Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Hondo Company, Inc. - 2008-08-18
Council/Agency Meeting Held: Deferred/Continued to: *Ap oved ❑ Conditionally Approved ❑ Denied i erk' Sign t re Council Meeting Date: August 18, 2008 Departmen ID Number: CS08-020 CITY OF HUNTINGTON BEACH REQUEST FOR COUNCIL ACTION SUBMITTED TO: HONORABLE MAYOR AND CITY COUNCIL MEMB SUBMITTED BY: PAUL EMERY, INTERIM CITY ADMINISTRATOR/' PREPARED BY JIM B. ENGLE, DIRECTOR OF COMMUNITY SERVICE SUBJECT: AWARD LAKE VIEW CLUBHOUSE PROJECT MSC-439 Statement of Issue, Funding Source, Recommended Action, Alternative Action(s), Analysis, Environmental Status, Attachment(s) Statement of Issue: In March 2008, bids were received for the Lake View Park Clubhouse ADA Improvement Project. Staff recommends the award to Hondo Company, Inc., as the lowest responsive and responsible bidder for the contract. Funding Source: Funds in the amount of $119,601 are budgeted for the project in Community Development Block Grant (CDBG) ADA Account No. 85782015.82000 and $4,199 in Park Acquisition & Development (PA&D) Account No. 20945101.82800. Recommended Action: Motion to: 1. Accept the lowest responsible bid submitted by Hondo Company, Inc., in the amount of $123,800 for the Lake View Park Clubhouse ADA Improvement Project, MSC-439; and 2. Authorize the Mayor and City Clerk to execute CDBG construction contract MSC-439. Alternative Action(s): Do not approve the contract and direct staff to re -bid or abandon the project. REQUEST FOR COUNCIL ACTION MEETING DATE: 08/18/08 DEPARTMENT ID NUMBER: CS08-020 Analyses: Lake View Park Clubhouse is located on the northwest corner of Slater Avenue and Newland Street, adjacent to Lake View School. It is offered to the community on a rental basis for group meetings and small events. The facility is mainly used by non-profit organizations such as scout groups, and by a variety of community organizations. This neighborhood park support facility includes exterior access restrooms, a meeting area, and a kitchen. The Lake View Park Clubhouse is a wood framed structure with an interior area'of approximately 1,200 square feet that can accommodate up to 70 people. Built in 1972, the interior of the Lake View Park Clubhouse is very timeworn and in need of refurbishment. Accessibility issues also need to be addressed. The existing wheelchair ramp exceeds slope standards per Americans with Disabilities Act (ADA) standards and will be brought into compliance. The main meeting area of the building includes a step down floor and single step landing. A ramp will be added to enable wheelchair access. Restrooms will be modified to achieve clearance requirements and fixture heights. The interior doors will also receive hardware upgrades to include actuated levers. The Lake View Park Clubhouse project has been awarded $119,601 in CDBG funding over two budget cycles. $4,199 in PA&D funds will also be used to complete the project. Improvements to the facility will better serve the various non-profit groups and community members using the facility. Staff is recommending approval of the CDBG construction contract with Hondo Company, Inc. for the improvements described above, and lowest bidder as listed below: Bidding Contractor Bed Amount (As Submitted) 1. Hondo Company, Inc. $123,800.00 2. GTA Construction $129,000.00 3. Caltec Corporation $184,000.00 4. W. E. O'Neil Construction Co. of CA $196,533.00 Environmental States: Not Applicable Strategic Plan Goal: Improve the City's plan for funding and completing infrastructure needs, and develop strategies for resolving crucial infrastructure problems to preserve the physical foundation of the community and enable the community's value to grow. Attachment(s): G:\RCA\2008\08-020 Agreement for ADA Improvements to Lake View Clubhouse.doc -2- 8/5/2008 2:08 PM 1111, , iq AF F�I*Wll IN In 4 E FEDERALLY FUNDED COMMUNITY DEVELOPMENT BLOCK GRANT CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND HONDO COMPANY, INC. FOR ADA IMPROVEMENTS TO LAKE VIEW PARK CLUBHOUSE THIS AGREEMENT ("Agreement") made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and HONDO COMPANY, INC., a California corporation, hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as 'PROJECT," more fully described as ADA improvements to Lake View Park Clubhouse in the City of Huntington Beach; and The PROJECT to which the construction work covered by this Agreement pertains is being assisted by the United States of America and Federal Labor Standards Provisions are included in this Agreement pursuant to the provisions applicable to such Federal assistance. Housing and Urban Development Act of 1968, as amended in 1992, Section 3, Title 24, Code of the Federal Regulations, Part 135, Economic Opportunities for Low- and Very Low -Income Persons, Section 3 contract clauses, the work to be performed under this Agreement is subject to the requirements of Section 3. of the Housing and Urban Development Act of 1968, as amended, 12 U.S.C. 170lu (section 3). The purpose of Section 3 is to ensure that employment and other economic opportunities generated by HUD assistance or HUD assisted projects covered by Section 3, shall, to the greatest extent i feasible, be directed to low- and very low-income persons, particularly persons who are 08-1659/23356 1 recipients of HUD assistance for housing; and CONTRACTOR has been selected and is to perform said work; NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 08-1659/23356 2 w 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council, and any revisions, amendments or addenda thereto; D. The current edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 10801 National Boulevard, Los Angeles, CA 90064, and all amendments thereto, 08-1659/ 23356 3 f written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 08-1659/ 23356 M 07/23/2008 WED 11, 21 FAX 7143741654 City of HB, Comm. Serv. 12001/001 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed One Hundred Twenty Three Thousand Eight Hundred Dollars ($123,800.00), as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within six (6) consecutive months from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to 08-1659/ 23356 5 the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the Agreement price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work 08-1659/23356 6 11 due to unavailability of the job site, for any reason, relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the Agreement price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the Agreement price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final Agreement price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within.ten (10) days of filing of the Notice of Completion. 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten- (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOWs risk and own cost and expense. 08-1659/23356 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of working days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of Five Hundred Dollars ($500.00) per day for each and every working day's delay in completing the work in excess of the number of working days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. 08-1659/23356 8 CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless DPW shall grant a further period of time), notify DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY 08-1659/23356 9 or delays by other contractors or subcontractors, will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DIFFERING SITE CONDITIONS A. Notice: CONTRACTOR shall promptly, and before such conditions are disturbed, notify DPW in writing of: (1) Subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents; or (2) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be made and the agreement modified in writing accordingly. B. Time Extension: No claim of CONTRACTOR under this Section shall be allowed unless CONTRACTOR has given the notice required hereunder provided, however, the time prescribed therefor may be extended by CITY. 08-1659/ 23356 10 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of Agreement items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, 08-1659/ 23356 11 and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined in its sole discretion by DPW, less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the Agreement price shall not be considered as a acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items, if any, to be set forth in 08-1659/ 23356 12 CONTRACTOR's affidavit covering disputed claims, or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all, claims, damages, losses, expenses, judgments, demands defense costs, and consequential damage or liability of any kind or nature, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 08-1659/ 23356 13 0 19. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall maintain workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 20. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, 08-1659/ 23356 14 of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than One Million Dollars ($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees, agents, and volunteers as Additional Insureds, and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary. Under no circumstances shall said above -mentioned insurance contain a self - insured retention, or a "deductible" or any other similar form of limitation on the required coverage. 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. provide the name and policy number of each carrier and policy; 2. state that the policy is currently in force; and 3. promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. 08-1659/ 23356 15 The requirement for carrying the foregoing insurance coverages shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under the Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 22. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten (10) days of receipt of such claim or claims. 23. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect 08-1659/ 23356 16 not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 24 and any damages shall be assessed as set forth in Section 23. 24. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause, and whether or not PROJECT is fully complete upon seven (7) calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience, the CONTRACTOR shall be entitled to receive payment for work executed, and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 25. DISPOSITION OF PLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 08-1659/ 23356 17 0 El 26. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety. 27. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 28. STOP NOTICES: RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100) for every Stop Notice filed in excess of two (2), regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 29. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States Postal Service, to 08-1659/ 23356 18 the addresses specified below; provided that CITY and CONTRACTOR, by notice given hereunder, may designate different addresses to which subsequent notices, certificates or other communications will be sent: TO CITY: City of Huntington Beach Community Services Department ATTN Dave Dominguez 2000 Main Street Huntington Beach, CA 92648 30. SECTION HEADINGS TO CONTRACTOR: Hondo Company, Inc. Attn: Bob Lloyd 2121 South Lyon Street Santa Ana, CA 92705 The titles, captions, section, paragraph, and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions, and do not interpret, define, limit or describe, or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 31. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 32. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that 08-1659/ 23356 19 pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 33. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees and the prevailing party shall not be entitled to recover its attorney's fees from the nonprevailing party. 34. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 08-1659/ 23356 20 35. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 36. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. 37. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 38. COMPLIANCE WITH APPLICABLE REGULATIONS. The parties to this Agreement agree to comply with HUD's regulations in 24 CFR part 135, which implement Section 3. As evidenced by their execution of this Agreement, the parties to this Agreement certify that they are under no contractual or other impediment that would prevent them from complying with the part 135 regulations. CONTRACTOR agrees to send to each labor organization or representative of workers with which the CONTRACTOR has a collective bargaining agreement or other understanding, if any, a notice advising the labor organization or worker's representative of the CONTRACTOR's commitments under this Section 3 clause, and will post copies of the notice in conspicuous places at the work site where both employees and applicants for 08-1659/ 23356 21 training and employment positions can see the notice. The notice shall describe the Section 3 preference, shall set forth minimum number and job titles subject to hire, availability of apprenticeship and training positions, the qualifications for each; and the name and location of the persons taking applications for each of the positions; and the anticipated date the work shall begin. CONTRACTOR agrees to include the Section 3 clause in every subcontract subject to compliance with regulations in 24 CFR part 135, and agrees to take appropriate action, as provided in an applicable provision of the subcontract or in this Section 3 clause, upon a finding that the subcontractor is in violation of the regulations in 24 CFR part 135. CONTRACTOR will not subcontract with any subcontractor where CONTRACTOR has notice or knowledge that the subcontractor has been found in violation of the regulations in 24 CFR part 135. CONTRACTOR will certify that any vacant employment positions, including training positions, that are filled (1) after the contractor is selected but before the Agreement is executed, and (2) with persons other than those to whom the regulations of 24 CFR part 135 require employment opportunities to be directed were not filled to circumvent the CONTRACTOR's obligations under 24 CFR part 135. CONTRACTOR agrees and understands that noncompliance with HUD's regulations in 24 CFR part 135 may result in sanctions, termination of this Agreement for default, and debarment or suspension from future HUD assisted contracts, and With respect to work performed in connection with Section 3 covered Indian housing assistance, Section 7(b) of the Indian Self Determination and Education Assistance Act (25 U.S.C. 450e) also applies to the work to be performed under this 08-1659/ 23356 22 Agreement. Section 7(b) requires that to the greatest extent feasible (i) preference and opportunities for training and employment subcontracts shall be given to Indians, and (ii) preference in the award of contracts and subcontracts shall be given to Indian organizations and Indian -owned Economic Enterprises. Parties to this Agreement that are subject to the provisions of Section 3 and Section 7(b) agree to comply with Section 3 to the maximum extent feasible, but in derogation of compliance with Section 7(b). 39. MINIMUM WAGES All laborers and mechanics employed or working upon the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR Part 3), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the CONTRACTOR and such laborers and mechanics. Contributions made or costs reasonably anticipated for bona fide fringe benefits under Section 1(b)(2) of the Davis -Bacon Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of 29 CFR 5.5(a)(1)(iv); also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs, which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. 08-1659/23356 23 Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits on the wage determination for the classification of work actually performed, without regard to skill, except as provided in 29 CFR Part 5.5(a)(4). Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein; provided that the employer's payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classification and wage rates conformed under 29 CFR Part 5.5(a)(1)(ii) and the Davis -Bacon poster (WH-1321) shall be posted at all times by the CONTRACTOR and its subcontractors at the site of the work in a prominent and accessible place where it con be easily seen by the workers. Any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the Agreement shall be classified in conformance with the wage determination. HUD shall approve an additional classification and wage rate and fringe benefits therefore only when the following criteria have been met: and (1) The work to be performed by the classification requested is not performed by a classification in the wage determination; and (2) The classification is utilized in the area by the construction industry; (3) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination. If the CONTRACTOR and the laborers and mechanics to be employed in the classification (if known), or their representatives, and HUD or its designee agree on the 08-1659/ 23356 24 classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by HUD or its designee to the Administrator of the Wage and Hour Division, Employment Standards Administration, U.S. Department of Labor, Washington, D.C. 20210. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise HUD or its designee or will notify HUD or its designee within the 30-day period that additional time is necessary. (Approved by the Office of Management and Budget under OMB control number 1215-0140.) In the event the CONTRACTOR, the laborers or mechanics to be employed in the classification or their representatives, and HUD or its designee do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), HUD or its designee shall refer the questions, including the views of all interested parties and the recommendation of HUD or its designee, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise HUD or its designee or will notify HUD or its designee within the 30-day period that additional time is necessary. (Approved by the Office of Management and Budget under OMB Control Number 1215-0140.) The wage rate (including fringe benefits where appropriate) determined pursuant to subparagraphs (1)(b) or (c) of this paragraph, shall be paid to all workers performing work in the classification under this Agreement from the first day on which work is performed in the classification. Whenever the minimum wage rate prescribed in the Agreement for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, 08-1659/ 23356 25 the CONTRACTOR shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof. If the CONTRACTOR does not make payments to a trustee or other third person, the CONTRACTOR may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program; provided that the Secretary of Labor has found, upon the written request of the CONTRACTOR, that the applicable standards of the Davis -Bacon Act have been met. The Secretary of Labor may require the CONTRACTOR to set aside in a separate account assets for the meeting of obligations under the plan or program (Approved by the Office of Management and Budget under OMB Control Number 1215-0140.) 40. PREVAILING WAGE LAW. The CITY has ascertained from the U. S. Department of Housing and Urban Development ("HUD") the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this Public Works Agreement. CONTRACTOR agrees to secure payment of compensation to every employee. 