? 7300S7DLPtJN1'S77J77O1Y 6..2sZJ/JP FaWfS AL16&S'T?ZYJ7- Contract Amount Type of Work Date Completed LDS GNG CLGS 60VAI TV 54N/T7a T717A/ lD LT'17UC% /CIS 6LVfiKMh7/1 A/1/ZL FC/-7 Name and Address of Public Agency UJ+H IT1 UK CA QVC,61 Name and Telephone No. of Project Manager: IVtE L/SSA 12,E&F2 7,15- coo EriLD iSCAf 0V ubse/rt- CZ)NIVcc: 6C" 1V 1-/i7 j /l//- Contract Amount Type of Work Date Completed C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX K) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a quote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this nroiect. The following shall be amended from the Specifications, page 4 in SECTION 13005: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Attention to Mr. John Murphy, ihmurphynmurcal.com -1- v'" gN The following shall be deleted from the Specifications, page 15 in SECTION 04230: ' 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, dated January 26, 11. Company Name By Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. i -2- City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 Notice to All Bidde Please note the fo The attached ni added to the Sr All references t considered as E The following s 15250 — This modification c This is to acknowli �'CiLi EVA Company Name /a3izr - Date January 28, 2011 revision to the project, Specifications. - SECTION 15250, "Insulation for Exposed Piping and Equipment" shall be ifications, within "PART 4 — TECHNICAL SPECIFICATIONS". "Heat Shield" on the Mechanical dwgs (M-1, M-2, and M-3) shall be posed piping and/or equipment insulation as per Section 15250, para. 2.2. be added to the Specifications, page viii in the "Table of Sections": Insulation for Exposed Piping and Equipment not change the Engineer's Estimate bid date of bid opening for this project. ge receipt and review of Addendum Number two, dated January 28, 2011 By All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. �°A SAFECO Insuranee Company PO Sox 84526.-- . Seattle, WA 96124-1526 FIRST NATIONAL SURETY BID_ BOND KNOW ALL BY THESE PRESENTS, That we, Sepulveda Construction, Inc. of 233 W. Cerritos Ave, Anaheim, CA 92805 (hereinafter called the Principal), as Principal, and FIRST NATIONAL INSURANCE. COMPANY OF AMERICA (hereinafter called the Surety), as Surety are held and firmly bound unto City of Huntington Beach (hereinafter called the Obligee) in the penal sum of Ten Percent of Amount Bid Dollars ($ 10% of Bid ) for the payment of which the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. THE.CONDITION OF THIS OBLIGATION IS SUCH, That WHEREAS; the Principal has submitted or is about to submit a proposal to the Obligee on a contract for Water Well No. 10 Rehabilitation Project CC No. 1380 NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within such time as may be specified, enter into the Contract in writing, and give bond, if bond is required, with surety acceptable to the Obligee for the faithful performance of the said Contract; then this obligation shall be void; otherwise to remain in full force and effect. Signed and sealed this 2nd day of February See attached notary acknowledgement Witness S-0053/FNEF 10/99 2011 Sepulv a Con uction, Inc. Prin6pal Title FIRST NATIONAL INSURANCE COMPANY OF AMERICA By� Pamela McCarthy Attorney in -Fact ® A registered trademark of SAFECO Corporation FRP CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT State of California SS. County of San Bernardino ) On February 2, 2011 before me, Cynthia J. Young, Notary Public Name and Title of officer (e,g., "Jane Doe, Notary Public") Personally appeared Pamela McCarthy .�; CYNTHIA J. YOUNG COMM.# 1806614 NOTARY PUBLIC - CAUFORNIA K ° SAN BERNARDINO COUNTY My Comm. Expires July 15, 2012 Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signat4e of Notary P is OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: O Individual i7 Corporate Officer Title O Partner -- © Limited O General ® Attorney -in -Fact 0 Trustee O Guardian or Conservator Other: Signer is Representing: Top of thumb here City Of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov Office of the City Clerk Joan L. Flynn, City Clerk April 15, 2011 United Engineering & Construction, Inc. 336 N. Central Ave., Ste. 10A Glendale, CA 91203 RE: CC-1380 — Water Well #10 Rehabilitation Project Enclosed please find your original bid bond for CC-1380. Sincerely, Joan L. Flynn, CIVIC City Clerk JF:pe Enclosure g9i9m0ii 6ontA*&.pJavvmo* Waitakere, New Zealand 2011 FEB -8 pp; I. -So SECTION C PROPOSAL for the WATER WELL NO. 10 REHABILITATION PROJECT CC No. 1380 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL. OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 