Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Hondo Company, Inc - 1991-05-06
t L.,1 • 1'.ly�ln � F to Min . r it to 1 tf40 7 ifti,r ti , 1•,= 1 � t�. 7 a r 17,•Iti, ♦�r '� ( .1C � �d . rl�r t'? ��11 �• �� CITY OF HUNTINGTON BEACH t� •; ,. ' t, • � H*7 INTER-DEPARTMENT COMMUNICATION { 1 to , -f To THOSE LISTED HEREON rrnm ADAiINISTRATIVr SERVICES Accounting do Records ''' Subject 10y� TTTION PAYIXNT Data off 'z The 'conformed copy of tha Notico of Completion for the above contract has teen filed. Theµl_ r o thirty-five (35) day waiting period has elapsed or will elapse before payment ',s made. f.j Processing of the IM retention payment is rerommended so long as no stop notices or outstanding invoices are on file with the City. ,,`r\ t y lw},\t ly���{�•re' r''C DAN Tt LLELLA Director of Finance c' ' 1 �'; "► „(IDS !. .;; ',t' 7r t� ° � .1 I certify that no stop notices are on fi.e on the subject cor.trac t this time. •r}t� L' Date:"Iwdi;�^r i LOUIS F. S DOVAL :; •, �� 1 , f , ` Public Works Director 1�" f;'tk ".�•' ;'r I certify that no crop notices are on file on the subject contract and that a guaranty, bond "�4;� ;R',>�i<jtir t � ;� ,,: has been filed. � }/+ 1 ,�•'1: �',' It t'y,� �r. • 4 � � 1 Y� 4 ► r i �t. , +tit • Ddte: CUNNIE SROCKWA ., ,y 7I.1�t� �� `,.�,' . � '�� •� Li Clerk �� r• • , 11 certify that there are im uuts+anding irvoines on file. �•;' t. to L �� � ,.`•� . 1 f� ,� �4•. eta r j Date: , DONALD WATSON City Treasurer 31r' "�t f��:�tt�^, 5j��t►tr� ,ir. I�r�t t � "� 1'7' `Jt/ .:1� 05741 # S t!r�'/�Lt �i7 L ?!'%* 1:', , �r-: fyS:{ ;r;+�'�i \��'�,+ +!••� i, � ,L ' ' - 1� I a • t.��r•Gj'J�J'i 1 � 1�I r 4 . It ` 'A 1..1 IM°• t'r ,!// ��..-'r Y /'••�tR)Yr4�'..'Ij t!i. L.'w, t _..,r.r.' -... `- 'T.� ....... _ ._. _»..�.o,.... �� 1«-..7.7...1: -n x> �' IJ:k •!! r 1 :� � �!� '` '/.��",� ' �r �` J li '.t `��� Lr - .l ,� r i , '�* Y•. :A .:�', ail.,,✓ :1 '� ��. l�P�".�,. Y (!`" s :''<. t 1 i �: i ! -. w ' ,I, `• -'11- ', i' .. •1 }' 1 1 ' ,�' .';• •rl7 � P Y,,„ i.; -.,yl �j�' ' }'' �t: i�,55'' f Zy c. +� • j�' • •'! S'.�1 :1� +tk •t•r i' Jx 11'',.. � 1<j..'1 :, iy ��''` ,+ll�� I �f }.. rf a�t• ,a�. :,},, 1 r�E. �1_ 'Y +t' 1;: ;5••,. ,1 A"{ .r •��t0^JF� r�ll,.g. n. �. 'i� " fi�'t•j't,1',yl(j�fc',h,.•!'� ''•+dl 1 •'`,1., tS..'•1' +�,=7 t I�•.'ik a�• 1 1 _ ;, ,1• 1 ;� �JI { ,1� 1. ,e.' ,�Ll",^. Ji' �� 1. • MJ 1: '� �'f' fir ., .� � d � ��, r 1 Aft rr°• �'. � '/ r •t lE.� � t,, �,. 1. ti' •� 1�•�, . t:l .,! +, .. 1. 1.: .• '�, '•1 i.. ..�.,C , f<` 71 :i�' t�,t•1.' }'r' itl 1 •'LN • /?+�� '.1Y,j"4)it� t 1'. .i ,i�`�1'It' •.'yt 1,)t.`.�{�1}�r .ra�,,�.'ii :R`.;1 VMLi�v f ••��..{•'�.. .G�� ��ii i Tt' � •�4/ �'/{�',+,'I,C� Ir ' :fir, µ%. t f,l� ` 11 1r, t3•.1 ! :`l 't + '.i + 1 t ii. �'t r-'li�Y•r 4�T��} +•1�' ^ tt �.i���� :t,.�• �, �'. LI. 1 1 1•p L ;, d `... L •aedr ti .1,f '1 . ' rt11 ry i l.: !� r { r a{i ti c c. 11 •! r ty,'}�1, ''y L::. �, Ifr�' 11. •# I "�. rr Sf1. 'r 5�11.`t�• +r 1 •7+, yr. 1}�•li�<Fi ;• t N,14 }: it .1 1r '�" r, T r'- �' 1� tr. ',�i.�`(•l lyir�`'T[`� -.M �ti �t M. �i 'd `�j ..S)• i J-',:' ( 1. ... .• r-i^ 'ir �Iil�l fK�*•'r tS'1'�,) r lf�+ (;! �T i •��• rj, 'iin J•,.,' '' �{f. VI, `� '' !'. ,� ;+, +'.. (1 1 � •1•.i'. . r. .,,(',C . + ''� r it�'i '�• 1 Hr . ' /• ,r .. '11 , r7 �'' L 1- .�t t{. ..rl..:\tl {1%rJ, d �5:• '' i�3 1 1 ! t f �! ' ' ,' � • t , 1 5,. ' i. ,.! ("� � t 1, r rL i, tl {r'' ` 1 i+ti t ,i� J,, +.. 11' J ,•i r: t+:,tf+t�: , 1 Ir• 1 •. �11 • .January 28, 1992 Ef ns !!!l.er 11gr COh'tl aoiS z1?1 S; xah [�%X) S'avl tiziul( Ant, CA -MITI; 7W •1.1. -0MW FAX 71.1.11.1.1116 1, .I II 1 1 ,r. City of Huntington Beach Department .%F Public Works f P.O. Box 190 1{untingten 'Unch, CA 92648 1+ EAttention: Randy Huttenberger �.� Subjent: Ce. ;ificaticn of Comrl:anue with Ti,4. TUle VII of. the C!vil Rights Act and Equal Employment Opportunity Act of 1972 ' i Gentleran• > .. • l: Y7 l The undersigned, contractor on Project No. CC-803, Landscape Construction on the Handicap Play Area in Central Park. hereby certifies that .111 laborers, mechanics, apprentices, trainees, taatchmeii and guards employed by us o' any subcontractor performing work under the contract on the project have been aid wages at rates not less than those required b the contract provisions, p 8 q Y P and that the work performed by each such laborer, macnanic, apprentice or V•• ; trainee conformed to the ciasaifications se:. forth in the contract or training ��a 7 , ' t�• , ` V ,i y - program p•oviaions applicable to ::Le stage rate paid. RONDO (.:l:iPANY , INC. }�} "1 Vil Michael Woods, P e den yr I •i �,I�. � ,,. ('.. 4•• i It. ! ,t,';. Robert Lloy , Secrelk ary/Treasurer , , r T , f / c { I , . l t, v 3 !Al r 1 - il`, I .. t. r y i"T .l•'r :..r•.... ._ -: 1 "7 .�•, .�. �` 'i J,"tl';,. �!^tr. .. ,.. �.t1�1' �13r, •• r . ,: .. c:;tiirii.�t „y�r 1. `r.y. •' , •,Tn.,... i. ,. ,j.l f •.! �(• ,, -.,, rlf,,,�i:kr-:'f-'x�Cr.Lt. .1 r.�,� .:�.L r:A1, ��r -•••;c} �;� � � ��,• S j \fi}I,'C ( r.) ;•i. - •• •�, ll,`,1,1 ;t� .; (�/�l r�N L• ,1 i t,, '. `• ('fir kl I -'i I T,, '• / I _ I 1 I .1� ',-s1-�' l �•%/,4, , l�� ���1��;(J' \S ' ,' • •. ,. • , ,. \y}\1 ?{I �'i .1 - - _ 1 r ',•ill lh r,, 1 1 , ,! t I t t 1� '�.1 {i �t Mi :}� , J , . 1. COMPANY 114C ! I! I ti(x1111 i►C xl Slllr'I t 'tillutlr�l�l,l.A'171?� I 71•1.11.1.OKM I Jai%Lnry 28, 1992 frk\ 71-1-11.1d1115 1 ✓ Statement of Satisfaction of Claims i With regards to your proj9ct, Landscape Construction on the Handicap 1 Play Area 7n Central Park, we do state that all workers and pereonn employed, ' all firms supplying materials and all subcontractota upon PROJECT have been ��.,'► I paid In full and that there are tic claims outstanding ugain-;t PROJECT for I either labor or material, except certain items, if illy, to be set forth •' in at. affidavit covering df.oputed claims, or items in connection with Notices to Withhold which have been filed under the provisions of the q'' statutes of the State of California. HONDO COMPANY, INC. . H o el oode tegi 3 t 1) ►�.� t p Roberr. I. ayd, Sdcr tary/Treasurer �, .�• r rs1 r �.,..� .wwo — - STATE OF CALIFORNIA 1 COUNTY OF Orange 1 1-27-92 b h Y1 efore me, t e undersigned, a Notary Public of sLid county and state, personally appeared Richard C. Lloyd , personally known to me (or proved to (' me on the basis of satisfactory evidence) to be the person whose name is �gubscribed to this instrument as the attorney - in -fact for_ neat: American Insurance Company r and acknowledged to me that he (she) stibscribed the name on !' behalf of the corporation therein named as surety and his (her) own name as attorney -in -fact. Witness my hand and offical seal. ; �•, r,�r�crrun�c.cx►oarw Notary Public -State of ifornia �1;, � o:a�a►cave '--aver-v---ra••yt r M I I ' SCNT .%Y:t1rt4AT AMERICAN WEST i e—"I -a0 10: 10 i 71474037r0 s 714 049 0050:17 2 I OhtAl Alf[A1GW tteUMJIDE ppu1LA { 11NtNCMJ 1{ATipKl r. /tt 041URMCI COIDLW . LUIRICali ALLlr1 U 04LAMC11 'D0u'drr. AO+.:j0UW INgUO&Ncf wu{Ah► .. _ ... tnA+sa n {utlkINr l!r{.In{! f71!!ht1M{1r'1k. 1 •� Bond No•3503080 GUAT AIVERICAN INSURANCE COMPANY ,,. ►o roe 't•r\ JL MAINTENANCR BOND G ►t• �r lou G hil' C1 %`� ptt�rnny ALL MLN BY THESE PRESENT'S tltatwe LNOW A Hondo Company Inc. as Principal, and the GRISAT AMERICAN INSURANCE COMPANY, a corporation onitmizid 'tnder the laws or the state of 01110 and duly authorised In trantaC au►Iness In the Stitt of California u Surety. are held an! Armly bound unto City of Hunt,.n ton Beach r ,tit y1�4. Y Y u Obllgee, In the suns of `? Irl Fifteen thousand three hundred sixty nine dollars- DO!1ARS, for the ptvment wltereor well and truly to be midi, the Principal and the Surety bl!.i themselves, their help, exccular:, adrnlnlsiraton, tuccesturs and asslgns, Jointly and teveraliy, Armly by thane presents. SIGNED, sealed, and doted this 27th day of January , 1992 WHEREAS the Ptindpsl and the Obll=at hive entered 'Into a written, agr_enlent dated the��. ' 5-28— day it , 19 92 ,tor Construction of Hundicap ppia area �f 'r ; ' �� , the terms of which P.greement were completed Ane' accepted the ploy of r 2. , t .l9 ;and �: 4,.}•' a .��!t.� %HEREAS Or Principal has given r' One year inaintenaurce SuaranIL4 undo: said agreement or otherwise againht detective,naierls)v And tvorkmanshlpr NOW, THEREFORE. the condition of this obliwtion is such that If the Principal shill well and truly comply r' with such aur:antae, then this obligation to be void; otherwise It thOl ratnAln In Nit torso. 1` PROVIDED that no riot of action shall accrue on this bond to or for the use of any person of corporation r1R other than the Obllite named herein; and PROVIDED FURTIIER Viet the Surety shall have no liabilityunder this rand unless the Obligee A&D give � , y i`.t �+';�: ! _ written notice or claim or the IP6ndpal c fallute to comply rvr•;t such }uaranteed to the Surety at Its Administrative l O(Tlce at SOO Walnut Street. Cincinnati, Ohio 45202 such notice to be Ewen within thr One year r, , ��� a �' r t: malnterltrice period.►�';;,;�i , :l. Honda Company I ' r, art ` Principal � � rti,t ; r;. •; dL C:,i=ntaritgiied: �/�//%� '.., tt S: ,► r.tjr1 !yam �.. \. s t GREAT AMERICAN INSURANCE: COMPANY I t 1 Ry.�.,...��...� by ` ; !tnrhirnr A�trnl Arrr,n,r n•F'arr ' ' � If >>'7�.1,� .� r* r f.fIFO1C•'� �/1i Nnn{M fn l•,.A.A Jl k i. , 1t '9�, i'• J 1; 'i \Y�,') tf.; I „ 1� 'j ',.• f..` !� .. II i4 rs i.n N)fr '��Ls r , i ill /•� f, i• el �., '44, �V,4' ' r 1. .{�' ; - • , • I' r:1`\, o�� •• : ,� a �,' �y��4. ..,( f� 1� r _ j I 1 ,..\ ••y =a 1 (( t t i 1• 1 •�I 1, 4 .1 j'r;�4r: i.,l`�i �`.r rr,�•'I i.. , tr ,. .' r°If)i• '��'�!^i \e't •' A �..'. ; SI l.l!'• ij�'-s�+�,�,r�lsrj ,V,, ) ! i�r rjr ( II } ,' t" �.t'' {. \ .1? ai,l 1 I'. fi i 'fi1��'i t • q � .15 1. 1 jtr i• .rYL'.1-i. n.w.,\.�La.nr. .. r... u..,,.\�•l_r.. . ,, ._ .... .. _......�_..._. r..-_ GMAZAIVERIGNN INSURANCE CONVANY The -.comber of rencns suthotitrd by th;s power ut'attorney Is not more than No. 0 13194 ONE POWEP OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY, aeorporalion urganired and existing under and by virtue of the laws of the Stott of Ohio, does hereby ;tominate, constitute and appoint the person or petsons named below Its true and lawful attornt:yin•fact, for It and In its name, place and stead to execute in behaif of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations In ltte nature thereof; provided that tlic {lability of the fait] Company cn any such bond, undertal:ing or contract of suretyship execated under this authority shall not exceed the Iitnit stated below. Ncme Address Writ of Power RICHARD C. LLOYD IRVINE, CALIFORNIA UNLIMITED J, This Powerof Attorney revokes all previous powers issued In yehalf of the attorneylsl•in•hct na-ned shove. l ; j IN WITNESS WIIEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate oiYiczn and its corporate stal hereunto afllxed this 13th day of Jul y .19 90 Ai!est GREAT AMERICAN INSURANCE COMPANY i r,, It •t�' � - __. fir! .' .• jSTATE Or OHIO, COUNTY OF tIAMILTON — ss: ` On this 13th day of July$ 1990 , before me personally appeared WILLLIM 1. MANEY, to me known, being duly jwom, deposes and taya that he tesided in Cincinnati, Ohio, that he is the Vitt President of the Great American Insurance�,r� S r Company, the Company described In and which executed the above lent rument;that he knt.:n the seal: that it was so affixed by authority of r' . it ` 4i. � 'lk +� 3 tI ( his offlet under the GyLawsorsold Company, and that he signed hit name thereto by like authority. • � is t This Power of Attorney is Smitted by authority of the following resolutions adopted by the Eaard of Directors of Grea; y American Insurance Company by unanimous written consent dated August 20, 1979. �•, �, A, ESOLVED: rrisat the President, the several Vice Phrsidents area Assistant Vice Presider, rs, tr any one of them, be and hereby is u ` authorised. Irons time to time, to appointcu one nr morr Attorneys•Jn-Fact to exer. bi behalf of the Cumpzny. as surety, any and all bands, undertaibGip and eontmetr of suretyship. or other wdrten obligations in the nature the►eo ; to prescribe their respective duties acid the retlretetire IUdn of their ewhodty:and to revoke any such appointment at any time. {, ' RESOLVED FUR 7NER: 77wt the Company seal and the sianarure of any of the afonsald officers may be affixed by fat.-simde ti T r to ony power of attomey or certificate of dther liven for the exectrtlon of any bond, undertaking, contract or surerythip, or other : i f( i written ..bligrttion in the raeture tkerraf. sulh Qrurtutti and seat when to used bring hereby adopted by the Comlxtny as the ud#nut 1 ( towture of such officer and the tied/ hd sail of the Company, to be r•alid and binding -upon the Company with the some force and effect a though rnarrually affixed. 1 , CERTIFICA1 ION >> 1, RONALD C, H AYES. Assistant Secretary of the Great American insurance Comrany. do hereby certify that the foregoing t Power of Attorney and the Resolutiors of the Board of Directors of August 20. 1979 have not been revoked and a,•e now in full fore: snd tl1 .3 ' i efYet.1. !►. �� � t r t0s, ,r . y� Signed and sailed this 27t b day of Jttttuah� . 19 92 \ { ,rt t. •+MMtir.LK7A1Nti;:4'7fSQ'f'111 :}\7..: t�P., l.n.. cN17. J1.� :L,.r';r. .... ,. .... ..: \.:+.. n..n.�+r.....-.(i-nrcV _.. RC•iir• Mfi (Ia !r ., ,� .T.,•w.w ,,,'•. ,glees �� r ♦.` 1 f � -1 `; , i r H •I 1 . � tr tr Y� r� r , " 4,vt', L : .waiOal�Qt�,l«•wsw•w.. n..," ... a .r,. „4 _ • .. r1 WHEN RECORDED MAIL TO: RECORDED IN OFFICIAL RECOr^'� OF ORANGE COUNTY, CALIFOfial), r '' 91 -7QT 185 "f CITY OF HUNTINGTON B CFI 11:00 UEC 11991 Office of tine Cit) Clerk j P. O. Box 190 1 H{intinvton !_lr.)ch. Calif. 9260 „ mot, Otte 64#4&UREcons NOTICE OF COMPLETION NOTICE IS HLI,�'BY GIVEN that the contract heretofore aw3t•.;ed by the City Council of I� the City of Huntington Beach, California to Hondo company, 2121 south Lyon street, ! Santa Ana, CA 92705 who was the company thereon for doing the following work to -wit: —�tI•• _ �.'`,• lands -ape coustructla:; on the tlandicnp Play Area in Certral Park, CC-803. $ Owneri City of Huntington beach p9dDi �' • - oa NM $ ' 2000 Main Street Huntington Beach, CA 92648 �� r Other ' Site: Edwards and Centrnl Park Drive TOW i �� i Re a .'� Nature of Interest: Park improvement t PCO DMF ` .t r RUE• 10 That said work was completed by said company azcording to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and f; that said work was/acceptedbyn the City Council of the City of Huntington Bach completed at a regular meeting thereof head on Monday, December 16, 1991 That upon said contract the t? Y Great American Insurance Gum an ' was surety for the band g i van by the sa'd company as required by law. i Dated at Huntington Beach California this 18th day cf December 1991 ; +r r'City Prk and ex-o fic o er Yr� of the City Council of the City of Huntington beach, California 1 , STATE OF CALIFORNIA County of Orange ss : 1 f City of Huntington BeachzA ) rl�_•• 1, CONNIE BROCKWAY, the duly appointed and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington Ceach, Ca 1 i forn•ia do hereby ti, �1''�l` • r certify under penalty of perjury, that the foregoing NOTICE OF COMPLETION is tree and correct, and that said NOTICE OF COMPLETION was duly and regula, ly ordered to be recorded in the Office of the County Recorder of Orange Cuunty by said City Council. ,� i. • ., r r , t • �.. , i ,f' Dated at Huntington Reach, California, this 18th day of December 1991 t, c� ;, � t.Ml _ it ,� t a •�: -•'r. 0 This document is solely fat- the official business of the City E. rar 1,�1;jHsrG I ' f;�+� of Huntington Beach, as contem- ,r11r�� �s �r ;i plated under Government Code Ci t erk and ex-offic Y io C1 er • , ► sec. tiI03 and should be recorded of the City Council of the City t i'1 �ir r1 Mr, ,. r t srti,lr"� �,�f�ti, rT r. 3a� f y :y free of cbarse. of Huntin ,ton Beaus, California i F' /rt � „ ` • � � _ ,� r , �'� r A1, t�• Y • 4� 9 : � � y �w� r .....r„-..............�,_.- ,,..-.,,mac., •,.vim• - . .. ,,, „ . I .. � � � ' � ��� � •'r' {i 1 I �/ -. 1 :s '17t �'T.�1'arn:n!.'•.r.. r Ht; saa..l* +' •i�R._/;�i�dw iRY." TAT/'.:I}rlwarvrr.+•n!•r, ! 4�, 1.. (:SC 1 r ,V r? "• IA. l , , • ��rl�''^ • • ! - 4 I, '> EST FOR CITY COUNCIL. ACTION, ! �•� �- j, REQU Date - December 16, 1991 , APPR01'EA BY CITY r,OUNu,,. ♦+'; Submitted to: Honorable Mayor and City Council 1 Submitted by: Michael T. Uberuaga, City Administrator �" ty•1 f 1 Prepared by: VA .outs F. Sandoval, Director of Public Works Cl Subject- Subject: CONSTRUCTION OF HANDICAP PLAY AREA, CENTRAL PARK; CC-803 Consistent with Council Policy? O Yes O New . olicy or Exception X t Statomont of Issue, Recommendation, Analysis, Funding Source, Alternative Act=ons, Attachments: STATEMF.N1 OF SS 1 1f If , t 4 Jv !\ Hondo Company has completed the construction of the Handicap Play Area in Central Park.zw �t1 CfJa Accept the Improvements and authorize the City Clerk to file the Notice of Completion.. ANALYSiS: �} On May 6, 19�91, the City Council awarded a contract to Hondo Company for the construction of i the Handicap Play Area In Central Park. The construction of th_se Improvements are complete per the approved pions ar_d specifications. The following is a summary of the contract costs; ! Council Approval �q E2We .IIIIIL� , . •� A to 1 en Contract Amount: S 131,699.35 140,229.03' r Construction Contingencies: $ 1�,62Q,QQ TOTAL: $ 150,369.35 148,051.43 Actual field quantities for clearing, q g, (,►ruobing, demolition, exported soil, A.C. paving, '=' ►"17a ` �,�,ti4�r ,- •:+, headers, and the irrigation system were greater then estimated. ' i •* Construcdon Change Orders included conduit relocation for existing park lights; lowering of irrigation controller; additional hand rails on dock; removal of trees which interfered with location of walkways; additional plants, wood chips, and a concrete mowstrip on the slope created by lowering of dock; relocation of an electrical pull box; tamper proof : coating on bolts; and additional catch basin and drain line along side dock to prevent erosion. FUND G SOURCE: Staff budgeted $165,000 for this project In fiscal account No. E-SK-CS-601-6-39-00 (Handicap ' Play Area). A►LTERNAIM ACTTi �: N/A MAC HEM: None t � MTU:LFS:RH:gd �'•' , ''1 7c?� , Ilf 3117g%14 7 , PIo SIBS t� ,•. 1 ,: .' '.• I _-. -.�. ,•-•* !'r, '�' +;;. .r .:a: c r 'rr.^ia.,-:atr+rr:�•�.•s1� r{.' �1,: `'• 1 . 7 . t,t �7 i" .. S.t�Tlfl �, \/lira • , fit• .r:r, ;iyc. r - ill �•.,t •, ul iQ .•�• ' (Y a ` a''�' .1 r 1J'- �6i1 y`�.`�,f r i ' 1 `•� 1' /1 :' I' `, -y(J • • y; �x.7 ;' 1 •'� ris�j.• `L ' ,- - ` .,.. _ 1 rat+ a�: - I'.x•. , i As: YJ YL 6 have received the Faithful Performance Bond and the Labor and Material! bond for Undo Comnany. Construction nandivap Qla r area, 11CP, CC-803 on behalf of the Tripasurers Office, All AV' Of. '4 Dated__ i, P-D T, Is— A 4 T,! • NIX RS 10 01 f , •-: - •' -- « e.,,, ♦ i .. t1L1L1-..lr at.,w.rW11 ,!•� .. 11 �.�.j,�/.�.�i'i4►�01�rr.NYY.f�•�MMF.i1f�I'./R...'t. �31N14rrLM.NM.�w•ti.n+.MY...-.. _.._.... _.. .. .... ..... _..,,r-._-.. ..-r...�.. � I � T,�,.•r ' i '1 fit. , .f• 'rc• . I r 111, `7 •i — • Bond No. 35030 GUM M&IOG W INSURANCE COMMW PERFORAIANCEJLAP R AND 1IATERIAL PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS, That we, (hereinafter called the Principal), as Principal, and the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and exisCag under the laws of the State of Ohio with Its principal office in the City of Cincinnati pphlu (,?reinafjer called the urety), are held and firmly bound unto lrity o. Hunt ngton Beach XftOVM AS TO FORM, (hereinafter called the Obllgec), In the jest and full sum. of GAIL HUTTtON, City A'ttorns7 One fifty three Thousand three hundred sixtRyiti eD 35y Kesttoraoy Dollars, to the payment cf which sum, well and truly to be made, the said Prinapai and Surety bind t selves, and their respective heirs, administrators, executors, successors and assigns, jointly and severally, firml these presents. ' SIGNt-1, seated and dated this 17th day of May 1991 WHEREAS, the Principal has entered Into a certain written contract with the Obligee, dated the xr day of May 19 91 to ,, The Construction of Handicap Play area, Central park, Cash contract 803 - which contn.ct Is hereby referred to and made a part hereof as fully and to the -ameextent as IIrcopiedat lenth herein. ' NOW, THEREFORE, the condition of this obligation Is such that, If the Principal shah faithfully perform the work as specified in the contract on his part, and shall fully indemrlfy and save harmless the _ Obligee from all cost apd damage which the Obligee may suffer by reason of failure so to do and shall fully reimburse and repay the Obligee all outlay and expense which the Obligee may incur in making good any such defrilt, and shall pay all persons who have contracts directly with the Principal for labor or materials, then this obligation shall be null and void, otherwise it shall remain in full force and effect. PROVIDED, HOWEVER, it shall be a condition precedent to any right of recovery hereunder that, l In event of any dcfault on the part of the Principal, a written statement of the particular facts showing the date and nature of such default shall be Immediately given by the Obligee to the Surety and shall be r ' ft ' forwarded by registered mail to the Surety at its Administrative Office at 580 Walnut Street, P.O. Box 2575, Cincinnati, Ohio 45 20 1. AND PROVIDED FURTHER, that no action, suit or proceeding, except as here;nafter set forth, shall be had or maintained against the Surety on this Instrument unless the same be brought or instituted and process r. irved upon the Suraty within twelvo months after completion of the work mentioned in said contract, whether such work be completed by the Principal, Surety or Obligee; but If there is any maintenance or guarantee period provided In the contract for which said Sureov Is liable, an action for maintenance may be brought within six months from the expiration of he m tenance period, but not L Tt i afterwards. 1 Hondo Comp c. 1 :,,,, r• _ melee tt' GREAT tElt AN IN 4iPANY 4 (RPANCr/1". u 1 1 u,,,,il'-•,f, ; Richard C. Lloyd�rin7fier�n% it ;AMJ m re f 64 — 1 �• , 11 ., 3µ.�, tip ��t.. .•etc. ,, t, N�' I t .w y ' 1 l i7 ! t, ! ,, ►1'r.rr r�, �K 1 F l y tlI' 1yyy.% ,'` Yllf' a /��s� µr 1 �t r r �• t � •'U1.S �f 7 j (�■ t r... _ ,. 1` �y , �i.� /�K•,� � .I �',T�T�,Yj i, ly { ..y k� f i� 1 R r i �' �, � i .� '•I ' ,� + , l -..f C Jl jr, ��. ,' ` 1R1�� ! i. r '.i ` IsIt � ��'„. J L� • •. J, I ,/ �tTL 1�' Y\ 7tf �%tI`e ir(r` ` , t , ! .,�I \, 7IL`����{r �� y , ��l i r ' k 1 ,; t ♦;'+' 'i,' j�! }fig rl •�l.''i, Y.b,�y l , }( 1 •.` � I•, fY •v + 1 r.-, ' �, � r. ', 7.� 7 r r�•/,++ f.k* r ', �)� �r ,.` ,r:' t-' �+:i�llL,► t,f't 'r' f�. \.-. r. :.•• I ' , 'r �.r r�'' ti�%)'L ., � ^ .44 �► a `1 ! } 17 �:��"1' !ad, 'i!„ tr"1 �, � .1. ! l+ 7 - •+, � ,• i 1 � :� { \ •'3�,�� t` �'�� `'j •��; ��w�y 'F ;� 1 �'.�1 ly,, 1, , 1,�v �`t+r 1 .� it 1�t'7' t ,• t�y,l.f��'., 1 YY 1 1y PL rt � : r t } lJ +.7 t•j'�%1! r 1, l\ t• ` ^' ' + I. � t,�t '1 tt■ . . .te- . , , . . I r-.. ...s>.,..,.....,-. -I -.. 1.11-- .-... -.".,A � 0 ctEATAnEMc;ty iNsuRwcE COMPANY 'tr T' The numbet of persons suthorited by this power of attorney is no! more than No-0 13194 ONE POWER OF AT. ORNEY KNOW ALL MAN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY,acotporation otganited and existing under and by virtue of the laws of the State of Chio, does hereby nominate, constitute and appoint the person er persons named below Its true and lawful attorney•ir.•fact, for It and In its namz. place and stead to ex -cute in behalf cf ih: said Company, as surety, any and aU bonds, undertakings and contracts of suretyship, o; other written obligations In the ^..ure thereof; provided that the liability of the said Company on any such bond, undertaking nr contract of suretyship executed under this authority shall not exceed the limit statea below. N dd I.! I f P tine A rags m t o ower RICHARD C. LLOYD IRVINE, fALIFORNIA UNLIMITED I` M Phis Power ofAttomey revokes all previous powers, issued in behalfuf the 21torney(s)•in-fact named above. j 1 IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COM°ANY has cat.sed these presents to be signed and attested by Its appropriate officers and its corporate seal hereunto affixed this 13th uay of July .19 50 Attest GREAT AMERICAN INSURANCE COMPANY �� 1;1, STATE OFOHIO,COUNTYOF11Ah11LTON —sr: 1 On this 13th day of July, 1990 . before me persoaally Lppeared WILLIAM J. MANEY, to me known, being daly sworn, deposes and nays that he resided in Cincinnati, Ohio, that he Is the Vice President of the Great American Insurance Company, the Company described In and which executed the above instrument: that he knows the seal; that It was so affixed by authority of hit office under the By -Laws of uld Company, and that he signed hit name thereto by lik3 authority. a , This Powe. of Attorney is granted by authority of the following resolutions adopted by the Boatd of Director of Great " American Insurance Company by unanimous written consent dated August 20, 1979. RESt7LV£D: That the Presldcnt, the several Vice Presidents and Assistant Vice Presidents, or sny one of them, be and hereby is authorized, from tone to tim_, to appoint one or more Attorneys -In -Fact to execute In behalf of the Company, as surety, arty and ull brands, undertakings and ccntracts of suretys.'rlp, or other written obllgtrtloni Gr the mature thereof, to prescribe their respective duties Jf and the respective limits of thdr authority, and to revoke any such appolarmeht at any time. RESOLVED FURTHER: 77rat the Company seal and the signature of any of the aforesaid off leers may be ef/Ixed by facsimile j to any power of attorney or ceitifint. of either given for the erecution of any ::and, undertaking, con!rsrct or .wretythtp, or other i?;1 %ritten obliptlon in the norure thereof, such slgnature and seal when so used belnd hc;eby aduptea by the Company as the urigittal '• •ystgnature of such o ver and the jJi eviginol seal of the Company, to be valid and bincing upon the Company Hith the some force and effect h as though nunually affixed .1' CERTIFICATION 1, RONALD C. HAYLS, Assistant Sctretary of the Great American Insurance Company, do hereby certif,• that the foregoing Power of Attorney and the Resolutions of the Board of Directors of August 20, 1979 have not been revoked and are now in full force and 1 effect. e t,, t t 17 th May 91 Ir, ' Signed and seated this day of .19 .I t 1 s ;11,11 ): t. r+J 1 1.' Ill � 1 _ . .. - _ _ .. _--....—•'"•+4' . a z.:;n ^-'7�+1lrit13't ' �+ ` � fit'' (f t i ', r y a ] 1 �' .•,, t '.� fitVb- S lit `t. 171� tT, RN 4 A 0 -11 all 4 14. A A A -it% .50A"44" CITY OF HUNTINGTON BEACH 2000 MAIN STREET CALIFOi;NIA 32649 OFFICE OF THL iNTY CLEAR May 22, 1191 Michael Woods IlDndo Company 2121 South Lyon Street Santa Ana, CA 92705 (Al RE: Construction of Landscape construction an the Handicap Play Area in CEntral Park PPOJECT CC-803 .4 z % Enclosed is a copy of the executed contract with the City of Huntington ii;j' t Beach, a Declaration of Satisfaction of Claims and a Certificate of Compliance form. The Declaration of Satisfaction of Claims and the Certificate of Compliance form MUST BE RETURNED TO THIS OFFICE AFTER THE PROJECT IS COMPLETED BUT PRIOR TO THE RELEASE OF PETENTION FUNDS. In addition, the following item must also be on file, with this fffice before the City can release any retention funds: A warranty bond guaranteeing the final amount of work and materials for one year. If your perform anco bond does not include specific wording for a one year warranty, then a rider or separate bond must be submitted. Should you have any questions or concerns regarding the enclosures or .61 items that must be on file in this offict., prior to release of retention funds please call Don Noble Contracts Administrator 6419-rAAI V A Connie Brockway City Clerk CB:bt tint: Cash Contract 4 b. Declaration of Satisfaction of Claims Certificate of Compliance 1?.5AQ.. Lk S;y - F9, V 0 ITeliphone: 714-535-5227) V , c:' I ) 19, t;..S*i-_ !.- I I . % - , 1 4 7-, a, - 4 ; . -, , : , , t , tj Lt �i ot, I V., " a" E I1 f � CON'SITUCTIOU CONTRACT BETWEEN THE. T" C C 1 _ OF "TINTINGTO W BEACh A,"li) IiONDO C OMP N , INC. FOR 1J.ND ;CAPE � �• HISTRUCTION ON Till: HANDICAP PLAY M A IN CI;NTRA1, PARI, j 4 j f j t; " j - il-It" I • •j ` 1 5 i ;Z ' ci i 19 6T Kilrq!Z I& a-NONGV-NON 6Z T s WMIMD d!82 ILCY N .L�twIi �` rid G at�fSS� d ' EZ i 1 6 T IF�Sf�.L alM - I Q�t @` f ' Z Z PT 9 ET uua __ ZBf��[$�du, l CI Q £T I ZT mmnsul ' 0Z ? T Sr H'"li4titfH C1n?�!'�'s13?3r1 '''•�i"11�t1 I3I i �aAI ' BT IT SATV. a3`TOY 1f9AIT Wl ' L T IT STti.' �di�53� [Z���3 � 2b M A � Q 191 IT 9 0 T 2111L I H NOI��1IL MllsI SCUIYJ VUIN61—Tel M. 11.i�1 OGT 0 Y N.dTi.KVC1 S?'suSbt�f3 G �I,�i�f1IRr a1,jt?TI.LS1 r�%IcSl'71 ' f. T B- 9 `�CQTcM�rlt JCS' i I l ' t T 3 SI.tIf 6? ' 9 9 WIN .9 1 92 mvm ifi b �:�ii~U���:If�iAi'l::l��i �I'ii�l��:,; ' r! ��•,�� v Y3 e tIti :i si;Aai%iu5 • t1UI,LiiJIi1 )Ic�S � 1 SIN31NOO 90 RgUV.L I TABLE OF CGNTENTS A 2ITI E 26. ,9TQP li T ICE 27. 28. a'...9 . 30. IN TI3_F--'JY 1(1 1 r 1 ,E 1 r, 15 15 & 16 16 17 Cr)NSTRUCTION CONTRACT HETAIEEt4 THE CITY OF HUNTIff.fOti BEACH AND 11011"0 COMPANY, I*1C. FOR LANDSCAPE CONSTeUCTION ON THE HANUIChP PLAY AREA IN CENTRAL, PARE THIS AGREEMENT is made and entered into on this 22nd Gay of _�tn_ , 1991, by and between the CITY OF HUNTING'TON BEACH, a municipal corporation of. the State of California, hereinafter 11 11 i 7 refer. red to as CITl, and HONDO COhLPRNY, INC. , a corE10ration, horainaZter ieferred to as "CONTRACTOR." WHEREAS, CITY has so .icited bids for a public works project, hereinafter referred to as "PIZOJEC'r," more fully described as the landscape construction on the h,.:ndicap play area in Contra! Park in the City of fiunti%gton Beach: and i CONTRACTOR bas been selected anC. Is to perform said work, I NOW, THEREFORE, in consideration of th:, promises and agreements I�I hereinafter made and exchanged, the 4 g rartie� covenant and agree as � II follows: I i 1. !iTTEr EN WQRK` ACC _P i E op_p S CONTRACTOR shall furnish, at its own expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other - items, services and facilities necessary to complete and construct the PROJECT in ,i good and warkmanlikc mannar. CONTRACTOR agrees to assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance, from the action of the elements, from any y _ i Is. , r , C W unforeseen difficulties which may arise or be encountered in the f pros,.cution of work, and for sl1 other risks of any description connected with the work, including, but not limited to, all expenses incurred by or in ccr.sequence of the suspension or discontinuance of � work, except such as are heroin expressly stipulated to be borno by K CITY, and for well and Faithfully completing the work within the stipulated time and .in the mars :•r shown and described its this I _ Agrceiner_"_, and in accordance with the requirements of CITY under ' thorn for the compensation set forth in the accepted bid -proposal. However, the total compensation to be paid is to be computed on 0 + the basis of the: units of work as it is actually performed, in accordance with the stipulated rises named in the Bid Sheet s. P P � ) � 2. A=JANCFjof -QQNDj-jIONS OF 1DRU- PLANS AND-JUKQ—IFISCAT I O'NS CONTRACTOR acknowledves that it is fully familiar with all the II I teams, conditions and obligations of this Agreement and the Contract Documents (as hereinafter defined), the location of the jc,b site, and the conditions under which the work is to be purformed, and that it enters into this Agreement based upon its investigatlon of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents sre incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length hernin, and that CCNTRACTOR and its subcontractors, if any, shall be bound by said Contract�- 1, I Documents insof6r as they relate in part o: in any way, directly or indirecL-ly, to the work covered by this Agreement. • F ! 2 t' , y ,y „ 9 "Contract. Documents" as defined herein mean and include: A. Th1e Agreement; R. Bonds covering the work herein agrer-.d upon; C. The Cl"T" S standard Plans and Specifications and :special contractual provisions, including those on file: in the office of the Director of Public Works of CITY and adopted by the City Council of C?TY, and any revisions, amendments or addenda thereto; D. The 1988 cc;ition of 5-tApO.Lrc ? S-'-!�I Lgns Us— irU-UL9— xks n, published by ©ui'de,r's clews, Inc. , 3055 Ovoiiancl Avenue, hos Angeles, California 90034, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Associat-ion and the Southern California , District Associated General Contractors of the California Joint Coorerat-ive. Committee; E. 3id documents including the Notice Inviting Aids, the Special Instructions to Bidders and the Contractor's Proposal (attached hereto as E:thibit "A"); F. The particular plans, specifications, special provisions and addenda apr,Iicable to the PROJECT. Anything } mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentio_ied in both. In case of ►liscrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as "DPI -I, ") without whose decision said discrepancy shall c C. i'y+•. `` J) ♦ 4 A�rjJ�I Jy •riffs•': r, ��k 1 1 1I F J not be adjU3ted by CONTRACTOR, save; only at Its own risk and ezpense. Should there be any conflict bou..aen the terms of this Agreement i Iand the bid or proposal of CONTRACTOR, then this Agreement shall �} control and nothing herein shall be considered as an acceptance of v the terms of said hid or proposal which is in conflict herewith. 3. C-.0iEIIS.c'L'�MN j r � CITY agrees to pay and CO14TPNCTOR agrees to accept as full I compensation £cr thQ faithful performance of this Agreement:, subject: to any additions or deductions made under the provisiuns of this I +1,• Agreemen,. or the Contract Documents, a sum of One Hundred r ;' Fifty -Three: Thousand, Thee Hundred Sixty -Nine Dollars anu 35 Cents J �. ($153,369.35), as set forth in the Contract Documents, to be paid as provided for in Sections 1, 6, 13 and 14 herein. 4. MME VMMME_t3T QF MUM CONTRACTOR as reds to conunence the PROJECT within ten (10) ; working days after notice to proceed is issued and shall diligencly prosecute PROJECT to completion Within One -Hundred and Twenty (120) consecutive calendar days from the day the "Not -ice to I%rocned" is `�• f two,; issued by Department of Public Works, excluding delays provided for in SGction 11 herein. ! 5. TXME Ok THE ESSENCE , The parties hereto recognize and agree tLat time is of the } essence: in the performance of. this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for al't shop drawings, details and samples, and do all other things necessary and inci.denLal to the prosecution of ' A 4 i 1 N1•I. I its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordint;te its work with the wnrk of all other contractors, subcontractors and CITY forces working on the PROJECT, in z manner thzt will facilitate the efficient completion of the PROJECT and in accordance with section 4 heroin. CITY shall have complete control c,f the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, nubcontractors and CITY forces and, in general, rill matters concerning the tii.oly and ordoriy conduct of the work of CONTRACTOR on the premises. 6. U `-Uhi CONTRACTOR shall adhero strl-:tly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by the DPW. CONTRACTOR agr.es to make any and all changes, furnish materials and perform all. ,4ork necessary within the scope of the PROJECT as the DPW may req-aire in writinq. Undar no condition shall CONTRACTOR make any changes without the written order of the DPW, and CITY shall not pay any extra charge, made by CONTRACTOR that have not been agreed upon in writing by the DPW. When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the effect of the change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated by the partles upon cost and pricing data submitted by the CONTRACTOR; 5 I V.1 1 thereupon, CIT71 will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upwilrd or downward accordingly. . M:CCF n No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed t hiE been given to the CONTRACTORLy CITY. CITY does not warrant that: the ,pork site will be availaLle on the date the Notice to Proceed is issued. In event of a delay in commencement of the work � duo to unavailability of the job site, for any reason, relief to the , CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 1 t . 1, 1 CONTRACTOR shall, prior to entering upon the performance of this ` Agreement, furnish the following bonds a pproved by the City Attorney: One in the amount of one hundred percent of the contract price to guarantee the rnNTRACTOR'S faithful performance of the work and to warrant such performance fnr a period of one (1) year after CITY'S acceptance thereof, and one in the amount of fifty percent: (50%) of the contract price to guarantae psyment of all claims for labor and materials furnished. 9. 1~1ARRA_T FS The CONTRACTOR unconditinrally guarantees all work done under ` ( this Agreement including, but not limited to, any workmanship, 4 installation, fabrication, material or structural facilities I constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate 6 x, ,1 I, 1 , • , �1 ll I ,,) • 1 i repairs or replace the defective item of items. Upon expiration of such ten (10; day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S risk and expense, 10. JUMETItMEM CONTRIAX-T-0 It is understood and agreed that the CONTRACTOR is, and shall be, actinq at all times hereunder as an independent contractor and not as an employed of CITY. CONTRACTOR shall secure, at its expense, and be responsible for any and all payment of income lax, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees, and all business licenses, if any, in connection wits the PROJECT. 11. LLQUIPA Al 'p :SS, It is `greed by the partioe hereto that in case the total work called for hereunder is not in all parts and requirements fini3ned or completed within the number of calendar days as set forth in Section A herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determi—ie the actual damage which CITY would sustain in the event of J I and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of Two Hundred Fifty Dollars ($250.00) per day for each and every working day's delay in completing the work in excess + of the number of working/calendar days set forth in Section 9 I herein, which sum represents a reasonable endeavor by the parties hereto to estimate a fair rompensatinn for the foreseeable losses i CITY would sustain in the event of and by reason of such delay; snd i :I CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will he granted an extension of time and will not b assessed damages for any portion of the delay in completion of the work due to unforeseeable causes beyond the control and without th fault or negligence of CONTRACTOR, including, but not restricted t acts of God or o; the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning any such delay (unless the Mq shall grant. a further period of time prior to the date of final settlement of the Agreement), notify thi DS1 in writing of the cause of the delay and CITY shall extend thc: time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of the DPW shall I conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion c the work by the act, neglect or default of CITY, or. should CONTRACTOR be delayed waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockouc by CITY, then the time herein fixed for the completion of the work shall be extended by tl numb3r of days the CONTRACTOR has thus been delayed, but no i j I J t I. � I allowance or extension :hall be made unless a claim therefor is presented in ciriting to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, li respective of the cause thereof:, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of time for completion shall be the sole remedy cf CONTRACTOR. 12. PiFLR-113a STTE C:ONP.J1'TOjVc2 (1) N_otLGY The C014TRACTOR sha) 1 promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) Subsurface cr latent physical c%inditions at the job site differiinq materially from those indicated in this Agreement or thn Contract Documents; or, (b) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. The DP;,. shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly; (2) TtMrg k;�cLejlajQn No claim of the CONTRACTOR under this Section shall be allowed unless the CONTRACTOR has given the notice required hereunder, provided, however, the time prescribed therefor may be extended by CITY. 9 1 i -r-�r r , a n 13 . The quantities listed in the bid schedule will riot govern final payment. Payment to the CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and speciEicat'•ions. Upon completion of the PROJECT, if thr_ actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. The DPW may, at its sole discretion, whan warranted by the facts and 'j, ,�•' '' circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction oL the PROJECT are in variation to the quantities � listed in the bid schedule:. No claim by CONTRACTOR for an equitable adjustment in p' :e or time for completion shall be v1lowed if asserted after final payment under this Agreement. If the quantity Y }' variation is such as to cause an increase in the time necessary for completion, tha DPW shall ascertain the facts and circumstances and i t make such adjustment for extending the completion date as in its rw "• judgment the rindings warrant, 14. P�f34SH���_��tlCnTs Each month the DPW will make an estirr,ate in writing of the worn ,1 per.fcrmed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY ` and the remainder, less the amount of all previous pa,^nents eince ; .yti'►' commencement of the work, will be paid to CONTRACTOR. 1 When CONTRACTOR has, in the judgment of the DPW, faithfully i j - executed fifty percent (50%) or more of. ':he value of the work as 10 7t 1 • . , :fr."..:.-... .;.•... .... a ' , :!'-�' 1. r. ram' , r 1 determined from the bid schedule, and if the: DPW finds that satisfactory progress has been and is being made, the CONTPACTOR tray be paid such sun) as will bring the payments of each month ul) to one hundred percent (100%) of the value of the work completed since t.hr co-amencement of the PROJECT, as determined by DMI, less all previous payments and less all previous retained amounts. The i:i,�al payment, if unencumbered, or any part thereof unencumbered, ,hall be made thirty-five (35) days after the accepLance of the wort; and the filing of a Notice of Completion by CITY. Payments shall be mane on ` demands drawn in the manger required by law, each payment to be accompanied by a certificate niched by the M-4, affirming that the + �� 1 work for which payment is demanded has been performed in ;, cordancq with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an I ,,`;•., acceptance of any part of the wozk. 15. Y ktHr��S�4 _-SIBSTIT IONS F 1. r.(XRITICS At the request and expErnse of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any tbesreon, CITY `) shall permit the substitution and deposit therewith of securities ='•'r' equivalent to the amount of any monies withhald by CITY to cnsurc performance under Section 13 of this Agreement. ; ;I i 16. AEFIDAV ITS OF SA.T:51-ACT,1DR OF CLA 11��,5 1 �I After the completion of the work contemplated by this Agreement, � r CONTRACTOR shall file with the DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors upon PROJECT have been paid in full and that there, r. J i. I ,I arc no claim,; outstanding a(;1liw:t: PROJECT' f.or eit:hr.+: labor- or mator 1 1l, e:{rel)t; cr'!rLa111 lt(_'1ri:i, if orly, t'0 be so": fort:tl 11i :111 affi.da0I- i:nvf:rIng disput:ed claillis, of 1te1115 ill Connect, I(.)r1 with 00(:icr. , to Wit:hilola whit). have 1).!en f i led under tt11: pr0vi..i0llS of thc: statute%- of the tate of California. The acceptance by CONTRACTOR of the paylnr.nt of th, i—inal certificate :.child constit:utc a waiver of all claims aic,airwt. C11"17 under or arising ou). of t:hi:, Agreement. 18. ,�'J1D1; Alt JFTCA,rTQti..---f�l C1v.ti1 ,�iLOLD 11J112TIL.FS i. CONTRACTOI: hereby agrees to protect, daf.end, inderr,nify and hold and save harmless CITY, its officers, and ennp!oyees, ilgain:;i: any and all liability, claims, judgments, costs and demands, howeve: caused, including those resulting from death or injury to CONTRACTOR'S em111oyees and damage to CONTRACTOR'S property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, including those arising front the passive cor_current negligence of CITY, but save and except those which arise out of t h:., active concurrent: negligence, vole negligence, or the sole willful misconduct of CITY. CONTRACTOR will conduct all defense at it, sole cost and expense. CITY shell be reimbursed by CONTRACTOR for all costs or attorney's fees incurred by CITY in enforcing this obligation. 19 . l'LQIRKCR,S' QO-', E 1 ,7qI.i1541F i,IICF Pursuant to Ciali_fQ+rn�-i ci_r313G1, CCNTI:AC',"CT; acknowledges awareness of Section 3700 et seq. of said code, which requires every employer to be insured against ':iabil.ity for workers' cornpenr�a"Lion; 12 7 ,t c: COWI'RACTOR covenants that it will romply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall maintain such Worker.;' Compensation Insurance in ar, amount of not less then On(.- Hundred Thousand f)ollars ($100,000) bodily injury by accident, each occurrence, One Hundred i Thousand Do' lars (,$1.00,000) bodily injury by disease, ;each e;r,31oyee, and Two Hundred Fifty Thousand Dollars ($250,0001 bodily injury by Ji ease, policy limit, at: all times incident hereto, in forms and utiderviritten by in;suratice companies satisfactory to CITY. i COi7'rItAM'OR shall rr•nuire all subc:oRtrr.cLors to provide such I Worlcc.r;:' Compensation In:,tirance for all of the subcontractors' nmployeus. CONTRACTOR shall furni•;h to CITY a certificate of waiver of: subrogation under the term:; of the: t, )rkers' Compensation Insurance and CONTRACTOR shall Similauly require all subcontractors to waive subrogation. 20. TNf-Jjr<1' 11cr CONTRACTOI. shall. carry ?t: all times incident hereto, on all opevation., to be performed hereunder, general liability nsurance, incltl(linq covor.age For bodily injury, property damage, r�rr�duc tsicutnl�let�.ci (:pf,xatior,s, and blankei_ .ontractual liability. i Said insurance slic-ill also include automotive bodily injury and propel: tl cl.lniage l],-thilit:y insurance. All insurance shall be j under;jritJ.,_, n by insurance companies in forms satisfactory to CITY 1 for all op,:rations, subcontract work, contractual obligations, product or completed opet'at:io:in and all awned vehicles and non -owned vehicles. Said insurance sl:.:,ll nar::, the CITY, its officers, agents and employees and all public agencies as determined by the CITY as 13 I r� 0 H Additional Insureds. COUTRACTOIi shall subscribe for and maintain I said insurance policies in full force and effact during the life of t this Agreement, in an amount of not less than Jne Million hol'lars i ($1,000,000) combined single limit coverage. It coverage is provided under a form which includes a designated general aggregate limit, such limit shall be no less than One ?Million Dollars ($1,000,000). In the event of aggregate coverage, CONTRACTOR shall immediately notify CITY of any known depletion of limits. J, CONTRACTOR shall require its insurer to waive its subrogation rights against CITY and agrees to provide certificates evidencing the same, 21. SiJ�'I'LF��C�ITRS�F_��TJ)3c'�ri'�R�S�I�k��I�lI1�L-NP4aSFJIM �. ?�a �,' ;',• � Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificateF, of insurance subject to approval of the City Attorney evidencing the Foregoing insurance coverages as required by Sections 19 and 20 herein; said + certificates shall provide the name and policy number of each carrier and policy, and shall state tha` thy; policy is currently in force and shall promise to provide that such policies will not be P p �`. cancelled without thirty (30) days pri''1r written notice to CITY. CONTRACTOR shall maintain the foregoing insurance covor-iges in torce until the work under this Agreement is fully completed and accepted by C I111. i; The requirement for carrying the foregoing insurance shall noi, derogate from the provisions for indemnification. of CITY by CONTRACTOR under Section 18 of this Agreement. CITY or its i + representative shall at all times have the right to demand the original or o copy of all said -elicies of insurance. CCNTRACTOR i 19Xr ,. `? i i shall lay; in it prompt and timaly manner, the premiums on all insurance heruinabove required. A separate copy (.f the additional insured endorsement to each of CONTRACTOR'S insurance policies, naming the CITY, its officors and employees as Additional Insureds shall be provided to the City Attorney for approval prior to any payment hereunder. 22. :AUiT—Ak'Q--TJaMJLA7:LQN If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete tho work within the time specified, or is ,adjudged a bankrupt or makes 7n assignment for the benefit of creditors or becomeu insolvent, or violates any provision of. this Agreement or the Contract Documents, CITY may give notice in writing of its intention to terminate this Agreement. Unle:,s the violation is cured within ten (10) days after such Notice of. Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may ave, terminate this Agreement upon. the e:_pirstion of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agieement; in such event C TY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. 23. WGPOSITION O—F—PIANS, E�TIMATES AHP S��Ii-R_DOC.URE CONTRACTOR agrees that upon complation of the worlt to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other docume''.s pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. II •, 15 I i� t - �• I is t1,I ' ` .,\ Kf 1 �C .. ' i 'l 24. NOILASE10AR1hUY CONTRACTOR :shall riot sell, assign, transfer, convey or encumber this Agreement, or any part liereo�, or any right or duty created herein, without the prior written consent of CITY and the surety. 25. r'=�MPLQYI�FE�Nn OFL�71�h CONTRACTOR shall employ no CITY official nor any reqular CITY employee: in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of -Qa-jjf-Qr a Government ^QdD Sections 1090 et seq. 26. ULD-' NUNEO: MOVERi` OF -ADMINIaMMUILCOSTO CITY shall be entitled to recover from CONTRACTOR its reasonable administrative and attor.ne,•'s fees, coasts and necessary disbursements arising out of the pro-cessing of said Stop Notices, Notices to Withhold, or any similar legal document necessary to tale prosecution of such action. Said obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One --Hundred Dollars ($100) for every Strip Notice tiled in excess of two, regardless; of whether or not CITY is named in an action. CITY may set off any rnre,imbursed cost or expense so incurred against any sum or sums owed by (wITY to CONTRACTOR under this Agreement. 27. _1rMMATION CONTRACTOR shall he responsible for full compliance with the inuriigration and naturalization laws of the United States and shall, in particular, comply with the provisions o£ a iZ�, §1329a 1� I regarding employment verification. i 1.6 i �r a r, ti oil 2 8 . OTIM Any notices or special instructions required to be given in writing under this Agreement shall be given either by personal delivery to CONTRACTOR'S agent (as designated in Section 1 hereinabove) o= to CITY'S Director of Public Woks, as the situation shall warrant, or by enclosing the same in a sealed envelupe, postage prepaid, and depositing the same in the United States Postr.l Service, addressed as follows: TO CITY: TO CONTRACTOR: Louis F. Sanduval Michael Woods Director of Public Works Hondo Company 2000 Main Street 2121 South Lyon Street Huntington Beach, Cl: Santa Ana, CA 92646 92705 29. C P.�LM Captions of the sections of this Agreement are for convenience and reference only, and the words contained therein shall in no way be held to explain, modify, amplify or aid in the interpretation, construction or meaning of the provisions of this Agreement. REST OF PAGF NOT USED 17 ra.. I 3 U . EILT-IRETY The foregoing represents the entire Agreement between the parties. IN W.' .'NESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers the day, month and year first above written, HONDO COMPANY, INC. CITY - OF HUNTINGTON BEACH a corporation a munici al corporation of t a tat6 of CalVjornia BY Mayor Its: __P�e���ient/__i�1G�nE�.-- �.c�r�v D By: Its ATTEK T •u City Clerk VIEWED AND APPROVED: A City Administrator l oy cL APPROVED AS TO FORM: City At orn y I11jF1,ATEe 10&vR9VED Director of Public_ Works '- Z4 --I I I' 5. J i� .r ' tI + 1 -1 t r, I A0160111P, CERTIFICATE OF INSURANCE IDSUE DATE •1�r/'DDIYYI - PRODUCE,I THIS CERTIFICATE 18 ISSU FAB A MATTER OF INFORMA710�_51111.2�_N ONLY AND CONFERS 110 RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE CRAIG FOSS INSURANCE SERVICES DOE: NOT AMEND, EXTEND Oil ALYER THE COVERAOF AFFORDED DY THE 25431 CA1301'• ROAD, SUITE 207 POLICIES_EELOW. LAGUNA, 111U,S, CA 92653 COMPANIES AFFORDING COVERAGE 714-455-9808 A LETTERI1V NATIONWIDE, 0111AL INSURANCE COMPANY COMPAIIY p INEUnEO LETTER H014DO COMPANY, INC. COMPA LETrEnIIY C 2121 S. LYON SANPA ANA, CA 92705 COYIPA LETTERI+Y 0 COMPANY LETTER COVLR?AT:B THIS IS TO CERTIFY THAT THE POLICIES OF IN URIANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSUPED NAMED ABOVE FOR THE POLICY PERIOD TERM OTHER DOCUMENT RESPECT THIS INDICATED, NOTWITHSTANDING ANY REOUIREMENT, OR CONDITION OF ANY CONTRACT ON WITH TO WHICH CERTIFICATE MAY BE ISCUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSION3 AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. CO TYPE OF 111SURANCE POLICY NUMBER LTI1 POLICY EFFECTIVE POLICY EXPIRA71014 LIMITS DATE WPAIDOIYY) DATE IAI14II1'01YY) GENERAL VAIILITY r� OEFiERAL A0pnE0ATE 1 2,000,000 A X COMMrncuLGENERAL L1ABILITY 73PROO7376-51302 6/1/90 6/1/91 PncDucrscc?AFIOI'$On 11,000,000 CLAIMS MALE X OCCUR. PERSONAI 0 ADM. ' 1,000,000 t OANFIt'6 a COIITOACTCn'S rnOT. EACII OCCUFIFIENCE 1 1,000,000 rinEUAMA3E,ASYcmaIt,•) I 50,000 1AEO EXFENSE IAry we mmm) 3 5 , 000 AUTOMOBI.E WA14LITY COVOINED FINOLE 3 ANY AUTO l IV.I 1 , 000 , udd ALL OWNED AUTOS P ;OILY INJUPY S A X SCHEDULED AUio:, 73BA007378-0001 6/1/90 6/1./91 Ira,ro,,or•, I X 141SED AUTOS 1!001LY I!IJoURY r X NCN-OWNED AU10., Ire, or, Oe WAGE UABILITY FWFf:RTV DAMAGE I M EXCESS LIABILITY ^~ EACH OCCLRPENCE S UAIBTIELLA FCnAI AOORLIIAIE t I OTPLR TIIA1 UMBPELLA FONIA�- --.•_.I WORKER'S COMPENSATION STATUTORY L1MCI1 A 73WC0073 78-0003 6/1/90 6/ i /91 EACH ACCIDENT 1 100,000 AND DISEASE—POUCVLACT i 50n,000 EMPLOTER9'LIABIIITY OTHER DISEASE—EACHEAtPI.OYEE S 100,000 �� r DESCRIPTION OF OPERATIOIIS,70CATIONSIVENICLCS;3PECIAL ITEMS OIIL IIUTTOH, City ,tt07rv8 gyL �t tamoy I CERTIFICATE HOLDE.1 - CANCELLATION SHOULD ANY CIF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE ' CITY OF HUNTINGTON HACH F.XPInATICIIJ DATE THEREOF, THE ISSUING COMPANY WILL E2]Dw IKXTD MAIL 30 DAYS WRITTEN NCTICE TO THE CERTIFICATE HOLDER NAMED TO THE PUBLIC WORKS VEPARTMENT 2000 MAIN ST. LEFT,}g�C`.T7llU1RK.TRhUt�'!'tEDf'iCS��,7i►�i�:E ..`iA'xD65.iD4X�43c1�dXCi�R!i{ HUNTINGTON BEACH, CA 92648 }Ix1I40Lxm"K}Em"%vxt►m#• L to Ii!C> (�iuJ[TiXJ1J�NC7iX AUTHOR13CO REPREtENTATIVE A�04--. ACORD 25.8 11/90) CORO CORPORATION 19201 t I 1 4 �1 rl' L,Y 1 ` •I l I _I I ;I 41 ,' w 1 POLICY NUMBER: 731'11007378-5002 NAMED INSURED: HONDO C011PANY, INC. THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED ---OWNERS, LESSORS OR CONTRACTORS (FORM B) ' This endorsement mollifies insurance provided under the following: !• t CONINIERCIAf, GE.NEIIAI, I,IAIITI,I'I'Y COVI:)tMIE, PART Name of Person or Org+tnization: CITY OF HUNTINGTON HCACiI, ITS OFFICrIiS, AGENTS 6 DIPLOYEES ,r�r 2000 KAIN ST. HUNTINGTON BEACH, CA 9264$ { WIIO IS AN INSUKFD (Section II) (y amended to include as an tusuied the Person or Organiza- tion In the Schedule, but, this insurance with respect to such Person or Organization applies only tc the extent that such Person or Organization is held liable for your nets or omissions arising out of and in the course of operations performed for such Person or Organization by you or your sub- contractor. , • 1 • �r j Cas. •1190 11-901 i 1 1} , yn � !i y r Ir '• � .- ,: ' ' ' �Sa FAR+.-�ee*�aw.r+tv.-••...•......... -... _ N r r a•+ r. t�' i , / ~1`' / t � i it , �"I`�! � ��� +j r J ,• +.........�..............-.-..-.J.._---.r �. �. _. r... � ..... .. .._-..._. .. ,., _. _ ..�....... ram, n•• .. w- -1.in .. 'Yr1f'.+'+--1 J I ' r • ,il• �, r i� ', , `" �....w+. "• �r , ,:'{ rill tr �la,i�, - , C , [ e I REQUEST FOR CITY COUNC IL ACTION ; Data May 6, 1991 ? , Submitted to; 1•lonorable Mayer and City Council Submitted by; Michael T. Ul,erua,a, City Adrnin+strato ~ Ronald Hagan, Director of Community Services `' _�__ Prepared by; Louls F. Sandoval, Director of Public Works p � Y at7'Y ' Subject; HANDICAP PLAY AREA, CENTRAL PARK; CC-803 Consistent with Council Policy? [ Yes [) Now Policy or Exce Statement of Issue, Recommendation, Analysis, Funding Source, Alternativa Actions, Attachments: STATEMENT QF iSSU.0 Authorize staff to terminate the award of a construction contract to Artistic Landscape and approve the selection of the second lowest bidder. RECOMM —D-A• O-N- ; 1. Terminate the award of contract to Artistic Landscape. 2. Approve the second lowest bid as submitted by Hondo Company. 3. Authorize the Director of Public Works to expend $153,369.35 ►o cover contract costs of $1,36,699.35, anticipated construction change orders of $13,670 and anticipated ANALYSIS; expenditures of $3,000. i2YSIJi On February 4, 1991, Council approved the plans and specifications for thp. construction of the Handicap Play Area in Central Park and authorized the Director of Public Works to solicit bids for construction. Bids were received and opened on March 5, 1991. On March 111, 1991, Council awarded a $144,638.60 construction contract to Artistic Landscape. Subsequent to this action, it became apparent that Artistic Landscape's bid Included the construction of a floating rather than a stationary dock. Obviously, the handicap cannot safely use a floating dock. The cos: of constructing a stationary dock, as required per the approved plans and specifications, far exceeds Artistic's bid for this Item. Therefore, on April 16, 1991, Artistic Landscape formally requested that their bid be withdrawn. Staff From Community Services, the City Attorney's office and Public Works concur with Artistic's request. The rejection of this contract, while recommended by staff, will necessitate one of the following actions: Awarding the contract to the second lowest bidder, rebidding the enta e project, or cancelling the construction of these Improvements. Tile City has received a state grant for the construction of these Improvements and must encumber the funds as soon as possible or forego the revenues. Therefore, rebidding the project or cancelling the construction of these Improvements is without warrant. Awarding a contract to the second lowest bidder has the most merit; however, this action will result in a greater cost for a smaller project. Specifically, the play equipment included as an Alternate Bid item In the contract awarded to Artistic Landscape will be deleted in the second low bid r' contract because of the cost to construct th'-! fixed dock. Plo 5/as jr [ , , Request for Council Action Handicap Play Area Central Park May 20, 1991 Page 2 Staff has reviewed In detail, the second low bid of $167,299.35 (less $30,600 for the play equipment) anti recommends that a $136,699.35 contract be awarded to Hondo Company. This contract would Include the fixed dock as originally requested in the bids; however, the construction and Installation of play equipment will be deleted to offset the cost of ; Installing the: fixed docks as bid by Hondo. The city annually budgets $75,000 in the Park Acquisition end Development Fund's Capital Improvement Projects budget for play �I,t equipment. This account will ue used to purchase the $30,600 in play equipment for this project. EuNn1dS��QSLL��� '' . Contract Costs $136,699.35 Construction Change Orders: 13,670.00 incidentals (l,e. soils testing, utility costs, etc.) Total $153,369.35 B �f Engineer's Estimate: $150,000 c * The project budget includes sufficient revenues to cover construction costs, "incidentals"; anttcinatcd change orders, and project however, staff is not authorized . to eniumber funds for "incidentals" without Council approval. Therefore, it is recommended that $3,000.00 be encumbered for project "Incidentals". Revenue Sources: i An unencumbered balance of $165,000.00 is available In fiscal account { E-SK-CS-60' 1-39-00 (Handicap Plan Area) for this project. LTC- RATlYE AC110N, 1. Deny award of contract to Hondo Company and select one of the other bidders. 2. Reject all bids and forego the construction of these improvements including a state grant of $100,000. ATTACHMENTS; None LFS: RI-I:ib ; 2937g/13 & 9 •I� ,y .t Submi!ted to: Submitted by: Preparod by: Subject: REQUEST FOR CITY COUNCIL ACTION ��'' J�<<•r Date _` March 18, 1991 Honorable Mayor and City Council Michael T. Uberuaga, City Administrator o r APPROVED DY CITY COUNCIL Ronald Hagan, Director of Community ServlcE: •� ,9- r Louis F. Sandoval, Director of Public Works HANDICAP PLAY AREA, CENTRAL Pj!RK; CC-803 i 1 ' Consistent with Council Folicy7 ( ).Yes ( ( New Policy, or Exception Statement of Issue, Flecemmendation, Analysis, Funding Source, Alternative Actions, Attachments: ffAlE iEMLOr—, ISSUE: Bids for the handicap Play Area in Central Park, were received and opened on March 5, 1991. BE-COtrIM>~NPA IM. 1, Approve the low bid submitted by Artlst!c Landscape and Engineers, Inc. 2, Authorize the Director of Public Works to expend $162,101.60 to cover contract costs of $144,638.60, estimated construction contingencies of $14,463 and anticipated "Incidental" expenditures of $3,000. AMUSM On February 4, 1991, Council approved the plans and specifications for the construction of the Handicap Area in Central Park and authorized the Director of Public Works to solicit Wds for construction. Bids, as suntmarizod below, were received and opened on March 5, 1991. Alt (1) Alt (2) Alt (3) Alt (`I) 't3ase Bid, (5) Pius Alt's Contractor Base Bid #1 #2 #3 P4 1,2&4 1. Artistic Landscape $102,250.80 $3,499.80 : 31,344.00 $660.00 $7,544.00 $144,638.60 2. Hondo Company 125,024.35 4,465.00 30,500.00 510.00 7,210.00 167,299.35 3. Clayton Eng. 146,671.10 4,750.00 31,500.00 480.00 29,500.00 212,421.10 4. Sunrise Landscape 185,648.34* 5,399.80 31,376.00 465.00 '16,800.00 299,224.14 5. R co Constructlon Y 188 270.05* � 2 850.00 � 21 000.0o � 490.00 30 200.00 252.320.05 6. Marina Contractors 188,891.25 7,077.50 34.773.00 570.00 7,544.00 238,285.75 7. Br) Park Ent. 199,069.30 3,600.50 30,511.00 540.00 14,500.00 277,680.80 ` 8. Valley Crest Lndscp. 205,715.00* 5,510.00 28,300.00 432.00 61,575.00 301,100.0U Audit total (i.v, the actual total cf bid after correction of math errors.) I .) :.r I Handicap Play Area, Central Park; CC-803 March 18, 1991 Page 2 1. Alternate #1 includes adding resilient tiles and asphaltic concrete base. 2. Altertzte 42 Includes adding play apparatus. 3. Alternate 0 Includes substituting 15 gallon trees In place of 24" box trees. 4. Alternate 44 '-icludes substituting polyethylene decking in place of wood deck. S. Staff and the landscape architect have reviewed the base bid and alternate cost figures and recommend that the construction coatract include the base bid plus Al',ernates 1, 2 and 4. Alternate #3 calls for substituting 15 gallon trees for 24" box trees as t•riginally specified In the approved plans. Based on the outcome of the bids, staff recommends that we not substitute the smaller trees. Staff has reviewed each bid and suggests the selection of Artistic Landscape. Therefore, the Director of Public Works recommends that a contract in the amount cal' $162,101.60 be awarded to Artistic Landscape. �D1��v�VRCE. Contract Costs $144,638.60 Construction Contingencies;: 14,463.00* Incidentals (i.e. soils testing, utility costs, etc.) _af Q(..«• Total $162.101.60 Engineer's Estimate: $?5-i,000,00 * The Director of Public: Works is authorized, by Resolution, to spend up to 10% of the contract amount, but not more than $50,000.00, on anticipated change orders (i.e. unforeseen work etc.) The project budget includes sufficient revenues to cover construction costs, contingencies, and project "Incidentals"; however, staff is not authorized to encumber funds for "incidentals" without Council approval. Therefore, It is recommended that $3,000.00 be encumbered for project "incidentals". Revenue Sources: An unencumbered balance of $165,000.00 is available in fiscal account E--SK-CS-601-6-39-OU (Handicap Pan Area) for this project. ACE RNATIYRACnQU 1. Deny award of contract to Artistic Landscape and select cne of the other bidders. 2. Reject all bids and forogo the construction of these improvements. , ti ell ,t f i LLTACHMEN I: None ! r 1 ♦ r I Y C s V� ' h ' • 4r, r 4 • f p' ,s ppyy J'-M ! � ; Ar 4 1 'J may. r' � , r J ,'. �, .yi..:�.tr... F1'.'�:�• ..-.-.i�'1 �tix�AJ.�... ..it�- -.r ... <.•'X�:•��ii�t'I�:�..4 dill:.�-,2.•Y.:i,•.:>d[W+..v�.+...�—....r..r—r.r. r+.�.r.wvr�c+\. _ +;� r� ��,Sr +',I,f ' , r � AID PROPOSAL FROM Hg0110 Coarpan�+. Iac. �`tti'f, �,,, r >, ►' Firmf Na" , ♦1 �j*�« +fi t l +; To the Honorable Mayor and City Council, City of Huntington Beach, California: r + ',�� ����It 1 .•s• In eomplicnce with the notice inviting waled proposals for the Handicap Play Area Central Park Specification No. CC-803 / � •� � ' t l•� , t� '� ' it ,' , . I'�,''��; f� I hereby propose and agree to enter into a contract to perform the work herein described and to furnish the materiats f- therefore according to the plano, specifiations and spedil provisions for the sold work and to the satisfaction of and under . , the suparvinin of the Directov of Public Works of said City of Huntington Beach, California. The uridersined has not accepted any bid from any submntracter or materiaiman through any bid da osito the b Iaws, rules or regulations of which prohibit or prevent the contractor from considering any bid from any subcontractor or ' materiaiman which is not p►acessed through sold bid depository, or which prevent any subcontractor or moterialman from bidding to any contractor who dor. not r r: the facilities of or accept bids from or through such bid depository. f Far the furnishing of all fader, materials and equipment, and at all inciden;ai work necesur, to deliver all the improvamanti complete la place in strict conformity with the plans, specifications and special provisions, on file in the office of the r Directer of Pubil: Works, laity of Huntington Beach, California, I propose and agree to take full payment therefore at thL+ .'. + fallowing unit prir.:a, to wit: r S• r1 M rITEM 4. APPROXIMATi? QUANTiTY ITEM W1111 UNIT PRICE WRITTENfV WORDS UNIT PRICE 13AL 1 � 1. I LUMP SUM MOBILIZATION --���•� 2. LUMP SUM CLEARING, GRUBBING, AND DEMOLITION _.-----. $SuD.04 Eighty Five Hundred Dollars 3 • LUMP SUM EARTHWORK 35M.oD 'thirty Five hundred Dollars 4. 1,200 CY EXFORTED SOIL %OD 9doo.D r. Seven Dollars and no cents I 5. 100 LF 4" SLUR 35 ORAINLINE '�.S© %Sp•aa Seven Dollars and fifty cents x t r r1 ' i1" l'• •1 i! 1 ' f� i 'n�rt r: 1 ry ,t ' •��r�i ,«r 41 ' 1 ' , ;� �',, . . alb f 1,�• �' ,� .�,) - 1�.,1 J'y1rM i t „4r ITEM APPROXIMATE ITEM WITH UNIT MICE NO.-OUA)MT11 1Mf11TTtN IHMf01iM ^` t �(?• 6. 135 LF 6" SDR 35 DRAINLINE Nine Dollars and no canto f •� r ' I'+' 7. 3 EA 12" x 12" CATCH BASIN Two aundred Fifty Dollars and no cents 1 8. ; ..: 1 EA 24" x 24" CATCH BASIN 1ij Four Hundred Fifty Dollars and no cents 9. LUMP SUM DRAINAGE PIPE CONCRETE BULKHEAD .'•' ,�., �; Pour Hundred Dollars and no cents �4 1. •IJ 10. 2 EA PLAY AREA SUMPS kiftX D211ars @4 dd Uo cents 11. 2 EA CLEANOUTS One Hundred Fifty Dollars and no cents 12. 300 LF CHAIN AND EYE BOLTS Three Dollars and no cents ' �r'': 1 1 13. 60 EA 10" DIAMETER WOOD POLES f f ' •"4,'! = S1xtY, Dolisre and no cants r •t, 7 r r t+ it r rr`. `ter. 'Tfir -14. 2 EA WOOD POLES AND SIGNAGE Two Hundred Twenty Five Dollars and no cents , �+ M -WOOD. FISHING DOCK, COLUMNS RAILS, BEAMS {_'tlti:; tit 15. F7r SF RETAINING WALL, AND CONCRETE CURBS i•• e n Do11.ArB gnd tl!en&X CXp renta 1�t�t�lr �r • ` yR % 4r i JAI ►':1 i t rl, .k �.too , :4 d'ti.0(1���.A-w.'�-NI IL ,- T i ' l :.,rn kb.od 1'5(000.00 N ," ;1 i r + .4 f r, S t t' 1 1' ' ,ii�t,}�� •� r� I .' � r4�. 'fl•'Cr�r%'iTtl�y��y v�.:�CdCh � Z�� �',t� " „• � • lilfi_'1 �1 , �rr y 0 1r f ji r , t t : "rat � \ t;� �. } • an! r t) yy •M 1t � ' r / C rl.•G� r �.• I t 1fI r 1 rr M i yL:. fit, , ♦♦♦fllk�,r •' ,t t f� f F r try �t }, { �I � , •. ll 1 — I.f�tl Ir, rt r. i\...-•j 1 S: r y��►s y t i` � l 1; � ' Y r 1! �il y � 1.• r . 00 tv •41 r YI • _I� + (N ' y1 ' ' •' i=f - r �• 1�1 1Ft 1 ti r f• t � " A. 1'�.. •r�i, �yi r'`�rJ!• .,t 1.-.� �� tk.Sta R r' ITEM NO. AMROXI:II:i1T9 CNJA ,ry ITEM WITH UNIT PRICE WRIT'TKN IN M "04 UNIT FRIQrr TOTAL. 16. 6,560 SF ASPHALTIC C0NCi0IV, PAVING AND HFADER BOARD D . One Dollar and fifty cents 17. 355 IF COtJCREM PLAY ARV% CURB + �,,O �,� Twenty Five Dollars and no cents 18. 1 EA Cflrz = WHEEICHAIR ACCESS RAMP �{04, cdr,1n.0o Your Hundred Dollars and no cents 1.9. 156 CY PLAY AREA SAND Z4.00 Twenty Four Dollars and no cents 20. 3 FA WOOD BR%U ES 7CO3D0 ZI60•00 Seven Hundred Dollars and no scents 21. 2 EA DOUBLE TRASH CM HOIDERS WIMI Fa)m,4IS AND CAN ��D.1�� 4410-W Two Hundred Wenty Dollars and no Geogs 22. 2 EA BAR-B Qm '! r3n•UD . 1 .OD Throe Hundred Dollars and no cents 23. 3 EA WEEELCiAIM ACCESSIDIE PICNIC TA13LES . �p.00 Iq.5D.00 Six Hundred Fifty Dollars and no cents 24. LUMP SLIM MODIFICATICN TO EXISTIN(' IRRIGATICN SYSTEM �V�/ V.•I i Fifteen Hundred Dollars and no cents 1 •' r 25. 30, 975 SF NEW LIRIGATICN SYSTEM lie, 487.5D '. Fifty cents 71 i; r ;T �awr...�""""��»r•�..w�st{>7wvattM'..c4•✓I.+, s. r:rrtr„I'.'.t;t rw -u•. r.: xr.v ... ., t'rrrsr-..,. r •11 .w ..........�+.....wa. 1,,T, i 1. r 1 ,1, c.:;..."'.'^".rvai�l{Flri\J.iS`Ar'7.�.•i �ir ( ! ti + t t rJ • Tji r1 ! Ir ltr�t tl r\• ' m I m Lrl l tilt ri Ifrjj l,�, �ytt�t,r. 11 r it • --� l ty 1 it � YkriYw. r !1 }. a it tJ ITEM Nq.' A"ROXW"Il ,QUAR ITY ITEM WITH UNIT PRICE WRITTEN IN WORof UNIT IRICf TOTAL 26. UM SUM i2EIi0CATED CCMROLIER, ENCU6 ME, AND HOOMP Five Hundred Fifty Dollars and no cants 27. 30,975 SF SOIL PREPMATION AND FIiv'E: GRADING — FIAT Eleven Cents 28. 30,080 SF SEEDED TURF . 07 �Io5.bD Seveu cents I 29. 895 SF SODDFl? TURF lot) 637.00 Sixty cants 30. 6 EA 24" WX TREES 1 Q 00 12 bo•oo Two Hundred Ten Dollars and no cents 31. LIAP SLIM 30 CALENDAR DAY PLANT ESTABLISHMMr PERIC'.D --- 47s, Dra Four Hundred Seventy Five Dollars and no cants 32. LUNG SUM 60 CAIMW DAY POST INS'rAL.IATION M.kIMWN= �-- R�•i>o PERIOD Hine Hundred Dollars and no cents 33 . 1,200 LF Tg4pDRM FM CING WITH ONE SET OF DdUF Z GATFS O )WD.Ob One Dollar and no cents MTA.T, AINGCiDli' OF PARK BID (Shall correspond with amunt stated in Contra t) Alf. Yll ;r t % r /)�*'/1 1 . +r... +•n...r..�... wrv. •.van« ♦ it 1 .. rl r•1 or'! Yt \i f /1 }lRlCVAf 0.*..v+'. . .. .� •n.+. „1 ; r. r l.it:i1Y to a y::ji tr w f• �1 i i � 1 Y:•rr r•+J"�:" si t r6 i`1 1„ t �• i 3 • �(Yr ��1 iS•+ • i � ' 1 ^ J } s t 7 'f � J� •I�1, l :'r7,q ITEM NO. A"ROXIMATE OUANTITV ITZLI WITH UNIT NIIC! w"Ir"m IN r1O1101 UNIT FRI;& TOTAL AM ALJTEIMTE 1. 190 SF R3rSiJ.Mir T.[I.,ES AND ASPHALTIC CONCRETE BASE 'twenty Three Dollars and fifty centre 2. LU4P SUM MAY APPARAWS 15 GA= TREES Eighty Five Dollars and no cents �. 3. 6 EA 4. LUMP SUM. POLYETHYLENE DECK Seven 'thousand Two hundred 'ran Dollars and no c ante 'I Z 1 0, DD ," ry�- O.,,r 1 , { , +�—" � w�..ww+��..rwr.I N,R\.I +/1' uSfa wl'i3'.' 'F •'�' •,CAL Y... r..^����+.r �, LIJ l r LL !'•r try ft_,f J� l •�r.+ , �Y� rl , aN 7 • ° fi I ZI1 (. ?1 f.rr�rjY �St�L �Ilrt`krl:�F+�,, j, 00 It Is understood and $stord that the approximate quantities shown In the foregoing proposal schedule wo sulely for the puipow of facilitating the comparison of bids and that the tontractot's temp2nution will be tomputed upon the basis of the act ual quantities In the completed work, whj,1A!ier they be more or lam than those shown heroin at this unit pticia bid In the proposal schedule. The undff signed understands the contract time limit allotted for the contort lit)caninvor days. if awardedthe contract, the undersignod hereby agrees to sign aid contract and furnish the necessary hands within ton 110) do". of the sward of said contract, and to begin work within ton (IQ) days from the dito of approval of the can• tract by the city of Huntington such, California, The undersigned his examined artfully the site of the work contemplated, the plans and specifications, and the proposal and contract forms therefor. The submission of a bid shall he to'nclusivo evidence that the bidder has Introstl led and h atlifladatto the condhionsto be ancountated, as to the character, quality, and icupt of work to be performed, the the quantlWas of nosteflals to be furnished, mrJ as to the requirements of the proposal, plane, opeciflations, and the oontnal. Accompanying this proposal is Bidder a Bond Ton Parrant N13TICE: Insert the words "Cash," "Certified Chick " or "Bidder's Bond," as the an may be, In on amount equal to at least I a percent of the total bid price, payable to the bity of Huntington Beach. he a ' no undersigned deposlu the shove named security as a proposal guaranty end sift#% that it 1 11 Is forfeited to'the 'T - - :, , �, I", � I City of Huntington Beach as liquidated damages In case this proposal Is accepted by the City and the undersigned shall fail to extalle contract for doing mid work and to furnish good and tufficlont bonds In the form atforth In the spiciflootlom and oont"Mocurnintsofthe City, ,with surety sitlifictary M the City within 10days eftor the bidder has received wift-n notice of the award of the,.,orrtroct; otherwise old security shall he returned to the undersigned. Licensed In accordance with in act providing for the tollitntlon of contract License No. 373104 I.,: Y. Uondo- COW4ny, Inc. Z�l Robert UIVOYT Signet ►I of liddr Rob t Secretary/Treasurer Business Address 605 "A" East Alton Avenue, Santa Ana 92705 Piece of Rnidanca gun Cleeante JDated this_jth_d#y of Narrh jg Bidder here, If shall signify receipt of all Addends any: P. Addendum No. Bidder Si Date Received • One 2128191 1001 Tiro 3/01/91 IA 4 1 16 NI r 1 �, , t. a i . •: 1 i, 7 , t .: •. t i.l'>&1.t2 r f 1rf I 1 i �1f4[1 % dYee.•• a N1y�W' r r i iX�Cl�." y �ir1;.; �rRa�tg' :"►t:4'iS'�tt;:t��r�a=a,�,:wa :Wf�ardrs PROPOSED INFORMATION REQUIRED OF BiDDER maw Bidder is required to supply the following information: Additional sheets may be attached if necessary. 