41. WITHHOLDING. HUD or its designee shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld from the CONTRACTOR under this Agreement or any other Federal contract with the 08-1659/ 23356 26 same prime contractor, or any other Federally -assisted contract subject to Davis -Bacon prevailing wage requirements, which is held by the same prime contractor so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees and helpers, employed by the CONTRACTOR or any subcontractor the full amount of wages required by the Agreement. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee or helper, employed or working on the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), all or part of the wages required by the Agreement, HUD or its designee may, after written notice to the CONTRACTOR, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased, HUD or its designee may, after written notice to the CONTRACTOR, disburse such amounts withheld for and on account of the CONTRACTOR or subcontractor to the respective employees to whom the are due. The Comptroller General shall make such disbursements in the case of direct Davis -Bacon Act contracts. 42. HEALTH AND SAFETY. No laborer or mechanic shall be required to work in surroundings or under working conditions which are unsanitary, hazardous, or dangerous to his health standards promulgated by the Secretary of Labor by regulation. The CONTRACTOR shall comply with all regulations issued by the Secretary of Labor pursuant to Title 29 Part 1926 (formerly part 1518) and failure to 08-1659/ 23356 27 comply may result in imposition of sanctions pursuant to the Contract Work Hours and Safety Standards Act (Public Law 91-54, 83 Stat. 96). The CONTRACTOR shall include the provisions of this Article in every subcontract so that such provisions will be binding on each subcontractor. The CONTRACTOR shall take such action with respect to any subcontract as the Secretary of Housing and Urban Development or the Secretary of Labor shall direct as a means of enforcing such provisions. 43. PAYMENT OF TRAVEL AND SUBSISTENCE ALLOWANCE. Section 1773.8 of the California Labor Code, regarding the payment of travel and subsistence payments, is applicable to this PROJECT. 44. APPRENTICES AND TRAINEES. Apprentices will be permitted to work at less than the predetermined rate for the work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Bureau of Apprenticeship and Training, or with a State Apprenticeship Agency recognized by the Bureau, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Bureau of Apprenticeship and Training or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the CONTRACTOR as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage 08-1659/ 23356 28 4 rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman's hourly rate) specified in the contractor's or subcontractor's registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice's level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination. Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination. In the event the Bureau of Apprenticeship and Training, or a State Apprenticeship Agency recognized by the Bureau, withdraws approval of an apprenticeship[ program, the CONTRACTOR will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved. Trainees. Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they 08-1659/ 23356 29 are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration. The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration. Every trainee must be paid at not less than the rate specified in the approved program for the trainee's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In the event the Employment and Training Administration withdraws approval of a training program, the CONTRACTOR will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved. 08-1659/ 23356 30 45. PAYROLLS AND BASIC RECORDS. Payrolls and basic records relating thereto shall be maintained by the CONTRACTOR during the course of the work preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work (or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project). Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in Section 1(b)(2)(B) of the Davis -Bacon Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5 (a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in Section 1(b)(2)(B) of the Davis Bacon Act, the CONTRACTOR shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs. (Approved by the Office of Management and Budget under OMB Control Numbers 1215- 0140 and 1215-0017.) 08-1659/ 23356 31 The CONTRACTOR shall submit weekly for each week in which any Agreement work is performed a copy of all payrolls to HUD or its designee if the agency is a party to the Agreement, but if the agency is not such a party, the CONTRACTOR will submit the payrolls to the applicant, sponsor, or owner, as the case may be, for transmission to HUD or its designee. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under 29 CFR Part 5.5(a)(3)(i). This information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be purchased from the Superintendent of Documents (Federal Stock Number 029-005-00014-1), U.S. Government Printing Office, Washington, DC 20402. The prime CONTRACTOR is responsible for the submission of copies of payrolls by all subcontractors. (Approved by the Office of Management and Budget under OMB Control Number 1215-0149.) Each payroll submitted shall be accompanied by a "Statement of Compliance," signed by the CONTRACTOR or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the Agreement and shall certify the following: That the payroll for the payroll period contains the information required to be maintained under 29 CFR Part 5.5(a)(3)(I) and that such information is correct and complete; That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the Agreement during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions 08-1659/ 23356 32 have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in 29 CFR Part 3; That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the Agreement. The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the "Statement of Compliance" required by paragraph A.3.(ii)(b) of this section. The falsification of any of the above certifications may subject the CONTRACTOR or subcontractor to civil or criminal prosecution under Section 1001 of Title 18 and Section 231 of Title 31 of the United States Code. The CONTRACTOR or subcontractor shall make the records required under this section available for inspection, copying, or transcription by authorized representatives of HUD or its designee or the Department of Labor, and shall permit such representatives to interview employees during working hours on the job. If the CONTRACTOR or subcontractor fails to submit the required records or to make them available, HUD or its designee may, after written notice to CONTRACTOR, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR Part 5.12. 08-1659/ 23356 33 46. WITHHOLDING FOR UNPAID WAGES AND LIQUIDATED T)AMACTFC HUD or its designee shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the CONTRACTOR or subcontractor under any such contract or any other Federal contract with the same prime contract, or any other Federally -assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime CONTRACTOR such sums as may be determined to be necessary to satisfy any liabilities of such CONTRACTOR or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in subparagraph (2) of this paragraph. 47. SUBCONTRACTS. The CONTRACTOR or subcontractor shall insert in any subcontracts the clauses set forth in Section 44 of this Agreement and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in Section 44. 48. FEDERAL PARTICIPATION. The PROJECT pursuant to which the work covered by this Agreement is being executed is being assisted by the United States of America. Several Agreement provisions embodied herein are included in this Agreement in accordance with the provisions applicable to such federal assistance. As federal funds are financing all or part of this work, all of the statutes, rules and regulations promulgated by the Federal 08-1659/ 23356 34 Government and applicable to the work will apply, and CONTRACTOR agrees to comply therewith. 49. DAVIS-BACON ACT. CONTRACTOR agrees to pay and require all subcontractors to pay all employees on said PROJECT a salary or wage at least equal to the prevailing rate of per diem wage as determined by the Secretary of Labor in accordance with the Davis -Bacon Act (40 USC section 176a, et seq.) for each craft or type of worker needed to perform this Agreement. CONTRACTOR agrees to comply with all applicable federal labor standards provisions; said provisions are incorporated herein by this reference. 50. DISPUTES CONCERNING LABOR STANDARDS. Disputes arising out of the labor standards provisions of this Agreement. Such disputes shall be resolved in accordance with the with the procedures of the Department of Labor set forth in 29 CFR Parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the CONTRACTOR (or any of its subcontractors) and HUD or its designee, the U.S. Department of Labor, or the employees or their representatives. 51. CERTIFICATION OF ELIGIBILITY. By entering into this Agreement, the CONTRACTOR certifies that neither it (nor he or she) nor any person or firm who has an interest in the CONTRACTOR's firm is a person or firm ineligible to be awarded Government contracts by virtue of Section 3(a) of the Davis -Bacon Act or 29 CFR 5.12(a)(1) or to be awarded HUD contracts or participate in HUD programs pursuant to 24 CFR Part 24. 08-1659/ 23356 35 No part of this Agreement shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of Section 3(a) of the Davis -Bacon Act or 29 CFR 5.12(a)(1) or to be awarded HUD contracts or participate in HUD programs pursuant to 24 CFR Part 24. The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001. Additionally, U.S. Criminal Code, Section 1010, Title 18, U.S.C. "Federal Housing Administration transactions", provides in part "Whoever, for the purpose of...influencing in any way the action of such Administration ... makes, utters or publishes any statement, knowing the same to be false ... shall be fined not more than $5,000 or imprisoned not more than two years, or both." 52. DISCRIMINATION, MINORITIES, ALIENS. CONTRACTOR shall not discriminate nor allow its employees, agents, principals, or subcontractors to discriminate against any employee or applicant for employment on the basis of race, religious creed, national origin or sex. CONTRACTOR shall take affirmative steps to hire local qualified minority individuals when job opportunities occur and utilize local business firms when possible. 53. EQUAL EMPLOYMENT OPPORTUNITY. The CONTRACTOR will comply with all provisions of Executive Order 11246, as amended, and 29 CFR Part 30. The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements. 08-1659/ 23356 36 CONTRACTOR is required to have an affirmative action plan which declares that it does not discriminate on the basis of race, color, religion, creed, national origin, sex or age to ensure equality of opportunity in all aspects of employment. Section 503 of the Rehabilitation Act of 1973 (29 USC Section 701, et seq.) prohibits job discrimination because of handicap and requires affirmative action to employ and advance in employment qualified handicapped workers. Section 402 of the Vietnam Era Veterans Readjustment Assistance Act of 1974 (38 USC Section 219 et seq.)prohibits job discrimination and requires affirmative action to comply and advance in employment (1) qualified Vietnam veterans during the first four (4) years after their discharge and (2) qualified disabled veterans throughout their working life if they have a thirty percent (30%) or more disability. To ensure compliance with these requirements, the CONTRACTOR shall provide,the City with its written affirmative action plan prior to commencement of work. The CONTRACTOR is required to provide the CITY with a listing of its subcontractors together with a completed affirmative action program from each subcontractor when applicable. 54. COPELAND "ANTI -KICKBACK" ACT. CONTRACTOR and its subcontractors shall comply with the requirements of 29 CFR Part 3, which Act provides that each shall be prohibited from including, by any means, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he is otherwise entitled. 08-1659/ 23356 37 55. CONTRACT WORK HOURS AND SAFETY STANDARDS ACT. The CONTRACTOR shall comply with the provisions of Section 103 and 107 of the contract Work Hours and Safety Standards Act (40 USC 327 et seq.) as supplemented by Department of Labor regulations (29 CFR, part 5). Under Section 103 of the Act each CONTRACTOR shall be required to compute the wages of every mechanic and laborer on the basis of a standard workday of eight (8) hours and standard workweek of forty (40) hours. Work in excess of the standard workday or workweek is permissible provided that the worker is compensated at a rate of not less than 1-1/2 times the basic rate of pay for all hours worked in excess of eight (8) hours in any calendar day or forty (40) hours in the workweek. Section 107 of the Act is applicable to construction work and provides that no laborer or mechanic shall be required to work in surroundings or under working conditions which are unsanitary, hazardous, or dangerous to his health and safety as determined under construction, safety and health standards promulgated by the secretary of Labor. These requirements do not apply to the purchase of supplies or materials or articles ordinarily available on the open market or contracts for transportation. As used in this section, the terms "laborers" and "mechanics" include watchmen and guards. 56. IMPLEMENTATION OF CLEAN AIR ACT AND FEDERAL WATER POLLUTION CONTROL ACT. A. CONTRACTOR stipulates that all facilities to be utilized in the performance of this Agreement were not listed, on the date of contract award, on the United States Environmental protection 08-1659/ 23356 38 Agency (EPA) List of Violating Facilities, pursuant to 40 CFR 15.20. B. The CONTRACTOR agrees to comply with all of the requirements of Section 114 of the clean Air Act and section 308 of the Federal Water Pollution control Act and all regulations and guidelines listed thereunder. C. The CONTRACTOR shall promptly notify the CITY of the receipt of any communication from the Director, office of Federal Activities, EPA, indicating that a facility to be utilized pursuant to this Agreement is under consideration to be listed on the EPA List of Violating facilities. D. The CONTRACTOR agrees to include or cause to be included the requirements of paragraph (a) thorough (d) of this section in every nonexempt subcontract, and further agrees to take such action as the Government may direct as a means of enforcing such requirements. 57. ENERGY CONSERVATION. Agreements with federal participation shall recognize mandatory standards and policies relating to energy efficiency which are contained in the State energy conservation plan issued in compliance with the Energy Policy and conservation Act (42 USC Section 6201, et seq.). 58. HOUSING AND URBAN DEVELOPMENT. CONTRACTOR agrees to comply with any and all rules, regulations, guidelines, procedures and standards of the United States Department of Housing and 08-1659/ 23356 39 10 Urban Development and complete any and all reports and forms that may be required in accordance therewith. 59. SUBCONTRACTS. The CONTRACTOR or subcontractor will insert in any subcontracts the clauses contained in 29 CFR 5.5(a)(1) through (10) and such other clauses as HUD or its designee may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all the Agreement clauses in 29 CFR Part 5.5. 60. CONTRACT TERMINATION; DEBARMENT. A breach of the Agreement clauses in 29 CFR 5.5 may be grounds for termination of the Agreement, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12. 61. COMPLAINTS PROCEEDINGS, OR TESTIMONY BY EMPLOYEES. No laborer or mechanic to whom the wage, salary, or other labor standards provisions of the Contract are applicable shall be discharged or in any other manner discriminated against by the CONTRACTOR or any subcontractor because such employee has filed any complaint or instituted or caused to be instituted any proceeding or has testified or is about to testify in any proceeding under or relating to the labor standards applicable under this Contract to his employer. 08-1659/23356 .O 62. CONTRACT WORK HOURS AND SAFETY STANDARDS ACT - OVERTIME REQUIREMENTS. A. No CONTRACTOR or subcontractor contracting for any part of the Agreement work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of eight hours in any calendar day or in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate no less than one and one- half times the basic rate of pay for all hours worked in excess of eight hours in any calendar day or in excess of forty hours in such workweek, whichever is greater. B. Violation; Liability for Unpaid Wages; Liquidated Damages. In the event of any violation of the clause set forth in subparagraph (A) of this paragraph, the CONTRACTOR and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such CONTRACTOR and subcontractor shall be liable to the United States (in the case of work done under contract for the Distract of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in subparagraph (A) of this paragraph, in the sum of $10 for 08-1659/ 23356 41 W. each calendar day on which such individual was required or permitted to work in excess of eight hours or in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in subparagraph (1) of this paragraph. 63. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact, held by the signatory or is withdrawn. 