100 working days, starting from the date of the Notice to Proceed. BIDDER _declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within C-1 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find ►jB V in the amount of $ which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: 0/27 /II C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For WATER WELL NO. 10 REHABILITATION PROJECT, CC1380 January 26, 2011 Notice to All Bidders: Please note the following revision to the project, Specifications: The following shall be amended from the Specifications, SECTION A, page A-2: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. Shall be changed to: Installation of natural gas Waukesha engine shall be by AGENCY approved subconsultant as a sub -contract to the contractor as defined by the contract documents and Specifications. All construction sequencing and coordination between all trades shall remain the responsibility of the contractor including but not limited to systems testing, start-up and commissioning. If any of the subconsultants listed under the AGENCY approved list (APPENDIX K) decides to bid as a contractor, rather than as a sub -contract to the contractor, that subconsultant must select from the remainder of the AGENCY approved list to perform the task of installation of natural gas Waukesha engine. Furthermore, such subconsultant must inform all other potential bidders who requested a quote to perform the engine installation, and will withdraw all their quotes as a subcontract to the contractor for this project. The following shall be amended from the Specifications, page 4 in SECTION 13005: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Shall be changed to: Installation of engine control panels, instrumentation equipment, chemical equipment, and associated equipment shall be subcontracted to MurCal, Inc., 41343 12th Street West, Palmdale, CA 93551. Phone: (661) 272-4700. Attention to Mr. John Murphy, jhmurphynmurcal.com -1- The following shall be deleted from the Specifications, page 15 in SECTION 04230: 3.16 SEALING A. All block walls, unless otherwise indicated, shall be sealed on the exterior with a water-repellent sealer as specified in Section 07130, Concrete and Masonry Sealer. The sign -in list of attendees of the January 26, 2011 mandatory job walk for bidders, consists of 3 sheets, is attached to Addendum Number one. This modification does not change the Engineer's Estimate bid date of bid opening for this project. This is to acknowledge receipt and review of Addendum Number one, dated January 26, 2011. LANI-MV Vq QPV,51LIISf Company Name By 112r1 1It Date All bidders must acknowledge the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Duncan Lee at (714) 375-5118. -2- PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 1 1 Mobilization LS $ $ 5i Urn 2 1 Temporary sheeting, shoring, and bracing LS $ 55� $S,Son 3 1 Removal temporary sheeting, shoring, bracing LS 4 1 Demolition of existing muffler room, blower shed and paving LS $.' ${ 5 1 Grading and trenching LS $ Z©o $!3,, zon�,_ 6 1 Install gas engine, driveline and appurtenant equipment LS $7�— $ 7i.50O 7 1 Construct muffler room and instal' silencers LS $ 5-Oo $79Ooo There will be a mandatory iob walk for bidders- on Wednesday, January 26tb_ at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Construct engine room roof, engine room/muffler room mansard, control room wall, and install new doors, frames and hardware, including surface preping, painting, and 8 1 repainting LS $140,0( $110 Install yard gas piping, yard electrical conduit, and electrical 9 1 ductbank LS $2go0 $ 2$,000 Install engine room mechanical piping, relocated existing LPG vaporizer, and install piping and valves associated with 10 1 LPG vaporizers LS $7.�i®ob $ 00 0 11 1 Install 16-inch flowmeter LS $ rF $ Ub 12 1 Paving LS $ $ 30,0© e� 13 1 Install catalytic converter and engine exhaust piping LS $(Loon $i 000 There will be a mandatory gob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory iob walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount Install engine room roof mounted exhaust fan and muffler 14 1 room roof mounted blower LS $ .