1. Firm Name: Honda ConaBy. ins. 605 "A" E. Alton Avenue 2. Address: Santa Ana, cA 432205 3. Telephone: (714) 44-010 d. Type of firm -individual, partnership, or corporation: O012oration 5. Corporation organized under the laws of the State of: Catifernia 6. Contractor's License Number: 373104 Expiration Date: 4/30191 _ (NOTE: REPRE5ENTATI;ONS MADE THEREIN ARE MADE UNDER PENALTY OF PERJURY) 7. List the names and addresses of all members of the firm or names and titles of all officers of the corporation: Bichsel Woods, President Robert Lloyd, $acre tar,X/Treasurer S. Number of years experience as a contractor in construction work: 12 9. List at least six projects completed as of recent date: CONTRACT CLASS OF DATE NAME, ADDRESS & PHONE AMOUNT WORK COMPLETED NUMBER OF OWNER y o nc o ucaa-nga 1 652 646 A 10/90 P.O. Box 807 91730 "t. 2104 City of Hawthorne 4 lz treat 9 County o range u — 3 90 F.O. Box 4048, Santa Ana 92702 City of Tustin (714) 544—i�890 r. City of Riverside (714) 782-5744 City of Orange (714) 532-0339 86 0 A 1 9 '1 , i t• 1 � 1 o.3lAti i 'F! 4A A 1 , ;fi, ,,yt�r.r,i , 10. List the name of the person who inspected the site of the proposed work for your firm: Michael Woods 1 '• .� ,r ��+ "' �i� c x .ill , ! Date of Inspection: Z (0 1 g 9 -. llkl ?1VPI tad b the City, 11. If requested y y, the bidder shall fw-nish a no•arized financial statement, Itj , ',� r, y, f financial data, or other information and references aufficlently comprehensive to 4 F' t, permit an appraisal of his current financial condition. 17, ' . .rir�����f��'�l .°a, � •� ��• 11�J"V , Il.�y f , •, r;i'+T'.�%•+•4LJl7t1A,►w---..r....�— �.�.. w.+��.,t't'.,•wn+•,e.�r_s.�n,..w..r+--- «.y..�.....•.. .+�-.-.iJj., 4; 1 1 w• t f , e (11 •�, to ir {• I/ • • ' + fir 1 rNo.7 (1 _ ,•,t "+��� � I w•wr..-.. - - __........_.._.._._�..... �.... .r.......... .-..ralrnsl ww�►w.+...•.wl� SZ. ; Its 1. DESIGNATION OF SUBCONTRACTORS ;` { Iri compliance with the "Subletting and Subcontracting Fair Practices Act" being Sectlons 4100.4113 of the ��f "�► �' +� Government Code of the State of California, and any amendments thEreto, each bidder shell set forth below the rams and location of the place of business of each Eubcontncior who will perform work or labor or render service to the prime ton - tractor in or about the construction of the work or improventent in an amount in excess of one -hall (K) of one percent (1X) of thi prime contractor's total bid, and shall further ail forth the portion of the work which will be done by each subcon- 1 tractor. Only one subcontractor for each portion shall be listed. ;•,; � ,� K c If the contractor falls to specify a cubcol'trrretor for any portion of the work to be performed under the contract, he shall be deemed to have agreed to perform such portion himself, end he shell not be permitted to subcontract that portion of the work except under the cenditiors hereinafter set forth. Subletting of subcontracting of any portion of the work to which no subcontractor was designated in the original bid shall only be permitted in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the legislative Body of the owner, PORTION STATE LICENCE OR WORK SUBCONTRACTOR'S NAME AND ADDRESS NUMBER CLASS J. C. < rv; or. I,• ,1. .r , �•h,�r, r Ltt' Y;I�I�Iir • r a 1 � ,� , 1 J j�', t �,It • J' By submission of this proposal, the contractor certilies: 0. 1. That he is able to and will perform the helince of all work which is covered in the above subcontractor listing, ,- r '•; ,f+;'�`'1 r, Y,t 1 Z. That the City will be furnished copies of all subcontracts entered into and bonds furnished by sub•eontroctor for ►'+'s y project. r_�� ,1 �•�...,.�__,-..�.._....�.... fr,•..•:,, ,. •',':. �. _ ., ..'.dry-.; q'1'+:.J I . •J • ` r .NA i t r • ; . : t„rk if ',.�r ` � ,: +. �i, W- t. )p J1 V!i STATE OF CALIFOnNIA SS. COUNTY OF L-1 On this 5th day of - February In the year 1991 before me. the undersigned, a Notary Public In and for said Stale, personally appeared Robert Lloyd personally known to me (or proved to me on the basis at satisfactory evidencel to be the person who executed the OfFir SEAL �LLOYD within Instrument on behalf of the Corporation therein named, and acknowledged ic me that RICHARO C. LLOYD -California Holary Public S CoUgTy lho Corporation executed It. LE LOS ANGELES COUNTY 0. J.'. official s Mv cemin. Ego. Mar. d. 199f WITNESS my hand And V Notary Public In end fdr/s �Id Stale. ACRWNUDGM10- r*r814M-rftkM11 Win ZMA-1 -11,1T. 5-81 cry,: wacatil. 1116Ipme CIOn 1.21 c r , IL r ��•111111 .c�•I .1 � •. .�� t �',�r I Y r..,l a V�• -7 r: i . I Y f• it .r''7Mr '/ , T y 1 • 0 '1 .p' r'• , 1, t�` �.r. .4 T.i t Ifj�•�,t � .� ,i i 0 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID Robert Lloyd being first dttly sworn, deposes and says: 1. That he or she is 8mcrctaryJTreaeurer___ of Hondo Comnq, Inc. the party making the foregoing bid; 2. That the bid is not made in the interest of, or on behalf of, any undisclosed porson, partnership, company, association, organization, or corporation; 3. That the bid is genuine and not collusive or sham; 4. That the bidder has not directly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone refrain from bidding; 5. That the bidder has not in any manner, directly or indirectly, Bought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or fix any overhead, profit, or c,-ost element of the bid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the propomed contract; 6. That all statements contained in the bid are true; 7. That the bidder has not, directly or indirectly, submitted his or her bid price or ar,y breakdown thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. I declare under penalty of perjury, under the laws of. the State of California, that the foregoing is true and correct. ATTACH APPROPRIATE CERTIFICATION OF NOTARY PUBLIC HERE. 1.41,P•/,t •� i y1 i �.A/ /'•s �"'%.tix.�ii11.1i-`^=rr...:m:utv..•\aa�ro..�..u..+•...... ....,.. 1:---- . rlfJla7..l 1 , t a, li ` ! r VJm�Gl.,7tVR� � f•..Clr�r.�P I•n�y r, r 7r r 1 'eli t. 'Y (This guaranty shall be executed by thn suc cessful bidder In accordnncn with Instructions in tho spacial provialan9. .p� The bidder nmy execute the guaranty an this page M at the time of subn !ttinq his bid.) r.UARANTY '.• To the City of Huntington Beach, Department of Public Works: S' („f•r,� ; k6 •''` PROJECT: , t' i►'r►ILf 8ttndicap Play Area Central Park The undersigned guarantees the construction and installation of the following w,,jrk lnc!'sded In this project: e, t,. L,i.rr Should my of the material3 or equipment prove defective or s'iould the work as n �• whole prove defective, due to faulty workmanship, material furnished or methods of installation 7r should the work or an art thereof fall to a crate properly as nrl inall• Intended and in eccordan_e with the plans and specifications, due to sny of thu above ` �, ;'J "`" causes, all within 12 months after date on which t1113 enntract is accepted by the raty, the ' undersigned agrees to reimbruse the City, upon demand, for its expenaa3 incurred in restoring said work to the condition contemplated in said project, Including the =ost of any such equipment or materials replaced and the cost of removing end replacing any other work necessary to make such replacement or repairs, or, upon demand by :he City, ` q q'; rIAYj to replace any such material and to reoelr said wurk completely without cost to the State so that: said work will function successfully as originally contemplated. r, i, M.},, The City shall have the unqualified option to make any needed replacements or -,• ' ''�i'����, Jr,,�'% r r ,rl a :., �.'sy.,, .y y , • •,� ,, ti repairs Itself or to have such replacement.. or repairs done by the undersgned. In the # 1 .• + event the City elects to have said work performed by the undersigned, the undersigned r ,r '} � >t��t+�,+•� f4f '`'�Yr agrees that the repairs shall be made and Such material3 as ,are necessary shall be furnished and Installed within a reasonable time after the receipt of demand from the y. City. If the undersigned shall fail or refuse to comply with his obligations under this guaranty, the laity shall be entitles to all costs and expenses, Including attorneys fees, reasonably Incurred by reason of the said failure or refusal ' r Rondo Company, Inc • • .� r a ►.+r ��r �' j,'x , �7>~<;;'� �' ��r hobert Lloyd, Se retary/Treaunrer� AW ontracto ' March 4. 1991 I'`J �Jfl� J' �� V. , ��.► Ito S , ' 101r-G/553:� �1,{ ,• �.J. 1,'+r la .. f', 1l '. ,! i •1-....- r r-• i .1., �tl � .; N L �" •.. � �,� , ,t� � a� ,1 r� , ." - '-_ �..... ...... � •. -. i1'>:�S"' .r t roc, i .. - -1, It _ , •�.����. f,,�i ti.7!' r ��,° ..i�r. f y j 1 /• i _!1•:L,•t', r.•j r J� I J t' 1 1(i. S i' I'. �:' 'tt "{`rv11�� V�T•' fq sir' J - +: ..1 , 1 Ir r'.,= f, 4r ,. � _ f fi) ,� '1 �' !jf ,' f ♦ � r J' �.rr• / , rr' (kr Il. ,'af 4:l. 1 rll�l h C1 ,. ,, r i:•��rr'r+ +� 1 J+ I r� 1. 1 ... I ',' v �` 1 �rfl F ' Is �� , i,, J ) l�ir ri M 1 �1 �,� 1 ,J��... • .. .. ,+ t. 'l� t� '} ' h+���.r,�'�l(. Jfi jl� 0� F iUM ILL HUNTINGTOA �jl V,_): TY OF, 2000 MAIN STREET P.O. BOX 190 CALIFORNIA Louis F, Sandovni Public Works Dopartmont Director (714) 636-5431 j, ADDENDUM NUMBER ONE HANDICAP PLAY AREA, CENTRAL PARK CC-903 & FEBRUARY 26, 1991 k Nitice to All Bidders: Ail. Please replace sheet #5 (add Alternate) of the bid proposal packet with the revised bid ' '''y t' „t��!`;; ;�j; sheet as enclosed. Note, Additive Alternate Bid Item Number Four Is'hereby added, This Item Includes the substitution of a polyethylene material for the wood deck an the fishing pier. Tha suggested material Is "superdeck". Superdeck Is manufactured by the Wakefield Company I (see copy of attached Wakefield brochure). Very truly yours, , f. I ", , .. 11 1 . % Robert E. Elchblatt, P.E, T.4 City Engineer RF.E:RH:lb This Is tc acknowledge receipt and re-lew of Addendum Number One, dated February 26, 1991. It is understood that the revision of new documents shall be included in the bid documents. 5 1 5 I ll *W11 Hondo Coupany, In Company rr , Y �,4�si'"�.�`s ,} }+;i �}�,:' BY'Rober0toyd, !fecre tary/Trea surer cc: Jack Miller Don Noble CC 803 "Gen. Corresp." . . . . . . . . . . 0 March 4, 1991 Date I kf -4- I., t I I V 21 9 'Y i r �, a�"''� � , � - �!i _ � �;� � �t�y r • tit+ ��t� Ali ;�y'`{r^��In �+,'' f :. 1 I ! •_ : 1 � 1 + `v! lr "I�S' � t :r: • I rr'+�� J.rr� r�JYiyt' _ !) .• ,� t !, _ a5'�' � � ti �RI 1; it c+ , iy It S t It Aft 4. ' i � r "I [. •� ' ; t .i ' 1� ,. �.1 ��(/pp - A��1,1. �l Arl���, , ' ,, i �.r�l�a'1 1 ,v, �� � ! •,i, r• i fi' i .�'"f!� Yi4,rt�ury �` ,,,.� a. :•" • " r��iYrYwr,�ra�.irr.la�rr__�:_•`«���#s�.'1�S11�iiOJia���1 Yr/M.t:.1�'q�ti/�rf-/�:tf�'�.1jl�:ianl�:xsl I 'i, CITY OF I-�1ll.. NTI!�''�1JG"�" ON KNACK-1 °�� i 2000 MAIN STREET P. 0• 13ox 190 CAL IF3RNIA 92643 Louis F. Sandoval Diroctor 1 r 1 Notice to all bidders: 12 The second Addendum Is hereby issued to clarify the following items and or discre ercies: RE: Bolt size -Detail 'IF", sheet 7 of 11 of plans: 9/2" Bolts with 2 1/211 x 51811 washers T ." should read "5/8" bolts with 2 1/2" x r, 5/8" washers Typ." refer to note 4, Min. bolt size shall be 5/8". , RE: YL� M . RE: E: .E °, I RE: ADDENDUM NUMBER TWO Public Works Dopnrtmont (714) 536-5431 � ��•.�� �; �ir 'J{mot Ya��;• Iy ' '. �r,� sgrr fl st RE: � ,,+?. Its,•?, � "ri `, I �. .:tt ,• r7r f��1, [� , �� , RE: 0iO4V '•ik.`�ty 1 ]G '' AA •••,,MMMpLLL I �j,;yy l ••�� i y r i r,i, 1• r, f ►J .JfT1 i I �'''r�{( n, a-. ,J.;i '• +{.t, ,t S t. r i � 1. • . • J. 1 t , ,t'. � •.till HANDICAP PLAY AREA, CENTRAL. PARK C C-803 FE•BRUARY 28, 1991 Phone number incorrect - Detail "E", Sheet 7 of 11 of plans states Perma-bar is available from Peck's Products at phone Number 714-642-6131. The phone number Is incorrect and the correct number cannot be located. "Approved Equal" will be accepted. Bid Item No. 15 - Quantity unit is incorrect. Should be 900 s.f. not 900 ea. on the "Bid Proposal Form". Bid Item No. 25 - Quantity unit is incorrect. Should be 30,975 s.f. not 30,975 ea. on the "Bid Proposal Form". Lake Draining - The lake cannot be drained by contractor, nor will City drain lake for construction of pier. Lake Bottom - The lake bottom is a natural surface and is not lined with clay or any other material. Play area sand - Refer to Section 16.03 of tim Specifications for details of the sand. Type of sand to be Class I Beach Sand available from Til Tom Materials at (714) 837-•6677. Add Alternate Bid Item No. 2 - Refer to detail "A" on Sheet 9 of 11 of plans, "T-for three swings" should be deleted and "Arch Exerglide" be substituted. "Arch Exerglide can be obtained from Hanson & Associates at (714) 258-1616. Color to match iron forge play equipment. (see attachment) �.Y•.. r r / 1. • ,)) j - ,P ng •''''tl� 'l u.S.!1 .;; 1•^.,`�,,:F rt. ; +,tlN, �r3,l,Y+i': I�iiC:`.�+•i- a`/>'a:•:S:!' '!,' •yl••••.^--+�=n f(d7Rp{y�{rTV ..,ilf��• !1 ,,,.+�a ij��"S t �•• ,;,z;�i+�tt;: 1. T ,�,�-�wZrl'�,,'.i'1 -7, I r ' lit(-1�l� ! } t IfJ _ � 'r 1 ,1,r a • � J7 q w.p Ar.e' N .� � � ��� ���. ��1%"Y r •� { ' .d� .•1F ..,tri'i'l1�AI�i f 1 ''^ l��r,•� fG 1,, 11 ... 1 � '.,•- `•.•. ll}) l �, a I 11•'1 ,.,,, .r"i•�1� S `1, �. � � i f'��� �, ' I' � r � � E - Y _ }�� � � - r � � Ate• � ����� i 1 r,al1 �� i I�r•, Y� r �� � � �.��t ,91f. 1 I F , � � 11 L ai: .ti ,` � �1} 'i• 1 .'.. •,r Y el �`tp'�r, `� a;.. y�. J' Page 2 Addenduin Number Two dated February 18, 199I Very truly yours, Robert E. Eichblatt, P.E. City Engineer This Is to acknuwledge receipt and review or Addendum Number Two, dated February 28, 1991. It is understood that the revision of new documents shall be Included in the bid documents, Company By Robert Uc6► ;w�Secrltary/?reasurar cc: Jack Miller Don Noble Leslee Temple, CDH CC-803 "Gen. Corresp" 2859g March I.. 1991 Date ...+..I+rwrOR! 11111111111g (1 r � �f,,��,,,'�•!�� ✓"'f?i:�r'uh� iJ���M1�.�7 �1�� 4 T S ���i'r-�t•} li� ;z� �Ea M, f� l i s -1�1% 'I,W��f Ol ol WIN Ay-- 12% o4 Ai -I t1�,• �' 1.42 ;c 1 --. tr t.'•.>rw ,,.,. _ _ .,.,►:.. ...r,.a�.i.da.�.s:GT E�3�,i DATE: TuesdaY / March 5, 1991 2 p.m. ENGINEER'S ESTMATE: 150K JOB AND CC NUMBER: HANDICAP PUY AREA (Central Park); � r 'Ph'1'� � "•ref .,- RECEIVED BY .,i reenurer's Office CC-803 / �� / B nT nERS 11AME TOTAL BID AMOUNT 1. Artistic Lands i a ae a �`—Q 2. B. J. Construction O-mpany 3. Bo Park EntErprises S 0 Clayton Engineering .4. S . ! 7 i buzuExcal� l zi_ bt= Cbntracti , In rated 6. Hine.: Construction 7. Hondo crinpany S 3 S 8. Irvine Engineering Corporation _ 9. J. D. C. 10. K. V. S. Construction 11. Li d Flow 12. Los Angeles Engineering CwTpany 13. Marina Contractors 14. Pacific Design Concapts + 15. Byco Construction 7 OL, O_S` 16. Solid Construction 17._ Sunrise Landscape 18. Valley Crest Landscape O / !, D 19. Wakeham Baker, Ln rorate-d 20. The Wakefield Cmpany r f ' �� '_,.}6 � � C� � fl .,►.tea.'......,.... w.. —.,. _....—.�,.,•...7:IHC:7. �. ......�,.r.«,... ill:, ��< r, { � �, �,i1 f,h t i I.,, A.t1 ii.'r."'•A,': }I':'Yi, StV.dtMa:.�rar-..+ ..nnr.-i.�.nn � , �� n �6��1 �, 1 f,l r . r �l,►'S+1Stf ,,.i'.il'r�71���'ti�4, , ar"�� ��� � � -. i }�. ��t�' 1 �`1 r , �y} r, ;,^ .J` 'iT' ,� Ti..7 ,'`,}; It, '�',.fa t���r,.jy ��•%+� ,. is ? fc��:.lt'7�'� � i I>, �) r^ .. - � - - j ��+ tt �iN`r r• rl+�,`ry _ � 1.7 pit. �` ''�f fly. l ��,.. �'..� � "•. •. �'�� � +� r � , '. �`` r, ry��. ! �'�+y �.� ]51Y ~fir 14 ' " fi,¢t,► ,` fps �';� \ 1'{�� .ris Y .� �'� Y 1 1 1�l'i 7 �! _ - . • ' j r 0r r: ; , . •ri � � ��' �' .!t ' �r "'fit • � ,1 + Mond No. GWM M0r.JtIGV4 INSURANCE COMPANY KNOW ALL MEN E3Y'fIEESE: PRfsRENTS, that we, Artistic Lnndsca c. and Eng ineering, gineering, Inc. ' +"'!• r i as principal, and file GREAT AMERICAN INSURANCE: COMPANY, a corporation existing antler the Imes .0 5:� of the State of Ohio, having Its Administrative Office at 580 Walnut Street, Cincinnati, Ohio 45202, ,is 1 y , surrfy, are beld and firmly bound unto, city of Huntington Beach '.r-.: ,71 `•'+" as obhgec, in the penal sure of ***Ten Percent of Amount Did*** DOLLARS ($ lawful money of tic United States of America, for lltc pnyment of whicit, r well wid truly to be made, we bind ourselves, our heirs, executors, administrators, successors anti assigns, jointly arid severally, firmly by these presrnts. SIGNED, sealed, and dated tills 18t tiny of March I991 WHEREAS. the said principal is herewith submitting a proposal for "Handicap Play Area" NOW, THEREFORE, (lie condition of this obligation is such titat, if tite said prittcillal shall be awartled the said contract, and shnll within Ninety y0 ) tints after receiving notice of such award enter Into a contract and give bond for the fnithful perfirmance of the contract, theft this obligation shnil be null and void alh^rwise the principal and surety will pay unto the obligee the difference iut money between fife amount of the principal's bid and the antomit for which the obligee may legally contrncl with another pnrty to perform the work, if the latter amount be in excess of tic former; but in no evc!It sliall the liability hereunder ex.:eed the penal sutra Ilcteof. Artistic LandscaFe and T�pgineering, Inc. 1 hy,�� J 'rincYrlvl r;R1f�AT 41A , Ht cN # 1i ANY hael A. Quiglt�yA Itrrt' i►r'l ir�v r,gttr►c- t�/a21 llflo rggMt � !Y ���I�k l •.r i '. 1. i � h F y , + :stir (tt , ;.. � • �'�. tl- �Illi{i �p��'yjr �i�, .; h yl.�Jt �' r : ,ti �•' ,il?''+ r I •' r� , 211, \ * A4- •,f, , - r -1 ..it71 �tdilk 1• 11'4 t •t��Y•i 4r. i�j' • r• GlEt T ArVERICA 11 INSURANCE COMPANY The number of persons authorized by this power or attorney is not more than No. 0 13266 THREE POWER do ATTORNEY iKNOW ALL MEN BY THESE PRESEN7S: That the GREAT AMERICAN INSURANCE COMPANY, a corporation organited and exhiing under and by virtue of the laws of the State of Ohlo, does hereby nominate, constitute and appoint the person or persons named below its true and lawful attorney -In -fact. for 11 and In its name, place and stead toexecute in behairof the said Company,as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof; provid-d that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not excee:l the limit stated below. Name Address Limit of Power Michael D. Stong of Riverside, California all Michael A. Quigley of Irv'ne, California unlimited Carrie L. Price of Riverside, California This Power of Attorney revokes all previous pawers issued In behalf of the attorney(s)•In•f act named ahnve. IN WITNESSWIIEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these present! tobesignedand attested by its appropriate oflicersandincorporate seal hereunto afnxedthis 15th day of January •19 91 Attest GREAT AMERICAN INSURANCE COMPANY STATE OPOHl0,COUNTY OI tlAAtILTON--ss: �W Y y t>if•;,' `a`'�� On this 15th da of Januar 1991 , before me personallyappeared WILLIAM . MANEY to me known, being duly sworn, deposes and says that lie resided In Cincinnati, Ohio, that hethe Jlce President of the Great American Insurance ly" ti e Company, tl'.t Company described in and which executed the above instrument-, that he knows the seal; that it was so affixed by authority of R' 54, his office under the By -Laws of said Company, and that he signed his name thereto by like authority. r,'r y • `' ! } .� �•,rl�,'!. s� rer l y,r4 'y i. �y11N'`Li/, .x•.�,r4! Pf j This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great i'':• [� ,��:i ` . •,; Amedran Insurance Company by unanimous written consent dated August 20, 1979. RESOL VED: 77at the President, the sereml Vice Presidents and Assistant Vice Presidents, or any one of them, be and heret y is authorized. Itom time;J time, to appoint one or more Attorneys -In -Fact to execrate in behalf of the Company, as surety. anv and all' : I bonds, undertakings and contmea or- Curet sni or•other written obligations in the nature thereu to prescribe their respective duties +F'�1. ;i�'r;r.•�,�•,,rY+L•• ds Y p• g f' P P and the respective limits of their erthorlty. and to revoke any such appointment at any time. r RESOL VED FURTHER: 77rat the Company seal and the signature of an of the aforesaid offrcen may be affixed by factimik ' k' to any power of attorney or certlJL-ate of either given for the execution of any bond, undertaking, contract or rrret}'ship, or other t e o ; ��,,ri'` ; tr vrrl:ten ubligarlor in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the uiginal :( +, `y signature of such offFeer and the original seal of the Company, to be valid and binding upon the Company with the same force and effect '• � �, ro r , as though manually affixed.�'�� l t i 7+ j1�,r.� P i •� CERTIFICATION P Y • " °' x 1, RONALD C. HAYES, Assistant Secretary of the Great American insurance Company, do hereby certifv that the rorcgoing '• z ,�^ Power of Attorney and the Resolutions of aie Board of Directors of August 20, 1979 have not been revoked and are now in full force and effect. l 7 aS�, Signed and scaled this 1st: day of :larch . 1991 *J, raj F 1,1%•L q`t 't'�� i ' ��� 51019M t07/901 � ,fir ��• • � �S;I r�`. •rid ._...,.•. r— .......w.+www•�••.rr�w.,r.�........ww......r«�...+..�..+•..��....,���,..w...--: S�T'!w,e+,►�"'^.•..,�.•-•+.,� i,R,'�� ' 7��t1 y,.(. t !j y+{• (� . �,1 ,, t f , , +� r�.r t •i S 4C i � 4' 1, ,: 1.i'Isr',, YNtf�•I( v' tr , ` '1 41 f 1 \ ` ` �• ��•1,. r i, �I. �,t f ,ir,� fflT�1;,i125(r�,r ,'�(�+ r.,l, S 1��1 - r - � ,. i � .. ,t ' 1t,1,+',• 1'�Y.I,,'�"Y/� �f°r.1 1rr•�'1,•fl �I i.�, ,�;, £ i. ,,. ;!,,!�J s, ;411 ti '/,fir }.,r ,f tl, I. • t t+' .i n I4, `L�., t.lr�lt 'i^+�F.�r,.Y + i• `' j1 �L: fr. j.��(, .S aS 4 •i{t F�f� '' ' �{ • t �f >tl. 4 I,[i ij t•,Q iy i •,79 l f i�;,, 4�# �f/�l7j114•:+ { r+,l; �'a, � ,�. r rer ' , I /}' � , r{ �• 1 •$i �,ff�}I S�1 re'i1 'I�{ it 1 t,1 ,`1'' " ,r'.�rt •,: I' 1 , _ ,7, t, '•c l r' }j }it7�1�.ti�t V. 't. -�f �{i �t� !it i.a : 1 f •. f � , ' •' �•, r i -. ,' t .�!4 i'. •'r. , �Si i � 1. i,►11 ' :'�. , �����rl y��}tel+l \ r\eft • i`' ,, 1' t ti�fi t ��� �7+ '��1(y!!}•+ t i � ����•'{ I . ' i ti:_ e , ���tt� tiff . r iw , ! ., .( +..1 �. , a i .� ,, .fir• -�� F'''�R. , 'N !'\!i �, '/(}c'f (t ! 1 ,' •' - - N I 'r. Il tt,t �'�A '�Y•S, r l,r S'•`,' iti f�' i T • H iy } 1r, •i r ., •� :1 t . J' M , ' '� 4 . a: c a _ ;�. { �!,{ar �.:}�tiMfi�_.,rt , J t11,• - 1 , L Ji •��, r ' r , • �" THE AMERiCAN INS''ITIjTE OF ARCHITECTS t AIA Document AJ10 ra,. rtti?Bid Bond I ysi}� KNOW ALL MEN 'BY THESE PRESENTS, that we SOPARK ENTERPRISES, INC, lrtlts,eun foil lief led lddr,ns H I tl 101• of Crllrlaafl 8560 VINEYARD AVENUE SUITE 103 RANCHO CUCAMONGA, CA 91730 as Principal, hereinafter called the Principal, and GREAT AMERICAN INSURANCE COMPANY 1 4 I loot, l•►ytl owl M-0 W'd U*11"t of Irill 1114 01 srruyl ?50 THE CITY DRIVE SOUTH ORANGE CA 92668 a cofpu►atlon duly orgsnixed under the laws of the State of OHIO !,.•; `;'•' �f,,�r;f r,il' as Surety, hereinafter .ailed the Surety, are held and firmly bound unto Mat inttrt toll neMf /d.ktu of Itad title of 0wnlq CITY OF HUNTINGTON BEACH ,1 e• ,, �:;.1 as Obligee, hereinafter coed the Oblillee, in the sum of TEN PERCENT OF THE AMOUNT OF THE 7• . ,, � ',v��- Tit , ACCOMPANYING 0I0-------------------------___----------Dollars ISM ,Oil 0 BID -- for ), .t.± for the`Nayment of which sum well and truly to be made, the said Principal and the Isald Surety, bind ourselves, our heirs, executors, administrators, successor: and assigns, jointly and severally, firmly by 4 these presents. y1,,., �. �f ' r�''� ; ''ti,`f "" WHEREAS, the Principal has submitted a bid for rrb.v,watt toll ,u..ot, rdlarus sold d4tcrstnlet+ N sfrl•mt HANDICAP PLAY AREA » CENTRAL PARK 4 1� NOW, THEREFORE; If the Oblistte shed accept the kid of the principal and the Mndp.l Oull enter into a Contract p t_ with the Obl:gee In accordance with the terms of such bid, and give such bond or bo(sds as may be spottrled in the bidding or Contract Ommenu with &9W and sumclent surety for the faithful panioeeance of such Contract and for i:s prompt payment of labor and material (afr(1ilhed in the pro"cuticn thereof. of in the event of the failure of the irineipat to enter e rr s4ih Contract and Five suzh bared or bands. If the /rincipal atoll per is tits obligee the diAertme na to esered the penalty , hereof Netwe'en the amount speciflod in old bQ and suds Luger anoint far Nhich the Obbgre nW In Rood faith contrecl wish another parry to perfo(fr. the Work t-wared by sold bW. then th!s obilgAlion shin be l%it and wid. otherwise to remain in full fora and effect. a' tJ � ySISned and sealed this 4TH dg of 1 19 1 1 y r1ARcra g1 k' :F t 1 r{ i BOPARK ENTERPRISES. •' ''• .s�: ; �;cs:: �1-tcirl Gc.� %�.A-Q�d'►�-J rpr;nd .q rso,sl � 13Y: GREAT AMERI17AN INSURMEC Y (fuftrfYI fsed� s fYVitness) BY b5Lk"g �T.. b f KIM M. WALKER rid*) ATTORNEY -IN -FACT AtA 00CUAI11i11r A410 • dip 110140 • AIA 0 • ItIlRUART IM t0 • THE AWRICAM ItifTIM111 Of A9011T[CTS. 1735 N.Y. AVt, H.W. WASHIMMM, O.C. 7o0R`1 i , A?", WwaiGi't WRn4IR 7tlro n"iIiZT-,•'4*e"•71"P!.'!•a(1 "Vtt1Yt1► (t �� �. f �� ', ;, � ' is l , � , ✓' �� . , t l l , •t l � S, lu 4.1 1. l.t 1• , 1.. 1. :,' tr -r I 1 -. :� .'r1 J, 'ii„' 'i Y{� r'��1 r'� !t '''111 i.1' l �{��! r'i\1',.� .in+fi r�f 1 �\,' �' r. • � - '.. 1 , ` � '�..! i3 r t' J^+i Fi�1.4 is ti•:r ��s n �1a� �,a !Ir i�t. ,y,i� `. I: ,I . .. •! i� f 1 '�-�rJ ti 1 �• 'i•�1:l/1 / 4• �, ir.� .l - .1_,! I A / t., t11.{+�`. Y 'r • � Ir 4t Q •.i. i 7+9• 1 �� 1. i. ..�,r�r .: .:i t *. 1. , /�l r ',i •y7 1�1 � Jf,w •:' •"' .;Yt}.IS, f 1 �{ � ,�� a, 1 1}r' • � } r �.r . f r�, liht� t.t.� •1� 17,} � d •'� 'T yS �. , , � t,. I 1 1 , r, • 4l1 �t r [ �l ., �Z'•. ,.• ?t Jhr'r'�� 1i••1 h• _•�. i .., -1,,. S�I�'�,+tt'elra 11!✓ra i MI' r ii't,l 11'll��i,lr 1 +r;• `^I its; t �I}• „g§11fs� rip �. !r{ rp`',I�tL', ! yl.;•r. . .�,��• 1 t! .t + t 'i��lrt r?{,.r� mil ,,f r�„.il;: (� (,�,�, .y�j I' lr .i. ', _ `` j_'Iltr .,,,� r• J` �j'k5wffll ' ."Sir /' 777r' r.�i� I !,• 17� t , G � J �' � f '^ { , i! l y f' r 1'� ti l V 1 [ � � [ 7' 1 J J/I • I L "1 1 L' ' [ I , t l . \ .. t 1 � f � �• 1 • a r ;,7 h ,s/ G I I 47 jjt . 4 _ 1 F . , [j+ :; Z�tr t• �" r GT�' NERICNN INSURAN1.JE COMPANY },kayh The number of persons authorized by this of attorney is not more than No, 0 13241 power POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS.- That the GREAT AMERICAN INSURANCE C04PANY, a corporation organized and existing under and by virtue of the laws of the Sate of Ohio, does hereby nonfinite, constitute and appoint the person ur persons named i 3;t below its true and lawful attorneyIn•fict, for It and In Its name, place and stead to execute in behalfof the said Company, as surety,any and �f all bonds, undertakinyp and contracts of suretyship, of other written obligations In the nature thereof; provided that the liability of the said rF^` • Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. = 1 t Narre Address Limit of Power JOHN CALVIN DONALD R. DES COMBES ALL OF ALL ROBERT J, CULP PHILIP E. VEGA POMONA, UNLIMITED JAY P. FREEMAN KIM M. WALKER CALIFORNA'A l This Power of Attorney revokes all previous powers Issued In behaifuf the slaimney(s)•in•fact named above. n IN WITNESS WHEREOF the GREAT AMERICAN INS URAN E COMPANY has caused there presents to be signed and attested by r Its app. oprlate officers and its corporate seal hereunto afllxed this 9tin day of June , 19 90 ' Attest GREAT AMERICAN INSURANCE COMPANY � rr f rr I Il I tl h I T 1 t •a tC,3 .VT,11)• M �1/ r STATE OF OHIO, COUNTY OF HAAHLTON — ss: On this 29th day of June, 1990 , before me personally appeared WILLIAM J. MANEY, to me known, being duly sworn, deposes and says that he resided in Cincinnati, Ohio, that he is the Vice President of the Great American Insurance Company, the Company described in and which executed the above Instrument; that he knows the seal; that It was so affixed by authority of his office under the By -Laws of sold Company, and that he signed his name thereto by like authority. This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American insurance Company by unanimous written consent dated August 20,1979• RESOLVED: ?'7tat the PreAdent, the xevrral Vice Presidents and Assistant Vice Presidentr, or a.tv one of them, be and hembv is authorized, fiom time to time, to appoint one or more Attomeys•In•Fact to execute in behalf of the Company, as surety, any and air bonds. undertaAfnp and contracts of suretyship, or other written obligations in the nature thereof; to prescribe their respective duties and the respective limin of their authority: and to revoke anv such appointment at any time. RESOLVED FURTHER: ?hat the Company scut and the signature of dn),. of the aforesuld offlcen may he affixed by facsimile fo any power of attorney or certificate of either given for the execution of any bond, undertaki►tg, contract or suretyship, or other written obligation in the nature thereof, such siartature and seal when so usrd being hereby adopted by the Company as the original slgrsature of such officer and the origfnai seal of the Company, to be valid and binding upon the Company with the same force and effect ss though manually affbeed. CERTIFICATION I, RONALb C, HAYES. Assistant Secretary of the Ghat American Insurance Company, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of August 20, 1979 have not been revoked and are now in full force and effect. Signed and seated this day of , 19 51029M 103/90n •i7rw r•'�Y'�+.nr`.w•kf.w•:•-•�arNM•�•-rr.[n.ww..�w«rw►[lrlw7 cwy�r�:.R/1,}{+�7U11{�/ ill � S 1,F� �i '.n,/� 1 � �~j`,�/�ko SW 1'. ��;.I '. •• �' r 1'.-� � —��. '.._.. ..�"J. � i• •1 'e`,'�.' rs:l,)t +� r ..i j'• �r':L •� J/1 + t ' � -�' , ` ' l/l )- �1jS .lal��.`i r�+'�,jr,j�?�`.,t ` '�• S �j! •! �1 ( ll�'' �i ' _ � ,{i�j7'�1�ii +'tr i• f 3� ��. r� l lax J.r {. .' �'. •..j. i _ .1. + , r: ' Mai 41..F 1P.rf' l�)Y>, !. t= ,..t. '•�' 1 1• �, r .l. t _il ' tit,v.�1�7rr'� l��,Ar ! 1, +.�r'l� L =4d �f6:r �• , i. 1. 1 tr. .',, . y�trlt t: + � r ' � '1 ' , ,- ' � t 1 , _ • =t,'. ,. 1 ,�� 11 t l,ll�l t�l} �,' , ��1.,' J! �i,,•t1/ •, + I t• _ � + , , r 1,, lt.,. {•T,y y,J ;,. �r'T 4 h • •• i� �rw r ter a,/ c r J *fir ,�. �+ "y1"i;�;: ,,• r.,*r.� r_. '4.:r'. T`.:` •�a• fit:/-( V. t 7, YF iY I N I MW ra r CO � f , s SAFECO INBURANr.E UJMPANY OF AMERICA GENERAL INSURANCE COMPANY OF AMERICA FIRST NATIONAL INSURANCE COMPANY OF AMERICA HOME OFFICE: SAFECO PLAZA SEATTLE, WASHINGTON 90185 Hand No. 5510107 KNOWALLBYT/IF.SCPREUP'N ,,,Thal we, Caton Engineerind,�Inc.- of Laguna Hills, Ca•t,i£ornia_ (hereinafter called the Principal), as Principal, and SAFECO INSURANCE COMPANY Of: ANIIERICA (hereinaftet called Cite Surety), as Surety, ate held and firmly bound unto City of ll*mtington Beach (hereinafter called the Obligee) fit the penal suns of Ten Percent of the Zbt:al Amount HpidDollars ------ rrr...nwwww���wwwwww r�� wwwrir 10ib fur tie payment of which the Principal and the Surety bind themselves, their heirs, executors, administ•ators, successors and assigns, jointly and severally, firmly by these presents. 771E CONDITION OF TiIIS 08LIGATION 1.1 SUCH, That WJIEREAS, Cite N incipal has submitted or is about to sultndt tt proposal to the Obligee on a contract for Handican P14Y Area Central Park _ NOW, TyIEREFORE, If Cite said Contract be timely awatded to tite Principal and the Principal shall, within such time as may be specified, enter Into the Contract in writing, and give bond, if bond is requbed, with surety acceptable to the Obligee fat the faithful performance of the said Contract, then this obligutior shall be void; otherwise to remain in full force and effect. Signed and smiled titis 1st day of March 19 �1 Clayton Engineeringp Inc. (Seal) Principal r Witness _� �EW M. MUg", lft.. Title SAFECO .ASURANCE COMPANY OF AMERICA ny z BY4J I, Attorrey.ln•Fact J t' PRINTED IN U.S.A. 11/75 r � `r• ii,# Y.• }}+(ter illlt jt �',� i "•,, t t 'Ir r�,T ., is �, t 1.• I/ , t �I ! liirlt �r }a }!r!r i M,r 1�•�C�, a ,•}+ r i ,�'i } t lArhrf+iyi� , r r i r I 1 C, A 3 , i , r rw�rr 7,tr.;.i41 t I t od f� 11,j' ,. r •�. � .. �SIS of .� • 4ir 1 a � f "r. ;-. '+` I�� it � 1 ' :, ,,,� ' .+,'irt�+nr+:ww..aw,wl.r,..1..et.r..r.•a - '< 1l t, 1�1�'' , °, ANY ��• •' a POWER SAFECO INSURANCE COMP OF AMEI ICA OF ATTORNEY HOME OFFICE: SAFECO PLAZA r' SEA"LE, WASHINGTON 98185 ' 94FCal No. 8096 KNOW ALL BY THESE PRESENTS: That SAFECO INSURANCE COMPANY OF AMERICA, a Washington corporation, dues hereby appoint 4—JEANETTE A. FEDERICO; JEFFREY R. GRYDE; Irvine, California--___--_--_-- its true and lawful attorney(s)•in-fact, with full authority to execute on behalf of the company fidelity and surety bonds or ` r f undertakings and other documents of a similar character leased by the company in Iho course of Its busine••s, and to bind + SAFECO INSURANCE COMPANY OF AMERICA thereby do fully as if such instruments had been duly executed by its I�' regularly elected officers at its home office. IN WITNESS WHEREOF, SAFECO INSU6ANCE COMPANY OF AMERICA has executed and attested those presents tf.is 19t— day of tanita y CER71FICATE Extract from the By -Laws of SAFECO INSURANCE COMPANY OF AMERICA: "Article V, Section 13. -- FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appuinied for that purpose by the officer In churge of surety operations, shall each have authority to appoint Individuals as attorneys -in -fact or under other appropriate titles with authority to execute on behalf of the dompuny ;idelity and surety bonds and other documents of similar character issued by the company In the course of its 4usiness ... On any Instrument making or evidpnc,ng such appointment, the signatures may be affixed by facsimile. On any Instrumont conferring such authority of on any bond or undertaking of the company. thn seal, or a facsimile thereof, may he impressed or affixed or to any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of SAFECO INSURANCE COMPANY OF AMERICA adopted.luly 20. 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V. Section 13 of the By -Laws, and (ii) A copy of the power•ol-attorney appointment, executed pursuant thereto, and (ill) Certifying that said power -of -attorney appointment Is In full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, Bon A. Dickey, Secretary of SAFECO INSURANCE COMPANY OF AMERICA, do hereby certiry that the foregoing extracts of the By -Laws and of a Resolution of the Board of Directors of this corporation, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both thn By -Laws, the Resolution and the Pourer of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto sat my hand and aft xed the facsimile seal of said corporation this 15t day of t'=h r ;� r9r +j �•r�0011SLlA yJ;t r `4 i M11NrEe Ih V S A • � ° 7 �1• _--------...r..............�....r.—rr.rrww•n �,uwnw.Yww.....�•.-......... , _•---�-....r.—. M ,�� 4 s 't•' f� I t� '� 7 r I � 1 Q, � r t>,; .r ry: f �1iii*;. �� 0.�;• I tt1...Itt�.�'j li +� . ,l ,1 I. ��� ,.' .r '. I a 1� }IGt . 4 ,,, i . y .JY tf ,,.. } �i d ° I ;+. ' ,'a ` jl�,Y:•,•. • l.' ,�. I•YI i :M°� G" it d�.. r_..•...•. nr�.. (,,. 1 ,, 1+.. r.. '{.�' r ,.�'. rl It, 1 �,� !.'17 7• :1 t: �1�-. YI�,rA '�`�• fi j _1: ,. it t. t i i � t1. ,i 0�. ..` pt:a ti't�•Q3�{` I e+!•:�i I �•'i'. . . �' :�, ' ,r ' ° t.,-.° r�r(�r'41F,�' ,It7 .I' r /if �1• I � I /':T��rr� ,'. ,')I a t' � :•, i. i' � •1� ' •Ir. �• �°i1��7 ".�•�!•. ,40r1�;. r l�r { '� Lr`.`a1r ,`i• i J _ •A, - 7 r rI 4� to%'Jliti 94fj�i ,�Tt�. I'•f� t�, �: t y ,y i 1 /,t a.,;�' t.�,+yY�„li �. , iyy,.� Ir', }I :'J,r'il•'[ jt ��''7°�, j.�r r. '+ I{• �, _ .+ J1: 1, •i 17���/�.I`` �t°'1�' � � � Lllf:^i.!Mj7, Yt r.•° ,r . ,a ,. �1 � { � . I1 .. � I ', �i � :1� + }11 -J! 1 'I ',' �.. f , ' ; }�. !�'. r ,t� ' 1.1�( Ifs, t�' •F t Mir � �i � .: ° a �'��J Yh � �.' � tl .l• �� 'y a'',{i�.r?li`vti��:tl�t '�, '''.'� tti ° .' 4 e a 1�• ,"�, 7 r ; 1 I r I r i; ,'i 1 _t I J`(�,• , t t�tt a•,+rt�•�` t 1�;,art,✓t"f 7 s! ra ' r 1 t rr �ti• l a': fr+ t i so, .f I tt1Sr'•I , a `t 'i , w lytf ° J �, . !1 1 iL'( :b ''°h• j;. 1 .• },, !' '7t f` , y f 1 {• 6 11 y7ty +t 1 r) r` _ fl Bond No. GVF. XMIUCM INSURANCE CDMPANY KNOW ALL MEN BY THESE PRESENTS, that we, A r .r ►icf; � Y Hondo Company Inc. 1 10 as principal, and the GREAT AMERICAN INSURANCE COMPANY, a corporation existing under the Irws of the Steta of Ohio, having its Administrative Office at 580 Walnut Street, Cincinnati, Ohio 45202, as surety, are held and firmly Found unto, city of Huntington Beach as obll7ee, In the penal sum of Ten percent of the bid DOLLARS (S I0X ), lawful money of the United State: of America, for the payment of Nfhicl), well and truly to be made, we bind ourselves, our heirs, executors, administratmrs, successors and assigns, y. jointly and severally, firmly by these presents. SIGNED, sealed, and dated this 22nd day of February 19 91 WHEREAS, the said principal herewith submitting proposal for Improvements at central park for the handicap play area NOW, THEREFORE, the condition of this obligation is such that, if the said principal shall be i awarded the said contract, and shall within ( ) days after receiving notice of such award enter into a contract and give bond for the faithful perforrmance of the contract., then this obligation shall be null and void otherwise the principal and surety will pay unto the obligee the difference In money between the amount of the principal's bid and the amount for which the obligee may legally contract with another party to perform the work, if the latter amount be in excess of the former; but in no event shall the liability hereunder exceed the penal sum hereof, F,9r36K—• (3/a2) (eta FOAM) Hondo Co/pny/ Inc . Robert Mayd. G PriJ'rrip21 Secretary/Treasurer GREAT AMERICAN INSURANCE COMPANY By Z— Ana711-N-Mart ,Y 1,1 (�� �R.L�S,Y t) !t ` 7-i J r, , i "".�'^ •` t,`.� 1 tr.p� i 1r , 1 , ' �� �''•;t taryY •)jl t1)_r�•'r,' t r.) ,t � ..; - '..' 11 �' r r't r�,i )y -•'^�''�����5 �� 1j"Yl Ili fkl�� ;':1 tr 1 .,INiy �4hl� f.� t t lr: � tip 5'�, 51 •1 Il r 1 - �-� 13 t� ; r� ��l f�, jl 'Tlel +�•, Jt ri •5•' t.G r �••tj'jjj]]}7f)�`t. 1 .,. 5 1' `• 1 1'J!� l- T +1 j Yn.. � �''r r'.� �1. 1,1�I�AR�I)r~ ��.r )+ �, �r :'1 � ,t��•1 rt� a ,'! •y'+, ,I r' ' �lr'ctit' .t��y. � ,ti ',l, r y '.' .. "ti �1 r1+��' r IN, „f `�. f/ I�, i4 �},� .i. t' ; 'i{' ; 1•, , .. t t r tt��t rl: •. ��� r '� 11 �� ( rf{ •'� L I� � r 1 j' 1�` r '', a � 4fr�� jja... ti t )~� .` f 'i � (f •f �"-� YI + :f I" +�i. t�•iq fvr �r. „ 1\(It�l;t I /. Iz It r �•1 j1 •�t� f'�'.� IG,L 1{�,�4 1�'• �t + .j.+•r y � r��{l Z �•+�`''� ... � ��ft1 , 5� ' ,, t.�.i����j. ti' '��x;� •.I, j `• .�� ,4+` 4' !n, .l'((� .i 1; 5 ;l`'i t t1 , 1 t 1 '�• 1 .I � � C � Niel ,jd''i tip! /1�I/ its ' f,` •. 5 r ' rr 1 '? ytLr �'� rr ��{,� �r4X11I 1',!/''" r f. c i a � ci •', f r . (,rl yi,l�,t f•a ~���1� ,'.5 �"Ja , - 1' '(,- �S �.:', .11 �rf •t Ij � !Al ��fy ill'•A:;�t irr � i�� �"���s� i •� - _ r f (�� t' ,� I t . _.n -- •Ilan .ss-�,__.. ._i. _.—.---��_ ..._._--- -- ---- -... .. - _ 1 ' , '\ �' '"•� •�{!< r r '1 t�J���J' , 1S1 jt"1 �•/ A' � ' r�i + . i r ,Jr•'JF3��5iXif/t %4 � o de so ;j ' • GAT"AKRIM 1NSURMCE COMPANY' i• „ �� � �gg ,.{ The number or persons authoriLed by this power or attorney Is not more than No, 0 13194 ONE POWER OFAT7URNEY +'' �>+r+ ';i +•,o .,r ;' , . KNOW ALL MEN BY THESE PRESENTS& That theGRl:1'CAMERICAN INSURANCECOMPANY,acorporstlanorKanised and%'-', + •�<<l- `rFt'' `' �� rp1+ '� :' existing under end by virtue of the laws or the State'or oldo, does hereby nominate, constitute and appoint the person or persons named,,^ram �.I . below Its we and lawful attorney-in•fact, for it and In fit name, place and stead to execute in behalf or the said Company, as surety, any and'?.- s�y all bonds, undertakings and contracts of suretyship, of other written obligations in the nature thereof: provided that the liability of the said Company on any such bond, undertaking orcunirsci of surelyship execuled under this authority shall not exceed the limit stated below. Name Address limit of Power RICHARD C. LLOYD IRVINE, CALIFORNIA UNLIMITED 'w `'i?c�' This Power of Attorney revokes all previous powers Issued in behalf or the attorney(s)•in•ract named sbnve. ...� •; ` a, . r; rjll 4t;: �'f' ''�r!'(r •� ` IN WETNESS WHEREOF tF iGREAT AMERiCAN INSURANCE COMPAN?• hat eau:ed these presents to be slaned and altesied by . its appropriate orlicers and lit corporate seal hereunto affixed this ' 13th day of July .19 go'' • •�, rc� _'. •i `'`>'� 4`�r �; 1.�:: Attest GREATAMERICANI SlIRANCECOMPANY A t•iton► .%&V#.1dr I Vice ACA.ent�I ` STATE OFOHIO,COUNTY OF)IAMiLTON—ss: ,r On this ' 13th day or July,,1990 ,berote me personally appeared WiLLIAM J. MANEY, to me t ' �I1,,?�� r1•,'y Ifs'!',. known, being duly sworn, deposes and says that he resided in Cincinnati, Ohio, &hot he is the Vice President or the Great American Insurance Company, the Company described in and which executed the a6cive Instrument; that he knows the sal; that it was to affixed by authority of ' his ornet under the sy•Lawt of said Computyy,and `,that he signed his name thereto by like authority. r , ' p�' 1,~�'1' ' 1,+ +i„7 , ,,Sr if ` 't • ,� mow.'' Ei.ViIJ A. FLAMM 'r:` `f J ° ',, ''' •' °• Nolnry Pubiic. Slate of and r I, •," F' fly 7�>`1 F ;•, .!.�.: •� • Mr Cclnmisslo0 �tFltCi litL 13� t?91 Lr .ram �,� '� ., , .,� _.+•iti c1t1J +:.r � r 'FJ 'tt `i •1 , � r, .•.• rL, ..f Yr �1}fir+~{. 1� -'r �: .. •t .r, ;r • J This Power or Attorney Is granted by authorily of the following resolutions adopted by the board or Directors or Great t y/ •' American insurance Company by unanimous written consent dated August 20,1979. RESOLVED: 7lwt the f'►tesfdent, the several Vice Ptesidrnrt and Assistant flee Presidents, or any one of fhttn, be and hereby is ;l t'f f i I lr .'� • ' , + , r1�s�• �' autholised,!rom time to time, to appoint one a more Attorntys•In-Fact it, :secure In behalf of the Company, as surety, do} ar,Jall Ir • '' rr�;;� f I'4R�'; ;' ';; bonds, undertakings and contractt of suretyship, or other written obligations in the nature thereof; to prereNbt their rlerNtoNE dultel y,',; and the njpectlrt llndis of theirauthority; and to revoke any such appointment at any itnle. t !., , t f �• r 'r '' iQE'SOLVED FURTHER: That the Company seal and the signature of any of the aforesaid offlcen may be afnxed by facsimile 1" ' to wry power of atlornty or rerd.07edte o either yen for the execurto:i of an bond, undertaking, contract or surer shi , or other . • J ., ,r f .., Y Im f ti y g y p ,written obligation in the nature thereof, such signature and seal when so used being herthy adopted by the Company -as the original r' Ir s rises o such o err and the o►f trot real o the Company. to be valid and bind! upon the Company wi:h the same force and a ect •, . ' 4lna t 1R ti ! pa y, rt6 Po pd y f% • . ' ,c,";J„ J`;; a,rthoushnsanuallyaflhred r' till t CERTIFICATION 1, RONALD C. HAYES, Assistant Secretary or the Great American Insurance Company, do hereby certify that the foregoing r K ° ' Power of Attorney and the Resolutions or the Board or Directors or August 20, 1979 have not been revoked and are now in full force end-. {r, � + �sr; t - . erfectt . � '•� ' ''• '• •fit .�{ !(' 2nd February 91 r Signed and sealed this ly + } �`� 2 eaves ,19 :• `y � ��. � � , r., , ,c i -•'• OK , �Z•e.}!R�S '+ ���777 Agri �, tit, u � "'!Z� 1��ff,,,��YYf r A.ur.t(.'rn! .�'ct•n•1�IY.' • ' � .. Y��i:` ; ��,-�� •t i" 5 10204 103/201 • •' ��5,+. ,r �-tf. S ,} ir1,f• �'�i 1rY, ,.. r' ,, itc..•.a,wr�..,......... _.—_..•...-........_..._.-..�•.-•—•-'�........�... �wwr �'�tTl•,w...w�.,�...r.r'w. '•IS 'l�`c{•,,+ •D� q� '�,iA ��}. fJY1f.1 A 11,+ i t t•l _ ,1 •, 14 �.'!f' 1 � ` I +" 7� ' � $ '�li ter �' ,1 t - - r • ' t f 's ' vA � r' i V' r •a1• ,?•i�{ 'k ',t iy�w^T ,7 , .ej, r J - ; • Tt+• ivy+/ \ 1. r` ` r J. (' ` • t, �l\�,^ •r.. ,t + iy+i4a'f t ij• ... .\ ,,}.•�#. " F'r.� I',t, r.'+ , IN r - • r 1. ''/ ..' , 'ir y(. `'�. 1 l•��'r 1 l,'.`:+ It •,�/Ij��uj�,f rf: r C{',� � . , .�r r i ��(I�,•� "Ni�{ ir� t; F �'!-4iir'�i , ' •1a i v 3i r' 'I Yi`� l+ 1;.1 , t I,,' 1� '\ Ir r� + fruit i� f„J •,t t �er h� ttl`riti ,iP�t}r ;.•, r ,�, ItA r'-. �r ` ... - .. I ':, , • - 1 N` 'A �\ f:. 'i. -, ' `' � .1'f, ... �.1 • i- f stir M : v •r .�� .!� •f �+,► , +tom ., s �r � 2. 4-1,,Wnfinen'tal rance., KNOW ALL biFN BY THESE PRESENTS: BID DATE: 3/5191 BID BnHD That,....MAN NA„CONTRAC.T0RS,, INC. •.....•................................,...........,,................. � State . ,......;....... ..........................• of ................................................... ;d hereinafter called the Principal, sad„KIR�H, N'.�...INSURANCS_q.QMi', jl�„OF,N :��1RKj...N W,,Ji~i;Sg,Y, ......... , hereinafter called the Surety, are held and firmly boupd unto. CITE„OF„�1l�NT NGxrJ11„its, Cr}i..... ...... ........... ................. ....................................... I .................. I .......... ............................................... .................. . ...................................................6......................•. State o f................................... of ................................... ............ . .. . ........... ................. ................ hereinafter called the'lbligee, In the sum of „TLrN PERCENT; �lay�„ JF„THE TOTAL AMOUNT OF THE BID , ,,, ................................................. .......I ............ .....................................6.........I.............................Dollars; foc the payment whereat to the ObIlget.......... the Principal bind..... I.......�t$................................heirs, executors, administrators, successors, and ■:signs, and the Surety binds Itself, Its successors and assigns,. firmly by these presents. Signed, sealed and dated this..........),af:................. day of .......... Mlgr.rh....................... . 19.1.L. Whereas the Principal Is herewith submitting the accompanying bid dated ...... for.... .............................................................. ............................... PROJECLI10.,, C¢1N,........ I............................................................................................................................. Now, Therefore, the condition of this obligation is such that if the bid be accepted as to any or all of the Items of material and workmanship proposed to be furnished thereby, or ns to any portion of tie same] and if the Principal will, within the period specified therefore, or, If no period be specified, within ten (10) days after notice of the award of the contract, enter Into contract with the Obligee, to tarnish all Rork and material at the prices offered by said bid, and will furnish bond with good and sW:Icient surety or sureties, as may be requited, for the falthful and proper fulfillment of su::h contract, then this obligation shall be void. And the Surety hereby binds itself and Its successors to pay to the Oblfgec, In case the principal falls to enter into such contract, and give such bond within the period specified therefore, or, If no petlo.! he specified, within ten (to) days after such ;_'ice of aware` of contract the difference In money bera'een the amount of the bid of the Principal on the work and mar;rial so accepted, anr+ the amount for which the Obligee may contract with others for such work attd material, It the latter amount be In excess of the former, but in no even► shall the Surety's liability exceed the penal sum herevf. lu fellness whereof, this instrument has been executed by the duly authorized represcrtatives of the Prlr. eil:al and the Surety. MARINA CONTRACT ... f INC:... . .. ........ .... ....... r (See)) /1 �ilincipil• .......................... FIREMEN'S INSURANCE COMPANY OF NEWARK, NEW JERSEY ............................................................... •Surety ©�:.......�.Qs�u�... .... ..................... LINDA D. COATS, Attorney--In—Tract Attorney �-4 moan x .r....iva M1�117r �'l p rw,twww�vaT,areMfn�.rna-o+a � (� i � ('1(�. trt�t'y'��.'f �'• � ,�'fti i 1,� i •. i 1z � I� } I �`•' ! I. 'i�l.i y`/`'�1,{{. V.�j. + ��.�r�.. 19„^■�!, i,i{,t� \ ,..,i),.(. `f�, ( ,�, '., " it . 1 S tt rix i, Irto 14 R� f '].r., ' c•. A', rl� r'. i; Sf {• I I' 'i.� t tY to ti` t . ( '�/ t .. I. ., `.' - -. -t. - w isr ��Srr11<r j ,•t j � ��� t � �.'r?y�s}:1 "'t�, '117. �rC'I r , • 1' .r 1 , / r,. 1 • / F} :qyy S af� %1t'A'fy�M��•�n i� T 7f �% r� '' '� •• `fir rY ` � •'y'"','.1 jt'r, ,{'�ti�,�jT r , : i . • 1 , t ry / t � , ��r �.�.rrs•.ve:x+exl,tw..w�r+iA.,.rasi:rr�►1-� t .'r `r�g7r.Mtd!fY' ' r• , f A, ,W Firerner.'s Insurance Company of Newark, New Jerseyall 180 Maiden Lane, New York. New York 10038 GENERAL POWER OF ATTORNEY Know all men by these Presents, Thai the FIREMEN'S INSURANCE COMPANY OF NEWARK, NEW)ERSEY has made, constituted and appointed, and by these presents does make, constitute and appoint Linda D. Coats of Pasadena, Caltfomla f t' its true and ltwful attorney, for it and In its name, place, and stead to execute on behalf of the said Company, as surety, bonds, updertakings r { 14' 7' - and contracts of suretyship $so be given to J. Ey Obligeesy 1 t� J1Yl -r 1 }4,� h�✓ it ~ •.r1' Z' 1 prcwided that no bond ur undertaking or contract of suieefshfp executed under this authority shall exceed in amount the sum of ..l �, rr .�.i rs t•' , Ten Million ($10, 000, 000) Dollars This Power o(Aftomey Is granted and Ii signed and sealed by facsimile under and by the authority of the following Resolution cdoptedby the Drsard of Directors of the FIREMEN'S INSURANCE COMPANY OF NEWARK, NEW )ERSEY at a meeIIngdolycal led and held an the 20th day of February,1975: �I or "wavit), that the eh.bmm of The ioard, t6 Vice Chsln rt d the loud, the Arskit t, an Emwive Vice Preslden) or a Santa Vice Ihtshte t a a We Plasigiet ar at'rrt Company. be. antigulexhtjtsnydthemha lkawhariaedtoe.erutePowendananepgwAr dlhoanan ir.IM#dlntheOvenPawwrdnnomeyroeaecuteinbeWforthe FIREMEN'SINSURANCICOMPANY OFNEWAAK,NIWIERSEY.booth,urderakintiSMANCWtradl01SU! fyship;andlhrrtanAsthunlVitaftnidentaSeCf" ivAnA44solam 50001MY be, and that tt, h tx"d them Ioireiry It, audartted Tastiest the execution tar any such Power dAnorney, and to attach tMrelo the sect of the Comperty, RX711ER RISOLkEo, That thi s1 ruluen or omit often and the tat of the Company may be aHired to any such Rawer dAnoeney a to any, cmirkate relaiw* thetsto by ' taalnrite,and any PAftwerdArtorneyorrealficatebearinFouch facsimtlesipwturn orfacAmilewatstun be valid andbindinaupon t'reCompanywhensoaMaedandinthe lidLire ' F i with tespeo to srrr bor4 undenskk* a cocrtrad d see p to w hkh ft Is attached:' in W1tmt W ITerecif, the FIREMEN'S INSURANCE COMPANY OF NEV/ARK, NEW JERSEY has caused Its official seal to be hereu,►to affixed,eit s 1 aril these presents to be signed by one of its Vice Presidents and attested by one of Us Assistant Vice Presidents Ihis lit day of May,1985. ;l FIREMEN'S INSURANCE COMPANY OF NEWARK NEW JERSEY Attest: By ' .jfY` rS,�rlt, rx Z Ittk tf W. 1 ha Adift• St., Attiatant Vice Prnkteni •; �,• Mk t -t r .11ci'i'+r:ii,' '� ;Yr •r1r4t� 1'. ='• j,�.. I•�rifTH!`rt. %kt Re+WMII �t i' r tJxYtttl y , '`"i ' t• STATE OF NEW PORKIOU . COUNTY OF NEV On this ist day of May,1985, Wore, ifie personally came Michael). Deernaert, to me known, who being by me duly sworn, did depose e rr°�� +, ) and sat that heisa Vice President of the FIREMEN'S INSURANCE COMPANY OF NEWARK, NEW JERSEY, the corporation described in an' r; 1 at (Y/ t u ,�, r ,y ;.i;: which executed the above Instrument; that he knows the seal of the said corporation, that the seal affixed to the said instrument is such ter , corporate seal, -that it was so affixed by order of the Board of Directors of said corporation and that he signed his name thereto by like order.A.{' tr}tr, !A. tip. r r' rjt'�,•r ,�'1 unKr' t?NELTARAkto j t 1. '�.'% �;dlT '•,: ;, r�� NOTARY PUBLIC. State at New Ya* t� ,rl No. 244h0l 17 quit. ki Kkvpp Comfy J rc V •'t Comnihilon Iapies March 30.1966 CHITIFiCATIE I, the undersigned, an Assistant Vice President of the FIREMEN'S INSURANCE COMPANY OF NlWARN, NEW JERSEY, a New Jersey torporatiun. DO HEREBY CERTIFY that the foregoing and attached Power of Attorney remains in full force and has riot born revoked: and rt it r furthermore that the Resolution of the Doard of Directors, set forth in the said Power of Attorney, Is now in force. Slgn&J and sealed at the City of New York, in the State of New York. Dated the 1st day of March .19 91 M. Keane, Atthtanl YKe PtrtldeM jr, ' 21 BOND 4115K I ' f4Sn ,v1 ,n I r ''�it ,;{,'t sly ,.,..,t• �� r..-- •.••..•.,*.�._.._....-�..».�. arwa„A,y / 7.7 sr; j ; ;.,., rl �•}t57�,r• r 1 ' �} ,i , '`. r r ;.i fi 7. � �, ;/s :� .i i / �°J' !61.1 t I1!+j 1( ` r{' �'•. +fi 1 .�'. Y)� � ;�F {^' , ; I 1'� t ' i ' -1 ,i I tr , l . i�l,"I,,��i �' t(,.•! �r I,i, `J ,i ..�. , + ., ,%, r, V'r• j T+r 7 r t r$ .trrl s };S ta:�+� ,1• , I 1 ' I � r' �' a.�^� +t trt:,%��( `7i .y 1 t , • fr..'f �}, 1�(a1Y r {1 ., • ` lie . 1 • i 1. '1 I r • • tr r�,i,,' 1. ,� t�r1 'i'}{ rlt'f•''''� 1y1 1, (�iX�l fr/ ki 1 ,• rif�7�' i d•Y rr 'hi f t i lJ•,rr. ����jt1iJ t1, 'r `i' ,i �, .)� V%1i�1'i,,jrfi f j ,Ft•*!'�i ti ',�i �y• -� , �t`r ����t7rV 1 `u �♦�. fr tit, tor_ rj. ` i. ,• ,':, r '.. �� }a' :� a3 1 1 ai�✓ rl'. '�11 tt � 't , t+, I � L / ,', - t iI' , J, t'+ ( 't :1!a�w�' , tt !t Y;i,.• 'k �' I' 1 .. � fir �tf•gt r• , •t t r. I i• . �1 lyr_' ' I 4 ��►r IZu' a.� i �•k s E • � ,,, f I li t r- � � , fA r•I ' ^lM��,•• BEST PHOTOGRAPHIC �* �~ IEPR0DU C T 10 N ''Y t' rj r 7t " fir•• 'i •�.. . ,i POSSIBLE, DUE TO ,. �•� `t � � it AGE AND CONDITION � ! {buy �, I.r.'• k+lY t 1 f OF -ORIGINAL II �, DOCUMMNTS 4A 1klyr 1r ,y �r (�fr , •�L�, �1 1 t �•�i � fy,`.iy �•hi.:�in-1,�,-.�: ��r � �".i' `I. � j��r 7.. ^,' .z,. ';•.�,. .Cc•1�, #t,�r_ r1,,Ljir',fl•:, �,i ,, f' 1- ,I: ark ,,I � ,��,t�, � r J .� yr;'i4tr,4�t�Irt��M`�• �. Jtt7 •:.1tfSi�,� `�ir:�� �N+ I K� '� 4t t r Aft" a ' a:''1 ,.1�'' fN�, 1l,.r3•-' r;�; j t�T.k � �l: >'lr , 'r - • niJ /) j1r; � ? f,j''f'�.I � i fS •.' y ,�4 21ii V t Po' ALLIED MIC�tO-C3RAPHIGS 13766 ALTOM PARKWAY, SUl"1E 143 IRVINE, CA. 92718 k," •�y ik V • t. r hA+ �r ly� It rf r.�•'L'�� tt�%t ti. rrt,h �F ,i' ' t , l+.��r, � � (% , r I `•t� )t1Fl,,'trt,p� � � r � �.'( sy � �t;r�� it `'S !� I l�f vI � (r r .l"'•rr5 `� 'r .. 1 f�` r1 I I I 1�k:r ':.���S.x:+, �11 ~.�: "''t _•.�: r. :I ,ia• ...i�r�i'iw�-� .. i. ���"'�►• ° ,� ,,�tQfdJrr'f � Yl .. °a, ,`i r'�j''.�r �/ '}`r�t���>Ir'r �i�, i .'1`r t' It �' Ir•,, 17 �i ks�ty. ji�t� ,.tt�l�`�,��,`+�I,y�����, h » jl � (. r.ik,• I,(jl � Zk,� rf ' .I 1 �'` 7'tr� d�`'f'�' (� ri i 4 'E a,1;y', '`r ,� J'�t'J3 �,.I� , r r �. ,r,•� / , iY��I .>s t� "'.i55i . 1 ' 1,�'"�'rr� , , t. ; yr� . , • ,' � Pi r , If N + 7•y. � r ,W INDEMNITY COMPANY of CALIFORNIA BID BOND KNOW ALL MEN BY THESE PRESENTS, That we, Ryco Construction, Inc. 20555-�1A0 BOND 140, PnEmium: INCLUDED IN BID BOND SERVICE as Principal, and INDEMNITY COMPANY of CALIFORNIA. a corporation autnorl:ed to transact a general P. aty business In the State of Cailfornia, es Suroty, are hold and firmly hound unto City of iftin ti n gt011 13eliah -- Ihere;nefter celled the Obligee) In the full and just sum of test percent the amount bid in Dollars, ($ XG�fi *'` �'` '�-'� * * * * ��tar the piymant whereof In lawful monay of the Unitsd States, we bii.d ourselves, our heirs, administrators, executors, succestors Intl ansignt, Jointly and severally, firmly by ihu:e presents. WHEREAS, the said PRINCIPAL his submitted the accompanying t:ld for Handicap Play Area �. NOW, THEREFORE, If ilia said contract be timely awarded to the Principal and thu Principal shall, within such time as may be specified, enter Into the contract in writing, and giva pond, with surety acceptable to the Obltaae for the felthful per. formance of the ield contract, then this obligation shall be void; otherwise to remain in full force and affect. S gried and Sealed this , Sth day ofMarch 19 91 o j:oneltuct REV, 4.86 , In INDEMNITY COMPANY of CALIFORNIA principd T. L. O' LOUGHLIN Attorney-1At"RV" r'"r wwwwwwwwwww _lea +,N �' + !i'1i1 1 •',Iti r ;,I � ,. - t i r,r 1" et. `1 1 -''�T 1 'J , . j r{ �,, � �t�'f`i1��1�4. ,���j 7 �•�) r trifr4 / t � .� � � � •.',' .' 11 '.', 1 , �_ 7fY: "1� t �iirl�; G }rh '"� I itK'J� r jIS \,• t 'i ' � — �t 11 i i"+ti�S\ ' '�'S i (f1i ;r f J u < ►.ill f i; n f •' t � , ', , ' , '' I���,��ti •� E � f ' ' ( ,,•its ��I ,f ►' /Ja :ytit re t,_ i. t . _ {t � a/ Jr 5- cl •f I �z t; •,�. !1 rI 0 so f , PowEn OF ATTORNEY OF 0 t i s, t INDEMNITY COMPANY OF CALIFORNIA N_ �. 7C %� .A+NO DEVELOPERS INSURANCE COMPANY P.O BOX 19725, 111VillC, CA 92717 a 17141 26J•33G0 ;� r lh•tl ..rf r'A" r' , I ', I, 1I .r'r.-.1 ` j` , ' ihis 1,•err rl All't•'' Jt.,,, -1 I, 1, 1, II ,•;1 1 .1r r lhii 1',,..of of Alit I:. I 1 •11 t 1 1 u ,r rl It n'I _ ' T .� 5 ir-.Il•Arl f1 •111urii'' Ir—.:1 p„. •Lr. ..'1.r l.rrf I,r go KNOW AL MEN ::v 111r5E PMSIIWf 1 . that, 11.tsl'1 ,b n.Crnstty fifn red. 14DEMNITY :OIAPA•IY OF CALIFORNIA am Or'/E'LOPEnS INSUHANC[ CvMPANY, do r2rh i l aerer-1111, Lul slut ;clolly, helbhy tntlir, tWnl;l dle ,I'Wd IlPpulr.l ? iee r (' HUN WILLIAM (i. VAN ROOM JOINT!.Y OR £iEVE:RALLYeeY JAMFS H. RE:�TkICK, T. L. ) LOUG '„ftt Ir:•1 , M It a 1n1e sill Ilalul Ahnere,lal fact 1.1 r•l kc Irr rrA n•I t•rhnl)of nrrchpl yn d rpFimr3Unns os eurelms. bnndr, Lind 11tn11npi, inJ conlincligof 1 ' r r suro;yehq)it) e1I slt'ollnl nut t„f ••••u lip b•',nray r"' the. rsi lid Doda,s (S75 COPI fitnny sl. Ulr undriliklnq; (v.Ing rind pr'nt!avi unln said AIlc.nuylr)-In•Ft clIto papa and ,•\ ., r in do and to perform e.u'y of t lau.•r'v, lhrput h' or nrolnit In ho thine n Lannruakun Ihrreaah At eaCn(if a.r!f. corporehuru cauid on, b:drnsarrufg to M ;hn'. swd rn•pnrol'onf lu!1 Im."t, of suhihfutrnri Inc} re.rc;of';'• n 'd ,fit r,I It— )rl% of •,a';1 Aoofnrtisl•in l art waswo I I,I n •,':n ptose-lh, are hr, ploy t tlhmf null ronl,-mvil lit" suit'(my sod powucs co h, 1,, 1 P.' 'er ,I Alto tr r, t10 rol o-Iond Iu an, t'1Pill ludn. n') bnhdx un(Istrinlol')n o• (onllm is of %00vnh if 1 •, (lank dnpofllgry :nnd1 Ina-, ,',••'tl•• c"r'(t hnntli. Uu Jra It)r: I'I 'n11.1I'mrnl Impuf, 11Wr. (III.vilrIve t`011f.f. tionds nnl'r1ntI1111r'.Il IfUl (,ri lease 1Jt J hen,]!. er 1 (�nn.11. L(1r11ry bnnr!1 ( r t',, 1In "If. [•i:.. ihlrlbwafofAlturnet tgranImlit, 1'zrll'ndfit tecT...... 0onlir,-IndIt, &or,ontyufo-t-f Ilner7r.tn ni,,rlrpinclfor w.trnrprri,,,"V:)ardi lot [,'fllciorir)lINOEMNITYCtYIAPANY OF CALIFORNIA anti U[voLLP[iIS IW.UlIA11t7F COMPAN if, will 0. •n di of ;;nptnrnbrr i1 17P1, "1 r lIAESOLVED,thatthe(r'a'rmnnnlIlinIk Irlf.I-,.1',ef'dP'�Ian4Alto Vice Pres,oswlnlthe (,rl"r.h,.hlr.and1•W1r.Cf•.clmemilb tlt('y,s.authorliedlreo,n:LifePOwehofA•+•-,voi ^ riji tlnO the .Iforn6y1/1n imod m It Tl'uee,/ of Art n•r of l�)rinnlla oil hJtlsllol thr L(Uporal-.'., „till+und,olai�nga Will cnnlfrl.li ' 61'fIlly11,1Olilld lhnl lr,T foACretn•Y sir A—. ApA'.)%, It, nLn) Stl!r(lt/Iy nl 11'u Cur, (rift ;,n t r .1'.:I ' r f.l fr pre hlfur,i t.. aulhorlt oil Vi a!Irtit It'll rrlot Ion of any ;orti hu.t tit nl All(,, lot (.: •. . U NESrn,vCD.run (. ,u ner .r tr')I'rn•lotl" ..It-( s linn(1 t ay list aN1oan, ti,..:h llnvorw rm AA,t'rnny or to acerl�l�rAln lnlalctq l Porab)it,fai-smrfr. r'nd Apr nldh::nis- • C'f Alfo•. I nul r1 •..�,:.,1 L. (14/(4.,e1111l1_e111 htl.{fl''l)IUlh It( •R'r•1'rir';rlulrlVd')lu'.Idlf a'f.lt''nlf.11tfUl'11i111 r1'llli•11.1i',when S')11111trl1 Jlltf In the h',uln N'It' IN•,prr.1",an,1,1•n:1 ,'r'1Pr1,11Inc) rr ((-'•ari Jl sufelysh'p lit *1 IN ,t III•h.r, • 11 t IN1VItIjLS1i'N1111if(11i1stl[IANIT•,GOf,111ANYnrCALIIOff III AandIICv1aopens INSUPANCFCOMPAAYI Itnst• r, u,t filly r:lutn�.10.,.. ,, ,,n"nf�l',.'hr S•rinn,t sly fit, •,•yn•r tl .r [( i}i:.,' t [ f f) low" III s-wfr•ll'i lllld Ill... is:11,, 'I.r,�l r,�•(,r . '•'rr'1,''�. "11) 1, off,), towl,t t')111 INOEMiIITY (COMPANY or CALWOFNIA r VF.VELOPEFIS INSURANCL COMPANY t a y t r;J fly r .., _. L [',. 1,.1 •(\. 11 ,fit (; I:n•tt',I 11r•' /fin, l — (tiny C rrnweu. 111ru,fr'nl 1' • tii - , _ _. `�,• lip � � ,t,, t., % r, r. AIT�$1 ej ,itTfal i c t hills i 1„ sty .._ Us t it 1 t1Lillnr A ( ru,trt', .rrrrnl,tfl' IsValivi A t 't ill 3TATF OF CAI, itC,INIA iso ( UouNTY Or OIIANOC �! 1rd.vn�l{ : OnJ►.nuary?'1001 belornmr,ihtr'mtleis'rint.dnNnlaryfuyhclndndfor n,Lill;(lnh'.Oarsnnally,ittpn,uotlNl: :uryCh>,.nllnndNerA Ern, isuregnnllyk•tnxnlnn171orC•�.nrtlu ,, rr •4� ��,: �+ , mornIna hxeliulanilsta•:mlyov,deniminitn this prrtorswr)ofllect.1c(lthnwdhminoittrumenl as; l'rnfufnntAnd:irroilntyonhnhnlloflndmmidyCornpnnyofC. 6f(onlaanllno%1' •suU•nt i� and Secrplary or. befisitl o1 Doveloper5 InL,Macrl Crmp..irri. the Cnlporm-on9lhf•rtoo n1wroj ,Y'rf n'annwb d(ptll In flit. Won't the t. 'p(olillolIt' e.t•t ul.hl it ) I V4ITNES9 fay hand and olL•urn soil l -• i 1..:. '; 1 t OFFICIAL SEA( �.u•.uLA- fir ��,��r� *1. VIRCEr+,,I M. LOUMAN r '�1 1�� Slp•talu:• r. / NC1YJtY 1'I10LIC•CALIFOQUTA NuNry t)ublz ��PRINCIPAL OFFICE IN (t`;�ORAPKif COUNTY I : i'1 W Cor.amhsion Ito. Ay. 9. 191) t I t, r LL�J 1 T soma CERriFICAT!? Tho underslpneG, no Vice PrettiestIIIvi IWMNITV COMPANY aF CAUronmIA, and Vice riee ilorM of OrVCLOPERF INSURANCE COMPANY, noes hetahy cetht. hAt Ih,t twellolnp any allnehnd :'awe• of Attorney remains in lull lorre And tins not been tevaked; And furthermore, flint the prntla+ons of file resafuha,ls of tuft rail ochve fiolrtlis of pntlCrore r t < of said corporations not trills in the (('prior of Allurncy. sire In force as of the dale of this Certificate, Ihis CerNicete Is executed In the City of (•drip. C-ldrrrua, thin 't�- d•ly at _. hf[irCh 1D9 _ 1 1, `` i~ f io iNOP11NITY comPAN7 of CALIFORNIA DEVELOPEnS 1NGORANCE COMPANY 'fi i•AM► / i i r ^) / �%�yoai •/ !• h'���ir�_;�yt �iytrJji,ry .� OY. _.— � — - --- '• � Oy-----__'�-� _ _ u I� fu (1''t I�• j f� tT L,C. Fi.b:�er d� UGi /'� •!' G is b i�/+/ L.C. I bbiper n n !f 3w1(1 Senior Vlcn President . .[►nR.• �`• ,?sins Vice rlfestrfo•1, \v\•, rr •i ; �/ • i tt IDO•rnEV.l./BO tit '�`Tjr171►•`1T�• V l t_y1t' ' 1l r. '•� r r l' ))r f• Ir 4 •i i .!1r T _ r •:1 f i ,if �!'tir I l.•r r , _ b �, ' ) .7r) )1, yf� i�f jtiit i y �rrl ir}i t 5 f ) r,.. 1r'' h' 1fr %+, r , i' S ('r•t+� ;3 if1 fir`:. 4 If;►� it a �(}J5�, I/fflllljj YYri ii '' 11 . lV i (i 7 t i 11 .il •f `V r I l r' •l.r'11'tirr Yi���Tl' ,r� rl�)l' ,I 11� , \ -;L'. i. � r,,� i�-,L l- r• , c. Coll , ySt f( rFJL�Sf.'r h Y ! • t. , , t i }� f ,. i rI. toriJ ,( •.,i t ��� I ,i. ,• i It f. ri��. �. if t �-It L r�, , 'I ,1' t t t1 , i�•fJ • t ' W U I Ar 4 if. ? If OA*- rt , V ti A4- INSUnANCE COMPANY Or WEST x P. O. nOX 115563 -SAPI DV GO. CALWURNIA 02130-6503 7 AV, MI) ()It 11101110SAI IWNII KNOW ALL MEN BY Til CESE PRiSFNTS: cf Vint wit, Sunt-Ine Lationenlie Co. inc. U 9. (holelliallpf colled the principal), ariv INS111`14NCE COMPANY OF I ilE WEST, .1 corlintalinn oiqnniied Pnd (filing Ijusiliessundo( Rilff by vii fit, (11 the laws Of t1jo state nI Crillfornia, and duly licensed for the purpose of making, guaranteeing of becoming tole surely L upon bonds of undertakings itiquited at rtilhoriled by the law! of 1he State of Calif nritin ',A R as Surety, ate held and f irmly bound unto -oin Heach (110failiallet called 11 a abligep) City of lluntinj;t 1 "if ns In 1111 just and full stint of **i,ca rercent of Arnoui,t Bit e.-ihik 4 , A DollarsO _0- ------ lavJul money of ilia Unilett States of America, :at the payment of which, well and truly to be made, we Hereby bind owselves and 01if .11111 each of our $11-cullols and assigns, jointly -Nnd severally, firmly by their presents. THE CONDITION OF THIS OBLIGATION IS SUCH TIIAT, WHEREAS, the above bounden prencilial as alwesilid, Is aboin to hand in end submit to ilia obligee a bid or proposal doled 3/5/91 lot 0-c'. 16N Ill.-.y Area -Central Park" landi..-ap f Q 0 In accordance with the plans and specific; lions filed in the office of the obligee dnil under ilia notice inviting proposals thereforti•. ,hit 1 Y NOW, THEREFOPE, if the bid at proposal of said principal shall be accepted, and ilia contract for such waik be awarded to the principal thereupon by the said ahligee, and said principal shall enter into a contract and bond for the completioti of said work as required by law, Ilion this obligation to he null ind void, otherwise in he and remain in hill force and effect. 4(d V) X, 0 1: 114 WITNESS WHE."MF, said principal and said Surety have caused these presents to be duly signed arO sealed this 27th day of February '1991 Sent-iHe La nclocape Co., Inc.- 13y. OF TV. 6 Me T B Michael A. quigiciy )\�,,�At orney-in-Fdct CW CAL 170 r .,o4 t'j, 0 .1 4 kl� Iv> , 4 it N, - A —1, , I 011 7 kj. 4 A!: INSURANCE COMPANY OF THE WEST HOME OFFICE: SAN DIEGO, CALIFORNIA Certified Copy of POWER OF ATTORNEYI. KNOW ALL MEN BY THESE PRESENTS: That INSURANCE COMP#'.NV OF THE WEST, a Corporution duly outharizud end ox*16ting under the laws of the State of Cvli?ornia and having its principal. office in the City of Son Diego, California, does hereby nominato, C unitituts and nppoint: Michael A. quJpley its tiva and :awful ALtornay(a)-In-Fact, with full power oiid authority hereby conferred its name, place and stead, to execute Beal, ocknvwladqe and del.ver any and all bons undertakings, recognizancon or other written abligatiorc in the nature thereof. This ?ewer Gf Attorn is granted and it s!,gned and sealed by ruceimilo under and by I cothority or the ir:ylawing Resolution adopted b the 0 0 ard of Directors or TNSURA? COMPANY OF THE WEST ut a meeting duly called and hard an the Sixth day of Fubrvory, 19, whtth said Resolution has not Kean ew-..ondod or rescinded and of which the foll,')wing it trva, full, and compluto copy: "RESOLVED: That the Prasido;it cr secretary may from time to time appoint Attarn.7)ya- Fact to ruprament and act for and on behalf of the Company, %id viViar the President SecratorV. the Board of Directors or Executi%* Committee may at any time reminvw su Att,ornoyuin-F,3ct and revoke the Power of Atte-sisy given him or iler; ind be it further nESOLVEDi That the Attorney -in -Fact may be given full power to execute for and in t name of and an bohulf of the Company any and all fonds and undertakings oL the business tho Company may r:quiroj,,and pany tgtjch bonds or undertakings executedbyany such Attarno in -Fact shall be n bind upon u ComponV as if signed by the Pro idert and sealed a attested by the secretary.?. IN WITNESS WHEREOF, INSURANCE COMPANY OF THE WEST hoc caused its official Beal to be her unto affixed and thos3 presents to be cignad by its duly au'uharl2ad offLcorr. th 3rd day a,' August, 1968 INSURANCE COMPA14Y OF THE WrST resident STATE OF CALIFORNIA PA"KITV nl� CAW nTOAn On this 3rd d Aup.4sc, 19B8 hofnre the subscriber, a Notary Public of the Stn of California, alnoufnd Tor, the Count of Son Diego, duly commissioned and qualified, ca BERNARD M. FELDMAN, President of INSURANCE COMPANY OF THE WEST, to me personally known be the individual and officer, described in and who executed the preceding Instrument, a he artknowledged the execution of the same, and being by me duly sworn, dopoteth and sait that he is the said officer of that Corporation aforesaid, and hot the seal offi�fod to It preceding instrument is the Corporate Seal Io'e the said Corporution, and that the so Corporate Soal and his signatue.. an such officer war" duly affixed and subscribed to t said instrumetnt by the authority and direction of the said Corporation. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my Official Seal, at the CA of Srin I n- rst above written. NORMA PORTER NOV AM PUBLIC - CAL $to"& M4 VIEGO mlily WISOMMra-M tip jdfubm I Ma STATE OF CALIFOnNIA COUNTY OF SAN DIEGO 1, the Yondersiarvid, JAMES W. AUSTIN, 111, Secretary of INSURANCE COMPANY OF THE WEST, 11 hereby certify that the nriginal POWER OF ATTORNEY, of which the 'foregoing Is a full, tr and correct copy, is i.j full force and effect, and has not been revoked. IN WITNESS WHEREOF, I have hereunto subscribed my name as SocretorV and affixed t. Corporate Seal of the Corporation, this 27th day of February 1691 PP24d 4 ICW CAL 37(REV. 5/87) toot - C, 'A'i j z in- or ch rr he of nd to me to and h, he id he ty Al ,r ' t ,.••1 1 J. , do uo A'p he I I 19 c r Ef WIUSA i 4 �r, insurance Companies 1111) (lit 1'1t(II'( SAL BOND KNOW AI.I.1N1'.N 11i' TIIESL PRESENTS: l,hat We. VALLEY CREST LANDSCAPE, INC, Any correspondence in relatinn to this bind should be directed to +. Wausau Insurance Companies Bond Departmanl 2000 W�sbvood Drive r' Box 8017 Wausau, Wisconsin 544(,2.6011 DATE: 3-5-131 (hrr:inafler called the principal), as principal, and EMPI OYFRS INSURANCE Of WAUSAII A MUTUAL COMPI�NY a enr nation or anized and doing business under and h y ►'irtuc of the I,rs+'s of the State of end t my licensed P H Is 1 WISCGNSIN' ` a for 'lie purpose of staking, guit►antecing or becoming sale surety upon hands of nnrlettakinps required or authorimd by the I;tics + al• the State of CAL I FORNIA A'), as Surety, areltcli and firmly hound unto CITY OFHUNTINGTON BEACH (hcrrinullcr called the Ohligcc) Ir r, 1, Ir in he just and full sum of TEN PERCENT OF TOTAL. AMOUNT BID. Dollt.rs ($ 10% ) lawful money of the United States of America. for the payment of which, w'c;l and wily to he ' + made, we hereby bind ourselves ind our heirs, eon. hors, administrators and each of our successors and assigns, jointly and +� severally. firmly by these presents. I THE CONUITIONOhTHIS011LIGATIONISSUt_'N•T►lAT,WHEItEAS,thcr.bovebnundcnprincipalits aforesaid,hahoul to hand in and submit to the obliges a bid or proposal frir the �' ; , ::fir;.• '!' HANDICAP PLAY AREA - CENTRAL PART; r z SPEC. NO. CC-B03 in accordance with the p' ns and specifications filed in thr office of the INiLee ,end under the notice ink-iting proposals Ilie rcfor. ' NOW, T11 ERFFolk 1:,;f the hid or proposal of said principal shall be accepted, and the cont ract for such work he awarded to the {? principal thct.upon cry the said oi,ligee, ants said princip;,I shall enter inton cootrrct ant'. hand for the c'omplction of said work as t , required h� 1asv, ,hen this obligation f!ntinn to he null �.nd void, othrrtsisr, to he and rentals in full I�srce :rr,d cl'fcct. �`� „'F Jr, • '�j Sf •� ' `tom• ` IN WITNESS WIIF:It1:0F. said Principal and said Sittvty have caused these itreseitts io he duly signed and scaled this 27TN r 1 + it d;i% oil FFBRUArZV .19 91 VALLEY REST CAPE NC r � t+ J, ( -� ! Its' '�' e _ 4 '''` ,• r r�'' 't. EMPL0LRS INSURANCE OF AUSAU A MUTUAL COMPANY 1 Si rn P a � r ,..{ DOUGLAS RAPPAuorn rn•t'ar' �f t . rrtxl5-i:2$.I .Lill PRTr). USA y, " , k1 ' r - r.-♦: +! ,r S •71 .' ,.. �. NrJ �C a t'ttl'Is. VSA " ' c :s Nc , � •r } ltl 1 Itr c C� I EMPLOYERS INSURANCE OF *'I&Ski A Mutual Company POWER OF ATTORNEY FOR BID BONDS ONLY) KNOM.' ALL MEN IlYTIMSF PIIF:SPNTS. That the E,NIPI.O1'EIIS INSI'IIANC'E O." WAUSAL; A Mutual f.'otnppnm. a carporutiun alai) nrf(anired and existing under the lawro fir the Strifeof 1Viaconsin. nnal havin;" its principal office in the City of Wnueou, County of Marathon. Slate of Wisconsin. has made, constituted and appoinled. and allies It% these prehrnts make. pone, lute nor: appoint _ __ GIAS A. RAPP list true and lawful oetorney•in•forl with full power find ntirhority hereh)' conferre(I In !is name, place and "tend. to execute, seal, nclinntrledge and deliver ANN' AND AI.I. HID BONDS (IR 11'Iul,mm DOCUNIPNTS IN11(11.11ING 1111) GUAHAN• TF:F:StIll INI'HI:NATIIllEI'll FIMAFTER _-•--_.--------..----_-_: � ant to I� +tad h n+rpurntion thrreh)' not fully and to the flame rxt-nl an if Burn bonds weer flip no -if I+y the l'rrsident, senled with the corporate oral of the cnrliwalion and duly nttr%1e:1 by itm rrrretary hvrel,v ralifvinK and confirming fill thol the Knit, nitnmrr m fart mot• alit in the premtees. ThiA pnwrr of i.ttni nry iK Kra nted ttiurmunnt to the follt,wililt resoluliun aalopted fit• the Ronrd air Ilirrcaors air said 0itnpaity alit mretinR duly palled and held ran tlir Ilith Clay of Nlov. 197:1, which reirntututn to pill', In effect• " ICES14ATI). that the President ar.d any fire President — vlrcti%r or is ipointive -- of F Nil,i.O1'F:ftS WSiIHANCE OF WAVSAII A Mutual C'ninpnny lip. and that each of them herrhv is, autgorized a+ execute Powers af atiornry qualifying the attornr%natned in the given power of nttornev toexecut Tern hehnif of F NIPI.OYF:It` IN:%l'!(AN('F:OF WALISA11 A Mutual C:.nipenvhrinds, undertakings and lilt contrarip of Pura '%%hi1), and ,lint Inv serrvinty fir assi6tant secreinr)• be. and that r%.•It err any of them herrhv is. nuthiihit•I In nnesl the rxrrutinn of arty such power of nnnrnrv. and to attach lhrrrh• Ihr peal ad 1:1fF'I.0)TII3 INSURAN(T OF WAUSAC A Mrlwtl ('nrnpnnc" "FtIHTIIEItIIFS(ll.A'F.I).1hittthemignatuuesofmuchuffivrni EndIha-mealofF:Al1'I.(1YF:It;1NSITAN('EOF WAUSAU A Dlulwtl Companv may !iv afftxrel to anv much power of attnrnev for to am• certifirote rehiring threw.. h}• fnctiimile, and n% 'u% h staMt•r of att++rnry air rertif►catehearing "ach fat-Mmilemignaiumv and facsimile meal n1vill he vnlid land hindinst upon the F:\It•I.0VhItS INHLIIIANC:: OF %VAI.ISAII A Mutuol ('ompnr. %%lien %,t if fro xral .and in he future with reftprvt tit an% bond, undertaking air vointrort of aurelaship to which it irk ntt,tchrd.•' IN WITNEr-; N'IIF:10:OF 0111I.01o'F:IIS INSIIHANCF:0F11'Al'SAl' A Mutual Climponv ho.roused thrsrpresents if, hr ,ipn'.tl ht tht• •%roar %etc prc%idrni and ailcNed by it% m%smitat %ccretar[ end it%corporme %cal in he herein atfiud th,% da) ,� uI - f.Ml'1.O1'f1t5 IVSl1HANCE OF 1VAl'SAII A it Camr..n% /limitation ccR. C Heaeca.a� Scn.ar Vice pretident Attest w Z R. J. liestcmaln Assistant Sowtary 0 "TATF:CF %t';Sc'c)tiSIN i on Cot INTN'OF MAHATIMN i lL O 1In Ihr% --AST .1,a% of ._.— MARCH �- _ _ . 14 $9 . before me rersomllr Came tr H C H%acr.aih to me kr.oun. %tho being h% me dul:, twoln. did dero►e t S tnJ alb,ohci%a•cnuu%avrrr%idrntoil the F%1111 VI'HSrtiSUk.U'('F0f`WAUSAt1rlMutual('nmpany.thtcorrnruurndetcnhedan t end %%ha%h %%%,oleo the ahu%r owtvmcnt. Thal he know. the %Cal nl %aid curporoll:on, that the %roll alfi%ed to .a d inorumeni is such rat female Intl .and Ihit .! ua...r ,rl.i%cd h% %,rurr it the Hoard tit I)nectnr% at %atd cnrrnrrtran .md that he %rp,trd hit namr Iheretn S.,like order ' %! 1\ t1 I I \I N III ItI 111 1 h.a%e h;rcunm %%t m ",and and illr%rd nit %dtt%ral %cat the da% and )car herein fir%t abo%r %%riven It \ KI Nails, Puhhc atriva r eman Z N6'V \H1' I'11H1.IC' '`Jro S •j'�`�'r � ;' A N VI \1F (IF WISCONSIN M1' COMMISSION EXPIRES Jlltil: ?. T tiTATF 11F'11'Itil'(1NSIN i CERTIFICATE CITY OF NAPSAl' (•OUKTs' nF'MAHATHON I , J 1, the undrrr.ignr•d. a%Kurtant set•rt•tary of EN1:'I.(IYEHS 1NSUHA,\('F: Or 11 AUSAU A Mutual Compnny• n WI"nlnrin �i r corlmrrnt:on,.lnhert'byrertifvthattheforegoingandaltar•nudoiwerofatlurnrv,Will 'HMl►STCONTAINAVAIJDAT- IN(i tiTATF:NF:NT PR1NTM 1N THF: MARGIN THF'HF:OF IN HEI) INFO, rrmainr. in full fare-1 and has not been i rr%oi rd, .End furthrrmorr that the rrxnlution of the Hoard of Ilirw tnr..r t birth in the p.,wrr o 2u�eN Signedand st•) iK mall in fnrrr :. scaled in the City of Wausau. Mnrathnn ('',unit. Statr rf Wiscons`.t.:his / _ day r, ar of _FEBRUARY t991 [ %,t••" a W J. licstcman Assisiant Secroar)' ,• SEAL ' � it ! •+x : t r;)'r ? ►air ;i t, , ', �.. `%jjl •T \ fo r 1 NOTE IF Y(W HA': Y ANY (IIIENTIONS !(EGAHI)INI; THE Ok C 11'tsltl)INl'. F' HIS POWF:lt (IFr%.�`i iINWIS tIoNSIN CAI.l.lr1a11)4 (1i1tli r1 � t r • K15•'%222•I n147 r , .hit ...--.-...� ..�..�.. %. T. f r ' (u,� •.�rj- _ - ,,, � `,� � 'fir r .f. t� , l.f>fj,l,� t+`',' %Y \` `[ j •• [ + rr C. rr� ;r,f r �. •_ r� ) r ,c �tv, ,. � � r! • } t ii) 1 ,ri r7 j ,/. V ' e F t ttr 1 f� It % t [7+t i fi '`fit 4f' . 1 9 OF ft'1{ .0}�T w 1� , , - f ' `Y.`li S4'. ` .,i M�ii:!'