64. ENTIRETY The foregoing, and Exhibit "A" attached hereto, set forth the entire Agreement between the parties. No waiver or modification of this Agreement shall be valid unless in writing duly executed by both parties. The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiations, and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements, promises, agreements or warranties, oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that parry has not executed this Agreement in reliance on any representation, inducement, 08-1659/23356 42 promise, agreement, warranty, fact or circumstance not expressly set forth in this Agreement. IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be io executed by and through their authorized officers on /'"T(�- G U S % � 0 HONDO COMPANY, INC., a California CITY OF HUNTINGTON BEACH, a corporation , /j municipal corporation of the State of California e By: Mayor Bob Lloyd A 9ftj City Clerl g By: ��� AI Bob oyd, Sec etary / Treasurer INITIAT D AND APPROVED: . - ,- �' 17 of Communi REV EWER' AAD 21 PPROVED: City Admiiistrator APPROVED AS TO FORM: City Attorney II^,V 08-1659/23356 43 COMPANY INC. March 21, 2008 Sharon Griffin Purchasing Department City of Huntington Beach 2000 Main Street Huntington Beach, CA 92648-2702 Re: Lakeview Clubhouse Improvements Dear Ms. Griffin: Engineering Contractors 2121 South Lyon Street Santa Ana, CA 92705 714/434-0104 FAX 714/434-0215 We are please to submit a quotation for the above mentioned project. Attached you will also find a listing of recently completed projects. We are currently working for your agency on the Entry Node Signs which are being overseen by Todd Broussard from your Engineering Department. We have also worked extensively for Ocean View School District doing ADA upgrades and modular building installation at several locations, one of which was Lakeview Elementary School. Hondo Company Inc. has been in business for 29 years, under the same management, specializing in public works construction. All projects are managed by either Mike Woods or me and we have a sufficient work force to accomplish this work in a timely manner. We look forward to an opportunity to work for you. Sinc y your i ��,-� i� ��s■ AZT Completed Jobs City of Irvine City of Irvine City of Mission Viejo One Civic Center Plaza One Civic Center Plaza 27204 La Paz Road Irvine, CA 92713 Irvine, CA 92713 Mission Viejo, CA 92692 Douglas Davidson Douglas Davidson Jerry Hill San Leandro Park Blue Gum Park Aurora Park 949 724-6675 949 724-6675 949 470-3064 $315,040.00 Contract $657,513.80 Contract $869,400.00 Contract $327,707.00 Completed $690,090.50 Completed $875,625.50 Completed Completed April 2007 Completed April 2007 Completed January 2007 City of Yorba Linda City of W. Covina City of Santa Fe Springs 4845 Casa Loma P. O. Box 1440 11710 Telegraph Road Yorba Linda, CA 92886 W. Covnia, CA 91793 Santa Fe Springs, CA 90670 Steve Campbell Mike Schott Harold Quan Vista Del Verde Park Monument Signs Parkette Fountain 714 961-7160 626 939-8425 562-868-0511 $980,930.27 Contract $120,900.00 Contract $199,145.00 Contract $1,051,633.00 Completed $194,955.00 Completed $207,007.00 Completed Completed May 06 Completed April 06 Completed Feb 06 City of Cypress City of Santa Fe Springs Talega Constructors 5275 Orange Avenue 11710 Telegraph Road 951 Calle Negocio #D Cypress, CA 90630 Santa Fe Springs, CA 90670 San Clemente, CA 92673 Mary Lazzara Harold Quan Brian Mangano Various Parks Heritage Crossing Fountain Recreation Center #3 716 229-6747 562 868-0511 949 498-1366 $281,810.00 Contract $351,261.40 Contract $682,214.00 Contract $288,815.00 Completed $380,326.40 Completed $734,326.20 Completed Completed June 05 Completed July 05 Completed June 05 City of Santa Ana City of Santa Fe Springs City of Lake Forest P. O. Box 1988 Dept M-22 11710 Telegraph Road 25550 Commercentre Dr. Santa Ana, CA 92702 Santa Fe Springs, CA 90670 Lake Forest, CA 92630 Michel Girgis Harold Quan Bill Seitz Santiago Park Gateway Monument Nature Park 714 647-5042 562 868-0511 949 472-3505 $284,426.00 Contract $57,260.00 Contract $702,888.17 Contract $247,5958.00 Completed $57,260.00 Completed $708,288.16 Completed Completed August 04 Completed August 04 Completed June 04 PURCHASING DEPARTMENT CITY OF HUNTINGTON BEACH 2000 MAIN STREET HUNTINGTON BEACH, CA 92648-2702 «Company» «Address» «Citystzip» «Attn» 08-0321 Show this number on outside of your envelope. Date: January 28, 2008 Bids will be received until 4:00pm March 21, 2008 at the office of the Purchasing Division. Sharon Griffin sgriffin .surfcity-hb.org QUANTITY UNIT DESCRIPTION UNIT PRICE: AMOUNT 1 LS The City of Huntington Beach is accepting uotations for the LUMP SUM 123,800.00 Lakeview Clubhouse Improvements MSC-439per the following specifications. All Labor must be based upon prevailing wage. Bid Schedule must be submitted with bid. There will be a Job Walk on Wednesday, February 6, 2008 @ 8:00 a.m. Prospective bidders will meet at the Lakeview Clubhouse, 17461 Zeider Lane, Huntington Beach. Any questions will be answered at this time. Any questions regarding the specification, exceptions or approved equals must be put in writing to the above buyer. If the bidder is responding from our Website you must notify the appropriate buyer, which is listed on the front page of the RFQ. This is to notify the bidder of any addendums that may occur during the bidding process. Quotations are requested for furnishing the items described in accordance with terms set forth herein. All quotations must be F.O.B. delivered. The detailed specifications or brand names or numbers given herein is descriptive and indicates quality and style of item required. Offer to supply articles substantially the same as those described herein will be considered provided the articles offered are equal in quality, durability, and fitness for the purpose intended. Acceptability of alternates will be determined solely by the City of Huntington Beach Delivery to be made on or before: 4:00 p m or -- days from receipt of order. Address you reply to: Purchasing Division City of Huntington Beach 2000 Main Street Huntington Beach CA 92648-2702 (714)536-5221 All quotatio �s/ us a signed -i natur Hondo q10 pany nc. Robert 'Lloyd Print Name Title Sec/Treasurer Date 3-21-08 Phone Number 714 434-0104 THIS IS' NOT AN ORDER Total $123 , 800.00 SalesTax included Total $123 , 800.00 Terms net % 30 days Email: hondoco@gmail.com EMAIL AND FAXED BIDS ARE NOT ACCEPTED Addendums 1 — 4 are acknowledged PURCHASING DEPARTMENT «RFQ» CITY OF HUNTINGTON BEACH QUOTATION NUMBER 2000 MAIN STREET HUNTINGTON BEACH, CA 92648-2702 VENDOR NAME «Company» REQUEST FOR QUOTATION QUANTITY I UNIT DESCRIPTION UNIT PRICE AMOUNT Page 2 Appendix I Bid Schedule 1. 1 L.S. Furnish and Install All Restroom Appurtenances (Include Door Widening) Thirty Four Thousand --- Atone Hundred DollarPerL.S. 34,100.00. 2. 1 L.S. Furnish and Install All Kitchen Appurtenances Sixteen Thousand.Eight --- At Hundred Dollars Per L.S. 16,800.00 3. 1 L.S. Furnish and Install Facets Relevant to the Raised Floor Twenty Eight Thousand Two --- At Hundred Dollars Per L.S. 28,200.00 4. 1 L.S. Furnish and Install All Handrails/Guardrails Seven Thousand Eight At Hundred Dollars Per L.S. --- 7,800.00 5. 1 L.S. Furnish and Install All Concrete Areas (Include Reapirs to Landscaping) Thirty Four Thousand Four At Hundred Dollars Per L.S. -'- 34,400.00 6. 1 L.S. Furnish and Install Signage and Markings for Accessibility Two Thousand Five At Hundred Dollars Per L.S. --- 2,500.00 CITY OF HUNTINGTON BEACH Finance Department Central Services Division February 6, 2008 Dan T. Villella, CPA Finance Director This is an addendum to Bid #08-0220, Lakeview Clubhouse Improvements, MSC-439, which is follow-up from the job walk on 2/6/08. There will be testing of asbestos and if found the removal will not be included in the bid. This will be done prior to the improvements. Sharon Griffin/Buyer 714/960-8878 2000 Main Street, California 92648-2702,6 Phone 714-536-52210, Fax 714-374-1530* www.surfcity-hb.org CITY OF HUNTINGTON BEACH Finance Department Central Services Division February 12, 2008 Dan T. Villella, CPA Finance Director This is addendum #2 to Bid #08-0220, Lakeview Clubhouse Improvements, MSC-439, which is to extend the bid due date to March 5, 2008 Change all bid documents to Bid #08-0305. Sharon Griffin/Buyer 714/960-8878 2000 Main Street, California 92648-2702* Phone 714-536-5221* Fax 714-374-1530+ www.surfcity-hb.org CITY OF HUNTINGTON BEACH Finance Department Central Services Division February 27, 2008 Dan T. Villella, crA Finance Director This is addendum #3 to Bid #08-0305, Lakeview Clubhouse Improvements, MSC-439, which is to extend Bid to: March 21, 2008. Change all documents to Bid #08-0321. This is due to changes in the bid, which we have not finalized. There will be another addendum to follow. Sharon Griffin/Buyer 714/960-8878 2000 Main Street, California 92648-27024 Phone 714-536-5221* Fax 714-374-1530* www.surfcity-hb.org CITY OF HUNTINGTON BEACH Finance Department Central Services Division March 7, 2008 Dan T. Villella, CPA Finance Director This is Addendum #4 to Bid #08-0321, Lake View Clubhouse Improvements. These attachments are plan revisions and summary of changes. The engineer's estimate is $91000.00 Sharon Griffin/Buyer 714/960-8878 2000 Main Street, California 92648-2702* Phone 714-536-5221+Fax 714-374-1530* www.surfcity-hb.org CITY OF HUNTINGTON BEACH INSTRUCTION TO BIDDERS If the bidder is responding from our Website you must notify the appropriate buyer, which is listed on the front page of the RFQ. This is to notify the bidder of any addendums that may occur during the bidding process. ALL PAGES OF THE BID MUST BE RETURNED EXAMINATION OF BID Each bidder is responsible for examining the invitation to bid and submitting its bid complete and in conformance with these instructions. DISCREPANCIES IN BID DOCUMENTS Should bidder find discrepancies in, or omissions from the invitation to bid, or if the intent of the invitation is not clear, and if provisions of the specifications restrict bidder from bidding, they may request in writing that the deficiency(s) be modified. Such request must be received by the City's Central Service Manager five (5) days before bid opening date. All bidders will be notified by addendum of any approved changes in the invitation to bid documents. ORAL STATEMENTS The City of Huntington is not responsible for oral statements made by any of their employees or agents concerning this invitation to bid. If the bidder required specific information, bidder must request that it be supplied in writing by the City of Huntington Beach. BRAND NAMES AND SPECIFICATIONS The detailed specifications and/or brand names stated are descriptive only and indicate quality, design, and construction of items required. Offers will be considered to supply articles substantially the same as those described herein provided the articles are equal in quality, durability, and fitness from the variation in the bid. Acceptability of alternate will be determined solely by the City of Huntington Beach. Bidder must submit specifications when bidding alternative equipment. RIGHT TO REJECT City reserves the right to reject at any time any or all bids, or parts thereof, and to waive any variances, technicalities and informalities which do not impair the quality, utility, durability, or performance of the items. SAMPLES Samples if items, when requested or required, must be furnished to the city free of expense to the city and, if not destroyed by tests will, upon request, be returned at the bidder's expense. PRICES Individual item pricing must be shown for each line item. In case of error in extension of prices, unit price will govern. All prices must be firm for the contract term unless the city specifically provides for adjustment. All quotations must be FOB delivered. FORM OF BID AND SIGNATURE The bid must be made on this form only. Bid should be enclosed in a sealed envelope, showing the Request for Quotation Number in the lower left corner, and addressed to the City of Huntington Beach, 2000 Main street, Huntington Beach CA 92648-2702 , Attn: Purchasing. This bid must be signed by an officer or authorized employee. Bids may be rejected if this form is not signed. SUBMISSION DATE AND WITHDRAWAL OF BIDS Each bid must be delivered to the location and received on or before the due date and time stated. Bids may be withdrawn without prejudice, providing the Central Service Division receives the written request no later than the time set for opening bids. Withdrawals will be returned to bidder unopened. FAXED BID IS NOT ACCEPTABLE. AWARD OF CONTRACT The City reserves the right to award this Contract by item or in its entirety, whichever is in the best interest of the City Insurance Requirements/Encroachment Permit Applicants and Contractual Services quErerr�rtsdtd�ouy4ruar gent ' i y City Resolution 2001-065 requires that licensees, lessees and vendors have an approved Certificate of Insurance (not a declaration, policy or statement) on file with the City for the issuance of any permit or city contract. Simple receipt of an insurance certificate is not sufficient. The insurance certificate must be approved by the City Attorney's Office as to meeting all of the city's insurance requirements. Please be aware that part of the insurance requirement, the Additional Insured Endorsement Page (required for both the General Liability and the Automotive Insurance Policies), can take as much as a week or two to obtain. In addition, the typical insurance approval process varies from several days or more so it is strongly recommended that you have certificate(s) submitted at least one or two weeks prior to your scheduled needs. An original certificate is required or a PDF version attached to an email may be forwarded. If the insurance certificate is fax'd, it must come directly from the insurance provider to the City (not from the Insured) to ensure its validity. ➢ Private Property Work Permit Requirements. —If the planned work does not involve public property or its right-of-way (e.g., sidewalk/street or abutment to same),, the Workers' Compensation Certificate is the only insurance requirement. However, if the work site is adjacent or attached to public property, the City Attorney's Office must be informed for consideration of liability and decides whether or not to approve the certificate with a specific Private Property Only approval stamp. ➢ Encroachment (City/Public Property) Permit Requirements. —General Liability, Automotive and Workers' Compensation are required (see General Liability Insurance Certificate below). ➢ Consultant Services. ---Professional Liability Insurance Certificate is required (i.e., Legal, architectural, etc.) in addition to a General Liability Insurance Certificate and Workers' Compensation Insurance Certificate. ➢ General Liability (GL) Insurance Certificate of 2$1,000,000 combined single limit/per occurrence An Additional Insured Endorsement Page is required bearing both the GLs policy number and specifically naming the City of Huntington Beach, its agents, officers and employees as additionally insured and, when applicable, the Redevelopment Agency of the City of Huntington Beach must also be named as additionally insured. Per the resolution, the insured definition must read as "the insured is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of "your work" for that insured by or for you." It is not to read, "...but only with respect to liability arising out of your ongoing operations performed for that insured." Type of coverage must be "per occurrence" not "claims made". "Claims made" designation is only acceptable for professional or pollution liability insurance. Waiver Information. —The following information is required for completion of the City's internal insurance waiver form: A brief description of work and/or nature of business, timeframe for completion and dollar value. The exception to the waiver process is the General Liability's and Automotive's Additional Insured Endorsement Pages which cannot be waived. For substantial deductibles and/or SIRs a financial statement (e.g., Brad & Dunstreet, etc.) is required as part of the insurance waiver process. ➢ Workers' Compensation Insurance Certificate of statutory amount is required. If you have no employees, you must sign a Declaration of Non -employee Status form in lieu of a certificate of insurance or provide a certificate of Consent to Self -Insure issued by the California Director of Industrial Relations. Page 4 ➢ Professional Liability Insurance Certificate of >_of $1,000,000 (applicable for professional services) Type of coverage "Claims Made" designation is acceptable for professional or pollution liability insurance. In addition to the above, ALL certificates must contain the following: Insurance Carrier Rating. —Insurance must be placed with a California -admitted carrier with a current A.M. Best Rating of >_ A: VII. If this is not possible an insurance waiver is required. Certificate Holder. --The City of Huntington Beach (2000 Main Street, Huntington Beach, CA 92648, Attn: Risk Management). Deductible, Self -Insurance Retention (SIR), --The city maintains a zero deductible/SIR requirement. Any deductibles/SIRs in force must be listed on the certificate. In the event of any deductible/SIR, the city has an insurance waiver procedure to request a waiver of the zero deductible requirement (see Waiver Procedure below). Cancellation Clause Notice. --There must be a thirty (30) day notice for policy cancellation. A ten (10) day notice for cancellation for non-payment of premiums and/or salary reporting is acceptable in combination with the required 30-day notice. Waiver Procedure. —In lieu of meeting the City's insurance requirements, the insured can request a waiver of a specific requirement. To do so, the insured must provide the City with a brief description of the work/project (one to two sentences), the timeframe for completion and the dollar value of the work/project. (not cost but value to the Insured). For a substantial dollar deductible/SIR, a financial statement (e.g., Dunn & Bradstreet, etc.) is required for the approval process. Upon receipt of this information, the City's internal waiver form should be completed and attached to the insurance certificate and submitted for approval to the pertinent City Department Head, the Risk Manager and the City Attorney. The approval process can take from one (1) day in a best case scenario to seven working days for completion. ➢ General Contractor/Sub-contractor(s).—Both the general- and their sub -contractors must provide proof of insurance subject to the City's insurance requirements. Please forward these requirements to your insurance agent/producer for their processing of your insurance certificates. Page 5 City of Huntington Beach REQUEST FOR QUOTATION Community Services PROJECT # & TITLE: MSC-439 Lakeview Clubhouse Improvements TABLE OF CONTENTS INSTRUCTIONS TO BIDDERS 1.01 General 1.02 RFQ Schedule 1.03 Scope of Work 1.04 Contractor Qualification Requirement 1.05 Form of Guarantee -Warranty 1.06 Codes, Rules, Ordinances & Approvals 1.07 Protection of Work and Property 1.08 Security Regulations, Tools/Equipment control & Vendor Conduct 1.09 Notice to Proceed 1.10 Time of Completion 1.11 Liquidated Damages 1.12 Payment 1.13 Salvage and Disposal 1.14 Wage Rates 1.15 Bonds 1.16 Insurance Appendix I — Project Bid Schedule Appendix II — Location Map Appendix III — Insurance Requirements Appendix IV — Payment and Performance Bond Forms INSTRUCTIONS TO BIDDERS 1.01 General These instructions are to BIDDERS for the complete project known as: MSC-439 Lakeview Clubhouse Improvements. The project will be submitted in strict accordance with the specifications as prepared by the City of Huntington Beach and procedures set forth by the Department of Community Services. The amount of each RFQ shall be deemed to include the entire cost and expense of every item of labor and material necessary to complete the work bid upon, as specified, in full detail, ready for use. The successful bidder shall assume the risk of all such costs and expenses. It is the intent of the specifications to call for finished work, tested, and ready for operation. Any incidental accessory necessary to make the work complete in all respects and ready for operation, even if not particularly specified, shall be provided without extra compensation. Minor products or items of work, which by custom are not usually shown or specified, but are necessary for proper installation and operation of the completed work, shall be provided in the same manner as if actually shown or specified. During construction, there may be delays due to various reasons. These needs are to be taken into consideration in your submittal of the RFQ. The department of Community Services will not authorize extra compensation for these delays. The department will assign a representative to work with the selected contractor as liaison. City Representative(s): Dave Dominguez Title: Project Manager Purchasing Representative(s): Name: Sharon Griffin Title: Buyer Tel. # (714) 960-8878 Fax # (714) 374-1530 1.02 RFQ Schedule (Appendix I to be submitted with bid) The project shall be bid as per specifications for the complete project. A. Labor shall be separated from the equipment and the dollar amount totaled separately, which will be prevailing wage. B. Prices should be extended in decimal, not fraction, to be net, and shall include transportation and delivery charges fully prepaid by the Contractor to the destination specified in the RFQ, and subject only to cash discount. C. Addendum's should be priced out separate from Base RFQ. 1.03 Scope of Work Removal of interior non -bearing walls, double floor and plumbing fixtures and cabinets (see details provided on plans). Construction of interior non -bearing walls, cabinets and exterior ramp, steps and porches (see details provided on plans). 