�_ $ 19t0D_D_ Install instrument and controls, cable and conduit, electrical wiring, control panels, and SCADA equipment. Installation 15 1 of engine control panels to be conducted by MurCal, Inc LS $30 $ 16 1 Install fencing LS $,�2_ 17 1 System testing and commissioning LS $ O O $ DO 18 1 Clean-up & demobilization LS $ CO' 00y $�o1�L8SZ 19 1 Provision and implementation of the SWPPP plan LS $ $ 6"IOD cn There will be a mandatory job walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee of the mandatory job walk will proceed to the Well #10 site. C-1 PROJECT BID SCHEDULE Item with unit Item Estimated price Extended No. Quantity written in words Unit Price Amount 20 1 Provision of Traffic Control Plan LS $ $ I 21 1 Provision of implementing traffic control LS $ 14c,o $ I Total Amount Bid in Figures Basis of Award): $ Total Amount Bid in Words: Se �✓P±� o Q %i r _._.................._...................._._. U St Y, Notes: All extensions of unit prices will be subject to verification by Owner. In case of a discrepancy between the unit price and the extension, the unit price will govern. The Owner reserves the right to reject any or all proposals and bid items. There will be a mandatory iob walk for bidders on Wednesday, January 26th at 9:00 a.m. The location to meet will be near 16192 Sher Lane, Huntington Beach, by the City park just north of Sun View Elementary School. From there, every attendee --of the mandatory Job walk will proceed to the Well #10 site. C-1 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. �L&° ) C i I CID c tc By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-1 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange being first duly sworn, deposes and says that he or his of U N ► TIG7p the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. State of California WN (fib�� County of Los Angeles Name of Bidder Subscribed and sworn to (or aff oeed) before me on this day of Feom-odw,20 1� by proved to me on the bas, is of satisfactory evidence to be the person(s) who appeared before me. Signature of Bidder Si ____ -� 3 36 ►� • G� ti1Tl�t,... A-V�. • 4� 1 � f t 6LP- NOALZ- , CA cj 1ZOS Address of Bidder Subscribed and sworn to before me this day of , 201_ j� LAUREL. PAVONE COMM. #1846257 N r'. NOTARY PUBLIC - CALIFORNIA 2 LOS ANGELES COUNTY �! My Comm. Expires Apr. 25, 2013 NOTARY PUBLIC NOTARY SEAL C-1 UTILITSi AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the WATER WELL NO. 10 REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved. " The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal -OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Date: a / g I It C-1 uN1 �T1SlN�7Ll�� �,GSfi� �a3c Contractor F'r-2A- By pis' l nf5nr T Title BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: U H 1-rjF--b INC— . Bidder Name 334 N-C6-�JIVA-PAIE•#►d Business Address G LEN ►5)PNL-V-- G (3 City, State Zip S1g > 1P(P2 - gdss Telephone Number Ib31.62 State Contractor's License No. and Class g13D/0'1 Original Date Issued al -.?>a lit Expiration Date The work site was inspected by W%A of our office on % 1 a.. (P , 201 . The following are persons, firms, and corporations having a principal interest in this proposal: C-1 DISQUALII+ICATI®N QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes ,0iNo If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-1 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Date: 2 d g I �� C-1 UN) 1-r-19 5706) Contractor By P► s J vey3t Title The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. LAOilTTV0 CTIbN�1NG . State of California Company Name County of Los Angeles Subscribed and sworn to (or affiVed) befpte me on this L day of na -A- .20A by-Kn'N F-gTmre of Bidder proved to me on the basis of satisfactory eviden to be the person(s) who appeared before me. �j 1 or Typed Signature SuYsscribed and sworn to before me this _ day of NOTARY PUBLIC LAUREL PAVONE COMM. #1846257 201 NOTARY PUBLIC - CALIFORNIA LOS ANGUS COUNTY �' My Comm. Dpaes Apr. 25, 2013 NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within. the past two years: I. Sf"a ykVKC-Ntp 2. 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Contract Amount Name and Address of Public Agency Type of Work Name and Telephone No. of Project Manager: Date Completed Date Completed Contract Amount Type of Work Date Completed C-1 - ------------------- -- SUMMARY OF RELEVANT EXPERIENCE CITY OF LOS ANGELES, DEPARTMENT OF PUBLIC WORKS 1.A Project Name: HTP VDM Pedestrian Bridge Rehabilitation, W.O. SZH11544 Contact Name: Anita Wu, (310) 648-6243 Description: Remove & Restore Aluminum cladding panels, Blast & Paint Bridge, support structure Amount: $ 457,400 Start Date: January 2010 End Date: On -going COUNTY OF LOS ANGELES, PUBLIC HEALTH DEPARTMENT 2. A Project Name: Acton Rehabilitation Center Contact Name: Everett Bryson (661) 269-7003 Description: Restoration of existing building at Rehab Camp Amount: $102,000.00 Start Date: December 2009 End Date: February 2010 ENVIRONMENTAL MANAGEMENT CORPORATION 3. A Project Name: Clement Pappas Mechanical Contact Name: Randy