. / °, ' !: _.,. . r•, a. itt..rl. .. r, r i . I1 ?!'' . -1' .. ... ,�: �.�:'.., lr. YifN d Authorized to Publish Advertleomitnte of all kinds Including I public notlnee by Demo of the $upo►lor Court of Oraltgo Ccunty, Califomla, Number A•6214, September L9, 1941, and A•21A31 June 11, 1963 ' r STI-TE OF CALIFORNIA 4 County of Orlenge r t / I a,n a Citizen of the United States and a resident of the County aforesaid; I am over the ago of eighteen years, and not a party to or Interested In the below entitled matter. I am a principal clerk of the ORANGE COAST DAILY plleuc f�D1ic� 'z� PILOT, a newspaper of general circulation, r,"n> Nonce printed and published In the City of Costa Mesa, Nc,�, ,W`� p„ „►�, t ►el4d Vas wAl bit ►1 I11 �1 a ' County of Orange, State of Catifomia, and that by t" Cn of IUmlksGior1 c,. ho attached Notice is a true and complete copy as L r*wC10% a C,,, 09a� ` Merr • Blnal, Hurllny,cq was printed and published In the Costa Mesa, [loath, Ca,+altix Unit the t, , Writ d 2.00 F rr•. or Much 1 Newport Beach, Huntington Beach, Fountain S 1"l. M wfilen thN tt*v + blWy Vallev, Irvine, the South Coast communities and andn.dtioudinIrA i) 'r c CR tTtirnb A tot ON HXIA*- Lag.,na teach issues of said newspaper to wit Ct7f'ftAM►.CaWdPluIt.' << the issus(s) of: c+rY a tka,ui,glaRt 1 4`r. ldotxrnsnto Aiayfj obtitn*j , . un room" 14e1 e! Ins 5? , hebruary 8, 15, 22, 1991 works moo Man Strom; kunlin{11CA DMeh, :.till• ., •; , { , - ,t ,IorMt� U(/Jt1 rtMt of non•I.tundlbfIts oawf s Woo. t, HitA ' tM PtgiOMl. ,k►n tlyd h \1 { '',� K• •ti, dw & i a proNdol In the CWdrod &C~ W4 bb r I or a Md bw 76f trot It" i "iMftof 111411 grid" of 4t' cr C" •r Bond LsWAot tradpl�ot Meet di .i } '►.�s_i�.� �� t c4norrio and 0*W tsel at _ nw Sots of C I, i veellar onsl wI +: t O:a!1 ptK rnsy a rW1ArE + r .t two&,1h1 ibroiM. stwrtcl ; •�; purs�a+r po vftiYprsosed• � � , ,� '.� ,•�/� . � MrsurrJn pr+ trDarY , -� and 111100101% 110" not Uuln r :r, � declare, wider penalty of perjury, that the .Yp.r..d.d by therl .: {, r ' foregoing is true and correct. r�►, al Me to Sa i crawl e. ony a, nr i1ot:1[otlplo+rsxer�A Executed on _..... Uruary 'z 1 "•"ram., I ` at Costa Mesa, California.„' "O'"' 1 aoR„►dSAM rrrth tile ) ) t) Exh WdOer rn,nt km r Wortew all *Mo pro• 7pIM4Md tN rrgd'rtrd 6ewr j i " 'f Signature rXV61in.r�lyr�Abrij d w cv.rt eiao, VrJW -d vie CRY + �oum9 0l tlw Cffy of h�ton 8roct CwttanMs uw , ' 1 y 4 [Apt, vI F�frtriry. 1fI0 t - 'i' ? PROF OF PUBLIWA':1�iV .1 IwresRcrlrl-r.>rwl. f `4 F�bNM'W lm" CW" r E1r- r I` �14 wr,�, e. ill, ' 1 of f ' i1 ,` Ill' ',� t I �� 1 � `�' - • ' ''�' �,� ��r�}� / • "�' T. t!5 , l f t, r1r,.. l-sill i , ,�:. �'it •— /, _ { ' +. �- � _ `�` ,I � ^, ' � :,Cr1.1�� �� 1, ''I� ,.^,�Yr� i ;� � �f. i �. ' {f 1 i i I 16 ��� �n � '� '�'. � �� 'jIP. � ' 1. II ail : _ '1l+3�7 i,it"� I q3; l3]3ti i , _� r. � f ��,� . <��;, , r ,,I,�,,,1'h, , J i� , `� U s -; `. `�- i 'C ;�: ':: C�'I �'. r. _ l�l ''• +t'*,i; .���:i %�'it:�r��, j�r.�;�) ?. `}���1 ,��'',�' i,^ � ! :��-�, ,.�.: t' [7— NOTICE INVITiNG BIDS CC-�� Notice Is hereby given that sealed bids will be receives; by the City of Huntington Beach at the office of the City Clerk at City Hall, 2000 Main Street, Huntington Beach, California, until the hour of 2:00 p.m. on _1_&JA,� �� , at which time they will be �opened publicly and read aloud i the Council Chambers for ' the ;Any—ir, the City ofI ' Huntington Beach. ` A set of plans, I specificatlnns, and other contract documents may be c,btained , on -T . 19421 at the Department of Public Works, 2000 4atn Street, 1 Huntington Reach, Callfornia, upon receipt of a non-refundable fee of $ "� Each bid shall be made on the Proposal Form and in the manner provided in the contract documents, and shall be accompanied by a certified or cashier's check or a bid Land for riot leas than 10% of the amount of the bid, made oayable to the City of Huntington Beach. ' The Contractor Fhall, in the performance of the work and improvements, conform to the Labor Code of the State of California ai.:' other laws of the State of Californla applicable �7 thereto, with the -exception only of such variations that may he required under the special , ; o statutes pursuant to which proceedings hereunder are taken and which have not been superseded by the provisions of the Labor Ccde. Preference to labor shall be given only In the manner provided by law. r.' No bid shall be considered unless it is made on a form furnished by the City of Huntington Peach and Is made in accordance with the provisions of the proposal requirements. Each binder must be licensed and also prequalified as required by law. The City Council of the City of Huntington Beach reserves the right to reject any or all bids, 1! By order of the tCity Council of thr City of Huntington Beach, California the . of 5im 191gr,,; (7 1, City Clerk of the City of Huntington Beach �t14 i •t i 2000 Main Street (714) 536•-5431 ft'r 0328G rA Al y .jive tr.•' �i I J � _ - ,. .. Ii I' + .r�=. 1 �:, . r Jl� � �Ei i','r_' ' J fr f. i •i- r' r t ! ! r 1! •J ' L ,trl' .�i11 l l i 17 { ••r , j. , i1'; 'I r• . 1 •, •� �i (...� it •`,. ar + I l • rah tillefaEI�1 SSSta7u'I: w modP i ti ,, . ... 1 tt•, tHyr�lr•f.•.,�w�.. ��..—,.—.�.... —. �.a. ,. -.. __.. .: ... .� ... _.._ ,.._ ...,......... ....�-.—_..... - .. , .. .- ..r.a )O'ti :'nt.. .1 J, CITY OF HLaNT'INGTON F3E,piCH 2000 MAIN STREET P.O. BOX 190 CALIFORNIA 92648 1 Louis F. Sandoval Public Woks Dopurtmont j r n1roctor ADDENDUM NUMBER TWO 1714) 536-5431 , HANDiCAP PLA1' AREA, CENTRAL PARK J CC-803 FEBRUARY 2-t, 1991 i Notice to all bidders: The second .Addendum is hereby Issued to clarify the following items and or discrepencles: RE: Bolt ciie - Detail 171, sheet 7 of 11 of plans: 111/2" Bolts with 2 1/2" x 5/8" washers Typ." should read "5/8" bolts with 2 1/2" x 5/8" washers Typ." refer to note 4, Min. bolt size shall be 5/81'. :, `;� 1, RE: Phone number incorrect - Detail "E", Sheet 7 of '.1 of plans states Perma-bar Ise, , available from Peck's Products at phone Number 714-642-6131. The phone , number is Incorrect and the correct number cannot be located. "Approved i J Equal" will be accepted. RE: Bid Item No. 15 - Quantity unit is incorrect. Should be 900 s.f. not 900 ea. on _r 1 the Bid Proposal Form".It r (h. 1 yr• ,, 11 RE' Bid Item No. 25 - Quantity unit is incorrect. Should be 30,975 s.f. not 30,975TO _ . t�•: ' t,'. ea. on 'he "Bid Proposal Form". RE: Lake DrainingThe lake cannot be drained b contractor, nor will City drain lake for construction of pier. ' ll s<,�:j it � �,1✓�'., +�1e�� RE: Lake Bottom - The lake bottom. is a natural surface and is not lined with clay or f. any other material. v! ! . RE: Play area sand - Refer to Section 16.03 of the Specifications for detailr of the y sand. Type of sand to be Class I Beach Sand available from E1 Toro Materials at i (7 1 4) 837-6677. r) 1 tTt;`Ar. , RE: TddrAl threats Bid swings" should be deleted to detaii "�1" on Sheet $ of 11 of plans, ' 1�•' t �,�.4}�� w�, S (ryL1 g " s t d and "Arch Exerglide" be substituted. "Arch Exerglide can be obtained from Hanson & As ociates at (714) 258-1616. Color to match iron forge play equipment. (see attachment) ' yl .jl. V. 1. ,1 �l'���� �)l t,t• ,irtk � , '� .,. ! f 1\ r. l','. i}'tt1., ��ns,,. ` j, �� { r AZ . 1• f j. 1rra - ,tf1 I � I. t w.. At!'.'iil.f!.dY1.1aC_F:'•.!J`�t�.":.IMLtt:ra;Yt'!M►.":c:3':fii2F,a•:l.'A'.:.•_.s.1Cr:[Swsxt'3(.•r.!aetl['tr.zc`::V:t..s.....1QtSii.#�•iit�:r.3.1�.v.,4a#M'.1 t Page 2 Addendum Number Two Dated February 29, 1991 Very truly yours, df G Robert E. Elchblatt, F.E. City Engineer This is to acknowledge receipt and review of Addendum Number Two, dated February 28, 1991. It is understood that the revision of new documents shall be included In the bid documents. Company Date t't I ' t4•�'1t{tr ��, ,aY '� .� By rt cc: Jack Miller � t, Don Noble 'i` .ti; Leslee Temple, CDFI CC••803 "Gen. COFTesp" 2,S5p �.�.i fol 14 It ' ,it• ' •11 f r Ir';1 .�o ir! (fir-• !, �'%=t �:yl �•,,t 'Yr" +jr�. 1, ii , ,fi. 1 ��. v ♦, i�•� a � �. a1 _ f•r S r � t r F., t••1f� r. if y^r ' ! �I! 1 °,� ,'j!, :f '.' F � r �.�\`�f�l�; �ft 11•,`�"i•` t �'r'�{t rr'i:�yw4�r/l ��.r�,I,,��IJ�y`,tt. I`�. y�r y ,• �, iy, ' ,, r ! rf V,r d.�iti � , itj �.• +j�"tile l�Y(�1 �y�5 C {� 3. j Z 3�r el i'I�t� i j'CII;r'7f1`l, ri'I .tlit 1, � •�'raT30�R'fn IFN�?A^iMi�i:.,�,�1ain.-.LY f�'!:.,.. ...:,L S. .» :i ..,.i'.r 'f•rY•�.« I�r�,y...., •.:j_`,rS'. �1;►1r„C. •.�'i,�r Uy..T..�..y y.,.. /,., =.�,r� '�,,i y. �I �.1 �; i�,sl "t .S .t,((!j! }:.'r t,,t, - 'M .� Yi' �f'•Y �i�. F llr 'j,� �;. °R/✓•S�1`r{1r r. �t . 1 !• _ • ,,r i. A it r:j 1 C l.i�� V i ra , Ir r , I1.' 1 ' . ,1 F':•r 1, ,�, �rLt 4t»!(t SJ dal ,4r '•�y! �' � 4 .. i { ' '' St' ` t}. •y ice. � i • ., •.• tr ji l-: `c .. �7j�"`:, ,:.J 'r; _ .. �': .. - �' 7(ry t a'``r =• 7� • `'f�Ji.� .•I' 'r %,' /n�}a `y.,'ii.{t`'•� i � ,..;. R r •�1 1 1: I, raj r.n,�/t5nj t'S�''t �r?(. fJ r S �'; u' , �' r� >. r.r 1� 1 s,•Vt! ,� i;- F,�, r�r ����1 .[r} • �'. t' -•; Tf� It. ~•�' }'r ,F r r�. +. ''rI •L'.. 'i, t �'�f i�i».t>.'1���✓'r; ',.1L cjt((jjt,4.``. ,k, '� /j � .f,'� ! i ,Y'%t[ 'R:r,li,i ,: .. i � 1' 'tl..'• 'i l ,iy 'i;`7t� I.�.,bf}•. ,f '... �� �, •,i,. 1,'., 4i r „ rl 1• •��. �'��i,,.1'! S� i}il� .�r� it. ,, f. � , 1 f r�iy � R� r t'i'i� y'��,rlr�': 4// i 1+✓t''�' r�l •1t. '".' 1. .� ! " •+; SI`, 3' y ' y. :i'� F � r�y,�1 y�ly Y •`,` tf, Y 7 ,_ •f' ., ' I t'r ~�S r i` �, 7. .', I "R ,Z i',r� �� i ; � t;1,h'rf�t i'� , � r . •j .. 1 !. J � r V! tL�:;ft. , � r' t I , t f` I r, I `,'.j.N�,tal3�tj4,r'Jr.M::....1tf.;•yv�IMlr.fw •. v. vl.',. •� .�. h:a,.Y.r. d.r _. .?y/I_ttitt '.: , 11- t r ` •I ! t I r )r r 1 ��f t: Y � t•}'�'r 1 i r PI Jliy t t' �3 }••' t r A 1 • 1• •fr Hi -:a.. •.. ,, ., .••;:;f:ft::�t•^.A-{Iit+S:i9i�:L"a^.iC.•�'a:[.t�AJ'ti«t.. 1 ,Iilk , It I I i kit r 1•C,' t. i r � � •1 Ira r ��.�,. Jf •111 1 .. �i:l 1 r•ISt{I /' 1I/AI'1Y.1�•.�y([,`.�Iy ,. � 1 (,��•'' f'r is ` +t •' �[ c,�l art t j '')? 1� •ttl� +'.-,�.� A',s1..fi,i •,r:•.,�i-..—.jr,.o.r; �. �, �.^.. 1,' 'a t )1�.1f.• s Il' 1 , , r 1 tii+N..; rjPt ,, ,crrr.• �'l'. `p' ,.,r ,1tl:r is/f r., 1, '3! �... f+'s .•.. - .'�--*J;rtc:-�rrla,l.+al' r� . ,,. I�,:i, y yr +1 ,� , A 71 <., C\` tt lUJii•}1-:�:�i.'r 'T�' i,v� ih•r✓ • r /� s`' 1 +s4 ✓ �)'Jr{7i it I��jr�3 .N� , t ls' � •1� , t.r` f ', 1 ' : � i ,' + tj t � , ,#, : 21C1+t(�'Ail]i if� •'1 ., 1� 1. .+ 1 r ', 1! , , t), ,:, �4 �11 .7 vt '1.n I rt/• � � . '`: , f •+ i �, ,�I Jr� , r� +fit r� sit , i i `+ � � 1 .' I '• �\ ,.A1�'/ ' rf �'.'1 • 4�'�i�►j ', liv �,��, r 1 r 11 '� i 'I, 'i` i'�t f � � z I lI ��L , hi��t/ ..3, r�1fY aI[. { i I ♦I •�3 � �• {^$(}}.++/ , 1 � tit ' : _ '' ' / • •" lr, r ;�J 11.1ii.', •C. ';'C\ .7 i,. I ,l - •t. .(1 1�, r �.., } } r /, +, t 1' .• '• )fit :; •. .t, , ..:1 t; 1 (�. j ITEM NO. A"NOXW"T[ OUANTITY ITEM WITH UNIT PRICE WRITTEN IN MMO�IOl UNIT rn;& TOTAL 6. 1.315 LF 6" SDR 35 DRAINLINE 7. 3 EA 12" x 12" CATCH BASIN B, 1 EA 2411 x 24" CATCH BASIN 9. LUMP SUM DRAINAGE PIPE CONCRETE BULKHEAD ' 10. 2 EA PLAY AREA SUMPS 11. 2 EA CLEANOUTS 12. 300 LF CHAIN ANC EYE BOLTS 13. 60 EA 10" DIAMETER WOOD POLES -14. 2 EA WOOD POLES AND SIGNAGE 15+ 900 SF .WOOD.FISHING DOCK, COLUMNS RAILS, BEAMS RETAINING WALL, AND CONCRETE CURBS + j 1. 4 ITEM A"AOX&MATE ITEM MTN UNIT PRICE W. Oti"TITY WRI`rrEN IN WOfIDS 16. 6,560 SF ASPHADPIC CONCP=- PAVING AND IWMER W.� 17. 355 Lr W)CIZVrE PLAY AREA CIXIB 18. 1 EA rGNC= WfErr iATR PLKS S RAW kf� ty UNIT rRGE TOTAL Bolm f 7 19. 166 CY PLAY AREA SAND A 20. 3 EA 1-nW BDUIPS fib, K zl 21. 2 EA DO JBLE TRASH CRI HOL Wrni F=. MS AND CANI 22. 2 EA I SAR-B QUES 4 PA o4k 23. 3 FA NIEMalAIR ACCESSIBLE PIMIC TABLES 4,f is 24. LUMP CL24 tl10DIF1C1r71CN M FMb=)G nUUGNT1Ctq SYSTEM j 25. 30,975 SF NEW IMGATICN SYSTEM -41 It, -,I 4a, jjj 1q. A Jilt. AV- L I I 1 1 Fab. 27 191 1'7: 2A 0000 CARDOZA D 11_F -0 TEL ^ 1-1- 5-1-^.ids P . i 1 SECTION 16' r ' WON -VEGETATIVE SITE. ; iA'IR1tIAIS p 1 16.01 GFlOAL Contractor shah 1 provide all l;rhor, nr'erinls Midequihmant for furnishing and 4 abxeniinf; or applying materials no detailed on the drnuirgs mvi specified in this ., Section, i Contractor shall le responsible for establi.slihig aubgrcde and providbig rlralnage j in accordance.,! with Section 10, earthwutie, aM purlunning wod abatce✓,t c aratiorta 1 s prior to plocen,enu of rorrvegetativ,) imterials. Quantitlea or non-vebetativu nmoriala will be so nenoured in place and corapan- ' f hated for at the (bntraet price stipulated per cubit yard, , a, 16.02 i m) d13ATr.WM AND SOIL 1RFAMM' Contractor shall. appply, in areas to be inatalled with non-vevptati �e rnnterialu as a , described in thto §colon a nal ective pre -Lae ent, ourfoce-applied 1•,erbicide ` Surflan, or, rvinufackurEd 6/ Planes; or approved equal at the rate of five • one-'thirid (5 1 /3) pounds per acne. r pplicattott method a6l 1 b a as reco,mmerided try ;A3 , `- nlanufacturer. 1 r visible weeds shall be ©praayyed with anon-aelective. post-am.-rgent he,-ide Rour.3u as manufactured by hfonrranto Cgmp{a�ir, or approved egaal, er_ the rate 01 five ��) quarru ^er acre. Appl i cation method shall be as recommended by nmufacturer. Contractor shall apply agray c .!Micals %&en air currents are ati.11; preventing i drifting onto adjoinpo ing property and preventing any toxic merre to persons S 1' `.» whether cr not they are in, or naar, th:: proj at,:t. { Maraical treatments shall be applied to eie satisfactiom of the Fngineer before i I cement of ruxrvcgett':ive materials as described in thin Section. 0`0016.01 SJWO ' Sand for lay equilsmt areas shall consistof natural or n=wEactured grenular material free of clay, deleterious amounts of orgaltic material,, broken glass cestg or other substances not' imitable for the rpurpooeu intended. Sand al -All be tl nrotr- I ghly and ur+iforn17 a�h�., Planter sand is unacci-ptable. I' ,fit 17 E. I Gontrrecor ohall be responsible Lor loadir>f;, hau.ling and placiirg san{i to a miriimcm „ ' 1 depth of twleve (M) Inchea as detailed cn the drawings. 1 yr i j i Prior to sand placement mud to the Eigineeen satisfaction, the play equipuenC '�" "4 . �f � J) ' a�r�lea bleshall be free of aril debris, concrete overaptlls, opuro and loose c=reto ,` ,.�QQQ��vvv3111 . i 41 11� , � 1.{•r,l' i r, � ' •ft' t �i, z •.1 i' ` r I� ' - '� `• ; ll r.11 � 1 1 a S' 1 ,, 1( �f r , _ .1.. � nttrir,ra�yp �J•t`twet� v�1� � i, ,' Cc Nr t r? 'A��Yp'/ r `•�' a� �'��°1" Ijyf + f ' R`I _ J '• - ` ,•ti '� J ti''' tj i ' Y It Y a lli lrt i 1 i . r r .�•w�ir ` r I+'SIY ''.1'1. <YI 1 .n ,� 1 •I 'l'. �,'t tl �I S/ , •. �. '11• �' 1 c :�/t�111/�1�4 r'yl t�'� ( j ll I {, , .. „J,1 . ... 1, '• t • �tI � r !y. i il, 'a3a1 , 1'.' 11 �1 1 /�.ji ���! S� y�, +, {,J f �,1'1i1 r i� Mr�i ' S � � � y � , �/: 1 i'• `,7. 'r,4cl;�� f, •' t � i ` r t Ir , rf1Y .- 1J `1 1i tt ., - V,RT fs s' ,r 7+ } �r.0 r•.1 '�• fM� ; 1. Of r. ' i.,./.�ClllMtltMiSfsf�'a(.Yrrlr..-:.A�lkT1 "•7 •:al•?.P.'1Jn ;r... .�, :::::+'r; ; ,=.Lt:'fi .. _ .. _ , _ ,, .. . , i.. ..., .. .. .. _ �(I .. Feb. 27 '91 17:'et-1 021100 CARDO A DitALLO TC-L ?.�-754-'7�•1� r. i' ! _.; AI .. , L-u y.L t„cu <<,:�+, 11.)bU) TES TEL NO: '71a ,,1• r, NOSCAPE p�2!=7J +yt hAYFOLAnal 6AM NOTE t ISTUVOM 8IFN 1 OVir A FAUN 3W 'l-K rvACA r ... :. Yya�`&I Cine:ole FLWioe ,•-•, r,a ''. AV— Atch I 1'� i Teo Gam Cenler • °� iy+�l i Redul'I A Middle Arch '� I ., 0' ►i :. TYPIC&I 4r tr i Swinp}: 1 Gernp j 1 ,•. 1, rt, -`ter 1 ;;. ,. I• r, S 1, 1' ir, � iw•' �� t t. A. ' } , Exirglido f +I•l, 1 ' tr 'n f �ETAILITEE CLAMP PASITIr..tl / i i'I t l� M' ,'1/ I Lf' 1� 2 �T •'fit 1 Teo Gln:t►p/Sstm rt I t •' u �)' �� i`I t�'� •i t of i f •� i' ' hivnp i,,:, �. P�prlve•tt I n P t , 't !s , ,, , �.• ;; FloeGlant 5urt�oe' � • � :� �;';+ _ �',, ' j} v i ZV�r r ►1l `{•a'' "! 1j �; %I,I • '�/, r r,• AiCil t., , 1`� yl-c/.+ ' t"' ' �iJ �-c �• r - 9e6Yy lea! • pp • r •14 f�r�tr 4pncrstti Footlnga WE: Use �► For VOO % 1� FlatX•pk'1 Cap tf ✓� , it ii Scrows A Ta.! WL ,•, 1 i �'1 � '''�••� .. r J r All B08I0 pIa 848-2272 Arch EmIIriQ r % 1,.' _ �� ` { 1(� =`I•�'/ tI -'{�,j { , {� •.-...�....•..�—�__ ... __ .. .._ _ .., ±_!_.�....._.•_._.�..�—_� «^••w••u!^.C� (;,"<'� i'i +� ^.:7'` � t.. f� � � arr yf,��� C�: 1 t:� I r � .s J ,r i , �. �1�'i� �*,_..tlry� !�I',a��� c .t I) fit•, , If,�:�J•k t w t'` I' .,.•, fir i, `) ... 1' � tl., r ��'. Irr ir1f ',^{�'r\ �'�liiil �rr+, }_;. ,�'�S �,.ti t .• �• r /." Jf 't , ' •1 , Ir ,_ �'i lrl ✓} r r,.,l ` r gar 1 fi'1, 7,r� I M, f,�, �tr I �o , � •1 �(• t , � �• � 1 r, ." . t . , • t rt/ ,r j`.'. 1��� '1,.� n " I�jr ►�rt �;Z; ,r •! r , I r _ t a Y �LL)r(�•r�� �{ �; �,y �t� a,' , • I• \ ���•. � � ', • • , ' ' I' •l .Z, �1 .l �(��..;4 `I I�LI'•` l�r, �„ivr Jr �I�1 �'�• `t f<�?},'L�F ,i r � � ' r •1 I' 'r , 1' 1 �1 !, 1 , M�h���f{it"'?��f����1'y�r��, I?� 1+} � 4�4��`, jai" �i.a l I ' (r ,' 11 • I rr , r � , +t. l\' t�+, ��w.a�� .ra,1tf � ,,1i1i ; Zry � ' � a 1 •L. .. • � t SJ,%�, � iri I,". r 'I �� 1� } 1 lr.'� �r ��, 1 , '� .. _ .' ' 'II. y•i� 4 }i 1 w' A { i • , , � 1"I `+ .�, � G {� (. ;�... i mot. :,. 1�11 . ii�l,!;'::; t... ,. +! ,'..c:,�4 �� ....3 ...,� 1��:.a�s�, ",loo MAirr, r,i w-,, P. HOX, l�jr CAI I 1 11NIA :12ir,1i3 t_nui:; >»cl{wal Puhho Worlc:, D ?partmunt f itvc:to1 (714) �I11�► ;"•;;'{1��,1 �ll�,`.11,1 11 tr;Jl� 11-\NDICAP i`! AY ARVA, l'AN)" 1-1-AIRUA Y :?(), 1101 Nl{t ico to All 1'Ic,ts:� "uplace ',add Alternate') of tl,(! bid l)CopOS.-II p,tcl:ct t;Jth OW reVl .cd bid Note, Additive Arturnme Bid Item Numh-r lour is hoieby added. This item includes the subrtitutiott of a polyethylene material for the woad deck on they fishing pier. The ,uF,gestcd ntateria'. is "superciccf:". S1111Prdre1. is manufactured t�; the Wakefic-ld cmilptny (sue copy of Wak.6icld lrc.hure). Very truly your:,, 1:obert E. Eichblatt, P.E. City Engineer RE1 :1t11:11) This is to acknowledge receipt L nd ,•eview of Addendum Numher One, dated rebruaty 26, 1991. it is unrierstood that t!, = revision of new docurnents shall be incaudeci hl the bid documcmts. Company By cc: Jack Miller Don Noble CC 802 `G-n. CCorresp." ITFM FIA. APMOXIMATt ou"Mry IT[kf WITII UNIT A111Cr YMITTCN IN M�QFIOS UNIT rmi; L'- TOTn!. AIX) i'.L'I7 TPL'VlT 1. :'.. 19U Si' :,i-�I'I RESILIEjil TILES AND—iPHALTIC MI CREIT•. RMP, MAY JLnPI1MUS I 1 3. 6 r:I: i5 cAual '=1S 4. LUMP SUM, R>LYETHYLTNL DECK 1 1 I 1 i 1 I I E I _ 1 Ar' 1 ' � �•1 1 tl�.. r i1'. t ., 9,; `.�V , 7, THE WAKEFIELD COMPANY IQ 1434 E. Borchard Ave. g� �7 f zv SINTA ANA, CA 92705 1-14) 542-4255 An rTL 1 t.. O's )4 T .4 AOW I 1 BID PROPOSAL FROhi Firms N1m• To the Honorable fAiyor and City Council, City oflirintington Beach, Catiiorr,ia: In compliance with the notice inviting sealed proposals for the I hi :,a " otopose and agree to antn:r into r. contract to perform the work herein described and to fernifh the materials therm ra according to the plans, sl ecific.3tlons and special provisions for tin said work and to the satisfaction of and trntier the supervision of the nirectlir of Public Works of said City of Huntington Beach, Californis. The .ndersignid has not accepted any bid from any subcontractor or materhiman through any bid depository, the by-laws, rues or regulations of which pruldbit or prevent the contractor from considering any bid from any subeontrctor or mAterfalman which Is not processed through said bid depositary, or which prevent any subcontractor or materialmon from bidding to my contractor who does not sue the facilities of er accept bias from or through sn:sh bid depository. Far the furn(shing of ell lahar, materials and equipment, and or all incidental work necessary to deliver all Une impravemeia. , :ompl?te is placiI in strict conformity lath the plans, specifications and spi,.ial provisions, on file in the a,fice of the Oirectpr of Publi.: 'Ncrks, City of Nuntl�ytan Bea,.h, California, I propose and agree to take full payment therefore at the following unit price, ►o wit: FEM APPROXIMATE ITEM YJ1111 UNIT PRICE UNIT 7. 'UAKTITY WRIr1EI'1 "J WORDS 71ALr' �r'n!CE ._ • LUMP SUM I MOBILIZATION LUMP SUM I CLEARING, GRUBBING, ANi LUMP SUM EARTHWORri 4. 1,200 CY EXPORTED) SOIL I IITEM NO. 4M110XWiATV (XIA"TY ITEM WIT" UNIT FWCO WhITT1ININMR04 UNIT I•lill,la TOTAL 6. 135 LF 6" SDR 35 DRAINLINE 7. 3 EA ) 2" x 12" CATCIi BASIN 8. 1 EA 24" x 24" CATCH 3ASIN 9. LUMP SUM DRAINAGE PIPE CONCRETE BULK11EAD i0. 2 Eli PLAY AREA SUMPS I.A. 2 EA CLEANOUTS 12. 300 LF CHAIN AND EYE BOLTS , 13. 60 EA 10" DIAMETER WOOD POLES -14. 2 EA WOOD POLES AND SIGNAGE 15. 900 EA FISHING DOCK, COLUMNS RAILS, BEANS RETAINING WALL, AND CONCRETE CURBS ITEM No. A"ROXIMM QUAMITY ITEM Ki1TF1 UNIT rmcc MIn IN IN W01105 UNIT ►NIrr&• T L TOTAL _ a 16. 6,560 S. ASPH)ITIC MUM I'11:rlM AND lfr-ADM BOARD • i 1"; . 355 I.,F � CCOCM Ti INLAY ALMA CURB l 16. 1 EA C W-RME, «iMMUR A(CGSS Rl1'•IP { .� 1 � 19. 166 r;Y PLAY ATT-A SAND 1 20. 3 EA ?JOD J3F.IsQIES ; 21. 2 M DOUBLE M',%M ( CAN HOLDERS MITI FOO►M& S AND CAMS 22. 2 EA EW-B QUE—I' 23. 3 EA PIHE=31 M ACCESSIBLE PICNIC 'IMLZS 24. UZT SLM MODIP'ICATMU TC EYJroTRr3 1RPJGxNilICI4 SYSM, 25. 30, 975 FA NEST IRRICATICxd SY..-.i M i irEm mpnoximAir ITEM WITH UNIT PPICE UMT Wi. QUANTITY MITTEN 110 WORDS R I r, r, TOTAL 21G. - W."Llp SUM I llZM= M- CaRrROLLM, FA'Xlr6UlT, AND I 100rTJP m i� I ITEM 1K1. &PPROXW.ATL QUANTITY ITEM WITH UNIT PRICE YMITTEM IN WORDO UNIT lRIt;G TOTAL � AM AM NA'IE I 1. i 190 SF iiMILLW TILES XM ASPIU\LTIC C'OOMMULT WOr I 2. ull/p SUb! PLAY APPAPA'IUS 3. G -11 15 GAIZEN 'IT,F F.S i I - 1 ' � r It it understood and agreed tfiat the approximate quantities shown in the foregoing pinpotal schedule are soleli for the purpose of laciliutinq the comparison of bids anJ that the contractor's compensation will be coutputed upon the basis of tht actual quantities in the compielO worth, whether the j be mere Of k1i than those shown herein at the unit prices bid irs the proposal tehedule. The undnsigned understands the contract time limit elfotttd for the contract is —120 zammair days. It ewsided the contract, the undersigned hereby agrees to sign said contract and furnish the necatsary bonds within tin (10) days of the swa!d of said contract, and to begin work within ton (10) days from the data of approval of the con. tract by the City of Huntinglun Beach, California, The undersigned hat eximined carefully the site of the Mork contemplated, the plans and specifications, and the proposal and contract forms therefor. The submission of t bid shill be :on-Jusive evidence that the bidder his Investigated and it atirfled at to the conditions to be encountered, as to the character, quality, and scope of work to be performed, the quantities of rtaeterals to b► furnisheu. end at to the requirements of the prolsostt, plant, specifications, and the contract. Accornpanying this proposal Is (S ..... ), PIOTICE: Intrr the words "Ush," "Ctrtl► id Check," or "Diddur's Bond," at the ass rosy be, irr an amount equal to at Wit 10 rireent of the total bid price, payable to the City of Huntington Beach. fie undersigned deposits the abode named security as it propesat guirsnr{ oral egress that k shall be forfeited to the City of Kntingtnn fleach as liquidited damages in caw this proposal is aecopij!d by the City and the undersigned stroll fail to execute cortttactfor doiup said work and to furnish good and sufficient honJs in the form sat forth in the specifiations and cssrtractdeuumants of the City, with :urety satirfactory to the City within 10 dtys after the bidder has received writt:n notice of the svrard of the contract; atherariss aid security shall hL returned in the underigncd, Licenud in accordance with ass act plov;ding for thr, registration 0 contract License No. Signature or Oldd►► Businets Address i Uce of Residence Dated this `&y of ,19 Bidder Chill signify receipt of all Addends here, if any: Addendum No, slate Received ^B'dder's Ci ng ature w C PROPOSED INFORMATION REQUIRED OF BIDDER Bidder is required to supply the following information: Additional sheets may be attached If necessary. 1. Firin Name: 2. Add: ess:. _ 3. 'Telephone: 4. Type of firm -individual, partnership, or corporation: S. Corporation organised und,:r the laws or the State of: 6. Contractor's L!cArrse Number: Expiration Date: Z (NOTE: REPRESENTATIONS MADE T}IEREIN ARE MADE UNDER PENALTY OF PERJURY) 7. List the names and addresses of all members of the firm or names and titles of all officers of the corporation: 8. Number of years experience as a contractor In construction work: _ 4. List at least six projects completed as of recent date: , CONTRACT CLASS OF DATE NAME, ADDRESS & PHONE AMOI;NT 1 WORK I COMPt ETED NUMBER OF OWNER 10. List the name of the person who inspected the site of the proF.)sed work for your i firm: Date of Inspection: _ 11. If requested by the City, the bidder shall fury!:h a notarized financial statement, financial data, or other Information and references sufficiently comprehensive to ne.re:.,r 2— , appraisal of his current financial condition. P-4 i 'i i . 1 Ali I •! J_ .1, :i- ff, DESIGNATION OF Sidi owmACTORS In compliance with the "Subletting and Subcontracting Fair P►retices Act" being Sections 4100.4113 of the Government Code of the State of California, and any amendments tLereeo, each bidder shall set fnrth bcI iw the name and location of the place of business of each subcontractor who will per form wrrk cr labor or render service to the prime cap - tractor in or aboutthe constructionof the work or improvement in an amount in excess o1 one-half ('/,) of one percent (1%) of the prime contractor't total bid, and shell fusthet set forth the portion of the work which will be done by each subcon- trectur. Only one subcontractor for each portion shall be listed. If the cantrectot fails to specify a subcontractor for any portion of the work to be performed under the contract, he shall he deemed to have agreed to perform such portion himsalf, and he shall not be permitted to subcontract that nurtion of the work except under the conditions h=reinzfter set forth. Subletting of subcontracting of any portion of the work to which no subcontractor was designated in the original bid shall only be permitted in cotes of public emergency or necessity, and then only after a finding reduced !o writing is a public record of tht legislative Budy of the owner. PORTION STATE LICENSE I OF WORK SUUCONTRRC'OR'S NAME ANt` ADDRESS NUMBER CLASS I t. By submission of this propoul, the contractor certifies; I 1. That he is able to and wi!I perform the balance of all work which is covered in the above subcontractor listing. 21 That the City will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this proieet• 1. f I , • J i,• � � 1 ��� fit, �'J"I 4i iri l 0 1 NONCOLI„ SION AFFInAVIT TO BE EXECUTED 13Y BIDDER AND SUBMITTED WITH BID being first duly sworn, deposes and flays: 1. That he or she Is of the party making the foregoing bid; 2. That the bid is not made in the interest, of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; 3, That the bid is genuine and not collusive or sham; 4. That the bidder has not directly induced or solicited eny other bidder to put in a false or sham bid, and has not directly or indirectly colluded; conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone refrain from bidding; 5. That the bidder, has not in any manner, directly or Indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or fix any overhead, profit, or cost element of the bid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposes contract; 6. That all statements contained in the bid are true; 7. That the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham hid. I declare under penalty of perjury, under the laws of the state of California, that the foregoing is true and correct. ATTACH APPROPRIATE CERTIFICATION OF NOTARY PUBLIC HERE. 1 it I i I i I I (This dunranty Ohnil brs axoru.nd by thr. , icre;aful hidde.r In accordnnc^ :with irintructinni in tho sherhil provkioni. The hid►'rr may r'xecuty the 11►mrant y on this page at the time of ruhrnitting his bid.) rMARANTY To thr, ''Ity of Huntington 13(mc:h, Deportment of Pw)Iic Vlorl;s; PRO.7FCT: i hr. ,ndersigned guarantee:; t:ie rrn!;►.ruction and installation of t'ic following work 'r, this project: Should any of the materials or equipment prove defective or should the work as whole prove defective, due to faulty wor'x:-nnn::'iip, material furnished or mo:t.hods of in3tall3tion, or s!iould the work or any part thereof fail to opr.rate properly as origin�ll•! Intended and In n:cordance -I the plans and specifications, due to poor of th;` a!�ov:' cnuses, all ,vithin 12 mar . after dat►. on %,Nc-h th13 contract is accepted by Vil! '-'ity, th^ undersigned agrees to ., .mhruse the City, urion demand, for its exprnsss incurred In restoring s,ald wor'c to the condition conl:cmplated 'n said protect, Including the =ost of any such equipment or materials replaced and the cost of removing and cepincing any other %vr:rk necessary to make such replacement or repairs, or, upon demand by ;tie City, to replace on/ such material and to repair said work completely without rust to the State co that so!-' work will function successfully as origlnally contemplated. The City shall have tho ffiiquallfied option to make any needed replacements or repairs itself or to have such replacements or repairs done by the unde—Igned. In the event the City elects to have cold wor}c performed ty the undersigned the under. rgred i agrees that the repairs shall be made and such materials as are necessary shall b4 ` R furnished and installed within a reasonable time after the receipt of demand from the City. If the undersigned shall fail or refuse to comply with his obligations under this ' guaranty, the City shall be entitled to all costs and expenses, Inc:luding attorney's fees, reasonably Incurred by reason of the said fallure or refusal. i i i i Date , . r , 1015G/5538 Contractor j 7r, ►�' r :� ifs i r�^ 1 1 t li4M)ICT PLAY AR:A C12- Imm, t'UK in ajv; for Me CM OF IMERMIM mml fE"ARINFM Ol' PIAI.IC 61MYS 2000 Kaln Street Huntington Dosch, California 926348 SEI-MICATION NO. W-M DATE: FEMRW, 1991 GSRDCYII-DiIAIL(34WiR.'=ON, 1AblIriOME AFDIIIMURE end PIMaM PARMM911P 3151 Airany Aveuse, Suite J-3, Oosta lbsa, CalLfornln 92626 (71i•) 7544-7311 �t _,._t. 0 0 IM c;i :J T.',II1: of CU rMn ro)tice IrArirr.; x!al(d P1&; .,;_ 1 ln.'3tr1k:Li011-; to Piddcr, K- 3 Bid Pn)ru--,A Form P- l Prop:.ul Ininruithu 1Uquin:d of V,1d(!,'ri P-- () N.41gruciun of :'ruxvntr,, rr:; r- 7 Non-GAILl."ion Affidavit i'- :l Qurimty P_ " Sample Contract C- I Ciry of lincirigtcn U.-tch C-axian! sP!c1,1Cnt1on;; 1 Pxtachrx'nt A - A6ricultural Suitability Soil Tost Rep)rL Attachriait D - Suter (Lulity Control 1'e1iniL Stnrctural Calculatlon`i - Vali N;soctawi Sp-cial Proviso-vi s,-cticxr i Definttirni of TemS 1 Section 2 C.xatrol of th,_ lbr'r Section 3 C u%es in the lbrk 8 Section 4 Control of Materials 10 Section 5 Prosecutiun, Pragress aw Accelxance of the lbrk 0 5-:tion 6 PLslvnsibil itie , of du ContC1CLor i Section 7 tLasrtrcm= wid Payment 23 Section 8 W11.Uzalon 24 Section 9 CLeartng and Gruubing 25 Section 10 F3rthwork 26 Section 11 Draingge 91stuans 29 Section 12 tsouLtic Concrete 31 Section 13 Concrete 33 Soxtion 14 FuLgh Carpernty 37 Fection 15 Miscelluncoo, tL%tal 39 Section 16 tbr-Wetative Site Materials 1-1 Section 17 Pax'k Furniture arts Play Apjvrarus 42 Section 18 Irrigation 43 S•2ctlon 20 Flaimig 50 Section 21 n1ant Establishnnt 1Lrio.1 55 Sc-ctic,n 22 Post-Installattcn Mointer ince '.4,riui 57 Section 23 Electrical 60 . F - i In Ij(t ro 0 0 I+t yril : II►'VITIIV, ;;I i m 13I16 M-W3 Iycltir- I tleretry F;Lv-n that tl!_ City (bLmcii of tlx Cityof 1lultingtoll 13each, Galifurtlia 11 receive scaled bids for the im-v-ezents at Central Viak for the li.indivaj) Play Area In the City of Huntington i3eac�i, c:r+i�l�rn�fi�In acc�irdance uTt - p ami anT sjv..ifieatlu s and s{xcial provisions in file in the offic-: of tha Dirtctrr of hllI c 14..7:ks. Documents will be availabl•� on Feorunry 5, 11M. A chart;•: of $30.00, not reftcdable, will t,e required for vach !;et of gvci.fictiom,; and 1lcrosT4xL,Ivin;r DIREMt OF PUBLIC Wb'.S FS " 41TE Wbrk I um Qh ntity 1. lloblllwti�x•, bimp S= 2. Clearing, Gruhhin,3, id Dmi3litio;1 lirp yin 3. G3rtlmrk Ump Ikzl .4 Dcrorti-ci Soil 1,200 CY 5. 4" SDit 35 Drainlilir_ 100 IF 6. 6" Silt 3` Dralnlinc 135 IF 7. 12";c12" Catch iiasin 3 EA B. .4"x24" Catch Basin 1 Ei 9. Drain:;;-, PLIc rencrete r}.111:1-mr.►i Lump Sim 10. pl V Ivea S1.'v ; 2 FA 11. Clc:llouts 2 Gi 12. QTain b F�o RAts 300 IF I% 1;I' D�.r,.:tr:t„�SN-Al POIC-; (30 EA 14. latx .co i lblcs d 2 FA 15, li,uci Fishing 11)Cic, Coltssans, hails, Manx, Petainit,; Wall, 4 Crantnete Wet.,, 900 SF 16. Asiilkaltic Gxlcrao PaAR-1, mA 1Laler Ward 6,560 SF 17. Clonc mtc My ,leer, t111 b 355 U, 18. Ccxicmte -gig lrh-iir CCLC;.'; FMIP 1 FA 19. Play Area -ind 160 CY 20. WxA Pen_I>.:!s 3 EA 21. Double. Tvv-,h Cin II,Ic':r; with Foot..iiv;s and Cim; 2 EA 2. Z }A 23. My.%elchair rccus.;ibl.o Picnic Table-; 3 Fly '4. IL,illi.ention to Dxtstir.;; Irr1:;atfLx1 :i:s,r:m Lufnp Sua 25. 1'-iw I: rigation 9, c;tm 300975 SF 26. 11i2lec}tc(i Gxltrol!cr, Fnclo�;Ure, aryl liximp .4rp Sm 27. �;)i l i're� 1r;1t is ;t%t?. , i r°:1 .�t, :a_nt 30,975 SF 2t}. ',-.I 'iAlrf 30,i)AO SF 29. �i�lc1'.1 `Iarf 895 SF 30. 14" U�:: Ttut , 6 EA 31. 30 tl.y Mart E;;r.►latistr.:.:',c NriM Lunp Slsa 321. Gi) i:c11aMnr l:�)' R).rt IRrit•111ilti(al Ml1ntuT1:1;)Ce Btri(XI Um S11] 33. Tun,x1ra.:y I'%r-irk; with Q,e v°t of I�1�bl� Cate, 1,200 IF 1. Pes' l i _n . 'hies ,, ki A;,'.41.1lt.iC CD-lcrete also 19C1 SF 2. FI j !,t•,:,.c.:cu:, lu-.p Sua 3. 15 Calif ii 1:, •:, 6 EA In accordance Frith the prT;vis1Aon3 of Section 1773 of the L-bur Code, the State of C31icornia, Dire,tor of th! D,p1rt,?jit: of Industrial Fulatirnu sh311 determine the gee -,ral p.-evailikt rate of apt-1 iczbl : Lo thc! w3rk to 1sz copies of the latest gcneral w-1gr, rate detertiiinatter_, aru on file ot. Ov-, office of th3 City Cletk and Or office of t11` Dit-ectc;r cf fiIbL!_C 1,hr1:s caf the G`itV Of flrn:irC-tal Burch, Gilifornin. 41H Q I w n `I I I is Plano anh specificaticm, together with proFusal fora, may be obtained at tiv: office of ffe Director of Ibblic Gbrks, City hall, Itnntlrgton [Each, ('<111fornia. do hb bid will be received unless it iu mde on a hlcmik former furnisl" it/ the Director of Public tbtka. the special attention of Prospective bidders Is galled to the propnsal requirements, set forth in the specificatinro, for full directicns ae to tl,e billing. 'the above quantities are approximzte only, being given a.r, a husf i for the comparison of bids, and the City of Nurrtivitar Beach sloes not expnene or by implications agree ' `tiat the actual crment of work will eoruasrord therevith but reserves the right to ir....ease or A decrease the krount of arty class or portion of the cork, its mry be deertA necessary or exlr.-client by the Director of Public Vbrko. All bids will be eanpar•ed on the basis of ttr_ Director of hiblic tents �istim►te of Ove nsantities of work to be dorw., the substitutiar of securities for any money withhold bl the City, to ensure perforuvmc e, shall be lrrmitted in accordance with tlar_ provisions of thr. C:,liforrria Coverrrr3rt Gode. Section 4590. Each bid shall be made out (n a form to obtained at the office of the Director of Public tiotks, Departmmt Wing, 2000 t-'ain Street, limtington Beach, Wifornis; shall be sealed sad filed With the City Cleki. at the Civic Center, Second Floor Adainistration Rtildtrg, 2000 Main Street, 1kintington Beach, California, or, or before 2:00 pm of 'hleoaday, Marcia 5, 1991, and shall be opened by a comittee canlnsed of the City Clerk, than City At,-:,rtrey and Director of Public Fbrks or their authoritcA representative and the resulto of said bidding to l l be reported to the Ci y Council of said City of Illntirgtora Bewc l at their regular meting to be held on hixdal, the Mardi 18, 1991, at the tour of 7:70 pa in the City Council (lramers in the Chvic Center of said City of liurtingtarr. Beach, and shall be acted upon by said City Cbunril at the regular meeting of Much 18, 1191. The City of licrtirtgton Beach, California reserves the right to reject anv or all bids and to accept the bid deemed for the test interest of the City of Huntington Beach, California. By order of the City Cbuncil of the t1ity of liantington Doadi, C.rlifonlia this 4th del of February, 1991. 4 ATI%SY: Alicia Wentworth CiE'.1 T—" — h M Q 14-2 ,i• i GO 10 1. PPOPCSAL REQUIREMENTS 10) I6 INSTRUCTIONS TO DIDVERS Proposal rolulrew.ents shall be as described In Section 10 of tho City of lluntington Beach Standard Specifications herein. 2. SUBXI TTALS Olds shall be submitted In sealed envelopes bonring on the outside the name of the bidder, the bidder's address and the nano of the work for which the bid Is bainq submitted. It Is the solo responsibility of the bidder to see that the bid Is rocolved In proper tlmo. My bid received after the scheduled time for opening of bids will be returnod to the bidder• u,iopenud. 1. LOWEST RESPONSIBLE SIDDER The City, In dotorminlrg the lonost responsible bidder piny, among other things, take Inter consideration the quality, fitness, capacity and adaptability of the respcctivo equipmunt, matorlals, articles,dovIces, ajparntusus or procnss proposad to be used by * any bidder hereunder. E C b) A. SUICONTRACTORiS n10 A person, firm, or corporat!nn who has submlttoid a bid as subcontractor To a prime contractor Is not dlsqualIfled from suLnitting a subco.itracting bid to other bidders. 810 I!EIRIFS ALL Irvfuteles for clerlflcatf, cif contructfon doeursenta during bidding shall be directed only to Ion Poble, City of Ifuntington Deoch Peblic irks Depasrtmst, (714) 336-5441, vM will be tbs solo rasponslbfo Ittdlvldlnl for such Intorpratalf[co. 6. CONTRACT TIME Contract time fcr the inprovemecits at Central Park for the ►4sndicap Play Area as shown on tho drawings and specified hnreln sha 1 I be 120 consocut ivo calendar days. W 1 h 1 I F 14 rl,iirr"7 f_1 r� N-3 1: l . I r i6 BID PROPOSAL FROM Flims Nim• To the Honorable IV13yor and City Council, City of Huntington Beach, California: In compliance with the notice inviting settled proposals for the IA 0 1 hereby propose and agree to enter Into a contract to perform the work herein desuibed and to furnish the materials therefore according to the plans, specifications end special provisions for the said work and to the satisfaction of and under the supervision of the Director of Public Work: of said City of Hunt=npton Beach, California. The undersignedhas not accepted any bid from eny subcontractur or nuteri:iman through any bid depository, the by-laws, rules or regulations of which prohibit or prevent the contaactor from considering any bid from any subcontractor or materiolman which is not processed through said bid depository, or which prevent any subcontractor or materialman from bidding to my contractor who does not sue the facilities of or accept bids from or through such bid depository. Far the furnishing of ell labor, materials r.4 equipment, and or all incidental work necessary to deliver all the irnprovemenu eomplsr.e is plbca in strict conformity with the plans, specifications and special provisions, on file in the o,fice of the nirectrr of Publl; Werks, City of Huntington beach, California, I propose and agree to take full payment thorefore st the fyllowing unit prir•4, to wit; ITCA1 APPROXIMATE ITEMM111 UNIT PRICE UNIT •91AL "7. CUAi4TITY VIRITI EP! IN 1VOnDS PnICE 1. LUMP Sint I 140BILIZATION 2. I LUMP GUM %LE: "'NG, GRUBBING, AND DEMOLITION 3. LUMP SUM I EARTHWORK 4. 1 1,200 C1' I EXPORTED SOIL f ..� xir •�� 1 ' f Y 1 �ri1 �1 - fin; ' • f,. 1' 1 l r S. 100 LF 4" SDR 35 DRAINLINE r';= 1 i 7 I .r M 1 7i r •� `•. 0 i 0 o h, I i� r ;r ' j 1 �f .r IT914 NO. A"ROX&MATA 1 ITEM WITH UNIT MCH OUANTM WRIT'11114 IN VOORDQ UNIT tRt�t: TOT�1. 6. 13F LF 6" SDR 35 ORAINLINE 7. 3 EA 1211 x 12" CATCH BASIN 3. 1 EA I ' 2411 x 24" CATCH BASIN 9. 10. LUMP SUM 2 EA DRAINAGE PIPE CONCRETE BULKHEAD PLAY AREA SUMPS 11. 4 EA CLEANOUTS 12. 300 LF CHAIN AND EYE BOLTS 13. 60 EA 10" OIANECER WOOD POLES I -14. 2 EA WOOD POLES AND SIGNAGE 15• 900 EA WOOD.FISHING DOCK,, COLUMNS RAILS, BEAMS RETAINING WALL, AND CONCRETE CURBS 1 r . r a r�r t a.4J. rt: E * : r 1' .rr• ' i ' • • • � ... - .... , . .:,.... � .. � �a r.h•w'Ii it . . �M1i �4. t �,�� �'! . +' m2o 4 gy I � ly.. n.•....rw � •"�,��f T �i 1 f iU � $ l} ��f ri ' 1J . •'. ' �r 3 rY, 1, {'� �� r; ..' �l 1 ;r girl !if'•= ��,+ tiwh f �:. ,'1 .�l ', .' It J, ' a ;•. , f I. s J IR J ITIM NO. APPROXIMATE QUANTITY ;TEAT VVITN UNIT PRIC4 WRITTIN IIj WON= UNIT AR1�6 TOTAL I 16. 6,560 SF ASPHALTIC CY..tJCRETE PAVIN3 AND IIF110E3i BOAM) 17. 355 Lr CC)t\r—R= PU'-.Y AREA CUITI 18. 1 EA COt1CRCI'E S1tiC 1AIR ACCESS RAI'SI' 19. 166 CY PLAY ATTA SAIM 21. 3 EA 2 FA IAXD BEMMS D(XMTI-: TM911 C'AN HOLDERS VIM[ I'OQQ7NG5 AND ONE 22. 2 EA W.R—H CfJFS t i 23. 3 EA WFiI=UM ACCESSIBLE PICNIC 'TABLES 24. iu•IP SUM TO EXISTII3 IR?. rGATICN SYSTEM 25. 30,975 EA DIE3ti IMGATICN SYSTEM I'l ■ t , Ca 6 t' V i ITEM No. MtROXIUATE ITEM WITt , UNIT PNIC9 CAJAJ31"T11 WRITTEN INIM111Di UNIT PRICE TOTAL 26. UZT, SUM RMLrj►Ti:1) CUI\PIMI,LM, MCLCGURE, AND HOOKUP 27. 30,975 SF SOIL PREM0ATION AND ME GRADING -- FI1V1' 26. 30,080 SF SEm- m uyw- 29. 895 SF SODDM) TUW- 30. 6 EA 24" BOX TRE£S 31. IJJMP SUM 30 C1iIMMU DAY PLANT' ESMSLISIu L24T PERIOD 32. IMP SUS f 66 C'AIMMAR DAY POST 0STALI TICti 1`IAIIsI�E PI:IUM 33. 1, 2 0 0 1V MPORAiiY Ti7 X:ING WITI I = SE7 i' OF M ?'3LF: GATES TOTAL R KUNr OF PARK HID (Shall correspond with amount stated in (Dnntra t) i� k t ' 1 I ' i ( IAi IA ITEM !t0, ARRQXMATC GUANroTY ITEM AITN UNIT NIICB WAITTlIN IN wo"Do UNIT IRISCr 7pTAl ADD AL'PEFd NI1. 1. 190 ST. RMILIOU TIMS AND ASt`'�iALTIC OO U :M BME 2. lull' Seri PIM APPARATUS 3. 6 EA 15 GALMN MIS t _I r I. 1 � l�If t ?'1 1 rt� ' IRfi� r d1,41 t •ir �4jAY �'!, I, ,. �1 .�' '• ' • ' • ' ,_ .t\ Iltl�,}'�! f.'..�1 r +� ;rely , ! !: � � ('"J�, I �Yi II ,�+�r •r ■ r- LI ' r i I� It n understood and agreed that the approximate quantities shown in the foregning proposal tehedule are solely for the purpose of facilitating the compariwn of bids and that the contractor's compensation will be computed upon the basis of the actual quantities in the completed wnrk, whether they be more or leu than those shown herein at the unit prices bid in the proposal tchrdule. The undersigned understands the contract time limit allotted for the contract is 120 camnuar days. If awarded the contract, the undersigned hereby agrees to sign sued contract and furnith the necessary bonds within ten (10) days of the award of said contract, and to begin woo within ton (101 days from the data of 3ppmvil of the con• tract by the City of Huntington Beach, California, Tha undersigned has examined carefully the site of the work contem7plated, the plans and specifications, and the proposal and coninct forms therefor. The submission of a bid shall be concluciva sfvidence that the bidder has investipated and it satisfied as to the conditions to be encuuntered, as to th charector, quality, and scope of work to be perfnrmed, the quarnities of rtaterials to be furnished, and asto the requirements of the proposal, plans, spwiliationt,and the contract. Accompanying this proposal Is NOTICE: lasert the words Cath, Certified Check, or Bidders Bond, as the case may be, in an amount equal to at least 10 percent cl the total bid price, payable to the City of Ifunticr;'on B?ach. The undersigned deposits the above named tac.rity as a proposal guaranty and agrees that it shall be forfeited to the City of Huntington Bleach as liquidated damages in case this proposal it accepted by the City and the undersigned shell 5il to executes contract for doingsald work and to furnish good and sufficient bonds in the form sat forth is the specifications ■ !d conntact documents of the City, with surety satisfactory t ) the City PAthln 10 days after the bidder hat received writt: n notice of the award of the contract; aherwia said security shall be returnad to the under:igned. Licens:d in accordancq with an act providing for the registration of contract Licence No. 0 Hushmss Addren Mom of Residence 4 Dated this day of ,19 0 V �! SrpnNureof Olddn Bidder shall signify receipt of all Addenda hero, If any: Addendum No. Date Received Bidder's Signature i I I• PROPOSED INFORMATION REQUIRED OF BIDDER Bidder is required to supply the following information: Additional Sheets may be attached if ' necessary. 1. Firm Name: I 10 to 10 I W 7. Address: 3. Telephone: 4. Type of firm -individual, partnership, or corporation: S. Corporation organized under the laws of the State of: G, Contractor's License Number: Expiration Date: (NOTE: REPRESENTATIONS MADE THEREIN ARE MADE UNDER PENALTY OF 7' PERJURY) t 7. List the names and addresses of all members of the firm or namec and titles of all •f�;,' ' ,,:� ,;r'A� �r officers of the corporation: :I C I i1, S. Number of years experience as a contractor in con. truction work: f 9. List at least six projects completed as of recent date: CONTRACT AMOUNT CLASS OF WORK DE.Tc COMPLETED NAME, ADDRESS & PHONE NUMBER OF OWNER 10. List the name of the person who inspected the site of the proposed work for your firm: Date of Inspection: 1P r, 11. If requested by the City, the bidder shall furnish a notarized financial statement, financial data, or other information and references sufficiently comprehensive to permit an appraisal of his current financial condition. c . I „f •�.� t c t i1 P- 4 , , r r •rvt.�} , � �� t , i t. , 2 z r r I •1 , � j I 1 e4 . DESIGNATION OF SUBCONTRACTORS In compliance with the "Subletting and Suhcontract hig Fair Practices Act" beinry Sections 4100,4113 of the Government Code of the State of California, and any amendments thereto, each bidder shall set forth below the namernd location of the piece of business of each subcontractor who will perform work or labor or render service to the prime can. tractor inarabout the constructionofI)e work or improvement in an amount in excess of one-half ('h) of one percent (1%) of the prime contractor's total bid, and shell further set forth the portion of the ,York which will be done by each subcnn- tractor, Only one subcontractor for each portion shell he listed. If the contractor fails to specify a subcontractor for any portion of the work to be performed under the cnatract he M M a I� shall ba deemed to have agreed to perform luck portion hirn:olf, and he shall not be permitted to subcontract that pottiast of the work except under the conditions hereinafter set forth. !' Subletting of subcontracting of any portion of the work to which no subcontractor was designated in the original bid ; f•, shall only be permitted in rases of public emergency or necessity, and then only after a finding reduced to writing as u public tecotd of the Legislative Body of the owner. ' PORTION STATE LICENSE { OF WORK SUBCONTRACTOR'S NAME AND ADDRESS NUMBER CLAS:i I' •` r IOU 5 1 r' 1.. try_• sl - % i By submission of this proposal, the contractor certifies: t. That he is able to and will perform the balance of all work which is covered in the above subcontractor listing. 2. That the City will be furnished eop;ss of all sub -contracts entered into and bonds furnished by sub -contractor for this ornieet. i 1 .I r fit- � r I • r, I A NONC OLLtisION AFe !DAVIT TO HE EXECUTED BY A IDDER AND SUBMITTED WITH HID being first duly sworn, deposes and says: 1. That lie or she is �._ of the party making the foregoing bid; �• 2, That the bid is not made in the interest of, or on behalf of, any undisclosed parson, partnership, company, association, organization, or corporation; 3. That the bid is genuine and not collusive or sham; 4. That the bidder has not directly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, cr agreed with any bidder or anyone else to put in a sham bid, r,r that anyone refrain from bidding; 5. That the bidder has no;: in any manner, directly or indirectly, sought by agreement. communication, or conference with anyone to fix the bid price of tht bidder or any other C� bidder, or fix any overhead, profit, or cost element of the hid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; 6. That a;l statements contained in the bid are +:rue; O 7. That the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or v agent thereof to effectuate a collusive or sham bid. I declare under penalty of perjury, under the laws of the State of California, that the foregoing is true and correct. �O ATTACH APPROPRIATE CERTIFICATION OF NOTARY PUBLIC UERE. i N r't 1 � � �'• J': i y % .,, ' 4 ' f , •.;gyp ,;n t+, ,1 y 4 i Pq [•: O •'.Thi; guaranty shnil be executed by the hiddee :11 .1Ccordtlncn with instruction i in tho siir,cial prov'tsiam, Thn lflddcr may r:xer.uta the 11ijarrinty on this 1)ar)c -it the tnrle of r;)rhrnit►.ino hi, hid.) r'IL1ARA1'•!TY To the City of Huntington Bench, De^nrtmrnt of Pu`)lir: Worlcss The `:-iderskyled guarnntr3s, the cr:t,,trur.tion and initallatlon of the following wort( in^!':Jed In this project: Should nny of the materialsi or equiprn4nt prove defective or should the war:( co n whole Provo d,:fective, due to faulty wcrk:nrrns°.ip, material furnished or methods of instailation, or should the -:iorir or any part thereof fall to opr.rata properly as original!-; Intended and in accordance -pith the plans rind specification,, due to nny of th:.' ahrwr-, cnYises, all :khln 12 months after date on this contract is accepter! by Vie '-'ity, the• undersigned .ngrees to reimbrus^ the City, upon demund, for its exprnaa, Incurred In restoring sald work to t;ra condition contemplated in said project, Including the :ant of any ,uch et.jApmerlt or materials replaced and the rost of removing and repincing any other cvor'k necessary to make such replacement or repairs, or, upaln demon:, , by t.ie City, to replace any -trch material and to repair s31d wore cumpletely without cost to the State so that said work will function successfully as oritlinaily contemplated. The City shall h,vo the unqualified option to make any needed replacements or repairs itself or to ha-/e sr.ch replacements or repairs done by the under-ignedr In t'ia event the City elects to have :)31d worsc performed by thr; undersigned, the undersigned agrees that t're repairs shall be made and such materials ,3r are necessary shall be furnished and ln3ta:led wiOln a reasonable time after the rece!pt of demand from the City. If the undersigned shall fall or refuse to comply with his obligations under this guaranty, the City shall be entitled to all costs and expenses, including attorr,ey°s foes. reasonably incurred by reason of the said failure or refusal. , Contractor ► `' Daterf 1 ! l (k W1-1 C ---• rig, �j� , � F''� „�; �ar Yij f4 r J , n r, 2 a E '44 I "A . 01. E_ 11,' T. hr la l� 4:jr l ,,r1 N1 r ly .' ri �1•j't; Irl ' `LI. ,.t't. '11 , i r ,. •�'- ,r• � ' ,,'' J: SAMPLE CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND l�, FOR LANDSCAPE CONSTRUCTION ON THE HANDICAP PLAY AREA IN CENTRAL PARK THIS ACiREEMLNT is made and entered into on this day IN Of , 19901 by and between the CITY OF HUNTINGTON BEACH, a 3 ;: •; , municipal corporation of the State of California, hereinafter C referred to as "CITY," and , N a a _ hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, i hereinaftar referred to as "PROJECT," more fully described as the +�i landscape construction on the handicap play area in Central Park in • l the City of Huntington Beach; and CONTRACTOR has been selected and is to perform said work NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows' I.r• ij �''.h: ,"h > 4;jt 1. STATEMENT OF KQRY;AC • gl!TANCE OF R i QK r it f• f'y �i r� 1 �, f� �►�j• ,�; L,-'t"��,>�j �;f. C:ONTRACTOR shall furnish, at its own expense, all labor, plans, rK( O tools, equipment, supplies, transportation, utilities and all other .yj items, services and facilities necessary to complete and construct j the PROJECT in a good and workmanlike manner. CONTRMCTOR agrees to assume the risk of all loss or damage P rogress or arising out of the nature of the PROJECT, duringits 'R r � ' ���• ;µjtlya prior: to acceptance, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any description ,1.. v i 1i allexpenses p7,+,��.��+,,�:;;: connected with the work, including, but not meted to, X O incurred by or in consequence of the suspension or discontinuance of li'R ,'1• � I,ta1� + ' 41 f ,�' �r rj gib; �r -- — �*---•— - --- — .--...........,.rr.�,.,n.,, p Cr r J� t? llrrll;�b"'lS����'r '`I ,t.'r 1 t.•ejVrl.tyy�i4j�,rl�, ° '„ ';'. .. ,' /;1 , J } ' i ': il>6�rf�r .!( it •r' �', (�� ...1 � , i.•;, � ': {,,• +.',J fill. . , � , 6. r. j t , + ci�,` '•f-'t 4[' l�j•t �U+I SJF r.� ' '''�'' �`1� r 1 r 'tip re %•�. Y`,`+1 f� �It :,! f7 r, r r7 1 , '. - : f JML work, except such an are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY under them for the compensation set forth in the accepted bid proposal. However, the total compensation to be paid is to be computed on 10 the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s.) 20 ACCEPTANCE _QF_COHDjTrQNS OF -WORK.# PLANS AND SPEC I FIQATIONJ . . . . . . . . . . CONTRACTOR acknowledges that it is fully familiar with all the terms,, conditions and obligations of this Agreement and the Contract 4 Documents (as hereinafter defined), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the some were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by said Contract Documents insofar as they relate in part or in any way, directly or V, indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: ;.Z' A. This Agreement; it B. Bonds covering the work herein agreed upon; C. The CITY'S standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the `k City Council of CITY, and any revisions, amendments or addenda t Y P4 "9 -2- �0 j 11 It 4, rtt.0 41 ir I Jr� r i :7 r >n 1� 13 � �� �,� viz �-YID • . thereto; D. The 19BB edition of ,Stand xd fioecifications fer._ PUbl{e Wong Conetuntion, published by Builder's News, Inc., 3055 Overland Avenue, Los Angeles, California 90034, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association, and the Southern California District Associated General Contractors of the California Joint Coopera,:ive Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Diddera and the Contractor's Proposal (attached hereto as Exhibit "All); F. The particular plans, specifications, special provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like affect as if indicated and mentioned in both. In came of discrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as "DPW,") without whose decision said discrepancy shall not be adjusted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in Conflict herewith. `�? v 3. QQMPKNS_ATTQH �t44 t CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject {' to any additions or deductions made under the provisions of this -3- r l 1..1�, '�V4` ri,� '�i ll "j+Mkt , r .� � ; -t,l •, i, , r' .0 , t �.... �..�T .—.rw,.lAnaRR' r rt• r � �r:' �.. r . 1 ,j1 t • � RI r� •i' .t ,i i�',. �: 'S pp ,1 ' '1 ,r. �' 'j�'rIc l.�l)• L1 r���.'; ir,�r' li'i:''� i, , rti tilrc Ft- ZV + st 1 { 7,.j fr;• ii i 46! �„ f�y ��. J� 1' jil 1 �.�. �r�• ,�5 r � _. � S rS��x���{�tv'u�( jW �'���4y1..,, ru S' - ,, ,I 1 .I• �' rJ �'7��'��,Y�.rl•' �w'J'Is�'+� 7r Agreement or the Contract Documents, a cum of i. DOLLARS ($ ), as set forth in the Contract Documents, to be paid as provided for in Sections 1, 6, 13 and 14 herein. CONTRACTOR agrees to commence the PROJECT within ten (10) :y ., •., working days after notice to proceed is issued and shall diligently h 9 Y p ' prosecute PROJECT to completion within Gii.e-Hundred and Twenty (120) • consecutive calendar days from the day the "Notice to Proceed" is issued by Department of Public Works, excluding delays provided for in Section 11 herein. S . DIME OF THE ESSENCE • The parties hereto recognize and agree thet time is of the ,`�,:'� ` •+i�-a essence in the performance of this Agreement and each and every I ,:;+ provision of the Contract Documents. r , w' . VIM r�• CONTRACTOR shall prepare and obtain approval as required by the �� Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of 4 its work in conformance with the progress schedule set forth in the i• � � � yy 1,1 ..i• Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors and CITY forces '•� 1 J1:; hit 0 working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance with Section 4 i' herein. CITY shall have complete control of the p premises on which O the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR ;1 •�. on the premises. q •��,. ' _q- M, �! S.t Its • .'lj ',j lr f ,\!/w Ir `I rr 3 .}r. ' ,r• , rl 'r !tifi'Z .., 4IVy !'��• j.. 1, '! � i rN.\`'F �ifi 7. ,fi h J �T.•I 11 I' - •l r Il r�' I 1{ ,r `J Ill•.- � ,• ci (i .. t .. yYlo.'f 1'Alms ./ /1a�} , '� ��r, , (�t� l` 'r f1- I _ ,, I _ r r�l• fli'r;k�/ , ►�, 1", +,1 , r� ft ) , :,�� 1r .y��C r ! r ' S )��C.rj�l •' i 1� t LY�.�, l�r l .{jll 1 ; / r '• + r' Ir 41, !:41 �;� ' ••"I: ,,{�!/ 1 ' '. •, _ �! x 7 yr , r r. • � { � •t Ilfli� r, i 1ri1 7 +'�•" , ', r'r•T'` , ,'.1 `•, Q•i l! /f`b.�, l` i : {� 4 '}! 't+�,! ,lam ,,,' ,. � � 'j• 1 y, / 1 r f } 4 �I �: � I�(+tx L / � f 1 _•.tires) 0 6. CUMM CONTRACTOR shell adhere strictly to the plans and specifications t met forth in the Contract Documents unless a change therefrom is wit authorized in writing by the DPW. CONTRACTOR agreata to make any and 'Ir• ,'i all changes, furnish materials and perform all work necessary within the scope of the PROJECT as the DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the written order of the DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by the DPW. When directed to change the wo.-k, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the effect of the change. Should this DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated by the parties upon coat and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to „1 CONTRACTOR and the contract price will be adjusted upward or � downward accordingly. ;_2 No work, services, material, or equipment shall be perforated or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work site will be available on the date the Notice to Proceed is issued. In event of a delay in commencement of the work e a h job site for an rea on relief th F" ,�', • 1„„ �,,;�.• du to unavailability of the j , y s , to e CONTRACTOR shall be limited to a time extension equal to the delayx� t,!` ifi � +yR ;y ��rt, O► due to such unavailability. �- CONTRACTOR shall, prior to entering upon the performance of this ZI t�r� ' M ' � _ ..__ _.._. .. _._,.._....__ _ ..�, lid"� A t •q tip} .ir ,Y I�.n''��irj,7F }il �.,1 7 �• ��' C r'.: _�� 'r _ \1 '� i) �� - i' �}i ' '( ' � r��' '� � / %' �1,Y�� IY lI i4� t, , , �)I' '• irk �� 1 !I I�t : MtL� I t r�, � 4.'; i 1 •i f t Y �' ��.T f r� �, 1{3 1,'. 't: .+� '3'Yr ?$ �4.ct�.% u, al'y I` ,• ' t •� •4:. I ! '�° Lrf i�;'.��.+� 1 f. 8�R�}}t �,f� t �, •' - � !, '= r�..f,, t _ !t. ��, r 1 I lli�,'�.tr! �.r. , Ir I,IS jt f 11 1 •L}! * 1 . �, ' `,,;i `��, �'a ( 1 .1 , .' r (I�f� ! 1. ,., .f(Y ri, _ •Ir r � 1` ,1•. �1' � � T .C� I = ( r; 0 Agreement, furnish the following bonds approved by the City Attorney: One in the amount of one hundred percent of the contract 1 • price to guarantee the CONTRACTOR'S faithful performance of the work and to warrant such performance for a period of one (1) year after !. CITY S acceptance thereof, and one in the amount of fifty percent �. ♦ (50%) of the contract price to guarantee payment of all claims for labor And materials furnished. V f , 9. jjARR&HTIE6 ' `�.'ii • The CONTRACTOR unconditionally guarantees all work done under ' this Agreement including, but not limited to, any workmanship, „rf•y, installation, fabrication, material or structural facilities �• �� "x i constructed. CONTRACTOR, within ten (10) days after notice by CITY `' ,•,; r,s Y P appropriate ,c,;, , �,.ifp,;,l�'�.,r�;'•�,a.�;,�of an defect in the work, shall have the option to make ''+ + repairs or replace the defective item or items. Upon expiration of ' • such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S rick and expense. P 1 •. I i 10. rNDEP►NDENT CONTRACTO �;1;J ,,`fir .r • It is understood and agreed that the CONTRACTOR in, and shall ��, � r�• ,.r ' .ter �� be, acting at all times hereunder as an independent contractor and not as an employee of CITY. CONTRACTOR shall secure, at its "+�� • expense, and be responsible for any and all payment of income tax, social security, state disability insurance compensation, 4 ' unemployment compensation and other payroll deductions for r CONTRACTOR and its officers, agents and employees, and all business licenses, if any, in connection with the PROJECT. QUILIATED D MQES/DELAYS "' ''�' • It is agreed by the parties hereto that in case the total work •`�`�' called for hereunder is not in all parts and requiremants finished or completed within the number of calendar days as set fortis in -6- r �''ir I r �' •, , i. • � . its , ,� "h t, �,•�, .,. ' h :' .r �', �J'41 �, .i •'fir f:, -11 k r YM I �ryyyty. r gg filly �l +1 1 . J J'i i•''r4 ` ��� ��Jrr� 'I r� ,� 'r I t nr t I "Ij I. •ir y 1 dui ' Section 41 herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and 1 determine the actual damage which CITY would sustain in the ovent of and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a °�. i�►• "'� penalty, the sum of Fer day for ,fr r • Yrr t ' each and every working day ' s delay in compl,titing the work in excess of the number of working/calendar days set forth in Section 4 herein, which sum represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable losses r CITY would sustain in the event of and by reason of such delay; and j,;,' ''�; • CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies duel or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in completion of the y JJrt� y1'�r• •:. work due to unforeseeable causes beyond the control and without the s� '. ' . s}?`:t • fault or negligence of CONTRACTOR, including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions: strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of final settlement of the Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the time for Completing the work if, in its judgment, the findings or Ili<<' �� �•:aa �'�,�;;')' O fact thereon justify the delay; and the decision of the DPW shall be conclusive on the parties hereto. ! a -7- �1 I Y I 1 I r, ' f F. r ,r• .. _ � � , Fly :1 ' `,' `� ' rw►..+!—� ...•••^.^^ ^^ — — "w r.+' Wit^•. -•♦ {t[ y+' J4 r •�: rA 1 � 1, i :i1, t ��' {, � I % Et,' �+ } �rI � krJ .� r'��? ,l ;{ , � .l. r � ,`� =, ,r�•�y,1 R.r ,�i17.��''vY t'•ir{��. _,y2 � 11,E I 'r,�l r i t , r '., 1 11 y1 •G''Ir 1 ,r ��. i I r^ 1 .,r1 �J, r 1�,u/hr1 'r ! r rr.. ' ��'' ( .. •I' r�,f 'I't ���� l ��' y • I i1(1j`�q�'� ��1 L�,� ��� tl 1 IJ � � �', � lr t 4 7.�,1 .. '•�Ir1 .� 2�y+rl��l: � �1�f (��ii�''"Ii �y.t Ii itljytYl �t1 i�• , i.. r .1' I rt I • I � � I .. 4 I.� r, (��,�Y I r���. �(I , TT } S00 7-7 41 l��iit��ff w. " J" li �+ '' 'f .L - I �.) I +. •.r ;r � f�%{nlCfr�l� �'•' f. r i, Arat,^1 'Pow", ,t ,t� l ,r J •rl, I � c tl'; , 1 ?- ♦a' , Q. y �•r.i. Y � � :. � � /fY J •q'r� Br r F-w I ;l ' •., � � !' _ ',r I I♦ �. dot♦1t R r � Ir � { � I r _ C 14 ,'1�-;_r � .4'� 1�. � .r- L . • ++,-i ail-r•+il ♦ � :*�.�" # � ��y .7T� �-; `, ' «{ n �J Should CONTRACTOR be delayed in the prosecution or completion of 4 the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed waiting for materials required by this 1i Agreement to be furnished by CITY, or by damage caused by fire or ' other casualty at the job site for which CONTRACTOR is not �, it • responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time • herein fixed for the completion of the work shall be extended by the I' number of days the CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is • presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, rM �'�;�� • irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or { ` t?' ( subcontractors, will be allowed and said a»tension of time for completion shall be the sole remedy of CONTRACTOR. 12. 121FZERING SITE CONDITTON;i t• r )' 1 '� S•' I4 (1) Not;r_Q The CONTRACTOR shall promptly, and before such • conditions ara disturbed, notify the DPW in writing of: (a) Subsurface cr latent physical conditions at the job • fFl. site differing materially from those indicated in this Agreement or i�,,.j► • the Contract Documents; or, �. (b) Unknuwn physical conditions at the job site, of an unusual nature, differing materially from those ordinarily t r�{%, • encountered And generally recognized as inherent to wank of the character ►.o be performed under this Agreement. The DPW shall kj ;x promptly investigate the conditions and if it finds that such �i 7 ll/r: ,• +'�3il�,i{r�'jr�,l: P�Q iLril ±�i�%, I 3'f16'•F1•-i�1;T?i�Y:t1.:/".r1C�3i:'fYIY.Yd4:.i:�'Tifls'fl'{ 79W1 -?r 1Z. .7' v �':f:' I•� 17 •„'•Fi,tis�t7�J:7+\:,!F ,, I�. ,54f y� , I^(li,l �,�'i � 1; '1'/.a �I 1. tr ',�'r/ 'll�Ii•l !., f•11 f1t, r�� �y ''r_i • SJry�I1. i ,+., ,rl! r ', 0� G+fr 'r .� />f , ,.1 f•'C 1 .� t. .,�7� � �rr ti > 'L1►�'��, ' ` ;, r ,�. r ,'. - it �� � S . ���1• 11�., ` "; '��Nrl i. i,: ,W �j•• �J.ff �� '� �7 rj , �� �i� �. .. _ .. 't, +, i~ t j ' 1 r •",} '�t7.,'',l '�1r }�rY 4f` •/ l ' l L r{•.•y' + If , S'�r/1'♦i �aa I , r rf . �f 1 � �4./j ��tr 41ri >,17/, - ,I•i . � ., y rl 1 �,Yt +� 4 r + { +, �� ��: �' • � r �i, I� ;, ,,' 1 • r-, t1t �'' � .•;: 71 r I `', ( ,'. � •�,.. �. i l} t, T 1 'rl'1 �: ,l�ijl, � rr,ttn•• i .., i , r � .. •� - - ,i ',,r 11'•I��+•r '', ,r�l. ,> 1. , 1;A , I t7 •7r !r`i-j 1 }; ,+�' , • ;t �iMila/ I�i r. � 1 . 11, .I ,` 1 ��',; r' Irk• nr • t tia'T. r t� ` 'N',• l �yljR�T , , „ �• 'f •,, ti ,I j (q� 14 AFL ! ' t( ,r� 1 ( , •/ , 1 - I ,cur j ;� ! • r rITT .j:, �, r p '_ 'Ili. r1.�/1 r. .., 1 •r.• , .1 1 1•; 'j' ram.- _'•__ - � IL L4 conditions do materially so differ and cause an increann or dereroase in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly; (2) Time xtensJsLn No claim of the CONTRACTOR under this �,. Section shall be allowed unless the CONTRACTOR has given the notice i required hereunder, provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED_ OiIANTITIES The quantities listed in the bid schedule will not govern final A payment. Payment to the CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or f lesa than the quantities listed in the bid schedule, the bid price 1r shall prevail subject to the provisions of this Section. The DPW 11.E -: • may, at its sole discretion, when warranted by the facts and ;la circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in • construction of the PROJECT are in variation to the quantities listed in the bid achedula. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allov:ad if t 0 asserted after final payment under this Agreement. If the quantity variation is such as to cruse an increase in the time necessary for completion, the DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its Judgment the findings warrant. WE n r J j lswN wv►++r.r.. ^. �^...• }","^"S .. ,., _.- ,elf r• ...r 'T-T^'1 , 'fit .,'. ,� s `,!•}' f /My+�_ , , } • •' l I - r -hart - i ` • � �' � ' , - SIX# '� • +� 14�.�J it - r 1 :+ r � � . .�t' .. i w /F�I� 1! t ,i ii i(' �l •i. r c� jr. yu;. ,�j'4/l�r''i�Srl4x���"` ���f , ,r�•. : ' r jYl�}•j, /�S Y., 'i II r,'i �7 , 1 ' _ r•`•� l it ,6r },, 1; 1� �. .{►?}Ii �/ �1 � 1 (t�' ,� �I�`ir /1I r }r',r 1 7• ! •'. r , t I�f �,r�,�n {.S �J�� �+l 7•1.,•� r , r: .• ,'� ,_r �.i 1 F,:'' ��'`,• I'i,/ , _ j S Jr 1: Y f} y' V�,• �i � • 1 t4, ,. t k � ,1 ,r. j H . i �1�� •rf � i ! .r r .1� r"�j i r»•, 'j �: :'I�a-',:. 7 +-t• 'i... •�f IIYS.n�t �, . •d+l. ti �+ � r; n r' ,j, y ifr°'I'�^lddM Ka v ',+ li .y 9J.+r,71 '�'� l��r i'�� � ai•�! 'ti, � .. '�. r•�rY , t !1 �J fl � S�t1 h ' ��. l.t; .. ...,�1l� �',p, w' r 1 i. �•i•',ll 11 i '..,7 ��` , 7!, • �T Y 1 1 771�MIr� •�titk� . 14. PROGRYSS PAYMENTS r Each month tho DPW will make an estimate in writing of the work i� perforMa by CONTRACTOR and ::ie value thereof. From each progress OY y. 1 estimate, ten percent (10%) will be deducted and retained by CITY and the remainder, less the amount of all previous payments mince w; commencement of the work, will be paid to CONTRACTOR. i When CONTRACTOR has, in the judgment of the DPW, faithfully ll 1.r'r , , executed fifty percent (50%) or more of the value of the work as i ,xh•� ;r determined from the bid schedule, and if the DPW finds that satisfactory progress has been and is being made, the CONTRACTOR may be paid such sun as will bring the payments of each month up to one hundred percent (100%) of thn value of the work completed since the commencement of the PROJECT, as determined by DPW, less all previous payments and less all previous retained amounts. The final payment, if unencumbered, or any part thereoL unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner rP;uired by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contr&ct price shall not be considered as an acceptance of any part of the work. At the request and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure -10- r 1 , ,,.iJ 1+4 •IYa 1.�1•'.! �. }•t} f t ,t 1 ;. '�y.•,. •`,, .'.r r.•, f ` I `1 *• C' JY tl+' 1 .. f.. .. \kio , ,. ,, •', .. .. l,t• t � I •�.,.'.r'. �'1 I �.,17i+" � 1 t rryy j11 � � fY[,j� .� .7;i tY r '7 ,1 1 .. 1 +.: t 1c �• Yr �� 1 �}�,•r� M,a �. (i i ' 'f 1 1 .. •. 'r. ) r[" ''1 _ . �:. r ��� 7• r j .. ! i11���i•� J,1.11�i>,< ( ,�'. ,: ct. ".,. + r .�. � .. '. '� 't rr j ,�l SY%i 7 :!i 'i• )r T •��' Y 7r 1 •.' �/��r'r� �r ••t .t .. �,i �.i rr t :+: �f;l$'��r' {��' t� i 7 �Ir �. p,t: ' •IY i 1 1 •7 �� 2. ., - 1 ., ., . rr' t. I �i+• ��yy. 1.f•��.) i., \� f '_� J• Zia 4L 1. ,• ,f 7• - , 1. , ,! .1 .,• 1i �7•�.,. � a, •,•. � } 11 �fN �' r�•� a + 1� r r.` ,f 7•♦� ._ �7 i'�!. ' k �)f; tF • r�Yri 'h ��ls�li:l'7�,, '/t� 1 _ r�S �) 1 ,i 1� tI •,I�i r �1�;3,!' �/7�i•�1,.; �I }If r Mr, "i� ''r f• � ifr;.cl fr ,�� t ,,, ..1 �.; �� _ _ !�• t•/!`Ni7fa,l,:�'•; A }, a w,'±t�' .;... ,�• 1• (/' �} '}1 `},+' ��• lit ; 1 r�Yr id ,n i i r �.� �1 j !} � r <<� �'rf�^a��•� 5. .,, �S I }, a 1 1 ! �I.►a �,, ,IY� {` I'ti° tom.' a performance under Section 13 of this Agreement. 16. AFX1 1. 9 OF SAT SSEAMQU OF CLBL After the completion of the work contemplated by this Agreement,, CONTRACTOR shall file wtt-h the DPW its affidavit stating that all workers and persons employed, all firms supplyingmaterials and all subcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PROJECT for either labor or r material, except certain items, if any, to be set forth in an " A affidavit covering disputed claims, or items in.connection with Notices to Withhold which have been filed under the provisions of the statutes of the State of California. O 17. HUM OF CLAMS (u a• The acceptance by CONTRACTOR of the payment of the final •' r certificate shall constitute a waiver of all clainis against CITY under or arising out of this Agreement. ' 18. NI DEM IF.iCA TON, DEVEHSF. HOI —1jAEM ry, ' CONTRACTOR hereby agrees to protect, defend, indemnify and hol d • © and save harmless CITY, its officers, and employees against any and all liability, claims, judgments, costs and demands, however caused, including those resulting from death or injury to CONTRACTOR'S t® employees and damage to CONTRACTOR'S property, arising directly or indirectly out of the oLligations or operations herein undertaken by CONTRACTOR, including those arising from the passive concurrent � der negligence of CITY, but save and except those which arise out of the y �'c active concurrent negligence, sole negligence, or the sole willful misconduct of CITY. CONTRACTOR will conduces all defense at its sole © cost and ezpense. CITY shall be reimbursed by CONTRACTOR for all costs or attorney'o fees incurred by CITY in enforcing this obligation. r, �t r 1 ` fr ,� ` !1 J/ ,�, , ' .i / 1 •,�_ , � .. I ., '. •"f•��Yy'r �rM'lr 1,� �}� i J1 r r 1 •' l� ' '�, . r, � .1' I f � La i, , ,rl, y r 1 til t s '1 >•) r 4 rr cE. • t d , �•' t• 11 t �{ � � h4 1•�� S; � k.. �. J � ia' 1�11 /i r,�4 rlll `; 1 + } � } � - � � r • , 1 _ - r !Y♦rril i ! f i l� 1 Wi /4 „ to A • , i ON 1 'to) l S - . • 0 Pursuant to California Labgr Coda 51861, CONTRACTOR acknowledges awareness of Section 3700 at seq. of said code, which requires every employer to be insured against liability for workers' compensation; & CGNTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall, maintain such Workers' Compensation Insurance a in att amount of not less than One Hundred Thousand Dollars ($100,000) bodily injury by accident, each occurrence, One Hundre(i Thousand Dollars ($100, 000) bodily injury by disease, each employee, a and Two Hundred Fifty Thousand Dollars ($250,000) bodily injury by disease, policy limit, at all times incident hereto, in forma and underwritten by insurance companies satisfactory to CITY. ! CONTRACTOR shall require all subcontractors to provide such Workers' Compensation Insurance for all of the subcontractors' employeea. CONTRACTOR shall furnish to CITY a certificate of waiver ;J i of subrogation under the terms of the Workers' Compensation Insurance and CONTRACTOR shall similarly require all subcontractors to wave subrogation. Is 20. INSURANCE CONTRACTOR shall carry at all times incident hereto, on all operations to be performed hereunder, general liability insurance, Is including coveiage for bodily injury, property Camage, products/completer; operations, aLd blanket contractual liability. Said insurance shall also include automotive bodily injury and r property damage liability insurance. All insurance shall be underwritten by insurance companies in forms satisfactory to CITY for all operations, s,;Icontract work, contractual obligations, product or completed operations and all owned v hicles and non -owned -12- 1 rT 7VT !� t f • il'�S' }J} "t,t .i r�r 'r.• 1 '. �r 4 ,'f: ' r}.}1lltr r � 11,1ry Vic• �► 11 '��y i�' t4�j. t�t�j �.,, t l i ,1 i I L . I t' .. .. r r l,} ,t it I t ✓ }�.;t, \ "�^p Yl i (►tt1� 1ri [ 1 t r r fl a �r. , r �. (y� , { ,.. 1'� 1f. i� j,{ i' ►;irk t,1 rL�t� i+' �v1 V�f •,�i , ,� ! � r ' 1sr a: . . fur �' ;! � ��� .r (. 1 tCt"r ` 1 '' , (S• . 1 'J ;; 1i:. �,� r 5 1" ({r t�f r ;fit r• - - .1dh `+1 r t, tr,lr ' ..'r� r� t r AL 1L�{� t.. 1 ,+r, �„ ,r } 3�+�FY�ir�rr�.� • �:� •, •. �t • ) c_.��..7,It' IYl 1��1��,r `F."4>�,y�,r r , ,: i i s �•� , . rf F,r�, . Jr r ����� .�. �k1• ` t� /// ,t I ' r• r ,�� +f► !f ,f ' �I"�n 1t11 �. , I!, 0 vehicles. Said insurance shall name+ the CITY, its officers, agents and employees and all public agencies as determined by the CITY as �.