1.04 Contractor Qualification Requirement The contractor shall demonstrate capability to execute this contract by submitting evidence of the following: 1. Ability to perform the contractual services as reflected by technical training and education; general experience, and specific experience in providing the required supplies, materials, equipment or contractual services; and the qualifications and abilities of personnel proposed to be assigned to perform the contractual services; the personnel, equipment, and facilities to perform the contractual services currently available or demonstrated to be made available at the time of contracting; and, a record of past performance of similar work in regard to supplies, materials, equipment or contractual services. 2. It is the responsibility of the contractor to secure all licenses, permits, approvals, or other documents necessary to complete this project. 3. Listing of at least three projects of similar scope and size that were performed within the last twelve months. Include the name, address and telephone number of a contact at each job that can be contacted and who is familiar with the project. 4. The Contractor shall use only skilled workmen who are trained and experienced in the necessary crafts and familiar with the specifications and methods needed to properly perform the work required by this project. 1.05 Form of Guarantee — Warranty All work shall be covered by the standard one (1) year guarantee from the date of substantial completion, and the material per the manufacturer's warranty. The Contractor shall furnish to the City Representative the foregoing documents in the following manner: Name and number of project I (We) hereby guarantee (or warranty) the referenced project for a period of years from to work on the against failures of workmanship and/or materials in accordance with the specification. All guarantees supplied by subcontractors, suppliers or manufacturers will be counter signed by the General Contractor. The contractor shall remove any and all defective work and replace with material that meets specification requirements. 1.06 Codes, Rules, Ordinances & Approvals 1. All materials furnished and all work installed shall comply with all the latest, at the time of construction, applicable State and Local codes, laws and ordinances, rules and regulations. 2. It is the intention that the specifications not violate any of the above. Where violations occur, such codes, laws, rules, ordinances, regulations and recommendations shall be complied with. The Contractor must call any and all such violations to the attention of the Street and Facility Supervisor before making any changes to the specifications or proceeding with work. 3. The Contractor shall at his expense give all notices, obtain all permits (permit cost are paid by the City), licenses and approvals; pay all government taxes, fees and other costs in connection with the work; and obtain all required certificates of inspection for the work and deliver same to the Street and Facility Supervisor before requesting acceptance and final payment. All apparatus, equipment and construction shall comply with the recommendations of the Cal -OSHA and approved revisions. 1.07 Protection of Work and Property Use of Premises: 1. Nothing contained in the specifications shall be interpreted as giving the contractor exclusive use of the premises where the work is to be performed. 2. The contractor shall be held solely responsible for any and all damage to the existing structures; systems, equipment and site caused by him or his employees and shall repair or replace it to their original condition as directed at no additional cost to the Agency. The work in this contract shall not interfere with the normal conditions and safe operation of the Facility and if such interference appears possible because of new connections to existing work or other reasons, the work involved must be done at a time and in a manner directed by the Facility as a part of the contract. 3. All building equipment, furnishings, grounds landscaping, etc., shall be protected from damage of every description and any such damage thereto shall be repaired or otherwise made good at no expense to the City and to the satisfaction of the Facility Representative. 4. The contractor shall supply and install any and all protective coverings and barricades necessary to protect at all times the public and building personnel and the building from injury. The contractor shall provide and install all plastic sheeting, batten cleats and other materials, which he may require to protect all open, unfinished work at the end of each and every day. 5. The contractor shall be held responsible for, and must make good at his own expense, any water damage or any other cause of damage due to improper protection. 6. Due to the nature of this facility, it is mandatory that all rules and regulations are strictly adhered to and the necessary precautions taken. 7. The contractor shall, during the progress of the construction, assume all responsibilities for loss or damage by fire to the work included in his contract until completion of the contract. No flammable material shall be stored in the structure in excess of the amounts allowed by the authorities. 8. The contractor is responsible to assure that all work is performed in accordance with all current State regulations including, but not limited to, OSHA, State Fire Codes, 2001 California Building Code and all Huntington Beach Codes. 9. The contractor will at all times keep the premises free from the accumulation of waste materials or rubbish caused by his employees or work. All accumulated material shall be removed from the site daily at the contractor's expense. 10. Work completed when Staff is offsite — Contractor is responsible for the security of the facility. All entrances accessed by the contractor after hours shall be secured after each form of egress. Internal Construction Activities - Any or all of the following measures may be used depending on the scope of the project: a. Construct barriers to prevent dust from construction areas from entering patient -care areas. Barriers must be impermeable to fungal spores and in compliance with local fire codes. b. Seal off and block return air vents if rigid barriers are used for containment. c. Implement dust control measures on surfaces and divert pedestrian traffic away from work zones. d. If necessary, create negative air pressure in work zones adjacent to work space areas and insure that required engineering controls are maintained. Monitor negative airflow. e. Monitor barriers and insure integrity of it. Repair gaps or breaks in barrier joints. f. If practical, seal windows in work zones. g. Direct pedestrian traffic away from construction zones. h. Provide construction crews with: Designated entrances, corridors and elevators if possible, essential services (e.g., bathroom facilities) and a space for changing clothing and storing equipment. i. Contractor shall clean work zones and their entrances daily. j. Contractor shall cover and secure debris prior to removal from the construction area. k. For major repairs that include removal of walls and disruption of the space within, the contractor shall use plastic sheets or prefabricated plastic units to contain dust and a HEPA (High Efficiency Particulate Air) filter machine to clean the air. I. Upon completion of the project, contractor shall clean the work zone according to facility procedures, prior to removing the construction barriers. m. Due to the nature of this Facility, it is required that all rules and regulations be strictly adhered to and the Facility's schedule must be maintained. The contractor shall keep the City's representative informed as to location and hours of operations so that necessary precautions can be taken if needed. Fire Protection: A) The contractor shall, during the progress of construction, assume all responsibilities for loss or damage by fire to the work included in his contract until completion of the contract. No flammable material shall be stored in the structure in excess of amounts allowed by the authorities. No gasoline shall be stored in or close to any building at any time. B) The contractor shall not, at any time, for any reason, or by any means, block, impede or inhibit the free flow of egress for example hallway and exit doors. C) The Contractor shall ensure free and unobstructed access to emergency services and for fire, police, and other emergency forces. D) The contractor shall ensure that additional fire -fighting equipment and trained personnel are on site as required by OSHA and other regulatory authorities. E) The Contractor shall prohibit his employees from smoking in the buildings, or in the areas adjacent to construction areas. F) The Contractor shall develop and enforce storage, housekeeping, and debris removal practices that reduce the building's flammable and combustible fire load to the lowest feasible level. G) The Contractor shall provide and maintain his own independent portable toilet accommodations (unless approved otherwise). H) The contractor shall supply to the agency a copy of all Material Safety Data Sheets (MSDS) for all products used in the process of construction, construction materials and products brought onto the premises. 1) The Contractor shall secure and his unfinished work areas at the close of business each day to preclude passage by any and all unauthorized persons. 1.08 Security Regulations Tools/Equipment Control & Vendor Conduct The following regulations and guidelines are "general" in nature and vendor(s) may be subject to more restrictive regulations and guidelines while performing work in any one of the facilities. TOOLS: All tools are to be accounted for at all times. At NO time shall tools or equipment be left unattended. At the end of the day, tools left behind MUST be secured with a padlock. EMPLOYEE CONTACT: Contractors shall NOT have any contact with employees, exception to be employees that are involved with the work to be performed. WEAPONS & ILLEGAL SUBSTANCES: NO Weapons, Alcohol, or Drugs shall be brought onto facility and smoking provisions should comply with California Government Code Sections 7596-7598 (within 20 feet of entrances, exits and operable windows). SAFETY: All injuries shall be immediately reported to the work crew supervisor and City representative. All workers shall remove ignition keys and lock their vehicles. No parking in fire lanes. Egresses cannot be blocked. No disruption to fire alarm/fire suppression systems without prior notification/approval. The integrity of the building cannot be tampered with. 1.09 Notice to Proceed The contractor shall not start work until he has a fully executed approved purchase order. Within five (5) working days after receipt of the purchase order and prior to the start of construction, the City shall schedule a pre -construction meeting with the contractor and at that time a start date will be established. Following the receipt of Notice to Proceed, (receipt of Purchase Order) the contractor shall begin construction within ten (10) working days. Working days shall be considered as Monday through Friday. The Contractor shall upon request by the City representative, certify, by providing a written list of not less than five (5) references, that he has a minimum of five (5) years of continuous experience in the type of preparation and application required by this project. The Contractor shall, upon request by the City representative, certify, in writing that his shop and personnel have the capabilities to install and connect all items required to complete this assembly expeditiously and on time. Failure to start construction by 8:00 a.m. on the morning of the eleventh working day following the receipt of Notice to Proceed, (receipt of Purchase Order) shall be considered as approval for the City to cancel the purchase order and award such work to the next succeeding low proposer. The original low bidder being assessed the monetary difference between the lowest and second lowest bidder for the total contract amount. 1.10 Time of Completion The project will be completed within 40 working days. For all Phases Working days for this project shall be Monday through Friday from 7:OOA.M. to 5:00 P.M., exclusive of City observed Holidays. No Saturday or Sunday work will be allowed without special written permission. Once on site, the contractor's work force shall remain mobilized until work is completed unless otherwise is specifically approved by the facility representative. Upon completion of the contract, the contractor shall make a request in writing to the City representative for an inspection of the work. The Contractor shall provide safe access to the work for use by the City representative for an inspection of the work with the contractor's representative. 1.11 Liquidated Damages It is hereby declared and agreed by and between the contractor and the owner that the date of commencement, rate of progress, and time of completion of the work are essential provisions, conditions and that it would be impracticable and impossible to determine and ascertain the actual damages the owners would incur by reason of a delay in the completion of the work. It is, therefore, covenanted and agreed by and between the contractor and owner that the contractor shall and does hereby agree to pay the owner as liquidated damages (and not as a penalty) the sum of five hundred dollars ($500.00) for each and every working day that the contractor shall be in default, hereunder for failing to complete the project on the date specified above except as such date shall be extended, in writing upon request of the contractor, for the period of an excusable delay. Any such payments due to the owner by the contractor may be deducted by the owner from any sums due to the contractor. 1.12 Payment Payment will be processed as follows: 1. Projects under $25,000 - A single invoice submitted by the prime contractor following the acceptance of the completed project. 2. Projects $25,000 or greater — 30 day progress payments will be utilized. It is the agency's prerogative to retain 10% of the final payment for a period up to 90 days to insure the final completion and functionality of installed components and systems. 3. Payment terms Net. 30. Special payment incentive discounts may be offered. 4. The invoice shall contain the City Purchase Order number. Invoices received without reference to a valid City Purchase Order number will result in delay of payment. 1.13 Salvage and Disposal 1. All removed materials that are salvageable (copper or lead) are the property of the City and shall be delivered to and accepted by the City representative at a time mutually agreeable to the contractor and the City representative. 2. All debris resulting from the performance of this contract will be the property of the contractor and shall be completely picked -up and containerized at the building site not less frequent than at the close of business daily. 3. The Contractor for this project shall provide the dumpster to receive all debris generated as a by-product of the work called for herein. The Contractor shall cover the dumpster at the close of business each and every day. 4. If the Contractor encounters hazardous materials during the course of commencement of the scope of work the Contractor will contact the City representative before any removal process takes place. 1.14 Wage Rates This is a Davis -Bacon project and the Federal Regulations will be enforced. Any contract entered into pursuant to this notice will incorporate the provisions of the Federal Labor Standards, which are on file at the office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648. 1.15 Bonds (Appendix IV) Bonds must be provided on City approved forms (see Appendix IV) In conformance with the State of California Government Code, Chapter 13, Section 4590, the Contractor may substitute securities for any monies withheld by the City to endurance under the contract. At the request and expense of the Contractor, securities equivalent to the amount withheld shall be deposited with the AGENCY, or with a state or federally chartered bank as the escrow agent, who shall pay such monies to the Contractor upon notification by AGENCY of Contractor's satisfactory completion of the contract. The type of securities deposited and the method of release shall be approved by the AGENCY. 1.16 Insurance See Appendix III BLKG. BLOCKING Mi METAL B.O.P BOTTOM OF PIPE N.I.C. NOT IN CONTRACT BUT, BOTTOM NO. NUMBER CBC CALIF. BLDG, CODE / NUMBER CONC. CONCRETE (N) NEW CONT. CONTINUOUS 0/ OVER COL COLUMN O.C. ON CENTER CLR. CLEAR OPNC, OPENING CLG. CERING OPP• OPPOSITE CORR. CORRIDOR PLUS PLACES • DECREES E PLATE A DIAMETER 3 PLUS OR MINUS DWG DRAWING REQ'D REWIRED DET. DETAIL SIM SIMILAR DI A. DIAMETER S0. SQUARE ON. DOWN SUSP. SUSPENDED D.S. DOWN SPOUT SIL STEEL ELECT, ELECTRICAL SIRUC, STRUCTURAL 05T'G EX. EXISTING STOP, S70RACE EXIST. EXISTING SH, SHEET (L7 EXISTING TM. TYPICAL EA. EACH THK. THICK EXP. EXPANSION U80 UNIFORM BLDG. CODE FRY. FINISH U.N.O. UNLESS NOTED FL F LOCR OTHERWISE F.D. FACE OF VERT. VERTICAL GA. CAGE W.W.M. WELDED WIRE MESH GYP. GYPSUM W/ WITH HM HOLLOW METAL W/O WITHOUT HR. HOUR W WIDE HT. HEIGHT WD WIND HOWR HARDWARE ma WINDOW REVISIONS TOTAL OFFICE AREA BOB Sr. I CONSULTANTS I ARCHITECT, CASH A: ASSOCIATES STRUCTURAL ENG9R, 5772 BOLSA AWE., 100 CIML ENOR: HUNTINGTON BGA(2L CA 02540 CONTACT: DAVID BACNLE, A.I.A. (714)895-2072 SYMBOLS 01 KEY NOTES O ASSEMBLY NOTES O DOM SYM80. O WINDOW SYMOOL IFO-01 ROOM NUMBER ' /�---- DETAIL N0. SH7. ON W,iICH DETAIL IS SHOWN SECTION (SEE ALSO DETAIL ABOVE) SEPARATE PERMITS MECHANICAL PLUMBING ELECTRICAL um - BONS A^ SW IW Nu+Abbn TNatli, (:A pL10.1tM Ttl: R1a)D082W2 Cash & Associates RFIM VICINITY MAP TITLE SHEET :CT NUMBER 6378.05 NO NUMBER T-1 BLICG. BLOCKING MTL METAL B.O.P BOTTOM OF PIPE N.I.C. NOT IN CONTRACT BIT. BOTTOM N0. NUMBER CBC CALIF. BLDG. WOE / NUMBER CONC. CONCRETE (N) NEW CONT CONTINUOUS 0/ OVER COL COLUMN O.C. ON CENTER CIF. CLEAR OPNG. OPENING CLG. CEILING Opp. OPPOSITE CORR. CORRIDOR PLCIS, PLACES • OEGREES E PLATE p DIAMETER 1 PLUS OR MINUS OWG. DRAWING REQ'D REWIRED DET. DETAIL SIM SIMILAR DIA. DIAMETER SO. SQUARE DN. DOWN SUSP, SUSPENDED D.S. DOWI SPOUT STL. STEEL ELECT. ELECTRICAL STRUC. STRUCTURAL EXISM EXISTING STOR, STORAGE EXIST. EXISTING SH, SHEET (E) EXISTING TP. TYPICAL EA. EACH INK. THICK op. EXPANSION UBC UNIFORM BIDG CODE FK FINISH UXO, UNLESS NOTED FL FLOOR OTHERWISE F.O. FACE OF .1 VERTICAL GA. GAGE W.W.M. WEIDED WIRE MESH OYP. GYPSUM W/ WDH HM HOLLOW METAL W/O WITHOUT HR. HOUR W WIDE HT HEIGHT WD WOOD HDWR HARDWARE WDO. WINDOW REVISIONS TOTAL OFFICE AREA 806 S.F. I CONSULTANTS I ARCHITECT, CASH k ASSOCIATES STRUCTURAL ENGR, 5772 BOISA AVE., SUITE 100 COAL ENO L- HUNTINGTON BEACH, CA 92649 CONTACT: DAVID BACHE, A.I.A. (714)895-2072 SYMBOLS ❑1 KEY NOTES O ASSEMBLY NOTES O DOOR SYMBOL O WINDOW SYMBOL T00 ROOM NUMBER DETAIL NO. A SHT. ON WHICH DETAIL 15 SHOWN 2 A-3 SECTION (SEE ALSO DETAIL ABOVE) cEPARAIE PERMITS MECHANICAL PLUMBING ELECTRICAL "ftwI 'h OA Rffi1"m m(T14)BA620T2 Cash & Associates >:«:D1.," VICINITY MAP N.T.S. VIEW COMMUNITY scALE 17461 ZEIDEIt tALIE NONE HUNTINGION BEACH, CA PROJECT NUMBER 6J78.05 TITLE SHEET ORAWNC NUMBER T-1 g p WEE lie Si �IN e a Off? a d gal a� a mar �g all 9gg IR m 9 a e WN !Ell Ile lip Ijig g +a N a y $ 7 S y� T� F �R I s M11 It gig D. MSCEIA A WiEMVR FAOME Rm PATCHING COPOUTA Be me VANVOCRING1 MR THE OBIDIIDNS OF IAA � RND LIKE REVISIONS E. uwun A>yunlwce A PROVIDE PRIMERS AND OTHER UNDERCOAT PANT pR000CE0 By SAMAPPROYm BY PAINT ~ACTURER AND II= ONLY WITHIN REDOMNENOED LIMITS 6. OELIAM. STORAGE AND I-MAMID A oarAR ILL wmALs TO THE SITE M THE MANUFACTURER$ ORIGINAL CONTAINERS WITH LABELS INTACT AND SFAS UNBRWiEN. IL STORE MAIEIR IJ IN A LOCKED, WELL-AENIMAFD ROOM OR SHEM C. COMPLY WITH HW]11 , FlRE REGAATIONS, AND BEST MANAGEMENT PRACNCEs (BMW). 