Jones, (303) 518-5865 Description: Install reverse Osmosis Treatment Plant for treatment of wastewater from Juice Factory Amount: $405,028.00 Start Date: March 2009 End Date: December 2009 3. B Project Name: Clement Pappas Sewer Line Repair Contact Name: Randy Jones, (303) 518-5865 Description: Install new 8" sewer line to tie new treatment plant into City Sewer System Amount: $243,187.00 Start Date: January 2009 End Date: March 2009 WORK EXPERIENCE — STATEMENT OF QUALIFICATIONS ATTACHMENT A SUMMARY OF RELEVANT EXPERIENCE COUNTY OF LOS ANGELES, DEPARTMENT OF PUBLIC WORKS 4. A Project Name: Warm Springs Tank Install Contact Name: Louis Nagy (805) 653-7900 Description: Install Water Treatment Plant for potable water. Amount: $137,018.00 Start Date: October 2009 End Date: December 2009 CITY OF ALHAMBRA, DEPARTMENT OF PUBLIC WORKS 5. A Project Name: Almansor Park Lower Lake Improvements Contact Name: Ali Cayir, (714) 883-8677 Description: Restoration of existing lake. Removal of old liner & placement of new along with decorative rock & landscaping Amount: $446,602.00 Start Date: April 2009 End Date: October 2009 INSTALL INC. 6. A Project Name: White Wave Foods Sewer Line Upgrade Contact Name: Kenneth Cronch, (919) 774-0506 Description: Install sewer line to tie in new Biological waste treatment plant to City sewer. Amount: $95,400.00 Start Date: September 2008 End Date: October 2008 DEPARTMENT OF TRANSPORTATION. 7. A Project Name: El Centro @ Sunbeam Rest Areas Contact Name: Alan Babicky, (858) 688-1526, District 11 Description: Effluent Water Disposal System for rest area Amount: $961,427.00 Start Date: September 2010 End Date: on -going WORK EXPERIENCE - STATEMENT OF QUALIFICATIONS ATTACHMENT A C=CJiV ?7C:`7"I SUMMARY OF RELEVANT EXPERIENCE Additional Experience as Noted: * worked as Project Manager (Reza Fard) & Project Superintendent (John Massie) under PPC Construction, Inc. CITY OF LOS ANGELES, DEPARTMENT OF PUBLIC WORKS Project Name: Hyperion Treatment Plant Primary Treatment Polymer Facility Contact Name: John Hamilton (310) 648-6129 Description: removed the existing primary polymer feed system and installed a new batch polymer system including 9 positive displacement pumps, two (2) 3,100-gallon FRP tanks, polymer piping, motor operated valves and associated electrical/instrumentation Amount: $2.8 M Completion Date: 2009 LAS VIRGENES MUNICIPAL WATER DISTRICT Project Name: Portable Water System Rehabilitation Contact Name: Brett Dingman, (818) 251-2100 Description: Demolition of existing structures, underground and above ground valve replacement, pipe replacement, excavation and grading Amount: $213,975 Completion Date: 2007 WORK EXPERIENCE — STATEMENT OF QUALIFICATIONS ATTACHMENT A 7ua� IINSCO INSURANCE SERVICES, INC. Und~ting Manager for: Developers Surety and Indemnity Company Indemnity Company of California 17780 Fitch, Suite 200 - Irvine, California 92614 - (949) 263-3300 BOND NO: KNOW ALL MEN BY THESE PRESENTS, That we, UNITED ENGINEERING & CONSTRUCTION, INC. n/a as Principal, a ndDEVELOPERS SURETY AND INDEMNITY COMPANY a corporation authorized to transact a general surety business in the State of IA as Surety, are held and firmly bound Unto CITY OF HUNTINGTON BEACH {hereinafter called the Obligee) TEN PERCENT OF AMOUNT BID ---- in the full and just sum of Dollars, ($ 10% ) for the payment whereof in lawful money of the United States, we bind ourselves, our heirs, administrators, executors. successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the said PRINCIPAL has submitted the accompanying bid for WATER WELL NO. 10 REHABILITATION PROJECT #CC1380 NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, or in the event of the failure of the Principal to enter such Contract. If the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and Sealed this 4TH UNITED ENGINEERING & CONSTRUCTION, INC. Principal 0-1198 (tad Bond) (REV 1101) day of FEBRUARY 2011 YEAR DEVELOPERS SURETY AND INDEMNITY COMPANY Suety 11 By. �7G A)�J. "�L Attorney -in -Fact TAMI PRITCHARD CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT T State of California County of San Diego On 2` y '' 1 before me, Stephanie Bondurant, Notary Public Oate Hee.nsert Name acd Tfil ct t`te Of�cer personally appeared-_,_____Tami Pritchard STEPHHANIE 80NDURANT Commission # 1884868 Notary Public - California z Z San Diego County r My Comm. Expires Apr 2, 2014 --- _-- Na-nNs; of signer($, who proved to me on the basis of satisfactory evidence to be the person�a%,6+ruhose name44islem subscribed to the within instrument and acknowledged to me that 4r_,'she+` @5—executed the same in+mr/herAhr%is authorized