� Additional Insureds. CONTRACTOR shall subscribe for and maintain enid insurance policies in full force and effect during the life of this Agreement, in an amount of not less than One Million Dollars ($1,000,000) combined single limit coverage. If coverage is provided under a form which includes a designated general aggregate :imit, such limit shall be no less than One Million Dollars � 'fie =. •,r�•, 41 ($1, 000, 000) . In the event of aggregate coverage, CONTRACTOR shall immediately notify CITY of any known depletion of limits. CONTRACTOR shall require its insurer to waive its subrogation rights against CITY and agreem to provide certificates evidencing the same. 21. CERTIFICATES OF IN6URANCE : AgIQ TIONAL INSURED EIIDQRSE14ENT Prior to commencing performance of the work hereunder, 41 CONTRACTOR shall fur.Ash to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by Sections 19 and 20 herein; said certificates shall provide the name and policy number of each r, carrier and policy, and shall state that the policy is currently in force and shall promise to provide ;nat such policies will nat he cancelled without thirty (30) days prior written notice to CITY. "'•, CONTRACTOR shall maintain the foregoing insurance coverages in force ,�,•�� until the work under this Agreement is full completed and accepted 9 I P P "'., a'ri•�, 0 b y CITY. The requirement for carrying the foregoing insurance shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under Section 18 of this Agreement. CITY or its representative shall at all times have the right to demand the original or n copy of all said policies of insurance. CONTRACTOR -13- i r A ,i+, lrJ i7 Yk + .rJ'• l .�, r � � ' � rr •1 i r.f'' ,. r: '�,. r- ,. �',. I ,r 'r l� +'+r �t`,�+^•i�, {f+' •� 1 i 'tJ[ .t � I � , � t ., I 51• ft� r rr � , !f�' `try f r r' .t •�� ,, � �>�j•a�r� + ��'r rr" i I �) ;')f ~`,.j 1 ` .., t ' 1�•. I''t. t f tr:. yJ ltl rr, i 7 t a�,.tk+ Y1E; ,y�i, � + t ' r; t ; ` i, ' .r. � 1• � I � . '}"}"}"��,��'yyyyyy�����1 �• ; � f +, tJ i f . I +J ' f t , ! ,� f i • , , . � it � �{ yr t;�, i�y�t�'��5[�,� J �t�C i ,f / .! �t ' .. t '. �f, , .. �'1�14 ` r•r � +I '1ji if',Tr R9r ;•�;' , rt ,r.r r I r 1 + ff/ r+. � i l f• ` ti �� � 7.' _♦1. fir; �(� +- _.1 {1, '1, .���>,r r a� L 1/ ll'. �•fir' � � 11 r�i i, P+ }. 'r/. .�,! � ( ,'' l .,i' + , :' 1 •. 1 t ' 1 1 :,.., U :.'"tr1 '';., ;�l' � + .• �' ♦,+e„yry WL�'',!•� •, , . �,� � �' r; to ,,-t,�va �, ` �� /Ai�ti � :, �: •,fir;• , ! +!� r., '+ �� � �� �, .�: r ifs, , n �, to / +' t•� •ir i ,' - j,p r�`, + r#};�' M'. , Ll e .10 v� IF ly N t• shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. A separate copy of the additional insured endorsement to each of CONTRACTOR'S insurance policies, naming the CITY, its officers and employees as Additional Insureds shall be provided to the City Attorney for approval prior to any payment hereunder. • If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged a bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the ezpiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, naps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. CONTRACTOR shall not sell, assign, transfer, convey or encumber -14- �i ct.�..Rtir..rawwsi.wwr►a s+.....r, �..w..ww.�rnw•r. .�•--.n.... r..7.��..r.-rtri-71y� 4♦ ( ��� k^, r 7t r r, r r r1 l 1 �• � .1_: .. J• , Y ; f r •qt.+ t r r � ,, 4 5,0 l• vrfA ��1 r .��� } ,,i r I � +': f t c . F,I � 1 .. S ,1 •' � ` `' ' `ti S-� r ' lid i� / H �,�;� 1 laijf �, • �'� t .r, �Y'1' � i � � lr.. ,1._ % +. 1 .':�. .' ; - 1 tr�1a � '•,�,.r� �I,,� I1, Nrl*J1.� _ � " .�•.t , '�1. � •'� � 'rl+'� ' ���s" t {L9,l,ry �yti: r; i < r ,:. r f j) r, ��,' t • + t � � o u,{ 1 y.lr rot GG•�,v,Oki d �'l , y, � 2 ,l Ld: this Agreement, or any part hereof, or any right or duty created heroin, without the prior written consont of CITY and the surety. 25. CITY EMRk=ES AND OFFICIhLS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of California Gov r �nment code Sections 1090 of seq. 26. $Top NOTI MS ; RECOVERY OF ADKIIIISTRATIVE COSTS, CITY shall be entitled to recover from CONTRACTOR its reasonable administrative +,:td attorney's fees, costs and necessary disbursements arising out of the processing of said Stop Notices, j,. Notices to Withhold, or any similar legal document necessary to the prosecution of such action. Said obligation shall be provided for 0 in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One -Hundred Dollars ($100) n, g for every stop Notice filed in excess of two, regardless of whether ' or not CITY is named in an action. CITY may set off any t unreimbursed cost or expense so incurred against any sum or sums owed' -by CITY to CONTRACTOR under this Agreement. 27. CONTRACTOR shall be responsible for full compliance with the " immigration and naturalization laws of the United States and shell, I O in particular, comply with the provisions of 8 U.a.C. §1324a regarding employment verification. 28. fiQr = Any, notice% or special instructions required to be given in writing under this Agreement shall be given either by personal delivery to CONTRACTOR'S agent (as designated in Section 1 4'W}1 ^Y'�r =+r�'�,," 11r ♦�' ,•_ Jl...r............�f.:r' `� ti--♦�1 y= '��( ';f ♦}1} t�y1��1 } `-�.'./f 1�Y i _f' }�; '''. ti r t7, ,,.' \'FY f 1 �r> ♦ 1 r r I � a , 1� S� it � ' .} . JJ � [ 1 �+-_ „4.. I1�, ' ,,,{'I � ! .. •I1. ,� ryy� 1 7 tea, '� tt {•l �t�i t� 1 ,f♦ri ' E. � t i �,.i �.. r. t r' f fl / 7. �yM � 7 t�..i ,. 1� Iri '•T 1 i�iyt%I 1 �.yr( !r lr ..I� !. ! 1' •, ' •I. � " y` r ).}'y 6rY {� r a� ",'r4 N }f� � 1 ! 'I' `1� � M�' = er . r'y ♦� ( �. r. I1 iT� � ltltCr ' 1 \'h 7 n� i }'yr .;i ¢ �ft r'y♦}'. l,r � t =. 1i1•, 1't V, Ir , '1,, �•1� ''1 ='�i ' 1.',1. �}�1�,�11 �1 -i� t !'1 ' .1 7 I"•r ; it 1j ' 0 rg, It'sr •V{y il• ry 't.``�f r �ilr�il t.rr�/..r-� .1, ,. 1, ' �'•r Jl�..riµ"f :1..� r� '�'' ,y,a hereinabove) or to CITY'S Director of Public Works, as the situation shall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States postal Service, addressed as follows: TO CITY: Louis F. Sandoval Director of Public Works 2000 Main Street Huntington Beach, CA 92648 1 N 29. MEMO li I1 U1 C7 TO CONTRACTOR: Captions of the sections of this Agreement are for convenience and reference only, and the words contained therein shall in no way be held to explain, modify, amplify or aid in the interpretation, construction or meaning of the provisions of this Agreement. REST OF PAGE NOT USED -16- r t ICY. le'�I�WWI "hx,,( jrt r1 i •_ y S,,�a •� ., r,,r ttr .r.' (� r '-{ 14 r lr( I r, rl 1F1t, f 1 J c,flil �y ,,t ��i ( y• { rl ,,,i(� ��� �( •r r I• ' rl i''�r+ t,- r 1 �irt��i �i, i�, •J1i � 1 f. ��.� a �t' { � ( ��', ( ! � ( � ' 1. : 1 ' '1 r � �'—t 1 ..f' i•ri I t,{,f i j 1it; Y f�i A,if,�cf Iy� rr ti.l t�+� ; uhi' ,12;, � 1 -'� � 1 li � i - 1 rtif, �1• 1 t�` C IL.�I �fU� � �,IA + ifs jj/I_"'Y1.�t '`i r tt �• I , 1` !J. 1• '',/r I .,' 1 1-'r{7rf `,;,� f? td(tr'; 1 ,It Ir i ✓ � i �i/L r r .,t '.T 1 r � 1� { `r � rr Ip . rr[�r�II� -t' (.,:,' 1'�1' � ,/ ,r .. ;, I,• 1 i' r 7 it ',jYt''r i' L }I ,�1 f �� t•7r ;3. � ( � 1 � � f'1 r �: .l ` ii�t�Ft, y a � } 'r ; _. ( 11 •. ' ` , r f r y . { ^ . `/ tl l 11,Sr ,� , `�Ili,tl"; :1 ' 1 '1 r .�-. r�, � .' )l�,' r ,ri.'r(Ili •� ,ir 1` 1��� `/ � ��. , ,., � � - ! / ( ' '' �1 •fit � � t I ./ ' ' •'f'�4 t ' ,ill a. r• 0 i 0 C L` 149 ti� �i� is �`. 1 • ! .,1� 1 ac(44 .{J/��Ir1t "•' r S�rA 'b/� 1 ,/ J `,� �{ r r1 �` N JI 1 � r ry 1`rl �� r t � ^I♦ � �, fl� ri ., I, + t L1�1 i/�( `+'vrJir. A. r1,, ;J �t S`f ;. .T: •� ` �t i" + 1 � �r' �J. � r ��'�i:r�i*; ryLL�"'M'1, �� -}► y�",:"`" 1yiii�}MrsJ'�`S+ ' 30. ENT1RSZX The foregoing represents the entire Agreement between the partial. IIN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their atithorised officers the day, month and year first above written. CONTRACTOR: By Its:— By: Its: ATTEST: City Clark REVIEWED AND APPROVED: City Administrator -17- CITY OF iiUNMOTON BEACH a municipal corporation of the State of California Mayor APPROVED AS TO FORM: WtornAt,t,,���� ;r INITIATED AND APPROVED! Director of public Works aj7 �` y 417• r f r- 1 (, +�"w."""'�^`..�-�,.wn►�Nw� {. �.ri( ���•ji �t i t 1 f'l �.y 1�(.1 t.'1`i11 r ! t ,i:.,Ir t < <` r Ji. i ( i�i ��) 1�/, • •3 �,t .t % t3�J�/'�,rt � yr� 1 �� f,Y : 1a, a -{ ,,@tit4 1;1�'• Y �r �� r{7�w Iti, 1rrY�i�t ,,.TI✓;y�•\,qi j! j ,� r��,�' 11 ( ./,/ ,,. ':1 Ir.t rj '� " y,� :tr't�l, '{'� f ;r + r„�. r r J; i � i , "+ .� � . r,i� ,.'� l { t� t t•r �' r� r < �' � r ' ` t ( yC.� tr,� 1 1�{: •1 t -•f. r :I' C } , .' .+ 1, ,..,.1 �' t r•f• J J CI r J l 1, ,. .t 1 A11� i ;` • ,.. i�, � (� � fit •� ��� , � t f. )2 E;! •i" ,•''� 1 ' 1'I1, 1 ttr'(j1.1 `1 t.yl.%! rf r7 . 'n •J r, !r r - 1 ,rr . nl' , f0 Ef R n 0 TABLE OF CONTENTS CITY OF HUNTINGTON BEACH STANDARD SPECIFICATION$ P!sa•. i Standard Specifications MR-2 General Spealal Provfslons HB-3 1-20 Daflnitlons HB-2 2-I.1 Award of Contract HB-3 2-1.2 Execution of Contract HS-3 2-1.3 Failure to Execute Contract HB-3 2-4.1 Return of Bid bond MR-3 2-4.2 Guarantee H9-3 2-9.1,1 Plans and Sprclflcstlans HB-4 2-9.1.: Colrpstency of Bidders b Payment for Plans d Speclflcatlor.s HII-4 2-9.4 As=Bullt and Record Drawings HB-4 2-6.1 Rempval of Defeative and Unauthorized Mork HB-y 2-7.1 Sall Conditions HB-5 2-9.1 Fermanant Survey Markers 148-6 2-10.1 Authority of Board and Inspection HB-6 2-10.3 Final Inspection HB-7 3-CO Change In Work 1,15-7 4-1.2 Protectlon'of Work and Materials HS-7 4-1.4.1 Test of Materlsis . HB-7 6-1.1 Constru,ition Schadulh and Commencement of Work H11-6 d-1.2 Progress of the Work and Time for Completion HB-6 6-2.1 Progress Schedule HB-6 6-a.1 Acceptance H13-8 6-9 L I qu l dated Damages HO-8 7-2.3 General Prevailing Wage Rates HB-9 7-2.4 Payroll Roux rds HB-9 7-3.1 Public Liability and Property Damage Insurance HIS-10 7-9.1 Permits and Licenses HB-10 7-6.1 Contractor's Represan+ative HA-11 7-6.2 Supprintandence HB-11 7-8.1 Cleanup and Oust Control HB-ll 7-8.9.1 Use of City Water System HB-11 7-8.7 Noise Control Hi!-11 7-ea 7low and Acceptance of Water ile-11 7-8.9 Eroslun Control HE-12 7-8.12 Temporary Fencing HB-12 7-10.1.1 Tratfic end Access HB-12 7-100.2 Safety Precautions HB-13 7-10.2 Storage of Equipment and Materiel In Public Streets HB-14 7-10.3 Barricades HB-14 7-10.5 Water Main Shut Down HB-14 7-15 Registration of Contractor HB-14 9-3.1.2 Payment General HB-14 9-3.2.1 Progress Paymen+s HB-19 9-3* 2.2 Final Payment HB-19 Section 10 Proposal Requirements H9.-16 10-1 Examinlatien of Plans, Specifications, Special Provlslons, and Site of Mork HB-I6 10-2 Proposal Forms Hb-16 10-3 Proposal old Bond 112-16 10-4 Wi}lidrawal of Proposals HB-17 10-5 Public Opening of Proposals HB-17 I0-6 Rejectlon of Propnsal Containing Altirstlons, Erasures or Irregularitles HB-17 10-7/6 Olsquallti catlon of Bidders NO-17 He- i :• � 's 1 `•'Iti t i«,<_ .:'7 •. ..':, ! .[1', ... ., r; .. !'. _. .. .. � '� - .. � - � .� i` C•,... !i- '•l ..•M"�^]I tv i➢�4�L'i�' "z • 4� •c. . O ! - ;d STANDARD SPECIFICATIONS Except as hereinafter provided, the grow Islons of 1he 1988 Edition of the "Standard Spealfloat Ions for Pub Ila Works Construction" (Green Book) published by Building Newa, Ina. 3005 Overland Avenue, Lai 4ngoIas, California 90074, and all omendments thereto, adopted by the Joint Cooperative Committee of Southern Cal ifornla District ano Associated Contractors of Callforniol hereinafter referred to as Standard Speclflcatlons, are adopted as the "Standard Speaifleatlons" for thla project and shal I be considered as a part of these Special Provisions. Where speclfled, tha speelfled editions of "Standard Specifications" and "Stnnderd Plans" of the State of California, Buslnoss and Transportation Agency, Department of Transportation, shell apply. If no date o: publlamtfon Is specified, the most recent sdltlon, as of the date of publleation of the Notlas Inviting Olds for this contract, sha)1 apply. GENERAL SPECIAL PROVISIONS The following edditlons are and* to the "Standard Spealfloatlons". If there is a conflict between the Standard Specifications and these additions, those addltlans shall have first precedence. 1.2.1 0ofIli ItIone- 1 ta) AGENCY The City of Hun•ling�on Beach, California at so hereinafter celled "CITY". (b) BOARD The Clty CouncII of the City of Huni'Ington Beach, Callfornla. (a) CONTRACT Documents Including but not Ilmlted to the OQCUAENT proposal forms, Standard Speclflcatlons, General Provisions, SpeclaI Provslstons, Flans, Bonds, Insurance, Con tree t Agreement and ell addenda setting forth any modifications of the documents. (d) ENGINEER The ad►alnIstretIng off Icar of the City of Huntington Beach or his euthortzed representative. (a) BIDDER Any Individual, co -partnership, astaclatlon or corporation submIttlog a proposal for the work contemplated eating directly or through a duty authorized representative. (f) LEGAL The legal address of the Contractor shall be the ADDRESS OF address given on the Contrector'e bid and is CONTRACTOR hereby designated as the place to which el I notices, letters or other communications to the Contractor shall be malled or delivered. (y) LABORATORY An established laboratory approved and authorized by the Engineer for tasting materials and work Involved In the contract. HB- 2 1 L• J tt/ .I� P, i• s is li fit 1 �.7���>..>sML f,.. .. '.. _.. ... . `•'.'+. f . 1 .1 .. .., .. .._ �y wil.rf l.t. il:l (h) SPECIAL The ''spool aI pray isIon I bra Soso ltle cISuess PROVISIONS settlog forth conditions or requirponts pacuiler to the work and sups lementery to these Standard ' Specifications. the Department of Transportation J pub IIcstlons ant Itled Labor Surchov . and Equipment Rftntal Rates and General PrevaliWage ,y Rates are to be considered as a part of the special provisions. (1) STATE Chapter 3, Park S, Division 3, Title 2 of the CONTRACT Government Codes The provislons of this act and other applicable laws, form and constitute a part of the provislons of this contract to the same extent as Is set forth herein In full. 2-1 st, Award of Contract The City reserves the right to reject any and al I Proposals. The ;• award of the contract, If It be awarded, wlII be to the looest responsible Bidder whose Proposal compiles with al I the requirements proscribed by the City. %% 2-1 2 Execution of Contract The contract shaI I bn aigned by the success lu1 21dder rithIn ten 110) working da11a after awero, and be returned together with the contract ` f:. ✓+ ,,,�'� bonds, to the City C lark's office. Work sha I I commence within 10 working days after the contract has bent f ul 1 y executed. No Proposal tha'►I be considered b1nding upon tho City untlI the contract is executed by the Contractor and the City. The contract tints! she I 1 S r� {r ,C'�i• j start on the day of contract execut Ion by the City. r, Y,i' 2-1.3 Failure to Exacule Contract 1 Fai I ure to execut•s a contracr and file acceptab I n bonds as provided herein within the time specified for the applicable contract category shell be Just cause for the cancellation of the award and the forfeiture of the proposal bid bond. _ 2.4.1 Return of R id Bond Within ten I101 days after the award of the contract,_ the City of 01;ntington Beach wl I I return the bid bonds accompanying the ,proposal which are :.at to be considered in making the awards AI I other bid bonds w t l I be held unr l l the contracr has been final l y executed, after which they wll I be returned to the respsctIve bidders whose proposal they accompany. 2-4,2 Guaranteet,; S' .i The Contractor, by submission of a bid for this project. expressly agrees to the herein stipulated guarantee of materials, products, �;,• �.;�;,?. workmapshlp, and Installations Incorporated Into this project. All wort' performed In accordance with Theis plans, standard specifications, and special provislons, Including, but not 1te14ed to, workmanship, Instal latlon, fabrications, material and structural, mechanical, or electrical facilities sha 1 l be quaranteod for a period of one ear, commencing with the f I I in of the notl cs of completion 41 ''{ ' V�4't �` ! and acceptance of the contract by the City, unless specific areas are to be guaranteed Longer as pray Ided In Specla 1 Pray Istons. , ... •.. _..... ...•_.. .. ....... _..-.__...•.... °'i` �!:..r �7. �'. �1�*i. + r. r,ti ,',,ice � •i .. .tr • .0 ILI Security of this guarantee shall be furnished to the City and may be Incl ►+ded as part of the Falthfu 1 Performance Bond. There she I I be express wording In the Performance Bond, If such bond Inaludes the guerantas or warranty of the Labor and Materials for a one-year period, aommetrolng with the f II Ing of the Notice of Campletlon and acceptance of the contract by the Clty, The guarantee amount she I 1 be for the full amount of the Performance Bond. Release of the Performance Bond shell not apply to the guarantee of warranty psrlod. The Contractor, by agreoing to this Intent dot act guarantee, also agrees that within 10 days after Pat[ tIcatlon of a failure of deterioration of a faclIIty or work covered under thls contract, he will reps lr, replace or show reasons bia cause as to reaeon for further delay, Refusal or failure to commence repair or replacement 111 th Clt t all I I I t th b d w cause o y o s c a m age ns c on , Except for the guarantee of labor and motor IaI1 0111 be defects caused by mats of God, acts of the Cl+y, sets of vande Is, or be sets i of others outside or beyond the control of the Contractor. `r 2-91,1 Plans and Specifications 1 ` ' IV The Englnver viol provide the Contractor, from of charge, espies of plans, special provisions, and additions to the Doneral Provisions of ,i�},: the Standard Speciflcatlons that are reajonable necessary for the execution of work. ' rt� Isar' Contractor shall, at Ills own expense, obtain copies of Standard Specifications and Standard Plans and Speolflcatlons of the State of r' Ca IIfornla, for his general use. If after award of contract, should It appear that She wor..'to be J. C done, or any matter rolall ve thereto, Is not sufficlently dotal led or explained In the Standard Specifications, Special Provisions and '/ r plans, the Contractor rhalI request from the Engineer further expl anatlon or Interprutatlon of the contract. Tho request by the Contractor and the Enginoter's respon6a shall be In writing. n �` All scaled dimensions are approximate. Before procoed)ng with any work, the Contractor sha l I carefully check and verify e l i d lmens ion a I�!' , • and quantities and shal I Immedl3tely Inform the Engineer or his representative of any dlscrepanGles. 2-5.1 x Ccmp*+snSX of B Idders and Ps 'tirvrt for Plana and Soael f Icatlona t•f' J; r� Plans, Special Provisions and Proposal forms wl:r be issued only to those contractors who can e,ua I Ify as competent bidders. A charge wlI I be required for the ta%cing out of plans, none of which r I I 1 be �S reful;ded to any bidder. 2-9.4 As-Bu l l t and Record Uraw l nga j The Clty she 11 furnish the Contractor with one 01 set of r reproduclbIs trensparenelei (contact mylars) and one (1) sef of bluoilna prints showing a I I work required under this contract. 'Contractor shell mat ntein and keep up to date, the set of blusIInot r, I shhow Ing the "as-bu I 1 t" i ocat Ion of major foa*ures such as potable i + wat6rIInes, electrical condult, etc. of the project and IndleatIng changes that may occur during InstaIIO lon. l HB-4 „ "- , ,. '�. ., r..rwrw,.�....,.. .... ., .,: ... •. -. •,.,.rl� ..,.,. ...x-:-y/•,.. ., ..711r �•,}•nrP,, I) i �a I i Prior to the Post- Installation waIntonance Per lad, Contractor shell returii to the Engineer. the City furnished reproducible transparencies as the Record Set shoring the as-bullt data In black Ink (no ball point pen) and eradicate outdated Items. 2�6.1 Removal of Defective and Unnuthorized Mork All work which Is defective In Its construction or does not most all of the requirements of the Plans and/or Speciflestlons shell be romedled, or removed and replaced by the Contractor In an acceptable manner, and no compensation wlII be allowed for such correction. Any work done beyond the Ilmlts of the IInes and grades shown on the plans or established by the Engineer, or any extra work done wl'hour written authority, wlII be considered ..s unnuthorized one wlII not be paid. Open failure on the part of the Contractor to comply forthwith with any order of the Director made under the provisions of this ar+lcle. the Engineer she I I have authority to cause dot matt ve work to be remedied, or removed and replaced, and unauthorlted work to be removed, and to deduct the costs and thereof from any mantes due or to become due the Contractor. 4-7.1 Soil Conditions The Contractor shell Inspect the Gall conditions himself before submitting a bide By submitting a bid, the Contractor acknowledges that he has satlsfled hlmoo lIF as to the quality of the work including but not rostr fated to the conditions effecting, handling and storage of materle19, dlsposr,l or excess materials, the ao11 conditions, and level and amount of groundwater. The Con tractor's attent Ion 1 s d treated to sal I s tests coir.p I sted by Soil and Plant laboratory, Inc. (Sde Attainment "AN.) The oval IablIIty of salts test results shotI not be construed to be a waiver of the Contractor's obIIgatlon to Inspect the soli condlttuns himself before submitting a bide By submitting a bid, the Contractor acknowledgws that he has satlaf led hleself as to the quality of the tests .lnaluding, but not restricted to, the conditions effecting handf log and storage of mattirlal9, dlsposeI of excess materlaI and level and amount of groundwater. .'i•' 2-9.1 Permanent Survey Markers The contractor shall be responsible for protecting at exssting horizontal and verltcal survey controls, monuments, tlos and bench y marks located within the limits of the project. If any of the above require removal, relocaffn or resetting, the contractor shall do so at his own expense. Such work shall then be reviewed and approved by i the City Engineer prior to final acceptance of project. if any of the above require remove(, relocating or raretting, the Contractor shall, prior to any conatructlen work, notify the Enginmer so arrangements can be made to establish sufiteient temporary ties and benchmarks to enable the paints to be reset after completion of is construction. 1 II •1 HB-D ' I , J 11 /�, , � �, I��Y�.Nt\Y •. :s 1 .. •.. . ,. .. .�.., r r. � .... ... � ST. .. ';'hl`I�L /�:>w tlj M. rI..J. ..i � l�. w li 1411 0 2-10,1 Authority of Board and InsUctlon The Contractor shell give at Iseat 24 hours' advance notice when he or his Subcontractor will start or resume the work. The @boys notice Is to be given during working hours, exclusive of Saturday, Sunday or City ha)Idays for the purpose of peralt'ring the Englnear to make necessary assignments of his representatives. It the Contractor elects to work under this contract more then 8 hrs/day or more then 40 hrs/reek, Saturday, Sundry, or City holidays he shell arrange with the Engineer for the rsqulrsd inspection servlcs and pay the speclaI Inspection fees which wlII be charged at the fol lowing retesi 4 hrs or less/day $200,00 4 fire to 8 hrs/day $400,00 When Special Inspection Is required, the Contractor shalt nutlfy the City and pay Inspection fees 24 hours In advance. If the Contractor Is'dlrected by the City to work under this contract more than B hrsldey or more than 40 ':•s/week, the Special Inspection fae requirements will be waived. Any work performed In conflict with said advance notice, without the pressnca or approve) of the Engineer, or work, covered up elthout notice, approval or consent may be rejected or ordered to be uncovered for examination at Contractor's expense, enu shell be removed at Contractor's expense. If so ordered by the Engineer. Any unauthorized or defective work, detective material or workmanship or any unfaithful or Imperfaet work that may be discovered before the final payment and ?Inai acceptance of work shell be corrected Immediately without extra charge even though It may have been overlooked In prevlcus Inspactions and estimates or may have been caused due to fallurs to Inspect the work. ' Ail authorized alterations affecting the requirements and Informatlon given on the approveJ plans shall be In writing. No changes shall be made.on any plan or drawing after the some has been approvsd by the Englnear, except by diroctlon of the Englneer In writing. Deviations c7 from the approved flans, as may bfi required by the exigencies of constructions wl ( 1 be determined In a I I cases by the Engineer anu authorized In writing. All Instructions, rulings and decisions of the Engineer shall be In writing and shell be final and binding on all parties unless formal protest lamed* In writing an1 as provided in the following paragraphs If the Contractor cone Ider s any work d@mended of him to be outside the requirements of the contract. or If he considers any Instrueiton, j ruling or daclsIon .of the Eningoer to be unfair, he shell within ten (10) days after any such demand Is made, or Instruction, ruling or I I decision Is given, flIs a wrftten protest wlt% the Engineer, stating e I eer I y and In detail his ob jectl ens and reasons there fore, Except for such protests and objections as are made of recorded, In the ". manner and within the time above stated, the Cnntrector shell be i deemed to have waived and does hereby we Iva al I claims for extra work, damages and extensions of time on account of demands, Instructions, rulings and decisions of the Engineer. HB-6 ' 1 �' Ell t� A • i µ , Upon receipt of any such protest from the Contractor, the Engineer shall review the demand, Instruction, ruling or decision objected to and ohs I promptly advise the Contractor, In writing of his final deolslon, which shot I be binding on at I parties, unless within *he ten (10) days thereafter the Contractor she I 1 f 1 Is with the Cl ty Councll a formal protest egalost maid decision of the Engineer. The City Council shall consider and render a final decision on any such protest within thirty (30) days of receipt of same. Final Inspection Whenever the work provided for and contemplated by the contract shall have been satlstactorlIV completed and the final cleaning performed, the Engineer will make the final Inspection. Change in Mork No claim for additions I work or eater l a l w i l l be a l loved unless supported by a change order Issued by the Engineer and executed by the Contractor. Ne additional work or other changes shell be started before the issuance of the order by the Engineer and the exoeutlon thereof by the Contractor. Payment for such cddItIona I work .III be made whore p"rtlnent on the basis of the unit prlcas bid by the Contractor for such work or If the unit prices are Act appllcsble for computing the additional work wlII be made upon the basis or a Iu*p sulk previously agreed upon by the Contractor end the Englnser and set forth In the change order or upon cost plus basis. Protection of Mork and Materiels Materials shot I be stared as to ensure the pre3ervatlon of their quality and IItnass for the work. When considered necessary by the Engineer, they shell be placed on timber platforms or other hard clean surface and not on the ground, and shell be pi aced under cover when so requested. Stored materiels shall be located to as to tec!lltate prompt Inspection. No materlaIa ►ill be permited to be stored at a city storage faclllty. Test of Materials All tests, of materleIa turnlshod by the Contractor shell be made In accordance with common Ii recognized standards of national organizations, and such special methods and tests as are proscribed In the Standard Specifications. No metwrials shaII be used untlI they have been approved by the Engineer. The Contractor shad , at his expense, to" Ish the City, In triplicate, certified copies of all re4utred Cory and mlil test reportse Any materials shipped by the Contrac•I.,r from 4 factory or gel I I prior to having satisfactorily passed such testing and inspection by a resprosootative of the City shall not be Incorporated In the work, unless the Engineer shall have notified the Contractor, In writing, that such testing and Inspeetlon will not be required. At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before delivery is �.,. started and before such material Is used in the work. 2-10.3 3-00 4-1 .2 . 4-1.4.1 Ve f` •' I t ':1 t 4 ;!( ` i, 1 I �• i t 17 ' a 0 E F I 1 '1 I�Ri i'A.�-..�.�, ..... �.-.........�.•..� .w •.I.f.'.69t'•h-r. .. • /. 1.. .. •.. ...,r .•..w..... .. ., r. .�• 1 n..s.fw,.rr.►•...•wr wVrfr � _-- '��• ) i� The Cityof Huntln tnn Beach vfl I g pay for the Initial Sall end material tests. Any subsequent soli and materials tests weaned necessary due to the failure of Iultial tests ■III be at tht I, }: Contractures expense. ' 1 {{ 6-1,1 Construction Schedule and Commenconent of Mork Pr for to the start of :fork, arrangements wl I I 5u mede for a meeting between the Contractor and the Engineer. The purpose of this meeting Is to coordinate the act lvltles of the Contractor within the Ilnits �. if this contract. review scheduling. discuss construction methoJs and clarify Inspectlon procedures. Tha Contractor shall submit for approve I by the Eng Inser a comp I eto schadul a showing the no !.bar of working days renvlred to complete the project. I.• ;1 Thu contract time she I commence upon the data of axe' � fen of the contract by the City. '... ,''1i1, `' it 6-l.Z Progress ,opt t011 Work and Time for Coe lotion The Contractor shsl I begin work within ten 00) working days ■ftir the contract has been 'ul!y execuied by the Clty and shall dtligentty prolecuto the same to campletfor. before tha axplrnt Ion of the time specified In the proposal, speclflcntfoAs, and/or contraat. 6-2.l Prearois Schedule When In the judgement of the City, It becomes necessary to accelerate the work, the Contractor, when ordered, shill cease work at any particular point and concentrate his forces at such other point or Points as direct—ds and oxecuts such por*tons of his work as may bs required to *nab le others to hoston and properl y enoago anJ carry on ���' !��` +i {'� •N 1 thoi r work* 6-5.1 Acceptance Should It become necessor'i-, due to dove loped conditions, to occupy ,-.'�, 4 11r, any portion of the work before contract 12 f u l l y completed, such occupancy shall not constitute accepttince. •;,. sr x` 6,-99 L IouIWed gamapss ti Section 6-9 of the StandnrJ Speclf Ieatloits for Pubf I Works Construction she l be nodfIlad with respect to the do Ior' amount of demagos per Jaye The dolly sun due oar day for each consecutive �,•` rj�. ,° �;�4-` calendar day In excess of *he time spaulflad for complstloc of the i work shell bo as follows: 1„,,,,• ,' Controc!- Amount n l i y Sum Due _Per 2M t _ Contracts up to $250,000. - S2S0. iContrscf s 1250, 001. to t 500, 00. S300/ Contr act a $ 500, 001. to $1 , 000, 000. S400. ? }' :� t ' ', , •' Contracts 11,000,001. -to S1,500,00. $500. �. Contrects 31,300,001. and over S670. .t r iJ .. r ( , I - 11 t 'fix ,�!•1• His-e , 1 . use+:-+.n..w....■�.vVr.+gP,.w.�u..Lr�w-Nt.'-.YT'. ., .p ,'J��'1'1. :!•`. N••.' , r,..•-•. .-. ,,,.•,. ....._..... ..,� _,... :rc ,,s rl;p•'. ,;r, �'' •` I j' ' I '�! • II ,t r t I 46 r- 7 J 1-2.3 General Prove II Inii Mege R_ a9_ns In accordance wlth the provlslont of Sictl.an 1773 of thu Labor Code, the State of California Director of tho Dapartmont o' Industrial Relatlons shell determine the 9-,aoral prevalIIng rate of wages, app!lcable to the work to to drips; copies of the Isirost gonoraI wage rats determinatlone are on IIlo at the office of the City Clerk, and the off Icts of the Director of Pub ;Ic ►'arks of the Cl`y of Huntington bench, Cr. IIIornla. 7-2.4 Pe rol_ Records The Contr'ctor's attention Is dlroctod to tho toIloving peovlslons of Labor Colo Section 1776 (3tats. 197b, CH. 1249). The Contractor shell bo responsibIn for comp llanre with those provlslons by his subcontrcctors. a. Each contractor and subcontractor shall kusp an accurate payroll record, showing tho name, adorasa, social security number, work classification, straight IIme and overtime hours wo-kod oath may Lind weak, and the actual per dtom wages pal to oacn Journsyma:n, apprentice, workor, or othor omPIoye3 amployed by hIm or her In connisat Ion with tho pub(Ie* work. b. The payrul . records onumorato-' under subdivision ta) she I be certifled aitd shal I be oval lable for Inspection at el I rensonable hours et the princlprf off Ica of tto contractor on the following has is: 1. A certl f loll copy of an emp I oyeets payro I I record she I I be made dva(lab (a to• fne.pect(on or furnishing to such employes or his or her authorized representative on request. 2. A eertl f Ind copy of a I I payro I I records enumerated I n subdtvls Ion (a) she! I be made oval labia for Inspection or furnished upon request to a reproseniative of the body awarding the contract, the DlvisIon of Labor Standardb Enforcement and the DlvisIon of Appienticoship Standards of the tlopartment of Industrial Relations. 3. A cart I f led copy of all payrul I records anumera:`ed In subdivision (a) shell he made evaflable upon request to thw public for Inspection or copias thereof made: provided, however, that a request by tlta pub 1 I c she I 1 Ue mcdo throuoh either the body awarding the contract, the Dlvislon cf Apprenticehilp Standards, or the Division of Labor Stenda-)s Enforcement. The pub I Ic she I 1 not be gl volt ac-ess to such receres at the principal office of the contractor. Co Each contractor shall file a certlrled copy of the records enumerated In subdivislon (a) with the r,ntlty that requested such records within 10 days after receipt of a written request, d. Anu copy of records made available for 'nspectlon as copies end iurnlshed upon request to the public or any public agency tty the awarding body, the Division of Apprenticeship Standards or the 0'vi s ion of Labor Standards En forcemtint she I I ne marked or obIItaratad In r•tich a manner as to prevent disclosure of an :ndfvldualt, name, addrfisa and social se.urlty number. The name and address of the contractor awardad the contract or perfnrming the contract shall not be marked or obliterated. r Contract-)r shall require ttat an approyou safety v+st be worn I ell personnel who are working at this project site. Any worker without a vest may be ordered off the job py the Inspector until such apparel Is acquired. Questions as to approved vest. shslI be dlrc.ted to the Engineer. 7_1017 Stordan of Equl a� ent and Heterfnl In Public Streets The Contractor shell so condue• operations as to offer the (east posslble obstruction rnd Inconvonfence to the pate l(c. The Contractor shall have under -onwtrucyIon no greeter amount of work then can be prosecuted properly with due rogaed to the rights of the public. The Con rector shal I Maintain a1 the construction site, and at any add ltlondI sltes provided for temporary storage of construction matorto19 and equipment, such security measures, Including watchmen, as Is deemed advlscbla. The Cly she, I not be raqulrod to provIdo prn•ectlon from trespass or vandalism. Nothing he,-eln shal 1 he cons•,rved to entitle the Contractor to the oxclusive use of any public straet', road or parking area during the performance of t1,n vork. Starlag of materldis shale be ailosod on the croject site only. Sctaty precautions will :e as stat ad In the City of HuntIngton Beach Standard Specifications heroin. 7-10.3 Berrlcedes All barricading to meet manual oi, Unf fern Trefflc Control Bev Ices - 1973. 7-10.5 Water Main Shut Dawn When a Clty water main or service Is to be Out down, the affected residents shal I be notified by the contractor at least 24 hours l n advance of the shut down. The Contractor shbII proceed with the meter fscIIItIa% work In an exped lent manner until thn water I mes are In 6arvlce. If water service to residents Is disrupted for more than 4 hours, the Contractor shal I provide temporary wkete,- service to the residents. The cost shell be Included In tho other Items bid. 7-I5 Roolstrbtlon of Contractor Prior t- the award of the contract, the Contractor shell be licensed In accoreanco with tho provisions of Article 1 to 9 Inclualv's of Chapter 9, Dlvlsion 3 of the f3uslness e.16 arefesslons Code o: the State of California and AmandmentiL thereof, providing for the registration of Contncctors, and defining the tovii Contractor; prrvldIrg a method of obtaining licenses ro a.tgage In the business cf crl,trac•e ing end f ixing the tees isr such I Iconses; and prescribing the punishment 'or vlofatlon of provisions thereut, as ac.en%ied. 9-3.1.2 Pa went deneral IJB-14 Payment for the turnisning of at l iptor, nets,riai•. and nquipnen* necessary to pv'form ell work Indicated an the plans and describe9 In i these ipeclflcatlons and Speclef Pt•ovislons shell be included In the contract unit prices bid for the Itons Ilstea on the Proposal, and no 1 additional compensation wl i l be allowed. Comoonsatlon far Items ct work shown or oescribed, but not i Isted on the proposal, of I I be considered to he Included Ii the prices bid for listed items. rr , ,l �r I. • A I i ci i I I Ih i 0 The Contractor shall provlle for and maintain rrovislons for public trafftc through the construction area at all times. Unless otharwlse specl119.1 In these SpeclaI Praylsions, work she I. bo In accordance with ScstIons 4-1.04, 7-1.00 through 7•- 1.95 Inclusive, 17-I.OY through I3-2.O5E Inclusive, a the State Department of Transportation. Standard Spec lflcot Ions, and as pro vIdad for In TItIa 8 of State of Californit, Department of Industrial Relations, Construcllon Safety Orders, and Chapter 12.24, "Wer.sing LIcghT% - - Berrlcodes^ 31 the Huntington Roach Municipal Coda. The ;nspec�or may roqulre addllIona I devices to control traffic as trafftc and construction cond!tlons requl-e. The Inspector may stop work at then Job site untlI the rcaulrod Safety and trafftc control dnvlcau are put I place by the Contractor. The cost for additional safety and traffic can-IraI devices shal I be Included In the tjnit prIus or lunp sum prices bid for the Job and n) additional ccmpnnsatlon wi I I be a I lowed therefat e. DuestIona pertalning to construction, varnIng st Igns and day cus she I I be d Irected to the Engineer. Prior to the bogfnning of work, the Contractor shaI I present to thri City a detour plan pertaInIrg to any detour s) he fools will be rep':red to properly prosecute the work. The detour plans, when accopted by the City, ±hall become the off1:laI document upon which detour(O shaI I be Fitt In pl ace and maIntaInwd when required. Any detour which wlll laat longer than three cal under days hhall be doII.ea'ed by ramoving the existing strlal-tg and legends on the pavement by sandbIastlhg and placing now striping and legends as may be apprnpr late to accommudate the detour. Upon cuwpIstion of the wort: and the restoration of The rood surface to ltv f Ira t condition, the detour striping she l be remov-od by sandblastfng by the Contractor and the orlginaI striping replaced. Cost for removal and replacement of detour st-lping shell he Included In the other Items bid for Tho cork a;td no additlonaI componsat Ion wlII be aIlowed therefor. The Contractor's att•ent Ion Is spec) f le s h y d i rected to tho HBNC Section 12.24, "Yarning Lights - Barricades", pertaining to the use of barricades and lights In excavation areas. Fleshing barricades wl I 1 be al lowed as a svbstltul-a for "I Ights" as dascrl bad In that se:tlon. 7-10.1.2 Safety Precautions The Contractor shall provide for and malntalit prcvlsfons for public trrfflc through the construction arua at all tines. Unless ot•herwlse specified In these Special Provisions. work shell bo In accordance with Sections 4•1.O4, 7-1.08 through 7-1.95 Inclusive, 15-I.32 through 15-2.05E Itic Ius[ va, of the State Deportment of Transportntlon, Standard Speclflcatlons, and as provided for In Title 8 of State of Ca I Ifornle, Pepa^tment of Industrial Re latlons, Construction Utility Orders, ar.d Chapter 12.24, "Warning Lights Darricodes' of the Huntignton Beach Municipal Coda. The Inspector may require eddltlonaI dovIcos as trafftc and construction conditions require. Questions as to construction warn!nr signs end devices :.hall be directed to the Engineer. r Li. The Contractor shal I conduct his o, atlons Is sucn a manner ghat sturfe or other waters mey proceed wit out diversion or ob!truetlon alone bxlstlny street end drainage urrese Oralnsge of water from existing cntch basins shell be rnalntdinsd at all tf&us. Diversion of water for short reactat to protect construction in progress w111 ba permitted If public or Private properties are not de -.aged or, In the opinion of the `nglneer, are not subject to the probeblIIty of oamagei. The Contractor %Fall obtain wrlttor permluslon f-om the applicable pubflc agency or property owner before any dl,#orslan of warer will he permitted by the Enpinenr. In the course of water control, the Contractor shall conduct construction operatlonr to protect waters from polIuTlon with fuels, of ;a, bi?umens or other harmful matarfals. The C1ty has recelvod a peralt for discharging froee the Cal Ifornla Regional Water Quality Control Board `het is reproJuced In these Spectal Provisions as Attachment B. 7-5.9 Er as ton Control The Con�ractor shall subm1t a For:tfon plan sopcifying methods to central orotr Ion due to the construction actl v Itles of the project. This plan shall be subnittod for sppro vaI to the Director no later then five (5) dews after the oponing of bids. 7-B .1 Z Tompararr F enc' nn Temporary S and ng, 6e It. height w 1•h lockable double gates at the southern and northern ends of the project .ito. ecua I to Nei Iona I Rent A renne. as approved by the Engineer shall be Instal led where shown on plans to prov!do for the enclosure of tNe MaIn construction arc& of the project site. Contractor shell remove the teepora;y fencing at the time doslgnuted by tho Clay Epaltieer. 7-10.1.1 Traffic and Accoas No f u I I closures, wl I 1 be perm Itterd. Dayl Ight lano closures wl I I be permitted with prior approval of the Engineer provided flagman are avallabia ror control of vehicle movements. Closures are IIisIted to between 9:00 AN and 3:04 PM. Safety precautions she I I coot orst to Section 136-e07 of State Standard Speci'ica`lons and these SpeclaI Provisions. Alpllcable sartions of Cal Itorn la Administrative Code, TItle .1, concernla; olectrlceI and construction safety standards and practices, shail be adhered to and enforced by the Contractnr. Contractor shall require that an epprovod safety vast be worn by ell personnel w;eo are working at this project site. Any workrr without a vost may be ordered off the Job by the Inspector untlI such apparel It acqufrnd. Questions as to approved vests shell be directed to the Engineer. Contractor shell submit, when necessary, a plan indlceting Iane clasuru and detouring layouts for traffic unglnewres approval. Nrn-1 2 ;J i 1 r I I i J'' v - o' . tom. :w I01 7-6.1 The Contractor's Ropreser.tativa Contrecto,• shstl also file with the Engineer, the address and telephone ,tumuers where he or his designated reprebantattve may be reached during hours when the work is not In progress. Instructions and Inforatatlon given by tho Engineer to tho Contractor's 3uthorlted vapresentative In person, at the address or telephone nu.ibers Iliad in accordance with this section %hall be considered as having been glve.i the contractor. 7-6.2 Supsrtntandence Whenever the Contractor Is not present on any- pert of the work where the City desires to give dlrsctlon, orders rill be given by the Director in writing, and sha I 1 he recelved and obeyed by the Contractor's superintendent or foremen In charge of the particuiir work In reference to w11nh orders are given. 7-8.1 Cleanup end Dutt Control At l spirp I us Rater la i% she I I be rcmoved from the s 1 to Immediate I y after completion of the work causing the surplus -naterfals. Unless the construction dictates otherwise, and unless otherwise approved by the Enl-lneer, the C*atraetar shall fornldh and opsrste a self-loodlag enter &weeper with rpray noxxte, a1 least once each Morklap day to keep payee arofts acceptable *leas whenever eomstruetion, Including reesaratloo, Is IncLaplete. 7"8.4.1 Us3 of the Clty Water System Cunstruci to, water motors are required on a I projects within the City. The Water Divlslon wit I furnish and set the meter with eddy valve. The deposit for the water motor Is $700.00. The service charge To sat the equipment and for each time the equipment Is moved to a new I-icetlor, is 125.00. Payment must bo in cash, cashier's cheek. none order or cash. 7-0.7 Nolso Control It the construction site Is located adjacent to a residential area, the Contractor• shall t4%e all necessary steps to Ilmit the amount of noose emitting tram construction equipment used. In addition, vorking hours shall be restrict4d to betwoe!, the hours of 7t00 AM to 6:00 PM. T-0.6 Flow and Acceptance of Water Store, surface and possibly ground or other water May be ancolintered at var0ous times and locations during the work. Such waters may Interfere rtth the Contractor's operations and may cause damage to adjacent or downstream private and/or public property by flood'ng or lateral erosion it not properly zontrol led by the Contractor and the Contractor ackt,owledges that tits bid was prepared accordingly. The Contractor, by subn,ltting a bid, assumes all of sold risk. Hi!-11 •J to M a MI a �o KWI 7-3.1 7-5.I HB-10 e. The contractor Shell Inform the body evarding the contract of the Ioeel-lon of the records enumerated under suo41vIsIon (a), Including the street address, city and county, and shell, wItt:ln five working Jays, prnvldo a notice of a chango of location and address. f. In the event of noncompliance with the requirements o` this section, the .,ontractor she I have 10 day►. In which to comply subsequent to receipt of rItten notice specifying In what r4spects such contractor must comply with this section. Public Llab IIIty end PropertyEroperty Damage insurance Combined Single Limit Bodily In ur and/or Prcpgrty Damage Inc.iu_ ding Products Llabllityt 51,000,000 Combined single limit per occurence. (NOTEt If coverage to provided uoider a form which Includes a designated general aggregato Ilmlt, the aggregate Ilmlt Tust be no less than 51,000,000. for tho avont of aggregate coverage, the policy holder wlII endeavor to give the Clty nodes of any known depletion of I Imlts.) 3u ch po l Icy shot I provide coverage at least at broad as tt.ot prov 1 ded Ill the Standard Forst approved by the Notional Bureau of Casua Ity Underwriters together with such endorsements as are required to cover the risks Involved. The Contractor ,hall arrange for tno policies ?o be so cor.dltloned as to cover the performance of "Er,tra Wor k", shout d such work become nocessarye Prior to the cummencement of work under the contract, evidence of Insurance she I be furn ishod on a form acceptable to the Clty. In addition. the Contractor chalI furnish evidonco of a commlttntent by the Insuranev company to notlfy thin City of the expiration of cancellation of any of the Insurance policies required hereunder not less than 30 days beforo any chat+ge In coverage. expiration or cancel iatlon Is effective. The Contractor shal I also show proof of Workers' Compensation coverage or a valid certlflt:ate cf swlf-Insurance In an amount of not less then S100,000. bodliy Injury by accident, each aceldgnt, $100.000. bodily Injury by disease, each employee, 1250,01JO. bodI I y Injury by disease, policy limit. Permits and LIconses Except as otherwloe %peel fled In the Special Provlslons, the Contractor shall procure all permits and licenses, pay all charges and fees e.nd gtviv all notices necessary and Ineldunt to the due and IasttuI prosecution et the work. These permits and Ilconsas shell be obte Ined I n suf f I clent time to prevent de 1 Pys ?o the work. In the event that the agency has obtafnod permits, Ilcenses or other authorltatlOns eppl Icahle to the work, the ,,ntractor she) I corepIy with the provisions of said permits, IIce!!sas -ind other authurtratlans. The Contraetot shall nbtetn from the State *f California, the Industrial Safoty Permit required for the various construction Items. i I � III i -19 I r- 10 flop -I fisted Items to be Included In thw unit prices bid for varloiin Iteras listed on the proposal consist A , but are not IlmItod to, the following. ). Naterinp and ds,!atering 2. Backflll, comphotlon and disposal of surplus material 3. Maintaining public utlllty facllitles 4. Miscellaneous removals 5. Trench resiirfaning 6. General finishing and clean-up 7. Barricading, traffic ccAtrol, and temporary striping 8. Restoring private property Improvements 9. Patholing utilities 9-3.2.1 Progress Paynents The City she I. once In each month, cause an estimate In wrlting to be made by the Cnglneor of the total amount of work done and tho acceptable materials furnished and dot Ivered by the Contractor io the Job site and not sod as of the time of such astlmate and thf4 value thereof. The City she I retain money In Via amount of ten percent (10%) of the progress payment unless approval of Enylneer for greeter percent of r•uch estimated val uo of the work done Is obtained. The City she I I rota In mnnoy In the amount of f I fty percent (50%) of the U value of the raterlaIs so estimated to have been furnished ano delivered and unused, provided the materIs! a were fabricated spoclfIca Ily for the project. No payment wlII be made for standard stork Items that have net been Incorporate4 In the work. The City she I I month ly pay to the Contractor whl In performing the work, the progress poymant balance, after deducting therefrom al I previous payments and all suns to be kept or retained under the provisions of the contract. No estimate or payment shall be required to be made when In the Judgement of the Engineer, the work !s not procwyding In accordance with the provisions of the contractor Ossa In his Judgment the total value of the work done since the last estimate amounts to Inss than three hundred dollars (1300). O At the request and expense of the contractor, suustltutlon of socurI les for any monies withheld by the City to Insuro performance under the contract shall be permitted In accordanca w!th provisions c4 the Californla Goveroment Code, Section 4590. 9-3.2.2 Final Payment U The Engineer she 1, after comp Istlon of the contract, make a final ostimete of the amount of work done thereunder and the value of such work, and the City of Huntington Beach shell pay the antlre sum found to be due after deducting therefrom al I prevlous payments and al I amounts to be kept and all amounts to be retained under the previsions of the contract. All prlor partial estimates and payments shall be subject to correction In the final estimates and payment. The final payment she() not be duo and payable until after 4he expfratlon of thirty-five (35) days 'rom the date of recording a Notice of Completion. 4 H9- 15 1 J R It Is mutual IV agreed betwben the Parties to the contract that no cortlIIcatn gIvan or payments made under the contract, except the final certificate of final payment, shaI I be evidence of the performancw of the contract, either who I or In pert, against any a I a Im of the party o f 1-he t I r .st Parl, and no payment she 1 I be construed to be an acceptance of any defective work or unacceptable materials. Sec 10 Proposal Requirements 10-1 Examination of Plans,_ Standard Spec S cISI Provisions and fj S it& of Mork r� The hldder shell examine carefully the situ of the wnrk contemplated eiid the propcael, plans, spaclflcations anJ contract forms therefore. It will be assumed that the bidder has Investigated and Ir satlsffed as to the getiural and local conditions to be encountered; as to the character, qua I ity and quantities of the work to be performed and ell materials to boi furnished; as to the chara::tar of egii I pmont and fecilltles needed preliminary to and during the prosecutlon of the Mork; and as to tho requirements of these specifications. It Is mutually agreed that submisclon of a proposal shell be considered prima facla evidence that the bldder has made such examination. No verbal agreement of conversation wl+h any officer, O agent or employbe of the City either before or after the exaction of this contract she I' effect or modify any of the terms or obllgatlons herein contained. i 10-2 Proposal Forms All Proposals must be made upon blank forms to be obtained from the Q office of the Director of Public Works at the Civic Center, Huntington Beach, Callfnrnfa, The Odder shall submit his Proposal on the form f urn i shed him. Propose 1 s subml tied on forms other than the one Issued to the bldder will be disregarded. All Proposals oust give the prices proposed both is words and U numbers, of which words wlIl prove#) over numbers, and must be signed by the dfddor with his address and telephone nraber. If the Proposal Is made by an Individual, firm or partnership, name, post office address and telephone number must be shown. If made by a corporation, the Proposal must show the name of the state under the laws of wh1ch the corporation, and the names, title, and business addresses and telephone numbers of the President. Secretary and �y treasurer. 10-3 Proposal Bid Bond RII bids she II be presented under sealed cover and shall be accompanied by cash, a cashier's check, certified check, or bidder's bond made payable to the Clty of Huntingior. Beach, for an amount Q equal to at least ten percent (10$) of the amount of said bid, and no bid will be considered unless such cash, cashier's check, certified check, or bidder's bond Is unclosed therowlth. G H8-10 4I r i 7 ' 4 Q 1 r I IJ w 16-4 Withdrawal of Proposals Any bid may be rlthdrawn at any tlma, prior to the hour flxod In tf Hui Ins to Contractors for the opening of bids, provided that request In writing, executed oy the Bidder or his duly authorlie representative, for the withdrawal of such bid, is filed with it City Clerk. The withdrawal of a bid shall not prejudice the right c a Bidder to file a nsw bid. 10-5 Public Opening o,f. Proposals Proposals wl 1 I be opened and read pub l i c l y at the time and, n lac Indicated In the ilotice to Contractors. Bidders or their e.thorlic agents era Invited to be present. 10_-6 Rejection of Proposals Containing Alterations, Erasures c Irregularities Proposals a:sy be rejected If they show any alterations of forr additions not called for, cor.dltlonal or alternative bids, Incomplet bids, erasures, or Irrugularltles or env kind. Any refs -fakes an their subsequent corrections shal I be fnitlalod by tnu Bidder. Th right Is reserved to reject any or all Proposals. 10-7 Disqualification of Bidders More than one proposal from an Individual, a f'rm, a partnership. corporation, or an association under the same of different names wil not be conalderud. Reasonable ground for believing that any Sidde Is Interested In more ?hen one Proposal for the work contemplate wl11 cause the rejection of al I Propoaals In which such bidder I Interested. If there Is reason for believing that collusion exist among any or ell bidders, any or ell Proposals may be re;ectsc Proposals In which the prices obviously are unbalanced may b rejected. 10-b The provisions of Section 7-1,125, "Legal Actions Against th Department„, and Sectlor 7-1.165, „Damage by Storm, Flood, Tlda Wave, or Earthquake", of the State of Cal i fornla Star.dar Spcclflcatlons, January 1978 edition, are herewith incorporated b refererce Into these Speclsl Previsions. NB- 17 a 9 f OR G ATTACHMENT IAA i AGRICULTURAL SUITABILITY SOIL TEST REPORT { 1, iv {, 1 ,I I, ' R,s U Orange Office Lab No. 33002 May 11, 1990 :1 SOIL AND PLANT LADORATORY, INC. City of Huntington Beach 2000 Main Street Huntington ileatt, CA 92648 Attn; Jerry Loctunsn CENTM, PARR ENIDIMPPED AREA Attar.ted are reoulte of analyses carriO out on the Central Park handicapped area sol). samwpla collected at the time of our inspection and nampl ing on 5-1-90. It was noted that the surface soil is generally dark brain in color and loam Li texture. F�Zil AnalsrsL Soil reaction is slightly a►l.Wine with lime content medium and boron concentration well below the toxic range. Me salinity We) level is low and bas>d on the EAR value soluble sodium is Wisquately balanced by calcium and magensium. In atrmmaxy, the soil are& sampled is nan-saline and non-nodic in nature. Available nitrrxjpn is low with phosphorus optimum, And potassium fairly but not excessively high. Calcium and magnesium levels are also satisfactory for a soil of this texture. The phosphorus &nd potassium dz.ta in particular indicate that complete chenical fextilizers mA&r manure or similar organics had been applied in the peat to this soil area. If surface soil cmgxctian oeenrs during relandscaping operations, to the extent poeeible the surf soil should be crossripped or otheLwise tilled to a depea of 9-12". For the turf areau the following amendment should be tmiiormly broadr at: and thoroughly incorporated to a minimuis 4" depth by means of rototiller or equal. M T/1000 SOW-= 3 cu. yds. nitrogen stabilized organic amendment derived from redwood, fir or cedar sawdust 8 lbs. ammonium sulfate If trees and shrubs are to be planted, the following soil mix should be used for backfill aroLT,d the root balls. j Po. 80, 0568, Orange, cahlori+a 92813•5560 ( (1141 :R-5777 FAX )114) )02.0515 a0 so. 13x &nla vain. cawainia 9soszaim ) (4as) n74330 FAX )408) t213125 PO. Box 1546 Bellevue. wa2hinglon 98009.1648 1)206) 746.065 N . -• tr, pax: Erg, ly a SOIL AND PLANT LA130RATORYPINC. Page 2 City of Huntington Beach tiay lit 1990 i parts bf volume on -site soft 4 parts .'-y volume nitrccyen stabilized orgar►ic amerdment 1 tb. ammonium sulfate per cubic yard of mix 2 lix. iron sulfate per cubic yard of mix. Zhe above =te:ial should ba thoroughly bl"a.d prior to We for backfill purposes. Also the iron suf atA rhould not contact cement surface sinoe sever: staining cowld occur. Sinoe both phosphorus and potassium ata optimum to high opt1=0 a nitrorgenr-rely maintananoe fertili.^er pxogram can be employed for at least thn first year. Beginning apirozimately 30 days after planting, ammonium sulfate should be applied at the rate of 5 lbe. per 1000 sq. fie. on a monthly basis. W w turf has became wa..11 estalalishel, the frequency of fertilizer applications can be decreased. Please call if y w have omy gmstions. EMU IMULUER FFshe EM EM a 0 l S i 1 ,y P.O. Box 0568, Orange, CaUmnia 92613.6641(714) 282-0777 and TPut 01ROW0buftato� ! PO. IB" 14 Ula Clara, CalG-urda t15W2. %W(?A6) 721-03:I FAX (40a) 727•:125 P0: Sac 16456 Bsllevuo, Washington VK%Ig�,�1(Md) 7464M City of HUntington Beach SM, Fl1EiT7L' XTY AND AGRIWLSURAL S7M62TAW v a vftian 2000 Main Street !iflJi) Lab No. 33007 iwtington beach, Ca 92648 May 80 1990 Newland Barn coil stele taken 5-1-90 Aictn: Jerry Uckman •_.__Aat=ation =tract VaIUOEL _ San Half ----Paxta per Million Dry Soil_ I Co Mg Na K B I FAR GM pie sat. I NCO-H N84-N MI-p K- Ca 1 10 IECO Me/1 Me/1 Me/1 Melt ppm I LIME 21 20 31 7 42 430 6240 347 7.8 2.2 12.7 3.2 7.5 1.2 0.02 2.7 MW MY Saturati►,n %-approx. field me'.sture capacity. SmUnity .. E'►:e (macho /cm at 25 degrees CA,, MR - Sodium Ademption Ratio. (1) Location 1 , t I . = is California Regional Water Quality ConLrul Board San..a Ana Region ORDER NO. 87��14 I NPDRS W0. CA 0106208 Haste Discharge Requirements for City of Huntington Beach Construction Dewoterir,g Orange County 0 U 0 J Z) The California Regional Water Quality Conti-ol Board, Santa Ana }legion (hereinafter Board), finds that: 1. on December 30, 1986, The City of Huntington Beach !here- inafter discharger), submitted a complete application, No. CA 0206208, for finste discharge requirements and a permit to discharge wastes under the Natinnal Pollutant Discharge Elimination System. 2. The discharger currently discharges wastes associated with construction dewatering projects into waters of the United States within various locations in the City of Hun' 'inttan Beach. Discharges from these locations are tributary to the Santa Ana River, Reach 1, the Polso Chiea Wetlands, and Huntington Harbour, which are ulti- mately tributary to the Pacific Ocean. The areas where discharges may occur are shown on Attachment A, which As hereby made a hart of this order. 3. These discharges are presently regulated under Waste discharge requirements contained in Order No. 81-167. Thin order is being revised to update its requirements. 4. The intermittent beneficial uses of the Santa Ann River, Reach 11 include: As Non -contact water recreation, and L. Wildlife'habitat. 6. the beneficial, uses of the Bolsa Chica Wetlands include: a. Non -contact water recreation, b. Ocean commercial and nonfrephwatr_r sportfishmg, • c. Preservation of areas of special biological significance, d. Wildlife habitat, e. Preservation of rare and endangered species, I f. Marine habitat, and X. Shellfish harvesti::d . I ', L_ j l L)F. e r Ho, WI-) Putts• Ci t;,• Iltrnt.ir:ttton ilr.ncl. ,I of r1%mt iilj:t (Ill llnr'trrlue include: + P / \!`,titiut1, j + 1�an-ront,t,ct ur~tor rcr.rcat.inn, �_•��,, W'� el, Or,0.11-1 C.M.I~Ic:1-01r11 tend �(ll i Cv hwbitnt., .3nc1 `?t_tiria 'r:.-.bit i . 1'lle of Lll t :tc� i f ?.cr oc enn ilIC lrlcie . , I l,ir.trirkI tii;r-v.4r,: ►iupp.15', � •�*�'r; l�. M%vi,•n pion, r , t1r.:.t;t oontcact ,- vcrer%1.i.on,, d . 11mi- c_ ontar,t_ water rt!r, rc!rsti on, F ' Ccona c:cm.mrcinl and nonfrenhWIte!r r:port.i'ir+hing, f , N. rine hnhite.t:, and !±, ;ihrllfi -h htz.rvcacing '�� 11, A 1, r Quality Cot,trnl Plan WELD nclontvd by the Board can HLIV 13, 1983. The Plrin contninn Water dun-lity objectiv:!.-i and 1)onu1'ici::l uora u; on tern in t:ht:• SnrrLn Ann RL-gi on. J. Thr, r `quirt.t etztr. in thisu order nre nLcer.crsnry to .implement Ulu Writer nr,ul.it•3, Control flan, i. 0.' y IJ 10. The issuance of tlkesu hunts dincharge requirecentD iD i exQralrt from, the provinionD of the Colifornin &nvironmen- till Quality Act %Pul•,lic Reuourceo Code, Section 21100 et neq,) in accurdence ;:ith Section 1 ;3119 of the Califurnin �# Water .;odc . 1x 11. Effluant liraltutions, national standards of performanrn-., arid. toxic pretreatment Effluent atandn_•cln entabliehed purntmnt to St_ction 20E(b), 301, 303(d), 304, and 307 of the Federal hater Pollution Control Aut-, an.i amendments thereto, ar•.: upplicabie to the diecharrge., A . The hoard hnr. ne::ified the dinc.-L rtier and other interes- ted agem•icr and rjnreano of its .Intent to prescribe waste � rliucharce requirements Tv.- t;1c dincharge. 13. The Poard, in a public meetint„ heard and connAdered all i coruuentr pertcininnt to the direhnrge. i 1 0 Order No. 07-114 - continued City of Huntington Rencl� page 3 IT IS HRRRBY ORDERED that the discharger, in order i.o meet the provisiona contained in Divinion 7 or the California Wager Code and regulations adopted thereunder, and the provisions cf the Federn). Wnter Pollution Control Act and regulations and gu.uelroes adopter_ thereunder, shall comply with the followings: A. I)Incharge Specificmt.ions 1. The maximum daily discharge for any single project shall not exceed 100,000 gullonu (360 mv). 2. a. The discharge of Wastes in excess of the follovina limits is prohibited: 30-Day Average Maximum Constituent Concentration Concentration 'fatal Sulfides 1.0 mg/1 1.5 rg/1 Suspended Solids 50.0 11 75.0 Mena emission rates have not been established for these diaehartles, since the flow for individual projects cannot be predicted at this time. b. The discharge of downtering wastes to waters which could reach Anaheim, Sunset, or Bolen Bays; or to tidal prisms of natural or man-made flood control ' channels in excess of the following additional limits is prohibited: 30-Day Average Maximum Cnnatituent Concentration Concentration Biochemical Oxygen 30.0 mg/1 45.0 mg/l Demand Settleable Solids 0.1 ml/l 0.2 ml/l Oil and Oreaae -- tione visible s_..lorine 'Residuals • •- 0.1 rag/1 3. The 30-day.average concentration nhall be the arithmetic average of all the values of daily concentrations: calcu- lated using the re3ults of anmlyxes of all samples collected during any 30 conaecutive calendar day period. If fewer than 4 samples are collected and analyzed during any 30 %= secutive calendar day period, compliance with the 30-day average discharge rate limitation shall be determined from the lant .t consecutive samples. 'If chlorination is utilized for treatment of wastPo �J Order No. 87-114 continued Page 4 C'ity of Huntington Beach 4. N-ither tLe treatment nor the disposal of Naster shall cause a nuisance or pollution as defined in the California Water Code. S. The dla..harae of any sub itanee in concentrations toxic to human, animal, plant, or aquatic life in prohibited. B. Receiving Water limitations 1. The discharge shall not cause the dissolved oxygen con- ccntration in the receiving water to be depressed below 5.0 mg/1. When ambient concentrations are less than 5.;; tag/l, the discharge shall not nauBe a further depression. 2. The discharge shall not cause'the receiving eaters to j have nn objectionable odor. 3. The discharge shall not cause a violation of any applic- able water quality utnndard for receiving Natera adopted by the Board or :.he State Water Resources Control Board, as required by the Federal Water Pollution Control Act and regulations adopted thereunder. If more stringent applicable water quality standardo are promulgated or approved pursuant to Section 303 of the Federal Water Pollution Control Act, or amendments thereto, the Board Will revise end modify this order in accordance with such more stringent standards. .;. Previsions 1. The dincharger 6hall comply with Monitoring and Reporting Program No. 87 -1 14 . 2. This order includes the enclosed "Standard Provirions ,and Reporting Requirements" with the r.xception c.:' tF following items; A.21 and 24-26; B.4, 6, and 7, C.2, 5, 7, and 8.b; D.9-11; And E.1-5, and 7. 3. Not-lna8 than 45 days prior to coymencement of a project (i.e., as noon as a firm pro,jco:. haB been devel+.�ed, but: not, later than the bid announcement), the discharger shall submit a report: to the Board for approval by the Executive Officer. A copy of thr, report shall also be transmitted to: Resional Managei D+partment of Fish and Game, Region 5 245 11. Broadway t Long Beach, CA 9o802 Attention: Rnvironme:ntal Services Branch L J I 14,14 order No. 87-1)4 - continued Page 5 City of Huntington Bnnch IH The report shall consist of the following! a. A plot plan showing the loontion of the proposed project and point(s) of 4sachnrge to surface waters; and b. A construction time. schedule, including the anti•- eipated cormmeneement dates and ccirpletion date of clewnterina activities. 0 %) 10 !V a 0 The discharger shall submit a report containing the following items to the Bcard for review and approval by the URcutive Officer ten days prior to ti-e c:ommcneement of the project: a. A description of facilities proposed to control the leve3 of pollutants (including, bu,_ not limited to, nuopended solids aril total sulfides) in the wastes, or or. explanation Why the use of such fanil:tien are not anticipated. b. A plan specifying methods proposed to control ero- sion due to general construction activities of the project. 5. The discharger shalt promptly report, to the Boaro any proposed change in the Character, location, or method - of disposal of the discharge, ur any proposed change of oirnership of the facility. 6. This order expires on October 1, 1992, and the discharger mue' file a report of Waste discharge in accordance with Title 23, California Administrative Code, not ltar than 130 days in advance of such date us application for isElu-- ance of new araate discharge requirements. 7. This order shad serve as a National Pollutant Discharge Elimination System permit pursuant to Section 402 of the Federal Water polluting Control Act or ame.ndnents thereto and shall become eff=dive 10 days after the date of its adoption provided the Regional Administrator of the Envi- ronmental Protection Agency has no objection. If the Regional Administrator objects to its issuance, the per- mit shall not become effective until ouch objection is withdrawn. a Order No. 87-114 - continued rage 6 t City of Huntington Beeach I I, James R. Bennett, Executive Officer, do hereby certify the for►. -going is a fell, true, and norrect copy o9' an order adopted by thu Califorria Reilional Wnter Quality Control. Donrd, Santa Ana Reoion, or October 91 19A7. Mfi9 R. H N N F T T r' ecutive Office- I 1 C C, is i a i i� �J I i --Jv J- 0 r- CALIFORNIA REGIOPA1. WATER QUALITY CONTROL LORD SANTA ANA kEGION iOctober 9, 1987 STAN' Rb PROVISIONS AND REPORTING REQUIRENENTa A. General Provisio, +) ! 1. Tht requireoents prescribed herein do not authorize the commission of any act causing injury to the property of ano0er, nor protect the discharger from him liabilities under federal, state, or local lays, nor Guarantee the discharger s capacity right in the receiving waters. Z. The diatharges trust comply with all of the terms, reguirtments and con- ditions o:' this order. Any violation if this order constitutes a viola- tidn of the Clear. linter Act, its regulationa and the California inter Code, and in grounds for enforcement action, termination of the order, revocation and reissuance of the order, denial of an application for reissuance of the order; ov a combination thereof. 3. The provisions of this order are severable, and if any provision of this order, or ;,the application of any provielop of. this order, or the application of aey provisions of this order to nay circumstance, is held iavalid, _lie application of such provision to other circumstances, and the remainder of this order shall not 3e affected thereby. 4. This order may be modified, revoktd and reissued, or terminated for cause. The filing of a request by the discharger for modification, revocation and reissuance, or termination of this order or a notifica- tion of plc ned chandeo or anticipated noncompliance does not stay any permit condition. i S. This order any be modified prior to the expiration date to include effluent limitations for toxic constituents determined to be present in significant amounts in the discharge through a more comprehensive moni- toring program included as part of this order. 6. This order does not convey any property rights of any sort, or any exclusive privi.egt. 7. In the .eveut•of any change in.. control or ownership of land or waste discharge facility presently owned or controlled b) the discharger, the discharger shall notify the succeeding owner or operator of the existence of this order by letter, a copy of vhich shall be forwardeA to this Board. G� I C? ! -7- .ry 0. This order is not transferable to any person except attar notice to the Regional Board. The Regional board clay require nodificsition or revoca— tion and reissuance of this order to change the name of the discharger and incorporate ouch other requirements an may be necessary under the Clean Water Act. 9. The diocharger ahaLl comply with effluent standardo or prohibitions established under section 307(a) of the Clean Uster Act for toxic pollu— tants within the time provided in the reaulationc that establish these standards or prohibitions, even if �hia order lies tot yet been modified to incorporate the regt 1rc-nerst . 10. Violation of any of the provisiono of the IMES program or of any of the I provisiono of this order may subject the violator tc, any of the penalties described herein; or any combination thereof, at the discre— tion of the prosecuting authority; except that only one kind' of penalty nay be applied for each kind of. violation. 11. The Clean Hater Act (CWA) provides that any person who violates a provi— sion Luplementing sections 301, 302, 306, 307, or 308 of the CHA is cub— ject to a civil penalty not to exceed $100000 per day of much violation. Any person vho willfully or negligently violates provisions implementing these aections of the CwA is subject to a Trine of not leas than $2500 nor more than $25,000 per day of violation, or by imprisonment for nct more then 1 year, or both. —� 12. The California Water Code prDvideE that any person who viola -co a waste discharge requirement or a provision of the California Wr er Code in oubject to civil penalties of up to $5,000 per day, $101Cr.r per day, or $23,000 per day of violation, or when the violation invol.�;xs the discharge of pollutants, is subject to civil penalties of up to $10 per gallon per day, or $20 per gallon per day of violation; or some cen— J bination thereof, depending on the violation, or upon the combination of vioiatinna. 0. It shall tot be a defense for a discharger in an enforceneit action that it anuld have been necessary to halt or reduce the permitted activity in order to mainttin compliance with the conditions of this order. 14. The Regional board, EPA, and other authorised representatives shall be allowed: (a) Entry upon premises where a regulated facility or activity is J lceated or conducted, or where reco -Jo are kept under the conditions i of thin order; J J (b) Access to copy any recorda that are kept under th, conditiona of this rrder; W To inspect any facility, equipment (including so-aitoring and control equipment), practices, or operation" regulsatad or required under this order; end (d) To photograph, ismple and ronitor for the purpose of assuring compliance with this order, or as other'vise authorized by the Clean hater Act. i5. The discharger shall take all reasonable st-_pe to minimize or prevent ;any diocharte that has a reasonable likelihood of adversely affecting hunin health or the environment. lc. The discharger shall take all reasonable steps to oininise Any adverse impact to receiving wateru resulting from noncompliance with any effluent Lim:tationo specified in this order, jreluding ouch accelerated or addi- tional monitoring as necessary to determine the nature and im ract of the noncomplying discharge. 17. The discharger shall, at all times, properly operate and maintain all facilities and systems of treatment and control (and'related appurtenan- eta) which are installed or used by the discharger to achieve compliance with this order. Proper operation and maintenance included etfective performance, adequate funding, adequate staffing and training, And ade- quate laboratory and proceas controls, including spl.ropriate qualit•r nautirauce pro:edures. The discharger shall keep in a state of readiness all systems neceasary, at any time, to achieve compliance with the waste discharge requkre-- ments. All systems, both those in service and reserve, shall b! irspected and aalntained on a regular basis. All reserve units shall bn regularly tested by'placing into service. Records shall be kept of th-: tests and made available to the regulatory agencies. 18. Bypass (the intentional diversion of waste streams from any portion of ,1 treatment facility) iA prohibited. The Regional Board may ts`-ce enforce - scent action against the discharger for bypass unless: (a) bypass was unavoidable to prevent loss of life, personal injury, n: devere.,properCy dam ge. (Severe property damage means substantia physical damage to property. ramage to the treatment fe•:ilities that causes theca to become inoperalle, or substantial and permanent loos of natural resources that cn:i reasonably be expected to o:cur ir. the absence of a bypass. Severe property damage does not mean eco- nomic lora causer: by delnys in production.); -9• J t�i U (b) There were no feasible alternatives to bypant, ouch as the use of auxiliary treatment facilities, retention of untreated waste, or etaintetiance during normal periods of equipment down tiace. This con- dition is not satisfied if adequate back-up equipment should hava been installeu its the exercise of ruauouable engineering judgment to prevent a bypass that could occur during tonal roeriode of equip- tatnt down time or preventive maintenance; and (c) The discharger oubmittcd a notice at least ten days to advance of the need for a bypass to the appropriate Regional board. The discharger may allow a bypass to occur that dose not cause effluent limitatirns to be excee►ied, but only if it iu for essential maintenntcce © to assure efficient operation. In such a cane, the above bypass con- ditions are not applicable. The discharges shall promptly notify the Reglonbl Board and the EPA within 24 hours of each ouch bypass. 