7. MANWACTURERS B. NOUN BARDS D. SHERWIN WEIAMS E BENNEMN-MODRE OTHER MANUFACTURERS WITH PROOLam EQUAL IN ALL PEREDIOEIW(>E. A'PRMIED BP TIE ENWNEE�N.pMENSIONAL ASIAM SMALL ESE Ch4N 7�0 AN6 THOSE W}MT�CIURERS THAT *J E MAMIFACNWAG FIL'RIIIES MYIIOI SOD MILS OF THE PRQRLT SITE 0. WTE78W9 A MATERIALS SELECTED FOR CWM SYSTEMS FOR EACH TYPE SMACK STALL BE DE PROD= OF A SBDTE NAHUFICTURIDL 0. FINISH COAIS SHALL NOT BE TRIMMED. C. IA( MA9U OF AM.' ABILITY OF wT ED .SEED (a� CONCERNING SAIISFACEORILY PROWCE THE WORN) WBL Nor IE ENtFRfANED. T E.SS SUCH CLAM S 4ME M 1D 10 1HE DWNFR BffCRE THE waRN Ns STARiFD. L DO NOT APPLY PAPA OR RAUSH VNBL CONDITIONS ARE SVEFACTORY.. C. COUMENCEIffNr OF WSTAUXIVIN CONSTRUED AS ACCEPTANCE OF SURFACES II. PREPARATION A PPOIFCIDNT 1. PROTECT ALL SURFACES NOT TD BE PA CA PREVIOUSLY PAINTED FROM THE DAMAGE DURDIO 111E PANE APPLICATION. LAPPUDATOR WEL BE RESPONSIBLE FOR THE REPAIRAND/CR AP RE AN REPLACEMENT OF Y WORN DAMAGED DURING THE PARR 0. UWACE PREPARATWNI 1• SAND SUOUGH AND EL SFTCnED. HOLM SPM AND SC TCHS SPALLBEPR AND SPACKLEO � SEMLL B� FGCTTPROAT, THE AWE Y� APPIGMAIM AS THE REMAINDER or ne SURFACE EsPAINT THMAG MATERIALS y SMALL ��NTIO�RE9M�NSRILACCORDANCE WITH SREDOMMENDAMOM TO PROMISE FINISHED MM R SAGS. WRINKLES. WORM MWAKS AND SWMI MAW. 12. APPLCATION A APPUCAION OF PAW SYSTEMS SWILL BE IN SnWr ACCORDANCE WIN MANIZACIYWA'S RECOMMENDATIONS AND W COWIM B. PROAOE RNSH COATS COMPATIBLE WITH PRIME PAINTS USED, 51728oMAAw,9W 100 HIIMMWA WGA CA D]I/>11M T.ERiN) AA620R Cash & Associates GENERAL. NOTES 1 637a 05 1 a SPI saDl�le �1 _o 2 DIRECTIONAL SIGNAGE DETAIL SP1 SOLO NONE NOTE; PROVIDE CONCRETE FOOTING AS REOIARED FOR SECURE AND PERMANENT INSTALLATION PER CONCRETE FOOTINC DETAIL 7 ' SIGNS MILL BE LOCATED IN LANDSCAPED MID PAVED AREAS CORING IN PAVED AREAS MAY BE REQUIRED. CONTRACTOR SHALL FlELD SURVEY LOCATIONS .NSTECTSIGN b I1B' ALUMINUM PANEL. � FlNISH BLUE, BOTH OF COPY & SIGN - FRONT AND BACK ,� PONDER-COA FL*w' RESTRICTED SIGNAGE SYMBOL & GOPY i '°I �r HELVETICA CONDENSED BOLD F «SWW TCHCAL ELECTROT FILM. N SEE e WHITE TYPICAL. ALL COPY r '^ wMl�tir cqp� .. IT TREMPOR 6 f 7M 1 Y,7N71! 5 0.0.P�h, �� �OMMIKS L ADIU( CORNERS PONDER -COATED BLUE I POST CAP LEFIERS 'FIN. GRADE Lu ELEVATION . DETAIL 4\ DETAIL 5 SIGNAGE POST DETAIL NOTES 8 N RESTRICTED PARKING SIGNAGE h SPt WIlk NONE SP1 SGIE NONE 9>I XRE:NGNE V1 SME-NONE 6mva p.,eW Iw umIAn6bbn ENGINEER RS LAKE VIEW COMMUNITYDESI 17" DER LANE CITY OF HUNTINCTON BEACH, CA °ALE CUE ORB ppgECT NUMBER lwd�CA OTANc11N TcCM4))0061man NTJ78.0.5 Q CAD OPERA- RNM A t T ISSUED FOR BID B ' Cash & Associates SITE PLAN & DETAILS DRAWING NUMBER NIIECKER RHM Q DATE DEsawTbN er a SP-1 REVISIONS PRO.ECT MANAGER RHM 16 PROVIDE 4' WDE BLUE STRIPING O S—O' O.C. WITHIN OUTLINED ACCESS IN PARKING AREAS AND SIGNAGE O EXISTING PARKING FOR VAN ACCESSIBLE STALL —SEE I/A5. 18 PROVIDE RESTRICTED PARKING %GNAGE AT ENTRANCE TO PARKING —SEE SHT. SPI tT PROVIDE 4' CONC. WALK W/ 8' THICKENED SLAB EDGES h MEDKUM BROOM FINISH. SLOPE AWAY FltOM BLDC. W/ MAX SLOPE OF 2X MAX, SLOPE IN DIRECTION OF TRAV SHALL BE 5X Ia PROVIDE NEW ACCESSIBLE LAVATORY—AMERICAN STANDARD WHEELCHAIR USERS LAVATORY. PROVIDE BACKING FOR HANGER AS REQUIRED, INSULATE ALL HOT WATER AND DRANK PIPING, - I® INSTALL AL TOILET ACCESSORIES AT HEIGHTS SHWON IN I/A4 ® INSTALL 4'-0' HIM FRP WAINSCOTWO AS REQUfRED AT RESTROOMS © PROVIDE NEW WATER —SAVING ACCESSIBLE TOILET CAROMA CARAVEUE 270 ADA ® PROVIDE AMERICAN STD SILHOUETTE 3Y SHALLOW. DBL BOWL SINK. UNDERCOUNTER MOUNT W/ DELTA 909 FAUCET W/ PULL DOWN SPRAY HEAD —SEE i/A4 FOR CLEARANCE REQUIREMENTS AT SINK (WALL MOUNT LAVA KEYED NOTES ACCESSIBLE SLTMIRCLN FMRACIRM �E OF NAX SLOPE IN DIRERDOTRAV X CONTRACTOR INSPECT AND REPAIR EASING PAVED SURFACES FOR COMPLIANCE TO 'WALKS AND SIDEWALKS' NOTES ON SHT. A-5 AND GRBLO' REPAIR OR REPLACE EXISTING PAVING AS REWIRED FOR COMPUANCE. -' 17401 ZEIOER LANE ivy 4T}O YW�Aw,aW IOU O S DRB CITY OF HUNTINGTON BEACH. CA. PROJECT NUMBER HOidVWM.*CAM0-11M CAD OPERATOR 4 07 ISSUED FOR BID DRB Fm�cDilil OS091 RHM 6J78.09 NO.DATE _ DESCRIPTION '— BY Cash &Associates RHM FLOOR PLAN DRAVANC NUMBER REVISIONS^_�� PROJECT MANAGER H. I A—t rfN SOUTH ELEVATION A-2 9GI - 1/4'-1'-0' REVISIONS °m °as. nw eua taa wntn°mn °..a, cAtau°.n>r r�pt0 s°saOM Cash & Associates um . yr .,..1-1..11 or+..K. = PROJECT NUMBER EXTERIOR ELEVATION 6 3 78.05 AND DRAWING NUMBER HANDRAILS A-2 rl'\ BEARING WALL SECTION INT. KITCHEN ELEVATION /-3'\ INT. KITCHEN ELEvATimi GRIND ALL PAINT FROM HANDRAIL PRIOR TO WERIDNC STL PIPE NON -SHRINK GROW Fi I ( i i 3/8' CALV. STL PLATE i HANDRAIL BRACKLT 2' V D Lp PAINT A E No N- WELDED TO BALUSTERS W/ WARN� NO STRIPE AT #OSwG WSPOSTIFFENER AT 0 INT AS 1-1/2' DIA. OF BOTTOM NOSING * LANDING IN 04OR. SHOWN-Fwww nNISH CONSTRASTING 2-1/2' STL PIPE SLEEVE RETURN RN RUN IELDED END CMS 10 WALL ON T-ING AN. M CONCRETE if F — AS SHOWN GRIND SMOOTH PAINT ENTIRE RAIL AFTER REPAIR OF GALV., 11 . ... . .... PAINT 2* WIDE NON -SUP.. L LEE WARNING WARNING STRIPE AT NOSING OF BOTTOM TREAD LANDING WELD HANDRAIL I 'N CDHSTRASTING COLOR. --- TO EVmG RAIL L PAINT GRNO Sw000TH & N ENTIRE RAIL__ — - - W� /-5-"\ HANDRAIL ELEVATION 66—TYP. HANDRAIL EXTENSION DETAIL 7 HANDRAIL EXTENDED AT RAMP /T*)I TYP. FOOTING GUARDRAIL DE AIL ULF, Hu+kgbns am CA s]Na/1N Tak ('14) n�m Associates ENGINEER ORR DESIGNER LAKE %A OM E 174MCOMMUNITY MR CITY OF HUNTINGTON BEACH, CA. Sc E /0\ DRS PROJECT NUMBER &T78.05 DRAWING NUMBER A-3 CAD OPERATOR AIL CHECKER RHM DETAILS ISSUED FOR BID DESCRIPTION VIslof,ls PROJECT MANAGER RMM 1 PLUMBING ACCESSORY MOUNTING HEIGHT REQUIREMENTS FOR DISABLED ACCESS —4 SCAM NM b ! " E E U., SAN SERIF UPPERCASE LPTTERINO TYP. M17TJL'N Ne9IX M@1 F.F. .tlOIE 1. WHERE PID AANIENF IDENTIFICATION IS PROMDED FOR ROOMS AND SPACES, RAISED LEITERS SFHLL 1$ PROVIDED AND SHALL BE ACCOMPANIED BY BRAILLE 2. SIGNS SHALL BE INSTALLED ON THE WALL ADJACENT TO THE LATCH OUTSIDE OF THE DOOR. WHERE THERE 8 NO WALL SPACE ON THE IGN LATCH SIDE INCLUDING AT DOUBLE LEAF DOORS, SS SHALL BE PLACED ON THE NEAREST ADJACENT WALL PREFERABLY ON THE RIGHT. 3. MOUNTING HEIGHT SHALL BE BO' ABOVE THE FINISH FLOOR TO THE CENTER LINE OF THE SIGN. MOUNTING LOCATION SHALL BE OETERNINM 80 THAT A PERSON MAY APPROACH WITHIN 3' OF SIGNAGE WITHOUT ENCOUNTERING PROTRUDING OBJECTS OR STANDING WITHIN THE SWINC OF A DOOR 3_ WALL & DOOR MOUNTED SIGNAGE (TYP.) —4 SCALE NTS TYP. wu eetoar �r r.r oa ttu HANDRAIL BRACKET woa � s tmr, b 4 1H R e211K11 eNL tb WNL {, ,411tlL Y10QT HANDRAIL AT TOP OF STAIR Rua t�11'-0' 2 9/16' 3/8- X 3- LAO SCREW—TW. INTD 9X BLK'0 BELOW ;O 'e A BASE PL DETAIL SCALE, NONE KEYED NDTEN ❑1 1 1/2' CIA. PIPE RAIL & BALUSTERS -PAINT, COLOR BY OWNER O RETURN HANDRAIL(S) AS SHOWN Qy SEE T 1 FOR HANDRAIL ATTACHMENT TO WALL O PEMKO RAMP R.SFAK 4 RAMP HANDRAIL ELEVATION —4.j SCALE: 1/2--1'-0' e1729*.Aw9u Tao pnFybnCA K1MF1tM Ttt a+o eR"eaaoa Gash & Associates 1—l714) 4"'2M REVISIONS r riom a enter �r tmrut m�wu , Vt' oiA eNn � twnta tm. tP19eWL y � twmtuA KMrJ¢r HANDRAIL AT BOTTOM_ OF STAIR @ wtn ,V.V HAN RAJL NONE DETAILS 4 SCAIE ONE DETAILS IPRO.ECT NUMBER I E37&03 A-4 ACCESSIBLE PARKING I BUILT—UP CURB RAMP 2 CURB —CUT RAMP a I XXX a SCALE 3/13' _ ,•-0' - SCAM N.T.& - SCALE N.T.S. - SCALE 1/2-1'-0' AQUESSMLE PARKING S ALL OUNCE'S WITH CONTINUOUS GRADIENTS SHALL HAVE tEVF1 AREAS A7 1. IN EACH PARKING AREA A OR CURB SHALL E PROVIDED AND LEAST S'.IN LENGTH AT INTERVAL& OF AT LEAST EVERY COD', HAT INTERVALS T LOCATED 70 PREVENT ENlAOACNMFNT OF GARB OVER THE REQUIRED ENCROACHMENT WIDTH OF WALKWAYS. B. WALKS SIDEWALK& AND PEDESTRIAN WAYS SHALL BE FREE CF GRATINGS WHENEVER POSSIBLE FOR GRATINGS LOCAIID IN THE 2 AN ADDITIONAL SIGN SHALL ALSO BE POSTED, IN A CWSPIOUOUB PLACE, SURFACE OF ANY OF THESE GRID PEDiRAPFICINGS IORATINGG SHAH AT EACH ENTRANCE TO OFF-STREET PARKING FACL177M OR BE LIMITED TO 1/2' IN THE DIRECTION OFS. FLOW IMMEDIATELY ADJACENT TO AND VTSIBIE FROM EACH STALL OR SPACE. THE SIGN SHAD. VE NOT t OS 1HAN 1, BY 227 IN SIZE WITH —NON0 ffdRL RAUPR SS NOT LETHAN 1' IN HEIGHT. WHICH CLEARLY AND CONSPICUOUSLY STATES THE FOLLOWING: UNAUTHORIZED VEHICLES PARKED IN 1 �ANSONS � MOM RAMPS TO WALKS, QUTTERS OR STREETS SHALL RE DESIGNATED ACCESSIBLE SPACES NOT DISPLAYING DISTUMISNINO FLUSH AND FREE OF ABRUPT CHANCES,. PLACARDS OR LICENSE PLATER ISSUED FOR PER WITH DISABILITFS MAY BE TOWED AWAY AT OWNER'S E7RENSE. TOWED VEHICLES NAY BE RECLAIMED AT (R BY 7ELFPROFBNo 2. MAXIMUM SLOPES OF ADJD[NINp GUTTERS ROAM SURFACE IMMEDIATELY ADJACENT 70 THE OURS RAMP OR ACCESSIBLE ROUTE, SHALL NOT NOTE BLANK SPACES ARE TO BE FILLED IN WITH APPROPRIATE EXCEED 1:20 WITHIN 4' OF THE TOP AND BOTTOM OF THE CURS RAMP. INFORMATION AS A PERNA.. PART THE 3 ON. THE SLOPE OF THE FAMED OR PARED SIDES OF CURB RAMPS SHALL NOT EXCEED t VERTICAL TO 10 HORIZONTAL 1. WALKS AND SIDEWALKS SHALL HAVE A CONTINUOUS COMMON SURFACE, NOT MMUPI D BY STEPS OR BY APT CHANGES IN UMEXCEED]NG / BRU 0: Z WALKS AND SIDEWALKS SHALL BE 4BW MINIMUM IN WIDTH. I WHEN CHANGES IN LEVEL. NOT EXCEEDING 1/2' OCOR. 71EY SHALL BE BEVELED WITH A SCOPE ND GREATER 1HAR 1:2 EXCEPT RIOT IEVE. CHANCES NOT EXCEEDING Ijf NAY RE VERTICAL 4, TABRUUPS CHANGE IN VAIN THE ALONG AN F ACCCESSIBLETS FORQUROUTEAREXCEEDING COM5, WALK AND SIDEWALK SURFACES SHALL BE SLIP -RESISTANT AS FOLLOWS A SURFACES WITH A SLOPE OF LESS THAN SR GRADIENT SHALL BE AT LEAST AS SLIP RESISTANT AS. THAT DESCRIBED AS A MEDIUM SA.IED FINISH. - B. SURFACES WITH A SLOPE CF 6% OR GREATER GRADIENT SHALL BE SLIP -RESISTANT. 6. WHEN THE SLOPE IN THE DIRECTION OF TRAVEL OF ANY WALK EXCEEDS I VERTICAL TO 20 HORIZONTAL, IT SHALL COMPLY WITH THE PROVISIONS REQUIRED OF A PEDESTRIAN RAMP. 7. WALK AND SIDEWALK SURFACE CROSS SLOPES SHALL NOT EXCEED 1/4' PER FOOT. REVISIONS 3. CURB RAMPS SHALL BE LOCATED OR PROTECTED TO PREVENT THEIR OBSTRUCTION BY PARKED CARS. S FORO HINGED ODORS, THE OPENING WIDTH SHALL BE MEASURED WITH THE POOR POSITIONED AT AN ANGLE OF iq DECREES FROM ITS CLOSED POSITION. S. WHERE A PAIR OF DOORS I5 UTILIZED, AT LEAST ONE OF THE DOM SHALL PROVIDE A CLEAR UNOBSTRUCTED OPENING WIDTH OF 3Y WITH NNE LEAF POSITIONED AT AN ANGLE OF 90 DEGREES FROM ITS CLOSED POSITION. 7. THERE SHALL BE A LEVEL AND CLEAR FLOOR OR LANCING ON EACH SIDE OF A MDR. THE LEVEL AREA SHALL HAVE A LENGTH IN THE DIRECTION OF DOOR SWING OF AT LEAST Bar AND ME LENGTH OPPOSITE THE DIRECTION OF DOOR SWING OF 48' AS MEASURED AT RIGHT ANGLES 1D THE PLANE OF THE DOOR IN THE CLOSED POSITION. a THE WIDTH OF THE LEVEL AREA ON THE SIDE M WHICH THE DOOR SWINGS SULL EKIEJNO 24' PAST THE STRIKE EDGE OF THE DOOR FOR EKTE TEOR DO0RR3 Ir PAST THE STRIKE EDGE FOR INTERIOR DOORS AMID 35' ON THE POL SIDE OF HE OR WHEN 1HE APPROACH IS LIMITED FROM HINGE MRECTION CHITHAT SIDE 9, ME FLOOR OR LANDING SHALL BE NOT MORE THAN I/Y LOADER THAN THE THRESHOLD OF THE DOORWAY. 10. UM EFFORT TO DOORSUR NOT EXCEMiSUCH"PIJLL 4VCMUOR RAMPS Q>YT m ONTNTTRTOLT FOR CAB POUNDS FOTE DOORS INTERIOR DQO"S 1. HANDRAILS ARE REQUIRED ON EACH SIDE OF RAMPS THAT PROVIDE OR PRH EFFORT BEING APPOSED AT RIGHT ANGLER ro HINGED ODORS ANO AT TINE CENTER PLANE GF'SIIOING OR FOLDING DOORS ACCESS IF THE RAMP SLOPE EXCEEDS l' RISE IN 20' OF HORIZONTAL RUN. CGMPEWSATMp DEVICES (R AUTOMATIC OOdR OPERATORS YAY SS DOORS US.- 7 4A%IWN EfTORST WV11: THE D MAYS 1. MANUALLY OPERATED EDGE OR SURFACE -MOUNTED FLUSH BOLTS AND SURFACE BOLTS ARE PRO IBITEA DOORS ARE EXIT DOOARE USED IN PAIRS INCREASED TO THE MINIMUM ALLOWABLE BY THE APPROPRIATE AOMINIS7IRATIVE AUTHORITY, NOT 10 EXCEED U POUNDS AND APPROVED AUTOMATIC FTUSH BOLTS ARE U5m, THE DOOR LEAP HAVING THE AUTOMATIC ilUL BOLTS SHALL HAVE NO ODOR KNOB OR SURFACE -MOUNTED HARDWARE THE UNLATCHING OF ANY LEAF SHALL Gt f%riS eNn �ttsLe 1 QUARMy IN LEVEL UP TO 1 s / ' MAY BE VERTICAL AND WITHOUT EDGE HOT REQUIRE MORE THAN Off OPERATION, A 2 LATCHING AND LOOKING DOORS THAT ARE HAND ACTIVATED AND WHICH ARE IN A PATH OF TRAVEL SHALL BE OPERABLE WITH A SINGLE EFFORT 2 CHANGES IN TRAM BE7WF/N 1/4 AND 1/2' SHALL BE ACCOMPLISHED BY MEANS OFWA RAMP NO 3 THAN 1VFRTICAL TO 2 HORIZONTAL BY LELk7t TYPE HARDWARE BY PANIC BARS PUSH-PULL MATING BARS OR OIHEIL HARDWARE DESIGNED TO PROVIDE PASSAGE WE I IF CARPET ON CARPET TILE IS USED ON A GRONYO OR � FLOOR SURFACE, REQUIRING THE ABILITY TO GRASP THE OPENING HARDWARE IT SHALL BE SECURELY ATTACHED, HAVE A FIRM OUSHION, PAD OR BACKING OR NO W9LI0N 0R PAD. AND HAVE A LEVEL LOOP. TEXTURED d HAND -ACTIVATED COOT OPENING HARDWARE STALL BE lEN1tNm LOOP, n OUT PILE, OR LEVEL. CUT/UNCUT PILE TEXTURE THE MAXIMUM PILE HEIGHT SHALL RE I/2. EXPOSED EDGES OF CARPET STALL BETWEEN 30' AND SA' ABOVE THE FLOOR. BE FASTNED TO FLOOR SURFACES AND HAVETHIN ALONG THEENTIRE 4. WHEN TNSTALLID. EDT DOORS SHALL BE CAPABLE OF OPENING SO THAT LENGTH CP THE EPOSED EDGE CARPET EDGE TRIM SHALL COMPLY WITH NOTE 2 ABOVE RIT2 BebA Aw, SUN 100 Hn4NW�A tNctlA CA P2MFitH Tacpu)aeuon Cash & Associates F«014'3D lNH A. IF GRATINGS ARE IACAIED ON FLOORS DEN THEY SHALL HAVE SPACES NO GREATER THAN I/2' WIDE IN OCE DIRECTION, IF GRATINGS HAVE ELONGATED OPENINGS, HAREM SHALL BE PLACED 50 THAT THE LONG DIMENSION IS PERPENDICULAR TO THE DOMINANT DIRECTION OF TRAVEL HAYARD,q AND PRt1 VOTS 1. OBJECTS PROEC17N0 FROM WA119 WITH THEIP LEADING EDGES LTETWEE! 27` AND BO' ABOVE THE FINISHED FLOOR SHALL PROTRUDE NO YORE THAN �' INTO WACXS. NMJ.S CORRIDORS PASSAGEWAYS, OU AISLES 2. PROTRUDING OBJECTS SHALL NOT REDUCE THE CLEAR WIDTH OF AN ACCESSIBLE ROUTE OR MANEUVERING SPACE _,WAYS 1. OPEN RISERS ARE NOT PERWTIED. SIGNS A IDENTIFICATION 1. THE INTERNATIONAL SYMBOL OF ACCESSIBILITY SHALL CONS ST OF A WARE FIGURE ON A BLUE BAC KORC Md. THE BLUE SHALL BE EQUAL M COLOR NO. 15090 M FEDERAL. STANDARD SM. 2. ALL BUILDING ENTRANCES THAT ARE ACCESSIBLE TO AND USABLE BY ONS PERSWITH DISABILITIES AND AT EVERY MAJOR JUNCTION ALONG OR LEADING 70 AN ACCESSIBLE ROUTE OFTRAVEL SHALL BE IDENTIFIED WITH A SIGN DISPLAYING THE INTERNATIONAL SYMBOL OF ACCESSIBILITY AND WITH ADDITIONAL DIRECTIONAL SIGNS AS REQUIRED. 10 BE VISIBLE TO PERSONS ALONG APPROACHING PEDESTRIAN WAYS ELECIRMAl I. THE CENTER OF ELECTRICAL AND COMMUNICATION SYSTEM RECEPTACLE OUTLETS SHALL. BE INSTALLED NOT LESS THAN 13' ABOVE THE FLOOR OR 'WORKING PLATFORM& L THE CENTER OF THE GRIP OF 7HE OPERATING HANDLE OF CONTROLS ON SKYCHES INTENDED TO BE USED BY THE OCCUPANT OF THE ROOM OR AREA TO CONTROL LIGHTING AND RECEPTACLE OUTLETS. APPLIANCES OR COOLING. HEATING. AND VENTILATING EQUIPMENT SHALL NOT RE MORE THAN A8' ABOVE THE FLOOR OR WORKING PLATFORM. 3. THE CENTER OF FIRE ALARM INITIATING OEVlCES BOXES) SHALL BE RIND SURFACE. ORDSIDEWALK. LEVEL OF THE POOR. ING PLATFORM, DETAILS & NOTES 'PROJECT NUMBER 6378.05 A—s Appendix III Location Map Appendix III Insurance Requirements/Encroachment Permit Applicants and Contractual Services Please give these requirements to your insurance agent City Resolution 2001-065 requires that licensees, lessees and vendors have an approved Certificate of Insurance (not a declaration, policy or statement) on file with the City for the issuance of any permit or city contract. Simple receipt of an insurance certificate is not sufficient. The insurance certificate must be approved by the City Attorney's Office as to meeting all of the city's insurance requirements. Please be aware that part of the insurance requirement, the Additional Insured Endorsement Page (required for both the General Liability and the Automotive Insurance Policies), can take as much as a week or two to obtain. In addition, the typical insurance approval process varies from several days or more so it is strongly recommended that you have certificate(s) submitted at least one or two weeks prior to your scheduled needs. An original certificate is required or a PDF version attached to an email may be forwarded. If the insurance certificate is fax'd, it must come directly from the insurance provider to the City (not from the Insured) to ensure its validity. ➢ Private Property Work Permit Requirements. —If the planned work does not involve public property or its right-of-way (e.g., sidewalk/street or abutment to same), the Workers' Compensation Certificate is the only insurance requirement. However, if the work site is adjacent or attached to public property, the City Attorney's Office must be informed for consideration of liability and decides whether or not to approve the certificate with a specific Private Property Only approval stamp. ➢ Encroachment (City/Public Property) Permit Requirements. —General Liability, Automotive and Workers' Compensation are required (see General Liability Insurance Certificate below). ➢ Consultant Services. ---Professional Liability Insurance Certificate is required (i.e., Legal, architectural, etc.) in addition to a General Liability Insurance Certificate and Workers' Compensation Insurance Certificate. ➢ General Liability (GL) Insurance Certificate of >_$1,000,000 combined single limit/per occurrence An Additional Insured Endorsement Page is required bearing both the GLs policy number and specifically naming the City of Huntington Beach, its agents, officers and employees as additionally insured and, when applicable, the Redevelopment Agency of the City of Huntington Beach must also be named as additionally insured. Per the resolution, the insured definition must read as "the insured is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of "your work" for that insured by or for you." It is not to read, "...but only with respect to liability arising out of your ongoing operations performed for that insured." Type of coverage must be "per occurrence" not "claims made". "Claims made" designation is only acceptable for professional or pollution liability insurance. Waiver Information. —The following information is required for completion of the City's internal insurance waiver form: A brief description of work and/or nature of business, timeframe for completion and dollar value. The exception to the waiver process is the General Liability's and Automotive's Additional Insured Endorsement Pages which cannot be waived. For substantial deductibles and/or SIRS a financial statement (e.g., Brad & Dunstreet, etc.) is required as part of the insurance waiver process. ➢ Workers' Compensation Insurance Certificate of statutory amount is required. If you have no employees, you must sign a Declaration of Non -employee Status form in lieu of a certificate of insurance or provide a certificate of Consent to Self -Insure issued by the California Director of Industrial Relations. ➢ Professional Liability Insurance Certificate of zof $1,000,000 (applicable for professional services) Type of coverage "Claims Made" designation is acceptable for professional or pollution liability insurance. In addition to the above, ALL certificates must contain the following: Insurance Carrier Rating. —Insurance must be placed with a California -admitted carrier with a current A.M. Best Rating of >_ A: VII. If this is not possible an insurance waiver is required. Certificate Holder. --The City of Huntington Beach (2000 Main Street, Huntington Beach, CA 92648, Attn: Risk Management). Deductible, Self -Insurance Retention (SIR), --The city maintains a zero deductible/SIR requirement. Any deductibles/SIRS in force must be listed on the certificate. In the event of any deductible/SIR, the city has an insurance waiver procedure to request a waiver of the zero deductible requirement (see Waiver Procedure below). Cancellation Clause Notice. --There must be a thirty (30) day notice for policy cancellation. A ten (10) day notice for cancellation for non-payment of premiums and/or salary reporting is acceptable in combination with the required 30-day notice. Waiver Procedure. In lieu of meeting the City's insurance requirements, the insured can request a waiver of a specific requirement. To do so, the insured must provide the City with a brief description of the work/project (one to two sentences), the timeframe for completion and the dollar value of the work/project. (not cost but value to the Insured). For a substantial dollar deductible/SIR, a financial statement (e.g., Dunn & Bradstreet, etc.) is required for the approval process. Upon receipt of this information, the City's internal waiver form should be completed and attached to the insurance certificate and submitted for approval to the pertinent City Department Head, the Risk Manager and the City Attorney. The approval process can take from one (1) day in a best case scenario to seven working days for completion. ➢ General Contractor/Sub-contractor(s).