capacity(4cb), and that by *@�her signatureoFlon the instrument the person06, or the entity upon behalf of which the persons acted, executed the instrument. i certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Fiaca tinta•q Sea.:+.,..,, [i,re a! ,l�ta:y ��atn- OPTIONAL though the reformation, be1Goy I's rot regure> 4 fy law. it may r3✓e rafuable to persons relying on t,7e doourne, t and could oreven! fnudWienl remo✓ai aPo '2at*aCPrrni{r] of this fpr,^ tO ar)LOW d9Cum6nt Description of Attached Document Title or Type of Document: ----------------_- -- - _ Document Date: __ --------__--- S'gner(s) Other Than Named Abode Capacity(ies) Claimed by Signer(s) Number of Pages: I - Signer's Name: Tami Pritchard Signer's Name: Individual Individual Corporate Officer — Titleisi: _-_ Corporate Officer — Title(s)---_-----�-- Partner ,—_ Limited General Partner— Lmiteo .General x Attorney ,r Fact _ Attorney in Fact , Trustee Trustee r. Guardian or Conservator Guardian or Cor,,servator Omer. _ _. Other. ---..---- Signer Is Representing: _ — - Signer Is Represen tic. �';'�.'�•Cz Cz:�lr�r.,GC;�r:,�,r��,Ct Y:� ��t:.,C.t. �S,T: a.,Y�:''{;i'�i- i yf :':r.;,?�4,'-1.c ;�.,�;�`: zY ;�Q`,;;�., ti��C,:fi:`,F�cY .� K:�_�:: Y� �-i.i:,Y �?`t=c`tF <.'.� , _. ?bir.D? v.n�C 3__ -` __'., . _r. _,�. ._ t 1' �. _. v�d i _ '_ '�_ ..•..e" ^al. - r. - �.,, ., ��� POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 263-3300 KNOW ALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, do each hereby make, constitute and appoint: . ***Tami Pritchard*** as their true and lawful Attomey(s)-in-fact, to make, execute, deliver and acknowledge, for and on behalf of said corporations, as sureties, bonds, undertakings and contracts of surety- ship giving and granting unto said Attomey(s)-in-Fact full power and authority to do and to perform every act necessary, requisite or proper to be done in connection therewith as each of said corporations could do, but reserving to each of said corporations full power of substitution and revocation, and all of the acts of said Attorney(s)-in-Fact, pursuant to these presents, are hereby ratified and confirmed. This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, effective as of January 1st, 2008. RESOLVED, that a combination of any two of the Chairman of the Board, the President, Executive Vice -President, Senior Vice -President or any Vice President of the corporations be, and that each of them hereby is, authorized to execute this Power of Attorney, qualifying the attomey(s) named in the Power of Attorney to execute, on behalf of the corporations, bonds, undertakings and contracts of suretyship; and that the Secretary or any Assistant Secretary of either of the corporations be, and each of them hereby is, authorized to attest the execution of any such Power of Attorney; RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any cerfificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures shall be valid and binding upon the corporations when so affixed and in the future with respect to any bond, undertaking or contract of suretyship to which it is attached. IN WITNESS WHEREOF, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respective Secretary or Assistant Secretary this January 1st, 2008. By:_� % .. { AND Daniel Young, Vice -President p #q��s,�y Y O 10 By: «c+ 1936 o. Stephen T Pate, Senior Vice -President ' s State of California County of Orange On August 13th, 2008 before me, Jenny TT Nguyen, Notary Public Date Here Insert Name and Title of the Officer personally appeared Daniel Youno and Stephen T. Pate Name(s) of Si ner(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) islare subscribed to the within instrument and acknowledged to me that helshelthey executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed. the instrument. comm. #,1791 NOTARY PUEiW CrrM.11I I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is OR"E COLOTY true and correct. itRjr CQtittR. evilres ftL 110% WITNESS my hand and official seal. Place Notary Seal Above Signature --- Je TT Ng n, ary Public CERTIFICATE The undersigned, as Secretary or Assistant Secretary of DEVELOPERS SURETY AND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA, does hereby certify that the foregoing Power of Attorney remains in full force and has not been revoked and, furthermore, that the provisions of the resolutions of the respective Boards of Directors of said corporations set forth in the Power of Attorney are in force as of the date of this Certificate. This Certificate is executed in the City of Irvine, California, this y'kdayof J421IJ�Q / 0 By: "`` J� regg Oku�,,,WtSecretary ID-1380(Rev.11109)