19. "Upset" meant an exceptional iucident in which thtre is unintentional and temporary noncompliance with permit effluent limitations because of ?� factors beyond the reesonable control of the dischaiger. An upset does not include, noncompliance to the extent t.auard by operational error, iLopreperly designed treatment facilities, inadequiste treatment flcili- ties, lack of preventive maintenance, or careless or improper action. A discharger that vishe` to establish the afr"irmative defense of an upset in an action brought for noncompliance shall demonstrata. through pro- perly signed, contemporaneous operating logo, or other relevant e:vidtnre Chet: s (a) an upeeL occurred and that the discharger can identify the cause(a) of the upset; 0 (b) the permitted incility was tieing properly operated at the time of the upset; W 14 L_ (c) the discharger subtaitted notice of rice upset an required in General Reporting Provision U.8; (d) the discharger complied with any remedial measures required under Central Provision A.15. Ho determination made before an action for noncompliance, such as during administrative review of claims that noncumpliance vas caused by an upset, is final administrative action subject to judicir.l review. 'In any enforcement prnceeding, the discharger seeking to establish the occurrence of an upset 1►.:e the burden of proof. -1' J -1 20. !safeguard to electric power failure: a. The discharger shall maintain in ,good working order a sufficient alternate power vource for operating the wastewater t:eatwcnt and disposal facilities. All equipment shall be located to minimiLt failure due to noisture, liquid spray, flooding, and other physical phenomena. The alternate, power source shall be desitInzd to permit inspection and maintenance and shall have provision for periodic testing b. if such alternate power source is not its existence, the discharger shall halt, reduce, other otherwise control all discharges upon the reduction. lobs, or failure of the primary source of paver. C I • C� f Vi i 0 M. ► v� i I �i -11 L_ J A 21. The discharger's wastewater treatment plant shall be supervised and operated by persona possessing certificates of appropriate grade pur- 04 suant to Chapter 3, Sv`�chaptcer 14, Title 23, California Administrative Code. 22. Solids, sludgea, filter backwash, and otter pollutants removed in the treatment or control of wastewater shall be disposed cf in the canner approved by the Executive Officer of the Regional Board. r1 23. The discharge of any radiological, chemical, or biological warfare agent or hiRh level radiological waste it prohibited. Fb ±rc 0 0) r] %4 0 L. 24. The following vastte shall not be introduced into the treatment works: a. Yvatea which create a fare or explosion t,xtard in the treatment ego rko ; b. Wastes vhicF will cause torrosive structural damage to treatment vorks, but, in no choe, wastes with a pR lower than 5.0 unleso the wo•ka are deaf gned to accorrssod:9te ouch wootea; c. Solid or viscous wastes in amounts which would caus► obstruction to the flow in sewers or otherwise interfere with the proper operation of the treatment ^jorka; or d. Wastes at a floe rate and/or pollutant discharge rate which is excessive over rerativaly short time periods so that there is a treatment proneau upset gild oubsequent loos of treatment efficiency. 25. The discharger rhall ensure compliaince with any existiag or future pretreatment standard promulgated by EPA under Section 307 of. the Federal Slater Pollution Control Act or amendments thereto for any discharge to the municipal system. 26. The discharger shall require et:h user to submit periodic notice (over i»tervals not to exceed nine months) of progress toward compliance with applicable toxic and pretreatment standards developed pursuant to the Federal Hater Pollution Control Act or amendments thereto. The discharger shall forward a copy of such notice to the >Board and the Regional Administrator. B. Provisions for Monitoring 1. Water quality analyses shall be performed in accordance with the moat recent edition of "Environmental Protection Agency Regulations on Teat 'Procedures for the Analysis of Pollutants" promulgated by EPA (40 CFR 136). In addition, the Board and/or EPA, at their discretion, may spe- cify test meathode which are mor,r sensitive than those specified in 40 CRF 136. 1 -12 -1 J -19 Z. Chemical, bacteriological, and bioassay enalyses ohall be conducted at a laboratory certified for such analysts by the State Department of Health Services or EPA. 3. Records of ennito-ing information shall include% a. The date, c:act place, end time of anmpling or meacurec+ents; b. The individual(s) vho performed the sampling or measurcuents; c. The date(a) analyses were performed; d. The individual(a) who perforjed the analyses; e. The analytical techniques or methods used; and f� T'he results of iuch analyses. 4. The discharger shall have, and implement, an acceptable written quality assurance (QA) plan for laboratory analyses. An annual report shall be submitted by January 30 of each year which sumeari,tes the QA activities :or the previous year. Duplicate chemical analyses must be.. conducted on d minimum of ten percent (10t) of the samples, or at least one sample per month, rihichever is greater. A similar frequency shall be main— tained for analyzing spiked samples. When req-.nested by tht Board or EPA, the discharger will participate in the WDES disc' •.ge monitoring report QA performancrz •study. The permit - tee must '.iive , aucceas rate equal to or greeter than 80%. S. 5o.mple coutainers, preservations, ani hold ti=es shall conform vith those ir. 40 CFR ;'art 136. 6. Influent samples shall be taken at each point of inflow to the wmotevetter treatment plant, upstream of any in -plant return flows, and ahall be re?resentative of the influent to the treatment plant. 7. Effluent samples shall be taken dovnatream of the last addition. of .+ante to the treatment or discharge works where a representative sample may be obtained prior to :sizing with the receiving ware s. B. All monitoring inatrumtnta and devices used by the discharger to fulfill the prescribed monitoring program shall be properly maintained and calibrated as necessary to ensure their continued accuracy. 9. The flow measurement syatem shall be calibrated at leas: once per year o: more frequently, to ensure continued accuracy. 1:- C� u a C� E. 10. The Ciean WAter Act provides that any person who :alsif+es, taupers with, or knowingly renders inaccurate any monitoring davica or nethod required to be maintained under this rarmit ohsll, upon conviction, be i punished by a fine of not more than $10,00u per violation, or by impri- �'g ooaa&nt for not more than six months per violation, or by both, i i C. haporting Provisions for Monitoring 1. For every item of asonitoting data where the requirements are not wet, tht discharger shall aubmir a stateuent of the actions indartaken or propoesd which will bring the discharge into full compliance with raquirements at the earliest tieae, and ahsll submit such information, in writing, within two weeks of becoming aware of moncompliauce. 2. By January 30 of each year, the discharger shall submit &n annual report f� to the Hoare'.. The report shall contain bath tubul,nr and graphical aua- 1 mariae of ''ea monitoring data obtained during the previauo year. In addition, thL discharger 4hall distaes the compliance record and the I corrective actions taken or planned which may bo needed to bring the diaehn:ge into full compliance with the waste diocherge require►aenti. 3. The discharger shall retain records of all monitoring information, including all :ampling -ind analytical results, all monitoring equipment calibration and maintenance records, all original strip eharta from con- tinuous conitoring devices, all data tesed to complete the application for this order, and copies of all reports required by this order. The sampling and analytical records shall include the tract '•o-ation, date, and time of sampling; the analyar'o name, and the analytical techniques uaed. Such records oball be retained fnr a period of at least thrta years from the We of the sample, report, or application. Thib period of retention shall be extended during the course of any unresolved litigation xagarding this discharge or by the rtque:.c of the Board. 4. The 4ischct er shall file with the Board technical re arts or, self- 8 P j monitoring work performed according tv the detaiied specifications con- tained in any Monitoring and Reportiap Program or so directed by the i Executive officer. ± C) S. Discharge monitoring data shall be submitted1 �o the extent possible on ` preprinted Discharge Monitoring Report forms to be supplied by the Board and :PA. Other specific reporting formats which -any include magrttic tape, punched cards or direct computer entry may be prescribed &t a later date. Unless otherwise specified, discharge flows shall be m reported in ter% of the 30-day average and the daily maximum discharge flovs. -The resuite of ell monitoring required by this order shall be reported to the Beard, and shall be submitted in ouch a format 06 tD allow direct comparison with the limitations and requirements of this order. V -I4- L� u. Thv rcoulta of zn,y antilysio o.`- shriplea tsiken rmre frequently than roquircd nt the loeationa sptcificd in ciiz i:onitoring Aral I►c;,ortirtii; 11ro2ram ohrll he reported La the bojaVd. 7. Tht diochrrycr shall submit to ths� hoard, by yanuut'y 0 of each yctl., an i unn!icl aui:.mary of thy. ql:antitius of all cht,-niccls listed by both trade and chemical n2meo which are uccd for cooling, acd/or boiler ir,ntcr t;eat- cleat and uhich Arc diech:arg,ed. b. The dischargs!r shall unil a copy of each sanitoring :cporL on the approprirte fo:m to ut supplied by the Board and nuy uthcr rep, i rcqui.red by thin order to: i j +.t. Calf foriiin Regional later quality Control Board Santa Ann Region 6809 Indiana Avenue, Suir.e 200 ( Riv_ratde, C:1 92`06-429R b. A copy of such mooitoring report for those discharjc s dead;n,ntr_d na a mnjor diecha.ae nhall be milod to: i j Regional Ildriniotratur rn%4ronnc!nta1 Protection Agency Region 9, Attention; C-A••GHR (W-3-1) 215 rrercont Street j Sett lrrenrieco, CA 94.105 D. General RFEortit%jrowL ona 1. All application,, reports, or infornation submitted to the Regional 1'iui•r0 shall be signed avid certifies in accovdnnce with 40 CFR 122.22. 2. The discharger shall s;ibmit to the 1loard on :sr before each compliance report` elate, a report detailing his coupliance or noncompliance with the specific achedulc: date, and task, 3. If tsoncompli.•_nce is bring reported, the reasur,b for such noncomplirince uhall be stated plus an estimate of cht date when the discharger will be in compliance. Ti.e discharger shall notify the Board bt letter When couplinncc with the time schedule lint been achieved. 4. The discharger, shall iurnich, ion thin n r-!ar:onablc time, an;, information the licgictial t',c,ard or EPA tiny inquest to determine uViether cause cTists for nadifying, revoking and reissuing, or terninati.ng this order. The diuc-hGrger shall also furnish to the Regiotirl iionrd, upon requeat, copieu of records required to be kept by thin ordc-. I I�l 7. `I b. i i J I er ahrll file with the Board a report. of wisete &Pchergi i ye btfore inking any unterial change or propoetd change r, location, or volume of the diachorae. er shall give advance notice tv the R-_gionnI Board an me of any planned phyair.al niterationo or additions to the ity. The discharger dhRll give advance notice to the Regional Board of ar planned changes in the permitttd facility or P.:tivity that Lsny rhaul in noncompliance with theme waste discharge requirements. lionct►mplinnce Reporting (a) 1'he discharger shall report any noncompliat►,e that may endanger health or the envirngment. Any information tltall be provided to Executive Officer (714-782-4130) and the Atfice of Em:rgtacp Service3 (1-000-052-7550), tf appropriate, Leo soon as the divch 1'`*"; beco::er- aware of the circumstances,. A written report: shall be s flitted c,itliin r` days and shall contain a description of the non- conpliant:e and ito cctune; the per.ioil of noncompliance, includin exact dckea and tiaea anal, :f '.he noncompliance hoo not been � corrected, thi. enticipated time I,_ :.e expected 4:o continjr.; mad atepa taken or planned to reduce, elia!"nate, and prevent reoc- currence of the .'oncompliarce. (b) The foliotring ohall be inOuded as information that nuat be reps within 24, hours under this paragraph: i. Auy uitan;:zciprtted bjpacn Ghat c:c.eedn any effluent limitation lido order. I ii. Any upset thnt: r.ace-edt, nny effluent limitation in thin order. iii. Ai, violation of a inn imum daily diacharge litsitation for an th(; pollutntity litcted in thin (c) The R. iorinl liu.jvtl may tai.vc the above-requlred vritten rtport of arse-L;-cane basis. Tae c1iuc)sargc� shall file: n written report with t'e Board within ninf (90) clayo after the c-%vernre dry -weather waste flow for any'month egnh or e:.c-.eda 75 I,ercer.:- nE the Benign capacity of hia waste treatment and/or facil.itien. The dinchurger'a aenior adainiatrative officer chilli ,it;n a lcttnr iihich tranonito tlx&L report and testifies that tbr. policy rz�iking body is ndequat�ely informed about It. The rep ahal! include: -1G- r; J I er ahrll file with the Board a report. of wisete &Pchergi i ye btfore inking any unterial change or propoetd change r, location, or volume of the diachorae. er shall give advance notice tv the R-_gionnI Board an me of any planned phyair.al niterationo or additions to the ity. The discharger dhRll give advance notice to the Regional Board of ar planned changes in the permitttd facility or P.:tivity that Lsny rhaul in noncompliance with theme waste discharge requirements. lionct►mplinnce Reporting (a) 1'he discharger shall report any noncompliat►,e that may endanger health or the envirngment. Any information tltall be provided to Executive Officer (714-782-4130) and the Atfice of Em:rgtacp Service3 (1-000-052-7550), tf appropriate, Leo soon as the divch 1'`*"; beco::er- aware of the circumstances,. A written report: shall be s flitted c,itliin r` days and shall contain a description of the non- conpliant:e and ito cctune; the per.ioil of noncompliance, includin exact dckea and tiaea anal, :f '.he noncompliance hoo not been � corrected, thi. enticipated time I,_ :.e expected 4:o continjr.; mad atepa taken or planned to reduce, elia!"nate, and prevent reoc- currence of the .'oncompliarce. (b) The foliotring ohall be inOuded as information that nuat be reps within 24, hours under this paragraph: i. Auy uitan;:zciprtted bjpacn Ghat c:c.eedn any effluent limitation lido order. I ii. Any upset thnt: r.ace-edt, nny effluent limitation in thin order. iii. Ai, violation of a inn imum daily diacharge litsitation for an th(; pollutntity litcted in thin (c) The R. iorinl liu.jvtl may tai.vc the above-requlred vritten rtport of arse-L;-cane basis. Tae c1iuc)sargc� shall file: n written report with t'e Board within ninf (90) clayo after the c-%vernre dry -weather waste flow for any'month egnh or e:.c-.eda 75 I,ercer.:- nE the Benign capacity of hia waste treatment and/or facil.itien. The dinchurger'a aenior adainiatrative officer chilli ,it;n a lcttnr iihich tranonito tlx&L report and testifies that tbr. policy rz�iking body is ndequat�ely informed about It. The rep ahal! include: -1G- r; r- 0 L 10. U. a. AverAae daily flow for the nonth, the date on whicS the instan- taneous peak flow occurred, the rate of that pebk t&ow, and the total flow for the day. b. The discharger'a beat estimate of whe a zhe average daily dry -weather flow rate will equal or e:rceed the design capacity of his facili- ties. C. The discharger', intended schedule for studies, design, and other steps needeO to provide additional capacity for this waste treatment and/or disposal facilities before the waste flow rate equals the capacity of present unit:$. (Reference: Sections 1326D, 13267(b), 'and 13268, CalUornia Water Code.) The discharger shall pro•*ride adequate notice to the Regional Board uf: a. Any new introduction of pollutants into the POTN from an indirect discharger that would be subject to Sections 301 or 306 of the Clean Water Act if it were directly discharging those pollutants. b. Any cubstsntial change in the volume or character of pollutantr. being introducted into that PON by a source introducing pollutants into the Peril at the. time of issuance of this order. Adequate notice shall include info rmucion on the quality and questity of effluent introduced into the POTW as cell as any anticipated impact of the change on the qurntity or quality of effluent to be d;icharged from the POW. The discharger shall file with the Board within ninety (90) days after the effective date of this order a technical report on his preventive (failsafe) and contingency (cleanup) plans for controlling accidental discharges and for wistimizing the effect of such eventa. The technical report should: a. Identify the possible sources of accidental lose, untreated vacte brpats, and contaminated drainage. Loading ao:d atorak. ,e areas, power outage, waste treatment outage, and failure .if process equipment, ranks, and pipes should be considered. b. Evaluate the effectiveness of present facilitieo rind procedures and cts.te vhen they become operational. Describe facilities and proceduren needed for effective preventive and contingency plane. c. Prediet the effectiveness of the proposed facilitiea an4 procedures and provide an implementation sebedule containing fnterie• and final dates when they will be conalructed, implemented, 'or operational. (Reference: Sections 1326700 and 13268, California Watcr Code.) -17- I _J 7 i l 12. All existing manufacturing, comatrcial, training, and aLlvicult dischargers must notify the Regional Board re soon as they knnw or rasson to b4lieve: i a. t1lat any Activity has occurred or will occur that would result is discharge of acy toxic poliutant that is not limited in this or y if that discharge Will excand the highest of the folly I'votificetion levels:" (i) One hundred micrograms per liter (100 us (ii) Two hundred Micrograms per liter (200 ugh) for ecrol2in �. acrylonitrile; five hundred microgramo per liter (500 ug/'i) 2,4-dinitrophenul and 2-mathy1-4,6-dinitrophenol; Bend milligram per liter (1 wg/1) for entire. (iii) Five.(5) times the maximum concentration value reported that pollutant in the permit application; (iv) :he level established by the Regional Board in accordance 40 CYR 122.44(f). b. that they have begun or expect to be,;in to use or manufacture a, intermediate or final product or byproduct any toxic pollutant i vas not reported in the permit application. 13. Except for data determined to be confidential under Section 308 of Federal Watev Pollution Control Act, all reports prepared in accord; with terms of this order shall be available for public inspection at offices of the Regional Water Quality Control Sosrd and :he Regi( Administrator of "A. As required by the Federal Water Pollut Control Act, effluent data shall not be considered confident; Knowingly making any false statements on any such report Nay result the imposition of criminal penaltieo as providea for in Section 30S the Act and Section 13387 of the California Water Code. 14. The CWA provides that any person echo knowingly rrkes a:iy false statcmc r4presentation, or certification in any record or other docusrant r Gy mitted or required to be maintained under this permit, including ac toring reports or reports of co©plLance or noncomp..iance shall, t conviction, be puuish•d by a fine of not more, then $10,000 violation, or by impriannment for not more than 6 months per violas: r or by both. I ra Z. DefinitiOna 1. The daily mass emission rate is obtained from the following calcu Lion for any calendar day: N Daily rinse enisalo:t rate (lbw/Jay) - 8.34N 1 �i Ci 1 1 It Daily mate emission rate (k�/dny) 10 Ain N 111 Qi Ci 41 is which N it the numbtr of samples analyted it any calendar d, Qi and Ci are the flow rate (HOD) and the constituent coccentrat: (tog/1) respectively, which are aseociated with each of the N g: sampled which may be taken in any calendar day. -17;- I If a composite sample is taken, Ci is Lhe concentration measured in the composite sample and Qi is the mvexage flow rate occuirrinS during the period over which saoplee are comFoaited. The daily concontration of all ccnstituonts shall be detetrmined from the flow-veithte4 average of the same constituents in the coubiued waste ntreamo as follows; 1 N Daily concentration . Qt 1 Qi Ci i-1 in which H {a number of component waste streams. Q and Ci are the flow vat c HGD) and the cons tituentconcentration (4 /1), respective- 17, which are associated vith each'of the N waste streams. Qt is the total flow rate of the combined waste stieaas. 3. The 1130-day, or. 7-day, average" mass emission rate is the total Rage emission rates by weight during a 30, or 7, consecutive calendar day period, respectively, divided by the number of days in the period that the facility was dinchavging. Where less than daily eaupling is required by this permit, the 30-day, or 7-day, average discharge shall be determined by the summation of all the measured eases emission rate@ by weight divided by the number of days during the 30, or 7, coa- secutiva calendar day period when the measurements were made. For other than 7-day or 30-day periods, compliance shall be based upon the average of all meneurecents made during the specified period. ' 3. The "daily maximum" discharge meana the total diacharge by weight during acy calendar day. 4. The "3O-day, or 7-day, average" concentration, other than for fecal or total coliform bscteria, in the arithmetic mean of measurements made during a 30, or 7, consecutive calendar day period, respectively. The "34-day, or 7-day, average" concentration for fecal or total colifo rm bacteria is the geometric mean of saeasuresents awda during a 30, or 7, consecutive calendar day period, respectively. he geometric reran is the nth root of the product of n nunbera. 5. The "anximum daily" concentration is defined as the neasurement made on any single grab sample or composite sample. bs A "grab" sample is defined as Eny individual sample collected in leas then 15 ninutes. 7. A composite sample. is defined t.s a combination of no fewer than eight indivvidual samples obtained over the specified eampling period. The volume of each individual sample shall be proportional to the discharge flow rate at the time of oampling. The compositing period shall equal the specific sampling period, or 24 Fours, if no pet -Lod is i specified. -i ►.a -1 ... California Regional Watzr quality Control Board Santa Ann Region Monitoring and 'Reportins Progrnm No. E7-114 �b f o r City of Huntington Beach Construction Dewutering Orange County V 0 n Ue O V 1oni toring 1. Fir discharges of dewntering wastes to waters which could reach Anaheim, Sunset, or Bolsa Hays; or to tidal prisms of natural or man-made flood Control channels: a. A sampling station shall be established for each point o discharge and shall be located where representative bam- plea of that effluent can be obtained. The following " shall constitute the effluent monitoring program: Minimum Type of Frequency Constituents Units- Sample 9fjmnl.►A,js Flow gallons Estimate Daily ; ToW Sulfideo mg/1 Crab Twice Meekly Suspended Solids " Biochemical oxygen " Demand Settleable Solids m1/1 " Chlorine Residual' ag/1 " (if applicable) b. A visual check for the presence of oil residues in the waste discharge shall be made daily and reported. � 2. For discharges of dewaterirg wastes to any waters not covere in 1. above:. CA A sampling station snnll be established for each point c dischargit and shall be located Where representative samples of that effluent can be obtained. TL,e following I shall constitute the effluent monitoring program: n 'If chlorination is utilized for the treatment of wastes. -zn- --J , w MhRP No. 87-114 - continued City of Huntington peach Minimum 4 Type of Frequency Consti turnt ,% Units •113nmpl.p of' 1tnrt1ysi a Flo►. gallons Estimate Daily 'total 9ulfie,ee mg/1 Arab Twice Wtnkly Suspended Solids L Receiving Water Monitarin During the discharge of dew-Atering wastes, two samples shall be oollected from the receiving water once per week and analyzed for dissolved oxygen. Qno sample shall be collected at a conve- niently .located atatlon 26 to 50 That upstream, or upcurresnt, from the point of discharge. The other sample shall be collected at a conveniently located station 60 to lOD feet downstream, or downeurrent, from the point of discharge. Reporting 1. The diacharser shell Implement the above monitoring program with the commencement of the discharge. Monitoring reports shall be submitted by the 30th of each month, and shell include: a. The results of all chemical anslyses :for the previous month, and b. The daily flaw data. 2. If no discharge is made during any given month, a statement reporting this fact. shall t,e submitted in lieu of the moni- toring reports. S. All reports shall be arranged In a tabular format to clearly show compliance or noncompliance with each discharge specification. 4. For every item Where the requirements are not met, the dis- charger shall submit a statement of the actions undertaken or proposed Which will bring the discharge into full compliance with requirements at the earliest time and submit a timetable for correction. -23 J H&RP No. 87-124 - continued Ginty of Huntinotur 8eaah G. All reports chnll be aigned by a responsible officer or duly authorized representative of the discharger and shall be nijb®itted under penalty of perjury. ri Ordered by ES it. BBNNST t L eoutive Officer Ontober 9, 19R7 ' N 0 b I t, i j I -2; - � *1 r- �ItM VALI ASSOCIATES -x.—�� _ W. _ CONSULTING ENGINEERS 4,Me�,l`, er_.� WO 14ci% *Marion, k: !a F. Anohsfn+, G M 7 DAYIN / V Phme (M) 652.72a FAX P14) 6324269 —._._ e14 / of 9 m 0 0 x d is aor, I►Js e' Ga C,C1 c c B �� r /3 S"r N. ` 64?- • Ir 7' ,a. -Z ,m try "Wu. Jr I Gr /2r .L w #f Vre M W 9v -9L we.. - alow .. -+arm .titl'�- -•ti1 _J O ALI ASSOCIATESU.��,�y �, .�� M�.��d :•�x - CONSULTING ENGINEERS T� _ r �•v t �.J• or L• �1 ..._ 12% Notes hffa wm Suns K Arwhelm. CA Wto /hare VU 632JVW FAX 1719) 632-0J,9 _. 11 flN_.L or O, 0 c� u c °n L- Am 1 I fd m', GTR Z s 2-P/ `ia o. $q�ft /*t/. t /0/ A',7- x f•S' is /17,X h .OT3r 16 ! ,c - 7 .� f rI d/r ,,7iw,4' 0 '� /," A- ,.ryj,- -9 rl- /• 7 PY It All ,�• ?sd'�...,` JL•3r' � , Gad � � � ,6�. ry Z� z l- /7. tf �f ' N6 or -ZILJ w rwsn, ++a 119'01, A *lt SLA v Awlf—w4w � rem Z! A� � a r- I I� VALI ASSOCIATES Ho.T7,o— 23 CONSULTING ENGINEERS { 040 !lMA Jsft"K % lUft F. AMh4Wm, CA 428M UATE �' 8 • ` Phaw QM) 6Y.t VY.2 F►1`( (71416J24269 eH m ` , G• C . /t� D s/� (�t'c V/e4�.�G ffl;WO-) 'I arc M � t LX./,o 177.1r r4 ��► xv le.10W. CP I 10 1 101 Q 14 /fie, 0 X : �J'//•:r 40 ' , s /_*. J. •:.'�, /r r !//• J- if/, 9% ' d ir44 (kL , •='tom Q 40a 6/41) O v I°� 'Oc /fe_`� ___� is - Pv/© ,�' Jaol7 ar el&,Vot /D,: 1o?p''r�% /��'fierElvd�► �/- /�1D X 7.7rys " YX. ox; x . 9', r ' 3pry r or. ea-wo0w) _J 1 Cal I 10 Q I p1 ALI AMOCIMES CONSUITING ENGINEERS BY. �•""l�. IM NorM JtffApwm Sint* F, Anaheim, c;A 92w? DATlf ftme PU) &22.92U FAX (M632tl269 SO 44-79r w 6v 7ry,;Nv, 77X 3 •../°�d7t 'l��I�Nf' e?riOCVA.t!Np+F'�. ` 1� R 04 1 11 al til i 021 ' VALI ASSOCIATES JOB 140.070—Z.3 A CGNSWING ENGINE RS _._ er. AA • 12110 Nxth Jifftn n, Suits R Anaheim, CA IM7 DATE Pho" (71i) WIM63 FAx (71A) 6328269 51; �saV 64 L t1WA..' 4P cA.-riG-'U : t 1 8*00 , Tt IVA�, (7y, e ms of'4os ', c C�,.v/ K "'/?��frt /,/3,-;.. ( G-' n As ea..:0) ,Or4Ve /P.P a j/� . *pi' / 2% d cy, e7AO..� �.,G, a�irx sew �.e,eo / (7�.+ • s S ��, /ly�'X (71f y; �' ir, 1►�f�,�yJ � �4��, 5 •Jer � / /J7b //X d�l✓ X /4 A f %� . 7 ?7-06 ' , i q & o pl-t i ' w r o ramb . i A VALI ASSOCIATES ,r C4NSUITING ENGIMEERS _ __ _._ ar iM 14orth Jo l?fWM Ulto F, Anaheim. CA 92WY JATI! Pix"e (744) 02.9262 RX (714) 67I420 ra — _ _ __._ a}, ei of — — . ��w -r G 1ls (� � ,. � .,,. r >,�(o } �r � . /d�► 7� � �'��' loc'sv 4s�"3•= nz%,soJ < ,Von, 7,41 /� yd n f:;; / pme. %" G v .-z' x �tm -v 1�,/¢ a a x J„a s? y¢ 1 AZ . 'r,0 ¢Gb 8'7 37s�y ��I�AL. '' `f S /tsf C�.V tX a$6n , 5)// 1 . &vc- ;; '/w f g C00 e /.a ti All. r O. !ar (.Y�"r. /�a o f /l.'l.oJ'JM � t r.J � Ztts.-Or A Sb> i _Of! %-- ft 1-71 106 9Gf �?Go ��C ..11 � r, }end •. I r IA CONSULTING ENoiN •, tllq Nash � an, � !� �r+ahNml a VIM VA bU#M FAX pia) a ' a ►r_ 4WTWve. Atf a eal ly "or Zows7e. �va.0 r � � . T�j1��►rr t'.. .•� Es ERS .,► �.�.,. am 1 ;c X,!A II ,'•� r Ow C/z rme (.. — IL,*"7,r As Z•T� 1 11 ,, it r t .r 7 A- •.z4 J. I,r, t 1 , ,r f rl r w 7 r , ,. •:. hs � � •' . ..- ... . . r .., . i, , w ...., j( . .c. - ., s,..,.. , � .. .. ',:a.i -,+r t1>iA 1.N..!/+.•t+,•q�:+--•.___ r•, ,,� ,�..>'Y!".R�I�ructiR.�f"tMLAtiJ..�1Zi.,t.•.:..lJ •,� .a.�.;�r °•urr �, r a _ _-..e, •,^,. �tdM�'� .%/rsrAR9. AP• - VALI ASSOCIATES 7�--. r .j CONSULTING ENGINEERS . By s r �.0 c�sCu�lu b�'✓�ry t . �'arG wl�4.ti ' • 40 ►F a .1 rim) r /0, � � 7-.�rr�r /s � ;W,4 vm j0 r tom' ,y 11: oz*40,ft S-w j �7Z ,* !'i%�/G"es'1.%fix %��•i�� -pal ? e K 12 set y J71•0L pwi tit '+ �' 6 • �,'p-' r �C.d' Cfto Pv- i' r� r r .1b t1.iJR CAftj 40# 9> A r 10, 4M7 4"" of. re >r I r,cpM ►I.Nw.r •n••r...,..,... ,..rr.. r._..r. ,«......�....,...... aay. .. a'r'.r �•Y r. r. ,r .... r. r... .,r.,�r .ya .....w •.. ............ ..... �.. r.. .. rr.,,w�:a'lrt,'..'7f.. .{`. r: 1i. �'!�_,.... rt I012t' L'4— �j r um" VALI ASSOCIATE s OONSUUING ENGINEERS 9 Andwft CA 9W (1" 4w"lm ffix (?" maw jr; II w V-4 L m M+ #1 AMA61-4v ~ •ot �7 DATIR cw -44 41 MI; lF ZI Aj . ty dr a x /Irp lip % t 1. i a 2 0 ATTACHMENT 181 WATER QUALITY CONTROL PERMIT �' ,� � rr J' ir� 'yr ���,4 / {'., ♦ !y t �✓ tt rl f�t. N ( nl. h.••>; rr t�� Iy1Jrj +r r �! 7 , �I� i fll � rj'y �'��, V {" t n�W� •t, t l i 1' 4' I �j�}r ' 1 �� t � /, , 1�' 1 f fill /'� 1!"l ° i r � � r tr t } �r�) , � • t r i rr 1/ ',r/l y .71V' , !r.)� V% )'1 ,�"�'ry 1 • it f.�l a�t��rlC r Zt4 �� ) :� to r ' fair J i� 'i I rat l/It r��trJ •F r44 �i `;1. {�;u*�+j 4,!/ii I}yt ,��1„ rl•. ( �l ! Y,1 ' r 1 '.t'::' '!�';.r 'r 111��r ;J �/y�� _,. A} ! " '� �t r`:. 1 r ,fir I t t 4';1 �S !✓ �,.'}� n !i 'ji y t, +' eri t!AA V� y) f a 1 V r ♦ +r. ,.�' Z�,: }i r r 1 e:.�. Vr� c3. �./V��y/." ' 1� 11��p}f Y�"� ♦�,''11 1 j r` i11x ) � ♦'It;_,_�r ,' r rl(l� l � ,` �liy`.� ��'r j�J rll%7 v J�' ',''i t � %! 5�:lk^•IV,r C'fr 5'*!{ f} I`iit 't, r„L� 1•. �L',vle i••` II' I :4• , .1.1 r r. Il•Ir },1 tt .•1 � r1 �./,. I' ,.t . l.' 1 ' r:l : '.'r rl, v.� 1 :+{/ 1N+}}� j. � C—,1,.1 r�'' A c; ! 1_'{•r l t! t }r,, ! � , ' "'�1 l {�'i I l�+S' rat` Iv � �(, '� / r, Pilo4-1 ri 1) ,, 7 'tl �V�'+ -♦ 1 ,!�r �f��{♦�� ii�+'%K!1'�t!r' � a tili-y ; j r•' .. f �� ! t ) '1�,6r1 r t4 if) i�) i� .YY f 1 1 R..J�.k''; P !" 1/ .1 1,•; it .- r , is SECTION I DEFINITION W ITEMS 1,01 GENERAL Unless otherwise speelficelly defined herein, or unless the context requires a different meaning, all Abbrey lotions and symbol shelf conform to the Iatast adI- tlon of the Standard SpeelIIcat Ions for Public ik,rks Constructl on. Words used herein In the mascullna gander Include the feminine and neuter, and vice vernal and the singular number Includes 'the plural, and the plural the singular. The word "person" Includes a corporation, essoclatlon or partnership. Unless otherwise specifically defined heraln, or utt less the context requires a different Meaning, all words, terns and phrases having d well known or tachnleal aeanirig Shelf be so construed. 1.02 DEFINITIONS i Menever In these speelficatlons, or In any documents or Instruments where these specifications govern, the following tortes are used, the Intent and meaning thereof shal I be as fol lowst CONTRACT - Thase specifications, the drawings, any addenda Issued during the time of bidding, the Notice Inv sting Bids, the bid of the Contractor and the Agreement entered Into pursuent thereto shell constitute THE CONTRACT boteecn the Clty and the Contractor. * C014TRACTOR - The Bidder whose bid is accepted and to whom the Contract is awarded. r SUBCONTRACTOR - The Individual, partnership, corporation or other legal entity entering Into a contract with the Contractor to perform a portion of the Mork. ENGINEER - The IndIvIdllal so designated by the City of Huntington Beach Public Mbrhs Department whose responslbl I Ity Is the Inspection of the work6 : ,r W*'� 4 , !�,{��j�':, ,Y �%,v; ♦ +J.,rr .'. ....7f, 1 r lty.., {rr l�iiyl !1 Jr. yyil��(��7 )f�t5 r �� � -iyf r i i .,. ,l � 7 J � r.,,Yp�l( ,� "1� Y••'" : f ^, l `I Y `�' � t % I - I 7 •, �r I 1111 �ls (I ,I Y I!t , rl ( i' , f'1 i,• '�., , art .( ! �"'�� :1 � ..�i� r��� .tf -•1r� ,.3 t{ r. al ,it „�f r l {.�fl ' � i:; r {' lif 1 •.t � -' � r V .. — � 1 Vt - t (� � , l i t 11.l1 J- r � 7.-N� �fr ftl�� ��l �� j� r•4�2'f �1 ���tt`�, t � {,• rj � 'i' ` ,'�l;ri i ,r!' r '��'115, , fl )7r ��� E SECTION 2 CONTROL OF THE NOIiK 2.01 AWARD AND EXECUTION Of 0011TRAC T Award and oxooutlon of Contract wl11 be as specified In the City of Huntington Useeh Standard Specifications herein, Unless otherwise set forth In the apedlflcatlons or In the bid, an award wl If be made for all (tone of the bid to one (II Contractor and Bidders era requested to bid on all Items of the bid schadule. Unit prices shall reflect all col lateral or Indirect costs connected with the work unless speelfleafly otherwise stated In the bid. 2.02 NON -ASSIGNABILITY Neither the Contract that may be awarded, nor any'af the ocales that may bscane due to the Contractor under such Contract, may be ass Igned by sold Contractor without the written consent of the City. Nothing herein contalned shall bo construed as a prohibition against the Contraotor subccntra*ting portions of the work required to be done herunder. My assignment of manoy sh■l I be sub4scr to at I proper astofts and withholdinge In favor n• the City and to ■i1 deductions prcvlded for In the Contract. All money withheld, whether assigned or not shell be subject t-i being used by the City for completion of the work, should the Contractor be In defeul-4 2.03 NON -COLLUSION AFFIDAVIT The Clty wlII require any Bidder, to whom It may make an award of the contract, to execute a Non -Col fusion Affidavit (see bid proposal forms). 2.04 MOI%'TO BE DONE The Contractor shell perform all work necesary to coop Iat* the Contract In a satisfactory manner. Unless otherwise Indicated, the Contractor shall purchase and furnish at I materials, equipment, tools, labor and Incidentals necessary to cm - plate the work as shown In the drawings and specif led herein. 2,05 SERVICE OF NOTICE The delivering of any notice, Instruction, claim or protest, or other written communication, personally to the Contractor or superintendent or to the City shell constitute service thereof upon the Contractor, or the City, raspeatively. The deposition In a postpaid wrapper dlractly to tho official address of the Contractor, or the City, In any post office oaf box regularly maintained by the ,cost off Ica, of any notice. Instruction claim or protest, or other wrlttsn commu- nlcatlon, shall be doomed sufficient service thereof upon the Clontrat:tor, or the City, respectively, and the date of sold service shell be the day following thi date of such milling. 2,06 -PROTESTS It the Contractor considers any work required to be outside the requirements of the Contract, or considers tiny rowed or rul Ing of the Inspelctore as unfair, he shot 1 ask .for written Instructions or decision Imteedlately and than flit a 1.r1ttan pro- test with the Engineer within ten (10) calendar days thereafter, or be considered as having accepted the record or ruling. It the Contractor disagrees with any terms or conditions set forth in an approved change order which has not been oxecutad, the Contractor shalt submit a written protest to the Engineer within fifteen (19) calendar days after receipt of such approved change arder addressing the points of disagreement, referencing this quAn- tltlos, cost or time involved. If a written protest Is not submitted, payment as set forth therein shot I constitute ful I compensation for at I work Incl Lf_:,d. ,1�'« �V'r tie ' ><_}art 4id �,t r .-s t ,.r 1i t+ , r• r 6 i ' 1 ' r111 ,.1 I .r ,,rj,. . 77 .t•', I r 1 r r 1 � - r . a +r+ �,`� �r'i .�jJi�f ♦,�l,�) �+ r�t.: '1����} If".�, �?w � • � " w ,+1,+ t rr 'r �4 r+ r � •, ('S�tr ;.�, h'r t' Irr,�� Jf t l + � ' ' � ar ��:•�"�yMFa �� `r;�+ r � r r , 1�" . r,, r� fig' �+ .I �r f I ' r r � ' tr , (/� � r�� +��I•�" a�t I r�l ���"i i �1 � r �: + . �'� r� ! �,+ •'• tl �'!.f i ('!�d r r �' h ; + j I r' > > f f 1 � + i + � t � J' A•, ff i�r7 t �4�lrt J+ , �,.� ,f 1} ! 1�;'•r � � �� ( �,r, r � + ��.) vy,Jyi V {t�)���,/,1 Jr ` �► / ! 1 � r I ( t� { + ,I �' ti�T�� J li+ + � ' i .�"{S +'��' L4 .Sry ..�, r= � t t• �}1 `ly i ". � ,{�Iti!f ,'`.�, i Sr 1 r� , ,• � �1 -!;T. ` "� •'� �i �.' �1. •S. it . `ri�?r';t m �� r ,, � r I t.. .• t ,,, r ,'� r I .., � r: � 14t. ,��i � � rf1 „tit �1� t4 , r (� '+Ir + r,�.. +� , /., r t ���� s r � r•?'- i frrty\/ �;c ��dh f( 1 ��' �Y c la SECTION 2 CONTROL OF THE WORK 2Ay Sued i The 61ddor shall set forth In the bid i. The name and the location of the place of buslnese � each Subcontractor who wlII perform work or labor or render sorvlce to the Contractor in or about the construction of the works or a Subcontractor Ilasnsed by the State who, under subcontract to the Contractor, spsclaIIy fabricates and InstsIIa a prof Ion of the work or improvement according to the drawings and spoctflcatlons, in an O amount In excess of one-half (1/2) of (1) percent of the Contractor's total bid. 2. The protlon of the work which wtl: be done by each such Subcontractor. Only one (1) Subcontractor shell be IIs-red for each such portion as Is defined by the Contractor In the bid. In each instance, the nature., and extent of the work to be sublet shell be des- crIbode The fal lure ut the Contractor to specify a Subcontractor, or the Ilsting ' of more than one (1) Subcontractor for the same portion of the work, constitutes an agreement by the Contractor that It Is fully qualified to perform Itself, and that It shell perform that portion Itself. The Contra ictor oust have the written consent of +he Engineer to cubstltute a Subcontractor other than that deslgnstsd in the original bid, to permit anyy subcon- tract to be assigned or transferred, or to at low a mubcontract to be performed by other than the original Subcontractor. Subcontracting of work for which no Subcontractor was designated in the original bid, and which Is Tors than one-half (1/2) of the one 0) percent of the work, wlII be allowed only in case of public emergency gr necessity, and then only after submitting written evllense to the Engineer, setting forth the facts conutituting the swergoncy or necessity. Violation of dny of the above provisions wlI I be considered a vlot atlon of the Contract, and the Clty may cancel the Contract or assess the Contractor a penalty of not more than ten (101 percent of the subcontract Involved, All persons engaged In the construction of the project, Including Subcontractors, shall be considered as employees of the Contractor and the Contractor wl11 be held responsible for the work of the Subcontractors, and all work performed by the Subcontractors shell be subject to the provisions of the Contract. The Contractor, or an authorlted representative, shall give his personal attention to the fufftiIwent of the Contract and shaIi keep tAe work under hIs control. The Contractor shelf perform with his own organization and with the assistance of workwen under his lnmsdlato suporintsndence a substantial portion of the value of all work embraced io the Contract. Where a prrtion of the work which has been subcontracted by the Contractor Is not ® being prosecuted In a manner satisfactory to the Engineer, the Subcontractor shell be removed Imoedtate;y upon written notice from the Engtnser and shall not again be "p leyed on the project. 2,08 CONTRACT 8=9 Before execution of the Contract by`,the City, the Contractor shall f I I a with the City surety bonds satisfactory to the Englnsor in the amounts and for the purposes specified. Bonds shall be duly executed by a responsible corporate surety, autho- rized to Issue such bonds in the State of Callfornla and secured through an autha- rized agent. The If cider shall pay all bond premiums, costs and incidentals. The bid bond, the falthful performance bond erd the labor and Material bMd shal I ba on forms provided by the bonding coepenv. Each bond shall bo signed t:/ both the Contractm and surety, and the signatures notarized. ��� ��' +n'•V �D�i f 1�t � '�r7,. rr ;?d .+a� '',Pf 1.. if/irhyr�hltrt�?.r��� �q� f .� '1 �Tjj r'i•;Ci�lf1r f,rt +� •V� -'Jov"i}r ..1 �;•�r i ',f t R L • TI`,,' rit7t'irY�%i�L•�r�if,� !r; l..1ly . 4 ��,� �f1 r' n ri `A� � �i{��_, �. } l l'.- ,� ► r- 1u </ /� r p -fti � • I t�.�/'., 1. r.�r jjyh. !r; i 1 �,' / r rr �� L t I f '�% ♦ �r '' 3 j _(, } i �)y�f/:i t 1 !!�L of rlifl x •y r .1r 1°��Ir'..rY �rr,• �.i 1.•�11 i I rr ,_ � '-• r , ! r,�a r r. r1 r et rI•l�� �r t�� fl.� tl r� L., rfl rr' , r ��� :i�\� � ! 1. .�r•'�7 i. � I '�p?ygy�'�r�ht�}�11��1•:C C ,I.I,�f� _girl .. 11 )' tjk�. � 1•�f, ,' �_ t ��y !'•r{ ��r� fYi���.W�j�R�rt� ",� j, /� r 1r, r , i r {L', r � i, .1�r 1�•. < �•�� .I H y, � iSsr�r'• { I � .:E�}r//t� .rti t�'at�i.ar �•, �r 4�1 r ft Jr,l IV tt I .,r r; � `1 f t :{ S1 '.1' S 1Z../,/)ki) j7ijltt�t�i4�i LEI jirj j` r�•(f ,r f �t: ..r•f I 1 rr 1 tf ` r r r r r�`t���.,' �,'if�+l ftl-, ,rf /!,� rt t ;r r r _ {t \rl��' i, IT 11r� �rrr•' t���y�l`•1Vh i Al r i• is Is li SECTION 2 CONTROL Of THE WOiiK The faithful perfcfWnce bond shall be In a panel Bum of one hundred (1001 percent of the total aeouwit payable by the forms of the Contract and conditioned upon the faithful performance by the Com,tractcr of ell of the covenants, terms, provisions, conditions and Ptlpullitlnns contained In the Contract, wlthli. the time prescribed, In a manner satisfa4tory to the City, and that &II materials and workmanship w1II be free from original or developed defects. The labor and mstarlal brand shall ba In a panel sum of not less thin fifty (S01 p: reont of the to7a I amount payable by this terms of the Contract and she I I w conditioned upon this payment by the Contractor or his Subcontractors for all mete- rlals, provlslono, pr;.vender, or other suppi lei or teams used in, upon, for or about the work contracted to bo done or for any work -or labor done theron of an kind or for the amounts due under the Unemployment Insurance Act. The bald shall be maintained by the Contreotor In full force and affect untlI the work Is accepted by the City, and until all claims for materlals and labor are gold, 4 Should any bond bacons insufficient, the Contractor shall renew the bond within ten (10) calendar days after receiving notice from the City. The Contractor shall 'furnith additional bonds, is my be speclfled to quarantse performance of all Mark under warranty provisions of the specifications, In the amount of money and tw the period of time stipulated. Such Ix"ds shall be furnls- hed pelor to acceptance of the work, on forms to be secured from the Englnaar, and shall owiform with all other applicable provlslons of this Station. Should any surety at any time be unsatisfactory to the City, notice wl11 bo Ivan the Contractor to that effect. fie further payment shall be deemed due cr wllI be meade under the Contract untI! a new surety shall qualify and be accepted by the City. Chengbs In the work, or extensions of timb, mado'pursuant to the Contract, shdi) in no wef release the 0mitrector or surety from their obllgatlonse Notice of such changes or extensions shall be waived by the surety, At the request and expense of the Contractor, substitution of securities for any moneys withheld by this City to Insure performance under the Contract theII be pert( tted In accordance with provisions of the California Oovernmont Code, Section 4590. 2. og CR41,1 1 AND SPECIFICATIONS This Contractor shell keep at the sIts',of the project a copy of the drawings and specifications and the Engineer shell at all times have recess thereto, The Con- tractor ahaII furnish h I I materlals necessary to fully and completely finish the project according to the true Intent and sdaning of the ipecIficatlons. and dra- wings, although every Item is not particularly shown or monrloned :n the drawings or specifications, and no additional compensation ohs II be allowed for the materials so so furnished or work so performed to complete the project. In the event 1? Is discovered that a dlsceparcy'exists between flguren.and/or drawings, ® the discrepancy shall be loewedtato)V submitted to the Inglneer for elnriflcetion and any adjustment made by the Contractor withnut obtaining such elarlfleatlon from the En Inver she 1' be at the Contractorls risk and expense and be subject is roeovap If said adjustment does not most the approval of the Engineer. Should It appear that. the work to be performed, or any matter pertaining thereto, is not ,iufflolently detelled or explained In the drawings or specifications, thu Contractor shall request, the Engineer for such further details or explanation as may be csonststent with the original drasfngs and specifications. Thu Contract docaments,,�,ss defined hereln, are Intsnded to be rated together to describe a complete and IInlshid piece of work, Including all labor, Wartals and equipment necessary for the proper execution of the project. Anything necessary to complete the work properly rnd In a..cordenee with the law and lawful regulations shell be performed by the Contractor whether set out speclfIca IIy in the Contract or not. 1MMything in the specifications ani not on the drawings, 'x- on the drawings and me. In the specifications, shell be as though shown or mentioned In both. The division of thi specifications into a number of sections is for convenience only. All of said sections shall be read and Interpreted as canotltuting a whole and no other construction or Interpretetlon shall be mode. r;� a) r t r�..T�tti�(/it,�•'t q Art'"C7 1 ( (ls�P1Y I �t IY IiY I ! I i 11 { (1 lit (1}j4 r �l`�r}�Y�,1qJ 1Ip� aS l 3� ',t r•r11 r I tf h((r� 1 �� Y (7���f'l7 � (� l � I�mrrl` l IA t. i I r l i t I 1' .1 � ��.. ���I :r'} 11r�y�'� kl�t •' ,� .� i� , I I 1 r'r 't i 1 �l r 41 •' 4S 1 ( .J- Y. t11 Kt r �r I Iq r' ( I i r Ti,, r/li • H. 41(, Al ti ' 1; ��.Ir� �� ��Jr{t•�51'' ' 1t it 1 �1.:•t, �I ,� 'S I',►�)S� tt �i'�j,� lr P SECTION 2 CONTROL OF THE WORK The drawings are Intended to convey to the Contreator the requlraments as to also, fors, dlwenslont and specific needs and pecul forltles of the Improvereents to be constructed. It Is the 11tantlon to convey the Impression that al I parts or elements of the work to be done she I I be complete In every dotal I, regard 1 ess of an owl as Ion thereon to name or show f u I ly any element or part. Olven dimensions shol l be followed In preference to scaled dlmonslons In all cases. All drawinge, speelfleatlons and copies thereof furnished by the Engineer are to be used tolaly for the project contemplated herein and upon request for the Enginoor, shell be returned to the City upon camp Idtlon nt sold project. 2,10 PRECEDENCE OF CONTRACT DOCUMENTS I! there 19 a conflict botweon contract documents, the order of precedents shall bat I. Permits from other agencies as may be reoulrod by laws 2. Project speclflcstlons. J. Project drswings. 4. Standard drawings. 5. Standard spool#Iclitlons. 6. Standard specifications for Public Works aonstructlon. Chan gge orders, supplemental agroments, and approved revisions to drawlngs''and ageclficatlons will take precedence over documents listed above, except 'permits from other agencies as may be requlred by law. Dotal led drawings shall have precedence over general drawings. 2.11 CONFORMITY WITH CONTRACT 000MENTS Work and material shall conform to the IInes, grades, cross sretions, dimensions and material requirements, Including tolerances, shown an the drawln2s or Indlcoted In the specifications, Although measurement, sanpling and testing may be const- dared t-vldsoce as to such conforalty, the Engineer shall be the sole judge as to whether the work or materials deviate free tho drawings and specifications, and his decision as toany allowable dovlatlnns therefrcae shall be tlnal. 2.12 *W OMWINOS OR WMINO DRAWINGS Shop drawings shell cahslit of manufacturarts cut or date shoots or working dotal drawings as are necessary to glve'a comprehensive Idea of rho construction contew- plated and to adequately control the work. Shop drawings, as required by the drawings, speclflcatlons a• requested by the 41 Englnerr shall be prepared In accordance with modern enpineering practice, shell be oft sufficient site and scale to c l earl y show al l dote 1 I s, erd sha 1 1 be arbelf tell v"tils flf use Ells ealerdss' de" efisr award of matrwet wW lit learnt ftlrfy E301 e• 1 ewder dap ler ler % Iflstel l 1 atlas. Materials shell not be furnished or fabricated nor any work don, for which drawings are required, before approval of the shop drawings. 0 Shop drawing.% wl 1 I he chocked by the fenglnver for genera I conformance Pith the Jeslgn concept of the project end general campllance with the Information given In the Oontract documents. The Contractor shell be responslbla for: dlmenslans which shell ba confirtsed and correlated at the project alto, fabrication processes and techniques of construction, coordination of all trades, and the satisfactory perfo- rmance of the work. Any action taken by the Eng Ineor she 1 I not be cenxlr ued as accepting or approving the dotal led design. Deviations from Wire contract documents shall be specifically called to the atten- tion of the Englnoor by letter of trnnsmlttal submitted with the shop dravimas. 0 1 )-�r r (� ��r�°.� 1�tfl�h'r1t1i��;�"��'i rf�r4 r! 1r, ..1t.7, ' r71e t 11�1 3 .4 �rl� `//y(y(4 yyy rt4 f�1�y{ 7v 1j�?iJh �r ��`, �t 1• � a S }���+L l5 r',!1 r .,, - � r � , , � + art r (. �' f r ,r£: r� i .1 1, ti". r ✓ + ` r 77, r 1f 1 A. y),'r Y� �G} y!' � 1•'i7 r 7' I I : +• r 1 r1 + e t 7 17 j 1 + , � ! J. r/t r ,a 7 d +i �y� i (t '+ %l -•rt ,1 + 7" � , �' r :'7 ' I i 1 ,1,. 1, {.,, , T i � � f { G ' r11 r t �+ , 44 s ly r rl M1 �S i + ( l� I � '- i - Ifri. 1. •r'. I � � r'' r � r.•, r��i +. r All f�� n ,1i ! I,< <� 'r��1r77' �� (r � j : ft�� rr. :.• it ! r SEC?ION 2 CONTROL OF THE WORK No changes or &Iisratlons shall be bade In any plan or drawing after the some hex been rav loved by the Engineer except by the Englneorts consent, ReVlow by the Engineer of the plans and shop drawings sha) I not re) love the Contractor of any (90 responsibility for accuracy of dIm ns ons and details, or of mutual agroment of dlawtnslons and details. The Contraator shall also be responsible for agreement and conformity of his shop drawings with the orlglnml drawings and spoelflaotlons, The coat of proparing end furnishing shop drawingm shall be considered as Included In the prices bid for the vsrfcus Items of work and no additional elIowence wlII be "tads tharefor. Contractor sha I i malntmin at the project site a coup! ote fi is of reviewed shop draw Ingf. 2.13 AS -BUILT AND RECORD DRAWINGS The City shelf furnish the Contractor with one (1) set of reproducible transparen- clue lcontact m fers) and one (1) out of biuel In# prints showing a) I work r 4olred under Me Contract. Contractor shell maintain and keep up to date the sat of bluslines showing the "eel-huilt" loaarlon of aajor features of the project and Indicating changes that my occur during Instal lotion. Prior to the Post -Installation Maintenance Porlod► Corltract3r shall furnish to the Engineer, the reproducible trensparoncles (contact syla:s) as the Record Set show - In the no-bulIt data, of a quality satisfactory to the En Iner. Transfer aa- heats. bu�lT date In Ink (no he I point pen) and #rodlcato outdated 2,14 SUDS�E DATA Where the City has made Investigations of,slte conditions Including subsurface conditions In @roes where work Is to be perfornoci under the Contract, -7r In other areas, sawe of which may constitute posalble local natai:,al sources, such Invostl- gatlons *remade only for the purpose of study and design, Al I loll end 000loglce) test hole data, water table alovetlons and aolI analyses shown on the drawings or A Included In the specfflcatlons apply only et the locations of the tes6 and to tho depths Indicated. The r6eords of such Invest+jeflons are not a part of the Ow tract and are shown solely for the convenience of the Contractor. It Is expressly understood and agreed that the City assumes no responsibility whatsoirer In respect to the sulfielency or accuracy of the Investigations thus toads, the retordo'•there- of, or of the Interpretatlons not forth therein or mode by the City':n its use thereof and there it no werrenty, or guaranty, either expressed or Implied, that the conditions Indicated by such In a. gotlons or records thereof are representative of those existing throughout such areas, or an pert therof, or that unforeseen developments may nit occur, or that materials other than, or In proportions dfff&- ront froru those indicated, may not be encountered. Additional subsurf6ce Investigation may be done by and at the expense of the Contractor. Sol i ogrlculture suftebl llty and 1*011 lty anelysan wi l l be obtained b�r theClty of a Huntington BedCh and paid for by the City, unless the request Is tnittated by the Contractor, who in such case shell be responsible for the costs InVoived. It Is tM' Contraclarts responslblity to determine and allow for the elevation of groundwater of the date construction commences. A difference 14 *1ovation between groundwater shown In soli boring logs and groundwater actually encounterod during construction will not be considered as a basis for extra work. 2.I3 S'dRYEylms Permanent survey starkers r111 be as specified In the City of Huntington Beech Standerd Spocltications hereln. The City wl l l perform, and be responsible for the accuracy of, turvoyl-ig adequate for construction. The Engineer wlI I establish a base IIns and the necessary con- structlon survey stakes and earls for the use of the Contractor. The Contractor ® shall give to the Engineer a notfcre in writing speclfying when he sill require the base line and survey stakes, said notice to be given at least forty-eight (lfl) • • , �rK y'77+ �� Ifi�l. ! {11 1 1 f J 2 1 r 7, J,7 ° �! •1 r �r lY9�� fry., r "i �,�C+1YI����� j i r� t• }�tr •r •i ( II �� + 1� PJii� �� Z� �iij�'� �•^ �� '., it + q�y1�S4 4i{ � t,; + 1 �{T I rl r I ,��1 � }1'1 _ 1 r � r[� r! �'�i� ►�+�y{r,l1�� r,S� TLlK�Y�r Yrr"1 � �r•l'y IV3Y/i11'!'� 171�! t\ Irk . r �+' {411 rt! r It-�� !}.r riljf� r��Sr�l rl•i��! St �r} l 1 r1 1° I 11, r4k , +Ai q F iI(t�It rr 1 + ra 1 t r r' L 17 1 1 y i r - t r7 +, �•�tir f r �t S �i�r li 1. �'�rrJ,/I II�jJ+it+ {T+ 'Ii + � .. +! r '+l ,''1 �+ / '�_•` fir.;, r ,I+: Iti !} �r�t�, rY 5 "f l�.,��! ��r! ul•r y 4 r t r (( t + �j � a�u aT lift d ���y�1,T1 �r rl�, � �, { 1 �LIr ,1 1 •r. 1A ��,1 V� 11 i.;{la' i 1 � i�f S f,l./• tr rl - ( r. t, d `('•I ��>.111 r! it Is SECTION 2 CONTROL OF T4E WORK hours In advance. The En Inser's marks, stakes, monuments and bench marks shal I be carefully preserved until their removal is authorized by the Engineer. In event of thalr destruction or ratnoval by the Cootroator's forces, the cost of their replrace- mont or restoratlon by the Englnaer wlII be charged to the Contractor. The Contractor she I provide al I other I Ines and grades necessary to proper I carry on the work, and these may be Checked from time to time by the Engineer# and any vurk which Is not found to cosply with the IInes and grads, shown on the drawings shell be altered or removed and replaced by$ and at the expones of, the Contractor, es the En Ineer may request. Trio Contractor shell check ell dimensions as a whole and In do all, and shell lay out and become responsible for the exact position and elevation of all parts of the work. 2.16 AUTHORITY Of THE ENGINEER � The Engineer shell doelds any and bII questlons ahIch may arlse as to the quo ilfy or soceptabl I Ity of materlals furnished and work performed, and as to the manner of i perforoancA and rate of progress of the work, and shall decide ell questions v+,lah my arlse as to the Interpretation of the drawings and speclflratlons, end 'al I gqiiesttems as to the acceptable ful fl I INot of the mntraet on the part of the tbntrm&*or, and as to compensation. The Engineer's declalons shel l be flr.�l and he shell ha:a the authority to enforce and make effective such declsions a•,d orders as the Contractor falls promptly to carry out. M 2,17 INSPECTION All work done and all materials furnished shell be subject to 'he Inspection of the EAI veer, Advance notice to be glven for Inspections shall !a as spocifled in the City of Huntington Beach Standard Spealffcatloos herein and as stated In these speclel provisions, The En9Ineer she Ii at alI limo helve access to the wo►k during Ita constructlon anA shall have every reasonable facility for ascertalnl:#g that the stock and materials used and employed, and the workmansh!p. are In accordance with the requlra.sents and Intentions of these specifications. The inspection of the work shell not relleve the Contractor of any obllgatlnn tn fulfill all conditions of the Contract prescribed. inspection of a method of procedure, procfrss or systafs of operations of the Contra- ctor, falIure to opcerve hazardous opererlona of the Contractor, or falIure of thu Engineer to warn tie Contractor that tills method or methods of construction adopted by him are hazardous to property or to persons shell not rellove the Contractor of his obligation her,under. In add Itlon to the required inrpecticns by the Cf ty's Building and Safatry Depar- tment, Coe}rector shal I notify the Engineer twenty-Mur (24) hours, prior to perma- nent oonceelaent of any work Including but not limited to the foliowleg: 1. %,"�1gh,gr•ading operatic�s. 2. oral system. ;. Foundation material, footings and slab beds. 4. Cloncrett and masoiry relnforcomeut. S. Ciontect surface of concrete forms. 6. 1%1 ovi-grads ep;lIcations of creosote or Permabar. 7. lerfgatlon systm layout, pre,zurs supply line test, and coverage tests. B. Sioll preparritlon and baekfili mixes prior to Installation. 9. Plenf•and planting holes prior to installation. 10. Flnitih grads prior to wood abatement operations. 11. Meod'abatast t operations prior to stolonlzing, 12. End of planting operations price to Plant Estabilshment Par IM, 13. Insp►ctlon of construction prior to Post -Installation Maintenance Period. 14, Mxvptaoce of work. If en'iWaritis concealed or perfortied without prior notice, the work shel i be a#jbj,=t to such tests or evpasure as requested by the Engineer, All labor and equipment necessary for exposing, testfng and replacement shall be furnished at the Ccntroctcr4s expense. 7 Irr,7 7 t Tf 1'.,�}�r I .IIY!. ,tpf1JA y •4 L �,1 � Nr r. ,er :If •r r ,' 1 1 i. ( l 1 �• r t l,i i r r•- f , J r N" , i ✓�� :�+1 ICJ �' rr� vt ':� y+1,:1 r tie 7 t,��7y1 •i 'r ,, J��' 1 f• 1 Iti •� tiY � �S } •, j,46� �. , a 1 • t �11 r t Jr t,ft %%tt ��� r�j1� ` y r h� r ��rrt� tt Jr •, t r 1 a [�f-.. 'iSM �, � � r 1 � i:` 1 +, 1 •'1 �1�1,r1� �r7 1'' 1'�j �+}W a•'i{ � a i ,� � ,• ., 1 t 1 It t u, r. i. (' !_/ 1 ' 1 y if 7h�t; ��r11C � 1• i, tl J • + f., J ♦ .; .•+ .., lie 7+.•r r r ','/l l tl ' r"S'Ir I '�T 7� 1 fR"t'��I. ��1t{ tiles t Ir .� _ I •I .f r 1 f,.< , �` ) f •`'7� 7. I.i •7, + ',. r�yy,, yl !, (17^'. �4+ r � i IL i � � ,� �� r•'`I� ,t 5 r 1 r t !� +�� 71r I'.lr s �{ i�,k ,J�� o � � It , � � f i r r l�► r . r,�r;' f 14 SECTION 3 CMNOES IN THE WORK 3,01 GENERAL i The City say at any time prior to the comp I4ticn of the project pre mIded for herein and prior to removal of Camtractor's forces from the Pita, by written order to Contractor and without notice to sureties, Increase or decrease the estimated quantity of wank or asterlel, Mks altaratlins, davlatlons, addlttons to or cals- slons from the drawings and specl f I cottons, and make changes In the project as may be deemed necessary or advisable by the Engineer, witlln the general scope therof, proVlded that such Increase or decrease In the quantity of work or materials, or changes In the project, shot I not exceed twenty -flue 1251 percent of the total eattmatod m,bntract w1 ce. Should it became necessaryy to exceed this Ilaltatlon, the ehengs shall be by written supplemental ogremsment betleeen the Contractor and the Cltv, Changes In specified methods of construction may be msdo at the Contreetorms re- quest when wpproved In wrltlnq by the Engfnear. Changes In the drawings and spealflcatlons, requested In wr tint by the rontractor, which Ao not materially effect the work and which are not strimantal to the work, may W gre%nted, Than approved In writing by the Engineer. Except as otherwise agreed In writing, the Contractor shot furnish all labor, water tole tools and equipment that may he necessary for the performance and cos- pletlon o� the additions or extra work In a proper and workmanlike manner. ShoUld any Contract Item be deleted In Its entirety, psyment wlII be mode only for actual costs Incurred prior to notification of such deletion, 3,02 CHANGE ORDERS !10 claim for addltlonal'%work or iaterlal wl I be at lowed unless supported 101 a change order Isswd by tha'Engineer and executed by the Oontractore No additional work or other changes shell be started before the Issuance of the order by the Engineer and the execution thereof by the Contractor. Payment for such aodltichal r work sit l I be made whore pertinent on the basis of this un It pi, less bid by the Contractor for such work or If the unit prices are not appllcsble for computing the additional work, payment for au.:h addltlona I work wl (I be made upon the basis of a lump sue previously agreed uoon by the Contractor and the Engineer and sa'' forth in the change order or upon a cost plus beala, The method of determining the cost of additional work shal 1 be optlonal with the Engineer. It the addltlonaI work materleIly changes the character of the work of a unit prime Item by an Increase or decrease In the a:tuns unit- price shown In the bid, such adjustment In comrpensation wtII be the difference betwoen the actual unit price bid and the unit price represented by that portion of work Involved In the change. The change order will note such credit to the City or adjusted unit price. When the change order affects an (tam of war where is unit pr;-" Is not appIIcab I47 O the Enpireer may request the Contractor to furnish mmdequate cost data for deterel- Ong compensation for such edi ttlona l work. Change orders 'ilia I I be In Mrtting and state the dot I or vo lue of the change or ostabllsh the method of payment, any adjustsent In contract times, and shall provide for the Contractor's signature Indicating acceptancmw. 3,03 EXTRA WORK New and un:orest~en work wl I I be aIeased as extra work when daterm#nod by the Engfnw.. that such work is not covered by env of this various Items for which there Is a unit bid price or by combinations of such Items. In the event portions of such work are determined by the Engineer to be covered by sow of flit various Itamas for which there Is a bid price or canbinatloas of such Items, the reaalning por7lem of such work wlI I be classed as extra work. a 1 i as l7. r'y }f1� v • c''fio � �+r '�S'f+r� l � 1% �1 ! iix' rl 7�` +riF�+mi�l)�Y +� 1 lr L r _`�1} 7 1 1 �ri�� Z, jlS �� �1r J�,flly r •y r cm t' " � 1t� "�� i I7 ♦ ;i r- ; r 1. r r5 f r : � il�it.fK��1 a,,�^, ti����,il � �t f� .S� 1 .l.. � ,�mJ r5 �Cf r•.r. 1 1� �t � 4� � �!�fi it "�e , � ��; • fl7:' a r v1 Y ! , i�`: ml 1 l r �•J '`� !� �'-'i,' S��: S , i , ^t da �, J� ! 1l;� a rl� � if ! � :r i`' f i� fib � �i•� r r.jili�� ,ll � i f rr i rr 7 J � 1 7,J,�/ .tlfimlYT)!rYt;i lj r ! l3 • JyJfi' Sjfr S. l t+`t J 4 flu �; 'J'jo1r f.' 1 r i i✓ 1• rr , 41 At y r 7r 1 , ,<i,, � r r s! ♦r y,1�yt: ,� e 11 9t rioN 3 cmAmen IN THE wok The Contractor shall do ouch extra work and furnish labors material, and aquipsent therefor upon receipt of an approved contract chsnpo order or other written order of the Engineers and In the absence of such approved contract change order or other written order of the Engineer he shall not be entitled to payment for such extra "k, The nethod of detoWn Ing payment for extra Mork sha I I be mutur I I y agrsgd upon betwii the City and the Contractor. + 3,04 �0 CONDITIONS Contractor shall Immadlately notify the Engineer of the following conditions before they are disturbedi I. Subsurface conditions differing materially frown those represented In the oontract, 7. Unknown phyal:al cohdltlons 'of an unusual nature differing material ly froa those ordinarily reoognlzed as Inherent In the character of the work being perforaede It the Engineer detaralnes that the cho ad conditions of I I eatsrlaI I Incresae or decrease the costa of any portion of the work, a change order will be Issued adjusting the cospensatlon and extension of time for such portion of the work sit prov Ided herein. Contractor's follure to give such notification of changed conditions upon their discovery and before they are disturbed shot constitute m waiver of all elzlms In connectlon thorewith, i i r s� 9 O iLfr f It r r �1, r .�`, ,t1 ti !J , ,T t K,�=/�' �! , 'iir r}!1 '�, `f;yJ{�,rol, 1 ���.�• lilt i,� f � „+ , � `. 1 1, , � Sl ti r Y k' � r t ,�,�, � •1i �� r S1jJ;�+�n, � y� y,�}�j��l rrt~. ��{rr 1 ',}I � S I.•', r r,. +.�t1', �( .1+ 7 i,. t�' { 4I�r'Y`Jf�����•'��,'i � � r�J I r. , �� �s• �W �'r `IJBI`f17, 'p /1! ,t� � , � 1, ( � ,!' � ♦,� ( u,qrr it !y� r ���L��+"���,�:i �r,�•i����rif�'� jr, f!t r+l�`1 � 7.ri�lr �.t ��� ��{r �^�� ��Er+r.{`v��rll'�! Vi'i?,. + 1�,yi 1�♦ rr, ! 4 1 i , t r, ,; :I Y�x.{tiF, jl r ,}.dal yl Y� t � '�:+, +i� 1. �1,r r i ! '•! ! ,.t ! + {� �I 1r �� ,'- �`{ �1�� r � � t f?,��, 10 Y� M��y rl,�,�r11} { ,���r �'� t +,' � � t }� � 1 J - �''�`{ti / , S•r• r , r. � S! 7`i Y„ � _.°91 Ir.+,t r , • � rf !� . � P , .tf r , �,�; " rf ' �I r �r i 1' r {•''' �, r, l , is Its is L +.t r Nr yr, ,`r F i 1��v�i}• rP'1, 1 Y im 0 SECtION 4 CONTROL OF MATERIALS 4,01 GENEML On ly patorls Is conforming to the requlremente of the spectf Ica'lons she I i be Piece- poratad in the work. Materials, parts end equipment to be purchased and furnished by the Contractor shot I be new, unless otherwlsa specified In these specifications or noted In the drawings, and adtistactory to th+r Engineer. The mararla is shot I be m6nufacturod, handled, and used in a wrkeenllke manner to ensure ca.piste work In accordance with the drawings and spectf;.iticns. At materials shall be subject to rigid Inspection and tt, In the opinion of the Ennggineer, the same do not comply with the specifications, said msstsrle's shad be, siada to conform thereto ' NaterlaI found to be unsatisfactory wlII be oejoated and If so ordered by the Engineer, shot l he Im Alately removed from the promises at the expense of the Contractor. If the Oo►,tractor fells to forthwith comply with any such order, the Englnar shot I 'cause said unsatisfactory material to be removed and shall require such anfect1ve asterfaI be replaced. The cost of the ramayaI of the dafaetive materlaI and rep leeewent themat she I be deducted from any mloiN�r dw or to became, due to the Contractor. All artlelas and materiels shal l be of the quality, specified heroin and fully equal to approved samples, when ssmples ore requested. Ilefore dollvering to the project any Mavens I or fabricated Item, the Contractor shall notify the Engineer of the source of sold mate;lala and the Englnoer shell 110 have an opportunity to examine and tost sold materials. It Is understood that such Inspections A.-.d tests It made at any point othwr thun the poinle of Incorporation in the work in no way she l be consldwod as a guaranty of acceptancs of such eaterlssI nor of continued acceptance of mmoterleI presumed to be simllor to that upon (filch Inspectlons and tests have been made, and that lnspeetfan and testing performed by the City shot not rel love the Contractor or his suppllors of responsfbllty for qqubl,pt control. Whom requested, Contractor shall furnish the Engineer wirh a GrtlfIcate of Oofrpllames from the wurce, stating that •the naterfal substantially mwts the sreclficattons. Manufacturers' warranties, guaranties, Instruction sheets and parts (fats, which ere furnished with certain erticlt% or materiels Incorporated in the work shall be delivered to the Engineer before acceptance of the work. 4.02 SAMPLES AND TESTS Twit of wAterlaIt wt I 1 be as specifled in the City of Huntington Beech Standard SpeclfIcetldns herein and the Nuntington Beach Lnndscepe and Arborlcultural Standwe Speclficattons. Soft agricultural i;uftablIIty and fertlllty analyses will be obtained by the City of Huntington Beach end paid for by the City, unless the request is Initiated by the Contractor, who In such caca shill be responsible for tie cosis involved, Floo torts of naterlaIs wlll also be made bf the Enginear when deumsd necessary and these feats shell be made in accordance wlth standcrd p,,actices of the Clty. The 0xitractor shot I furnish such samples of at I matnrlals as are requested by the Engineer without charge, and ell labor acid equipment necessary for the taking and furnlshlrq of sample• shot be furnished by fie Contr.bo:ur. fb material shall be used until It is approved by the Engineer. Wherever reference Is sado in these specificationx, to standard tests of the Amerl- can Society for Testing and Materiels, or any ether recognized notloal orgenlza- tlon, "a reference shell be construed to mean the standards that are In effect at the data bids are recelved for the project. 4.03 M ETHMS Gf TFFSTS Relative canpactlon Sest is dosigned to determine +he degree of ompectlon of earth. A test hole Iz excrvated and the materiel remved Is dried and weighed. The volume of the test hole Is mreasrred end the weight of the dried material per unit of volume of the test hole determined. The weight Is then `ou-.! of a suftt- elent quantity, of the drIcd materlaI to till e 10 17r7Y— -. ! J .,•^-.�^ r :.L�"' ""�'_�t ?�'7 �lti tS�Tr�ri `71wr tj, 1t "� i �.. I d'ac'r+ � t ♦ 7 � � � •;1 r J t' l 'fir (Ir !! �d' ! ti.�yl �!r.y+thy 11}.• ;r f r j, r 1 i y r. t.tl + ll r ` t* +i1 VA) y R yt l: rl`\ /yr J, , t t! ♦ 'iN, Jlli '� \ r ,(( � i A Lf � %,I (�`� J�j, +i'I .f,r r41. ,rw ,�) �'a `, .''Iri ar ��i ' , ,lrt+ ;art rfl� i. f:+ 0y � .1 .,+. + • 7 ;J 1_, , r. •� •y� ��. �" .4 r! .G1�„' n� ,} rn. �ilr �!' + , , ! J �# J�e �i+jt•f 1- �1�.'7t(i+l t1(ry' �t •f t -1:► VI 1'J-,'1 ; �S :fit `.� y�r ril I` t Ii IJ �ft y •�J !11 !} ,. it �. �' r t• �� fp Jf��ir�.l7�N�^.ty[y/J.j �,�, It � !r :l �� i rr yr +! � r1' '( • ii ,y( t�r►.1♦ `rite;,+. ,I,�J��r ��cr►(lf,f llr r 1 ! �r ! 1r y r.. r ' rr•+�- �,y _ r!� i�� �4 ;�d��lf�tir��)J7tiP _ � +��j1' +� f%ll i [ wa Ifl � J7 , �r.;. Jr! J � �' .1• 1 � -1 t yt tl i� a.ne �1,�� �rt � � n,�) 16 s£CTIO/! 4 CONTROL OF MATERIAL dlasator and elght (0) inches high. Ti,s quantity of material thus deterstned is then solstenod to the proper consistency for msxln m campectlont pi aced In the raid and compacted by means of a ►ll unger rransmpltting a force of two thousand (2,0001 puunds per square inch. Frees the resulting volume sftlor compaction In the mold and the weight of the dry matey la I used, the weight of the dry material per unit of compacted volume Is calculated. Tha relative compaction Is the ratio of the dry relght par unit of volume as found ectualI In place to that determined for a like unit of volume by means of the cylinder. fhe test for determining the relatlanshfp between the rmolsturs content and density of sells shal I be In accordance with the ASTM D-13% Field density test Is designed to dateralne the percentdge of density or'thm field density of subgrade and of select material boss after compaction. A test hold Is excavated and Ind- sample removed therefrom Is weighted. The volume of the test hole Is seasUred and the weight of the ,ample per unit of volume of the teat holoo determined. A portion of the sample Is then weighed, after whlch It Is umpacted In a cylindrical metal mold ■pproxlmately four (4) inches In dionfor and IoUr nhd Ml one-half (4 1/2) Inches In height, by Means of a natal tamper having a striking surface of two (2) Inches In dlsmetet,- wl hing i!va and one-half IS 1/2) pounds and havimp one (1) foot drop. The sonipla �s compacted 1n three (3) equal layers, eeoh layer to receive twenty -flue (351 b Iowa of the tmnper. Frog the resUl ting o"pection In the cola and the weight of that portion of the sample used, the weight of the sompl a per Unit of copacted vol uwe Is ca loulated, TTra percentage of density or the field donslty is the ratio of the weight per Unit of volutes of the sample as reproved from thm tes! hole to the weight deterMlneq for a IIke unit of volume of that portion of the sample compacted In accordance hsrevlth. The test for determining the in -piece density of soils shell be In accordance vlth the ASTM 0-15". Inspection of volding Is made to control the quality of workmanship In voided Assesbl ise and Is perfamod In accordance with the 'requlrwments or the knerlcen Melding Society+ All welding shall ba done by certlfled welders and To the sails-• faetlan of the linglnear as to appearance and conformity. 4,04 SIAlST i MI OW OR EQUIVALENTS For• convinlonce In designotlon on the drdwings or In the SpeciflGdOoss, certain ert(cles or materiels to be Incorporated In the work may be designated under a trade now or the name of a manufacturer and catalog number. The use of on alter- native article or rnaterial which Is of equal ouoIlty and of the rdqulred cheracto- rlstics for the purpose IntemOod wlII be permitted subject -to approval by the Englnaer. Mhsnivar,sny moisrlal js productI thin or, service speclfter herein is described by &is or nor* brand or trade naves and Is folloved .b the words 'for approved equal", the Contractor shot I have thirty-five 13S) calendar days after award of Cori -tact ,for 'the submltslon of dote subetantleting a request for a substltuOon_ of "en approved equal„ Item. If the substitute offered la found to be equal, the Ootlteio- tor;may furnleh'elther the materiel,. product, thing or service rpeclfled, or the approved substitute. if the substitute Is found out to be •Oust to the material, product, thing or service described,, then the Contractor shall furnish the sets- risl, product, thing or sorvlce specified, Should an tpproned substitute be evil - table to the City at a Wear cost and Is furnished 'oy the Contractor, the City she i I not bo ob I f gated to pay more than the I cower cos t•. The burden of proof as to the quslity Ind soItnbiIIty of alternatives she)) be upon the 0antractor and he shell furnish Information or data concerning any substitute and, If requlred by.the Engineer, shalI Must said substitute to be tested as to Its qquellty, atrannth and physical, chemical or other charactcrlutics, or Its durobtIIt , flnlsh, cffleiency or servlow by a reputable testing ungineer or labo- ratory satisfactory to the Engineer, Submitted duta Shal I Include mmenufacturerNs, grower's or supplier's name and ad- dress, catalog number and descriptive Ilteratcre. Cortatn minor Items manufactured by notINIA1 aft r*gi0na1 SUppltars wIlI be consl- dered for substitutlon during the .bursa of ttTv work If equivalent to the items specifled, 4�"PT � (�},( ' t �f��(� ;�� <:rV• sl r r-„1,�(f;'�jt�yL h5.e'.'S , � !'