—Both the general- and their sub -contractors must provide proof of insurance subject to the City's insurance requirements. Please forward these requirements to your insurance agent/producer for their processing of your insurance certificates. Appendix IV Bona No, Principal in strict accordance with the terms of the Contract as said contract maybe altered, amended or modified from time to time; and if the Principat shall indemnify and save harmless City and all of City's officers, agents and employees {hereinafter collectively referred to as `Obligees'} from any and all losses, liability and darnages,,elaim%. judgments, stop notices, fees and costs of every description; whether imposed by law or in equity, which may be lncurred.bythe Obligaes by reason of the 'failure. or default on the part of the Principal in the performance of any or ail of the terms or the obligations of the Contract, including all alterations, amendments and. modifications thereto, and any werantles or guarantees required thereunder, then this obligation shalt'be void; otherwise,+it shall be and shall remain in full force and effect: Surety stipulates and agrees, for value received, that no adjustment of the time or: price In the Contract or any alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, shall in any way affect, limit; restrict; impair or release the obligations of the Surety under this Bond. Surety waives notice o€any adjustment ofcontract Urea orcontract price, and Page 2 of 2 less than one hundred. percent {100%)W the total. price set forth in the.Contract; In W"ful money of the United States of America; for the payment of which sum, welt acid truly to be made;: we bind ourselves,, and each of our heirs, executors, administrators; successors, and assigns,, jointly and severally; firmty.bythese presents. THE CONDITION OF`THIS OBUGA11ON IS SUCH THAT, if the Principal, his, her, or its heirs. executors, administrators, successors or assigns, or subcontractors shall fall, to pay..any of the persons named in Section 3181 of the:CardornlaCivil Code ("Claimants")for all labor; -materials or services used or reasonably. required for use in performance of the work described in the`Corriracf; or any amounts due under:the Unemployment Insurance Code with respect to work or labor performed by any such Claimant, or, prevailing zwages: due and perialfles incurred pursuant :to Sections 1774, 1775, 1813 or 1815.of.the labor Code, or any amounts required to be deducted, withheld and paid over. to the Employment Development Department from the.wages of employees of the principal and Subcontractors pursuant to Section 13020 of the. Unemployment Insurance Code.with respeot to the work Pr labor performed under the, Contract, Surety will pay for the same: in an'amount:notexceeding the penal sum specified in this bond; otherwise, this obligation shah be null and void This bond shalt inure to the benefit of shy of the persons. named in Section 3181 of the'Callfomia Civil Code sous to give a right of action to such persons or their assigns. 16 case any, action is brought upon this bond; Surety further agrees to pay all court costs and a reasonable attorney'$ fee in an amount fixed by the court: Nge 2 of 2 5 j ' �� ���� VIEW COMMUNITY ��� ��' ®� ��� HUNTINGTON��� Hv ��■ &SCOPE OF WORK THE WORK UNDER THIS PERMIT INCLUDES: 1. REMOVAL OF INTERIOR NON -BEARING WALLS, DOUBLE FLOOR AND PLUMBING FIXTURES AND CABINETS. 2. CGNSTRUCTION OF INTERIOR NON -BEARING WALLS, CABINETS AND EXTERIOR RAMP, STEPS AND PORCHES. S. REMOVAL OF EXTERIOR WALKS FOR COMPLIANCE TO ADA ACCESSIBILITY REQUIREMENTS 4. CONSTRUCTION MENTS OF EXTERIOR WALKS FOR COMIPLIANCE TO ADA ACCESSIBWTY REQUIREtAENTS, 5. PARKING MODIFICATIONS 6. ADA RELATED SIGNACE EXISTING EXTERIOR RAMP AND HANDRAILS OF OFNEW 7. CONSTRUCTION 8. CONSTRUCTION OF NEW RAMP AND REPLACEMENT D HANDRAILS 9. REMODEL OF RESTROOMS INCLUDING ELECTRICAL SWITCHES @ RECEPTACLES FOR COMPLIANCE TO ADA HEIGHT REQUIREMENTS 8 GFl REQUIREMENTS 10. REIAODEL OF BUILDING ENTRANCES/DOOR$ TE DRAWING INDEX REY. DATE SHEET DESCRIPTION 1 S/5/08 T-1 TITLE SHEET 1 3/5/08 GN-I GENERAL NOTES 1 3/5/08 CN-2 GENERAL NOTES 1 3/5/08 ON-3 GENERAL NOTES I 3/5/OB SP-1 SITE PLAN A: DETAILS 1 3/5/08 0-1 DEMOLITION PLAN 1 3/5/DB A-1 FLOOR PLAN 1 3/5/08 A-2 EXTERIOR ELEVATIONS t 3 S OB A-3 DETAILS g R - - ^ 3 8 $ g 3 b is 12. REPLACEMENT OF INTERIOR FLOOR FINISHES 13. REMODEL OF KITCHEN INCLUDING OUTLET, SWITCHES AND RECEPTACLE HEIGHTS 14. MODIFICATION OF ALL ELECTRICAL SWITCHES AND RECEPTACLES THRO GHOUT THE FACILITY TO COMPLY WITH HEIGHT REQUIREMENTS OF ADA. RF(IIIATORY REQUIREMENTS GOVERNING REGULATIONS FOR THIS PROJECT ARE: 2001 CALIFORNIA BUILDING CODE (CDC) VOLUMES I, II, & III WITH AMENDMENTS 200/ CAJFORNIA PLUMBING CODE (CPC) 2001 CALIFORNIA MECHANICAL CODE (CMG) 2001 CAUfORNiA ENERGY CODE (GEC) 2001 CALFORNIA FIRE CODE CFC ( ) 2001 CALIFORNIA ADMINISTRATIVE CODE (CAC) SEE ALSO 'GENERAL PROJECT REQUIREMENTS' AND "GENERAL BUILDING REOUIREEMENTS' ON SHT. CR-1 FOR ADDITIONAL REGULATIONS AFFECTING THE PERFORMANCE OF THE WORK, NOT NOTED HERE. PERMITS k APPROVALS GENERAL' 1. THE OWNER WILL SECURE THE GENERAL BUILDING PERMIT AND EACH SUB-CONTRACTOR SHALL OBTAIN AND PAY FOR ALL NECESSARY PERMITS REWIRED BY THE GOVERNING JURISDICTIONS FOR THE EXECUTION OF HIS WORK, THIS INCLUDES, BUT IS NOT LIMITED TO. AOMD PERMITS ECPARATONS FOR DEMOLITION AND CONSTRUCTION. SEPARATE PERMITS MECHANICALoT ELECTRPLUMBIICAL 1 3/5/08 A-4 DETAILS I 3/5/08 A-5 DETAILS ABBREVIATIONS PROJECT SUMMARY O AT INSUL. INSULATION A.F.F. ABOVE FINISH FLOOR TNT. INTERIOR AHU AIR HANDLING UNIT ,ISi. JOIST ALUM. ALUMINUM LLV. LONG LEG VERTICAL X BY LLH. LONG LEG HORIZONTAL BD, BOARD MAT. MATERIAL BLDG. BUILDING MAX. MAXIMUM BLKG. BLOCKING MTL METAL B.O.P BOTTOM OF PIPE N.I.C. NOT IN CONTRACT DOT. BOTTOM NO. NUMBER CDC CALIF. BLDG. CODE j NUMBER CONC. CONCRETE (N) NEW CONT. CONTINUOUS 0/ OVER CCOILLEN7 LCLL,` L" O.C. CENTER OPNG. OPENING CMG. CEILING OPP, OPPOSITE CORR. CORRIDOR PLC'& PLACES . DEGREES C PLATE DIAMETER t PLUS OR IAINU$ DWG. DRAWING REQ'D REQUIRED DET. DETAIL 9M SIMILAR DIA. DIAMETER SQ. SQUARE ON. DOWN SUSP. SUSPENDED D.S. DOWN SPOUT STL STEEL ELECT, ELECTRICAL STRUC. STRUCTURAL E%ISTC. EXISTING STOR. STORAGE E%1ST. EXSTING SH. SHEET (E) EXISTING TIP. TYPICAL EA. EACH THK. THICK EXP. EXPANSION us UNIFORM BLDG. CODE FIN. FINISH U.N.O. UNLESS NOTED FL FLOOR OTHERWISE F.O. FACE OF VERT. VERTICAL GA. GAGE W.W.M. WELDED WIRE MESH GYP. G PSUM W/ WITH HIJ HOLLOW METAL W/0 WITHOUT R. HOUR W WIDE HT, HEIGHT 1YD WOOD HDWR HARDWARE WDO. WINDOW PROJECT ADDRESS: 17461 ZEIDER LANE HUNTINGTON BEACH, CA. OCCUPANCY(IES}. B OCCUPANCY SEPARATIONS: N/A TYPE OF CONSTRUCTION: TYPE V-N FIRE PROTECTION: NONE BLDG. MGT. (STORIES): 20'-0' (SINGLE STORY) AREA OF WORK: 9.265 S.F, TOTAL BLDG. AREA 9.265 S.F. TOTAL OFFICE AREA: 806 S.F. CONSULTANTS ARCHITECT, CASH k ASSO AVE.,ES SUITE 92 STRUCTURAL ENGR, HUNT BOLON BEACH. CIVIL ENGT1.: HUNTINGTON BEACH, CA 92849 CONTACT: DAVID BACHLE, A.I.A. (714)895-2072 - PY�• ems' iPi `.s' -t a( *'*`� y.f ( Sv 1 11 lµ } y 1 x s i r W t� ' c 3: F• +. - ( Pt s y ii v 3� E +�+eu` I �e"•„„y,)� �[��,ti.,.• - SYMBOLS.I... KEY NOTES ASSEMBLY NOTES O DOOR SYMBOL WINDOW SYMBOL F1067I ROOM NUMBER DETAIL NO. A 5"T. ON WHICH DETAIL IS SHOWN SECTION (SEE ALSO DETAIL ABOVE) A-J VICINITY MAP N.T.S. & gg L ffi g .: 51]]Balu Aw 9A 100 Hw1714) O•arA,G9MIFitM TN:ITtp —12. Cash & Associates 1u 1111eY613w ENGINEER DRB LAKE 174611 ZEIDER LANEN� CRY OF HUNTINGTON BEACH, CA. SCALE NONE DESIGNER ORB PROJECT NUMBER 8378.05 } 5 OB AD NUM / DRB LAD OPERATOR All. TITLE SHEET 4 2 07 ISSUED FOR BID DRB CHECKER RHM ORANING NUMBER T .'_ ' Y N0. DATE DESCRIPTION BY REVISIONS PROJECT MANAGER RHM 0 m z m F z p 95.13 eg2 - All E2. F; IL �o � a m 4 � $Am _A so mix m� i IN � Z 1 1841 Sao am asp Bea IN 2 A 5 !_ � MUM ��avN8o�8 gym- PUG �8� �- N _ UMW O Q m G G HiP .18 6 �� -t 8 �# OPMF^� gt� A�m a €gm a HIM200Sz c r 104, 51 WAR mig 9 ES ,H cl 'pA �e 44 8 �i � 5 16 j Alp m� � f ' o P11 S Mg� M9 A0 .% vm =9 = su Rix q� § b - x �P A X bmu$ m N m �T i Y N OS� Gl ��f- 2A OMAN. MADNO REOUPEAgIm (CONT) 17 EOENO 1. ALL EXIT DOORS SHALL BE OPERABLE FROM THE INSIDE WITHOUT THE USE OF A KEY OR ANY SPECIAL KNOWLEDGE OR MOM, ALL REQUIRED DUT DOORS SHALL BE EQUIPPED WITH NO -KNOWLEDGE K MDWME. THE USE OF KEYS, CARDS AND ANY OTHER TYPE OF SPECIAL KNOWLEDGE, INCLUDNO RELEAAi1NG OF THE DOOR UPON ACTIVATION OF THE FIRE ALARM SYSTEM, SWIRL. NOT BE REQUIRED FOR USE OF A REQUIRED EKR DOOR 2. ACCESSIBUIC 1. SEE SHTS'. AD-1 FOR ACCESSBILRY NOTES .COD DETAILS FOR ADDITIOWL INFORWIION. 1. CONIRACTDR SHALL M INTAN ME LANES AND ACCESS TO EXISTING FA LACES AND EOUIPMENT IN ACCORDANCE WITH LOCAL FIRE DEPT. REQUIREMENTS. 2. FIRE DEPARTMENT FINAL INSPECTIONS REWIRED. SCHEDULE NSPECTIONS 2 DAYS N ADVANCE. 3, LOCATIONS ANO CLASSIFICATIONS OF EXTINGUISHERS TO BE 0ETERMINED BY FIRE INSPECTOR. STRUCTURAL NOTES 1. THE CONTRACTOR SHALL MAKE AND KEEP CURRENT A SET OF RECORD DRAWINGS SHOWING EXACY DIMENSIONED LOCArOIONS OF UNDERGROUND UTILInES. STUB CUTS. CONSTRUCTION CHANCES, ETC. L INSTALL ALL TEMPORARY BRACING AND SHORING TO ENSURE WE SAFETY TO THE WORK UNTIL R IS IN ITS COMPIE'IEED FORM. ]. THE CONTRACTOR IS RESPONSIBLE FOR ALL EARTH EXCAVATION AND EARTH SHORING WORK AND SHALL BE RESPONSIBLE FOR ALL COSTS ASSOCIATED WITH REPAIRING DAMAGE TO EOSTW FACILITIES AND ADJOIMNC PROPERTY. 4, ALL STRUCTURAL DRAWINGS SHALL. BE READ IN CONJUNCTION WITH THE SPECFIGTIONS AND ALL OTHER DRAWINGS RELAYING TO THE WORK. 5. ELBEOOED MS SUCH M PIPES. INSERTS. SLEEVES AND CONDORS, AND ANY ACCESSES OR OPENINGS REQUIRED FOR UTILITY. MCHECTIIRAL, MECHANICAL AND ELECTRMYL NSTALATIONS ME NOT SHOWN ON THE STRUCTURAL DRAWINGS. CONTRACTOR SHALL REFER FO THE UFM ARCHITECTURAL, MEC NNE AND EI.ECIRKAL DRAWINGS FOR THE LOCATIONS AND DETAILS OF THESE ITEMS. L ND PIPES OR SLEEVES FOR MECWNIGL ELECTRICAL OR PLUMBING TRADES SHAM PASS THROUGH SIiWCRIRAL MEMBERS, UNLESS SHOWN ON STRUCTURAL DRAWINGS WRHOUF THE AP F OF THE ENGINEER. 7, SEWER AND UTILITY LINES ARE NOr INDICATED ON STRUCTURAL DRAWINGS. REFER TO CML PLUMBING AND ELECTRICAL DRAWINGS FOR THE LOCATION. PROFILE MD MAYS. THE CONIRICTOR SHALL COORDINATE SEWER AND UTILITY UHES WITH FOUNDATIONS SHOWN ON STRUCTURAL DRAWINGS. ANY INTERFERENCE BETWEEN SEWER AND UTILITY LINES SHALL BE BROUGHT TO THE ATTENTION OF THE ENGINEER BEFORE PROCEEDING FURTHER WITH WE CONSTRUCTION. S SEE ARCHEMPAL, ELECTRICAL AND MECHANICAL DRAWINGS FOR ROOF AND WALL OPENINGS, SLAB DEPRESSIONS, PITS, TRENCHES ETC NOT SHOWN ON THE STRUCTURAL DRAWINGS. B. ENGINEER -OF -RECORD AND THE CRY OF HUNTINGTON BEACH PLANNING AND BUSDINO DEPARTMENT STAFF SHWA REVIEW AND COMMENT ON ALL RU STCTURAL SHOP ORAWINGS PRIOR TO CONSTRUCTION. EARTHWORK & FOUNDATIONS 1, COMPACT THE UPPER 12 INCHES OF SUBGRADE BENEATH SWALLOW FOUNDATION BEARING AREAS TO AT LEAST 95 PERCENT RELATIVE COMPACTION LASED ON TEST METHOD ASM DISS7. 2. REMOVE M ALL LOOSE FAR, WATER, AND DEBRIS FROM THE FOUNDATION BED PRIOR TO POURING CONCRETE FOOTINGS. 3. COMPLY WITH THE RECOMMENDATIONS OF THE GEOTECHNICAL REPORT FOR FARTRRORK AND FOUNDATIONS. 4. PROTECT ALL BUS ON THE SITE FROM OWING- S. AFTER FOUNDATIONS SCAMATTON HAVE BEEN COMPLETED AND PRIOR 10 PLACING WNFORCM NO MIMAQRK, SECURE INSPECTION OF THE COMPLETED EISDAVATON BY THE GEOECHNICL ENGINEER NO H.B. CITY DEPARTMENT OF BUILDING ! SAETY INSPECTOR. REMOVE LOOSE AND UNSNTAS E SOLS AS EXPECTED N THE CECECHNCA ENGINEER, S. COMPACTION IMPORTS SHALL BE SUBMRED N CONTRACTOR FOR CONDITION& APPROVAL 7. CRUSHED MSCEUMEOUS BASE (O &) SHALL BE N ACCORDANCE WITH SUBSECTION 200-2.4 OF THE 'GREEN BANK WIIN FINE GRADATION. REVISIONS 6. ALI. FILL. BAD FILL OR CUT AREAS SHALL BE COMPACTED TO A MINIMUM SOX RELATIVE COMPACTION AS DETERMINED BY AS.T.M. MEMOD D1557, UNLESS NDIGIED OTHEROSE ON THESE DRAWINGS OR SOILS REPORT, SUB-ORANS SHALL BE PROAOED WHERE REDUIRED BY CODE. 9. PLACING. SPREADING. AND COMPACTING OF C.M.B. SHALL BE ON ACCORDANCE WITH SUBSECTIONS 301-2.2 AND 301-2.3 OF THE REFERENCE SPECIFICATIONS. COMPACTION SHIAI1 BE 95X RELATIVE DEIST". 1D. SAFE CONSTRUCTION EICAVATION AUPES AND SHORING ARE THE RFSPoNS1611I1Y OF THE CONTRACTOR AND SHOULD COMPLY IAW ALL OSHA AND DWS MPUCAHLE SARIY RECUTATXNS. 1. CONCRETE SIRENGIN (25 OM):- 4,000 M TYPE A POE SURD -UP - SAND .1 TYPE V AGGREGATE (1' WMMUM) AST. C-33 (HEAVY MEDIA PROCESSED FlHE AGGRE `LATE ASTM C-33 (111ASIE0 WNCPLTE SHAD) REINFORCING ILA' S AMA-615, GRADE ED REIN[ORCM BARS (1YELDA&F.) ASIM A-706 2. CONCRETE Al. DESIGN: CONCRETE SHALL HAVE A WATER -CEMENT RATIO OF 0.45 rIM; N .COD SHALL /NAVE A RUMP NO GREATER TRW 4'. MAXI N1UM ETJ.i SZE 1'. YIN DESIGN SHALL BE PREPMED BY CONCRETE SUPPLIER AND SUBMITTED TO THE ENGINEER .COD THE TESTING AGENCY FOR REMET. 3. MIMMUW CONCRETE CONER FOR REWIm.n,r.. CAS' AGAINST AND PERMANQlDY EPOS'F*V m [ Y CAST N FORMS AND EXPOSED TO FARTII OR WLA7HER-2' INTM R104 BEANS, 6QA6. MO COUAMNS 1-1/2' 4. RpOSSNFORCIHp 5]E0. SPLICES SIWL 0E NAPPED A MMMUM DF W BM OWIEIFRS (24 MINIMUM) MD SECURELY WIRED TOGETHER. SPLICES OF ADlAC REWIFORd C B4R5 SIWL BE STAGGERED WHEREVER PIBLE. SEE ORAYPIGS Fqt PAR11CUlAR REQUIREMENTS FDII SP10E BREWS. S. PROVIDE AND LOCATE SLEEVES FOR PIPES. AND PIPES CAST IN CONCRETE FOR WHICHN NO SPECIFIC DETAILS ME SHOWN, AS DIRECTED BY THE ENGINEER. S. SUBMIT THE DETAILS OF ANY CONSTRUCTION JOINTS. OTHER THAN THOSE SHOWN. TO THE ENGINEER FOR APPROVAL 7. FIRMLY SECURE ANCHOR BOLTS. RENFOHCMG STEEL DOWELS. INSERTS. ETC. N POSMON PRIOR TO POUPoND CONCRETE. B. VIBRATE CONCRETE AS O S BEING PLACED WIND ELECTRICALLY OPERATED VIBRATION EQUIPMENT. 9. SUBS SNAIL BE SPRAYED WITH A CURING COMPOUND IMMEDIATELY AFTER FINISHING. 1D. A11 EXPOSED CONCRETE EDGES SHALL BE TROWELED WITH 1/0- RADIUS. 11. ALL EGOS CONCRETE ARTWORK SHILL RECEIVE A MON-SLIP BROOM FNISN (NSF) UNLESS OTINERWSE NOTED. 1. CONCRETE ANCHORS SHALL BE INSTALLED IN STRICT CONFORMANCE WITH MANUFACURER'S RECOMMENDATIONS, IN SOUND MATERIAL WRIT NO LESS THAN THE MINMUM EMBEDMENT WECMED BY THE MANUFACTURER. HLTI HY 130 ADADADHESIVE ANCHOR SYSTEM - "O/ 5193. LADHESIVESWR/ 24397 LAR M253)9 OWN A7 ACRYUC ADHESIVE - 1CBD /SSBO. CONCRETE MASONRY 1. ALL OTHER MASONRY WALLS MASONRY WORK IS DESIGNED ON THE BASS OF Fm - I,S00 PSI MINIMUM COMPRESSIVE STRENGTH DF UNITS PROVIDED F'm . 1,900 PS ALL WANTS SHALL BE SPECIAL INSPECTED AND GROUTED SOLID. MOR AR: TYPE S' (UNIFORM BUILDING CODE) MINIMUM COMPRESSIVE STRENGTH 028 DAYS: IAW PSI. GROUP. MINIMUM COMPRESSIVE STRENGTH 028 DAYS: 2,000 PSI. 2. PROVIDE TYPE I DR I Jig WEIGHT SINGLE OPEN EHO GAD -BEARING CONCRETE MASONRY UMTS, CONFORMING TO /STAR C-90. 3. WBMTE CROP TURNED PULING. ACCURATELY ANO SECURELY TIE REINFORCING STEEL IN RACE BEFORE GROUTING. S. SANDBLAST SURFACES CLEAN ON WHICH BLOCK IS LAID PRIOR TO LAYING BLOCK. THIS APPLIES TO TOP OF FOOTINGS. 6. OPEN END BLOCK SHALL BE LAID WITH OPEN END AGAINST CLOSED END. CLOSED END SHALL NOT BE LAD AGAINST CLOSED END. SAWCUT BLOCK AS REWIRED TO MEET THIS REQUREMENT.DOUBLE OPEN ENO BLOCK S PERMITTED. CASEWORK/MILLWORK 1. Nl CASEWORK MALL CONFORM TO WOODWORK INSTMES MANUAL OF MUTIM LATEST EDOIDN. A BEFORE DEAEO ID TIC JOB SITE THE Ck%VM SUPPLER SHA L 691E A M CERTIFIED COMPTAWE CFMPIGTE INDICATING THE GRADE OF CASEWORK PRODUCTS ID BE FLPoRSHED FOR THS JOB AND CERIFTWG WAT THEY MLL FULLY MEET Al REOUREMEMS O THE ETUDE OR TRADES SPECIFIED. 2. Al WOOD "a BE FOREST StOMA&SNP COUNC1 (FSC) CpNNm. A PRUME EYDENCE OF COMPLIANCE NM FSC STANDARDS AS FOLLOWS: (1) DFMOSTRAE TRWT PRODUCTS ARE M-CERIVIEU SY PRDVDHG VENDOR PWOICS. RAVICES PILL CONTAIN THE VENDOR'S CAN OF CVSTOOI IAJYBER AND ODIIFY CAGW1 FSC�EHfFED fADOWf ON A F11R1W9HIF5 WOW PROQKTS TD IIOECT CONDIACIORS "/OR SUBCOOR/LIORS FOR OH -SIRE INSTALLATION. VENDORS SHALL BE CERTIFIED BY ONE OF TIE EOEO INC NORM AMERICAN ORIMIOnDN DOGES ANREOIED W THE ESE t0 COGIFY FORESTS AND FOE PRODUCS SCEDINC QMFICATIW STEMS b. WWWOOD c SS SSRp6 ANTI SENACES CERRBICATON, INC. PRODUCTS LACKING ACCEPTABLE DOCLRHNO110N WILL BE RF.ECIm. AND TIER ROOM REQUIRED L AL WMPSETE MATERIALS SHA L BE FREE OF URE-FORWRIDEIYDE PRODUCTS AND SNAIL BE COMPOSED OF RELTCLED WOW PRODUCM 4 AL CLUES AND ADIES145 SHALL COMPLY WIIN SCMMD RMAREYEMS. MNMUL SEE NOTE 6 FOR ADDIL REQAAEMIXIS S. SUBMIT SHOP MAIM FOR AL FRall CASEWORK AS REQUIRED HRE A SIM DRAWINGS SHALL BE PRE➢WS N ASORONCE WITH SECTION TO 1. L110ROF K SNIP WWYNCS; ME M IWNTML OFMLLWORK' S. NOT USED C SHOP DRAW= FOR CA9EWGRI( SHALL BEAN ME 1M CEEFED COMPLIANCE LABEL. DO MDT FABRICATE UNIT ROSS S C01PLElm. D. CUM SA P%ES OF CORMN SNOL BE SUBMITTED ID THE OWNER FOR SELCWNAPPROV& E FINISHED EDLPLES FOR EACH TYPE O CABINET DOOR FRONT. DUPER FRONT AO COOSED CABINET FILL TRAMPLES SAIL BE NOT LESS THAN 12 NCIES UM BY THE WIDTH OF WE ITEM BDNG CONSIDERS, OR 12 INOIES MIRE MAXIMUM. 6. GTE'AORK SHALL COMPLY WITH THE REQ WREMDO SPECIFIED BMW. A KITCHEN MAREIA IT CUM GRADE SEE SQO SURFACING NOTES FOR COUTTEGOP ! SPLASH EEO. S. NOT USED C NOT USED D. IF THE GRACE FOR TIE CASEWORK 6 MDT SPECIFIED. IT SHWA BE M E. CONSTRUCTION SME A FPNIEES F. CM67RUCIMN TYPE. I MULTIPLE SELF SUPPORTING WINS FASTENED TOGETHER TO FORM A LARDER UNIT. G. EDGE BANDING SHILL BE PNAOFD AT ALL CASEWORK WHETHER OEMNED OR NOT. ma BANDLO SHILL MATCH VIEW OR SOLID WOOD. K DOOR AND DRYER FRONTS SHILL BE RUSH OVERLAY WIIN 3/4' HORIZONTAL REYEYS ILO 1/5' VERTICAL RELWS I. (NEW DOORS SHALL BE TYPE A FLUSH WITH EDGE SANDND J. EXPOSED FASTENERS NAIL NOT BE PERMITTED AT WE DIVERGE OF THE CUKM. Tms 6772 BH6WW A....IN ORD HImmO4) 2072 926441134 DESIGNER CAD OPERATORn:OM)6BS2Dn RLR Cash & Associates F.