� �'�• ter• �� tt� t�r�� n )�t'� 'v . �1' V{'S,t��lti�l�it� � ' )' � '. }�• t h `, c r J � • tVf1., ay.tfl.i f`i�'Ty • ti� iy71... ,.I (� �' ' it �' •� , i t `� t ! t y.'f. 1' �i �1. ��,�' �; i'. �i ` .t l,�!/', t � t !/ � 1 'Ll 7� C n; AS; t •j1'!{ � � , � : 4 f � .rl� � ,�,,�>';,.�:t�5 �`��i � r f .. • Irt�t ':' T , t e'�'�'�'i yt7ft� 114 ('q�rt1 rilF. ilex !ttl,c. ',' rltlt 1� }Ir/r?'• •,tl t 't i}J��� 1 Al, � r' ,.��, /`1TSl�! �* ti.1 �tj tt •:l}j L.�) t / �it. r 1` ' t , / ,11 1 �t,,lyl, • 1. � fif ��itr �.�� t rr ►'. � 1�lJ(iy Vlr (.Vi. i 1� / ` ,�r;�i^,''t t``I :ir1 ��/�Ir' !;'f` � !•� ..r �'t1_�. (f/ Ip {� l•r ��) ,} r 1 ._ ` ��, 1 'tl�, �5 •}i fib t )�,lr 1 f: 1 r 1 j'f t • �}I tl y.�1j�TJ1 tf ;�•1 It + ' � ,°c t r 1i,�� ,. 1, a. � + 'C� 1 (�, +• ( �t�'�1 r i{�,(!,; (I`7 rr•t � li.}+'�t 1,;r/ f ( �, +.. , t t r 1 I} 7 (�r,��'��«t4tr�,t 'i i • 1 t �,, z ' �6ff l N I* i• li �6 0 SECTION 4 CONTROL Of 14ATER IALS The speclf led Contract comp l etlon time shot I not be affected by any circumstance developing fl-cm the provlalons of this Section. The Engineer shell be the sole its as to the quality end sultabll try of alterna- tivti articles or materials and Is decision shall be Ina1. 4.05 MATERIAL PURCHASE The Contractor shot 1 submit to the City within flue (51 calendar days, one ill copy of all purchase orders placed for materials. The purchase oruor slat Include a purchase ardor number, data, purveyor's name and address. It Is the Contractor's responslblllty to procure the materials and appllance3 necessary to perform the work Should the Contractor not be able to locate the materials specified or acceptable substitutes, he should notify the City. In wtrl- tlny, of the unaval lobt I Ity of the materials with a listing of those suppi term cy, manufacturers that were contacted while attempting to purchase the me -forts Ia. The City wtII assess reasonableness of the Contractor's dIIlgonce and advise the Con- tractor of any al►ornates. If the Clty, through normal suppilers, locetas the speeifled materials or acceptobI* substitutes, the Contractor wlII be bliled for the time and costs of locating the materials for the Contractor. All blIiIngo ell be at normal hourly rates. 4.06 CERTIFICATES OF COWLIAkE he requlred by the-s specilicationsi a Dortlllcate of Compiiance shall be fUrnlshed prier to the us* o: the mterfalse A Certificate of Cwpi lance she) I be furnished with each lat,of material del Ivo ed to the work and the lot so certlfled she l be clearly fdentlfled. Ai I materials Used an this basis of a Cortilicate of Com (lance may be sampled and testadat any tlms. The fact that material Is used on the bests of a Certlfltste of 0&ipllance shall not relleve the Contractor of r'sponslblllty for Incorporating mel!sris ''' In the work whlch conforms to the the requirements of them drawlcgs and speclffcottons and any such material not conforming to such requlrerants will be subject to reijectlor•. The City reserves the right to refuse to permft thit use of matarlaI an tho bests of a Crrtlllcete of Compliance. 4.07 S1•CRAN OF IkTER I ALS liitorlels shell be stared so as 1o•ensUre the preservation of thalr quality and fltnossi for the work. When considered necessary by the Engineer, they shall be plaoed,on timber platforms or other hard clean surface and not on ;,he ground, and shall belaced under cover when ■o requested. Stored materials shell be located to as to tool IItste prompt Inspection. 4.06 IIESPON5186tT FOR MATERIALS The O)ntractor will be held respanslblo fora II is::erlels furnished by the City attar s'uah material have been dellvored to the site and until such materiels bra Incorpc�rated•In the project and accepted by the City. Deductions will be made iron any Pzneys due or to beccins due the Con rector, to make good any doss, damage, shor+oge or deficiency from any cause whatsoever. Loss shell Include demurrage charges due to dellniluency In unloading. In case of s0spensloa of the work from shy cause whatever, the Contractor shall be responsible for all materials whether furn cshed by him or by the City and shall property store such If necessery. 12 d ,•> +,:i• '� \�.sj � s��j �i r , ry ,rt t�Y 7 '+ ,1. lr�T:l S��l'6�S t��� 9++{t l� � �J� It ��t t t•1 �ti� r`�e � t1 '���, �.1/, S r t �i� ly i�•+ I� ,1 iY>t� �IS��f'C �ti l� t • f j } ..� tNC t �'� i f� [ 7 + t r� t 1 v �.:' •1'It �SV� ''t �i S"t yn!AP✓� •77•.,�.[ J �'M .;� � -If i 7 .. Jri { :�'flf 1 ♦� 'i 4 (�.yy�cr'fl rLk }t�(• J 1 � 1 i r .r� >1 1 r' t�� ;• , -.l , � r • I f' 1 : % �',� t +t' � KfC ` W 1 �t 1�117 J lti �'+'r � ii��� t r, !•�� t '•'; +,�Y t, t �1� i, ��. ' � •t ; ,t�.r ti �a,;: "� L � J� r1J- �' 1 - t•�. r .'+ t ' �.�}rl 1tJ- i.:� art, . M �� i.'i { },,1`it !'rvil J 71� 4r �},fit f t � 1t' t +t:r.. 1 } . •t7.1 � tl {i.l ilA1 .�1�4 jI. � ,jt f'� J` ! 1 1 t�i ,Yllt ly•i� i✓r''O f�'�'�`i1P1 ' ��# rsti•� t `• ��f r �•'�� lc�.''��r. r11 .. i� I'�� r !" l� -1 i7�11 �1` 1AMR --kV 1'r"µis i -.,1- l 1#(• •"rj't cam« . Q SECTION 9 PROSECUTION, PROGRESS AND ICCEFTANCE OF THE WORK & 9.01 ORDER_ Of WW AND F'i1MESS SCHEDULE f In general. It Is not the purpose of tt.ese speclflceTfons to limit the order in f which the Contractor shai I ca+"once and care/ out varlous operations. However, prior to the camostnQasent of work, the Contractor shell submit, within twenty (20) working Bays of approve( of the Contract, a proposed construction progress schecule which slows each constituent operaticm, quantity, rate end period roqufred to ecaclepllsh -ths Mork. The proposed constructlon schedule shol I show that thb work will be completed wlthlr. the time limit spe.rl►led In the bid. Further, a progress schedule shall be submitted monthly, or as requested by the Englnoer, to show the progress of the work as It relates to the construction schedule. A revised con- strw0lon schedule shall bed semltted if the progress of the work departs epprscle- bly trim the original schedule. The Contractor may furnish the schedule on a form at his choice or, It requested, tho Engineer will furnish a form for the Qantrac- tores use No progress payawts wf l I be made for any work untl I e satisfactory schadulb) has been submitted to the Engineer. The Engineer may request The Contractor to submit for rovlow proposed methods of procedure which anuserate the methods and equlpnent to ba employed during each phase of the worlY.� If At any time before the commencement or durithe progress of the work such method of operatlons eppeari to the Eng Insengrt to ba Ina0eduete, he Vy order the Contractor to Improve their character, or to Increase their af+IClincy, and the Contractor must conform to such order. -The }allure of the Engineer to order such Improvement of methods or Increase of eitlefency, shall nat raflaVe the Contractor from his obilgetlon to secure the quality of work end rate of progress astabllshed In The specifications and bid. Contractor shell (maintain copies of the submit-toi conatructlan schedule, progress schedules and proposed Methods at the project sl+% 5.02 CCMiENCENENT, PROSECUTION A40 COMPLETION The Contractor wil l be raquired to eemwee work, to'prosocuti the work dil�gg.ntly and to. camp lore a ( I of the work within the number of days spa:l fled in i-hs bid aftd,` the dots of execution of the Contract or the date of notice from ths.Englnaer to proceed. Contractor shell, upon completion of the work, dallVer possession thforsof to City ready for use and free and discharged from all elates and demands Incurred for labor and materiels required in the prosecutlon of the work. 5.03 SUFFiCIENCt OF Tlilc The tlam sot forth In the bid or the tinselfoNed by th�a spoalflast lonb for the completion at the project Is to bed considered as suftilclsgt for sUeh completion by a Orntractor having thhe necessary aqulpment, cap I.C'nd experience. unless actraor- d Inary and unforesesen cony Itlons arise. Should this Contractor be obstructed or delayed In ins prosscutlon or eompiatlon of the pprroject by the act, qeglect, delay or default of the City, or as a result of strlkas, ?Ire, flood, IlghtnIn storms or earthquakes, or by unavoidable calaalty► or ather unforosoen caUess that In the opinion of the City, are beyond the esntrol of the Contractor. then the City may grant an extension of time for the comolatlon of the project. No such aIlovance of time shell be made for any elleged fall we of the City to furnish required materials or of the Engineer to turnlsh Informetlon. The Contractor will be allowed on extension of time for changes or extra work as descrlbed In these specifications based upon the effsvt of the changes or extra work on cc" IotIon of the project as a whole but will not be granted for chendos or extra work of a minor nature unless Contractor shows to the satisfaction of the Englnssr that such minor changes or extra work necessarily require extension of time for eoarpletton of the project. Should the Englneer determine that operatlons are not being carried on at a rate sulfl:lsnt to secure the completion of tha project within the specified time, the Engineer mmy at his option and after ten (10) calendar days written notice to the Contractor put on such additional labor or equipment as may be necessary to br'Ing the work to a proper state of advancemonr, and any actual tine) excess cost thereof to that City over what the wrk could hnvo cast at the Contractor's rate shal 1 be deducted tree. any sums due or to bacane due to the Contractor. Failure of the 13 ..-�"S ,�.�,.�.."wr'��."„�t'� "T t r T ,^ ,•1i�jn "1 r'�' ,c �'f 1. a ,,t.,',dr. , c, ° {: 4'/+Y.� Y� S , �}t `S + r .4 l ° t • I� 54 ! I°��y1' �L'1 V 'i��,. / ;.�(1 Li;.} 1 + 1 1 1 l:h '7 err, 1 J `; tl � rl ` ✓ 1, � ^5�{ �'i�� .I 1 1% f "Uf Skl rlr {r ,1 tJll 1 t t ° t{l� t S' 1pri � � ?f , •r r f ��f f V` V '(t<��, ' j + 1 1 •.rr , f 1 1 }fl X 'k �o+4j 11 1 � r � rt •{ { �• 1 (t '}, 1 �' f +L � t•r�[ 1 f , rr 1 ,1 7!c iAl 7}lt'/ �N +��i, V 11 (• L •,� rfJ ' + t '•'�l y t,f rl rh try r t 1j11r li4�r`t Ir �J�Ir., `�r.1t It tttt,,1f 11L1���(( � � { rr �'; � Y � { f ,� ' � � •r��, 11 '/ w(( r'��tr yl� °�.�1 �rf / i. r'r {I i .J , •. 1 S , r. •,fl 1 r , i + 'wy(!'! tf,rr 1r} ji %;�i r,i•1, ,',;�,t< rF(.f �f• ' 1 r t'} �'.ra ' 1•./ �!tV,'....( s SECTION 9 PROSECUTION, FOOCiiESS AND ACCERi'ANCE OF THE WMK Enylnser to serve wrltten notice on tits Contractf- to put on addltlonei labor or oaulpment 511411 not relfcve the Contractor from his oblfpatlon to secure the quality of work and rats of progress established In the specifications and h1d. My and ell extensions of floe granted under the provfslons of thou@ specifications shall not release the sureties on The Lends accompanying the Contract. Sold bonds shall rasoln in full force and affect untlI completion of Mork anelor torolnetlon of Contract. 10 5,04 OONTINUANCE OF WORK If the construction of the project Is not completed wlthln the time specified In the Contract for completions or within such tfas as may be extended by the City, the Contractor the ll continue such. construct ion in accordance with the praVislons of the Contract and unless othorwibo at any tine requested by the City In wrltlnp sold Contract shell reealn In full force and effect until the ewpletlon ct and th• acaeptance of the project unless said Contract is forr4l IV suspendM or terfolnetsd i In arwrdtnco with the terns of the Contract. 5.05 STOPPAN OF WAK AND kMIJLWNT Of COMACT It the Dantractor fells to a mtence construction of the project wlthln the specf- fled time, or it,+he construction of the project be abandoned by Contrmtorg or It this Contract bir seslgned or the work si'41st by the Contractor, @xwpt as herein speclfled, or If at any time the Englnedr shell be of the opinion that the perforti,Mnce of the Contract Is unnecesserlly or unreasonably delayed, or that the Contractor Is ofIIfUlIv violating any of the conditions or covenants of the Can - tract, or is executing the same In bad fslth, or not In acewdenae with the terpse thereof, the Engineer may notify the Contractor not to roo m# or to discontinue as the case may be# all work or any pert thereof contampleted under the Contract V a written notice served upon Contractor, The Engineer shall advise the sureties that they wl l l be iven f ive (S) rorkln9 days wlthln which to arrange for the coop) ton eoc of the prefect in ordance with terms and conditions of the Contract by doo her contractor satisfactory to the City. Should the sureties fell to effect 111t1b aa- tort' srrangenents wlthlh said f Ive M working day period, the Engineer rty take Intetedlate pabsesolon, on behalf of the Clty, of the equipment and nistorlals upon the fine of work without further notice to Contractor and use said aqulpment and saterlals to complete the prcj@ct. The Contractor shall not remove the equipment or any part thereof or any materials from the s,lte so long as the some may be required In the completion of the i •oj ecfs If the City takes possessfon of the equipment and materials, It tray "ter Into another contract to,'.+ho completion of the project contemplated by the Contract or otherwise undertake the completion of sold project► or such part thereof as pay have been suspended and teat' use such materlrls and, equipment as ,nay bs found U?on the project sits and may procure such other materials, labor, and equipment as may be requ red for the completion of sold project, The City shali charge the expense of such equipment, labor and mta+e-fals, plus ten (101 percent of the cost thereof, for administrative expemss &gains+ any sums of stoney due or to beccme due the Contractor, or against the sureties to the,oxtent of thelr Iloblllty, In the event that the total expense In completing the project exce@ds the Contract price, plus ouch additions or less deductions as may have been M melly approved by the C!ty, but is less than the eforeseld total sum plus the amount received from the sureties on the Iahor and materleI bond and ".a falthfuI porforwAnce bond, then and In that event, the difference between sold sum and the actual cos` of the contpletlon of the project to the City, less any legal deductions, wlII be returned to the surotles as their interest tray appear. When any particular part of the constructicn of the project Is being carrI0,d on by the Contractor, by contract or otherwlss, under the pruv slons of this Sections the Contractor shell continue the remainder of the construction work in conformity with the farms of tte Contract In such manner as In no way wlII hinder or Intorfore with the pwrsons or workmen empluyee, is above providers, by the City by contract or otharwlst, to do any part of the work or to complete the same undar this Seatloi. 14 i ✓ i;�� �,.. e� 5,?1 � t 1 � � z � '�, ��t i���"� Tyr" r�� I r ,t��) i'� fSh�%� '� r-i= t�/ttYti,n � �y��•. •gip{+ r �� 'fit =}�t:: L: �ti tit Ji> �ri�l�'U r I rH Y t f •M.T >(a T l {Il 1. Yl ( . 1 )r` 1�� t 1 _ �T rta rtl ,� Sri � t:' , ,1r� � 3JiY•i�T�la � 1 � e r �: i r��Y lr ';t ivt� Y,� t r. J ��, P 'S r ( �:�t �. 5r "i ■ r•�, tt sr, t ) t I ,t ,1 r ri � .T ,tt ,�Y � lr K�'"(�,����t7 Y�';r j. r�� r i ' � t.i 1! 1i�T!r �t� j ,: t• t ' SY�1`�°'R��. fii(�. A. r i o f , r■r_ l r jY , +1 „ a / f . t ) jt . M, �' Y to ' d4 � � • /5t i �' . { •1` .C.. ' ` 1°, ♦. �• I } ' liar i'��� �F� �,�� , �' !♦'I rrY �' e j t_ r•, ti• %5'rT7 15 l t 'Y A ��. 1 `t. �rfri,r /�(l • t' S r t ! ° r /. 5f 1 1 �'� Y��14 15 s Y� �l/�l r. , �' jf3t 5er �..n I �y. S91 :AJ• 7 , r ' i - " t '�� `}f�� - { hy��1 �� � L�'��� :�1Y d ,'�{�S1 j rt4 IY� J 51 r j 5 +i{ ti t %y 1 �,f' r �}'�,�j ��fT . t � r ` � t� _ 1 5 � , } v�.. ' it �� - � �� l�t . � ✓4:�} + ��;�'S�r{��� � xliy�,l�i '{ el{ J rt rj 4 r .t r t I �+ ,i' ` }�•�� S ' ���'��yt,��Jr.,{t ',.St'/TTTT '•�.N' \r c 0t J }1 rr rl� X Y i 1 ! i .rt 1'r~�. a 1' 'r�r T� :Itl r ,` 4• 1'r YeY. ,. 1 .t, 5t , r ( t ,� t t�� �� 5/ r r �:i' `_ t' •r ! )�i 1: t�. r _ ,���� 1�f,,'�{ a '!.5•tl�j"1 'fit•I � ° � r � .wit � {; �. � t }t•,it'd t � 1 y f `Y.�j , Ott ..r >•: r.,r�ftYt ♦T1,,;�I`tr' •+• t � `,. .°C °J •r i7�' �(1 -c,tia ' i � _ ' t _ . � _ _ . _ _ .. _ — _.. - ' - - _ _ �' _ _-�____. - _. _• a '� .—�1�1 ido SECTION S PROSECUTION, PROC41ESS AND M.'CEPTANCF Of THE WWK In the event the City undertakes to hove constructed the Project, or any part • thereof, the csrtlflcate as to the amount of Mork perfornwd and materials furnished and the costs therof, and the excess cost, If any, of eoorkleting the project contemplated by the Contract shall be conclusive and binding upon the Contractor, assIgnses and sureties. In'Ilet,,of the foregoing provisions to suspend the Contract, the City may pay the Contractor for the portion of the pro:act previously constructed according to the provisions of the Contract and may treat the portions remaining uncompleted as It N said protlons hel never been included or contemplated by 0! Contract, No claim under the provisions of this Section wl11 be allowed the Contractor for - prospective profits on uncompleted portions of the project. 3.06 TEWMARY SUSPENSION OF UM The Engineer ray order the Contractor to suspend the work on the project wholly or • In part for such perfcd of time as may be doomed no due o unsuitable *•other or to such other conditions its *ray be considered unfavorable for the suitable prosecution of the work or for such time as may be domed necessary due to the falIure of the Contractor to carry out orders given or perform sn•l provlslon of the Contract. The Contractor she I I limited lately respect the written order of the Englnear to suspend the work• whol ly or In part, as the order nay provida. *fork shell be res uned when conditions are favorable or when the methods have been i corrected, as ordered or approved In writing by the Engineer. 5.07 COWENSATION FOR DELAYS Contractor shall not bs entitled to any additional compensation or so extonsfon of toss for delay, hindrance or Interforrince in the construction of the project unlibs the City falls to ecqulrs a right-of,way for the project, or It the Engineer :Iva ,falIs to the necessary pemisslon to proceed with the project for an unreasonable time after the avard of the Contract and as a direct result ihsroof, the Contractor • sustains loss which cou!d not be avoided by judicious handling of Contractor's forces and.squipment. It t6a Ountraetor claims loss for the reasons above stated, he shall present to the Engineer a written request for ralmburswent within thirty (301 calonder days from and after the calendar month In which Yht dsrnags cr toss as sustained. If the loss for which.ralmburonment If sought Is sustained In more than one 01 calendar month, or If the repairs made necessary by negllgencs are not completed within the co(endor month, then a separate request for reimbursement mutt be filed with the Engineer for each succeeding *month. Ths. flllnpp of the request for relmbarewment with the Engineer, together with a develled Itemized statement showing the various Items making up the loss or the various items of expenses Incurred, shall be a conditicn precedent to the right of the Contractor to recolee rolrabursement. In ti+a event such c laim is made and I lab( I ity on the pert of the Cit��rr is found to nclft, the Contractor shsII be paid such amounts as the Engineer tinds to of fair and reasonable compensation for such loss and that the loss, or any part thereof, could not have been evulded or reduced. In any event, the Contractor shell not be entitled to recover for loss or anticipated profits or Indirect loss of any kind and no Item shall be Included In the claim other than necessary payments for It le time and charges on equipment. 5.06 FANTiAL ACCEPTANCE The C!ty may accept and take possession of any comp) ated portion at the project before completion of construction and acceptance of the work. Such partial accep- tance shall apply only to the particular arae accepted, and shall not constituto acceptance of any other portion of the project, nor relieve the 'contractor of any of the provisions of this Con tract. The Ckrntraa'tor wl I I not be required to reclean such portions of the improvement before acceptance of the work, except for cleanup made necessary by the Contrac- tor's operations. Nothing In this Sactlon shall be construed as rolisvtng the Contractor Iran full responslbllty for correcting defective work or materials. 19 r SECTION s PROSECUTION, PROORESS AND ACCePTANCE OF THE WM 5.00 tYA�IN� ESION AM ACCEPTANCE Contractor shall request an Inspection of cohatrue-Ion to begin the Post-Instill•- tlon Maintenance Period following the thirty 130) calender day Plant Establistm it F%rlod. Contractor shall request an Inspection for acceptance of the work at the end of the sixty (601 calendar day Pbst-lnstaIIstion 04 Intenence Per lode Both inspection re usets shall boo made to the City a minimum of seven (7) calande►• days prior to the inspsetlon. Contractor shall submit to the Engineer prior to the inspection for acceptance of the work all aatelrlsIs as required by the speclflcatlons. If In the Englneerie Judgement, the work has.been completed io accordance with the drawings and speclfieetlons and is ready I-- acceptance, It will so certify to the City Council, which may accept the co►splsted work. The Engineer will, in Its csrtltlost fcn to the City CounelI, giva the date when the work was ceapIstede This MIII be the date when tha Contractor is relieved Iran respons lb I I ty of meIntaI"Inil and protecting the work, This wl i I s iso be the data to which i Iqu Idated der.agas *I ! I be conouted. 1.10 GUARANTEES Unless oth•rwlss`specttied, thr Contractor shall gurfrontee that the work parfommod under th@.(bntrsct,,wlII be free from dalects of workmanship and naterldla for -aperiod, of one (1) year from the data of acceptance of the work and shell guarintae to assume responalbIIIty for costs Incurred for rspafr or repplacement of anyy. de- feots' In ►usterlals within that period of time not due to tbn City's or otheref fapropw or careless owstfon of the structures or eqquipment.' Whenever In thaso bpeeltloetlons wrlttyn querantees are requested, or different periods of time are ap"Ifled, the Contractor shell guarantee the products or installatlone therein described for the time spaelfl•d and no furth,*r guaranis* shall be required. if deteoflve imeterfa l or workknship Is dleeovered In the work requiring repalrs to be made under this yuarentee,' e11 such rapt Ir work shall be done by and at the expense of the Contractor within fiva (9) owking days attar written notice has boon given try' the City. Should the Contractor fal i to repair such dan1ja within f Iva (3) working days thereafter, the City asy hake the necessary',7wpatrs and charge the Contractor with the actua 1 cost of of I labor and material r44ulrsd. In anwgencles demanding Imed late attention, the City the I have the right to rspele the defect or damage and charge the Contractor with the actual cost of all labor and nletnrlal required, / 'iwYt ` '►t !'i' r i7 . 1P' �� �! r �:;� �1� 7 illAl,�7(j.�i }C �.:�fi � - ! 7�� ' r!,( }�� r y •,Y,�1' ?rl( i �•") t�;. ��j�ji1��• M1ttiL tflf ;.+�jt �.r` r! sf, �, rr,�; ,i.-,'1 r;�il r 1•..st 1 1��1r ij ,� ��C�'4,�;,G�.•< ] <r,'I! .... t •�! r }�{y+j1� � ,,'�, , t''t + ' � .�� ('�l } �t ..a �/dry"1• l Ire ji 141'�1 ( � �, j- L,i• � IFS � i ! ij .i '-� r 1 lr�� �� r � I bi ,r Mi{i�i•'-i�j�, 1. 1:�•lf ,yf. �� Y'. I� i .�;: \t� .� Sri r lY. ,,�����';� i 7 �r � ! ! �jh � {i t wit r. ' .1. 1�� lid,: �, 1 Yr! �•. yL�t 1. §ik. i r,r?' 1}?ti ' � "� •.i ,1 � 1�{ 1+. 1 !) i��ii �ijl ir; ��_ !1 /���� iY, � 1 i i,t i rt :'•7 iY .. , � I '(1 •f, '1! 1r t�rl �r ri}1�;..j\i(pp� C•{11H r'Slr lam. lrili 1, i. r jli ! i)i.%Y ! � t111�1, atl�'1 ' 1 J.��j�it7 il•{Y��ltV ��• 1� r� �.�rl r! r, i �fr' 1 1 ��1� slit ( i�• .t, r !r ;1 r ( } i'� 10 J �t •r���Fw +�� I Jt � ,Lr•r�A J<.}i�' r rT • t PP St, l-�) , , � a. h `..tt ' 1 3!n!�•"�'.��'t��'�+r..r'f�R.'�ti�t�`a���;,�'�":; �r :'.'r�'t�if,�?"�. SECTION 6 RESPONSIBILITIES OF THE CONTRACTOR 6,01 COKMWTORIS EQUIPMENT AW FACILITIES the %ntraetor shall furnish and maintain In good condition all equipment and feel lltles as required for the proper execution and Inspection of the work. Su:h squlpment and tact Iltles shall meet all requirements of applieabI@ ordinances and laws. Contractor shall furnish and Install temporary field office fset lltles of neat and subs'.a•IsI construction. The faclIItlen shell be Iacnted where requested by the Engineer and maintained In a safe and sanitary condition at ell times untlI Inupate- flon of constrovIon/ then removed from the site. Tolophone service shell be provided and removed at the expense of the Contractor. 6,02 MON OANSH I P " LABOR Al I work shall be done and completed In a thoroaaph and workmanlike wanner by mechanics skilled In their various trades. Al I work which Is not acceptable or which has been rejected sha I I be remedied, or removed and replaced, by the Contrac- tor In a manner acceptable to and as directed by thm Engineer. No compensation shal I be e I (owed for such remove I or rep) scemsnt. Only competent war Itmen sha I I be amp I eyed on the work. My person emp I oyed who Is foarai to be Incompetent, Intemerats, troublesome, d f rorder ly or otherwise obJea" tlonwble, or who falls or refuses to pet'form his work properly and acceptably, shah I be famed lots IV removed from the work by the Gbntractor and not be re-emapIoyed on the work. 6.03 SPECIFICATIONS AND CODES Reference Made to other speclflrotlone and cedes refer to editions In affect at the date bids are reeelied for the project and Include all addends and errata prior to that date. 6,04 LAMS TO BE OBSERVED ThsContrec�or shall be fully Informed of al I existing and future State`and National laws and municipal ordinances and regulations which In any manner affect those engaged or employed In the darks or the Worlals used In the work. or which In any way effect the conduct of the work, and of all such orders and decrees of bodies or tribunals having an Is Jurlsdlctlan or authority over the sans. If any discrepancy or Incenslatency dIseovered I•,1 the drawings, spectflcetlons or Contract for the work In r4latl.on to say such law, ordinance, rogult0lon, order or decree, he shell forthwith report the asom to the Engineer In writing. Contractor shall at all tines observe Ind comply with, and shall cause all his agents and employees to observe and comply with, all such existing and future laws; ordinan- ces, regulations, orders and decreesl and shall protect and Indemnify the City and all Its officers and agents and servants age Inst any chit or IIobIIIty orIaIng from or based an the violation of any such law, ordinance, regulation, order or, decree, whether by himself or his employees. 645 EIOHi-Hf)llft LAM Pursuant to the provisions of Arlit(w 3, Chanter !, Part 7, Division 2, of the Labor Code of the State of Cal lfornl;, ISactlons 1810 to 1015 Inclusive), eight (8) hours shell constllute a day's work In the p•"iormance and execution of any work that nay be performed within the State of Ca l i forn la under the Omtract, and the Contractor shell forfelt, as a penalty to the City, twenty-five dollars (S2.%OO) for each laborer, workman or mechanic who may be employed In the SteTe of Callfornla In the execution of the Contract by the Contractor, or any Sub- contractor under him, for each ctlendar day during which such laborer, wxkemen o"- meehanla Is required or psrmltteo to labor more than eight (S) hours In the perfor- mance of any work under the Contract. Provided, however, that Ir accor"dence with Section 1815 of said Labor Code, work performed by employees of contractors In uxcest of eight (e) hours per day and forty (40) hc!rs in any one (1) week at nor less then ono and one-half (! 1/2) tiaras the basic rate of pay, 17 /fo t. 7,', t t r ", r1,' 1�► 1 4�j �J� n' •] 1 't/ `, I} 1i r• 1ti " t, 1r�t,� ri tp ", .r,�,'� t ,)��r 'i; t � t !� r.♦ �., 1 �,,r �; r , �i ♦ t Y t1► �/A;I � rf �<L '+r ih I.%{;}'� ��'i !1/Y It 1 + rit.� ?'� +�'� �A r, �:i/rsY,+},►�rf .f'i �` y. 1 �,p J J I � Ial 1 /!a J► r,tI $: +. pt"t� 1 't it Y► til " ' ,` +t,� rtr ..", t ti tit Sl r 1', +, � Y,�I��. � �' ,In 11 �r�1�IF 'j ��!r tit �l l� ,: .1t'ly, t w•i� ;t \ t��'�'�.�,Cl°� 1 ,._ }�r l� 4 � 1'r► 1%S 't\t , t 't,• t 1�,•. + l/r ♦ Ij *[,r . tlIr. y `il •.t rf c, J r,. 1 ' , . ;�1 .t'C 1'r a, iL�� r��+• S r r S t r 1, t •t , 1 ,r. ��.1;, t ti $1Jr '1; , t , it :.l , r, i , µ ... t I ) A • f ,J• tr� JttYJ�,�,>("1�! , , t t,A rt�♦ 't . +r•1 ri, " ) - IJ i 1 r t�ti t,`4,.i..t �Ir r + 5 F. .'+fir dL11�¢ �I t .�� r,c, ,r i,a .t �, 1 1 1 �... tt t `+tr ♦t,,.� ` ,07, ..t to Jl r: Ir<K lt1►.S 111�'!.+'1 �.:. t,� ��+; r � ? ` Sid •,' �ti rMJ�,f; tlyRr�'" 1 T 4 a r.: rh t. •, ar tit 1 01 ;l rl 1.• �jirw 4ti . !'1 { r f• S {1 J t J �Y, 4+!"ti r y`*,at1 +It� } 'Ily�ra4..-. 1,•; �e„f �ry{i! Fdf�i: tll r r t + r'�a+v~�:S'��1� i i 4441 Rr'd R!• i IFJ� L SECTION d REZPONSMILIT1ES OF THE CONTRACTOR 6.05 DES P14ITION OF 11DRKINO. DAY A working day shell be an �r ley other than Saturday, Sunday or such other holidays -as listed in Sections 6700 and 6701 of the governmental code of the State of California, on which the normal working forces of the Contractor may proceed with the regular work for at least six (6) hours toward completion of the Contract, unless work Is suspended for causes bayond the Oontraetoris control. 6,07 FAIR EWLOYNEHT PRACTICES In the performance of this Contract, the Contractor shell not discriminate against any amployes,or applicant for amployment boauss of race, color.nn ''rsllgl, ancestry or national origin, The Ointractor shelf take i"fimatIve actlon to ensure that applicants ors employed, and that employees are treated during esploysssnt, without regard to their race, color religion, ancestry or notlonsl origin, Such action she I inel uds, but ,not be I (mated to the fol lowingt asmployment. upgradIny, dawo- tlon or fronsferl recruitment or recruitment advertlsingl layoff or terwlnetlont rates of pair or other forms of comensetlon= and selection for training, Including apprentices 1p, The Contractor shall post In conspicuous places, evellable to sssployess and applicants for employment, notices setting forth the provisions of this Fair employment Practices paragraph. 6.OS koya�4"•'1 or EWL, OOYKFS AND OTMb The ` Wntrsetor she i I take such precauf Ions as are n0essary to protect workmen engaged in the perlermenee of the work %peelfled and to orevent accidents or injury, to such workmen or others. The Oontractor shall comply with all safety orders a' 9 tht Olvlsloo of Industrial Safety of the State of Call?ornla Incofar as the son pertain to the Contractor's operations. Should any unusual or hazardous condition exist by reason of the work to be performed or should any unusual or hazardous condition InvolvIng a pecuItar r:.k of bodlly harm to worhow or others arlce, then the Contractor shal I take al l precautions necessary to protect workmen and others. The Contrector, during the porfortsance of this Contract, shel l cwaply with the provislons of Aeflzle 1, Chapter 4, of the Labor Cods of the State of Callfornla pertaining to Werhmenns Compensation and shal a furnish proof to the City of such coepllencti. 5.09 OHS M AND CARE 7F Pf1OJECT The Contractor shal I asslns ful I responslbll Ity for the, safety of his amployess, plant and saterlels, and for any damage or Injury sustained by or to then from any source or cause whatsoever during the performance of the Contract and untlI occsp- ® tones of the Mork. 0.10 FIIOJECT SITE MAIM E Throughout all phases of "Structlun, Including suspenslon of work, slid untlI acceptance of tho work, the Contractor shell keep the project site clean and free from rubbish and debris which may result from project operations. MotsrlaIs and equlpment shall be stored on Ma site In a neat and orderly manners and upon cospletlon of the work and before final Inspectlon the entire project alto shad I be cleared of squlpmnt end unused matertals so as to present a set Istactory clean and neat appearance. costs Incurred due to cleanup operations shelf be as included In the prices bid for thok varlous contract items of work and no separate payment wl I i be made therefor. Care shall b6 taken to prevent spillage on haul routes. Any such spillage shall be removed l/seedletely and the area cleaned. Excess excavated mattrInI shell be removed from the alto immadlate ly. SuftIelent naterlal may remain for use as backfIII If parmltted by tho Engineer. Forms and fors lumber shall be removed from the sits as soon as prattcaI a'ter stripping. No materlaI other than clear water, shell be aiIowad to enter the Clty's drainage system. water rcimo%od from excavatlons shell be disposed of In a manner which wlII not interfere with the operations of others In the ere&. le . ,y L �`i (—�,:.. r 1 r >,�, "L t +T•.� lir r~!7[� {I� i . •.Lr' p i ,� ,�.{f.• � I�S ' t 1 I�Y1� �i{f7 � {f�'J �4 1� b +!/� , J n r ry `�ry.i. , + V f / 1, , , ► t 1 Tj 4,Y i, � � v 1 {/��jr , 1 !, I I �i � j S r !,J' u P 1x��j I, t w'i'f."7'it 11 J t��L7✓;;, li i,r�lulro � { � 'Ir 1 /' 1{ ;'..��t +' � ,i ,.f ,.�� ,/�' I! �c +; 7 >, ,� ♦j ,JIrjJ't,�/ z -.1t ,`, +1� , J' ,: C� , 1i 1'I e I! r (ty�V1 ,�f ,� {, ,9� � 3+. 1 �.. �� I -• �1 1 , j l y 1 i .N Jf f dJ! „ t yYj ♦ t)' + , t ,': 1 �) a , .� ,' j 7f'�.,n ti`,P ��t1 1?�'� 1l •� '1e 1Y � t+. •fl tta' 'y� �' ' 1'r.l, 1 , 1 , � 1 •. , � • t � f.l 4t: 1 ! ' � ., 1 :1 �,, , 3 i � r77 Itf1 4.:•�/� I c ' �! � i., t, Y r1 .� �,1 v t•.f.� ��`Iw��rY' 't+ 1 ••1 t 1 ' 1 } ;{' yi ;I` 1 , ' 1 .t s'y� 1� ti�la 21 1• SECTION 6 RESPONSIBILITIES OF THE CONTRACTOR Fal turn of the Contactor to comply with the Engineer's cleanup orders my rdsui t fr' an order to suspend work untlI the condition Is corrected. No additional compsnsa- tIon wlII be allowed its a result of such suspension. Sell AiR POULUIQN Contractor shot I eompl y wl th a 11 air pal I utlon control rules, regua letlons. ordina- nces and statutes which apply to any work performed pursuant to the Contract and shall not discharge smoke, dust or any other elr contaminants Into the atmosphere In such quantity as will violists the regulations of any legally constituted a0ha'live Material to be disposed of shell not be burned. 6.12 SANITATION * The Contractor shall conform to the rules and regulations pertaining to sanitary provisions as established by the State of California as may be applicable, and shot t leave the work area clean and from from nulsence, Contractor shall provide and maintain, In a nest end sanitary condition, enclosed tol lets for the use of eRployses engaged In the work. Fool.11tlet shot I comply with all applicable Iowa, ordinances and regulations pertaining to public health and smI tatton of dweIIInga and campse Sswags flows shell not be Interrupted. Should the Contractor disrupt existing serer tact IItles, sewage shall ba conveyed In closed conduits and df1pos1d of In r sanitary :sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfI11. 5.13 1EMPOWY LIGff'i, POWER AND WATER At temporary connections for electricity and power necessary for the prosecution of the work she I I be subject to approve i by the Engineer, Al 1 temporary I late shall be furnished, Installed, connected and malntalned by the Contractor's expense prior to mcceotence of the work. If fresh water.is required at the site for the prosecution of the work, the Contra- ctor shall apply fa• service Iran the Dptrtment,-)f Public Works and shot I purchase and Install water meters as shown on the drawings per City of Riltington Beach Standard Plan 0603 IntluAing of appurtenances end water motor, U1tlI acceptance of the work, the Contractor she II pay ell charges for any fresh water necessary for, the proseoutlon of the work, running of temporary pipes that may be required nad sha'1. rn completion of construction and prior to the Pbst-lastsllotlon Nalntenavtc+a Perlod, remove alI such temporary pipes from the work. The flow, acceptance and pollutlon control of rater will to sa stated In the City of ffuntington Brach Standard Speefflentlons herein. 6,14 NOISE CONIROL Contracror shall ooeply with all County and local sound control Arid noise level regulations a,d ordinances which apply to any work performed pursuant to the Contracts end shell make every of fort to control any undue notes resuitfrig from the construction operation. Each Internal combustion engine 'tsed for eny purpose on the project or related to the project shall be equipped w14h a muffler of a type recommended by the wanutocturere, No Internal combustion engine shall be operated on the project without Bald muffler. Sale noise level re4ulrement shall apply to oil sq'uipmentonthe projector related to the project Inrludlnq but not ilmlteo to trucks, transit mixers, or transient equipment that may or may not be owned by the Contractor. The use of I oud sound signals shall be evolde6 In favor of light warnings except those required by safety laws for the protectlon of the public or Contractor's personnel. In rssldentlal areas, working hours shall be as stated In the City of Huntington Beach Standard Specifications herein. 19 n'N v v'�q� 1 'y4fl�F if ff4 i ti rt t i� Alto, ���; 7' I J It { }�.-"�'w � 1�.11{� r2q+� � f i Y, 'p�il'1 1.II ,:• ' i��, ff'��Li 'ram} '1 ��! �<1! 1 '+ 1 ��, �1.11 A� 171 rfj f� i(1� ' •,f .+I /. ry,i�,7 r. Ly ''�, � �����Y��( � f • I�dj'it���'y1 t.;J (t �iJ��iJ,u 1 t, f(r � � ' }'}. r �,'' 'cI''.�td ' "!: ! }} .� !f ��,+:. ts~ lr��. ,.,•. 1�'li., (( �/ I (i';i L I j (fq° J �iF 1, r �� i f ' '" y ipt{ .�'� ,-.trt�}y�,•�' It 40, i, +;"7•it l.�r ! tt; �! Jf _ ',� .�� r. IY II 1, ,+U I+� I��• f �:i'�t � n"i � � , �' •'r �� it 1 'r /:�� , e ��� Ill}�':. '�f�. v� },f �•,+ (j i' 1 it �C �, ! ' r, s r a i f' .• �Wy4'lfla� 1'`i.:L,ty�! 'yl[���r} '� ` �.. %�� Lr }'hf •�+tt ri 1,,A, ,.fey, 1�.41i : •,•+`i !, � ,rl� .�" 1 V' 1 �i �,��e,�n }tip i�,r( ,} `•l "{ 'rJr„��+ Ic I* 16 04 E r y.. ..t � `rJ _..'Nhr .- _ .�;' E�:>r . y W .. Aw �t - !. ..� 1'L - ear. �'+•k-} � ��t9 a ! h _ - - ♦ .. . •f r `RRl ..7 ,'.�, �F�h�sF; r..''. .?t•r1 rr:..�T-i !FfrY SECTION 6 nEspoNsleILITIEs ofr THE CONTRACTOR e,15 PESTICIDES Contractor shell amply with all rules and regulations of the Department of Food and Agriculture, the Departmwnt of Health, the Department of Industrial lie letlons and all other agenelis which govern the use of pesticides required In the performance of the work. Pesticides shell Include but shall net be Ilmlted to herbleldes, Insecticides, fungicides, rodenticldes, germicides, namotocldes, bactericides, Inhibitors, fumigants, Mal fonts, doslccents, soil siarllan'ts, ens repellents, Contractor shall apply spray chemicals when elr currents are stlII; preventing drifting onto adjoining property and preventing any toxic exposure to persons whether or not they are Ire, or near, the project. 6,16 DUST CONTROL the Contractor shell abate dust nuisance by aIeantitg. sweeping aid sprink Ing with watsr, L other means as necessary, and shell save the City free end harmless from any claim for Ices or damago sustained by others and resulting from operatlons on tse project siteo the use at water resulting In mud on *he publle streets will not be permitted as a substitute for sweeping or other methods. Contractor shall hemp paved areas accsptabl; clean wherever construction, Including restoreflari, Is Incomplete, Mailer for compacting embankment aaterialti subbase, base and su0mcing materlal, and for laying dust shell be epplled by osmas of pressure -type distributors or pipe Iloos egtiipped''with a spray system or hoses Nlth nozzles ti►at wi1I ansurs a unIIarm spill lostldn of water. Al I • equipment used fk.. rho appl Icetlon of water shal I be equipped with a positive means of shut-off. It a dust pal lotlva Is requested br tills Engineer ft'r the praventlen of dust nul since or erosion control, the Contractor shell apply a mixture with the water bells poIyywsrer atabllint, Ilordons oeotech, or approved equal, by mans of a pressure - type dletrlbutor truck equipped w!th a spprray systo% Compensation for applying a dust pal lative shall I be omsleered Extra Mo'k as specified In Sect?on L No separate payment will be mild e for any work performed or motor IaI utilized to control dust resulting from the Contraetor+s operstlons. Componsatloo will be consldarad as included In the prices bid for the varlour, Items of work involved. 6.17 UTILITIES The arlstonce.and location of any underground OfII ty pipes or structures shown on the drawings are obtalnWity a search of the available r4corda. Approvil of these plans by the City of Ountington Aeaeh dots not constitute a representation as to the accuracy or eospllateness of the Ioea',I:.�,or the exlstencs or non-existence of any underground utl;Ity pipe or structure 411-hin the lfaits of the project site, Contractor shell take all due precautlonary means to protect the utility sines not of record or not shown on rhea• plans. Inforowtlon related to existing utfI Most sly be 'obtained from Underground Services Alert. 000l422-4133r Contractor shalt determine the Iccatloa and depth of utlIItfes, including service connectlons, which are Indicated on the drewlhgs. Compensatlon for such work shall to considered as included In the prices bid for other items of work. The right Is reserved to owners of publlo utlIItles to enter upon the proje,st site for the purpose of making rr+peirs or changes of the property that may be roads necossary by the work. The City stealI also have the privilege of entering upon the site for ta+ purpose of repalring seers, water pipes, gas pipes or other pipes or awdults, .or making house connections thereto or repairing existing culverts or stem drains, The C"tractor shell provide protection for and shall not dIsturb any sewer service funotlon or house connection that may, during construction, be found located In any plsoe that Is to be occupied by some portion of the project which is to be oonstru- eted under this Contract unless a written permit is first obtalned from the Enginser. 20 ~r1 1l tit i �S �'i'/�! �}V,r•y ,11 ter• � r,'ji ^•/+f ..�% • ,'. � ,:IT � 4K'i: �trr r��MP r•S�}11L 1,4V'��,1K v r Lr !'i' ,•'� - r : y . -'t ti r �� �7 h r j C , �? +r i('Ni w aye 7 � vLrIr1J. -:rli}, i { !-tf'1 L g � .SU•`1''. , , •.. i f..+ 1 ! .1rf.1.: r_'��. ,r'1. ��,", �� �t }+ ~�•�1 ; -rffA� 4., L r ri I fi it rr: �+ �t � i y t (3lflir tI Y I+ . iC tY r '� yy, t i jd 5'' i� ! SF r � tj � ,,' ,, w, ;� f-{ir 1`i �)fl� •��u♦t' 7? 1•ti I ,� lirltrr 'r r1 r�T -•.r�;l/y;. r,'J .w +A � Sl, •;. rr(t. �r�" ♦�'E, r , l+ aYj !!C , '�j.�, „" � •. ,t�r�. •1-J 13 11 r}' it } , ,1 ,clr I ill +1 r�•-1 r + 4 '0. 1 T i1 -E% ��,rr jti rt 'r� fr , t e FJi 4.4C, +t�'r. r� ! �1� r^,, y„ t. , 1,' r ,t 1� r ,r �� l:fir 1}t -•r r +I .•. f lj •,�� 01, J , lj)YL �•� 1 f ci ���j��l tier' �r•1 �(',` }{•.iz;�`rt'!i 4'Ilrti�:,',\`r j'}:.f il; + .11 i. .1 't.:+ ..1' 141 SECTION d RESPONSIBILITIES OF THE CONiRACTOR is The Contractor shell InmedWeIy not ifyy the Engineer and utility owner If he disturbs, disconnects, or damages any utility located substantlally me Indicated on the drawings. The Contractor stiall bear the costs of repair or replacement, When placing concrete around or contiguous to any OfIIty, the Contractor shot assuno responsibility for costs to furnish and Install a cushion of expansion Joint :isterlal, clear opehing or slesve, or by othelr suitable means shed prevent embed- ment In or bonding with the concrete. Contractor shell notify the Engineer of Its construction schedule Insofar as It affects the protection, renovaI or ralocetlon of uttIItles. 6,18 FWLIC WNVENIENCE AND SAFETY The Contractor shell so conduct operations as to offer the least possible obstruc- tlon and Inconvenience to the pub(ic. The Contractor shell hove under construction no greats;` amount of work then can be prosecuted properly with due regard to the V*Ights of the public, The Contractor shalI tralntain at the construction sits, and st any addltioaol altos provided for temporary stcrsge of construction materials and equ pent, such seau- rlty Measures, Including watchmen, as Is deemed advisable. Tile City shot not be required to provide protection from trespass or vandallim Nothing hersiq shai 1 be construed to entitle the Contractor to the exclusive use of any public street, road or parking area during the performance of the work. Construction materials may not be stores In streets, roads or highways for PWM then t)Ve (3) waking days after unloading. Safat prece'utlon� will !se as eteted In the City of Hintlogtwn Beach Standard SpecI catlons hereln. Iii addltlon to conplytnj vith the Oanstroctlon Safety Orders of the California Department of Industrial -afsty, the Contractor she 11: 0 1 Prov Ids sofa access to all work which the Englnaer may be required to Inspect. (21 Itotect the public from hazardous conditions which they shot be deemed Inca- pable of recognizing, The Contractor shot l submit to the Eng lnee;• an aceelptab) a detailed plan showing the design of shoring, bracing, sloping or other provisions to be made for worker protection from the hazard of caving ground where an excavation or trench is five (S) feet or more In depths if such plan vlrles from the shoring system standards ast0llshed by the Oonstruettlon Safety 4ders of the State of California OIvlslon of Industrial Safety, the plan Wit be prepared by b registered civil or structu- rai englneer. io shoring, sloping or protective system less elfective that that requlred by the Constructlet Safety orders shall be submitted or used In such excavation. The Contractor shall not comenenca such excavation until said detailed plan has been accepted by this Engineer. The Contractor shall also ob+aln a permit for excavation and pay sal$ permit fees. Psyment for performing all work n,lcessery to provide safety measures shall be embIdbred as Included In the prices bid for the various i+nm of work Involved. 6.19 PAT'EKTS AND ROYALTIES Th,2 Con"oter shot! absorb In Its bid, the patent foes or royalties on any paten - led articte or process which may be furnished or used In the work. The Contractor shal I Indemnify and hold the City harmless from any legal action that enoy be brought for Infringement of patents. 6.Y0 PAYMENT OF TAXES The oontract prices paid for the work that I include ful l oWensation for of l texas on labor, services, materials, transporl-atlon, or any other items furnished our- susnt to,the contracts which the Coetr+setor Is required to pay, whether Imposed by the federal. State or local government, Including, without belq 1 im,lted to, Federal excise tax. 21 F a ,:. r � 7 •+�' .r • 1, i�� 'y. Fril 1° 4 l�i� 4 ! -, lR �)t, �q t:s rs �t` �, 1 �l/ l � 'Zi r�i"1 '('��'. n� 1 i��ly ♦ ��ry t � ��E/ kYll I• , °•I�,� �, ♦� rrr+t � i,l ( li r� , ���1i�1 der a� ��nj, 1 `ri"� ell ' w` Atir ".i�i ?J vti+�• n'1 I>", f �t 1f ,.e II 1 i . -r1 �i Yl / f ♦wy1�y �'. .} f1i Y{�1�1. tt t�l ' 1 l� t � i ♦ �14j�`i 1 t I..��P S t1' It/, `l �• � 1, �YiT. F11��t19�rv,�,yfZ O;.r ,1 i...�f t� i�.tr � � l 1 •IJ !,I � � J � + ter i,4ti;1'4;�' 'F�'.., r t 7, t i , �', r } ( 1` >• ;t C%l t�•:+ l : t 'r Pj �� ii i! �'♦t l �tr` a4 �w 1 �, Z}�,�YY F ✓ `���W t' ' 7 i } r'. �r J!�`?�! � 'f ♦ +fv)7+: lM�,i iti �%�lt -e -,i �� ,f 71 l�r� oe ) t': f: �.... - I• lie :1 0 0 SECTION 6 RESPONSIBILITIES OF THE CONTRACTOR 6,21 PE111107Ti AM is1001111111 7W ONOIMQIINI INtALL PRWM AW AM ALL PERMITS AND LICIENIU PAY ANY AND ALL ai�rrtNPUS O GIVE "ff (W tl�s�-loro-nC THE OONTIttACM WALL HAVE AND NAINTAIN T1ROW01017 TIE CIOWI E OF THE CONTRACT AN APPOM, I ATE CAL I FORN 1 A OONTIIACTCRIS LICENSE TO PERFORM ALL Vt'.IK NECESSARY TO CDMPLEft TIE WI MI AS WW ON 71E WAN I M AM sPIeC I F 1 ED HkW 1 IL NO >ti1 MTE PAWIENT r I LL. Of NW FOR PAOIA1t I NS IEIZWW IM M I TTI WO L IOts OM CVI10016ATION VILL K OOIISIOEW AS IN IAM IN THE PRICES 010 FM THE WPIOW IYMB OF II = 1 NYOLV06 6.22 COOPERATION AND COLLATERAL WQAK The Contractor shell be responslb16 for ascertaining the nature and extant of any sfaultaneousp collateral and essential Mork b� others operating within or adjacent to the project site. The Cityy, the Wnt-aeto^, and others shei I coordinate tt:a!r operatlons end cooperste To minlml:e Inierferanm No separate payment v i l l be Made for coord f nxt Ing the Contractor's work w i th others. Compensation wlII be considered a: Included In the prices bid for the verlous Items of work Invol ved. 6.23 TEMPORARY FENCING Temporary fanoing, equal to National Rent A Fence, 02 approved by the Englneer shall be Instal lad along the Inside edges of aIderalIts or curbs and open property Ile to provide fcr total .enclosure of the project site during construatlon. TwWary WeIn� shell not be InsteII*d where existing block wells or fences to' or h lgher) out ine the project property If ne. Contractor she I I remove the temporary fencing at the end of the sixty (60) calendar post installation maintenance period. '.` or •11 a 1 . .. r � fit• I p _ il.f �: t� .; i�. •Vf ;'� I �1 �..,- - i"yP- S • �A['�l �9 _ h _sS �f � �. , : y 1 J .,� [ �; '� ;� �a y` �y / l ii SECTION 7 MCASURDIENT AND PAIMENT 41 7,01 IEA4� T Unless othersise specified, quantities of work shell be determined frog measure- ments or dimensions In horizontal planes, Howevyr, Ilnser quantities of pipe, plling, fencing and timber shall be considered as being the true length measured along the longltudlnal axis. Volumetric quantities shal I be the product of the mean area of vertical or horlsontal sections and the Intervening horltontal or vertical dimension. The planimstor shal l be considered an fnateument of prealslon a adopted to the measurement of a I I oreas, Ali work to be paid for at o Contract price per unit of measurement ofIi be mea- sured by tPa Engineer In a:cordance with United States Standard Measures. 7.02 AW SUM WORA If the Contract provides for a 1 ump sun Itwn for which progress payments era to be made, the Contractor shell, before the first payment beeches due, submit to the Ehglneer a dotal led account of such lump Sum Item. The deist led account submitted al I be chocked by the Engineer and 1f such unit prices appear to be reasonable and properly be lanced, they wl I I be used In the preparation of the monthly estimates for permanent work completed. 7.03 BASIS FOR PATIENTS In preparing wwthly estimates, the unit prtees, Insofar as they are shorn In the Contract, or as dstormined pursaant hereto, ■II; be used as a basis for arriving at the owount die the Contractor, and sueh,estimates wlII Include only such materlsIs and suppI les as are actual I Iri place In the pre,Jlect, In accordance elth the drawings and specifications and satisfactory to the Englnlwr. Pa"onts for extra work perfonssed In accordance with these speclffeatlons da-Ing each calendar month wlII be made In tho sons manner and at the some time as the monthly progress paywts. 7.04 ACCEPTANCE OF WORK NOT A WAIVER Neither the acceptance of the work nor the p'iyment of any money by the City shoot operate to r waiver of any provision. 0 the Contract, nor of any power reserved to the City, nor of any right 'o damages or Indemnity herein provldedi nor shell any waiver or any breach of the Contract or any default thereunder be hwld to be a is waiver of any other or subsequent breach or default. 23 • t ?i i fSfit�ii 7 itk� ` � ` tart .��'r>► f �,tf t„'�Y,.+ y a �1 iS ��� t. '1`L:�;R ,lr� lJ ����•Z�{}�1 .i !a'�.•bS.1 , S' �� 7r7 I f! 1 '• f i, .. ,� ?t _ 1 +�,- + i + . lei ++, ••� 1 il^,�1 f 1•'�1��-f1�,1' 1 kQ4i{j'+. !t•-c° r er � a is � t.' 1 rig', t 1 ,' r •rTa J� �_i ��} J� (�', 1r�Rir AYt t 2•. Y tj},..i ,. j / S� �`., .,(_ c,j/+ ,y?fy'r�;t'i ) t71•' .,i ,e�/' A7 !1,•r tr; j �•J i;Y' I ��R •1-' � � 1 ,1 3:. 1 ..�;ij r �w l � It� ti �Z t4.1�j4 w � 1 11, ' t >, `j"i?Y F ;+S r� .t+ f ��• rt 1. ! I,}1 r r .. / �; r 1 L_J ��, L ��; ��Y � 1 ,•.��*sr +� 1 � ,fir r��,{�^f �f �,Y�t,, � Vtx SECTION e MOBILIZATION .soot DESOItIPTION �MoblIIzatlon ohm il eons(tit of preperstory +nrk and operations, IneIudIng► but not +IlMlted'to, those nesess.ary tar the movement of personnel, equipment, suppIlot and Incidentals to the project sltel for the establlshment of all offices, buildings find other facilities neuesslry for Mork oa the project; and for all other ,work and c perstlons ah leh mutt be performed or costs Incurred prior to bog lnr ;.t,v aorl: en the v•�-Ious contract Itaeis on the project sits. The Contract lump sun price for mchlll:atlon shall Include foil cmpensetton for furnlshing at l labor, materials, tools, equipment, and IncUontals, and for doing .' all the work Involved in soblllra~ion as speelflcd. Any adjustwat prov1plons as stated In thew, spec;fleatlons shot not apply r ep Is Contract l unp sin Itset for sob; I I rat Ion. 24 ♦ ! ? �JIr�?�',`'7�xT }r 4 s4jr�/r rtih�Af��4r;, 3 � ' f14h ;fir t*'1'ib�,t �''�4���'," ��' ill l� ? � �IF�' ;« y � ,,t�+;�•%� ► 1 Id,'T wA'i� 111r,`+{ � t Irk � f�� t r , ,� t r.;-yrls•;� ,, Rti �,7 3�,,� ! �S dd tC ..fly i 1 }1r s n , 1:;1 1{� ;! t v� t �: , ♦f�; { y Nfry ? �trlf �t7 � liil�-�1� } f t `� i � / �'.;lr Jti , l � 4y •{,� r 1 t i� �����1 ,I}+ -��, V I` i 1 1 i• y u t >♦ ��.l�rt tilr+�� ��tj� i' ••r 1� t�� S �r,�tl� ��S 1 �.•t l ,r {yil ���t I, 1Y1 t ' r, ;-i fir, �� ,• 1 Y D r I '14 �ylr4 F1 r �i1 r� i f r l .� �L r! ! �.rf• j{lrt ♦;�M}+ r 41 �tl1:t �� f�►ttil n3 ,1,'i�l tlf/ll�r!'%�;•�! �� � jai � l�r! t :lr ` 'T� �f �`l�rio;tf��� { •wtt �x �y♦ i { � l .�t} ) �, �'i, r \ . 11 f (1>/t i7. t ►� t� Yr , r,!`.� Y'{� �'ttr''.+���'�N �`:y` r{�','��` � � �''' •' �� , .•+�tSSI }��•r l.�+rt !'.i,•,Q�"+ �r.t��l ��I, '' 1;; �, J - 1 , r ! � r a t it ' �� �! 4f ley, l.,s� tiv�d•� Ar ►T �,1f r s lf�t` ,�� ! f�l� 1 ri;i+ �ly j !(�• ��},, >� r + i yt►1 t',i 1, -t�'� � Fr f�f� i (r •j'+I�1 � �.', �a ��,.fir'• + •:'l. i. ��, ,, 31 r�C '�;+��t1J�� r { �t li �~. Lsj ill i�f���if ,Ijr 1.. ,;� s1 �` ! .J� •' t r t•! r� `;) �-. ,n 1•!'' , n + 11 a fir' �1 a, r i•, . .L_ aw I ' t r''? ,T '+ f + 4t� >l1) SECTION 9 CI.EAP.ING sr,lf tlFiU061140 ?A rl {n y .f •IJ ,' ' 9.01 GtkERAL Coltrt.ctoe nhal ; provide al l labor, matortal! and squl{rment tar clearing and grub- '' bing cporatlans. We work she! I ba pertotmnd In advance of grading operation and t.. ;�+ ir; areordonco with the drawings end As specified hereln, subject to erosion control ,` �rl, •• requirements. 11 y ; Clearing and grubbing shell consist of remcving a;I natures and ertiflefel objec- '' I'onabIa isuter.aIa from the nai,arnl pround surface wlthIn the I imlto of construelon, to a depth ntmdswy, Including but nut Iimlted to rubbish, dobrls and vegetablo growth such as ttoes, stumps, root% onn and one-hoIt I 1/2) inches In diameter nt larger. t'urlod I oqs, Crush. gross, wood% and Itans as dobcrtbed i herein and shown on the drawings. E,olating culverts, drains, pipe,., cures, gatt&r3, sidewalks, pavorunt, condults and " r - other structures to be takon out or rtoI aced shall bo removed by and at the expanse tl �� of the Cootracto , unIass othorwlt+ shown on the drawings or as provided herein. 4aterfals removed shot I not be lu:orporatod In the prof act by the Cantrectar except with fSa permission of ti,a EngInoor or as indicated on the drawings. �1 ?,. ` No payms,;t of I 1 be made to tho Conir netor for etsarfng and grub5ing outside the �J��:•; �Y stated (tn+lis, unless such cork is authorized by Cho Englnenr. Trenches, holes, depressions, and pits clusod by the removal of racllltles or �+ f abjactlonabIts metcrlaIs she 1 be backfI I led with materlaI s aqua to or better that the surrounding sol1. 9ackfi! I areas she l brt comprct"d to tho sane drrslty as axt_tfng conditions. 9.02 PRESERVATION Of PROP£s TY Exis.ing istprovemsnts, plant �-sterfal, adjacent property, uti'Ity and other feel lf- `' tfsr shorn on the drarings and ituns noted "to be protected" or "to ramaln" that ' < '� '+".} 'F►r# '. r, sre not to be removed ot,al1 be protected from Injury at- damage resulting frra+ Contractor's Plant to be • er '��r operations. matarlal be protected shal I marked by the 1 , •� Engineer. Costs incurred due to ►'epolr, rustorattan or replacement of e+tlating IMprovernarlta whlnh are no!, designated for removal which are damaged as a rasult of construction �,��'�; �:'• �'T, ',j operations shall be the responsfblllty of the Contractor. Replacement shall be at least equal to the conditions when Contractor entered upon the work, and shal i match there in finish and dimension. Plant materiel shal I be sus replaced with the sans spseiss, size and In the wfglnal location. 9.03 REMOVAL AM DISPOSAL C!: MATMIALS At I materInIx removed shal I be disposed all off-slte. 6urnlna shal i not be permitted. No accunulatlon of flaereeble material shal 1 rtinaln on or adjacent to the project site. The roadway and adjacent areas shal 1 he left with a neat mrd flltished appearance. No additional pat,dent shaft be made for the hauling and dlsposil of materials. 9.04 14AULING OF MATERIALS In order to protect the City streets and pant troll and Welk system fast deterioration due to hauling of materleIs, the Contractor ohs II sutMlt %prior to pre -construction eeetlngl tar approval, a proposed route for the hauling of >� steterfels fit disposal. Upon approval, the Mntreettr shell strictly adhere, to the rout* only, unloes written permission Is obtained to charge the route. sr r 't"'yT--t; t T"-•^--*� .+►w�:+. .r. ..�. r _.�,,..,.....�T.i. " l!i, >i A?, [ I�S+ �2� � `7 ai+ fi .; f t. ,•', ,, � � ' - i" _ r {`''�l ;+ �K 4.,i..iA � � l + TTT{ •+ yd r rV°,1 'X,� h�` �f4( _++.h�+i �jTt!!i?•+ 1�{Z'�.��i, �;i'+�'{`,.+(+ ,t +' •� Al f+ 1%1�1'.Sv� +T ♦E ��,� ��'. tf �iid'�•f �`C`�tr �: � (J S� ,.�� t,n ; �,�.Vl�-kt .i •..i• : l� t.: t }3_; Z� +�•1t� t KSlY�/`hyldt r 11t r,Srl(j�C���W�t'� t.7!� ii, �l i .1, ,� � ,.+ t t 'j _�'._�ri� y�f11L� lim+��r� �.r.�J• ��' + fry +1 � rr% � � `r i i% 4�'.1 , f �, � ��t�,YI ,,.i��1,`., '��i'e�l�/�1, �ii'�':�a )rf ��'•y ti''i. + 'r1 ')���' ��� � - ( .. } � e, r ��."� +1�+ tr7��t11 15�::(tj+ + �� (�' '.T�kT•tF-}).'i �.� r � '� rr _ , r � •• SECT 14fl 9 CLEARING and GRUBBING I.07 CONCRETE REMOVAL Concrete Indicated on the drawings and speclflcea herein for removal shell to cut to a true line with neatly sar-d edges. If a sawcut Is within thres 13) feet of an exlsting •*pension or control 'ulnt, concrete shall be removed to that Joint or Mgo. Costs Incurred due ,a replacamert of evisting cuncrele not designated for removal and damaged during removal operatinno shell be the rosponslblllty of the Contractor. Boring under payment will not be altowe9. 9.06 ASPHALTIC CONCRETE REMOVAL Asphaltic coii-rate Indle.ated on the drawngs and ipeelficsd herein for removal shall be removod to clean, straight Ilneu. Saw cutting of edges to be joined Is aptlonal. Where only the surface of existing asphaltic concrete pavement Is to be removed, the method a removal shal I SA as approved by the Engineer. Minimum laying depth os caw paysment material at join 1lns shall be one 911 inch. Edges of pavement shall be trimmed to neat and straight IInes beforo resurfcLIng. Costs / Incurred due to !opla,emont of •lusting asphmltle concrete not designated for removal and damageu durlrg romovaI oporntlens shall be the rosponstblllty of the Contractor. Boring under payment will nzt be alinwed. 9.07 ADJUSTMENT Or UIW SHIM PAYMENT The Oontract lump sum price fnr clearing and grubbing shall include full compense- ?' ` I' tlon for furnishing al I labor, materials, tools, equipment end Incidentals, and fir doing all the work Involved In clearing and grubbing opnratlons as Indicated on the drawings and specl f led heroin. No add itione l payment she l I be made far ••he 1 � ;ti '• haul Ing, $a I vng Ing, and d Isposa I of mmterta I s. 1 Any adjustment In compensation dve to an increace or lficrease In the quantity of pork to be performed, which Is requested by the Engineer, wfII be made an the basis tit the twit of the Increased or decreased work. t r .i• 'n" i! z F r jr + r I •rfr �f t n, , iwtf+fF'''4j�.r I t ,I �1 r ,�,r l ��, ,fir •,1" � i�.• , t;L• 'fir tf4, Sa(1 n3if o t Iyt� t tit ��:ti ;` , , {•. �+t 1. i•�C���i (t ; ,! , 1.`f r .i7 J;1 ,j try '�5�.«, d � l,t�.! %� � - , : � • i _ - .. - .. ... � ter✓ • fl. r t��. t•�r ; ,r �,tf � ��,r ,yr�,�• 1�it{�;. 1s � a, '•� 1 Y,TAt 1 21 .., ..._.._..._ _. .. , , _ ....._._ �_._.._.•...,.,,... ,tea °� ' Vol - Olt, • � � i , .a �. IY � K • ,!' ,' ` S: i , rlt+�rr' ,. 1 ' - t I �.i . 4t,i 1�!� is 7,t it ,. •t� . J • ''1,- I.t -♦•{, �.Ctir' IIi{ f'�.: 4i '{`del _ r '., t t,' ` •`';r111 ctit i ri • !'��. 'SS:',�{ i.✓,� i1 i.1 1. ,l , ' ,,1' V . 1. 1 ''��. �., •''.�1'?'il:,,,;�� � I•{y „`, :�' ,. i. �,, ,•� '4�l2{ � :''�' :mot vs�;', M t r , (3 a fFr. o. a ri" Y •t. r'1 1, i y r ill , Yl"''� •• =� .�Lii� 7i {i r .. r•• Lam k_rrtl.rf " - ' — - r• • - y .1 f; SECTION 10 EARTIMORK 10.01 GENERAL Contractor she II provide al labor, metarlal2 and ululpment to perfcrm al earth- work v:-aratlons ss shown on the drawlerIs c"d specified herein, Including but not limited to site grading, excavation, backflll. snlr compaction control, finish grading and disposal of excess or unsultab:e mete{•tali. Survoying shal I be in ae;-.ordancop siltim rho provision for surveying ^a spoelf led In Sec!lon 2, Control of thu Mork. If, during grading operatlonF an excess or deficiency of earth becomes apparent, besides those noted, Contractor shall Immediately notify the Englneor. 10.02 PROIEC'i 1011 OF PROPERTY Existing Improvements, adjacent property and utlIltloA that -lr,% not to he removed shell be proteeled from Injury or damage rosulting from operations. Coats Incur- red drr• to ripasr or damage shal I be the rospanslbl lity of the Contractor. Contractor shal i furnish, place and Wntaln of I ohoring and bracing as my be required fir prctbction or existing strwfures durfma proper execution of the work* lhs adequacy of and responsibi l ity for proteetlon sh i I I be the Contr•ar, tors. All bench marks, monumonts and other reference points shall remain undisturbed unless specifically requested by the Engineer. When hauling Is done over city streets, loads shall oa trimmod and materiel shall Do removed from she f areas of vehicles In order to el rminate spill I Imrg. 10,03 PROTF:TION OF ML1C Contractor shall provide such barricades, temporary fences, lights, warning stgns, guards and otaor measures as may be necemisary to -t!sure safety and to doter trespassers. These temporary tiacl lltfos shal l be canstroicted, painted and main- tolnsd In strict conformance wf+h 'rho rogalraments of applicable local and state codes. 10,04 GRADING OPERATIONS Flnishod surfacet In el I cases she I c•.nfor'ra to the I Ines, greass, cross aeetions and dimensions shown on the drawings. Such deviation& from the original drawings and working drawings, as may be required uy the exigencies a(• construction, will in of I crimes be drmtemined by 'the Engineer and authorized In writing. Ffnlsheo grates shell be well compacted, roas:nably smooth and contort to the drawings, Insuring positive drainage, free of abrW grade charges. Irregulsrl- tles, water pockets or discontinuities in surface level. Subgrade for pavements, sidewalks, curbs, and gutter, and other structures shall not very more than one-half (1/2) inch from: the specified grade and cross-soctlon, Adequ:ta dralrroge shell bs provided throughout the progress of the work so that storms water will be disposed of without damage to the project or adjacent proper- ties. My such derange shal I be repaired a; the Contractor's exparfse. Prior to Import, amendments per agricultural sultab;IIty soils report shell be Incorperated In al I areas. ro within ono (1) foot of exist Ing t1•ees, to be stolonized/seeded as turf she I 1 by cross -ripped to n Minimum of twelve (12) Inches In depth, watered, aerated and recompactod. resth on ripper shall he twelve (12) Inches on center. All f In!sh grading shal I bn completed pr icr to weed abatement operations and stclonizing/seeding as ipeclrled in the P.'anting Sactlon. The CIt1•, at its own owpense, mey require a lolls test at the completion of gradlrrg operations. W _ 1 ! •� 4 `,� t , lr1t S 1 r . 4. 1• -^.Pl 't r" .. t1. I .ir 27 a [ �SP� r I r� qc 1 Si. Y tr • , tt r t r 1?G � ; °� � ,�r,#�`�,�D¢�,, rti , t1 'Al 14 ..� ,,t • �'�'. � ,•'+,,�•� ..+,�t iry�,S ,,�,11 S+ ;/►, - '� t `, ll .�t+ t f r t •t ��•'+ � {• is f'1 t1 r�.i�7.���i'1 t .,yil :T`. y' ' � '' r�'s ei i 1 •� 1•r+� jI R'� ,{ �':�, yi ���,i?� ��fr;L •,f !� t �' 1t'•1 1�'?' �^11f •' �.ril �fF �Y1'�'i '�.k � �i��, t(., ' 'r..7 'S� i4�� r, 1.1 •+S 1' I '•t1.i1 J'•ri1}'1.i i[ r, 't; 1 7 ,� ," � " t-s ' +. t 1 , ;; ' } Y { ; ;,t ill! � �...•. 1 Ce. , l 1 1 It , ('' '�.1 .`�.,ll i`, .'J t f4'S i1'S/I'IE+���>♦a. xr . J 'js ."}J l T' ` I ' ' •/� (`•tf 11 , •', t2 �'/'�SI: >. .! j I t r i t 1 , �Ytl lii C.+S•.ert+r.r.r r._ L�• .�'►....,..r.+•.�+. w.....rs.aN v.S►: aw•..Ira,w+r....r-C....w.r.rv:'.uL:La•i0YY7LArl�t%ilK:�..1Nlr jrw.+- I I . � ► '� �' 1 r i I : , , • r,,• r+ •r't' (' SECTION 10 f 1ii�t• ' �? :1� •+ EARTHAORK04 .tit ;A ls>N�/•'1�'ir,�} .• - r({ { :,•1• �• {t'' �f ), S '., lip IF In Ish grad ing ohe I I W done when the moisture content of the sol I Is so great `r ` i that sycesslve compaction w1 I I occur, nor %hen It Is so dry that dust w) I I form In the air or that clods MI 1 1 not :freak read i ly.• fa t l t r !J Prior to completl-)n of finish grading, al I rocks, roots or other foreign material :{f1, one (I) Inch t r larger In any d i-acaslon and woods she I I bot roiwoved from the top J �P +•,;� '' � t'•, two (2) Inches of the finish grade. 4yal.�,Yt,,f G ,' '' " Finish greda adjacent to pay ad areas, curbs, va l ve boxes and s lm l I nr features ; L n,f; 4v st.aI I be one (1) inch below the finished surface. 10.OS EXCAVATION i 4 i , The Contractor she I I make sufficient ancavatl'on to construct a I I of tho work shorn f! �' on the drewings or specified herein, and 51n I I sblds by the Construction Safety _l. ,fir.". ll.�r t•'ti•., It,:.-- L Orders Issued by the 0lvlsloa of Industrial Safety of the State of Callfernla. 0" Cxcevations she I ! be to the d lmonslons and al ovations Indicated on the drawings of � ,• t,N' sufficient uldth to provide clearances for setting of fonns and Inspection of the vsrlous .;lasslflcattons of work. `1 1 r,oncrete for fool Ings sho I I be n i aced against found isturbod so) Iff wh tah has been !horoughly wet+bd. Bottm of excavattens shell be loyal, free from loos: `aterfel, quireu levels in undisturbed earth. AiI o4cavatlons she eI be standlnq water. The Contractor shall asstmle ell rssponslblllty draining that may be necessary in carrying on the work. and to the re — kept free from for pumping or The Contractor sha I I eomp I y with State of California Labor Code Section 6703. In rho event on excavation Is f Ive (�) or more fewt sit depth, the Contractor she I I ceuso a competent person ?o be placed at the J?to of the work for put -pose of obsorvIng backfIIIIng operations In those a;,es whore the operator of a power unit engaging In such backfIIIIng Is uneb:e to see into the excavetlon. txcayetfons made to groater depths then indicated without spoelfic direction shell be tilled with c3nerste as specified for foundations at the Contractor's expense4 It the Endlnear requosis thnt excavations be carried be!ow depths Indicated, The Coniractor shall perform such work under the provisions for Extra (fork as spool — flood In Sectlor, 3. Acceptsble excavated malarial shell be transported to and iiloeed In fill areas wlthlrt the Iltrlfs 2f work. Ltncatlrfactory material sncounFersd withll the I1011ts of worl, i bn excavated below grade and replaced 01t11 satisfactory material ab requested by the Engineer. As approved by the Engineer, distribute satisfactory excavated subsoil obialned frcer grading operations for planting areas. COMMI—tU FILL Graded w4terlel shall not be left I loose Isyars but shell be compacted In thin loiters. At•,or required 4xeevatlons, undistributed or exposed natural rolls In areas of hydroseed-id turf shell be crossrlpped to a depth of twelve (12) Incites and brought to al*nln three (3) percent f optimum molsture and "pected. Tooth on ripper s'.vsI I be two ve (12) Inche: conter. FI I I rtiaterlal shal I be +camposod of satisfactory excavated material or approved Imported soft and shall ba evenly spread In uniform continuous hot•Isantel layers not more than six (6) Inches deep of unccmpacted thlckr+ess. 28 (.� •r�•�Y •/1'�" F� `t J I•: , l 1/ III ,f IG;+S}�Q�ll •++til/. M•t 1' r.'i� r� J it �,i1 i D►,i 3 i � 'Ys� J �..i 1 ti i. li i', l�r, t'-1J fL ♦r t ,_, F ,� t � I i, � S�!' ' �. < is ..j i 1-• , ,•`t tl , , I lJ , t i,' � liS�ti�ll ..� � 1��1,'i r -lam .i j f { It� �.tl �, 1'r , js` 4..'!,'r .• +_ '! - ij r'•}1 ij � f. ,r �yl.! .I Jy. �tir r�� ip (, . �J aT tl �/ i1 +: ' + ', + - , t�}'.•' t1 'tl! -r/ T� jf�~1�•�DIle �y'�I; tf tf�`gt 1. �� i• �'f r ;. t 1r, 1 ��1� 7 �IT11 r, 1 /•,.• �� ...I` r**"'ifrl �`,fR �7+1)y �1(: t�' � �1 /i FJFtt.1i, 't Er �i '� c! tiff` v , ' i .. �+SI ;.•r 1 .. t+ J � r t li,i�l�'l Yr fkA i tyfi. ' "x{!! �.'7/ �� ".1 �j ..✓; , t - r I , I I , J `. 1 t..1 1 ( t .JV1 �'t� T ilr; „ i I,' v . • �.'{,ji!►a; •E � � ). r 1 , 1, ', k., t '; }J—. t ; . , _► t- lr , .y,; `t'�7 r. Y ie jI.y rl.. I,s r t ., .ys l` S�t�' t�• A�h. •Il��+lj + ♦lit1t, I+ , ,S'i if ri ! , ! 'i:S ) � r I. Sf got f� s r !� ,I •I Z.) rr� it sjC+$S Yr' #iS�+.M•.3 ISJ �f {'�:r ,i4-/ +'• ll i e• - r ,' r}( �..1r .CI•tl T�'� r l�•,iti{5?,. 11.1 f � 7 ) l J : + »1 � ! ', � + � �{ii l'V� rb• t•' 4( i/ 1�/•. ��` , 'mot 't , S `'-Ilj, t�, I t Eft 1 A;.: -+I ,�'♦ 1t;' , }I-!1t" ( f i 1.., tr t, f , t,tL.� l i1 �x}7i• , ,rWit N `.:th�. t!;rLS ttJltl,f ���+ ; I.! •+r -J• •ir � (• � t'., 'f ! _ _ I,."Yr 'S .� �?r•6,�t. t1ti ''t '�•'1 .':k1 'f', r: ,1I. J t., . 1'i-; .i't i f�tKy yi ... ;;' •'(' a -this.•' t: - 1t, '+•_ '' • _ t n , ' l!;::. A i Lt. V7 i. /4 1 aiu f ,1. 1 . > h 1 • ,rt ,f + 4 1 + I col Tre,`, ' i, 1 i ~IC•Iljt J}��Jr' ie f SECTION IO f y EART►MORK ;+ it Each uncompacted layer the ll be moistened or aerated as necessary r, obtain an eve{, stolsturs distribution within three (3) percent of optf.4um misture content. Compaction $'isII b# per formod by sultabIc mechanical equipment' as a,(•r'3vad by the Engineer. Each Itft and the upper six (6) Inches of nature) solIs shell be compacted to at least 83$ of maximum density obtafnable in areas designated for planting and at least 90$ ma4lmum density obtainable In areas designated to receive pavement, structures and site em,enlNss In accsrdanco with ASTH 0-I557. Each I Byer of It 1 I I she I I be suf f fclent I y roughened of ter compact lorr to ensure t bonding to the succsedlnq layer. Yr�+; ` fti, •. Bring f I I I s to sultab Ia elevation above required grade to allow for shrinkago and settlement. r ,•�ti,'+ ti ' �� � ,; 10.07 I)AcKrII.L Trenches and areas adjecen', to footings and foundations shell not be backfIIIad untlI the work Is Inspected and approved by tho ;ngfneer. Excavated material, approved for back!Illing, shall be free from large clods, stones and other objectionable meterlole, exce-ding three (3) Inches In dlamter) and de;,oalted In layers not greater that, sin (61 Inehos, brattj�ht to 0thin thrs+e (3) percent of optimum molsture content and compacted by sultabl'e means to the requirements for compacted fill as speclflea herein. Prior to planting operations, trenches shell be at 'he comoacted finish grade (see Planting Section). Trenches that settle below grade shell be reopened to a depth required for proper compectlon, rot II led and compacted to Indlceted surface elevation, at loving for shrfnksge and settlement.' Compaction of backfIII by pondlrg and Jetting w!II not be -jermltted except for frollgatlon and onslto drainage IInes. 10,08 EXCESS OR UNSUITABE MATERIALS As requested by the F.nglnoPr, any orcoss excavated materials, except that which Is to he used as back flII, shell be removed from the project alto. Arrangements for disposal of the material at off -site locations shell be -fade with the owner's written consent of the property upor vhlch such material will be disposed. Satisfactory comp letlon of fill areas shalt be completed before disposing of any fndlcatea surplus caterfal. A shortage of mararfal caused ty premetfre 11aposal she I I be rope aced at Contractor's axpense. Unsuitable material, as deterelnod by the Engineer, encountered below the natural ground surface during constructlon, and not Indicated on this drawings shell bw excavet.-d and disposed of off the project site. Removal and d Ispose I of such unsuitable materials will be paid for as Extra Work as spe,:lfled In Section 3. 10.09 IWORTED FILL, Imported fit sholi be cloai, free from orgafnlc materials, trash, debris, rubbish of other objeeirlonable substances, Contractor shall vorlfy with Engineer the spealflo removal site. Pr for -to duIIYary to the project seta, soI! shell be tested In accordance with Sactlon 4, Control of Materiels. Englneor will datermine soil sultablllty. Importeo Ill) shell be placed In accordance with the provisions of this Secrlon for compacted fill, as to the nlnlmum relative compaction and placement method. Imported flit, along with the existing alto �neterlal, shall he thoroughly spread and mixed prior to rough g:•eding operations. Imported soli shell be subject to insoaction erd egrlcultu,ral %oil testingg prlc.; by the Englneor at the scurce of supply Arlo; to d:lIvory to the project Me. 29 , ( ' Ir11 n rar.�>Ayf.,oyw.a. .—•----� rr..—........n.-rT i.... ...,.} }r •t+ C i A � 3i�'',` cF I �, ,� M j it ,i a�'f I i, �r ,r t ll 11': i ' •.� �. 11, rt ,riQ ';rr .�'�':,y��� t '1, ! �t �'. 4 ,II 1 -`C! ,I( .. •.f r , ;�i,' - (t r � j' ',IF a{ er ' •� t !"1'.,�,i }.� ' ( t1 r t�:, f 1 •.I • �i r "11 `" 'l; �.�',fl!' 111';1. 1! "� YY1��1,�.'•' (it rJ'.��1�,•� r �ll a: tr. �; ,. .,'1 :.1; 1,�I.,.��rLl� I Y { 1},,iA�l ItI r1 �, •r � ���, !��.1� r SJ ' �lr ill f S-� • l l i ' I i� �� rt� 1•iyy i �,} r �'� r� 1 �, ,•l 1'r ' � ! 11 Y r, � r •' 1 1 ' , i ( , r r 1 4 �, Y ���rt►f S �. 1� ryl �, i ! �( t � � r j f 1 ,� '�' � I:, ��i> yf .t� ,�`,t 1•'•J'i `�'irrt '�t 4�1 �'!:` I "1' 1 `�'!� ,' ,.{� Its t f. ,- l « `If7, (1 %j r !.> ��;, *11•jw ' '':�,i i - ..i ., i ./ , .1 (.� l� t ,}' .'+ ! `a { T!r i.- "I vt r oifI • - �., S ,� � +'��,'� dl '.,1 l' ,.: t , • _ y l t 1,:� : / , t•; 1. { ::, l R �,,1 , . 'f �'!, ��i �{..�flt • :y k, ti �1 r'%''! lr r$�1' %i�� r , 1 _,,i ,, L j.,. 7 t(� r ,y i 'Y.Y i ft �• f ^v: .1 lrjIV a(rr 1 ,Fjr,.•�,' f�, !t'i.},� !'• �Y1 r ! •r .• , 1 1ri. rl, .r..i. ,rf t fi •'{ � `1(. rl�i / . u T•' •�+w"�1?�'C `,.,'!t'f r�' �a t t rfil � �1 ••f ..; �' '1� 1 5 'xYl .4•.ril ���"j�� .1 ,. �` ., • � 'i� �li.�� ••'r r. rr� ,, i 1 .'1 - � I' l if' `tf! { rr1�'fl it 'j �1. A .r YIPS ' ,�•^ 1• ( ' , 'R , J{. Y,•, ,r. L�( .' r r �� i' `i �� ��,•'i �l`;rr�, + t �. 'r r`. '� •j�'ti/ r' •�: ^ ,.r;•({ , z►>✓�: ; .. }aN�if.lri rJ y i•wf f �C - r 1 r , 4,, 1r. �•. i„{flr'd_ t 't 4Ji J ,it tri l rt r ! `a Fl? �4r-�%.;i'}373Y7"�`�'11f0'I�YM.•..+.......�: :Lr1 l"e�iv'.»-..•,.;ri lo CYr ii t - •.� /......r..r....w..�.�.ti:....•I:wv.>wr.rrnva\rrwt+Y".:ioi1L'St1fi.'. I ih'±. .drisfMi•�f�►+.t.sr.+ta + �1 •�_ . 1 .fir ' •, •?r.r t '• ® 1 1t f}t, ...'H�.r� , ',.ta1 •, t .' 1 jdAr ' Tl SECT i ON 1 I v ' DRAINAGE STiTGIS ' 1 1 1.0) GENERAL 1 A � Contractor sha iI provide all labor, materlals, and equipment to furnleh and f ` Install drainage systwms as Indicated on the drawings and as specif Ind herein. Contractor shall maintain project site throughout the progress of the work Ina reasom.able, dry, workable condition„ froe of surface rater. ? r vt o 1 - : r Contractor steal! be responsible for al cutting and parching of new or nxistinq walks, curbs, anJ pavements required for proper !nstrllatlon of drainage systems. ; ,•+m 1�•t !fit ,�) Interior of plpe she lI be thoroughly aleaned of alI foreign matter prior to, during. and after Installation In the tronch. Trench bottom shell be graded and prepared to provldo a firm and uniforms baring surface throughout entire length of pipe. �( �7 Connections that are to be made to existing pipe, catch basins or other cr ,, appurtenances shall be exposed before laying now pipe. The Engineer shell be d} c notlVed twenty-four (24) hours prior to connection for inspection of existing r ,4jtf �•# ' rs-. conditions in ord&.' •o make any adjustments necessary to accompl isl• the intent of the drawings.1 ., 11.02 HORIZONTAL SUSCRAINS 3r�yt�t\Sr „( t i Plastic pipe shal I oe InjectIo, ma"dad) rigid; unplasticlzed ployvInyl eholride (P VC)I NSF approved) of high tenb I 1 s strenth, chemical resistance and Impact strength. Hinleum pressure rating shal I not be less than the working pressure for the schodu;o end size of pipe Indicated on the drawings. •'•ittings end wupl Inys W„ ,+ 1.-' shall conform to ASTM 0-2464, D-2466, or D-2467 as appropriate.,' }' Drain boxes shell be pretest conerets drain boxes with cast Iran grate end :�r't< ,.• � extendears an needed manufactured by Brooke. El Monte, CA, or approved egaa 1, InstaIIed as detailed an the drawings~. Locations are approximate. EXeCt y ? �i'; , locations shal 1 be as requested by the Engineer. �.rl 1 .tr s �r .t / Drain cox ccvars steal 1 be from grey iron castings conforming to ASTM A-4S, Class ,,4, I r' ,,Mh j r Sri 'r , 35. Castings she I be truo to pattern In form and dimension, free from defects. Covers sha I I bo It to concrete boxes In accordance with the dotal Is on the drewings. Biel II U: ` Area dra Ins sha I I be ae sped f i ed on the drawings and Instal Ind In eccurdanee with t « ,' manufoct�rrerts reeommendatlons and as Betel led on toe drawings. r• 11.03 SUMPS and GRAVEL DRAINS+ 1 .. � .orflvel steal I be composed entirely of three-quarter-13.4) to one-(1) Inch particles i,+v I{,, that have no'stwre than one (1) broken face. Gravel shal I be clean, herd, sound, durable, uniform In quality, and free of any astriment&l quantity of soft, �r ' friable, thin, elongated or laminated pieces, disintegrated material, organic matter, oil. aIkeII, or other de later lous substance. '+ V Fllter fabric shall be composed of strong rot -proof fibers oriented Into a stable +� , ►r network each that flberi retain their relative pesttlons with respect to each e''r d r'` `� ' +:` r'T' ;y7 other. Fabri. steal ! be free of any cnesnlcel treatr•nt or coating, without flews 1, or doteats. Product sha 1 I be 10011 continuous f ! I it7ent Ito I Vaster nonwoven 't.;Lneodlepunched engineering fabric. When requested by rho E�Inoar, Contractor shall furnish mil l cortlficatlon. Fl Iter fabric sha! l be e2 d&tdiI*d on t%o drawings, r'�t4r„`,:+, i• + • ft ✓r+, :)+ avellxble from American Horticultural Supply, 25311 Avenuo Standford. Val:'scla. +,. CA, 80R-257•-47Ss. r r r*illy-. r�„1. F � , , �.d� •. Iirnvo I shal I not be dropped onto t I I ter fabric from a height greeter than three (3) feet. r Costs Incurred due to damage of H 1 1 tar fabric during Instal I ation or during �f F4l � ,JI)-i•' f`' ,I ,,' plae.smoot of gravel stall be the responsibility of the Contractor. b .i mil YCx S0 } 4 T ' ~• 1 i�fiji ..'.._.t�['.. C .w.. r. , ,'t l...� \ t. r •,plc. ( !� { .Ot i~"`•r..y'`..,i y, "y' `,.?3 A f.1 T { r V.i {mF I C, rt t ,r .; f,. " ��J� r1r ,r t, t �+ , N'� •i��'I , `�. y, �� i Y y1!' 1`;f t'� : gC,j4/� r ,. � lr ;.. Y,. . ..,•i r' .�? ' �• �.j j 1 (a' .r.rl. ' � ;�,' �,,tt'i.,1 1- �,ia r n t t .' •; _ ',. , rt � 2 � t � rff�j �, r'• it k i'. I �I�"Gt� , `t�}5j•r,r, t .f `1 l� t L r + t ,t';'r l •if,,, jtt '`!'�1.11 . '' .-i-,'' •,.` i"' 'tr r. !��/i' .y,�t s r '..,er•y,11tYi r J+y r11, \ i -i 1� i ' .:r J, .^�t 14�}a C*+'i'�',���1 IfI 1 � �~,. t•��\`I 1` . t''•t j,. 1 ;S",\ r.._ '', q.T i,\(, .. •\ r' .iC't (f itr?. i:: �% "+� •�..J •'?•1�� +it _ '\+ t. ' 't\1 " i ..1' ��.- ( 1\ I^. t. t r-!' S i ti.IS + "\•� t� l+f ```` '� n } '-1> c r ..1 t •`y1 1 ..r r ."f r t�. �,y L, v. i 1 . t 1 �,�•f `: ' �` i t t t ? 1' 1 , . .: ` • : t.t t l,' s �: � .� '/ �' 1 , r!a. r } Y! ' /h'i r:+ ,;� i. .. . •l.. .r „ f L tt. {5'..' ,i f)!.`'• ate„ t .. y 19• y 4�,?4� .` f ,.�t. .-:...i .\1 " t,t rC: r, '�[..f. ..l•, � ti,".au. , t . . , . / f�i�r �.'f :�� ,:�?. .. �'• 1rr�i. ;�j� 1 �` � �+' -+:\, , i�•f )�'f,��r 7:1.•�' r ;f r °• �;�.., Doti r +^p,,: q r! t ., +,1, 11•��f ;fits :i. `' ".. r .7i � , •, lA .r �, •.1 n/•.`, j' 'liii , t' •, a r t' -` r,,qf (F,l Jr', t' ` 1 4,, f.'. .. - , , fJ ;+r , r.l! r, , •,i+_'il,} ,i, ,� fJj �` yJ. , i,�'Nii:,.are .t.4� ,.(, *•:rt ' ' '+• t i ����� �'li.i •4.jr: 7A 'r. i r. j. G 0 , I` r SECTION t2 ASPHALTIC CONCRETE 12,01 GENU,.AL Contractor she i provide al i labor, +aaterlals and oquipeent fo{• furnisning, t ''c t.prerling, compacting and finishing asphaltic :jncre's facilities ds shorn On thu drawings and specified herein. r t{ Contractor shell be responsible for ettabllshlnp subgrade and providing dralncge in accordance with Sect�cn 10, Earth Mork, ead perforrning read t,batement o;*ratlons ,{�,' .Sr.,, end providing aggregate subbase end In accardsnee with th9 Subbas,o Materlets Section, prior to placement of asphaltic concrete. r� �� ;; •f Surface of finished asphaltic concrete at any point shaiI not vary more than two one-hundreths (.02! foot fro,, grade specified on drawings. ,`' ''t," r �, 'y• Asphaltic conereto shal I be the product of mixln coarse end fine aggregsts wlth paving asphalt at o central mfxlrrg plant until all aggrsgate particles ere a un I f or•m 1 y coated. Asphaltic concrete she:i be 'ype 1, Class r, viscosity grade AR-4000. Emulstflcd al t (seal coal) she I I be grade SS-1. Ahsr requested, Contractor she l l l urni sh the Engineer with a Certificate of Compliance stating that the moterfol substan- 1r,r'�1!!,",ti r tlsl ly meets the specifications, •' Irr;'�t!r , t1 Quentltles of asphaitic concrete col I be as measured in place and compensated for i, t ;1a4;tr i at the contract price arlpulatod par square foot. 12.02 WATER I ALS Pawin as halt shal I he stem►-rof Ined rrsduced train cr rda es ha I tic etroleus or M yy�r g r ,p N IF a mixture of refined ilqu(d asphalt and refined solid aspho It. Paving asphalt shall be homogensous and free from rater and residuen. obtained by the artificial distilIatlon of coal, coal to or paraffin oII. Agyregatee shall be clean and free from decomposed or organic ma+erinls, artd other do aturlous substances. Cos:se o gregate shall be crushed mineral rock or crushed air-cooled blast aurnaca slog. Tee portion of crushed rock that is larger than w!II pasA n three^aighths- (3/8) frch sieve shal I contain fifty (SO) percent of particles having three (3) or c xe fractured faces. Not over f ive (9) percent shal i be pieces that show no such faces resulting from crttsh!ng. Of the+ portion which passes the three-vlghths- (3/8) inch sieve, but Is retained cti the No, a sieve, not more !ban ten (10) percent shell he gravel pert is lea. Fine aggregate shal I be sat+-1, rock dust, m 1 nere 1 III I l er or a bland of these Materials. Sand shall consist of natural or manufactured granular tniterlal with ore -hundred (100) percent passing throe-slghths- (3/8) Inca sieve and seventy -flue (75) to one -hundred (100) percent passing No. 9 sieve, Mineral III Iler shal consist of port Iand cenegt or finely powdered material mechanically produced by the crushing of rock. Eaul sif loJ asphe 1+ (seal coat) shal I be homogeneous throughout, composed of a Wtuatlnous :raterial uniformly smul s(fied with rater and an emul slfying or stab) i l- sing agent that when stored shall show no separation within thirty (30) calendar days after delivery, 12.03 PLACING WHALr(c CONCRETE Contact surfaces of cold pavement joints, curbs, gutters, and the IIke 0LII bb painted with emulsified asphalt, grade SS-1, immediately before the adjoining asphaltici concrete Is pleeed. At the time of delivery to the project site, the twpereture of the, mixture shell no* be lower then 260OF or highs,.- than 320PF. Asphaltic concrete shall not be placed when the atmospheric temperature is below 40 F or during unsuttabie weather. 31 ..l + ,, a c+! + . t 71 A h` r � � t'�' •�'r r t {51j r} �, _ + 1 :�1 r 1 , ,' 'it + •-.�L r r ( Y,�(jr�. er� �� f r � tr { �'r �, �- � r ''�. ,j: , �ti '� ,'. i„\, I 1 � r � t1j�/t� { � � �•� ` T r 'i t 1;.• ' ''f� ', lr' '� �:1; ; / �arlr `. I�* +}+j', •'~ It >>'\7� iii��� /�! 1 �A } (r , + r + j � 5 r ' ! , a . + ' ' >t •jl. 7 � i' tlrj5;t+ F'r�r ''� S1 I-,' ; • ` �. 1 a •`r ��{ ,� :.' + 1 r -. t! r4 it�ti t,,.t � .. { ti, �,,} C' ,� {r�. '�' i r {'. Ytx1 '. 5,. 1 t� tl , •r ( lr rl 5�. j',l�t ,r 1 h It'll + `) �t ',r1ti �rY{tea ,��r. �S+• •r }� 1 ,' �r��r } 1�1� 11, �r 1 rr + `': `r'' � r. { � t''� �t t ,'y ' j{�St ' :�i j ZIP• 1��'��i awl ,} `�iy,�* +S j�+.y �r+fir )���1+�•r?t yi ill A.:• ,Lip + 'i: i, '' - 1 , �.� :r �n=1', �1 i �: trl i`��{ >r {l�l=i y� f �• r �L /j ,6t���;�'���� •5�+�r,7 � 1•,'. ,lr''. •_ �,+ r y) •'� l; `I `?r �rsir+jl([�".1l l+h�+rt ,y r� �S•,��ri !;{y�'� .SI2� +; .+r,`°'�1��1 {;�9t., �►�1 ,t �.lr ,.> `, rt r r� ,. ,;. 1, ,. ', , r''{� V j ! `.i-; 7"`•• + , _R i !F•„�11 A'4.�1f `� ,. 11, , i,+ r, - 1� r '�j ,. 'r/•?'!t rIi �..; • 1 �r r 1 + 110 W n nbc 1 t � " •. -', ` � r i i,' 1 • ,u, Tf' t I 1 i / / SS •i Y .y .1 't t,. 1 .I .a � 1n.'1.''�' ' v . ,4 :,7�1 , �.Y • 1 : it f 1 oil ;lei yb f !� t 1 rt' tr • tt r 04' .- y 1 11Y S'k I� ••}�,..�.1 r•i ra t ry..,,• .1 i...... �.�..tirw«�ti...-�... ��.�....r.. ��._..—...._.�.— __--_..�. _—"'�..i� ____-��rtK'.• J:1��-f:l— 1 740"4 M.1 M1 ll ill. l • t j y l\tiIil'r 4 SECTION 12 ASPHALTIC CONCRETE ' I �1 11 • ' ' Asphe i tic concrete she ( 1 be e, on I y spread up" the aggregate subbrse to such a 1;. ''•`•'t' ';;,-� i�i-I,t,• a�!'� depth that, after rol I Inn, It wl I I be of the speclf lefl cross-section and grade of the course as shown on the drarlNs and specified herein. �l t {• ,,.1 t3;' Deposliting# distributing and spreading she I be accomplished In a single, . continuous operatlor, by means of a self-propelled, mechanical spreadinp and flnls.3Ing machine equipped with a scread or strike -off assembly capablei of being f ::' iri 11 >✓, '.,' accurately recu{aced and adjusted to distribute a layer of asphaltic concrote to n + '; 3 1' :I I �;1 A definite pre -determined thickness. •, t 'n Aspho 1 t Ic concrete sha I I be thorough I y uampactod by ro I I ing. 1. i�, M1 •-11 �3, i, , The eeggcompleted surface shall be smooth; free from ruts, hasps, depressfons or ular tles. My ridges, Indentations or other objectionable marks shall be elhel 1 12.04 JOINTS U. rr Joints between successlvp runs shal I be vertical and at right angles to the line lr. rt of the Improvement. Care she l i be exercised wl th the construction of a l I Joints to ensure that the "�7eaf` YI surface of the pavement Is true to grade and cross-section. Lappud joints will ;r1 not be permitted. I,r 12.O3 SEAL CAT APPLICATION r t ,1tr}y, r"1', r Dlstrlbutinp equlpte. it u.) I Izing a hoax or bar through a year pump ur air tank wlII be acceptable for hand spriying applIcation to one one -hundredth (.01) goiIon "' I•' /,t, per square yard. Lw 1 1 J,'� Uniform covorage it I I be required. 12.06 TRAFFIC STRIPPIi10; PAVEMENT AND CURB MARKINGS A`�1'4 u ,ZF Palming shell be In accordance with the Painting Section.W. ;{ �r .� 'L+ -��` t• -� � 12.07 i1EPAIR A!ID REPLACE9ENT t } t'' t�it;a 17„ Costs Incurred due to repair or replecamen• of defective or damaged work tshel I ba dJ i hl �j ! ',l� f'• O the responsibility of thm Contractor. L fl 1 f,46. riS<�: yfl , v„1• �ff�i' r 1�• ,47 32 IPiy 3'a i I 4r 1 1 ..i"` t~ ...«�^—'-- • it•�1MT} K. 1 -3 n t)' f, V ;�R Li .Jrt� l 1.• t-•tr l � =t ,�, ��t...' f�. (a \ +V 3 �xr < «t 1 < ,` r � _ 1 ,. '4 t f Zt :_� 1 , t ., 1 !r l .f.,. I��f t i� •}yt� I� f �• '% [.' t t� 7', I t 1' t7.•�I 1 ,L 1(i� .•1. tvt��.<if Yj.= t, 1 I +�-.` � ,-;1'r t `r 1 I'' , P •I [ V' . I III` 1i i.� lJl.' �� ^+r `•n`f• 1y f r l . t ;, � ,I 1� ' �4�W h ' r {t1.f,__I$1 I n r 1'.,Zt„ tri _ t a 1' i ♦t li 3 1/ 1.. l� .,df. t [ . rr• t ` ^Rt�l., rl '� i ,y' ,S :fi 1 � t !,> U � "� , 1 `t t r `t[ -, 1 (,ay f 1 _ tS"�{-1 ) NX{ b t'> ` Y t I. � t ,t�((: �3 l 'rr �o� � �, 1( �1. •f \f 1 , r �/ t 'I l� ? 11 �(l _ Ir% � P• L�• Y�l . � �. 1� e� {.• �• 1 r •ilt �\^t+�( ri�t`!;r 1 4V..{.';,,• .. WI /'i,t4 (r r'•� :t�,iF L�`r^I �,7i tC Im •tf• 1 fi.i L' 1 � , ,1' 1 I l -. _ l.:'tl t 1 4r t , _ t �'w {� � �, t .• i ) <L•, . 1.11 tl lt,il h tF6 I � t 1•T .til ri r r r1 �jt •y r S ! / ? r �, , , f `trc.,. �'�r t\t r r ,, •1 t ,\rj -;�' .`. i? ill ,1 i 1 L• t 7 r I / '� 4 ! '� '•4�T1'�t � '''�.�t'N'��� l kj,�• t �t +^ n lit ,1� , ( _ r[ 1J.?1 ll�ty ll '%...il�Il ;, •`i �t 1 r'.. t. I L r _�.. \^, 4i rt '1 ,•l.i ,r. {. ) �'r't ,'�.., _ 1 tirfl�i,,;�a 1 '� r,•tr••x�ft �_. _� '_' .. 1 -- I—.—_ -- ; 16 rat 4A V. EE r By ICI t, 0, f L Fi . L r st CONCRETE 13.01 GENERAL Contractor shn I I provide al I I aboirs, materials. and equ Ipmont to constrict concrete foci I Ities as shown on the drawings and specified hareln. Componsution for concrete used In tontlngs thal I be considered as included In the Contract price for each at tte various Items of work Invol v&j. Concrete she I I consist a I port I and cement, fine dggragete (send), coarse aggregate and water, proportioned and mlxid to a"aln a twenty-olght (28) day conprossIve strength of at least 2,300 pounds per square Inch with n a I ump not tij exceed throe 4 (3) Inches. Concrete shal I not contain reactive aggregate nr calcluti clilcrijo. 13.02 MATERIALS Cement shal I bs, Typo 11 low alkali Portland cwnont conforming to ASTM C-150. Cement sh:. I I be of tho same brand and type used throughout the projoct. Send one I I consist of natural or manufactured granular materla I , fro@ of do I atv- rious amounts of organic material, mica, lo&n, clay, end other substances not suitable for Portland cement concrato. Sand shal I he lhoroughiy and uniformly washed. Coarse aggregate she I I be composed of gravel or a blended mixture of crushed rock and gravel containing no more then flfty, (50) percent of crushed roch partlales hav Inq all faces fractured and not less than twenty-five (25) percent of ravel. Angre-ates sha I I not exceed a diameter of one and one -hell 1/2) Inches. H ndrng she I I produce a uniform, consistent percentage of each. Rock product's shel I be clean, hard, soued, durable, uniform In qual Ity and Ire* of any detrlmon- A'q tal quantity of soft, friable, thin, alongeteil or laminated places, dIsIntzgratoad mat9rfal, organic matter, oil, al kal I or other deleterious substance. Wa Coaarie aggregeta for resurfacing material shall be of tho classification, pea rock. Water shall not contain del oterlous, substances or any amount or Impurities that wl I I cause a change In the time of setting. dater shal I not contain more then 1000 parts per ml I I Ion ch I or',dos calculated nor 1000 parts per ml I I Ion of s u I fates calculated. The jimount of water used In the mixture shal I not exceed the amount necessary I'a permit matorlml placenort and consolidation. Total free water (the ot total water minus absorption by aggregate In a saturated surface -dry condition) shal 11 not exceed an amount producing the mar Imam slump specified heroin. I&W FORMS is 7orms she I I be free of warps set pl unb and true to I Ins and grade wl th upper codges .4� fl, flush "Ith specified grade of ffnlshod surface of the constructed Improvan:nt, and not more than ona-half (1/21 Inch less In depth than the spselflod ihlekness of the edge of this concrete to be placed. Woodan forms shal I have a not thIcknas5 of at lonst otiv and one-half 11 1/2) Inches and shal I be free of Imperfactlons which would ImpOr the strength for the use Ntended. Edges and ends she I I be square. Forms she I I be secured by net I Ing to side stakes of sufficient lon3th and cross -sectional are.-N to &daquately roe I slr lateral dilsplecoment Juring placement of concrete, spaced not more than four (4) test apart and dr Ivan Into the subgrade ve-tica I I y to a depth nat I *so then twelve 112) Inches, and so that the tops of I I be below the upper edge 0 the form. Forms J shal I be clean and stial I rocolvt; a coat of light all ImmodUvrolu prior to placing concrete. Benders of thin plank forms may be used on curves. Metal forms shal I have suf 1141ent rigidity to reslat springing during placement of concrete. Forms she I I be secured by means of ireta I 31oalras spaced not more than f lye (5) feet apart and dssfGned so as to be drl%oen below the top of the forms through openings, looking them Into position. a , 7ko 4 0 ;X ; 33 uaC V14 J -14 777 7. 7 110i t - 1A A. I_ L f Y1, is U� 1 14 Z .1 ". L 4 I's 1 Ip r tj A7 , t) - T 7 0 SECTION 13 CONCRETE Forms that I be Inspected prior to p;aclng of crncreta. Tho Engineer stet I be notified two-!rV-four (24) hours prior to inspection. ti it Forms steal I romain in p1cce for a minimum of twelvo (12) hours aftor concrete has -1 A .L,, been plecod. 13.04 REINFORCEMENT RaInforceitent she I I conform to he dimenslons and uetal Is shown on the drawings 271, end shal I be cl-saned thoroughly of a(( ruse, ml I I scale, mortar, oil, dirt, or C J: b It' coating of any character which would be I 1kh I V to destroy or tape Ir Its proper bondIng with the concrete. Reinforcing stem I she I I be Grade 40 or Grade 60 bi I I at stet 1, conf ormIreg to ASTM A-6 I I Varying grades snel I not be used Intarchangsiably In any one (1) slab or walk system. Wire mash reinforcement that I conform to ASTM Atttifl% Cauqa of wire and dimcn5lon of mash shol I be as Ind,cated In the details on the drawings and sha I I be so construct ad as to retain origins) shape and form during the necassarr hand) Ing and IV 4. placing of concrete. WIro mash In wal kv, shall rot extend through expenclon joint material. RaInfor,;.weent that I be accuratey and securey positlened so that ;t wl I I rat be d1cpIaced by the placing of concrete. r 13.05 TRMSIT MIXES M Ix Ing she il be commenced as soon as possible al9tar tho cement Is placed In contact Lith 39gragates but In no event shell this Intervening time period exceed thirty (301 minutes. it Concrete rsIx.rz shal I be of such design and construction and so operated as to provide thoroughly and properly mixed concrete In which ngredlents are uniformly distributed. Transit mixers shall be of the type, capacity and manner of operation of the mlxlnp and transporting equipment for ready -mix concrete conforming to current t "Standards for Operatlon of Truck AIxar5 and Agitators at the National Reedy-Mf,,;ed Concrete Association" and The "Trlxk Mixer and Agitator Standards of the Truck Mixer And Agitator Standards of the Truck Mixer Manufacturarli Bureau." 141xlng ar.J del leery of readymlxsKJ concrato shall conform to ASTM C-P4. Voltane of mixing materle I s sha I I not exceed manufacturer's rated capactly of the L MlA6r. Each mix shell be complete)-1 discharged and at I wash water 4mptlad before succeeding load Is placed In druA. Adequate control of reedy -mixed concrete shot I provide for additional water to be added anti mixed Into the batch at the project site. Amount withhold shal I not 1 1; 1 exceed trn and one-half (2 1/2) gallors nt water per cubic yard of mix. The total elapsed time bettesen the addition of water and the batch plant and d1schargIng at project site shall not exceed ninety (90) minutes. When requested, Contractor shal I furnish the Enqfnear with a legIbIn certified welghme5ter's certificate stating the quantity of cement, water, fine and coarse aggregates, time of departu-s end dIschargo time for each batch Jet Ivered to the project site. 13.06 PLACING; CONCRETE T I nsta I I embedded I terns, I me I ud I rig but not I Im Ited to, s I eaves, anchor bo I is or V: -amisnt, prior to pla- cmdults, Iii their proper locations, secured against d1spla. alng concrete. Concrete shall bw placed on a compacted subgrado or subbase material as Indicated n the drawings, free of ell loose and extraneous material, sufficiently dampened eo ensure that no moisture wl I i be absorbed from the fresh concrete. 34 7yrTT "IN V 411 Vit r yf + 70, 4 1 t I lit r ;� , , ` +!' .•,r7it ''r1pr ' •t; lriti ,~�1 r,'1 1 + ',t ,•� 5 cl`•` �'�lT�, . f*4 71 V t 3- .1 SECTION 12 CONCRETE A: Concrete Ilia I I be deposited to the raQuIred depth over the entire width of the section, avoiding segregation or loss of Ingredients. Concrete she I I be thorough I y conso I I dated In a manner that of 1 .1 encase rho rainforcomant, f I I I the forms, and brfng the surface true to grade and crcis section. Surfaca shall be froo of any unevennoss greater that. one-olghth (1/0) Inch when rhocked with a ton- (10) foot straightedge placed on the sterface. Straightedge 5ha I I be aval lab lo on the protect site for use by the EigIneer. 4" Concrete shti I I be distributed unIfornly as It Is placed, and strc tk ott and tampad by means of moch3nfcal tamper operated at right angles to the cooter I Ine of the pavement. Number of vibrators employed shall be sufficient tr. consel Idate the concrete within f I ftfien (15) minutes after depositing, then I i oatod to a smooth flat uniform surface. Equipment used she I I not hnve any aluminum comp-3nunts coming Into d frect contact with the cmcrate. 13.07 FINISHING Concrete surfaces she) I be steel Crowe I I qd to a smooth, uniform f In Ish. Formed I,,-- edges shall be rounded to a radius of one-hol (1/2) Inch. Edges at expenslon Jclnts shell be rounded to a radius of one -eight (1/8) Inch. Concrete finishes shall be as Indicated oit the drawings. No ad vartls Ing Impressions, stamp, or mark of any descrlptlan of I I be ponAl, ;a on surface of concrete. Concrete she) I not he covered with plastic shooting. 13,08 JOINTS Joints shrill be constructed as shown on the drawings and In accordance wlth these ;, �,1W, specIflactions. , 4Y. Expansion joints she) I be as shown on the drawings and at corners, radius points and at regular Intervals not to exceed twenty (20) feet an center. Such Joints I h NJI be filled with a pro-molds4 joint f 11 for of a non-extrudinill durable, bitu- minous resilient mmtarlal conforming to ASTM 0-1751. Joint fl lerfhall boa mfnlmum thickne-3 of on"uartoor (1/4) Inch and extend the ful I depth to wlthin on"uarter (1/4) Inch of thij finished surface, and shol I be placid In correct position before concrete Is placed against It. Holes or Joints In the filler shell be 6 1 1 1 -A with mastic r- ..&I— I.t. shall A-. ...1-4 with a I sultIAM j A wator-rroof caulking. Control joint material shall be a T-shaped plastic strip at least one (1) Inch dehavInsuitable anchore to pro -tent vertical movement and having a remov- isp# g ag able le stiffener wlin a width of at least three-quarter (3/4) Inch. Edges shal I be finished to a red lus of one-@ Ighth I I /a) Inch with d silt J.31 n *or tool. Control Joints shal I be at Interval i not to e),ceed Ton (10) feet. M Saw cut Joints. where speal f led, she I I be as shown or the drawings or at Intervals not to exceed *on (10) test nn center, and sha I I be cut to a mIPfrum depth of three-quarter (3/4) Inch and a width not to exceed one -quarter (1/4) inch. 13,09 CURING Curing compound she I I consist ai a I Iquid compl yIng with AST14 C-309, which when applied to trash concrete by means of a srray gun, of I I form an Impervious mom- brane over the exposed surfaces of concrete. Curing compound shell be a blend of pure waxes and alkali -resistant p 19monts In a solvent Gimulsions manufactured by L. M. Scofield, or approved equal. , rct FF t UY 35 A - "A V 12; V 7 iIt 10 ? L NOT % A7 P 10 A t; 7"1 ry A�1 �; r M10 SECTION 13 P. � ,♦`' ':.. CONCRETE 1 r 1 ' Rate of application shall be sucn that the compound forms a :ontlnuous, unbroken .lash }{�� Cur ing she I i commence as soon as free water l eaves th,• sltr f oze but no l ater than thr.-+ (3) hour- tot lowing placement of concrete. •. ,t k', AM+}a� Soraying equipment she l be of the ful I etnmlting type, equipped with a tank ,•;r1 ' -, �� ?'i`i agitator of an approved typo which prov idas for continual agitation of the co�r- ,} r, ;_ ♦� ri pound during appllcatlon. 13.10 REPAIRS AW RLPLACEWNT r-%sts incurred due to repair or rapt actment of dotectivr the reeponslblfly of the Contractor. 13.11 BACKFILLINO BackfIIIIng shell be In accordance with Section 10, Ear. -WrIltEll Iry ., 1'r�e4yi y�71 A At •i � r I,t fit;•, �, t,I�t�_, •:5 f36 R Y 1t7:, 7•. �i',,' ir-.�•.------.—�..•...:.•--,way +....-�.-. �.. :...... ,' `'�;/ A rr'(,nidet�r%1 1•jr� YI I .I.�f JT,,. Jir,`i ;c f•. I S .r'• r ► 1 F Sri. � 1 ,.: , ! f� r r'' !' �t F i It' ► 1' +' � ►[1'1xY. 1 •i, 1.2 y r jfNt 4y,} ):} ttr ,�° y ,1vr�`�t�k '.�`1ri .}: ► ✓,; r {t}. '�•r�'^^�!„Vrj tliry,r I(t'II fr'i'iAi�Ji�r �i�j} ti4 I "_e1 J yrf /,.�f Y� I. rrr��,.r I}1',j J"'.'..t ar<� t•�. , 1 1Ij r, � � �, r} 1'ri 1! t•.K {i I r,�� �i {'+r r ,-� 1 1 ii . r {� Q' ♦ ti{ i'♦ r.;� C fy`«iy u `:•It r•1 r,; , .Ji �a�l.,..���1{� 'cl iy 1 i' ffi r� �� i� ,. 3 •l 'f I , ,�'+) 1r! '•1 ;.{i ��I►r � rt' z t t i r YJ t r f ;' �;�• ��r/n1�liM�lrY�f'r «Ir F�i;r 1,`i'.._ +L � ,,r r r/ 3. + '� . , i' _ ., n� I• , 1" t + '� ties 1� I 1:y � t• r tie' ! erl ..t .. .. ' f♦—' j 1 + tt .o , 1 it '•cl,: ,„ ft�, + it ` 1,1r{[[ �atj , ' [� Sri 11 I ' � 1 ' ,, �ii, .rl. ' I I I l ,. ' \ ; -1 .. �.�,.•.+ ' /(, 1, 'ili.l 1 I `✓. i'' ,', , , J . �Z',YI•Y .�� . __ - .......�..�� -�-�.. .�.-.�.. .- .�r�Y - -. . II .. .1. _. ...., ... .-1.�.�1. .r +•, t t'u'� it t iy tYf x %tS,r" max f; 111� t1 1 Tt LErrrloN 14 ROUGH CARPENTRY { s 14.01 GENERAL II ' I , Cort^actor she I I provide a I I I at,or, meterla I s and equipment to construct woaten Rtructures cunforming to the d trnens lens and details show on the drew ings and as specified heroin, ' ` 14.02 MATERIIA S Lumber shal I be straight; free from large, loose or unsound knots or knot i TF `:,ijr. clusters. scars, dacby, holes, insect damage, -,,d o`htr detects or Imperfections that wot.ld malarial ly Impair the strength or ouratl I Ity. Splits sha I I be no longer than the butt dlm+,nslon. No crocks wlII be parts Itteu. No nails, spikes, t J •.{ " �" i or other meta she I be present. s y IV. ' grade marlusd by a lumber grading agency cor+lfled by the All ss:mber shal I be American Ltzabsr Standards C'ommlttee. t Douglas fir shal I bee selected as to file s I za and grade as Indicated on the dra- wings and shall conform in al particulars to the Standard Grading Rulea fcr Its stern lumber, published by the Western Mood Products A3socletlon. !+ Ceder she) I bt selected as to size nPO gredo as indicated on the drawings and "SSsiii;�; shot I conform In al I particulars i o tho Standarw Grading Ru 1 as for Nest Coast fz • �,� 1'' ;; '; ,yap - Harrlaare shal 1 conform to the Ml sca l Idneous Metals Section. Unless oche-wlso tl vi r' specified, nal Is shel i be galvanized flat common. hl• j' ^I'i Poles shall ba cut from sound, I Ive, close-g-alned trots, free from large, loose or unsou') knots, scars, decay, toles, insect damage, or other eafects or Imperfe- r rrl . �,•.., uJ 1 f.t ctlons that wouf d materla 1 s , W Impair their strength or .lu; eDl I Ity. Poles she l I bb machine peeled and el I branch stubs a overgrown knots trimmed f lush wltn the ',l , . surfarre. Pb Ise she f I be frees of nai i s, sp lkes, or other mstn I, and troated with + '" +'�`z pentachlorophsfiol In accordance with applicable standards contained In tha t ;� 't 'tl •,, •� r'i', , nnerir.an Mood Products Assocfarlon manual. Tops to be chamfered ono -fro f f (I/2) Inch, and edges sanded to remove sharpness. r f k':►1 ' ' � �� : % 14.03 TREATMENT AND PRESERYA i I VES � • + � ' +•' K t4 + ,rx Typo of pressure treatment or preservative shal t be ass Indicated In the dotal Is on 0 the d^avings and slal i conform with the appl;cable standardse contained in the ,i, •� ►x' ;� •,� ,� .�tiz~�nf�);t + - Manual of Focosmmendod Practice of the American Wood Preservers Assocletlon. When requested, Contractor shal I furnish the Engineer with a Certlffcate of Ciampi lance for each load of pressure treated lumbers t♦i3R,«; l r «t /'itrr y�iJ ...•�.. M;1are a particular method of preevure treatment Is not indicated on the drawings, yaf' �r u_Q,rttu ' •{iC , f a+ ����r,.' t f ,• iha I umber she 1 I be aondltionid, seasoned, prepared and treated by the empty cql I pressure process wltq pentachloroohenol with sex-ttnl•hs (0.60) pormd4 or cubic .;�tJ t, ;- •' . p foot retention. Ponateatlon shal I be determined by the pantor ch+yek method. Icat Where ra, , treated w000 shal I be cut to f Irrai size and trimmed' '�I � 1} / •' p • prior tf! .5 y,•1 j f : y f Ir Ile ' t';,+{! )h !'lei ! treatment. it site sawingg or drl l t Ing Is necessary, cut surfaces shal I be thorou- 1:+ �{ • ;. , - t ghly brushed with two (2) coats of the same kind of preservative In conformance ,1� ;•I is f r: + �• erg+'� t r t ! � 1 ► wiih AYPA Specification M-4. The maximum protection required as specified thersrn `• y ; k i.r ,�,� G " she I I be mot in e I I Instances. 1 ����}'", ar• .r i 'k i 1= At the time of application, the moisture content of the wood steal 1 not exceed tw.'sty-five (23) percent and there she, I be no free mols+ljra an the, surface. ,'' f �i�y�,'t:f+R r, •� ,;11 P, rasa: vatfves she l l not bee I led in wet PD or damp weather. + r y) Portlons of y r, y, , , posts which are to be embedded In earth or concrete she i I be brushed t Y c •ie , ,: betore InstoIletlon with two (2) teats of creosote a: Perna -Dar, an0 non -toxic , r,•;'; ISi ceramic coal tar'comaosltlon which has a rust Inhibiting chemical in a water bash of homogeneous consiotency. Appl Icatlons shal I extend one (1) inch above finish kl ,t4 lrf, +';{;! d grade. Sprey�ng ri I I not be permitted. Parma -bar Is oval lab Is from Pock's s r �C f,` ,',,• Products. 943 upset Orive, Costa Mesa, Ca. 92627, (714) 642-6131. y Kit .� ' Y-. � 1`•' `Jr t.���y1" ,, i^ It.t. •�il 1, fn Y !. 37 WA 0 7771 �j ` ram} y .'1' M1,,� 1•, i Y f ,•' /��s�I�'{fyl i.+..(! J{ x `.Y�'.J tf�fr r'Yl s ./ 1 1 ..y. i.i1cC `'x t'SY. 4`y�f,, , 1 t. •�• ;yrhiy},'�`,'+ If'+;J'+ , It' � i ,, I '+' f :� 1 .<t;�±yT gg♦V � a;7/�1 /{hii7f. t'a Y•err{r77ri1, .t,. :`.(, +: !!�' t fl; Ni ', ' JM.ir, 1 ,! tit ,� - )! rit1 ,. .\ . d � 'C� .: , �.' 1 /�,.. , -•1 r'.��(^,`.. ,till °'.'i+f' Vy '•' �_. jY i. f, I .� rl`l i ,1, , ;-! ,.t', 4 }. ,i�'L: r• Ir r, :ti ` t,i ,� J f ,t,��. 7`..ilq�'1�"s, r 1 nR. / .i,t , , •yl-7 .t y / ra 6t�r�,A u1V`� �� ( ,yrr��':�y'. t ,' ll- l ,•/ , ,�' t. '.. ,n 1. '��Ii 1l ' rt. t7 l�tr� '�f l�i} i,. ), t,'ri;J{4,1.` , !'•w.:79 .,t lDf 1'�Ir�l byy 'x 'r •'1 � :, r{ t: xt :i ••' r,` .,,, y l � ii;Y �• � 1'.i Ili Y, f '!. •` i • , .1 I( 1 ! I: S: i'" 1 •:t 7r .n�rS � R !7- �' •� f +. i.l�'.•' }.• 4 • l' r' it 1.' ', ' •' J J ' f/ i 4 �, f .r f� 1 '.r �•.. it P ;, T 1 ,' •; )f+14+?�1 '* f ,J .�• ` , i .1',.. .r/ , (.. ., r, t•J';r'� 1 t' .3 ;'• ���, +S!+Jx'>',2r I ft ;' a '+ f+' * �f' ;, a� J'. ri1' ,!itj i i!X i• I tl�i tl.,11;FL '�. (4. , j i t;'i, y t �/,'r l',. y ,l J,1' C � I' j�� r�.Yr NJ:., l;.y f r •�' ,,h •�t1, t{��e �r1 "/ , t.' _ / ,` t .1.' i. ,, !t. t�} I 1.` ., a ' !�,' 1`r � y�/' I rir I • 1. ;A AI r ''•� ♦• r� J s rot I 'o � '�.,?',• � t jftl 5• c '�` r ' ' . t.( f l •\ -`,.1 t 1 � '� f :.f' } 1 1•iJ i r 16 T, V It - It It SE'"ICH 14 ROUGH CARPENTRY t 14.04 WORYMNSHIP Framing shal I ba true and ovact. Al I lumber and 1-;mbor shal I b,3 cut and framed to a close fit and she I heve even Larring -)ver the entire contect surface. All mmb3rs she I I be true to sire for the ful I depth ?.'.arvof. Ile sh Iffi.al rig wl I I be permitted. Lunber she I I be we I I na I I ad or boo I ted together as Indicated on 14m drawl nqx. Nails steal I not be oriven closer tugether than one-half (1/2) their lungTh. Whenever necessary to prevent the lumber from spl Itting, nal I hot as shal I be .'At! zs predrI I led. Care she I I be taken to avoid hawarmarks, moons, tips, or Sao cuts. Lumber shal I ba stood no fly In plies an skids. In such a manner that the/Ina} be A V .. .... readl I y Inspected, and she I i be handled In a warner 'thit ol I I avoid Injury or breakage. Treated luphar shall be handled with rope slings. Cant hocks or allier sharp I nsTr utsootit she I I not be used in Kind I I ng created I umber. Undue Injury In han- J T d I Ing wl I I be cause for rej eoc` Ion. 14.03 PAYWNt r No sep.,irato payment wl I I bo made for work under rnugh ep.,'-pantry. Compensation I I I be cenildered as Included In ilto prices bid for thoro vartrus items of work involved. I,11 A, r_z t Y. ?i, 10 5,4 11 vv �E 38 —7 .7. it /* 71 i4•, -1 " i - - - ; . I I , " 'I I I, , '- 'I - 'I , , , t . . , - - � 'J, - 'M "J., r 1 ; K, 7- o,: I i, t,. - S t11 iCI.LLANFLU S HFUL +i Contr.tctc•r• An prcvIdo ni l I W r, materials, and r+qulpount to furnish aim ir- stall ill, ..:I Inn,•nu- it.11 Iindlent,;,f nn tho +lrn.:!u,ls and no SpeaIt1041 i In. r' ii•I WIca Qns not Inc IWo rolafor!"I srucl Or ;uncrnra ind c,honr'y n,- Itry It; it iri ,•11h Irrlght Ion a" oI c]tr Q)I r,7k. kAf n roujistud iy Thu Enginner, ;map dravinys 59a; I t.o sutmlItoI I,1 tr'Ipl I -:at., io+Ing no!:! In, dimunwIcns, slln'1 c„ r•It t;ol- •nil ar 1 Intc,;nflnn ;md dat•t n 1 rc-,- tat.-I.-ticr of cr'..11 it+-,u. 4n:f ;I) it ,rl II tit) roturrmd to 'i..• i ' fr1,tc . Worl." neshlp nod f Ill .I 1, 11 1 r:. thin' to thn t r.t gr.nnr-r l In sto31 fat-Ic tr Inq ^hops. ' 1hu use of parolcular nothods dart oqurpr,ont shaII bo suSJo t to tho alprcvnl at I, Th f hog inonr. 1r. 1 ; ,ipprovo l sno t I :ant rr, l lovu thn Contractor of tho 4 rnoponslAllity for 'h't Moty of such r,othods and nquipr,ant, or for cnrrying nut i Y1•t 1;trr In ful I munnWanaa with thn drawingn and 4Prc111cotlons. Q taLrlcat)nr1, r .3 Ing, cutting, noIdInn, assa.nh!Ing or pat AIng OnII bs done � I Othout tho c.n:l1. knnttIedore. Any r r•k dono othr+ Oaf, wr I I h,^ %uhlrct t- t "" r o",,..t Ion• Tho accuptanco of ony rintorlul or t!nfshod rnuabor by thr rn!llnnur chnl I not pracIudo tha poss151 i Ity of subsequent rnjo:tlon If found ro be JoIM1vo. CosVi incurred for rnp Iacvnent of rnJewnd ?feria l s or wcr'rtnnshlo On i I -o the rospcn- s1b111ty of iho r'.-�n'ractor. When requested by My Englnoor, W or Q tabrlc3tlon, cantractar Shell furnish a rj t ml I I vortifi+td raport containing thn i onul is of ch,imlca1 end physical ttrsts ra- quiroJ by tho ASTII spoclflcatfonu for tho mstrrlals htln!i fabricators. .'j,�. Parts shot I by nccurate I y sssomb I A ca ;shown on tho drawings. Ntstn la I s sha I I bn earafurl ly hnndlod to avoid drrnago. Nnnaer!nq whleh wil I in•Iuro rr dlsrort nttnhers shnII not t» porn ifed. I Portions of wo-k oxposod to vlow shell be IInIshod nantIy. Shearing, flomo 4"0 Ting and chioping shali A done carefully and uccuratoly. III sharp cornars r.r.d edges that are narrud, out or roughonnd during orocTlon stealI b': slIghtly rounded by grinding or othor moans satisfactory to tho Enginon,. i'• r ar +1 7 ;i; r 13.03 h'EL01 NC: .',1 <) Hniding, woldar quo IIfication and inspo:tlor, of welding operations shnll conform to the roqufronnnts of tho American waiding Soclero and thoso ,pucifications. t:, Feld voids shut1 ba cleaned and Waisd ulth d cold -gal vonki l compound. +f' ' 15.04 P ATERIAL5 All mntarlals, prior to tabricntion, shall be thoroughly wire brushnJ and cleannd of al I scalp and rust. FlnlshaS mWars shot I to iroo from twins, bonds rr open �. Joint.,. r7 HI sco l l anoolls mote l I f cos nha l I conform to the d inons lclis and duta i l s as shown it ' thn drawings. Stool ears, plates and shope, sha l l unform to ASTIA A-36. Rolling and cutting tolnrancns, permissible varlatlons In walght ono dimensions, } " ! Ofects and Ir,porfoctluns sha I I no, exr:ond I imlts :onlalnod In ASTH A-6. r �f 'w+ 1 IryS ;!3 tl , 1• �- .,. , rill +�. I�,+J f 1 �rdi !, ll•Wr �: ,, 1 yi t+ , y. "r,A1' t--}.� � I � 'r r • e '�r l��I fry ,I�:,r '�. 01 �!\„ rIt r�l ,tt. I. ,.f rU.�,`t t '{3,lt 1.}tp�t+th d' •t +117 `If ,t + ., .. .. - , ' L� '• ;r ftf��I Sil�r .1 i� ��} +tr' •,:' •. 1.''1 + r!41+ ,r , 1t ��++r7 II t+ IMiP.o.MM.w..M,►y.►au.., fir 1° 501 el 15.05 DOLTSI_ NUTS AND FASTENERS 501 el 15.05 DOLTSI_ NUTS AND FASTENERS [to I ta, nuns and fastonbr-,# !;►:nl I be as specifled In tho dotell Is on thj drOwIng3, corstorAiln(l to AS71.1 A-307. teats sha I I be long enough to oxtend entirely th,-oLqh the nut but not more than 000-qua-tor (1/4) Inch boyend. Unless otherwise spocIllod cn the drevings, voWisrs thOl I T)WI bb f1l:'11100411 7 Ib I at; %ha I I be tj I ther punched fu I I sl ze, dr I I I ad I u I I % I ze, or nub -punched and roalood. Finish holes sha I I bo cy I Indr I ca I I porpend Icu leir to the p I anot of tho cunnnctlnii And ono -sixteenth (1/16) Inch largar than the nominal diameter of the bolt; tree of burrs, I Ins. sharp edgns eind hole Irreh]ularltIoi which would prevent tiol Id sE-at'.Ing of the parts. Anchor bolts sho I I bo carat u I ly Insts I led to pom!t truo positioning of the blotat-Ing a%;sombIlo5. 15.06 GALVANI ZINO Co I vnnlzlng shn I I be porform)d of tar fabrics^, Ion and prior to ascamb I In!] component parts. rabrIcation shal I Include of I operations such as shearl'i9p cutting, forming, drl I I Ing, ml I I Ing, banding, welding, and rlyot Ing. punching, Zinc used for gel vani zing sha I I be grade Prins Western conf orml nq to ASTM 8-6. Mdtarlals, shall be gaNanIzo,1 by the hot -dip m0hod or alectrodopositIng process. Mlnlmur. walght of coating she I I conform to ASTM A-123 for stool bars, platys and shapes, and ASr,4 A-153 for bolis and screws. Zinc coAtIng sha I I adhero tenaclougly to the surfe-co of the base motel, IF roo from blIstors and excess zinc. Coating .1hal I be even, smooth and unlfrrm throughout. Galvanized surfaces that are abraded or damaged aftoi, zinc: coating apollocatlon shall be throughly stripped and cleanad by w1ro brushing to ranove all traces ol. we I d Influx and loose cracked coatIng. The cIcined area shell be rpaIreb t Off" coating of "galvalloy", or approved scival, or of' a zinc coating appl led by, the hot -dip procossp or painted with two (2) coats of zinc ox1do-kinc dust primer proparly compounded with a suitable vehinifit In the ratIn of one (1) part zinc oxide to four (4) parts zinc dust by wo',ght. Finish coat to match existing flnish. "T Method or repairing damaged ereas shall be as ^ppravod by the Englinnar. 15.07 PAYMENT No separate paynopt wl i I bo made of any work perform Ad rolatad to mescal I aneous mo?als. Compan5ation wl I I be -:onrlderod as included In the price, bid for the various Items of work Included. W le 01 L 4 0 ?'h A, J�A It tV V, I I ''I I . , I : LaA I +. r,. II •' � r. I � 71 r• SECTION 16 NON-VEGETATIIE SITE MATERIALS 41 16.CI GF.NERAL Contractor shell provide a I I labor, materials and equipment for fu,•nlshleg and cpreading or applying materials .is dotal ;ad on the drawings and spuclfled In this Sactlun. Contractor Shall be responslblo for ostabtI;hing Subgvade and providing drainage In eccerian^o with Section 10, Earthwork, and performing wood abato,aont operations prior to pl ace,nent of nun-vegotativn :natnrlel :. - I t 4.. • fhlcntitlus of non-vedotetivo m2terldls will be as moasurod In place and tampon- , sated for at the Contract price stipulated pnr cubic yard. 16.02 KFED ABATEMENT AND SOIL TREATMEVT Contractor she I I app I y, I n areas to be Instal led w 11'i non -vegetative materials as described In this Soctlon, a solectivu pro-anorgent, surfaco-applled horblclde. Surflan, as manufactured by Elanco, or approvod aqua I, at the rate of (Iva and Tt one-third 0 1/3) pounds par acre. App) Icatlon method she I ba as : oLcmmendod h�l mrnufacturnr. Visible woods shall be sprayed with a non -selective, pon+-wnorgont herbicide, k7��1 1�'• Paindup, as manufactured by Monsanto Company, or approved equal, et the rate of 4 f I ve (S) quarts per acre. Appl Icetlon method stial I be as recommended by manufacturer. L Contractor snoll apply spray chomlcals when air currents ara stII I; preventing `'�i o 1 gritting onto adjoining property and preventing ably to+riz orposure to parsons whether or not tney are In, cr near, the project. ( !1 Chemical treatments shall be appllad to the satlsfaetlon of the Engineer before placement of non-vogatativo materials as described In this Soctlon. '.I. CO 16,03 SAND i Sar,d for play equipment areas shot consist of natural or manufactured granular material free of clay, deleterious amounts of organic material, broken glass, tens �,1• or o:I1er substances not suitable for the purposes Intended. Sand shall be th!rou- ghly anO uniformly washed. Plaster sand Is unaccoot:ble. :^ntrar� r she 1 be responsIbIa ter loading, haul Ing and placing sand to a mintmun depth o. ,rlove (12) Inches as dotallad on thn drawings. ► �� Prior to send placement, and to the Englnee,'s satisfaction, the play equipment area shall be from of al I debris, concrete overspllls, spurs afld louse concroto t• r; • '- 1 rnbblo. I • - I _ { f ! C ' t 1 • l d � r��11 a 1t f ` � � •fit 1' , ,I '� �,� I �• �• •� i` t, ,,f • I A�, M + , ,fr 't} , • .r' N 1 I 1 t IVP SECTION 17 PARK FURNITURE and PLAY APPAP.ATUS 17.01 GENFRAL Contractor shall provide al I labor, matorlals anu equipment to furnish, assemble ani perform the necessary fine grading, footings, ennerete pads, 'Lalnting, essombly, ant, Installation of Sho Park Furniture and Play Apparatus as shorn on the drawings. Wt thing I I f toen (1 S) ca i ondar days after sward of contract a -id at least thirty 130) calendar days prior to Installation, the Contractor shall surmlt shop Lfra- wings or manufacturer's cut shouts to the Enginuur In trlpllcata. Ono (I) sat rill no returnaa to the Contractor. S•"r•I' loestiens for Park Furniture and Play Apparatus shall be approved by tho i'nsrs� fr.• prior to dlgg1t,g for foutfngs ur Instal ling ugulr"6nt. if; •ubstIfution for Nark Furnituro and Play Apparatus will be considered which Is bssjd on matorlai d.11vert sehodulos, fnbrlcatlon by conrractce, manufacturer' carrying less than 111,000,000 product I Iabll Ity Insurance or wood members of a J+fferent ►poclss, quollty or IIrionsVon. 17,02 INSTALLIIT i ON Contractor' sha i I Instal I all Park Furniture and Play Apparctus In accordance with the manufacturer's recomeandatlons for each Item of work and as indicated In the details on 1ho drawln3s and as spoclfled he-oln. Touch-up galvanized i'rface blomist%os with °galval loyrr, or approved equal. '(ouch - up ungelvanlzed painted surfaces with r.r.t lead or zinc dust -zinc uxldo primer and finished coat to match ealsting flnlsn. Portloos of wood posts which are to be embedded In earth o•' concrete shel I be brushed before instailatlon with two (2) ccets of an approved non -toxic ceramic coin 'or composition which h,s a rust iahlb'tlny chemical In a water base of homogenuois consistom_y. Aypl iratlons shel I nxtend ono (1) inch abcve flnfrah gre.1n. Spraying wl l l not to pr,rmlttnd. Metal ccmponsnts, connections and iastenings shall ba fror of Any burrs or sharp points and odgtN. 4 r 13ackfI I I Ing sheI I ba In accordanco with Soctlon 10, Ea. thwcrk. 1 j` lllilrr+ •If �;': r LI 1 T , i c ( A 1� , r a 2 I... 'ti: ��, .�! ''ll lit .r7 _�...—.._..._.._...—......... ...•Iw•r+,s..^ ... —. .. �.._...�....... ...................•..�.•w...r(.-..», f! S I �.. �i•"7 J sT411- bl: �7 , i .�,•, ,� ''>< y '.fit ;( Tf, ,I ff .' • I r'" i 1 r '' ' r1� .Y.. 5 r J•� } lY, t�yr,v ( �� .i�l , r� L .1 .. 1 - ,� �' }y lrr,E f; }y{g"p�,�r i•{. r x; ll'. Jrl����i• li fir,.,_ r r�' .;, -! , •': .1 ... '�..:`��i,�„ It`r ,�+r`�r,'y�y. 1. �'Qs..} %�� 1 � ' } y�1 ���,r Cis-� � �+• '. 'T' 1 f� '� ,. � . r' 1 � r `s''" YtiE '�`�'� .Iraq°�♦, I t �: •.1 i, i, 1. , IV, trt �1a J11tj:. r, �. r�1 t JT y t 4'i��y .'�,`. I' ,'r ?,r l'' t{ li Y , c• ' . �. Pith. �/STr7l4t ,l• f, .•�/ �f'f,• i Y�1^r� :f}IF' •jt �1(?r y� �rM1Y� 3'S a yJ rI Zr, r 10.01 GENERAL Contractor steal I provide a I I I abor, mato.- In Is, and equipment niocossary to furnish and Instal I it, i Irr Igatl en system as st. )wn on the drawings and as specl I lud J 6 oral n. Including but root limited to IrrIantlon matorlais and ralatea appurtenances, connections to watitr and electrical Of I Itles, excavation and backf I I I of pipe trenchos, ro%:.ord drawlrg5, gueranteas, p.,rmlts i.nd I lConses. testing and Inspections and cloan-up oporatlans. Coordinate the Installation of all Irrigation materials with thu construction of slip annnitlu% and plaOlng, as Indicatod on the drawings. All work on the Irrigation system, Including hydrostatic and coyr.rego tests, oporatlona I tails and the backf I I I :ng and compaction of trenches shall bo rorfor- m3d prior to PI .3nt!nq operations. Lh-awlng,.% are diagrammatic end 3ha I I be adjusted as nocosshry to conform to ac+ua I f lotJ kl I t I ons. Co.;z Incurr.d duo to an adjuBtitunts for coverage, Including those roquelsted by the Englreor, rolative I• the location of Irrigation hands as shown on tho drawings, shall be the raFponsIbI I fly of the Contractor. Point of connection (P.O.C.) and oporatIng pressure (P.S.I.) shal I be nis Indicated 4i on thedrawings. Contractor shal I verity the location and size of water sourcF5 end a I actr Ica I supply prior to commonel ng instal I at I or. 18.02 QUALITY ASSURANCE All local and state laws, rues and ragulaflons governing or relating to any portion of the Irrigation system are hor0y Incorporated Into and made a part of It these specl I Icatl this. Nothing coataInad In these specifications shall be con- strued to cant I Ict with ano of the aforement toned rules, ragu I at Ions or requirements. Hnwaver, when those specl Olcatlono cal I tar or describe materla 19, workmanship or construction of a better quality, hl&her standard or larger 6I.-le than Is roquired by tho above rt at., regulations or requIromonts, those spocfttca- lions end tho drawings shal I take precedence. ,; In the avant any equipment or methods Indicated an the drawing or spoz1flee J. heroin conflict with applicable rogua I lone, Contractor she I I notify the Engineer In writing prior to Instal latlon. Costs for replaica"ont of such, Incurred duo to the fall urn to give such not I I IcatIcn, she I I be the Contractor's responslia I I fly. Due to the .zale of the drawings, It Is not possible to Indicate al I offsets, n" fittings. s I troves. etc. which may be required. Contractor she I I carefully Inves- tigate the structural and I InIsnod zondltlons affecting the work and Install a complete Irrigation system within the Intent of the drawings and spAcIfIcations, furnishing such fittings as may be required. where Manufactutherers'manufacturers spaclificatntionequIpmunts and detausel In lled cirawlnlthisr Contract shall bfurnishe followedInstallation In cases A W methods not shown In the drawings and specified heroin. Al I rateria Is she I I be of now stock and of brands and types noted on the drawings end as specified herein. or approved equal. Approve I of any Itams, alternates or substitute ; Ind Icalas on I y that the product aoparently meals ill spocIfIctlons as Indicated n the dra"Ings and h6relr. on the basis of the information or samples submItted. Manufacturers' warranties she I I not ref love the Contractor of I lability under the provisions for guarantees as sDoctf led In Section 5, Prosecution, Progress and Acceptance of the Work. Such warranties shall only supplement the guarantees. 4 3 7 , to AJ M I J I P, 41'. "1 .,1 r. :1 S' , z; J T SECTION 18 if',R IGA•i ION SYSTEM A 10.03 WITERIALS LIST Within tltteen 0% colander days after award of Crntract and at least thirty (30) calondar days prior to Installation the Contractor shall eubmlt to the Engineer In Trfpllcate a llsr of mrturlals Including tha manufacturer, description and model number and Installation data. Catsloq cuts and full descriptive literature Must be submitted whenever the use of items dlfferenr than 'hasp spoclflud are ranu4sted. Only (1) copu will be returned to the Contractor. When requested, Contractor she l l furnish the Etgftaer with Cori -It lcatus of Complion:e for Irrigation t.qulp"ont ;ndieatlrg thet the materiels comply with thaso specifications. Equipment or neturla)s installed or furnished without the prior approval of the 1 Engiuoer may be rejo:tod and such materials rumovod from thu site it the r' Contractor's expense. 10.04 PRODUCT DELIVERY, STCRAGE AND NAN31.1hr t ' It C.)ntractor one II exercise care In handl Ing, louding, unlc.tding, and storing of irrigation matorlels and oqulpnant. t � r l� ., it a,►-. Al i PVC pipe shal I be transported In a vuhlcla which al lows the Irngth of pipe to 1 to # 1 et so es not to he subJect to ..A., bend In g y con- n ra of erne load at antr polni. Any section of pipe that has been dented cr danaged .hall be rep I'Cod w}ih now t)po at the Contractor's o<ponse. j t- 18.05 PLASTIr. PIPE Plastic pipe shal t be injection molded; rigid; unplestlNiud polyvinyl chlorldn (PVC); NSF approved; of high tonsf to strength, chemical reslstanca and ImJpac! ' r strength; Type 1. Grade 1, Schadula 40 hydrostatic 0sfgn stress (PVC 1120). Min lmua pressure rating shell not be less than the working pressure for "hu f schedule and size of pipe Indicated on the drawings and specified heroin. Pressure mainline piping tvo (2) Inches and larger shall be PVC 1120, Class 315, conforning to ASTM D-1705, with Schedule 80 sol vent -weld flttings. Pressure mainline piping I ass than two (2) Inches she I I be PVC 1120, Schedu I a 40, F 'a1'•'�* ,�+ conforming to ASTM U-1785 with PYC Schadul a 40 Solvent-wold flttings. '.' Non -pressure lateral IOnes shall be PVC 1120, Sehoaule 40 conforming to ASTM D- is ►� 1_ t t L+� r 2241 with PVC ScheduI a 40 solvent'-'woId flttings. r " (� ;� " Fittings and coup IIngs she I be threaded PVC Schedule 00 conforming to ASTM D-2464 ;- or $1 fp-fitting, tai...r! socket, so I v xit-we Ided tyae, PVC Schadul a 40 conforming ' } to ASTM D-2466 a PVC Schedule 80 conforming to ASTM 0-2467. ( Solvent cement and primer for rigid PVC solvent -weld pipe and fittincgs shot I bo of '' t exemsrcia I qual fly. IAPM0 approved, conforming to ASTM 0-2564. fit. 18.46 NArErt PETERS I• Pr Service latere I and mat -or boar; have prey loual y boon insta I lad. The irrigation �r L, system the I I be cot,nactod to extsting water supply pol„ts of connection as ^; Ind'axtod on the drewings. , ., ilk I� 18.07 BAWFL0W PRE;t*NT10N UNIT Backf I ow prevention unit has boar praylous I f Inste I I ad. � rill .• Y f', . It �: ••i ,' i,.' Y• r ,`��,ItrJJff�J• ' 1 .hM►ey p,s, ` � lac 4� __ 55 1 ,r t� ,t � r,• t t4 7f (k r A'. lid ,!- i ri �JY •d� M p 1 fy Ir t�}rl /f'j, ll Slfr�;`t It,, •11 r 1 r ,rH 10 tf 10 1 nF"r, x(x y 'wY,t ' try Vil 1 I , I i~ r .f I* 101 10 Cr :1n f., [ W. ,I [ i lj I 3 SECTION 10 INRIGArim SYSTEId ,•,:_ r 10.08 DATE VALVES Gate v a I Yes sha l I be, bronin with ucrau-In bonnet, manufacturf d as illbco T-113, or aporovad oquaI, Instnliod as Indicated un thn drawlnps. The operating unit shuII be Ilna-slzed as Indlcetod on the drer.lnrgs end 4eve an erica cast in the motel Indlcat!ng the dlrnctlon of opening. Valve shell conform to Arorfcen Water Works Standards. Valves shal I be doslgnrd to permit dlsmantl ing to replace sa+illig components V i without rm"val of the valve body from the plpol Ino. �. Valves chn I I be Inst•s 1 led wit'' oporatlnj nuts, 18.09 ANTI. -DRAIN SALVES ' Anti -drain valves shall Do Toro Irtogra) chock vol•Ios or nrprovod aqual. r4 a 10.10 REMOTE CCkITROL VALVES ITI 'a:' r1 � ` • Remote control val. -ts sha' I be solenoid activated, factory assembled, a!s Indicated �3► } a i i( { ,t, In the Irrigation Legend on tha dravin -a, and Installed acc-crdin to the dutalls 9 e9 9 • 9 on tho drawings and I oca I ccdos. 111. 11 VALVE BOXES Valve boxes 'or gate ve I vos steal I be 0rooks Series 1100, 101 round plastic bou with sndp- lock tet cover pormanently marked by Indenting IGY" on the cover. M 7, �=. Ve I ve boxes for automatic remoto contr o 1 va I vas she ( I oo Brooks Series 1419, 14 1/2" x 19 1/2" x 12" plastic box with snap -lock tab cover parmanontly marked by ladenting "RCV" and station rumbov on the cover. I 1, Valve lax I Ids shaI I bo green Ir• color. Valve boue3 shell be sot tIush with finish grade, with valves sot at sufficiont depth to prov Ida c I earanco betwoon the cover and va I ve. a iS.1Z CONTROLLERS tip' Centro I 1 ers she I 1 be as ind icated on the drawl nps. Contractor sha 1 1 Insta I 1 r control lers in accordance with the manufacturer's recommendations and in ar {{' enclosure as irdicated in th details on the drawings. ;1£Yti+�t t'.{r•I }'''•" 18, 13 CONTROL WIRING Connections between the controller and the solenoid activated roiote control valves shaI 1 be made with dfrect bur lai copper wire, 014 AWG, Typo U.F., 600 volt. Mire shell be PVC insulated of single conductor type, underground fooder cable, L%I_ approved. Pi lot wires shrsl I bo a different color for each val vo. Connrm wires steal I be white with a different color stripe for each autcmatic controller, Tagging each ` and is an acceptable altRrnatf+e. Wire shell be burled a minimum of twenty-four (24) Inches In depth and whenever { possible shell occupy the syme trench; bundled and se.ureA to irrigation pipelines r f at ton- (10) foot Intervals with plastic electrical tape, provldfng sufficient slack fcr oxpanslnn and contraction. An expansion curl Oil I be provided within throe (3) feat of each wire connection ! and change of direction, and at least every cne-hundred (iW) feet of rite length on Icnger runs. Expansion curls shall be formed by wrapping at )east fifteen (is) ` turns of wire around a ono -half (1/2) Inch outside diameter pipe, than wlthdrewing the rice. 4 s r Y , I c a , A � t � L�A� f r • F I �l 1 i SECTION 18 IRRIGATION SYSiEM 1 ® All splices shell be mode with Scotch DnY Connectors or approvud equal. Use one (1) splice per connector sealing peck. Wire splIces shall be located In pulI boxes sot flush with finish grade. lflthollt prior approval of the Enginovr, IIofa splices hetwooti the contra IIor and smote ccatroI vaIins w I I I not he pormitrod. 10.14 IRRIGATION HEADS Irrigation heeds shall he of the manufacturer, size, type, and rate or proclplta- tfon with the dtamator (or radfua) of throw, pressura, and V schargo as specified in the Irrigation Legend and Insta,'od as shown In the dutalIs on the drawings. f Equipnent of one type and flow characteristic shell be from the some manufacturer and al I ovuipmront she) I bea,- the manufacturor's name and identlflcatiohm code In a „t position allowing Idenrlficatlon In the Instal fed position. i (41 klser units shell be oriented perpondfculer tc "ha finish grade, lneYal led ns .i indicated Ir. the dotal is on the drawings and specified heroin, with nipples of the sane size as tnn rlsor opening Ir '.he Irrlqatlon hoed. !! Spacing of heads shell not excood the maximum shown on the drawings and In no came � exceed the raexlmurn spacing recommended Gy the manufacturer. i8-15 PIPEL14E INSTALLATION } Prior to installation, Copt -actor shall stake all supply liras, rout ln9 , and locn•lnn of irrigation hoods for Inspection by the Engineer. Plpn shell be cut square and the ends roamed out to thn full inido diameter fo the pipe and thoroughly cleaned of dirt, dust aria molstur-) before Installtlon. Changes In pipe line s,zos shall bo accomplished with reducer fittings. PVC pipe shot i be protected from too( damage during assembly. Plastic plea which �' 1 ' has been nicked, scarred or danaged shall bo removed and roplacod at tN r Con•.-ractor's expense. t PVC solvent -weld Joints shall be made In accordance wltn ASTN D-2955. Pipe shell not be exposed to uator for twonty-four (24) hours after tolvnnt-weld Joints are I �: C� ecAplatod. Trenches shell be of open vortical construction to apprapr late depths as indicated on the drawings and spocified herein. PVC plpo shall be laid on a uniform compac- ' :.., ' +g ted grade, free of rocks or sharp -edged ed objects, and g J , snomcad from silo to side in - the trench to at low for oxDanslun and ccntractlon. Tat lon t;i 1 shall be used on all threaded PVC to PVC and on a)1 threaded PVC to (� /notaI joints. Light wrench pressure Is all that Is rnquirnd. ,a j roncrote thrust b I oc;:s she 1 I be Insta I I -id on a I I pressure main I Ines whorever , c, ' Chore 1s a directional change or as spec. lfIad by the manutacturor's j racprmerrdations. t 13.16 SLEEVING i Irri ation lines and central wirino shell be installed under paving In separate PVC Scheuu I e 40 sleeves. Sleeves sha I I be I note I led with the coverage depths as specified herein. t Flpfng under existing pavement may Do ;nstalled by Jacking, boring or hydraulic driving, except that no hydraulic G:fving will be permitted under asphaltic con- / crate pavement. Whore cutting ot- breaking of existing pavement is necessary, obtain permission from the Engineer before cutting or brosklrg p,wa mont and than a make all necessary repairs and rep Iacenents to the approval of the Engineer, and at no addltonaI cost to the City. ; 0 46 fJ i� ,r 0. - _. 0 SECTION 1© IRRIGATION S YSTM S Id. 17 LINE C! EAMWE ANO 00VENAGE +' At IInes shot) have a minlmum ho►IrontaI clearance of six (b) Inches from each other and from I Ines of other trados. Pttra I I o I I Ines steal I not bo Instal led dlroctly over one anothor. Prnvide the fol lowtny minimum coveraues for plpoI Inos: rossuro malniIn& 241 (•:3 iton-prossuro lateral I Ines is" VVitral wiring 24t� chord lines occur under paved areas for vohlculAr traffic, thcso cover -ago Booths ci she II be consIdero•i N Iow subgrads. 10.1B At))L'STiNG.Ai40 TESTING THE SYSTEM After complution of plpelInn essomily, prior to Installation of terminal fittings, entire systum shot 1 be thoroughly fIushod to remove dirt, scale or other doldtorinus material. Irrigation heads she II bo Instal lad only after flushing of the system has boon accomplished to the complete, satlsfaeften of the EntInoor. Contractor shall then furnish ell oqufpmont, matorlels and lauor to conduct pipe- 1 r• tt IIna pressure tests, coy orage teats and oporatIona I tests. All tests shell bo mrdo in the presence of the Enginoer, Prior to ,rood abataeor;t oporallons and soli preparation. Trgnchos shal I not ba beckfllled untl l the plpolino prossuro Costs have bean performed "o the satisfactlon of tho Enginoer. I" With open ends capped, test pressure supply IInes for six (6) hours at 25 PSI. j+ '"., f':'• ;,�r Center load PVC pipe with a smaI I amodnt of backtll I to prevent nrchfng and wllpping under prossuro. }' Coverage.t test she I I demonstrato that oath siatfon aria is ba lanced to pr ov ido I Q unlferm and adequate coverage. Operational fast shell demonstrate tho performance and operation of all components of the control Ier syst!.ti P,emote control val Nos sha I I be p-oporly balanced, heads adjusted for coverage and systom she I I be workabl o, c I nun and of f Ielont. Contractor shall be responsible for correcting any portions of thh work that are f not properly Installed and retesting until Installatton has been aecoptetd by Cho Engineer. 18,19 INSPECTIO14S ! t Contractor shall he responsible for notifying the Engineer twenty -feu^ (24. hours i �'r t In advance for iho folloaing Inspections: SyVam Layout Pressura Pipeline Tests i• Coverage Tests ,• Operational Test (prior to commencing planting operations) Coverage and aperctlonal tots rill not ctxmrence without as -built drawings. In the event the Contractor calls for an Inspection without as -built drawings,' without coarpieting previously noted correctlon9, or without preparing the system i •`,,. for Inspectim, Contractor shalI be responsible for refmbursing the C14y at the at rato of thlrty-flvo dollars (f35.00) per hour Iplt.-; any transportation casts at • twenty (20) cents par mlIal for the Inconvanlonre. No fur thor Inspections wlII bu ( ; scheduled until this chergo has been aald. j r I! ,•T. ! W r 1 I' 47 r + ji tt + .fit' t s " y' � �•, t . /., 'jp) •y t 1 tr ``„ fir t ,� f •�; i ' i "'• .1 ,j a II-- - Jr*.'-� .*�� 10.7.0 PACKFILLING ; Sackfllling shall be In accordance with Section 10, Eartnuurk. Trenches iyai( be compactad prlur to 3oll preparai'oon operations. Trenches located under areas where paving or concrete wl11 be installed shell be backfllled with a six- (6) Inah layer of send below the pipe And three 13) Inchon i above the pipe, and compacted In ae,:or'caneo %ith Soc1or 10, Farthwork. 10.21 F9ATERIALS TO De FOnNISNzb Contractor shell furnish the Cfty the toIIowl nq motor to Is at the and of ..anstrtntlon, prior to th,3 Post-Installatlon Nolntenanco Pnrlod. Two (2) sots of opoctel tooli rarlulrnd for removing, d Isasserbl Ing and adjusting each typo of sarInkler and valvn supplied on the project. Two (2) five- (S) foot volvu keys for operating gnto valves, r �; 't''' Two (2) keys for ouch contrallor and onclosu,'o, One (1) sot each approved mylar reproducible as-bullt one record drawings. Two (2) sots oath approved phasing dlnrrans. Five (D) Irrlytllfon hoods .,f oath tfpo spoclf lod and Instal led on this project. 10.22 AS -BUILT AND RECORD DRAWINGS i • °°- As -but It and record drawings shot I be preperoa In nccordanco with Sectfa.t 2, ,! ., , �'£•� Control of the Work. Q Dimension from two (2) permanent points of referunco (oul ldings, rnmumonts, side- walks, curbs, pavemont) of tha location of the fol lowlr,g Items. (I) Point of connection to existing water lines. (2) Point of connection to existing electrical power. (3) Gate valves. + .. i` (4) Routing of Irrigation o.,ossuro lines :dir..onsloils, maximum 1001 along route), �' ! i). © (S) Remote control valves. (6) Routing of control valves. ! <) Quick coupling valves. I ^ (b) O'thor rolaf.d epulpmant as roQuostud by tl,o Engineer. „'Iti r+ Locations shown on as-bulIt drawings shall be kept de;• to day as the prodxt 1; tJ being instal led. ` t i 18.23 PNAS I Nr,, MAGRANS As-hulIt drawings she l be approved by the Engineer before phasing alegrams are I 1 „ prepared. Contractor she I I prov Ido two (2) phasing diagrams for each :'ontrol Ier suppl led. �_.. Tile phasing diagrams snail show the area controlled by each controller and shell t be the maxlmuuri alto which The control Ier door -11 I i at low. The phasing dbgre°ns shot I boo photographic print with a different color Indicating the aroa of ; •,> t coverage for each station. ihen completed and approved, the phasing diagrams 1 ^�• ' I' shell be hermetically sealed bat —an two (1) piec9s of transparent plastic, each I + >j being a minlmum of twenty (20) mlIs thick. �' r< `° rl1,• I •+ , ' !�.1� Ott• � JJ I iL1,�i' ,° ° a�'rrir `��Si J 4'r �1' '. I ; 1. ., �� ' �� + $� /�� ,!• � � . rjG�s,�i� S1, � • / 11� ,�! ill `�� i .ii�1 �•. , ii, 'CJ ,r •'fir i'.. J'• i � I I i yNa 1 •r • 111+'u r ' � t , 4 ' k I SECTION 10` RRIGAriON SYSTD4 f �•t' f�41' . ,, ;3 18.24 'PERATION ANO MAINTENANCE WNUALS Propare and deliver four (4) Individually bound noples of the Operation ®r! i 0 1 , u+ ��.r lll'l 17 R.1 S5 i� t y � � � I �r�13 = ,1 • I Maintenance Manua I to the Engineer at I east ten (10) ca londar days P, or o I , acceptance of the work. The Manual shall Include descriptive material of equip- Pont Instal led and shal I be fn sufficient detall for City maintenance personnel to s. ';•' r? H+ understand, oporate and mtlntaln a I I equlpmont. Eacn comoIuto, hound manual shell �t'�:;• �" Incl ude tho fol lowingt�" ar1 ° (I1 Index shunt svistInq Contractor's adiraes and toIdphono nunbcr. Ilst of equip- 4� {♦� `Ih ment rlth nemns end nddrossos of local menufecturors' roprosentatIves. ! 'i'!''• (2) Cataloq and pens -moots on nil mmtorlaI snd nSulpmant Instollod. (5) Guaranton statoaont. i (4) Complete oporatlny and n,•Intonanco Inst:-uctlor.s. 18.23 GUARANTEE r � Ct,ntractor she l I guarantee a l I material and equl pmunt for ono (1) year from the ''� 1 >► ti, d.� ' ' �`'` deco of eccep.enca of the work. Should any trouble develop within the time ^' 'fix,', /,♦.t„,��..9' �' , spec if led due to Interior or faulty matey lM Is or wormansh 1p, the Centractcr sho f I be rusponsiblo for costs Incurrud due to repair and replacomont. rt'1^�"{,�y•C 49 i1y1 C' I ! .• f � 1,1,�. ^ a tj., ,��� - ,tlHir . ri c�,ir '"ttA'+1r'3 iy�J�O"'♦'; '•. . r ..V 4Y � :a ^ e��t-gip'•. t �;t►� �N��# ? � N�' -�- � �f2 r� r � 1.14..i ,d� 4f � .1hj*�•� �l�' '� iKf;dA� 1 . 0� +.��,.'se ! y ,� �A' s �A�r ♦� %r; � . i 7' 1,. A Y N vhll 'O,t! V. SECTION 19 PLANTING 17.01 GELERAL Contractor shall provide all lab3r, irotarlals and oquipment for the Installation of plant motor lei as shown an the drawings End as spr,,zl f I od he. -elm, Contractor shall coordinate planting with other site Improvoments. Unless other- wise specified. structural Improvor,;ionts shal I M conntructod prior- to planting a pevn t I on s . Its, Contractor shall be rosponsiblo for locating and staking existing sowers, water and utl I Itc I litas above or below grade that might be domagod as a result of planting operation. Contractor shal I assime sole rospon5lbf Iffy for any cost Invurrod duo to dweas an6 for roplaceirmont of aforementioned sltn Of I ItIr". All work on the IrrIgetion system, Including hydrostatic and coverage tests, oporationo I tells, and the tackf I I I I nq and compact lon of trrnchos s),a I I bu pfir for-- mcd prior to planting oocratons. S I p @z,g, , sabOttod I-o the Er.glnear Yor Inspection forty -night (-:8) hours prli,r to Incorporation In tho work. 19.02 PLANT MA7ER I AL !LA_L I TY Plant matnrlal Oal I be In accordance with the State Dopartmort of Agrl-culturelm regulations for nt -sory Inspoctions, rulai. and Irading. All plants shell ba of No. I Grade and have a normal habit of prowili, and she I I be 9)und, heal thy, 0 vigorous and free of Insiect, Infastarlons, plant d1sapses, sun scalds, fresh bark abrasions oi, other objactlonablo d1stIguromonts. Al I planrs shal I have a normal, -to I I -dove loped branch system and vigorous sad f lbrous root sysit" which am not pot bound and are free of kinked or gird I Ing roots. Nursury grown stock sha I I be so I acted from high qui I ItyO we I I -shapad stock, grown under c I Imat Ic cand It tons o Im I lee to those In the pt-oj act I oca I a. ?I In Inum accop- tab I a sl za of p lants spocl f lad she I I correspond with that norms I I y expected for the species and war loty of conmercl a I I y oval I Of a nursery stock. Ca I I per sha I I be tho diameter of the Truiik one (1) foot above the ground surface and shal I twi the determining measuremont for troo3 when sptoctfled. Oversl,a plants may be used It not root bound, but shall not Increase the Contract p.- le -. Up to ton (10) percent of unders I zo plants In any one ( I ) vor I at y and grade may bo used; proy Idod they are larger +han the avoragA sl zo of the next smal lost grade. 5cfoniff Ic and common nmnos conform to customary nursery usage. 1' Types, sl zes and quantities of plant materiels she I I be as spoc I f I ad on the V dravingt. The plant I Ist shown on the drawl�nnjs sha I I be used as a guide only] Contractor she I I verify quantities by p Ian ch 1 0 '4 - ZY 'rho Engineer reserves the r. -ht to raluso or reject any unsuitable plant material. at Unsuitable plants shal I be removed from the project site and replaced at the i Contractor's expense. New plants shal I be tho samo species, variety, 8.11zo and condlt1nn as specified. Pruning of plant materiels shal I not- be done prior to del Ivory. After piantlng, as directed by the EngInaor, pruning sha I I bo I ImItod to the min Inum necessary to V„ remove Injured trigs and branches, deadrood, and suckors. 1. 1 Plant matorta I specl f led Is su5joct to substitution based upon ava.' I obt I Ity. Substituted materla I s she I I be approved In advenco by the Englroor and sha I I conform to the re4ulroments of those original ly s�-iclf led and be suppllwJ by the Contractor. i' 1AL 6. 30 0 J. 7': OT A q Ise l Imo' f IMI 41 YI 4"o HI V SECTION 19 PLAMI I NG Stitad she I I be fresh c I eent, pur.) new crop seed, ms4han Ica I I V pro-M Imcd to propor- tIons specified on the drawings and delivered In opiginal, unopener, containers -rcont a and cortIficat" bearing the dealer's guaranteed analysis, garn.1nation p: &3 1" of release by t?,o County egrlcultural conimIssinnsr. Whon roquastoo, Contractor j, she I I rurnish the Eng Ineor wl ih such Cortl f Ica -to of Compliance. Sad she I I be grown from high qual Ity propagative rrateriall free from woods, diseases, and Instactal and Dal I be In accordance with the stilindards of the State of Ca I I f orn#A Rogu I at lonf. for Nursery Inspection, Sod she I I be machine cut at a uniform thilaftnois of t lve--solghih% O/V Inch (oxcl ud I ng top growth and thatch). Individual places shot) be cut to the supplier's standard width and length with an at lowab to dov lat Ion of Owe (2) percent. Broken rolls Or LISV*n ends VI i I not ble a ccep,ablo. Sod shat I I be harvosted, de I Ivitrod, and installed within a tuonty-four (24) hour porlod. 19,03 FE14TIL IZERS Fort I I lziors she I I camp IV with a;p I Icab I a requirements of the State AcIrIcul turn I X= Code and -sha I I be packages, first grade, comercla I quality products Identified as to source, type of matsrtal, weight and manufacturer's one I yi, It. ttitlarantaod Fortl I Iters she I I not contain toxic Ingredients n qu n as harmful to human, animal, or plant life. Whorl requested. Contractor shall furnish the Snylnear with a Oirtlf Icato of Cmpl lance stating that the miltortal substantially meets thn spociticaflons. bmI h C mlarclal fertilizer Izer shal I �* pool Jotod or granular product having thu chemical analysis spocIf led horoln ang shal I be frue-f loving matarlal dol Ivered In crIgInal unoponod containers. Use of material which tocomus caked or letherwise demsq*d ahal 1 1104 be C:vtrnitt@dL Iron soil fato she) I Po forrous sul little corts In Ing not loss t1l V.54 Iran oxprns- sod as more I I Ic I rcill 19,04 AMENDPENTS Nf trogon stabi I Izod ergenic amendment sha I I be a ground or processed wood product derived frcolln wood of redwood, fir or coder, troatud with a non-toxIa L4gent to le'!iosrob va-rar tlulcklyl partlela slia allowing a minimum of 95S to pals a nner- J. quarter- 11/4) Inch sieve. 00$ to pass a ono-olghth- (1/8) Inch stove. 0 to 301 to pass a one- t!. i rty -second- (1/32) Inch (or 035) sieve. Nitrogen content, based on dry wel9tt, she I I be WIS for redwood ant 0.7% for fir and cedar. Iron content, based an dry weight, she I I bpi BAIL Amendment mater to I shis I I be a mInIntsm of 98% organ lc with a max Inum saturatl on nxtract COAdUlCt 1Y Ity (Sd I In Ity) of 2.5 ml I I lahms/contlmotor at 250C. Pins sawdust Is not accnptahle. 19.05 MTERIAL DELIVMY AND INSPECTION Plant matorla I she) I be delivered with leg lb le Identf ficatlon labels, handled and j, 10 stored adoquatoly to maintain a healthy condition, proto. tIng them from drying out, windburn or any other Injury. Contalnor plant ratorta I shot) nut be plcp.od up by stets or trunks. Inspection of plent materials required by City, County, State or Fedora I authorl- tlea she I I bo the ros pone I bl I I +y of the Contractor. Secure permits or certificates prior to delivery of plants tj project site. When recuestod, Contractor shell furnish Engineer with cop:os of such permits and ctrtIfIcates. 0 Plants shot) be Inspected and approved by Engineer, at the Contractor's source prior to delivery to the project site and until acceptance of I ho work, for size, variety, condition, latent detects and Injuries. Poll'! )� 1�i�,.-! �`,, : . t, .:: ': "M 'All 1 17 All - Isr A 4! f .�� + 1 ! 11. '.� ,�/'. ...• �.. ,>{ i',11'� r J 4 4 7 i 1'+, � LIM ;0 h. `I. J0�� ,Y r i " ,, _ i � / } it � i ,!! •r,J r "yvp� i sl ��,•. ,• 11 'i' �i1,�,1 rrrq fj`Yi ., r', +',1 ' �'� ._..... ,y,. • . :: �' ;"'. 'M.f"....r»,+ . 1: r.._.,., •.-w.r. r ....dw.rr.C►L+ ` � 1 A ; .. 1 ' ` ' t'1 1 I_' � 1 1, rli���kh• .� SECEION I PIANTIth; 19.06 SOIL PREPAM-11011 � t +1 Fort IIIting and can dIton Ing materials sl:aI I be mechanically sprosd at a unIfbrm rr rate. puantlties of materials !tLel I ba verlt led by del ivory tickets furnlsheed in the Eng!near, betoro spreading and after dellvary to thu silo. '`�• The following amendments shall he uniformly cuItIVatud Into the upper six (6) }T 1. Inches, per 100D squnro; toot, of loll h suitable equipment y oporettad at approxi- t'q' • mate right ang Ins In at least two (2) dlro tfonsr } CY Nltrogon stab: l tied organic, "ondmenr : r 0 LOS ermnonlun Sul fate, RasultGny snll she I bn cloan, in c frlablo condltfon and suitable for planting. f , 19,07 DACKFILL 9Ackfll I as fol lows shal I he machine -mixed and approved by the Englrlear prior to ` Incorporetlon In pier Aog plisr 6 partn by volume On -sits Soil ,�,r�r";� 4 parts by vol ono Nitrogon stabtl f:o.f orrantc enandmont 1' I pounds par Cy of mix Ammonium Sulfate r 2 pounds per Cv of mfx Iron surfate ` 19.00 FINISH GnADING �,� ,,� �" `"�� -► Al : finish grading shal I be completed according •o Section 10, Earthwork, prior to woad abatement operations and hydrocooding. The City, at Its own expense, may rsqulro a solls test at the completion of grading operations. Any addlttonal sot I anondmsnts, othyr than statad heereit„ shal I bo provided under the provisions for �r ' ,•, Extra Rork as specified In Section 9. 1r r (( t , r • r � �' 19,C9 MELD AOATEWNT OPERATIONS The ter lgatIon system, so I preparation operations, and IInIsh g; ad shal l bs aeprvvod by the E:nglnow prior to woad obetomcnt oporatlons. �I ', �'• Wntractor shei I opnrnto the irrlgntlen systcm to keep pr Wing areas-,iiformly molst for a period of two (2) weeks (14 calendar days). At the and of the too (2) week period, Contractor shaI I spray sl 1 vlslble woods with Roundup at the r•ato of five (5) quarts per acre or approved equal. Application methet shall bo as rocomended by manufacturer. After spraying, planting crass ahal I remain unwa- 1 {; t;�t`•," ` / torod for a silnlmum of tcrty-night (48) hours. 