` ODES-1 CHECKER euu CASEWORK/MILLWORK (CONT.) IL NOT USED L CAMEL MANORS M. ADCAft WATER BRED. LOT VOC, MON-TOXIC. IVA ACHESNE N. CONCEALED KWES: W-CLOSPA W/ MID -SAW FUTURE GLUM OR APPROYFD EQUAL D. ALL6TA8LE SIN STANDARDS AND SLWPONA KNAPE 6 YOGI 255 OR APPROVED EQUAL P. DRINEN SLIDES: ACCLnpE 3132EC (1001 LOW CAPACITY). OR D PULLS SHAL BE BY HUIIE 1121JOS12 OR 11639140 FINAL SELECION BY OTHER 7. ENE. STOPAGE AND BMW CONDIONS SNAIL BE M ACCORDANCE WIN THE M MAUM. (SEE P. 238). 6. INSTALLATION: INSTALL FINISH CASEWORK N ACCORDANCE WITH 'GUIDELINES 10 CASEIIOOK INSTILLATION LATIDH REMAREMDRS. P.m OF APPENM OF THE W M111UW WOROMM9111P SHALL CONFWM TO TUS10M'.W1 'PREM." WADE REWREMEWIS, SEE NOTE B FOR ADDITIONAL EKORWTON. B. INSTAL CASEWoMK AS METED ON TIE DRALRMGS. "S. MAIL SQUARE TRUE TO LINE AND "AMY ANCHORED. C. XU S AND SCBEIK SHALL BE WEARY SET AND WOOD BASED IN THE DRIANO OF MALS NA SCREWS SHALL BE SAIOED SAOGTH. D E EIGI R COMER JOINTS SHILL BE M MS FROM CORMR JOINS MY BE COPED. CORNERS OF CASING TYPE TRW SHALL BE MITERED. E. WHERE MINDED MEMBERS AD10N OTHER WELDING OR PLAN SECTIONS, THE MOLDED MEMBERS SHILL BE ACC ROELY SCREW TO THE DARER MEMBERS. E7OOSED DOGES SHALL BE EASED. F. NOI USED. D SEGRE ALL NIEUOR TFUM NN FINISHING KITS OR FMEW-TEND SCREWS AS REQUIRED. UNLESS IG- OME06E SET ILLS AND SCREWS FOR PUTTY STOPPING OR PI11WA ALL P lm OR PANG MAUTIVLS SHALL COMPLY WIN THE REFERENCED REWREPtRS OF THE STQOM H. KAMM OR COOL MUMS OR MARRED SURFACES WILL NOT BE AGCEDMBIE ON MY EXPOSED FD04ED SINFALES AND AS EROSEE OF INTERIOR WORKMANSHIP. MAY BE WISE FOR DEVOTION OF SUCH WORK L PREPARE ALL INSTALLED CASEWORK FOR FHOW SY CLEARING AND SAINTING AS REQUIRED TO RECEIVE TOM SPEWED IN 'PAINTING' AND N ACCORDANCE WIIN THE REWODIEMS OF'CASENOM' FOR LOW -EMITTING WRRMLS. FMNB SHALL BE SHOP AAPED WHERE POSSIBLE W/ TWCH-UP WORK PERFORMED IN THE FDA L. PROECTDIB A At CASEWORK SHALL BE PRatOW FROM DAMAGE M M CONSmUCmK S. OFECRVE IA70W NO WORK A✓9MP WILL NOT BE ACCEPIED NO SHALL BE FOAM AND/Oft REPLACED BY THE CONTRACTOR AT 111E CoNTRACTOR'S EIOENSG 10. MISSING A SEE PAWING NOTES FOR REQAREIM SM. CH-5 JARPEIF 1. GEETCA • CORRATOR SHALL FLOM ALL WIEPMA LABOR, SUPER MOL TODIS. EQ•PMENT AND SERVICES TO PROVIDE ILO INSTILL AL GWPET N ACCORDIWE WIN EWRWAIUREAY LATEST AmpBE)MTKINS NO SPECNWIONS AND AS INDICATED ON THE PANS AND SPECIFIED HUM 2. ALL CARPET PRODUCTS SNAIL MEET THE CARPET AND RUG MISTRTE B1CIVMWLA= INDOCIR AIR QUALITY TESTING PROCIAM. AIDESNES OR VACIML SYSTEMS. 7. CAPLET ACCEmOPES A ADHESIVE FOR C4RPn PRIVATE ADHESIVE WNW COUPES WITH DAME SPIRED RATING REMIT FOR THE CARPET 6ATIEATION AS RECOMMENDED BY THE CARPET MAN PER MD MESS GREEN LABEL PIS COMICATON REQUIREMENTS GENERAL NOTES IPRDJECT NUMBER I 6378.05 GN-2 CARPET 1. MOM: CONTPALTOR SHOAL R1MH6H NL Wi1RU1S. IVBOR, SUPERISCN. TOOLS, EQUIPMENT AND SERVICES TO PROARK AID INSTALL ALL CAR IN ACCEPTANCE WITH MANUFACTURER'S LATEST RECOYMENTVpIb AND SKICIICATIONS AND AR INDICATED ON THE RMIS AND SPECIFIED NEI 2. ALL LIMPET PRODUCTS SOUL MEET THE CARPET AND RUG INSTITUTE TE!IVNG PROGRAM. INCLUDING AN CUSHION, ADIESNESGREEN LABI PLUS MOM MRORR VANW STIEMS. L CARPET SHALL MAIM FORTING N TYPE pwAY AND APPNF.ARpH. COLOR SELECTION SMALL BE BY MO. EXTENT OF REPLACEMENT SNAIL BE GUMMED BY OWNER AT TIME OF W. 4. CARPET ACCESSORIES A ALNESNE FOR CARPET: PROM DE ADHESNE WHICH COMITIES WISH FUME SPREAD RATING REARED FOR THE CAH'ET IFSRNU1fON AS REOOMWENM BY THE CARPET MANUFACTURER AND MEETS GREEN LABEL PLUS CO7WTGTKN REOUNEMENTS. B. BASE: 1. 4' HIGH CARPET BASE AT PUBUC AREAS AND TYPE II, 4 HOMES HIGH X 1/6-INCH GAUGE. 1N TOO FOOT CONTINUOUS ROLLS, WISH MATCHING PREMOIDED END STOPS AND EXTERNAL CORNERS; COLOR CONFORMING TO APPROVED SAMPLES. SEE SHY. A-7 FOR LOCATIONS OF DIFFERENT BASE TYPES 2. PROVIDE STRAIGHT. FLUSH TYPE FOR CARPETED AREAS UNLESS OTHERWISE SLTEOMED, 3. MINUFALTlRB(/CODR. MYSiRONG. BURKE OR ROPPE COLOR TO BE SDECIED B( OMIER FROM MAMIFACMRR'S CDLORS C EDGE TRANSITION STOPS: RFSILOT MOLDINGS FOR TRANSTON BETWEEN CARPETING AND CONCRETE GDI TEE, ETC, REDUCER TYPE MNNFACNRED BY AXNSINIE COLORS M BE SELECTED BY OWNER FROM MANUFACTURERS COLORS. 0. MSCEUAAEOUS MATETRVIS: PROADE FIDOR PATOING COMPOUND, ADIESNES. AND OTHER NECESSARY ITEMS AS RECOMMENDED BY THE MANUFACTURER FOR THE O MOONS OF OSTNIAION AND USE REVISIONS PEd�6 1. PANT ALL EXPOSED SURFACES IN ACCORDANCE WITH ME FINISH SCHEDULE AND THESE NOTES. PAINTING INCLUDES SURFACE PREPARATION. MASKING. AND CLEM UP. PAINTING REQUIREMENTS SMALL ALSO APPLY TO SHOP -FINISHED OR PRE-FIMSNED MATERAAIS PERFORMED BY OTHER TRADES SUPPLYING THOSE FINISHED PRODUCTS. SUCH AS CASEWORK AMID MILLWORK. 2. PAINT EXPOSED SURFACES. EXCEPT WHERE THE PMW SCHEDULES INDICATE THAT A SURFACE OR MATERIAL S NOT TO BE PNNIED OR 15 TO REMAIN NATURAL IF THE PANT SCHEDULES DO NOT SPECIFICALLY MENTION AN REM OR SURFACE PAW THE MEM OR SURFACE ME SURE AS SIMIIAR ADJACENT MATERIALS M SURFACES WHETHER OR NOT SCHEDULES NDICATE COLORS. IF THE SCHEDULES DO NOT INDICATE COLOR OR FINISH. THE OWNER WILL SELECT FROM STANDARD COLORS AND FINISHES AVAILABLE. PROJECT AREA SMALL BE ZERO VOC PRODUCTS UNLESS APPROVED BY THE OWNER A PAINTING INCLUDES FIELD PANTING OF EXPOSED BARE AND COVERED PIPES AND DUCTS (INCLUDING COLOR CODING AND FIRGT FIVE FEET OF INTERIOR OF DUCTWORK AT REGISTERS). HUNGERS. EXPOSED STEEL AND IRON WORK. AND PRIMED METAL SURFACES OF MECHAMCAL AND ELECTRICAL EQUIPMENT. B. DO NOT PARR PREFIHISHED ITEMS, CONCEALED SURFACES. FINISHED METAL SURFACES. OPERAIROS PARTS. MO LABELS. 4. SUBMITTALS A MATERIALS UST: SUBMIT A COMPLETE MATERIALS UST. IDENTIFIED BY HAIJUFACTURFRS NAME AND PRODUCT LABEL OR STOCK NUMBER. UST APPLICATION OF EACH FINISH. B. SAMPLES: PROVIDE 8-INCH K S-INCH BRUSH-OVT SAMPLES OF EACH COLOR AND FINISH. FOR TRANSPARENT AND STUNNED FNISHHE% PREPARE SAMPLES ON SAME SPECIES AND QUALITY OF WOOD TO BE INSTALLED ON PROJECT, SHOWING SYSTEM USED. & CIAALDY ASSURANCE A PROVIDE PRIMERS AND OTHER UNDERCOAT PAINT PRODUCED BY SAME MANUFACTURER AS APISH COATS. USE ONLY THINNERS APPROVED Of PAINT MANUFACTURER NA USE ONLY WITHIN RECOMMENDED LIMITS O. DEUVERY. STORAGE AMID HANDLING A DELIVER ALL MI RUMS TO THE SITE IN ME MANUFACTURER'S ORIGINAL CONTAINERS WITH LABELS INTACT AMID SFAS UNBROKEN. a. STORE MATERIALS IN A LOCKED, WELL -VENTILATED ROOM OR SHED. C. COMPLY ARM HEALTH . FIRE REGUM IONS, AND BEST TIC MANAGEMENT PRACES (IMP,). 7. MANUFACTURERS A FRAZEE B. DUN N EDWARDS C. ICI D. SHERWIN WILLIAMSE. BENJAMIN-MOW OTTER MANUFACRIREDS WITH PRODUCTS EQUAL IN ALL PERFORMANCE. APPEARANCE, MATERIAL AND DIMENSIONAL ASPECTS AS SPEa ED AMID APPROVED BY ME ENGINEER PREFERENCE 94ALL BE GIVEN TO THOSE MANUFACTURERS THAT HAVE MANUFACTURING INGRATES WITHIN 500 MRS OF THE PROJECT SITE & MATERIALS A MATERIALS SELECTED FOR COATING SYSTEMS FOR EACH TYPE SURFACE SMALL BE ME PRODUCT OF A SINGLE MANUFACTURER. B. FIMSM COATI SHALL NOT BE TINNED. C. UNSUITABILITY OF SPECIFIED PRODUCE: CLAMS CONCERNING UNSUITABILITY OF ANY WTERNE SPECIFIED (OR THE MMBILIIY TO SATISFACTORILY PRODUCE THE WORK) WILL NOT BE ENTERTAINED, UNLESS SUCH CRAM IS MADE IN WRITING TO THE OWNER BEFORE ME WORK 15 STARTED. f11A fMYR1TT D. NUMBER OF COATS SCHEDULED IS MINIMUM. ADCTTONL COATS SHALL BE APPLIED AT NO ADDRIORAL COST IF NECESSARY TO COMPLETELY HIDE FUSE WTERMIS, PRODUCE UNIFORM COLOR AMID PROVIDE SATISFACTORY FINISH RESULT. E. ALL SUBMITTED PAINT PRODUCTS SHALL BE IN COMPLIANCE MYTH ALL CURRENT LOCH., STATE AND FEDERAL MR QUALITY MANDATES. ACCESSORY MATERIALS SUCH AS THINNERS. PUTTIES. CAULKING, PATCHING MATERIALS. VARNISHES SWML BE OF THE HIGHEST QUALITY AND BY APPROVED MANUFACTURER MD SHALL. ILM COMPLY WITH ALL CURRENT LOCAL STATE, AND FEDERAL NR QVALIIY MAN DATES AND THESE SPECIFICATIONS. ALL PNW AND ACCESSORY MATERIALS SHALL BE ZERO VOC TYPE PRODUCTS, WHERE AVAILABLE. A ALL COLORS ARE TO BE SELECTED OR APPROVED BY ME OWNER AND ACtUAL COLOR CHIPS SMAU. BE SUPPLIED TO ME CONTRACTOR FOR MATCHING. ALL UNOERCCATS SMALL BE TINTED TO APPROXIMATE THE FINISH COAT. B. APPROVAL OF FINAL COLORS: FINAL COAT OF PAINT SHALL NOT BE APPLIED UNTIL COLORS HAVE BEEN APPROVED BY ME OWNER. C. ME NUMBER OF COLORS TO BE USED SHALL BE AS DETERMINED BY THE OWNER. OWNER RESERVES THE RIGHTTO VARY COLORS MROUGHCVT THE PROJECT. 10. EKMIDUTION A EXAMINE SURFACES SCHEDULED 10 RECEIVE PAINT MD FINISHES FOR CONOMONS THAT WILL ADVERSELY AFFECT EXECU DM. PERMANENCE OR QUALITY OF WORK AND WHICH CANNOT BE PUT INTO ACCEPTABLE CONDITION THROUGH PREPARATORY WORK AS INCLUDED IN NOTE 11 OF 'PANTING', 'PREPAPATION OF SURFACES'. ME CONTRACTOR SMALL NOTIFY ME OWNER IN WRITING OF ANY DEFECTS OR CONDITIONS WINCH WILL PREVENT A SATISFACTORY INSTALLATION. S. DO NOT APPLY PAW OR FINISH UNTIL CONDITIONS ARE SATISFACTORY. C. COMMENCEMENT OF INSTALLATION CONSTRUED AS ACCEPTANCE OF SURFACES. IT. PREPARATION A PROTECTION: 1. PROTECT ALL SURFACES NOT TO BE PAINTED, OR PREVIOUSLY PAINTED FROM ME DAMAGE DURING ME PANT APPLICATION. 2. APPLICATOR WILL BE RESPONSIBLE FOR THE REPAIR AND OR REPLACEMENT OF ANY WORK DAMAGED DURING THE PANE TION B. SURFACE PREPARATION: 1. SAND SMOOTH AND APPLY PRIMER AS SPECIFIED. HOLES. SPUDS AND SCRATCHES SHALL BE PUTTIED MD SPACKLEO SMOOTH AFTER APPLYING FIRST COAT. END GRAIN WOOD EDGES SHALL BE FINISHED TO PROVIDE THE SAME APPEARANCE AS THE REMAINDER OF THE SURFACE 2. SURFACES SMALL SE PREPARED AND PANT THINNING WTERALLS APPLIED AS REWIRED, IN STRTLT ACCORDANCE WON MAMIFACT RFIYS RECOMMENDATECI IONS AND SPFlGKIt$, TTO PROVIDE A FINISHED SURFACE FREE FROM RUNS, SAGS, WRINKLES, SHINERS, STREAKS ANDBRUSH MARKS. 12. APPLICATION A APPLICATION OF PAINT SYSTEMS SH A L BE IN STRICT ACCORDANCE WITH MANUFACIVRERYS RECOMMENDATIONS MD SPECIFICATIONS. B. PROVIDE FINISH COATS COMPATIBLE WON PRIME PLANTS USED. sm Ala.. Aw, s� too Huntliglm BpCI, GP261&11N rtl: 0lgees2on Cash & Associates ODORS R HOW Y� 1. FOR ACCESSIBLOY REQUIREMENTS AT DOOR. SEE SHY A-5. 2. DOOR HARDWARE SMALL BE PROVIDED AS REWIRED IN ACCORDANCE WITH THE REQUREMENTS OUTLINED BELOW. CONFIRM MM k GYUNDER/KEYING REQUIREMENTS WITH ME CT' PR10R TO PURCHASING DOORS R HARDWARE. A HINGES: MCKINNEY TQ714 4jX4f-NRP. SS 8. MRESHOLD: SEE DETAIL 6/A-4 C. CLOSER: NOMON. 1601BF (ALL CLOSERS TO BE MOUNTED ON ROOM SIDE WITH MINIMUM CLEARANCE BELOW CLOSER OF 6'-17 D. WFAMERtSiRIPPING: PEMKO 292AV (SURFACE WD.) E. DOOR BOTTOM: PEMKO 3452A F. LCCKSET(S): RESTROOMS --_SCMAGE D SERRES RHODES LEVER G. DEADBOT O WG ROOM DOORS: SCHLACE BC-100 SERIES COMPLETE WITH TAILPIECES R HOUSING SS FIN H. DOOR STOP: TRIMCO W1212, SS L KICKPLATES: TRIMCO K0050, SS FA SIDE OF DOOR 3. ALL DOORS SH AU. BE OPERABLE FROM ME INSIDE WITHOUT THE USE OF A KEY, SPECIAL KNOWLEDGE OR EFFORT. 4. Al DOOR FRAMES SHALL. BE HEAVY DUTY TYPE S. ALL DOOR DIMENSIONS ME NET FRAME CLEAR OPENING SIZES. PROVIDE REWIRED CLEARANCES PER DETAILS MD MFR/INQUSTK STANDARDS. S. ALL DOORS SHALL BE SOLID CORE EXTERIOR GRADE. PAINTED WOOD AND D SHALL BE 3'-0' WIDE. VERIFY EIDSIING NCICINIS TO FIELD CONOITIOMS. II�t� 1. CONDUCTOR SHALL MODIFY ALL SWITCH AND RECEPTACLE HEIGHTS TO COMPLY WITH 'ELECTRICAL! MOTES SHOWN ON SM, A-5 THROUGOUT THE FACILITY. 2. PRONE CA DEUCES AT RESTROOMS AMID KITCHEN. DRB SHIM GENERAL NOTES NONE I L PROJECT NUMBER 6376.05 GN-3 KEYED NOTES a '4; NOTE: FOR KEYED NOTES SEE SHT. A-1 7 q=5 _ 7 1/2" DIA. SM. RAILING 3 LEGEND EQUALLY SPACED , In• / I t I/2" CIA. STD. PIPE HANDRAIL Rp1tC101Rm SICM ACCESSIBLE PATH OF TRAVEL MTH MAX. ��-vy `'' 6 W/ 5/8' DIA. STL BAR BRACKET WELDED TD EA. BALUSTER - 600 CROSS SLOPE OF 2% & uAX. SLOPE IN / .� < DIRECTION OF TRAVEL OF 5x CONTRACTOR SHALL INSPECT AND - o 1/2' FIBROUS EXP. JT. FILLER REPAIR EXISTING PAVED SURFACES FOR "WALKS ^�'�' 1. 1t 1; i1 o w/ POLYURETHANE SEALANT AT WALL & ADJOINING SURFACE (E) COMPLIANCE TO ANIDjrtWALKV" 1: 11 17 1 NOTES ON SHT. A-5 AND'ORIND, REPAR INB'E CE 16 N " MED. BROOM FINISH O CONG ` E aar+axAo /Anne tnml OR REPLACE EXISTINC'PAVING'A5 REQUIRED FOR COMPLIANCE. 1. -. 1 1; .a r, i _ t 7/2" DIA. XS BALUSTERS- srza tnaN¢ — 10' _ NON -SHRINK GROUT 'I j ' q w++l rtsT� %5 - C-6 ' 4 ¢ /3 O 18' O.C. EA. WAY O SLAB } Wlil G GYV. Ts • rx�x,/x R H—"-- FIELD VERIF ; 6 i /4 NOR- O TOP & BOTT. v¢uD a o0 `J to S. NOTE: ALL HANDRAILS, GUARDRAILS & 1 2 POSTS SHALL BE GALVANIZED �. 5 9 CONC. WALL W/ LIGHT SANDBLAST ..... FlNISH. PROWIDE % DEEP EDGE ATT B BOTTTT OM OF WALL L �•%�/ LANDS APE (E) 57C MAX. / COMPACTED FILL TO SIDE BELOW 2' 6" RAMP & FOOTING S 2% MAX. 11 i^I / �;!/ a cRoss SLOPS 14 ,i/;;y to GUARDRAIL ®RAMP DTL. 2 DIRECTIONAL SIGNAGE DETAIL --... .... _. `" m �i 4 / ✓ `: '; m SPT 9ME1 1/2.-1•-0. SP1 mM[•NONE x, TING P 1 SITE PLAN SPT $CVi'i/16'-t'-0' _ s PR�OV�iDE CONCRETE FOpTN AS REQUI FOR SECURE AND 1-9• PERMANENT INSTALIATON 2/SP-1 0 AIL SIGNS MLL BE LOCATED IN LANDSCAPED D PAVED AR S. CORING IN PAVED AREAS MAY BE RE . CQN CTOR SHALL FIELD 7 B' ]1 ~ 27 I I ... LI 4'-3 1/2" 3'-1 1/2" 2'_9• 47- 1/2 4-3 1 SURVEY LOCATIONS (� REF11iECTORIZEO SIGN ] C .., 2•_8 /y 4'-3 1/ " 4'-3 t/ ' � ,✓— / p" ROVIDE i• ptp 125 ALUMINUM PANEL, FINISH BLUE, BOTH FRONT AND BACK t 14 ;' ":. t -� � �I Jf. FILLER W/ CAULKING BE7WEt?T RAMP E%15HNG WALL OF COPY &SIGN RESTRICTED SIGNAGE - n �.i NItlO FIAb & b 4uynl4 I � p1 PONDER -COATED SYMBOL & COPY, HELVETICA CONDENSED BOLA & R 17 :. ..-.. 1'-0' a SEE w r FMIM AM SCOTCNCAL ELECTROCUT FILM, '.�•�•.•.;: '• 7 - e �pw Y n WHITE TYPICAL. ALL COPY ----• I I SPl x�plro wMdN T1�aald� ndeYM 1 A _ _ D 14 Q b . I TeFnawB l mss slax --- n , y o r _ IN t Tal eTs La NU > ,6 9y �' _- ... 0' -8. _O'- 3' O.D. HEAVY GAUGE Y MIN. LOWER CAS E RADIUS CORNERS 1/4• (�') i ...._ a : I .. Jp•_6• 7'_y � POST. POWDER LETTERS .::.' .. • 4'-3 7/2' 4'-3 1/2' 4'-3 1/2' 4'-J 1/2' COATED, BLUE W/ POST CAP H v : � w : • .0 0 4'-3 1/2' 4'73 1/2 1-3 1/1 PROVIDE LEVEL FIN. GRADE i` LANDING O SIOPEC1 Lu ) A i•_p• ,o it BOTT. OF RAMP (2% SLOPE IN SLOPE YM..S1t—M. �'• DIRECTION) D _Bj S'-4' 8' •' A- SW TO OPAAi ro ":.. AVgDNO PUOOLIN' AT LLHAY T•. pw mgo,N ANTILBOR TI.1%V101M10 JI AM. ✓?i 1'-p' I ELEVATION '— w� 'w p' g• o 5 RAMP PLAN &ELEVATIONS ^ I �51 SIGNAGE POST DETAIL & NOTES _ %61 RESTRICTED PARKING SIGNAGE W SP1 SCAIL AS NOTED 41' x' N I4• '-B 1/2" SpT 9CtlE: NONE SP7 SCALE: NONE K mAP+ac WALE: , •.I'-o' ENGINEER ORB LAKE VIEW COMMUNITY SCALE Q ' £ SlTI BaNP An, &Y1s,oa DESIGNER 17461 ZEIDER LANE CITY OF HUNTINGTON BEACH, CA. DRB CAD OPERATOR PROJECT NUMBER t^"1"pl°^8°'d'•Gs�wltK J 5 OB A N 1 ORB o u Cash Tt 0u7 ®6M1] &Associates Fa OuIIBs,N1 RHM CHECKER RHM SITE PLAN &DETAILS 6376.05 t 07 ISSUED FOR BID DRB NO. DATE DESCRIPTION BY DRAWNG NUMBER REVISIONS PROJECT MANAGER RHM SP-1 KEYED NOTES ® 1 INSTALL NEW GRAB BAR NTH BLOCKING EPAIR WAL FINISH FOR Tplii EBEFNSTA OR UNIFORM LLED AND MOUNTING GTS�/A-4 SOREIES TOAS ■ 14 17 2'-0' MIN. TYP, Q INSTA EN SUPPORTS 16 20 1 21 'O 22 3 PROVIDE NEW DOOR -SEE SHT CN-3 FOR ADDITIONAL NFORMATI _ REPLACE THRESHOLD -SEE 6 A-4. 4 INSTALL NEW HAND RAILS AT RAMP & STEPS - SEE 4/A4 INSTALL NEW KITCHEN CABINETS- SEE 2. 1/A-3 .. REs1ROOM © INSTALL NEW RAMP -SEE 1/A3 7 INSTALL NEW HANDRAILS SEE - 4 & 5/A-3 R - B NOT U D ENTRANCE SIGNAGE - SEE 3/A4 `� 7 10 1_6• 12 20 IB 230 KITCHEN ARME VA-3 10 RESTROOM SIGNACE- SEE 2/A4 NS ,. _ 11 pIRECDONAL SICNAGE FROM PARKING AREA�� _ MOUNT ALL TOILET ACCESSORIES IN ACCORDAN7 "`9`' 13 13 CONSTRUCT 2X4 NON -BEARING WALL FLOOR/CLC. 25 ' ' _ TH 5/B CYP BOARD FlN. EA. SIDE I 14 REPLACE SIDEWALK & CURB RAMP TO COMIFLY W/ 'WALKS AND SIDEWALKS' �. 44 A33 NOTES ON SHT. A-5 & OTLS 3, 3A & 4/A-5. SEE SHT. SP-1 FOR ADD'L 8 m24 . _ RAMP UP. 1:12 MAX, 4 Y `/ INFO. 3 -' pRO" 4' WIDE BLUE STRIPING O 3'-0' O.C. WITHIN OUTLINED ACCESS IN AREAS AND SIGNAGE O EXISTING PARKING FOR VAN ACCESSIBLE 8 ® J PARKING STALL -SEE 1/A5. 12'-0' MIN. 16 PROVIDE RE ICTED PARKING SIGNAGE AT ENTRANCE TO PARKING -SEE . '. 6/SP-1 __ 17 pROVIOE 4' C. WALK W/ B' THICKENED SLAB EDGES & MEDIUM BROOM 8 8 ® 7 7YP' 7NROUra+0U1 24 FINISH. SLOPE AWAY FROM BLDG. W/ MAX SLOPE OF 2X MAX SLOPE IN ■ DIRECTION OF TRAVEL SHALL BE 51 PROVIDE SAWCUT CONTROL JOINTS 1' ®A-3 228 9 1 4 15 I6 DEEP, MIN. O 5'-0- D.C. 17 tii SLF SP-1 1B R D N A E B VA -A RI AN T AR CM IR A `. ® ,� 17 r USERS LAVATORY. PROVIDE BACKING FOR HANGER AS REWIRED. INSULATE ®. _, AND LL HOT WATER AND DRAIN PIPING .. ® .. .. 0 _.__. ..._... _.._..._.. 19 NOT USED INSTALL 6'-0' HIGH FRP WAINSCOTING AT RESTROOMS THROUGHOUT ® ■ `_ 09 � S ' SIM. 21 PROVIDE NEW ACCESSIBLE TOILET CARpAA CARAV11lE 270 ADA 1A '1A T 5 SJ i`j J ,n® ❑u PROVIDE AMERICAN STD SILHOUETTE 33' SHALLOW, DBL. BOWL SINK, UNOERCOUNTER MOUNT W/ DELTA 959 FAUCET W/ PULL DOWN SPRAY . HEAD -SEE 1/A4 FOR CLEARANCE REQUIREMENTS AT SINK (WALL MOUNT NOTE: '� _ bL MU4 SLOPE . 17 .. ' FIRE 0 RELOCATE FIRE EXTINGUISHER, WITH FIRE DEPT. APPROVAL TO KEEP OBSTRUCTIONS OUT OF THE PRIMARY PATH OF TRAVEL FOR INFORMATION ON CONSTRUCTION Of NEW RAMP, SEE eSPV-11 24 PROVIDE 2- CONTRASTING, SUP -RESISTANT STRIPE AT TOP OF LANDING r ® m ®� ' ALL STAR N09NGS-TYPICAL THROUGHOUT �� . Q PROVIDE ALUM. SLIDING WINDOW AND SECURITY GRILL TO ALLOW FOR THE 11 _ INSTALLATION OF A NEW HANDRAIL REINSTALL WINDOWS AND SECURITY GRILLS AT RESTROOMS ALSO. NOTE: �b L2 REVISE HEIGHT OF ALL ELECTRICAL ® PROVIDE SLURRY SEAL AT PARKING AREA AS SHOWN ON SP-1. RECEPTACLES AND SWITCHES IN ACCORDANCE WITH NOTES ON SHT. FLOOR PLAN LEGEND 27 PROVIDE EXPANSION JT.--SEE FOR ADD'L INFO. 5 i GN-3 & A-5. S) $ME: 1/4•-1'-0- 28 REVISE THE HEIGHT OF ALL ELECTRICAL RECEPTACLES AND SNITCHES --SE ACCESSIBLE PATH OF TRAVEL WITH MAX CROSS SLOPE OF ®� ® 2% IN DIRECTION OF TRAVELOF 5X GN-3 FOR ADD'L INFO. &MAX SLOPE AND REPAIR EXISTING PAVED 29 PAINT INTERIOR AND EXT. COMPLETE IN ACCORDANCE WITH GN-3 NOETES. 8 CONTRACTOR INSPECT 'WALKS SURFACES FOR COMPLIANCE TO AND MEWALKS' NOTES ON SHT. A-5 AND GRIND, REPAIR OR REPLACE ® CONSTRUCT CONCRETE RAMP ACCESSIBLE RAMP -SEE 5/SP-1 6 EKISTING PAYING AS REQUIRED FOR COMPLIANCE -SEE ALSO „ SP-1 FORADO'. INFO. ENGINEER ORB LAKE VIEW COMMUNITY SCALE t Q 5T129atl. Avtl, eMr Lao DESIGNER ORB CITY OF 7HUNTINGT461 ON BEEAACEH. CA PROJECT NUMBER Nuntl�v�NtlrA.GP2Q40.tta4 T'tl 0'pt4l14l msaaTi 6J76.05 J O6ENDUM j 1 DRB CAD OPERATOR RHM 4 7 ISSUED FOR BID DRB ' Cash Associates Fnppslnt FLOOR PLAN CHECKER RHM DRAN1NC NUMBER N0. DATE DESCRIPTION BY O �K A-1 REVISIONS PROJECT MANAGER RMM DEMOLITION NOTES I I 26'-O' 32' 1• 5 i � AREA OF DEMOLITION -SEE NOTES BELOW 3 9 I 5 it 6 O PORTION OF RAISED FLOOR TO BE REMOVED -SEE A-1 FOR SEE SP-1 ADD L INFO. • PLANTER KITCHEN SINK AND COUNTERS TO BE REMOVED ELECTRICAL (E) ,C i (E) & STORAGE WOMENS ❑3 N07 USED 1 IRRIGATION ROOM RESTROOR 5 CONTROL (E) CRAWL SPACE ACCESS 1 REMOVE EXISTING DOOR, THRESHOLD, k FRAME - WIDEN FOR M. �.;. rzl I S A ATION OF S 0• IWDE DOOR AND FRAME AT RESTROOM KITCHEN REMOVE TOILET PARTITION tz EA CONC. I ❑T ` .' cl„' ` /'•(+,:, 7❑ RELOCATE EXISTING WINDOW AND SECURITY GRILL AS REQUIRED. $ i MEN$ 4,^"-.,._ri__�•. ,. „ RESTROOu \ O 'K•� a REMOVE EXISTING GU S 1 ii:j / REMOVE EXISTING CONIC SURFACE 6: LANDSCAPE AS REWIRED FOR INSTALLATION OF WALK --SEE ALSO SP-1 FOR ADDITIONAL k krr •I B E RAISED FLOOR E GUARD RAILS () () WALKWAYS, CURB RAMPS 8 CURB/GUTTER TO BE REMOVED. REMOVE FLOOR FINISH - tt 0 REMOVE AS REQUIRED FOR PLUMBING REVISIONS VE FLOOR OU C EVI • ••• 0 4 I 1 12 EXISTING STEEL COLUMN TO REMAIN + - •;%,*':'':•;'''` e / 3 atANh , I \ 73 REMOVE EXISTING WINDOW h SECURITY GRILL g LANDSCAPE / z \ TI REMOVE ALL TOILET ACCESSORIES A FRP AT RESTROOM tff o 0 g `i / s /'••,SEE .