1 Afte. seven (7) calendar days from the ehawlcal appl lcatfon, woods and debris ' Svc t tVL' shal 1 be disposed of off sl'a. ,' �► ! t rti't1 Contractor she i 1 epp 1 y spray chomlca 1 s whin air currents are sti i I ( preventing • ', t '!_ drifting onto adjolning property and prevonting any toelc exposure to parsons whether or not they ar6 In or near tho project. After weed abatement operations, and as deternlnod by thu Engineer, planting areas shaII be roar Itled to a depth not to exceed one 11) Inch. Englneeir shaI I approve vend abateeanr oporatlons prior to stoloniting. �, ,�"t`:11 d io•, ;�; Ir. t �11'.'+ r ,�Yi_ i`�'11,�,y LICj�~ r�', �, ' i t,"It.t r' ..',, tl r ri( � • t ;��.�IL411,LfJr+r4 .'�« _ 1. '1 ,1 SECTION 19 rC y!`r, 1111 ;r} r i' 1�1 :. ,..,•, fr5'��, t =� 7 2 '� t� ����'�`+'� ,.,A f• - •w. .__�. •lam �1��rr-. • r\.�� � ; 15�:, '. .. .sir ' ,•1 "-& Ap jr 1'��� ,�', try 4„ t c_ • ( '., �}� •�• ` `i. . r..}i,r;.'`}� ,, CtJ 'l t'..,'. I'll I 't ,rf 1 1�1 _ ' + rr'• a .',t, r 1. ,l l 1"`,' ;i,t 1't '.;:.� I t}li e'`!; ;Si L7�\ ( fit , i Y � '`, Y, z ,' 1 ,.�, 1, tr t I ,• � .; ; i,, �!• 1 . �u ,`'r t eliti � t1 , t';�.f .1 f {',' Ilfi� �f • IrCTIGN 17 OLMIT11, > 19.10 II/STAI(Al loll III not trans accc,:,dfn(, to the dotal I , .-, shewn un tho drawlntls and n snncffled horoln, as stxcr as situ I r. avn l 1 ab: o nnc} wantt•,•r cond i tlon.; ar41 su l t.0l o. I r.shr l I tr i,os txiforo In/lns Are pl antcd. Stal..� plant IncstIons end to+; vej approval Irrnl the E1-g117uar hnforo oxcovnIIng plts, rnkirU nu=essnry adjusttionts as raquustnd l,y tho Cngfnebr. F,•-Zvvntod pit. shni I have vortl:nl and roughpnd sides a nlnfmun of fall , tho dtc,,\utor of th,, root t3l I to pormlt handl Ing wIlhout Injury ur breakcjo of t1,o rl•1's cr root t-, i. (1) PIts ,ho I I bo Iwl •:o tho dlenoror and anc. and nnc-ha I f t Inos dopt of thn rr-jtball. (2) Troes shill balslantud on mounds derived Irrn the import soll. (3) Pits shill to sduura far box-d materials! clrrular fcr contalnsr rntorlal. (4) Dust rod„ of Offs with gypsum tefora beckflIIInn. (S) Bottom 0% (6) Incho. of backll I I bhaI I to watorod and compazfej botfor.) true Is pi anted. Unsul table soli oncountnrnd In oxcayaticn shell be dlSp-3sod of off-slt9 and air• provtsd topsol I she I I t:o pr nv Idod. C,antalnurs shell bs opened and ro-movod In such a nennnr that tin plant rrot bnli +' ± .• :s not Injured. " Sot plants In cantor of pits, In vortical position so that crown of plant wlII bo 0;•^-. a level w!th flnlsh grade. Mator al I plarting areas thoroughly after Instal latlon of plant natnrlals. ( to I by 1 Additional bsckfl I shal : be added I I volds caussd water sattl"Vint. '{ t Inspectiot, of all planting shal I be made or the end of the construction period and �I Plant EstabIIshmont Period to ostabllsh the timo fo, the beglrnIng of thn Post- '�� Instal latlon flulr.tononco Par led. t Except 1n turf areas, plants shot I be set In a tmlporary watoring hi.In as nhown In the dotal I % or, the drawings. this tempo,-ary basin she I I to four (4) Inchos i r doop and the brt'un shall La at surrounding flnlsh qrado. o Ara:Is oroundplants shalt bo regraded to Indicated flnlsh grade. y 11). 11 TREE STAKING `t I Stake'iroas at time of pIant Ing ecr.ordIng to this dctslIS as shorn on the drawings. f Tree stakes shall be straight gralnod lodge polo pine, copper nepttlanata treated, froo from 4nots, apl Its or dlsflyurnnants. Provldo two (2) 3takos opr trap. St -rhos shal 1 1» f to (2) Inches In dlanatnr, ton (10) fat+t In length, conical ly polntt-1 at ono (1) ond, firmly Installed twalva (12) 'nchos boloo the plant hole. i Instal l Mith two 0) 1t1 x 3^ x 2111 clear heart, rough sawn rndwccd erase braces attached to poles with tout, t41 16d gal var,lznd nal 's per boori, bent over back of stake. Tfer shal l but twonty-four (241 Inchon In Innrdth, rubber tiro type, 1Gro- l� Straight^, or approved equal, instal lud In a Ir,so flgur-o olgh4, nttrchud to eressba.rd with arlo Mild, galydnizad roofing ne11 nor tIt ond. 19.12 WOROSEEDED TUAF t• i Tlo fo I lowing materials sha I I be of ouch a aharn:tor thn t when d Ispors•1C In a uniform slurry shaII form an absorbent p;)rous mat: 3000 gallons par a:ra Fresh water J� na�*r r • ; ..1 1200 pounds par ac-o Mood collulose flbnr 60 pounds per acre Organic Stabl llzar 200 Anmonlun cjlclum "�I pounds per scra sul!ato cr nitrate kh ,. 1 200 pounds for aura Urea forma!oohydo 100 nounds per n:ra :all sulfur ti t r� .'+) , 1 •R I ;fey 1."• .. t 1 i• L f s, fr.• .s,--, � 1 . It. N:: r I I �/�y� • �. i, 1+,' ''� f. .Y �.11� I'•'�, •a r,. ' .1y 1 u' S All h r I i + t + r' r. .�...,.., �. <w. ns -:..rr,unt!•>F1 XkiVAa ids , ,� +' Iasi •�; ' ,N Sood mlxturn .hull ba as Ind►cated in the Plant List on the drawings. Watar shall bn froth, fr&3 of Icrpurltlns, oxizp",s calor'ne and salts. t_'.f ' Flter Shall be clown, vood-I'von nulch of rood cnl luloso produc9,1 froo solected 7 harriwoods containing no gornlnatlen f>r growth-Inh iblting factr,rs, nenvtecturod Rs Hydro-Huluh Fiber by Cctrtwod U'Xp., 14IMGnpolIs, ►llimosotrs, or approved uqual. Fiber that I cemta fn a har m l ass, torn iarary graon dye, ; ` �• Organic stahll Iror shai I tXi Ecology Controls ff-i)Indor, Torra-Tack I II, cr noprovud equal. w l )r Mixing shall tie performed In a tank, with a built -In continuous agitation and r:'j,, recirculation syst►ro, of sufficlant operatlnq eapmclty to produce a homogannus ; slurry end a discharya syst•xi which wflI apply t`u Slurry to thn designated nroas i R at a continuous end u,rd form rate. { t- The s I urry p,-Pparat Ion she I I teki p I ace at tiro project sl to and sha i I bayin by nddfng water to the tanh bhun the onglne IS rt halt throttle. Hhon the water ?a Invo( has ranched tho height of the ellltator shaft, goo) roclreulotlon shall be ostniblishod, and at this tire& the seod shal l be added. Ferif IizafIon sh3l I thou ; ba cddtd tot l owr,d by t ho wood cot luloso fiber, when tho tank Is at least ono-th lyd (1:3) filled wsth wit',-. The angina throttlo shall be opened to ful I speed when ^► h tho tank In ono -half el/z) filled pith water. Spraying sin) I ccmianea or.". dlaloly u!;e,r, the tank Is ful I. .� I r1 SE(.TIN 19 P LA HT I HG C&!fractrr :h•II tprny dnslgnatod ur35s wl h the slurry In a bweaping ration, In an archad straro, so -is to fall IIP-rs rain a, lowing the Ilbor to build on itseslf unt) l n unfforn, coat I; a•.hfov.id and the matorfol Is soroad at the roqul;cd rate per acr• . A slurry rtlrrtoro which has not boon appl (od within four (4) houry after mixing shnl I ba roji�-tod rid roplact•d of Oho Contractor's exp-mio. Crsts incr?r'rod fni• relialr cr raplacc,iont of bare, sparse or dtrnog(A nroas chnI I bo tho rnsRonslbl I1ty rt Viti Conirnctcr. 19. 13 !_)r)D J TI1pr Aft.;' Wood abnt•-innt opurativns, Conti-n•:for shall rake, culTlvato, flooto, and roll untlI aronc to receive turf nrn in a sr••-:llh and uniform conditlon. Prlrr to Oddlncl, ;all shall Ln -oi;t to a mlr'rn., f,ptl' of ono ( I ) Inch. Sad -.hn i I i j I s Id and tn,lpacf vl th hutt Joints in a staggorod "running bond" potlarrr. Fftf�c• Inst,�ilet lcn, sod ^•Nair t:v rof Ind with a 206-pound rator-flllea layn rol(or. }sty Incurred fcr rops,r nr rnplacunot.t of boro, sprrst, ur dmaged nroas shot I to I%t r•- ons)b(I ity of tar Wr:sractor. I f S 19.14 (Mf NTEE Contractor steal I ova-antca r,fnr trooe throurrh urn (11 ful I year .ifter tho dote of ar.c*ptan.n (if t ht; nark. Foplacomont plant r-.ftnrla) r.hr:l 1 ho o' the snga verlety, size and candl- I t f or, as Shown on the drly (ng, and as s:)oci f f nd hn;-o in, and rtho i I be; nuurantend to. - ono (I) fuI I year fro,i tho datn of plant inr), n C_i ;.j1•r 177b. rf: 54 % , t �� i t^t n .` r � • i t +r-6 i Ar�rt . s•r ,n r� f�, S�• a�• ;. t •t J. M 1. 'f 4 � _ i ,~7` ►� +tr e r „-i} V.1 r,llrJi'Ii (�J Q. } � .�/�, ti�'• +��''i, , yr ;�C tl. 1� .I11 •'�•'. ."` LJ�rrrr�.fy�d•`iy�ll*il" '�Y i ' ?-� 1 `r . � ter t t •.� Lily, "f 4 • �� tip 1"S J .r xk -i �r �•� •�� �'" � t t i:'• ( r, a, •mil♦ (•' r 'Y t 1 1� r T L L 'L[czlvt...' tAYV..M..VL1:11YY1ffwWi• '' �+ SECTION 20 PIA'n ESrABLIsit4vir Puitoo f �. � • 20.01 GE1154AL r '• c 4 Contractor she I I t�' t p,•ov Ida o I I I aDor. malaria I s end aqu 1prr, mt to perform cork during 7{>' the f lant EstabllaMunt Period, sa speclfled herein, Including but not I lf.lted to; "'ti41' adequate watering of plant material, rtplaeing unsoltnb;e plant material and i' ,� ,� control I Ing veed=, rodents and other posts. SS } rr �' �• The Plant Establishment Period %ha l I consist of thirty (301 calendar days prior to the Post -Instal latf►vi Period. Fol loving Inspection of planting operations, including hydrosesd';ng, the Engineer shnl 1 notify the Contractor In writing to ts:Jri ' establish the effoctive beginning date of the Plant Establishment Period. r C . ap�'a • r{ r , +Y 'F Ja . r w 4 4W 4 + t 11 Tim* required for plant establlshmont shal l be considered as Included In tho total +Ime I lmlt specified in the Contract. Plant Estabilshment Period nay be oxionded by it,e Engineer it the planting areas are Improperly mairtafnod, appreciable replaeuraerit Is required or other corrective work becomes necessary. The park dill not be available for public use during thv Plant Establishment Period. Contractor shall conduct oporatInns so as to cause no Oangor or Inconve- nience to thn p'oh I la Ccr.tractor theII be re!.ponsiblo for valntalning adequmto protection of the park. Costs Ircurrad due to danbgo or ropIa,coont sheII be tho responslbIIty of ,ha rwintrector. Contractor she iI app;y spray chemicals when air eurrente nre 3t1Ii) preventing drifting onto adjoining property and proventing any tcr.., exposure to porsots rhother of not they ere In, cr near, the project. 20.02 RECUT 1011 All ernes of the park, Including, but not llml'ed to turf, concrete walks and slabs and sand, shell be kept clean and free of roods. litter tnd dobriw. Contractor shall operate the Irrigation systun autcmatfcaily and small prop(.-ly and completely maintain all ►,nrts of tho Irrlont!orr, system. Contractor .hall dol Ivor water In sufflcl;nt quantities and adjust water appllcetlon to compensolo for soasonni conditlorf. Before woods extend two (2) Inches In hel0itt, toot nhali be removed and dlapuced of oft-slto. Serious rood posts (I.,, bla:kborr , nut sedge, barmuda grass or bind read) shal I be sprayed with Reu^dup, as mi,nufactured by Monsanto C^., or approved equal, at tho rate of five (5) quarts per acro and left in P,'v a for soven 0) calendar days. Appl ienticn shall be as rectmmanded by manisfaclurer. As determined by the Engineer, a second application of Roundup shall be made soven (_) calendar days attar the first applicatlon. With both applications, areas sprayed shall rcmaln unwatorad for a minimum of tarty -eight (481 hours. Dead woods shall be rrmovod oevon (7) calendar days attar second applicntlon and dlspesod of off-slte. If the Engineer notlflo)s the Contractor of faliurg to control woods as specified herein, the Contra:tor shall kill 31) woods within ton 110) calendar days of such notification. TTYs Post -Instal latlon Ilalntonarca Perlon wl 11 be a:ctendad for ovary day after the ton (10) calerf.;er days until such woods havo been klllei. 5talonlled turf areas shell be es?abllshod In a healthy vigorous growth and to a minimum of two (2) Inches In halgnt. Costs Incurred for repair or roplacomont of baro, sperso or damagoo areas shell ba the rosponsiblllty of the Contractor. S5 7 yip ��' rw., (• . i. N s. r ��tt�(( �'� � •fit � *`� � 7. � {f n � sr, ryas N irrrerrY�� 1 �r 'o �•r 1� 1 �1 11 ''w4,FiaV ` by YAw'�m .._ .. _...�+,.,.�r.w.wrrwwa•. /.'.rli. V�.r�-t+a�,r:,IJ4�::lrilklLruvt.wu�1� 1�47T'q, r-�r rRRv1' i „ SECTION 20 PLANT ESTA13LISi1MEiIT FMICO First moving of turf shall be performed when the grass If tvo end ono -half (2 1/2) Inches In height. in no case shall the turf be cut lower titan aria and one-he0f (I 1/2) Inches In height. Fertilizing shnil ba corplatud In accordance with the 501Is report Included herein. At the end of the Plnnt Es-tahllslwnent Period, ale areas shell be In u weal -free condltlon and turf neatly mawud. 20.03 INSPECTION Upon completion of the Plant Establ ishment Period, Contractor sha 1 i request an (nspeatlan of construction to establish the beginning date of the Post- :nstal laticn Maintenance Period, The request sha) i be mode to the Engineer e P!nlmtm of seven (1) cslander days prior to the data for inspectlorr. As �61 \ f r Y y� .i1 � f •:i l i r.. � , - 1 • 1-0 v �i141 } tr a. ..F� ��1�tJc 1� )Y r ., .. ,� i• ,. ', - �� { �va tl�,�� r �a ;'�� Wit. ''%� (��ei�R;j,+�w�� � I fi rrn� r, � _•` `• 1' r � � _ - _ `� r r 1 i �:2K\,fr Y� . j.q 1,1�1 1 • ��, �1Vi+1 W r, e T 1 ). 44i ti � M ' t 5 rr' , .%3. �"v I t -: e SECTION 21 POST-114STALLATION WJINTFUMICE PER100 t - r Contractor shot I provide al I Icbar, motor IaIs and equIptont to perform work during i k �ip+ ,'`;: t. +j►t! r,: the Post-Inst:+i latlon Maintenance Period, as spe.lfled heroin, fnctuding but nct ':""tit 4 I lofted to, adequate watering of plant matorfal, replacinq ur.sultable plant mate•- :. rla I and contra I I ing woods, rodents and other pests, The Post -instal latlon Maintenance Period shall consist of sixty (60) calendar dayo. Ful loving insp,r:tfon of the Plant Establ fell,nont Perlcd and project conatru- ctlon t' fM1 rv�a,l' notiformed In accordance Contrector in Prlt ngwtohe tablleh the effective b"glnninrho contract doctinonts, the g (date ofneer y thethe n Fust-Installatfoa Mafntenarca Period. Contractor shall mafntafn the project an a continuous basis until acceptance rt the work. Areas shall be so carol for as to present a nest and clean condltlen at a I I times. The park vtII not he avoflab Ia for public use during the Post- Instal latlon Maintenance Period. Contractor shall conduit operations so as to cause no danger or Incnnventonco to the nubl I« r .r, �+ ,,' � l k t 1 • I f1� y a c : 1 e , w s � ' cn r. r i;,Jl,,t(i :....�.,.:,.J.TY.; ?. a -a _..,..,.-...u,�..... .tip.,.... _.... ,..,.. _ o 1 (•y+� tip' r • 7 r ? 21,01 CEHERAI- Contractor shell be responsible for maintalr,ing adoquato protection of the perk„ Costs incurred due to damage or replacement shall Le the rotpenslblity of too Contractor. Notification shot I bo given to the City forty -night (40) hours prior to the Contractor performing "spe.lalty-typo ororatlon!r, [nclrbing but not limited toi fertlllza''lon, cho�mfcal wood abatement and turf aerlflcatlon, de! -thatching and funglct0o applications. "Imo required for post-Installntion maintenance shall be conslderod as Included in y the total time Ilmit specified In the Contract. Working days when the Contractor falls to adequately perform matntensrce opera- tions as speeffled herein or dotormined to be noccssory by the Englnoer wlII not be credited as Post-Install.ttlon Maintenance Period days. 1 Post-Installntion Maintenance Porlod may be extendod by the Engfnsor if the pro- ,tact Is improperly maintained, appreciable ruplacemunt Is roqufr©d, or otter corrocti,ro work bacamos necessary. %i Contractor shall apply spray chomlcaI& when air currants are stlII; preventing �. y 5r drlf'fng onto adjoining property and preventing any toxic exposuro to parsons whether or not they are In, or near, the project. 1 ?.I.f12 E)(ECUT101% Ai 1 araas of tha park, Including, but not I Imitwd to turf, concrete walks and J 5�,'; •�' �, - 'r s labs and sand, she l I be kept clean and free of woods, I ittar and debris. r,s •' '�'�,. +r ��#•� AthIa+le equipmont and park furniture shot I be maintained In a safe candltlon b1thuut damajed or broken parts and free of "graffltl" and debris. Costs Incurred tr4 aM, for rupair or replacement steal I be the r^osponslbl I ity of the Contractcs^. =tct T`• ri Subsurfaco drains and entch basin grates shall be kept cloar of loaves, Iittor and debris to ensure unimpeded passage of water. Ural n l Ines sha l 1 bo period Ica l l y flushed with clear water to avcld build-up of sfIt and debris. I ! Trash receptacles shal I be emptied as needed and at o minftntn of oru, ovary seven t't `+' N , (71 calendar d]ys. f f� ('11 YlIJr 1 ,►,/ 1 /'Y �;II 1 `ji lll��)r . rt�y�a' 'f."' V5`fi}A PCrJ '+fie it I 11 fr.,,�'•/�, /YI:'l ,. .. ' r - rt + Fri//• I �+' ,li'W . ;�Sr I �.l_ 1 I ., . , - ). , ` `lf �.'l•, f It 1, ►(%rt,�y, �' + �, / '�• / �,., yr i�a r>y+�"�! � �.t�/� �I VC Ilo 'r; 4 61 A 1 O.W V. f xk :A SECTION 21 POST-111STALLATIO'4 MAINTENANCE I'MiOD Before woods bxaned two (2) Inches In heighte they ithe I I be removed and dl sposel of olf-site. Serious wood posts (I.e. blackberry, nut sedge or bind wood) shall be sprayed with Roundup, as mcnufacturod by Monsanto Co., or approved equal, at the rate of five (5) quarts per acre and left In place for seven (7) cLiander days. Application shall be as recommended by manufacturer. As determined by the Engineer, a second application of Roundup shall be made seven (7) calendar days Wo, • after the first application. With both Oppi lCatlDn3, areas sprayed shell rema In unwat&rod for A mintmum of forty--olght (49) hours. Dead "sedr, shall be removed seven (7) calendar days after second application and disposed of off -site. It the Engineer nottflas the Contractor of failure to control woods as specified heroin, the Contractor the I I ki I I a I I weeds within ton 110) cm londar daVs of such Al", notlflcatton. The Post-Instol Patton MaInTonancoParlod will bkoxtonded for every dbV after the ton (10) calendar days until such i6eeds have been killed. At the end of the Post -I note I I at Ion Maintenance Par led, al; areas she I I ba In a wecd-free condition end turf neatly moved. 21.03 IRRIOATION SYSTEM 'A Contractor shell operate the Irr #gat I on system automatically and shall properly and completely maintain all parts of the Irrigation system. Contractor she I I del aver water In suf f Iclent quantli Ins and adJu3t water application to componsata for seasonal conditions. Irr Igatton system Is designed for waterl ng f No (5) days a votak, 10 pm. to 6 a.m., with even d1stributIbn. Costs Incurred duo to repair or replacement of equipment she I I be the r9sponsibl I fly of the Contractor. Rap I acemen t parts shell be Identical the a, 1t material specified horein and on the drawings. . ...... 21.04 TURF as Fort I I I z Ing sha I I tee comp I ated In accordance with the sot I a report Inc I uded herein. Should fortlilzlng occur during the months of September through February, calcium nitrate shal I be used at the rate of five (5) pounds per 1,000 square feet 11 3 In I fou of atmonfum sul fato. After Initial rr*u0ng. 11irt sh) I I be cut as often as necessary to maintain the turf "'D at a height of two (2) Inches. In no case sha I I the turf ba cut (ewer thou on* o' and nnoh41f (1 1/2) Iiichos In height. Contractor she I I trim around Irrigation heads to allow for un Impaded spray and at borders along walks, mowstrlps and curbs. Tur I areas she i I cons I st of a un I f orm rov rr and present a hoa I thy v Igorous growth. M Costs Incurred for repair or replacament or bare, sparse or damaged erase shallbe r the responsbllfty of the Contraclor. ar Contractor she I I rm)ovo al I grass cl Ippings frcm project site. 21.05 TREES and SHRUBS fly+'0 0 Fifteen (15) calendar days after the beginning of the Post -Instal lotion Maintenance Period, trees and shrubs planted AS part of the Contract she I I be fed 01, vfth a commercial fertilizer at rates rncommondod by 'hc manufacturer. 110 I art I I I zor she ! I be applied d I rnct I y at the crown and/or during the months of September through February. Trees p I anted as part of the Contract she I I be pruned or headed back, as requested by the Engineer, to a I ImInato d Iseasoo or damagold growth, reduce Copp I Ing cc wl damage, maintain growth within space I Imftatlon3, malatain natural appearance, 61 1 yq 7 to balance the crown with the root structure. Uy a'+ A01 ,�4 r,)r • y.. �'t K, I -f ME 7 1 K4A "J61:s.lr•.'.r`. rw,,...r.....♦, at...•♦►,..•�'.t._•••a nra:•r.•!•u►.''►•'1�Y✓i.IPGilY.7i:! lLi • SECT I C41 21 POST -INSTALLATION MAINTEPL WE; PM I00 Stoking of trees shell be chocked froquently for dareage, and to prevent chafing or girdling. 'asis Incurred due to da"rago or ropleeenent of sraking matorlaIi shall in the ri 'ionsIbIIIty of tho Contractor. Contractor t.halI provide a cluarance of not less than seven (7) fact In height over walks, tlahs and active play areas, and not less then fourteen (14) feet 1n height over, ruadvays. As approved by the Englnaor, al I +rounds over ono and one -heel t 11 1/2) Inch In dlwseter may be sealed with a tree soal. Dead or dying trees shell be Immedlately replaced with material of tho wens species end itze and Euerantsrd its described In these $pactflcatlons. 21.06 INSPECTION Upoee coopl etlon of the Post-Insta l l atlon Matntenence Pef•lod, Contractor sha l I request an Ins,oectlon for acceptance of the work performed In accordance with tno Ccntrect docueonts. The request shalI be made to the Engineer a minIntin of seven t7) calendar days prior to the data for inspection. •rM �'i t( P"1 �1• =�, �11 i✓ 59 x 1 '��� � � rt �Ij ! � 1 't � ', rr f.: t" r If �,�"� t} a•� �. ,1 r r %� ii,�r-T1 Y � 1� t l{I r�'�. 7Yr , r 7. :• tl .�'�1,. i��, Y ,1 itY :1�,• �� •ril � !� t w +r -•rj � a R�;�r `jk i't^, fi } �I � 1 �t! ��+� ..o ,i �� �11•j�l"fy�#lt�% p�� 1 /� � � p1f' !�r 11ir 1 �'-".t r �.,', r. ' -•� r� r ., .r ' r �t r lit itt.+,t� 7,0, 1 ��l,, �i�1� `'�Y lrl r, 1� i . , } � )1 •:/ j. • ,. /r�(r Yr' i r •r� y,,� � \ , ,h� , M�r'i+j. �1'��, 7. �,},"'.� �, }'•>r �t ., ,t.' ' 1 �, ')^ rl l'S}. �, +, t ,. 1 t'�1 ~�i.�1 1?r fi \�r ,�� +l��rt�?;�� { Too • A -0 Em q • SECTION 22 ELECTRICAL 22.01 GENERAL Cortractor she I I prov Ida a I I I abur, materfe Is, and equipment to furnish aP4 In. stal I all &IcL:trIcLI hookups and f lxtur*,A for or. operabi " a I ectrIca I system Lis lndl4;etad on the drawings and spocif led herein. Con,wactw she I I procure a I I porml ts and I Ice.vios, pay a I I charges and fees, and give of I ro-tices nocassary and Incident to th@4 duo and lawful prosecution of the work..~ Contractor shall make appi Icat ion for elboricai service from Southern California Edison and verity the location, positioning and construction methods for alocirl- cal equipment Installation prior to cfywonclng constructfor. Eqijlpmon-t and materials shall be now, complying with the roqulrem-ants of the governing code, serving utl I Ity, Institute of El ecirtca I and El o4trcnlQs Engineers, National Electrical Manufacturer's Association, and be approved and identified by the Underwriter's Laboratory, Inc. 14-itarfal s and workmanship she I I conform to the requIremants of this latest edition -)f the National Electrical Code; Haticnal Life Safety Codes California Admlnlstra- live Code, Title 8, Subchapter 5, Electrical Safety Orders; Rules for Oyarhoad El ectrIca I Line Construction, General Order Ho. 95 of the Pub! I.: Utl I Wee Cowlsslon; Standards of the American Society for Testing and Materials; Am#rIcan National Standards Instittitai and applicable local ordinances. Acopy of a I I applicable codas stal I be available at the projoci, -site. 22.02 INTENT OF DRAWINGS AND SPFCIFICATIOAS Thin drarIngs and spoalf(crWans are Intended to cover a complete Installation. The omLsIon of expressed reference to any Item of labor or matnrtal for thc, proper exe4utlan of the work Or. occardanco with prosont pravllce of the trade shal I not relleve the Contractor from providing such lahor and materials. Olegrams and symbols showing electrical connections are diagrastonatic. WIt"Ing d lograms do nat necessarily show the exact physical arran9cment of the equ Iprent. W rl If there rre onIssions cr conf I lets ual%een tho drawings and %ji;3cf f fcoittona or applicable codas, Contractor shm I I notify the Enginoor In writing prior to submit- tInq his bid. 27.03 SHOP DRAWNGS AND MATERIAL LIST Within fifteen (13) calinder days actor award of confrocr and at latest thirty (30) calendar days prior to InStdl lotion the Contractor shal I suomit four (4) copies of shop drawings and material list, Including bit not I!nitcA to pales, fixtures, rountir.g hardware, panels, "tar and fittings, to rho Engineer, One (11 copy will Coo retry ad to the Contractor. 2ZO4 SUBSTITUTION 2EQUIREMENTS ell Electrical equipment salecled has boon zpo,:Ilfod based on quality and performance required. Raquest2 for substitution$ shall be mrde In vrltir.g to the Engineer prior to bid submittal and shall be accomranled by catalog cuts, performance data or too spect- f led product, substl ruted product, and a cost say Ings amount. The Engineer reserves the right, at *ho Contractor's expenses to have the Contractor furnish a s&-nplo at the sper-Ifled product And substvtution product. IV Theso Items shal I be del Ivored to the Engineer's office, at a convenient time, rand eisch product a I ovctrlca I I y wired for demonstration. 60 '�' 771 j�qq 4; oli - tip, ;( -10 A J' I A who 4 J D j � s � - 3.F. t� L° �iAr"• V. A, } t.ri Tll •�I. S k � , 22.05 CONDUIT t�•` `rli11�r 1 J 9y 1� i.yv,�► i Y l ....-.—�.._......«.�.,....+...w.u:r.:'•.r'Ywr_r..:•JIrY1hd.9:L:Y.WW-�.iW i i'�., ".'fl. Conduit and conduit fittings shall be galvanized, conforming to standards of rigid %toil zondulr as specified by Undorwrlter's Laboratory Inc., and shell beer the U.L. label on each length. Interior of eondu(t shell to zinc or enamel. Exterior` of conduit shall be zinc coated. Rigid conduit shall he of the size as Indicated on the drawings and used when InstaI'ad In or under concrete or rnndways, In masonry wells, cr expnsed on bulldingt. i1) reducing fittings will be permitted. The ends of tno conduits df.al I be free of burrs and rough erigos. Maximum bond of any conduit shall be goo and the minimum redlul of a factory bend sha I I be twelve (12) Inches. A 1 1 threads sha I 1 be treated wIih approved Joint :ompound de fore f IttIngs are placed thereon. Ends of rigid stool conduit she II be properly coupled. Runririg threads, thread- less connectors or thrandloss a,vplings will not be purnItted. Rigid eoadult In contact with ootth shall be wrapped Myth Hunts Wrap Process 03, or approved equal. Underground conduit shall be PVC Schedule BO installed wIlh a three- (3) Inch red oxide concrete cap. Trench depth shal ' be a minfrsu.s of thfrty-slx (36) Inches. Install a code sized lrsalatdd conductor (green) ground wire It. conduit for contl- nulty of equipment ground. Where installed below slabs o- below grade, uondults shell be separated by a mfnlmon of throe (3) Inches between fdenticaI systems and twelve (12) Inches between power or tolophons systems. A11 elbows and rtsars shell be rfgfd gel van Ized stael or PVC SchoduIa 8C, tin If - Ioppnd, wrapped with Hunte Wrap Process J3, or approved equal. FlexibIa metal conduit shell be Ilquld-tlght with ML. Iabs l and may be used whore permiltied by code. Fittings shall be "Jake+ and "squooze" type. Sea Itlght flex- Ible conduit shell be usod for al I final connections where drawings indicate flexible conduit. 22.06 CONDUCTORS Copper wire shall conform to the applicabio portions of ASTN 0-3 and f1-& Wire slzos shall be based on American Mire Guago MM. Conductors she I I bo su I Id copper, minlmLm 112 AMG, un 1 ess specf f ica I I y rioted otherwise on drawings. Conductors f8 AWG and (ergo- shal l bo: stranded copper wire. Typo of wire shdl I be as fcl loss: Typo THIN, 600 volt Insulation she 11 be uned for wot or darp locations. Typo Tllflff, 600 volt Insulation shall be used for dry locations. Low voltega a:ntrollor conductors for the irrigation system shall be Type UF, sized in accordanvo with the controller equtVmnt manufacturer's recommendations and Y.hal I to LLI. approved for dtrecr tivrlal instal lotion as specified In the Irrigation S&-.tlon. Connector aid, Burndy Pentrox A., 110-OX-ID. Grade "All, or approved equal, she 1 1 ..o used for all tarmir.ations and connections. 22e07 PULL BOXES lull bozos, covers and extensions shell ba precast reinforced concrete or plastic. Plastic eatarfaI shall be lire resistant and shale not burn at a rate greater than three -tenths (0.3) inch par minute per ono -tenth (0.1) Inch of th!cknoss when tested 1n accordanca with ASTM 0-635. kator(aI& shall be dense and iree of voids or pzroslty. Extanslons shall be of the sarme naterlaI as the pull box. 61 ' , / s r ,4 .,.�� W. q 4, �,�^ r „� �,� • it .fry 'may ° r •f °;. p� l r, ., 0 i T , r ew*�r ....,.w,' «:`= Lrr: t>rJ71s:S.�...taiL*a6►114+lIiriMeli�aM'4t1e�NMi11,i:K",�� M1 �r rid Ir' , r- ( `r r ( AL 1' ELECTnICAL 22.09 JUNCTICN EOMS ANO OUTLETS 41 Junction bones and outlets used in concealed work, except masonry, shall be galve- nlzsd or sherardl zed one- 11) plea", pressed stool, knockout typo, sited In 0 accordance with the coda for the number of conductors or the number and alga of condolts entering the box, but shell not be less thrn four (4) Inches square and one ar,d one-half (I 1/2) inches deep. ° 1 Ester rings sha I I tie prov Ided for al I flush nounted boxes. Junction boxes and outlets used outtlde cf building, on roof, or in landscaped areas shaI i be east a I urninum as mrnufoctured by Courso-Hlnds, typo "FS11, or ap- proved nqual, with condult hubs as required. 22.09 PANELMETER Panel/rooter she I I be as spoulf lad In the dotal Is on the drawings. Provlde a type- written direclory mounted insldr, the door in a metal fra►no which that clearly Idwttffy each circuit as to use and location. Circuit numbers shel I be stamped Into dee,dfrnnt adjacent to each circul•r bresker. ProvIde engraved screw -on naeep- latas on parel tr!xt indicating panel oesfgration. Exterfor of enclosure sr,a:l be palntod with tdo (2) coats of rust resistant dark groan onamo) Palrt. 22.10 FIXTURES ANO LAWS Lighting flxturo3 and lamps nhalI be as specified In thn details on the draw!ngs. 22.11 INSTALLATION Provide al l mounting facilities required for properly securing or hanging flxturos, equipment and r,utlets. Verify service locations and conform to the requirements of thn power and telep- hone co-epanlos and pay all service and uxcoss cable charges. Provlde all trenching, ducts and vaul t at needed. Provide junction or put I boxoe for put 1 Ing ccaductars, shore required due to oxcusslvo number of bands or on long runs, at ir.torvaI s of one -hundred (100) feat. Bury undurgrouna conduit to a depth of not less than thirty-six (36) Inches below finish. grade. Irrigation control wfring shall b Installed as specifled In Section 22, Irrigation. Provide expanslcn couplings whin conduft3 cross axpanslon joints or for contf- nucus runs In excess of one-hundrod (100) foot except when .x'beddod 1n concrete. For runs In excess of ono -hundred (100), Instal l long radius bends Irino (9) 'rWas the dlareotor of conduit) in urrd►irground service conduits. Cut and patch concrete as required for proper Instal lotion of eloctr ical work. Al I patching shal I rratch the surrounding work. Ground all equipment and services In accordanco with applfcnblo codes and as Inrlicsted on the drawings. Conductors shell be continuous between eutlots or Junction boxes and no splices shall ba nada oxeopt in nutle' boxes, pull boxes. panolb06.-d gutters or handholos, Al I joints, splices and laps 110 and smo I for (Inc 1 ud Ing f Ivturo p lgtof Is) sha I 1 be connoted with "Idea I" wing nuts or Sc,3+ch-Lok Connector `7-oa1Ing Pocks /0, or approved equal. No. 0 and larger shell be ctynnocted with soldorless connector or 1009 electrolytic copper. 011 or grease sha I l not be use9 whop 'tu t l i ng ccndrx:tcrs. Use on l y approved cab l e lubricants. 62 °} • `� �'•�* � °who, -I •� i� � • -•. 1 yr ''j >. r• - - ' :��. ��) . rc°P•yY� 7 SECTION 22 ELFCTA I CAL 1ra!n conductors neatly In panels, cabinets, and oCulpment. Rotlghten prassure type lugs on panels and equipment after load het► Dean appl W. All branch clr- cults shell be left tagged In the penelboards, In al gutters and of Junction boxes where used circuits terminate for tho purpose of Identif,ing the various circuits. F'eedors and mains shall be with adhesive typo mrrker, Brady, or ap- provbd aqua I. Ihste I I a ye I i ow pol yv Intl rope pul I wire, 200 pound lost, In a I I of4pty conduits. Tag each end showing origin and tomInatlon. 12.12 GUARANTEE Contractor shell guarantee a I I materlaIs end equipment for one 11) year from the date of eccmpt•ance of I he work. Should any trouble dova l op within the time %pacified due to Inferior or faulty materials or workmanship, the Contractor shell be responsible for costs Incurred duo to repair or replacement. 22.15 INSPECTION AND TESTS rerforml al tests as requosted by the Engineer. Adjustable lighting fIxturns shall ba aimed after dark In the preFunce tit, and at a time convoniont to, the Engineer. 22.14 BA:.;FILLINR Backtfliing shall be In accordance with Sectlun 10, Earthwork. 0 63 r y 1+ / �� AT•.f a+Hti� �aj7�h,:� J �+ A 'A ,ref - ,,;. � •M, `, Y-!I. •�`y' �"Tl.. �qr ,mo�tt AY�• , i ,� ' ,� 1�1i,V 4 :59 V-4-TI. 4' b4l, 4 ? p V REQUEST FOR (30ITY COUNCIL ACTION Dato February 4, 1991 Submivod tu; Honoranle Mayor and City Council 7 Submitted by: Michael T. Uheruaga, City Administrat APPR r1V By 031T %; Prepared by; Yr:COUNCIL It06 Ron Hagan, Director of Community Service Louis F. Sandoval, Director of Public Works P Subject: : t '° .1 J. C Central Park 11nndicap Play Area; CC-803 CITY, -, k Consistent with Council PoIICV? Yes Now Policy or Exception VStatement of Issue, Recommendatron. AnalVils, Funding Source, Alternative Actions, Attachmenti- F ISSU 6� STAT MMT-2 Plans and specifications for the construction of a Handicap Play Area In Central Park are complete. HEr—Offiff-MAIM: 1. Approve the plans and specifications and authorize the Director of Public Works to solicit construction bids, 2. Approve the attached contract subject to award of contract to Council approved ,J lewest responsible bidder. nkl 0,1; A N A A 515: - f t�q,. The landscape architectual firm of Cardoza-DIIallo-Flarrington has completed the the plans and specifications for a handicap play area In Central Park (see Location Mnp). This �Y play area, directly adjacent to Huntington Lake, will include the constriction of a fishing dock, plenin area, a sand play area, on -site park bar-b-clues and renovated landscaping. The City was awarded a $100,000 grant from the State for this project which Is designed to be handicap accessible. L Staff of the Development Services Department have determined that the environmental Impact of this project is Categorically Exempt (see attached); therefore, the City can proceed to construct Improvements as shown on the plans. Furthermore, the paisage of Measure "C" is not applicable to this project because the stnictures are Isolated and not part of an "Integrated" facility (see attached memo from City Attorney). 7 Therefore, -tor of Public Works requests approval of these construction hei Tore, the Director Ut.;U IC11ta 9111 L C; But or Lelk U" U OV L, 1. construct UV_L U"i J. N_Q SOB E: dscape architect's estimated for the constructlor of these Improvements Is 10.00. Funds of $165,000.00 have been budgeted for this project In fiscal account " S-601-6-39-00 of the $165,000 budgeted, $100,000 is from a State grant. A 11 - lit •( Yam„ k"1 .1j I � _ Y 1a , .1 a •.r�'i K114'M t .� 44 1� �`� �I Ile• vA �`I, .,. - i�/..Y � 111.q � u,:�'(9 (��� � ..�...Mwws.sux..n aw0i��%d�w;l•'�.'r/r+�i f� ( F S7nn / • •., 1 ..1 f Cenral Park Handicap flay Area; CC-803 is 'V February 4,1991 y Page 2 ARd.li�NATIL �bil?isaiscil• ( A u �� { •''.,� •' Deny approval of plans and speelfica tions and forego the acceptance of this grant and the construction of this project.ATTACHMENT r t� 1, Sample City Funded Construction Contract •(' r i� ` • 21 Protect Location Map 11 31 Categorical Exemption 4/ Measure "C" Opinion from City Attorney r � ' ^����;I• MTU:LFS:DRN:dw r1r J,SgM�I• t:' r iW��r � r ,• 2757g14 • j},,� IJ aid ' � ! 1.'+1,.,. 1 i�t,,t. � t � t^.'- 0 k,lll, 7; •t ' a ol t 'G +•• r t�Yr �• u' '+�.) � - .c',,...�..�1t —,. ..•e-.c•x,...1.w..-.��..�-�c.r..rZ-.,Ttrnrt:�•".'r�.+..•.ra.<...•..... ti.....�....�.... — .....i'+av,'�q,�+� c 1J y, 5 , 1, 1 I � , , 4{ 1 ,{ it f • 1 2 + J a ,', "r�, 1 '.. I r, w .,.»r.�a.........., h.,•...+•.t1.rs..CYr.'!•.•.ri_.,-�r`!'s��Y1 7'.,y�Mf ly 5AMPE CITY FUNDED CONSTRUCTION CONTRACT' 13 3TWEE1111 �., THE CITY OF HUNTINGTON 13EACFI I a AND FOR LA:;JSCAPE CONSTRUCMON ~ 4 01'7 THE Ii11NDTCAP PLAY -Rr IN CEUTRAL PARK L iFiIS AGREEMENT is made, and entered into on this day r of , 1990, by and between the CITY OF HUNTINGTON REACH, a ' f' " ?�' •y �+r'/;y'' municipal corporation of the State of California, hereinafter referred ta as "CITY, " any °'^,� "CONTRACTOR." ;,,y /F a • -..._ _ , hereinafter referred to as , _ WHEREAS, CITY has solicited hills for a public works project, it's: '.; �}• . � ';: � hereinafter referred to 3n "PROJECT," more fully described as the nk 2.•.. ' c •r' , 1 1, 41+r! • landscape construction on the handlicap play area in Central Park in the City of Huntington Beach; and �,' : • ,,fir, .;';' nrCONTRACTOR has been selected and is to perform said work, 2 r,,,, x."�,� �, �':'r NOW, THEREiORE, in consideration of the promises and agreements +� hereinafter made and exchanged, the parties covenant, rnd agree as fo11oF%J JrY t 1. _ TTEMENT Or WORK: ACCEPTANCE F' RISE CONTRACTOR shall furnish, at its own expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other J i items, services and facilities necessary to complete ana construct ` 1 � f 4; :' the PROJECT in a good and workmanlike: manner CONTRACTOR agrees co assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or ' prior to acceptance, from the action of the elements, from any ``,'' °Its'+•, L'11forG�Sde11 difficult? eS which may arise or be encountered in the h; • `s' �Y L ty ° �a�i � ;`, prosecution of wcrk, and for all other risks of any descviption connected with the work, including, but not limited to, all expenses ""� ,�• ? incui,red by or in consequence of the suspension or discontinuance of I �4 'tY��1`�ltrl,. ' + J 1115 \ • ; , , r ,-\ 1. , 'Ills � a r ! r • t f �• ' ' ,27 b ,� JVI 'l:' '• 1.1P�,�� 1'C If Y � ' `. i�;.! '; : `. ...t.,,' / 1 .. .: 1• 2 i f r ?.1. \�f •+ i 1 • b�y'4L�5+�I�r.1�' •• !t 1 .. ',,. , . !!, a rf,i-�J�''!. 2d1 ' �• ,Vi� t �., t �Y , .rA a .Y ti ill„1 of J •i) , +.�';''(ri`v 1 �\,'! '' ,, `t: IAi , '1•.rf N��f.'•.%� (, y 1 ,' ,, y 1 0.I`. r ;,t a t , ,, J s 111 k"It, , ,• � work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and ir the manner shown and described in this Agreement, and in accordance with tha requirements of CITY under them for the compensation set forth in the accepted bid proposal. However, the total compensation to be paid is to be computed on the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s.) 3, A CFRTANCE OF QQjM11TI0W Or WORK: PLAN$ ANd SPECIFiC&Tj, , CONTRACTOR` acknowledges that it is fully familiar with all the terms, ccaditions and obligations of this Agreement and the Contract Documents (as hereinafter defined), the location of thn job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such matters and is relying in no way upon any opinions or reprasentations of CITY, It is agreed that tha Contract Documents are incorporated into this Agreement by this referencK, with the same force an7 effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by said Contract Documents insof.er as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Cont-rar": Documents" as defined herein mean and include; A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY'S standard Plans and Specifications and special contractual previsions, including those on file in the office cf the Director of Public Works of C"rTY and adopted by the City Council of CITY, and any revisions, amendments or addenda _2- �I C 1 '{ J'•tit r�! ''•,. :4s 1/1 , 1 t'! If}r1Y r,. ' - �/ ' , �' i#�•t/ll�" J l ' , �•`, �i�>�1r1' . . h.,ti �, ,,lY rt r`tT' rsf r ;t, f 1 1 �N i +� I•. �'y j �144 lei , 4 /' r �1� 1 .1 ;� tt��ld �+�'. �,{ II`rC� / 1t� �i�/•�.'t ;� , r r .� i� AAr 1.'•�� 11�''TI r h IRL 1 �'. •�l +YhJ � . /"��,� ;I;Z'� .ill' � 'cS R } i, ° �L, rr1���♦, J,��ri -r yq1[�� 74 ��I�;�1'•�fh 1. rl �'"i'i, (f)h a��lr Js � � rl1 .� r r' _ 1}.+ :, )fir•» ��, thereto; Dr The 1988 edition of Stpnd rid Specifications for Public NQIh Const=C±, Qp, published by Builder's News, Inc., 3055 Overland Avenue, Los Angeles, California 90034, and all amendments thereto, written and promulgated by the southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Speciai instructions to Bidders and the Contractor's Proposal (attached hereto as Exhibit "A"); F. The particular plans, specifications, special - provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of discrepancy between any plans, specifications, special Provisions, or addenda, the matter shall be immediately slibmitted by CONTRACTOR to the Department of Public. Works of CITY (hereinafter referred to as "DPW,") without whose decision said discrepancy shall not be adjusted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in conflict herewith. CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made tinder the provisions of *his -3- J' 7 hN rtnt n�..�.•w.r're'I�'1"rrw!r�q^�+rr•+... '-1 r '7 '.:"^"'�'!'�'Y rR�f.[AN i�"��� 1 �, 1 1 1 , 1.' -f! / 1 d• r i ? 1 .. 1 �•• (• 1' '' li •i.� ( rY. 1� • �Zt� ',,1�"yf�r'� I,,yKk .1{ / 11 r' 1 I. t �' •1 a 1' j �'i;�lef�'a�+'w���t 4 r r 'r� I 1 r� � `a • ( r ) 7Tr( � !I a 1 } • � 7 lj�a T 1 � "� � T ,�I�r -,: / , � �� r! 11 J. •• •r , ' �.�r 1�' f �r �.(lr' lil , f 1 � J¢JF}t{ ,�111 r 1•,.1 ! ji 1� 1 r`•t ! .. � ` `' i � ,r�+ c+f fi� 4 rr ii , ., - rl ' J r •.rr 1 :I I I I �1?•!' v � d2 :1 '�'PI e � � •r 11 rl 1 , ,. r - I "`. '.r i ( r , 1 , ��( Al �lr �� � t 1/r:, �� �} ,f 1Jr t?•«j' F tJl, ?� ri �r -f' �} ' /�• � ` '- r r r�'l i' r�y��tl� .r rri'/t ,� j . ,h `�r� �' �a ✓tL./r, r�,..t .�,�Mt'a � •�QQ1, �1�'A , P �� � C tirJ,1's.S' }•'* I t ,i�/y(w[��,��' ks %,+,� :l {� r r ! .I lr'' 17 :✓" i; rf r rife s i ''.•S + i . r iy 3low F{:, r i f'r '�� 1 , r i ..11f " f ` y.'• 1 �d tr rt �ti , r'�` y , r���Y �ry MT "h l,w /!''s+ +' ' r fr ,; s• ..1 .} Agreement o�: the Contract Documents, a dum of DOLLARS ($__. ), as set forth in the Contract Documents, to be paid as provided for in Sections 1, 6, 13 and 14 herein. 4. 'l+IENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after notice to proceed is issued and shall diligently prosecute PROJECT to completion wtthi;z One -Hundred and Twenty (120) consecutive calendar days from the day the "Notice to Proceed" is issued by Department of Public Works, excluding delays provided for in Section it herein. The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every 2rovision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, detaile and samples, and do all other things necessary and incidontal to the prosecution of its work in conformance with the progress schedule set fortis in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors and CITY forces working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance with Section i hexein. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the Lime and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. -4 -- i .)f � 1 q t 1 y j i, ,1 _.!� / r y� , .. i 1 `.r ch Irl rrs y7As, S�, �,t/`1 -!� ( t rl � , 1 r ,ly L���k, f , r .r �r 1 liji I r� l✓r ti t y � � s i, r it i�,lirli?,fr �� 1�� .' �'isr y (r .•r��. t r 1 �i t� , y '� r}t', ,�{t, r :y► 1 r r r �rr'� 41 / rl s i , 1�T' � }.i1•,1% ••r'} .i♦, '}J�r•'i 91 ,:. �1,t 1 r `�• / rtl •tl ' r •r /, r • I I' !i / ,r ,r 'h'i! f 1•. +/ lr ,1 '�� �t r'1l-.t �'>`�r i ! 1�f��,'t; 1f J' :` (!!�'S l �I ,) �, .t •1, i1� ! y •',`+�• 1 •,1.' r?t�iylt ,;.0 ' ail tl�r/ ;? 11 t .. ����`ybbY,�'�� i► , �t,t� a �•; ',r t t ��/�,� .,� art x�51.•NI �C,„+ r;i ;' .f I ).. .. .. •~. .' ri;j l 1 ! �./rrl y"��.i 6, CiiANQF& CONTRACTOR shall adhere strictly to the plans and specifications set forth.in the Contract Documents unless a change therefrom is authorized in writing by the DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as the DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the written order of the DPW, and CITY shall not pay any extra charges matte by CONTRACTOR that have not been agreed upon in writing by the DPW. When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written rout proposal reflecting the effect of the change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated. b7 the parties upon cost and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly Issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingi:.. No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work site will be available on the date the Notice to Proceed is issued. In event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. CONTRACTOR shall, prior to entering upon the performance of this _5_ �5:7' 7!��.-^• ..1rw i•►nrrt���..'...^�"'f•��ww.. r.w.�.�wr...n.+. nav l�wl�vw �..�+ �'_'T� '��,,,.tlMNyrq . •jib � fJl Jl4 J IJ - a�tJi �k, 1 1 !'�' � }�. '' � �r ��I lr ��r r.'��'1 �r�l.{i �; 6�cr ♦1 ,,` rJ� 1 �,1 '1 i 1•i ,r•. �� � { ri_vf�j�} r 1j���1� 4`'1 �t1�JJ 1 r IJ •r 1 ',+ lei, ' x' �Jr( 1 fll'1�,�I'��C��{'fix 1 rK�(l ��r: r ��J �'. 1��'' 'l ��•', j Ar ( 1wiv ��r. r r}re �y r�i } III � � � ` 1 1 _. .�•, �r f � f !;� '� A y f ,� If t � r a. , j F •�� e } Y I�f" yr �� � �• Ij, J r•ry �bl 'y1 Agreement, furnish the following bonds approved by the City Attorney: One in the amount of one hundred percent of the contract price to guarantee the CONTRACTOR'S faithful performance of the work and to warrant such performance for a period of one (1) year after CITY'S acceptance thereof, and one in the amount of fifty percent (50%) of the contract price to guarantee payment of all claims for , labor and materials furnished. The CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S risk and expense. it is underRtood and agreed that the CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not as an employee of CITY. CONTRACTOR shall secure, at its expense, and be responsible for any and all payment of income tax# socia= security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees, and all business licenses, if any, in connE�1tion with thw PROJECT. It is agreed by the parkies hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth in -,_. _. .. _.r.-.,�.._....,�.. �......_._...�......r�.._-77 ' ,f t ♦ i 4 a i,, ' ,' • y tit. r ��T ', 1 �) 1 _ { i{! tA" 1 r, r.. ti 1 .• ii r +C. sf,�" "+w 1 ♦,. is . 1-,P .} ?� yyl ,, t ,,!', U �f ���yr r��l .,VC . �-e..•{r , � „ r}�,,t'• it I r h v• � 6 i � r al ,� i ��d,�j�� R� � 1. •,� � �M�h�f'I y r %Yy�,IY 1 �i It r,�Iy,' i .�Y ',np.� �� .�,i �(F 1.; �f� �i. ,�tS�y r' r �r� ✓/ "��7rty,1� • V n , 1 �. / �, r '!'i�w�N, P Yip f g rtt +al it '� �ti ,f r 1 ''•1I 'r T� (�i ��` r 1 Ikjj! ,�� i� � t���1h S�� (� % � �r1(�r�r y' ! Ir� r ! �, ril'Zt'• 1 rrl , err N h,�.N. iAai�' (,,., .i+'�1�• r 1. i i'; f !�l„;.;•� ..y. ,ry��,r ,rd 1 + Section 4 he*ein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of ($ ) per day for each and every working day's delay in completing the work in excess of the number of working/calendar days set forth in Section 4 heroin, which sum represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable losses CXTY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted en extension of time and will not be asseased damages for any portion of the delay in completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of final settlement of the Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of Fact thereon justify the delay; and the decision of the DPW shall be conclusive on the parties hereto. _7_ -� r .�,�• �T"•~t�-'..Z"rwwr� �%rgH�r�i'P�sa�'!'"'er"m"'^'�.•---- '�t tt vtJ4M•Srr� ' f + t '� r�,, ! 1 r , , 1 i,J,rr . ,t ,•�� , t��r• r ����i t( rid ,r J r , � ,, �. t , � �� ��.i 1 7 1 t �u 1 � dry, i,i Yl4.i�+� 11 il, �11 n• (al' 1f �, '� rY I.3 V 'i ry r ,li � iJ ��t-�i , rr,r jJ''r<.11�/ J ti+ r•, 1 i (1 1. (t 1 1 l . , rp }' rOft, I I r, ^1 rtR �. • r Sf/Y1 1,' r'�, r a _ '41r ,.: , ,`♦ l�•,-1�,r, �oYf��4i x1 �••y ' i�f �J1 , 1�� �, �,, .I � i,r ` 1 1 I 1 ' �'jr�J � f! ',7 'If!• �t •' r, A/,i,71 , ril ,i '.f 1 !., .r �+ 1.. `1 I '� 2 �r.r..• t 1 r 'i. 4 r , 1.41 t` ! till tp� • ,up. � q►,,r� �'.�/jl �i r � �' r, rt l t 1 �r t 1 r l' % ;. 14 (Iyli �, l,I r r1,. �•� ti / I` II ' 11yi• ( 1 , 1r;0r 9 _ !t Aj ��lt.:lrtr� � t { 7 'r T j� +�,�l; i i ���41�fMT�,Y��� • Ki:�r�.lr r r` 1� + ri• � � )1. ,�: +t����.^,t�hl�•+Mr�¢y� � kr Y I �,rrt'tri i? 1•%v )1 t.. I.. r t l ��� ,•, w�rr3 I �7¢ �yrFl *rl r )} ),i1� � ..,'r ' 1) .Iiv• "i''�4" � � �1 rY��if-"t��i '� 1 +' •�'! Iw'. � y �. kk 1)MA i 1, •:� ► i h r t i1 i r rein. i�! �ylnh � ry r ;'' } � : I .� � ti �, S , r p / ) ry ly} i . •,'� c y ��' ,i 1 r„� � 4 � �.,y,�� , �`'CWh • • �i'4 w i' r�l ,'j''.11 i F 1 � R�(. ~l!' i��rG���,w !�� ' '.'4s..�rT' �1�►�=>f 1,"',�nt It�Ei, s I ga r +CI sr sf -li; 5,+'• r • ' la 'O� n Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, noglect or default of CITY, or should CONTRACTOR be delayed waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is no* responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work .-hall be extended by the number of days the' CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of time for completion shall be the sole remedy of CONTRACTOR. 0 will �- /�� �►` (1) notice The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) Subsur::ace or latent physical conditions at tho job site differing materially from those indicated in this Agreement or the Contract Documents; or, (b) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. The DPW shall promptly investigate the conditions and if it finds that such ,A i )) r �� /�l '��. f � r �i.�1 1 � ��� •.�� _. ...- 1 , 't i rf ) f Yr +° a r � i,r err �tir lr �� ��� . ri,�, ' .t i ,I I�r /: t r1 t i •li I � 1 r I��y^� t VH=r/ Sr '( rr� 1%1�Ir, fl il�rr 11 r _ .-, ' 1� � ,, ! + `• t'%- 1 afGri`Q..r ;� .,�� Lfr ,.:��'rr 11f,! � Illy. , :1` Jf 1 '.'. _ t � .•� 1 r , 1,,, r) �.�: e��rr. •� S,1 Sir i:), At�r r•,r� �1_. 11�1 r {/• ) ,•� •rl. 'u ' c r r �� •tii .vtj �. ire}, r rfil�t, IN fit ,�i y 1 r' � ��� •1 �1 u J 1�);e�lvN l:.} t i ',i i I 1, .r r � I ;•1 i/ ly t S`�=•} r 1 r ' rff conditions do 'materially so differ and coupe an increase or decrease in the time required for performance of any part of the work under this Agreement, wh6 the.• or not changed as a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly; (2) Time Extgufiion No claim of the CONTRACTOR under this Section shall be allowed unless the CONTRACTOR has given the notice required hereunder, provided, however, -the time prescribed therefor may be extended by CITY. The quantities listed in the bid schedule will not govern final payment. Payment to the CONTRACTOR will be made only For the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bib schedule, the bid price shall prevail subject to the provisions of this Section. The DPW may, at its sole discretion, when. warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an gauitahle' adjustment in price or time for compl©tion shall be allowed if asserted after final payment: under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, the DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its Judgment the findings warrant. 52 �*"; r f •-Tj�;-•�••••,..�ro�wiuurr�wiagl+rll�i��pl�i■-�'PyAO'Ao1v'+�'rwa�attfw.rr.rt^••+x••'rF�'•! t-4�1�7irt ti t J e It J Il�,r•ifle ,a{'r •.ti frs t fr ', t 1 � f t �,' i ._ r� 7. I • %f��{;�.. r C�• i Y �� ��'�i1 � � t t41 y'i r ��i ! �! � {.a ! .f ��,�, t � r)r !, cf � l,,.{•'�it1,'ti,�r �'�tr(y% ',' � }�►� 'f. 1 :.� � �'�y:;• !� �� •: it , �,r ft•�r Jr_ r}{rf ,{�rJt�?'��/t7n i!u c, 1 ( r , {17,� r � , t r � 'f ., •Rr t�) �� i. !1 rho r r ,, t 1'1 �, � J �f��:;�t� t'•+'i Each month the DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate= ten percent (10%) will be deducted and retained by CITY and the remainder, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judyment of the DPW, faithfully ,executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if the DPW finds that satisfactory progress has been and is being made, the CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the Commencement of the PPOJECT, as determined by DPW, less all previous payments and less all previous retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHHELD -CONTRACT FUNDS] SUHS,%!jjUTION QE SECURITirs At than request and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure _10- + r • •R ,C r ff,71 ytr+• Mr �Yr(ft t}t ' `�{ � �� � ! 1 • � 1 't' � t. �_, � t I ! t � � + r ' r I `. 1 : 1 � r j � } Y�'�'ll . r ( t,,6, rf` t!•i i}I � ��,.}� 1 r ,, r+ f t; tt i 1�17t4 r r 1Nt Y ..` ,I• t f �i rr rir rt1 t • 11 r ;.�!'j' f �n t,'d �('jjjj�� a +ti � ' � - ��� 1•`- J �d1 . + ts��'L� s�;•s� y4; ,�/h; •��5.}1r�})• ti +'• i �, !. + Ij t + }' �; _ � t I ' t 1. {•�� � r v..` t1 / . U r�r •r�+ 4t :t I 7 � I t try I , Ct'r�'1�� 1�, t �! ))., .1- .: t 1 r tit; 11 , •ot 't:f II � � )! 1Yt l J ':` ' 'y' ` •1 t '.` �- ,, 11 I` "7 �, ' `, ~ f f .11 tf.' /� 4�ir�tt%�i' r itt, �t y IVI, it I ''" Y, '._ � +Jt 1 ', �, t I •`. � , •. I � �'A� ,I `' 1 ' 4� �1 a►oj2�t �)1; �� �t., ? 1 t , t , .. ' I t t !j , +, r' , ' r �''' HIV 1: r' 1 t.l I �� JY 1 •I• I 1; fI• . .. t, .rt y !: ,. performance under Section 13 of this Agreement. 16. &MDAYIIS OF _SA1,15FACTIUd OF -CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with the DPW its affldavit stating that all workers and persons employed, all firms supplying materials and all subcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PROJECT for either labor or material, except certain items, ;f any, to be set forth in an affidavit covering disputed claims, or items in connection with Notices to Withhold which have buen filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreetndnt. 18. DEEENIE, HOLD HARMLESS CONTRACTOR hereby a:)rees to protect, defend, indemnify and hold and save harmless CITY, its officers, and employees against any and all liability, claims, judgments, costs and demands, however caused, including those resulting from death or injury to CONTRACTOR'S employees and damage to CONTRACTOR'S property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, including those arising from the passive concurrent negligence of CITY, but save and except these which arise out of the active concurrent negligence, sole negligence, or the sole willful misconduct of CITY. CONTRACTOR will conduct all defense at its sole coot and expense. CITY shall be reimbursed by CONTRACTOR for all costs or attorney's fees incurred by CITY in enforcing this obligation. t1�.•"�.�-T��+�r.s��M/w.�.�+r^��.w►�w,.�+�••.,ww.�--�--•• �....� r-t ....� .«;-...w��MyAe��.� r r + t; , t+ , t, C• t , ifr , i! �i r ii r 1p 1' 'f7/iif f r i ..t 7 1 ': ►i tf '��fji/�{.t ! ' t`t ' I;} + ., + I �.•If i I 1 t,I, � ' I ' ii t ,� , t �� �1 �1 }L r C4. iC /� �+}'`S.. .S, i ,`� �{ {r t,;'� t 1 ` ' '� � ,n; f , L It ' � t • / �!t ' i t i'rr ii5�,�7•,;.,,'�I /�, �yN}. .,�r •t , Vi lrlyL�}�! Ft .r t='�fi`J•� t� .ti 6t ,! ,' 4� FFF���4r il�t1t �f+� l �, ,,' '.�• L 11 't 1 f1'` :1 ',i t+ 1 ,t s, t r .. 1 ti f1r 1,l is t*'+`�� • � i • i � � V � � 1 ♦ \ i : 1 Pursuant to W_;Eornia Labpr Col,& §18611 CONTRACTOR acknowledges awareness of Section 3700 et seq. of said code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall maintain such Workers' Compensation Insuranca .in an amount of not less than one Hundred Thousand Dollars ($100,000) bodily iniury by accident, each occurrence, On's Hundred Thousand Dollars ($100•1,000) bodily injury by disease, each employee, and Two Hundred Fifty Thousand Dollars ($250,000) bodily injury by disease, policy limit, at all times incident hareto, in forms and underwritten by insurance companies satisfactory to CITY. CONTRACTOR shall require all subcontractors to provide such Workeru' Compensation Insurance for nil of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the Workers' Compensation Insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. CONTRACTOR shall carry at all times incident hereto, on all operations to be performed hereunder, Veneral liability insurance, including coverage for bodily injury, property damage, products/'eo►apleted operations, and blanket contractual liability. Said instsrnnce shall also include automotive bodily injury and property damage liability insurance. All insurance shall be underwritten by insurance companies in forms satisfactory to CITY Eo'e all operations, subcontract work, contractual obligations, product or completed operations and all owned vehicles and non -owned -12-- rr Vq. .�4;! J' ...•�'+ ..^n; *, t fir•- — - • t..---�,....I....w=,atir�t�'�••wr !y� �j'11lFr�y ri 1'1 1��,...,ar}\'>��`rl�11 I, I( 1 r. .I�' " ,� •r 1 r; +;•, 4r`YI !%1� { I � i) +� � { i''i� r {\ r 1 , �' , j i{I fr � + r'•rR Slr • jlf •'r c1 fj '�, 1 ��( {i ,r t : fix' r,��.� ti , I F!'( �1 1 - �r�r �,-:' I (� %1'�i�l �,•,'{ f� �Vr ,�1 r.�; } I I •.• i I r I .I it �rr �V }- r 1 i+ I Jr, 1 /) lrl , ' tl •:iFFI+ n , "1 r•1 J r 'r 4` J� !1 1 ci 1 e/ .ir1 t•: I; �\ ���� 1��,+1 r�. + ��f • 1 !: ri,•,r I icy. ` t ( ' i I #, r; i-ir'li•:-,', irl"r/I• is "i" ♦ I�r 3 / + ' l� •1 1 (+�r�b i l7j(;r ,1i t ri '��Pj�'li �+ 1�r� •+Ir.l. t r� ri i. � 1' " � ( i�t1 t'rl I .� � l4 i, 1{S ''�il� ir:l���l ``t r } ' r', r � : r J�, I - �' .� • 1 {' '. r r r•r 1 i ' 4 Fri ��`y�� vrtl,' �'I •i � / 1` .. ;� !' S , �' ; 61 Il• -I INS 1}rz �9 r I 7. � '••1 (6}i 1-,; '� 't + �. , ywr• 3 ff�``.. ti �))t ri' ', r' F l.tP:,y: M .�, 1r 1 -.. -- r " r 1•a•'cj 77�• t '� .. , 1 t.►e:., 71 � r , 4..i ry kjy.._ v rl t, lrA-f�t,r �a�,J, r '+ ..fJ 71 h•S , S I 5 1 yira�/ ,V rr • rYr' 4•",�'1 r ref ;l SC •.�� , r t: rf,f iIJI. � � i'�jr r r. • r1��T� "`• xr` � T,y�i al�,+lt r1y��'�l+r ., + _ ,'��� ,1��� ����1�k��r I�,9��&A�•1.,�� `�� _K..a.�rrri�rw�� vehicles. Said insurance shall name the CITY, its officers, agents ' and employees and all public agencies as determined by the CITY as Additional insureds. CONTRACTOR shall subscribe for and maintain said insurance policies in full force and effect during the life of this Agreement, in an amount of not less than One Million Dollars ($1,000,000) combined single limit coverage, If coverage is provided under a form which includes a designated general aggregate limit, such limit shall be no less than One Million Dollars ($1,000,000). In the event of aggregate coverage, CONTRACTOR shall immediately notify CITY of any known depletion of limits. CONTRACTOR shall require its insurer to waive its subrogation rights against CITY and agrees to provide certificates evidencing the same. Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by Sections 19 and 20 herein: said certificates shall provide the name a,id policy number of each carrier and policy, and shall state that the policy is currently in force and shall promise to provide that such policies will not be cancelled without thirty (30) days prior written notice to CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement 's fully completes] and accepted by CITY. The requirement for carrying the foregoing insurance shall not derogate from the provisions for ind'emnificatior., of CITY by CONTRACTOR under Section 18 of this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all said policies of insure:ice. CONTRACTOR -13- r * '3l f.•^t�.r+�+•��ww••rrSorlan �-.+..+�ww.w.......�. •-� , I , t► rt! 'r r r•11 i i �T'Mt '� n{y1y'I i`'. 'atl l r,l ' ` t r ;7 � +ri � r•� 1►�h �•, �r 1 .i r ��, I � rr � ,�i Ord' t� i �� �1t+„�%tS ' fSJ ��,� I , + + r , ,. I i,,• i , _ 4+r( t i1I. Irl, j.. 7 �. lj1 ��f( , il. �i lr} 1� -.r ! t rJ rf'}.+y, •�7 a.:l\ fk`ri�J� � i+,}a x�fr , r{ `l��+y�`., e j rl, � � i. )- +. ''r'' � �) ���yn � +•rt�t ! i r7 a ' r �. I � � t.11 y r•'� , `r,• , t � ,. I.. >,,; .r �_•'f ,i i� ,.'i. lf(a}%i � r�y'• ��f }JYrj, �• a {� •I t�r�'�r�rt ! ,; � + !�r � r r 1 r� r y� ari%, 1 + � , r''1 n. 1 a z yv>r Wei {� i 44, ;;s r R,'��� i, '.rt ` ..' r J 1 •r,r r r r �C, � : � �'% r ' I ��. ', `ra I l,`. :^� Ii � , _�/ .f r � }}}�l�rj�r t� r r r �R�iri�•' r+ pi CIO,' �'!a.* r II,I•i, - ,fit 7 �r;f r j.i.,. !, I '.r• "' i C , `•'s r' r�'YI� tf t"�' shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. A separate copy of the additional insured endorsement to eactt of CONTRACTOR'S insurance policies, naming the CITY, its officers and employees as Additional Insureds shall be provided to the City Attorney for approval prior to any payment hereunder. 22. DEEAULTjiND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged a bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of -his Agreement or the Contract Documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such detatilt by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agrae.nent shall be delivered to CITY and become its sole property at no further cGst. •W�-T-Rv �:: * CONTRACTOR shall not sell, assign, transfer, convey or encumber -14-- , 'r'i rw'wwrtir�.t./R/I.l.w.�.'S'f1 �Ms�1�'7R7fi/471•�i11,N11/10A.,.�+'�"' r [ , . t t �`� i � , �t •'L iti rr.� � �.,.♦ t ��t�l � 1 Y� 1• r Jr r� - ' rY f,S t/j +in rsF i�i�:�t tl J 1• �Ik •�, itj�, �7 ifR '�. �Itf `pf i ,iyrp4,'', tat ;J , I - , •,r. , , 1 ��y�� �, r„ y, L t ter1►�,. �� �, t� tr y ?u. r I �WP ��f�t•r ( ,- •� ' 1. i*r t.. t7 h'.' T . Jlr f • , t � �. •+ .i� t�� +•,�, w �� ,���'"�,�,� it Fk'. � , + • I�' µ �� . ti a'�t / (, f It � �J,.j t,l opt U+�t�lli`y� rlt ��_•(��1 r� ! 1 f.-�ift "� r rrr y r ! ry tit , i ��'•��� �f���l���� rt rl "�; , sly r� '� r�. . '� jir h•I ?, I •t +3f'+ �;�.t Ifij`�+V. S t t s..r! ti ,ti '`"• '1 : +t '� thi;,, Agreement, or any part hereof, or any right or duty created herein, without the prior written consent cif CITY and the nurety. vP1--ff;j�j1jK0j CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. NO officer or employee of CITY shall have any financial interest in this Agreement in violation of Ca!1_ fornta Ggy jrnmgrk _ ode sacrions 1090 et seq. 26. STOP NOTICES; RECr- IY BY OF ADNINI}27:RATIVE CO M CITY shall be entitled to recover from CONTMCTCR its reasonable administrative and ettorney's Fees, costs and necessary disbursements arising out of the processing of said Stop Notices, Notices to Withhold, or any similar legal document necessary to the prosecution of such action. Said obligation shall be provided fore in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One-HUndred Dollars ($100) for every Stop Notice filed In excess of two, regardless of whether or not CITY is named in an action. CITY may Jaet off any Unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of 8 U-sir_., §:1324a regarding employment verification. 28. NOTICES Any notices or special, instructions required to be given in writing under this Agreement shall be given either by personal delivery to C011TRHCTORI S agent (as designated in Section 1 15 -• i(I i f'rj'� +�..*.M,?'.a..�1L �( ..-•j'1 r•+rw1•t{�,�, r .' r7 I.., �sxVatn•n■ts7l-n+n-.-.Y'•• ''' ;(„-..^' r . r �,t ri/I: IT.:`� ;"^f'•,7 ' TIP!, ,: I , �Y11 rSyf.,` r�.�r+l.}7 r• 1rl�rr, i{�� r. ;a .t I ,! t + r,y. rl lr ',•tP r• p tY,,�� � I 7f .t r Y1 %' :N� I . •1 �i ! •','- �' � ti,t}�j, , r,�,�� ! r ! • �! 1 •�!1 ', 1.,A ` ra 7� }t+7. ,; ' r ,'��, �+�'�'l J( �i�i,� 7 'Ylt; ' I t I :� 1 •,/ t! 7,vr r � ' yjS� �Zns t' • � fl� .� Vi , ` t,l) / t� ,a ', •! ! r (!j + ! +.fit ( r 1'1. rt r %r,, ti4i�„y a �' � , ,+�1 ! �y�'r j ' r r " f 1 � I' �. ' ��� tt. 'r, �� ' j ii! � r � l,.!1(L�'���L�,• ,,r'�'. I tl y.) r. I s x c L ..' ,,r� r , �t• '.r �� ( (: i;t r 1 ,• , y; t 2 / f r:; ,.{� Lr?t .7',. i f,') ; i ,1 f (♦ �'r ; �S•' rrr 1 ;rJ n f y i�tkr 'j 7�ylF a• , � t t SJ i ` � r � ' fh, ,,, ;;�`�j Jai ., f,{ t! Jr 1,•t.; Ir /,fa ( . ,L J7. , ([: ' Id1'>ti r• � a}�}�''�, > w a��, % ., ,rl :j! i. •,'t t< -+� ,r A 1rr�1� r�li� �%''r �f � rr `7et�kr ,�1 ,, i lyr ,, •� ',•t.. `1 �' < 1� f�r � f � r; 1.. i � ' ,, r. �(�. A'�J J f �� Z7 i, !( ,` r t• I � r ; 4' r f 1 t i'/.r +}}, Sfi t-1f[cg'�II �' fir+ ,. 11r r ,t;' 1 1 .� •, r . ' f .. l,tiF r I 1 7 i f r dry lif�',�•(�� .,1 � r,'p 1 Irrf»11./yry�i ��'t}r � � i I.t �' r 7 !.l r _ r !! �� 4r� 7• , .al j r • � � � f�'�4tL7 �7 � J )! ' :, /�l , ;-•( f 1. r ,t ,4 Y+� �'.t�• 'L •"' Ir '•�.1 it , , !r t , ) L yr + • ..i - I , r..j r {� fry...• '4 ,�' ,1 '� P ' TM.-w.<ir',.�Ar. I �x r r r r •��y}Y� T1 fyr1 1 ,� d f (" Y, ..i>jr ''+tyf� !i i 2' ;`=.L�, to + iJ ! 1. v '+� � •tt�`ftla , 4 4 .�,�, C1{�t.��)pt; f��y ' �f ` �`=4{• I ` ' y' 1� `' I tlr��q y � +� $ r `��1�rlf j ;,l ✓:��7'M , ',, Jt. ,,.. ��� r Y+ ter `�, � �Iff�i, ,!"d� ��� r�1 I � a��!'1 ,T rsl;��r l�+r+���, �, �� «� , •,1i i ` + 4 Z•, �� 1�`l�'��Yll�( �l I c� i4}�' �{�'rl � .S� i r,•� +... } 11 �,'. y FFyn ' • 1} , ,'. , '. ( I t �•�l / i �rr �•+Cfl� S,r,�ar. �Syi'R,r d y�.'a.,:�^ 1 r�J. v{��h{, t+ -r � .i "'V he:reinabove) or to CITY'S Director of'Public Works, as the situation Ahall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States Postal Service, addressed as follows: TO CITY: Louis F. Sandoval Director of Public Works 2000 Main Strent HunEington beach, CA 92648 29, CART ONS TO CONTRACTOR; Captions of the sections of this Agreement are for ronvenienWa and reference only, and the words contained therein shall ih no way be held to explain, modify, amplify or aid in the interpretation, cc'nstruction or meaning of the provisions of this Agreement. REST OF PAGE NOT USED -16- �{-.,+ r l41 jig , 77177�7 Tr ;' ai .� 1 r' J• r .. , r , tit 1} t r .:� 1 '(. `�• y8 .• � � r ._ � i � U. , 11•� ��{ :1r S f ��r� p, �� J ill r' '1 (�f+./1;1 ' j', J/ /..1� .`,11, ldf' r!', .� i ? i.'�"'i ,�+}l'.i•: `��ty�tu.i.Jli ,� J. C 1 � w 441 r✓4IRr.. ' �F`i�` ,'ll . !i s.i J Jrr • J C l� tr r r 1 ti� i pit f jf1+ 3 fi �7•`� t 1 r r +1 1 1 r 5• 1 'S t + rr /U { , ! I f' t r t11`, Ir r t 1 t1J l,..f o 1 1( I �, , y t +: .J 1j�1 f(r # �•i'�t c'', i +(1i1J/111t`f rrrr�i`7�ti •%�at� �j1' Ir !(I�r Iv '1/ }/•L 1 .i tl rl ri� i I;: 11 �..I{ f , 1 �'1, i,�,. %�1r#iJ+ 'ni' 111 t37 _..Y S( 1 f lr , ` 3 I , .• 1,,+' 1 �' `-l.1 +� , 1 } ✓f� J rl� !f� r� i �, ri 1t)f�[ r ;f �l••J r-.i , {'nE r� J',,r { }. ;j kl; 13. '� ` I. � 1 , r I:}J I •t rl�'` .. Ir Je' I �1 i� rr S I i •r� f r ��� lei , ✓r� +, - f:1� ,' ��j�. 1�1 f ?�; 1rr' ,+ . 30. ENTIRETY The foregoing represents the entire Agreement between the parties. IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers the day, month and year first above written. CONTRACTOR: By: - - Its: By: Its: ATTEST: City Clerk REVIEWED AND APPROVED: City Administrator -17- CITY OF HUNTINGTON BEACH a municipal corporation of the State of California Mayor APPROVED AS TO FORM: -tV::torney � INITIATED AND APPROVED: Director of Public Works +�'!^1!Fr'l Y"Nt ♦ ;�r� ''' rl .. tl •• w�C^ ..� + t t.1.4fI t+F i r {il/i rr r.i It � r�'i '%♦ 7j't rJ ' r r. i if.., r � (. i.tr t.;`�'r� ♦�`! tt �+Itt'S7�S � l��t, ,� Hi tr ♦ ' rf ry.- r L 'f-ri t ) t, rrr,' /11 r r,4 •j1f .It ,� ♦ {'P`t7 i�t l ltV (.� r 1 5 t� rr r r rJ.. 5�+1.• L �!`�1��5 tl.��?, ',i! ~ f r.. irr e. �j' + t r• , f i rii ��. 1 �r �i�. ♦r� { r 'llti f: ,: iy i,.•, 7�• rj ` C'.i , ,,).r �1`�1,ti/�t V•;. �r,"I•l IJ ' �+t ' •,-fir, 1..,,: 1 !�• 1 •, .t ,. r r� r' •t�r f r r+ � + J �tirrti I t?• f r � t �t `, « i 1 ,C , i,r{ -t•rf I•.r i�' ' ,i � ��!� ' t ''y♦ tr2! rlr^ "ti , r I SS f7•P'S `i4`,f�trl �!;� +`� ti ` ! rt�►t 'i.?U� �'1Y',�1 tr.' •� a ! ;/S� � t, � ?S,It At,. `o- ptJ ♦f ; � ' rl t _ �+ I,r r, � t t 1.. ,i. i / � , }, / 1 r f 4i' li 7{�',r�`/� ��. Ct r,}/,t 1 t r r�r r'[ i i 1 r r,•r r i1 7f/11 j, ��7�, �5ilflJ�w 5 :'1 ��• '1 '� r • rt. ♦ 1. r �1.` t�� �� `, i"` �11��ti�� lj .+�Ij4♦{�1 11. rr`� .�� •�r rtr ,i� rl + / r ��5 ,) i L `. ` 1 i C,, �r1✓t 7[�),i 1.. i ,t tl �r 5 11 � \fie 1, .t rf:� , .. r r i rr{• r ' 1 �tZ J 1 itl. il HUNTI NGTON H a w CINT91K DRIVE li{{ �[ �FJ7'1'1'Vrr.w..—«.++..r r��- •f ...,•ry\R'llt•MIMJAt71.�M�� A177;'i) i'li �M�,�i '1.� 11ti t f� tiJ,,� t 11 ,. J � � •,i �, Y,o rf �� s ( ij � ' FCC •J .� i , ��� 5, Id �� rl.�,� r r,• �(r�t��ii`y' fi ^�J�r,t ��'� r.. �1.1 -�� , tJ, .�1.^: ��1i�.,t i�/�'�,f� ..112iJ (+�Ifr•r;'^� � I+. ,r�t •� .r ,t .. ,..., •', 'f t ' `/ i-. t V NOTICE OR EXEMPTION , 1. TCh Office of Planning and Research PROW (Public Agency) 1400 Tenth Street, Room 121 ,fit„ �. } �..A.AOA-- Sacramental CA 93814 I County Clerk L E D County of _._. SE P 2 7 1995 legit Location -spec 2 jecct Loc on-'C3ty crlption of Nature, -. 1 r {I . i� , . Lhm ri�oject Locat N • 'urpose, and Beneficiaries of Pro) Name-ofrPuubilC ASdney ADpedyrnit ProFect Exempt Statust Kk On�� MinIsterla! (Sec. 13073) Declared Emergency (Sec. 15071 (a)) Emergency Project (Sec. 13071 (b) and (q)) Categorical Exemption, State type and section number. Reasons w f project Is exempts' Contact Person Area Code Telephone Extenslen U Mod y applicant: 1. r'ttta-:h certified document of exemption finding. 2. Has a notice of exemption been filed by the public agency approving the -: oject? Date Received for Filing Revised January 1995 �Wwrr"ti'wti^.h.Mwrt�wMw*�..�' r 'ZN 1 � �'�^•'w�{ll tli IeeTeAl {r')'arnlli -arc'��.+x.......++.�--.� �^•mil" ``il 1 •;. ire,. `y,• ' ' � , �u5`��1 •,1 r �� , r,•,'rJ � ,C.r } ', �, � 1 .. to �� ` � ,..` lt,t +1:, � J. -, •, ,JI` tr 1, 1•,'r�r .. .r '/ ,f }; l) I `{� 0. .. tr'• 1`j a'+ T fl7J to; tr to �rr+. r: ;•rl ,i� +��}y l��� ��t �,,a-r� �` .x��r ,':t 7:, ,� , 1 f+ a (., to a ix• F i tIK i4 �!.'.: 7 .aar. ,,,��.�,,.,.,:'.:,:.....iii.f I1►ll►iltjMMfISS + I� CITY OF HUNTINGTON BEACH %- INTER -DEPARTMENT COMMUNICATION hV%11%V0% 114C11 To Jim Engle, Acting Director From Gail Hutton Community Services City Attorney Subjl_cI Leasure C Issues Date January 11, 1991 This is a follow-up to our opinions of September 12,' SepL•ember 14, and December 14, 1990, wherein we stated that construction of structures costing less than $100,000 are exempted from Measure C, but that the city cannot "piecemeal" a project into smaller phases just to evade Measure C. Measure C precludes various protects on any park or banch without mejorit; votes of both the Council and the electorate. The measure has an exception for leases and agreements where services were being performed on January 1, 1969, and thelproposed activity would not increase the amount of parkland being used. In addition, we advised that constitutional restrictions on itipairrient of Contracts precluded applying Measure C to existing contracts. Unless a project: falls within the exceptions, a vote of the people is required. Applying these principles to your. Further questions: 1. Youth She,= If the youth shelter building is demolished, may a ne4 building by constructed without a vote? Yes, as long as the amount of parkland is not increased. (See our Senior Center opinion of 9/14/90.) 2. }ICP Handfc�npg Facility. Would a handicapped fishing/picnic/play area in Central Park with play equipment and fishing dock, each under $100,000, be excepted? Yes. The vote is required for a "structure" costing over $100,000. These appear to be isolated structures and not part of an integrated facility. (wee our Save Our Parks opinion of 9/11/90.) �!'r �7f r ^+.,.!w�.T�.wir. �..�YMw.ow�a�wrowvr.++wu �mryANy�+v M.tv+ ..�.�.+.+•— 1 _ �'+ rM'.Tr. 1 'oily r 113' 1_I (t• 1; � '3`. � r f �r.� ,fir ti. `•�1.� r�l +t. + 1 J.', �_ �' � :f 11 , Ir 11c f 1, )� L + �)i�.. ex. + Lt 4 1 •� . ��1• Jr1�11t )'''�:'i1' sl,, ;' I\ r 1• � tit. !.i x ,{� IV 1 f till N a1 9 Jim Engle Page Z January 11, 1991 3. Is expansion of the Newland Barn into areas fenced into the original project excepted? Yes. (See our 9/14/90 &eniur canter opinion.) 4. Does the proposed Youth 3por►,m Comple= fall within bhe exception, since individUel light poles, backstops, and snack bar ate less than $100,000, but the entire lighting system, baseball field, and complex cost more than $100,000? No. As noted in the 9/14/00 analysis, favorably on piecemeal contracts on an Unlike 'the handicappeu improvemehIL6 in only exist as an integrated facility. required. Gail Mutton City Attorney GH:RCS:sg cc: Michael 13beruaga a court would not look integrated project. HCP, this project can A vote appears to be r 7 - P7 g1�1*N S. rr w.Nw..w Irwu.� .r..++�.w i.t� Z ^+ j t .T T�^7'T• r `'f f1 j•..Tf1y th �d .7 yr✓ ,� �' j •.' rr�� r i � � + : tf !i 1!s jt� �. � j ,/� f% .r��t i r t r } 4 t t�,� 'rt ; f r t '..�ti +��.If tt�• /,r i 1.J� 'ti. �,} ( r.T �,�f,ly"1- r 1: t tie t'r }f• / 1� � ii' 1 1..`i Y 1�. rl�\7��klr�+IA tit', •, li r ,_ 4 _ 1 •f iJ •� i Ijfi'1,��(`�'�J -1 i�D !��( ���,+ ; •� � t � F ., 1 1,� �, t j'�, t.. � tit �\•. t J ly {' Ibj, f4; (( s� �711,1 •,�. ,Y� � / � ! 4 J �r1 , j� i°1 .rI4 „ 'It 7 ,�,✓ .�"►.yi a,#,fir j(� , .,. �, + n,:. � �,Ii } r ,,r��✓',��,�'',; yy�Iijl,. Ilr \� /f ' y '•+�4 Jy,1!� A�"^a�•'�y v it, ,•r �, .',fE +4F \ fey ��'y�� +� ��iE�L'�41S 1, ��} '�.._ ,Ir \ 7� r � •_v y t r ,"i �J� � ,�� r , 1 7.• 1 r rl v7 ,r r ' r ,. r 1 ��1 '� r f,9C �,rt� r j '. �1 �•r�t r!.ti�t 1 -, 1 ��.,��1 r. r ,4 Y' / r�•� �yl'���',j��A REQUEST FOR CITY COUNCIL ACTION Date _ February 4, 1991 Submitted to: Honorable Mayor and City Council Submitted by: Michael T. Uberuaga, City Administrator Prepared by: Ron Hagan, Director of Community Services Subject: Fouls F. Sandoval, Director of Public Works Central park Handicap Play Area; CC-803 Consistent with Council Policy? [xJ Yes [ j New Policy or Exception Statement of Issue, Recommendation, Analysis. Fundinq Source, Alternative Actions, Attachments: SIAIEMENT of LSSUF.: Plans auld specifications for the construction of a Handicap Play Area In Central Park are complete. R�oh�NQ1lT�QlY: 1. Approve the plans and speclfications and authorize the Director of Public Works to solicit construction bids. 2. Approve: the attached contract subject to award of contract to Council approved lowest responsible bidder. MAUSIS: J , The landscape 'archttectual firm of Cardoza-Ullallb-Harrington has completed the the plans and specifications for a handicap play area in Central Park (see Location Map). This play area, directly adjacent to Huntingtcn Lake, will include the construction of a fishing dock, picnic area a sand pay area, on -site park bar b-ques and renovated landscaping. The City was awarded a $100,000 grant from the State for this project which is designed to be handicap accessible. Staff of the Development Services Department have determined that the environmental impact of this project is Categorl6ally Exempt (see attached); therefore, the City can proceed to construct improvements as shown on the plans. Furthermore, the passage of Measure "C" is not applicable to this project bmAuse the st=turea are isolated and not part of an "integrated" facility (see attached memo from City Attorney). Therefore, the Director of Public Works requests approval of these con--truction documents and the authorization to solicit construction bidr. EUND1NG SOURCE; The landreaoe architect's estimated for the construction of these improvements is $150,000.0(1. Funds of $165,000.00 have been budgeted for this project in fiscal account E-4SK-CS-601--6-•39-00 of the $165,000 budgeted, $100,000 is from a State grant. i t P10 etas "�'T^• PIS w� , • ,' S'y'' t 1 ) � '--� . (F 1 ' ! ' � � ' } 4 + ' �1 % • � ' 1 ! t' { 1, \t� zt ,r` ,f , 1 ' .1 ' },. 1'1 j 1 1' '. rYt f it ) 1 Y} j r t f Z , r ,j ►Y� t ,(t, ! i # �`L� 5 ► ,}s jti '�-•. 1 .•Y. .Fi,)r�1.�'��''�7 �! •i ;•tt ` �fx ' ,lilt/�1 .!:��t,�+1 �'�S!� t<. ,1 �.� , •ti, i(,, a1. 1 4' r'