% s• L/ e S 1FOR� CONTINUATION x _ 11 RAISED 8 a" ,f1 %f Q t•-� `>5 >; 12 zr-s• , I I i I I g I I FLOOR PLAN � seve ,/P.Td �a " ENGINEER ORB LAKE VIEW COMMUNITY SCALE Q SIl]I,WU Av., sM4100 N"'m"cla^aaa�. CASmta„�I 17661 ZEIDER LANE CITYOF HUNTINGTON BEACH. CA DESIGNER ORB PROJECT NUMBER 3 5 OeDENDUM / 1 DR8 CAD OPERATOR RHM rr: pMt 119SAT3 e378.05 1 07 ISSUED FOR BID DRB '¢ R a Cash Associates Fa: ptQei6-t39t DEMOLITION PLAN CHECKER RHM DRAWING NUMBER N0. DALE DESCRIPTIDN BY D-1 REVISIONS PROJECT MANAGER RHM NOTE: ----- ------ - ---------- -------- - KITCHEN CABINETS SHALL BE PAINT GRADE CABS. W/ PLATIC LAM. COUNTER TOP. (E) BX10 (E) 4X14 CABINETS SHALL CONFORM TO WOODWORK INSTITUTE REQUIREMENTS FOR FACE FRAME, MULTIPLE SELF-SUPPORTING UNITS, CUSTOM GRADE UNITS WITH FULL OVERLAY DOORS AND CONCEALED HARDWARE AND PULLS I Arnc� � V-0' i I O.0 III \ KITCHEN AREA (E) BEARING i WALL i0 REMAIN (E) HANDRAIL �� i TO REMOVE + NEW RAILINGS b I SEE 4/A4 a ✓I - 25' MAX ' 14'-0' CLR. MAIN MEETING ROOM _ ... .. REMOVE . EXISTING i 5/8- PLYWOOD I .. RAISED iIDDR %12 k SHl'C O (E) 2X12 O 12" O.0 e Om '• E �, RIM JOil IST •+: �' C TO REMAIN -•y _ (N) ?-, (E) 3%4 T tr DECK'C I,I (E) PIER O V-10 O.0 8 1 INTERIOR RAMP SEC710 /-2"*N INT. KITCHEN ELEVATION �_31INT. KITCHEN ELEVATION q-3 Y.,VE 1/2'=f 0' A-3 SCALE 3/4'-V-D' A-J SCAIL 3/4"=1'-0' g 8 $ -1/2' STL PIPE 1 RAILING RAIL -SEE tA/SP-1 FOR .��. QADD'L. INFO. Iq�F��'I ) I NON -SHRINK GROUT 3/8' CALV. STL PLATE I 6 WELDED TD BALUSTERS W/ '^ 3/8- STIFFENER ATMIDPOINT AS / STL. HANDRAIL SHOWN -PAINTED FINISH t 1A STL. PIPE SLEEV PI Sv L ` TREAD �� 1'-0' (GALV) STL PUTS i n \ \�\ 12' w D CAP F. ,CONCRETE ^ _ '-- FIN FAC a — 37 - ---------- -: _ PAINT 2' WIDE NON -SLIP. n WARNING STRIPE AT NOSING iln OF ALL TREADS @ LANDING IN CONMASTING COLOR. y 5 E t5 \TYP. FOOTING GUARDRAIL DETAIL (3) HANDRAIL ELEVATION/RAMP SECTION 6 HANDRAIL EXTENSION DETAILS 7 HANDRAIL EXTENDED AT RAMP A-3 ScuE: 3 4_3 STNE I/2'-t'-O' A-3 SCALE t/2'-1'-O' A-3 SME 3/8'-1'-0' S ENGINEER DRB LAKE VIEW COMMUNITY scaLE 0 um 5772e .A-s im DESIGNER 17461 2EIDER LANE CITY OF HUNTINGTON BEACH, CA. DRB pROJECi NUMBER ADDENDUM / 1 ORB 1finBnR°inewd'•GA>12ta>11M CAD OPERATOR AIL CHECKER ,BBSf1 Cash & Associates I 6J78.05 2 07 ISSUED FOR BID DRB NO. DATE DESCRIPTION BY RHM DETAILS DRAWING NUMBER REVISIONS a PROJECT MANAGER RHM A-3 IIIIIIIIIIIIU 4 t t 5'-4' 6 t WEST ELEVATION SIM. 6_ _ A-2 SGMF i/4'et•_O• KEYED NOTES NEW DOOR FOR ACCESSIBILITY COMPLIANCE -REPAIR ADJACENT SURFA AS REO'D. FOR UNIFORM APPEARANCE INSIDE @ OUT. PAINT ENTIRE WALLS TO MATCH EXISTING. RELOCATE WINDOW k SECURITY GRILL FOR NEW DOOR WH R . ❑2 INSTALL DALY. RAIUNG/GUARDRAIL W/ PAINTED FINISH -COLOR BY OWNER. ❑3 NEW ACCESSIBILITY SIGNAGE AT RESTROOMS AND ENTRANCE -SEE 2 t S/A-4 ❑4 PROVIDE DIRECTIONAL SIGNAGE TO MAIN ENTRANCE FROM PARKING AREA -SEE SP7 FOR ADD'L INFO. Q PRONDE NEW WINDOW WITH SECURITY BARS TO MATCH EXISTING. PAINT TO MATCH. © CONSTRUCT CONCRETE RAMP -SEE 5/SP-1 FOR ADVL. INFO. 5: & " a ^ u a g 5772llo Aw gum 1. IWn Q-6w 1GAY7B1i1191 ra:0'uI lwsaw Fv:(Tt4)CYS129t Cash Associates LNUNLLR DRB DESIGNER DRB LAKE VIEW COMMUNITY - 17461 ZEIDER LANE CITY OF HUNTINGTON BEACH. CA. SCALE D 08 ADDENDUM / 1 DRB CAD OPERATOR AIL LHECICER EXTERIOR ELEVATION AND HANDRAILS PROJECT NUMBER 6.T7B.05 4 2 07 ISSUED FOR BID DRD N0. DATE DESCRIPTION BY RHM PROJECT MANAGER RHM DRAWING NUMBER A-2 REVISIONS X 1 1/2' DIA INSULATE ALL GRAB BARS EXPOSED HOT 12•MAX. 42•MIN. WATER AND TOILET POPE MOLDER WM WASTE PIPES 36'MAX. STOPS i BOTT. OF BOWL Z 12'2�j 11 J i DOC 1 2 n v 17' TO 19 4B' CLR. MAX. 7OE coos.. WALL OR FLOOR -MOUNTED WATER CLOSETS p TOILET ACCESSORY SCHEDULE NO. I ACCESSORY MFR. MODEL NO. 1 DESCRIPTION ra PAPER TOWEL DISPENSER BOBRK'K 9-3699 SURF. MID. S.S. PAPER TTMEL DISPENSER SEAT WAR DSP, BOBRK.K B-221 SURF. MM SATIN-r*m mmus5 on UNR © COAT HOOK BOBRICK 8-671 SURF. MID. SS COAT HOOK WALL MID. SOAP DISPENSER BOBRICIT 8-2111 WKL MID. UOID SOW 119-537t © GRAB BARS BOBRX:K B-68137 , , / rm4o nK/,IouWIM) NI7ImT, lxous nRtE A,Os4 M ■YL DBL ROLL TOILET TISSUE DISPENSER BOBRCK B-265 SURFACE WrD. ROLL DISPENSER A MIRROR BO rK 8-PISS TN8 CHANNEL FRAME MIRROR (24X48) ® FLOOR STANDING WASTE RECEPTACLE BOBRICK B-2250 SATIN-FNISH STAINLESS STEEL A I — —DOR BOBRIOT B-282 25 SURFACE MID, NAPKIN DSPOSLL 8O6RKTT 8-754 SURFACE NfC COVER -- h W,ISTE -WASTE TOWELS DRYER NAPKINS HOOICSyV� REQUIRED }0' r-----1 f CLEAR SPACE 14' I----1 MIN. I I .. i I I r___� REQUIRED ®.. .. ._ .... .'0.. .. D..0 1 1 ' MIN. CLEAR SPACE o 0 WALL -HUNG OR 2i I , COUNTERTOP UV. 1 I II 11 I I WALL MID. LAV URIN R-ESTROOM ACCESSORIES t PLUMBING & ACCESSORY MOUNTING HEIGHT REQUIREMENTS FOR DISABLED ACCESS -4 SCALE: NTS 1166 SAN SERIF UPPERCASE LETTERING IYP. � a •��i WOMEN WALL MOUNTED SIGNAGE TO BE LOCATED ON LATCH SIDE OF UNSIX DOOR CLEAR OF DOOR -SWING. MOUNT AT 60' TO CENTERUNE OF SIGN FROM FLOOR. ING DOOR -MOUNTED SIGNAGE , L UPPERCASE CHARACTERS r2-'N WALL & DOOR MOUNTED SIGNAGE P. A-4 SCALE: NTS REVISIONS S. 4 F.F. Ii4TE: 1. WHERE PERMANENT IDENTIFICATION IS PROVIDED FOR ROOMS AND SPACES, RAISED LETTERS SHALL BE PROVIDED AND SHALL BE ACCOMPANIED BY BRAILLE 2. SIGNS SHALL BE INSTALLED ON THE WALL ADJACENT TO THE LATCH OUTSIDE OF THE DOOR. WHERE THERE IS NO WALL SPACE ON THE LATCH SIDE INCLUDING AT DOUBLE LEAF DOORS, SIGNS SHALL BE PLACED ON THE NEAREST ADJACENT WALL PREFERABLY ON THE RIGHT. 3. MOUNTING HEIGHT SHALL BE 60' ABOVE THE FINISH FLOOR TO THE CENTER LINE OF THE SIGN. MOUNTING LOCATION SHALL BE DETERMINED SO THAT A PERSON MAY APPROACH WITHIN 3' OF SIGNAGE WITHOUT ENCOUNTERING PROTRUDING OBJECTS OR STANDING WITHIN THE SWING OF A DOOR. 3 WALL & DOOR MOUNTED SIGNAGE (TYP.) -4 SCALE: NTS v 1/2' SADDLE TYPE 5 1/2' THRESMOLLD 158-A NO 158- 5' AULK PEUKO 1565-A A B FACTORY PROVIDED \ SCREWS -TIP. A PEMKO R1OSS A.31' & B-154' R.75OSS A-7• & B-9j' RSCSS Aa3r & Dm12d' 6%61 THRESHOLD DETAILS kA-4J SCALE: NONE a axcno omne .aa mrx rnmxo WYl mnnnlnuN 11NL MMC11[f At .'d o.t. Alf. HANDRAIL BRACKET A u 3 10 I B Icn.a, .AA m •ALL i, xwouA uAav 04 -/ \91 TYP. 2 9/16' 3/6' X 3- LAG SCREW-TYP. VINTO 6X BLK•G BELOW ;0, 4 A BASE PL DETAIL SCALE: NONE KEYED NOTES. - CD 1 1/2' DIA PIPE RAIL & BALUSTERS -PAINT, COLOR BY OWNER Q RETURN HANDRAILS) AS SHOWN Q SEE 1-----4 FOR HANDRAIL ATTACHMENT TO WALL w� U _mil J� n PEMKO RAMP R.SFAK SCALE: 1 um 6T736eM. Aw, L,b 100 TK 14) S T2 "M"'N Cash & Associates Facn,o69s,29, HANDRAIL AT TOP OF STAIR a•.Tc n•.r-e• - ,KUP wcm a stiff •, onw KM1KW ro �u , ,/r a. atr. • rwno s1� xweKul }}16� ,.,Dolt Wuca7 $3 A HANDRAIL AT BOTTOM OF STAIR 5 HANDRAIL _DETAILS -4 SCALE: NONE LAKE VIEW COMMUNITY ISCALE 1 7 DETAILS :CT NUMBER 6378.05 ING NUMBER A-4 8'-0' MIN. AISLE WIDTH REWIRED 1/2 RADIO BLUE 2A �AT'VAN ACCESSIBLE WHITE . . PARKING STALLS.' REFLECTORIIID SIGN I�IR MIN. N. CONSTRUCTED OFN 80_ MIN, FOR 4' WIDE BLUE PRCEUIN STEEL WITH BEADED TEXT nrIRFiJPW KNAr/nmqMFREE STANDING 36' MIN. FOR STRIPE OR EQUAL S6. WALL MQUNTED TO TOP OF WALKING S�ICt�H TO RE CENTERED SURFACE ANDICAPPED dSI THE INTERIOR END OF EMBLUST BE LOCATED PARKING SIGN. (�') S' U PARKING SPACE AREA OF SIGN TO BE IN STALL SO THAT IS VISIBU BY A TRAFFIC ENFRCEMENT 5'-0' CONC. - A MIN. R 70 50. IN. OFFICER WHEN A VEHICLE IS pi BUMPER DESIGNATE FOR PROPERLY PARKED IN THE SPACE (CENTERED AT 4" WIDE BLUE STRIP ��Il�\\\ VAN ACCESSIBLE' WHERE APPROPRIATE ENTRANCE TO STALL.) FORCROSS DeDIl TALI'_ CDe(`L" crrnle('_G DFNCRAI OI RARI FD PARKING SPACE NOTES: i) DISABLED PARKING SPACE MUST PERMIT USE OF EITHER CAR DOORS. 2) A PARKING BUMPER IS REQUIRED WHEN NO CURB OR BARRIER IS PROVIDED WHICH WILL PREVENT ENCROACHMENT OF CARS OVER THE ADJOINING ACCESSIBLE ROUTE. 3) WHEELCHAIR USERS MUST NOT TO BE FORCED TO 00 BEHIND PARKED CARS OTHER THEN THEIR OWN TO ACCESS AN ADJOINING ACCESSIBLE ROUTE. 4) THE MAXIMUM SURFACE SLOPE WITHIN THE DISABLED PARKING SPACE AND ADJACENT ACCESS AISLE MAY NOT EXCEED 2% IN ANY DIRECTION. 5) CURB RAMPS MAY NOT ENCROACH INTO THE REQUIRED DIMENSIONS OFDISABLED PARKING SPACES R ADJACENT ACCESS AISLES. OACCESS AISLE (LOADING/UNLOADING AREA) MUST CONNECT TO AN ACCESSIBLE PATH R TRAVEL TO THE FACILITY. ACCESSIBLE PARKING t SCALE 3/16' - V-0' - SCALE: 1/2" - 1'-0' \� NOTE: BUILT-UP RAMPS ARE NOT ALLOWSO TO ENRROACH INTO LOADING ZONES. PARKING SPACES OR VEHICULAR TRAFFIC LANES >Ty. LEVEL k CLEAR AREA ti NOT TO EXCEED 2% GROOVED BORDER MUST BE R THE LEVEL SURFACE AT CROSS SLOPE IN THE TOP R RAMP ANY DIRECTION 1 s MOTEL 1RUNCAIED DOME d, DETECTABLE WARNING SURFACE IS 1 REQUIRED ON SHADED PRTIR OF THE RAMP WHEN SLOPE IS BETWEEN 5.0% AND 6.67X BUILT-UP CURB RAMP SCALE N.T.S. ACCESSIBLE PARKING & ALL WALKS WITH CONTINUOUS GRADIENTS SHALL HAVE LEVEL AREAS AT 5. 1. IM EACH PARKING AREA. A BUMPER R CURB SHALL BE PROVIDED AND LEAST 5' IN LENGTH AT INTERVALS R AT LEAST EVERY 400'. LOCATED TO PREVENT ENCROACHMENT OF CMS OVER THE REQUIRED WIDTH OF WALKWAYS. y, WALKS, SIDEWALKS, AND PEDESTRIAN WAYS SMALL BE FREE OF 6 AN ADDITIONAL SIGN SHALL ALSO BE POSTED, IN A CONSPICUOUS PLACE, GRATINGS WHENEVER POSSIBLE. FORGRATING$ LOCATED IN THE SURFACE OF MY OF THESE AREAS. GRID OPENING$ IN GRATINGS SHALL AT EACH ENTRANCE TO OFF-STREET PARKING FACILITIES. R BE LIMITED TO 1/2' IN THE DIRECTION R TRAFFIC FLOW. IMMEDIATELY ADJACENT TO AND VISIBLE FROM EACH STALL ORSPACE CURB THE SIR SHALL VE NOT LESS THAN 17' BY 22' IN SIZE WITH LETTERING RAMPS 7, NOT LESS THAN 1' IN HEIGHT, WHICH CLEARLY AND CONSPICUOUSLY 1 STATES THE FOLLOWING: UNAUTHORIZED VEHICLES PARKED IN TRANSITIONS FROM RAMPS TO WALKS, GUTTERS. R STREETS SHALL BE DESIGNATED ACCESSIBLE SPACES NOT DISPLAYING DISTINGUISHING AND FREE OF ABRUPT CHANGES. PLACARDS ORLICENSE PLATES ISSUED FORPERSONS WITH DISABILITIES MAY BE TOWED AWAY AT OWNER'S EXPENSE. TOWED VEHICLES MAY BE RECLAIMED AT OR BY TELEPHONING 2 MAXIMUM SLOPES OF GUTTERS, ROAD SURFACE IMMEDIATELY B. ADJACENT TO THE CURB RAMP OR ACCESSIBLE ROUTE, SHALL NOT NOTE: BLANK SPACES ARE TO BE FILLED IN WITH APPROPRIATE EXCEED 1:20 WITHIN 4' OFTHE TOP AND BOTTOM OF THE CURB RAMP. INFORMATION AS A PERMANENT PART OF THE SION. THE SLOPE R THE FANNED OR FLARED SIDES R CURB RAMPS SHALL NOT EXCEED 1 VERTICAL TO 10 HRIZONTAL WALKS AND SIDEWALKS I. WALKS AND SIDEWALKS SHALL HAVE A CONTINUOUS COMMON SURFACE, NOT INTERRUPTED BY STEPS R BY ABRUPT CHANGES IN LEVEL EXCEEDING 1/2'. 2. WALKS AND SIDEWALKS SHALL BE 48' MINIMUM IN WIDTH. 3. MEN CHANGES IN LEVEL NOT EXCEEDING 1/2' OCCUR. THEY SMALL BE BEVELED WITH A SLOPE NO GREATER THAN 1:2. EXCEPT THAT LEVEL CHANGES NOT EXCEEDING 1/4' MAY BE VERTICAL 4. ABRUPT CHANGES IN LEVEL ALONG ANY ACCESSIBLE ROUTE EXCEEDING 1/2" SHALL COMPLY WITH THE REQUIREMENTS FOR CURB RAMPS. 5. WALK AND SIDEWALK SURFACES SHALL BE SLIP -RESISTANT AS FOLLOWS: A. SURFACES WITH A SLOPE R LESS THAN B% GRADIENT SHALL BE AT LEAST AS SLIP RESISTANT AS THAT DESCRIBED AS A MEDIUM SALTED FINISH. S. SURFACES WITH A SLOPE R 8% OR GREATER GRADIENT SMALL BE SLIP -RESISTANT. S. WHEN THE SLOPE IN THE DIRECTION OF TRAVEL OF ANY WALK EXCEEDS 1 VERTICAL TO 20 HORIZONTAL. IT SHALL COMPLY WITH THE PROVISIONS REQUIRED OF A PEDESTRIAN RAMP. 7. WALK AND SIDEWALK SURFACE CROSS SLOPES SHALL NOT EXCEED 1/4' PER FOOT. REVISIONS 3. CURB RAMPS SHALL BE LOCATED R PROTECTED TO PREVENT THEIR 9' OB57RLFCIIGN BY PARKED CARS. RAMPS (FXTFRTR R INTENIRI 1. HANORAILS ARE REOUIRED ON EACH SIDE R RAMPS THAT PROVIDE ACCESS IF THE RAMP SLOPE EXCEEDS V RISE IN 20' OF HRIZONTAL RUN DOORS 1. MANUALLY OPERATED EDGE R SURFACE -MOUNTED FLUSH BOLTS AND SURFACE BOLTS ME PROHIBITED. WHEN EXIT DOORS ARE USED IN PAIRS AND APPROVED AUTOMATIC RUSH BOLTS ME USED. THE DOOR LEAF HAVING THE AUTOMATIC FLUSH BOLTS SHALL HAVE NO DOOR KNOB ORSURFACE-MOUNTED HARDWARE. THE UNLATCHING OF ANY LEAF SHALL NOT REWIRE MORE THAN ONE OPERATION. 2. LATCHING AND LOCKING DOORS THAT ARE HAND ACTIVATED AND WHICH ARE IN A PATH OF TRAVEL SHALL BE OPERABLE WITH A SINGLE EFFORT BY LEVER TYPE HARDWARE, BY PANIC BARS. PUSH-PULL ACTIVATING BARS. R OTTER HARDWARE DESIRED TO PROVIDE PASSAGE WITHOUT REQUIRING THE ABILITY TO GRASP THE OPENING HARDWARE. L HMO -ACTIVATED DOOR OPENING HARDWARE SHALL BE CENTERED BETWEEN 30' AND 34' ABOVE TIE FLOOR. 4. WHEN INSTALLED, EXIT DOORS SHALL BE CAPABLE OF OPENING SO THAT THE CLEAR WIDTH R THE EXIT IS NOT LESS THAN 32'. 45' Ai TOP 1.67' APPROX. 90' /4 AT BASE Ad" 2.3T5" Wi GROOVED 20' T. BORDER OETAtl TRUNCATED DOMES TAPERED TRUNCATED DOMES SMALL CONTRAST VISUAL Y EDGES WERE FROM SURROUNDING SURFACES & SHALL BE SEC71ON EXPOSED DSA-AC APPROVED. 0 PLANTER R OTHER j NONWALKING SURFACE (S j PROVIDE GROOVED BORDER AT TOP OF CURB RAMP -SEE s � PROVIDE TRUNCATED DOMES E FULL WIDTH R CURB RAMP -SEE NOTE: IF X IS LESS THAN 48', THEN THE SLOPE OF FANNED R FLARED SIDE MAY NOTE: CROSS SLOPE OF LANDING AREA NOT EXCEED 1:1I! &MA= 1� dI DOES NOT EXCEED 2% IN ANY DIRECTION 11u + 1:12 MAX. BEVELED LIP GROOVED eoaPER I `* a 1/2' MAX TYP. MUST BE ON THE N LEVEL SURFACE .' 1: 20 MAX AT THE TR 6 THE RAMP NOTE: TRUNCATED DOME : _4 '•',+: :.' :` 1� 1 10 SOX AND 8.679 CURB -CUT RAM n RETURNED CURB CURB RAMP DEL. a SCALE N.T.S. SCALE NONE - FOR MINCED DOOR£ THE OPENING WIDTH SMALL BE MEASURED WITH THE DOOR POSITIONED AT AN MOLE OF 90 DEGREES FROM ITS CLOSED POSITION. WHERE A PAIR DOORS DOS IS UTILIZED, AT LEAST ONE OF THE DOORS SMALL PROVIDE A CLEAR. UNOBSTRUCTED OPENING WIDTH OF 32' WITH THE LEAF POSITIONED AT AM ANGLE OF 90 DEGREES FROM ITS CLOSED POSITION. THERE SMALL BE A LEVEL AND CLEAR FLOOR R LANDING ON EACH SIDE OF A DOOR. THE LEVEL AREA SHALL HAVE A LENGTH IN THE DIRECTION OF DOOR SWING OF AT LEAST 60' AND THE LEMON OPPOSITE THE DIRECTION OF DOOR SWING OF 40' AS MEASURED AT RIGHT ANGLES TO THE PLANE OF THE DOOR IN THE CLOSED POSITION. THE WIDTH OF THE LEVEL AREA ON THE SIDE TO WHICH THE DOOR SWINGS SMALL EXTEND 24' PAST THE STRIKE EDGE R THE DOOR FOR EXTERIOR DOORS, IV PAST THE STRIKE EDGE FOR INTERIOR DODRS AND 35' ON THE PULL SIDE OF THE DOOR MEN THE APPROACH IS LIMITED FROM MINCE DIRECTION ON THAT SIDE THE FLOOR R LANDING SHALL BE NOT MORE THAN 1/2' LOWER THAN THE THRESHOLD OF THE DOORWAY. 10. MAXIMUM EFFORT TO OPERATE DOORS SHALL NOT EXCEED 8-1/2 POUNDS FOR EXTERIOR DOORS AND 5 POUNDS FOR INTERIOR ODORS. SUCH PULL EFFORT PUSH EFFT BEING APPLIED AT RIGHT ANGLES TO HINGED DOORS AND AT THE CENTER PLANE R SLIDING R FOLDING DOORS. COMPENSATING DEVICES R AUTOMATIC DOOR OPERATORS MAY BE UTILIZED TO MEET THE ABOVE STANDARDS. WHEN FIRE DOORS ARE REQUIRED, THE MAXIMUM EFFORT TO OPERATE THE DOOR MAY BE INCREASED TO THE MINIMUM ALLOWABLE BY THE APPROPRIATE ADMINISTRATIVE AUTHORITY. NOT TO EXCEED 15 POUNDS. FT.00RS AND 1 FyFLS 1. CHANCES IN LEVEL UP TO ve MAY BE VERTICAL AND WITHOUT EDGE TREATMENT. 2. RANGES IN LEVEL BETWEEN 1/4' AND 1/2' SHALL BE ACCOMPLISHED BY MEANS OF A RAMP NO STEEPER THAN 1 VERTICAL TO 2 HORIZONTAL 3. IF CARPET OR CARPET TILE IS USED ON A ROUND OR FLOOR SURFACE. IT SHALL BE SECURELY ATTACHED. NAVE A FIRM CUSHION. PAD R BACKING OR NO CUSHION OR PAD. AND HAVE A LEVEL LOOP, TEXTURED LOON. LEVEL CUT PILE. OR LEVEL CUT/UNWT PRE TEXTURE THE MAXIMUM PILE HEIGHT SMALL BE 11 EI(POSED EDGES OFCARPET SMALL BE FASTENED TO FLOOR SURFACES AND HAVE TRIM ALONG THE ENTIRE LENGTH R THE EXPOSED EDGE CARPET EDGE TRIM SHALL COMPLY WITH NOTE 2 ABOVE. ST2IINv Aw, &Mb 100 Tw!T4WIB 2v GA91Na11N ' TN: (T14189iAl2 Cash & Associates FAA:(714)119a,291 RHM 4. IF GRATINGS ARE LOCATED ON FLOORS. MEN THEY SHALL HAVE SPACES NO GREATER THAN 1/2' WIDE 1N RE DIRECTION. IF RATINGS HAVE ELONGATED OPENING£ 7HEY SMALL BE PLACED SO THAT THE LONG DIMENSION IS PERPENDICULAR TO THE DOMINANT DIRECTION OF TRAVEL �ABDe AND PROTON miN - R e iS 1. OBJECTS PROJECTING FROM WALLS WITH THEIR LEADING EDGES BETWEEN 27- AND SW MOVE THE FINISHED FLOOR SHALL PROTRUDE NO MORE THAN C INTO WALK£ HALLS, CORRIDORS, PASSAGEWAYS. OR AISLES. 2. PROTRUDING OBJECTS SHALL NOT REDUCE THE CLEAR WIDTH OF AN ACCESSIBLE ROUTE R MANEUVERING SPACE. SIIBTTBWAYS 1. OPEN RISERS ARE NOT PERMITTED. SWING k IDENTIFICATION 1. ME INTERNATIONAL SYMBOL OF ACCESSIBILITY SHALL CONSIST OF A WHITE FIGURE R A OWE BACKGROUND. THE BLUE SHALL BE EQUAL TO COLOR NO. IW90 IN FEDERAL STANDARD S99b. 2. ALL BUILDING ENTRANCES THAT ARE ACCESSIBLE TO AND USABLE BY PERSONS WITH DISABILITIES AND AT EVERY MAJOR JUNCTION ALONG OR LEADING TO AN ACCESSIBLE ROUTE OF TRAVEL SHALL BE IDENTIFIED WITH A SIGN DISPLAYING THE INTERNATIONAL SYMBOL OF ACCESSIBILITY AND WITH ADDITIONAL DIRECTIONAL SIGNS. AS REQUIRED. TO BE VISIBLE TO PERSONS ALONG APPROACHING PEDESTRIAN WAYS. ELCTRTCAI 1. THE CENTER R ELECTRICAL AND COMMUNICATION SYSTEM RECEPTACLE OUTLETS SHALL BE INSTALLED NOT LESS THAN 15" ABOVE THE FLOOR R WORKING PLATFORMS. 2 THE CENTER OF THE RIP OF THE OPERATING HANDLE OF CONTROLS OR SWITONES INTENDED TO SE USED BY THE OCCUPANT OF THE ROOM R AREA TO CONTROL LIGHTING AND RECEPTACLE OUTLETS. APPLIANCES, R COOLING, HEATING, MD VENTILATING EQUIPMENT SHALL NOT BE MORE THAN 48' ABOVE THE FLOOR R WRKING PLATFORM. 3. THE CENTER OF FIRE ALARM INITIATING DEVICES (BOXES) SHALL BE LOCATED 48' ABOVE THE LEVEL OF THE FLOOR, WORKING PLATFORM, GROUND SURFACE. OR SIDEWALK. LAKE VIEW COMMUNITY ISCALE PROJECT NUMBER 63' ZI DETAILS & NOTES DRAWING NUMBER A-5 REV # SHT. ITEM DESCRIPTION 1 T-1 I Revised scope of work for project 2 Revised dates of drawings and revision nos. in index I GN-1 NO CHANGE 1 GN-2 NO CHANGE 2 Added "Electrical" notes ADDED 4'ACCESS AISLE AT HEAD OF PARKING WITH ASSOCIATED 1 STRIPING REVISED AND ADDED ADDITIONAL ACCESSIBLE STALLS TOTALLING 4 WITH 2 ASSOCIATED SIGNAGE AND PAVEMENT MARKINGS ADDED REMOVAL OF EXISTING WHEEL STOPS AND PROVISION OF NEW AT 3 ACCESSIBLE PARKING ADDED DEMOLITION OF EXISTING CONCRETE RAMP AND CONSTRUCTION 4 OF NEW AT WEST SIDE OF BUILDING ADDED DEMOLITION OF PAVEMENT AND CONSTRUCTION OF NEW AT 5 STREET, EAST, SOUTH AND NORTH SIDES OF BUILDING 1 SP-1 6 DEMOLISH AND RECONSTRUCT CURB RAMP AT ZEIDER AVE CONSTRUCT CURB RAMP FROM PARKING AREA TO SIDEWALK EAST OF 7 9 REVISED DIMENSION AND NOTES AT DTL. 2/SP-1 INCLUDED ACCESSIBLE PATH OF TRAVEL FROM ZEIDER AROUND NORTH 10 SIDE OF BUILDING TO NEW EXTERIOR CONCRETE BUILDING RAMP CALLED FOR SLURRY SEAL AT SPECIFIED PORTION OF PARKING LOT 11 ADDED DIRECTIONAL SIGNAGE FROM STREET AROUND NORTH-WEST SIDE 12 OF BUILDING FOR ADDITIONAL PATH OF TRAVEL IDENTIFICATION Am 1 ADDED NOTES 9-14 AND REVISED NOTE 4 SHOWED ADDITIONAL DEMOLITION AT AND ADJACENT TO BUILDING FOR 2 CONCRETE WALKS, LANDSCAPE, HANDRAIL/GUARDRAILS, & EXISTING EXTERIOR CONCRETE RAMP (NOTE 9) ADDED 2 DOORS TO BE REMOVED FOR COMPLIANCE TO ACCESSIBILITY 3 REQUIREMENTS THRESHOLDS AT ALL EXTERIOR DOORS TO BE REPLACED TO BE 4 REMOVED (NOTE 4) 1 D-1 REMOVE ALL FLOOR FINISHES (NOTE 10) ____5 L� ADDED NOTE FOR REMOVAL OF FLOOR AS REQUIRED FOR REMOVAL OF EXISTING PLUMBING AND INSTALLATION OF NEW AT RESTROOMS (NOTE 11) — ADDED NOTE FOR REMOVAL OF TOILET ACCESSORIES AND FRP AT 7 REMOVE WINDOW & SECURITY GRILL NEAR SOUTHWEST EXTERIOR STAIR 8 TO ALLOW INSTALLATION OF NEW WALL -MOUNTED HANDRAIL AT STAIR 9 |CLARF|EDEXISTING STEEL POST TOREMAIN REVISED NOTE 1 ADDING REFERENCE TO TOILET ACCESSORY SCHEDULE 1 ON SHT A-4 NEW REVISED NOTE 3 REFERENCING NEW NOTES FOR DOORS ON GN-3 & NEW 2 DETAIL 6/A-4 3 REMOVED NOTE 8 4 ADDED DETAIL REFERENCE AT NOTE 11 5 ADDED DETAIL REFERENCE AT NOTE 12 REVISED NOTE 14 REFERENCING WORK SHOWN ON SP-1 & DETAILS FOR 6 CURB RAMPS 7 REVISED NOTE 16 REFERENCING DETAIL 6/SP-1 REVISED NOTE 17 ADDING REQUIREMENT FOR SAWCUT CRACK CONTROL 8 JOINTS _ _ _9 REMOVED NOTE 19 REVISED HGT OF WAINSCOT AT RESTROOMS TO & FOR ALL WALLS, 10 REMOVING "AS REQUIRED" ADDED NOTES 23-30 & ASSOCIATED WORK (23 RELOCATION OF FIRE 1 EXTINGUISHER; (24) PROVIDING CONTRASTING STRIPE AT ALL EXTERIOR A-1 STAIR NOSINGS AND LANDINGS (25) PROVIDE NEW ALUM. SLIDING WINDOW TO ALLOW INSTALLATION OF RAILING BELOW AND ALL 11 ASSOCIATED EXTERIOR WORK; (26) PROVIDING SLURRY SEAL AT PARKING REFERENCED ON SP-1; (27) PROVIDING EXPANSION JOINT SHOWN ON DTL 1A/SP-1 (28) REVISING ELECTRICAL RECEPTACLE AND SWITCH HEIGHTS THROUGHOUT THE FACILITY; (29) PAINTING OF THE ENTIRE FACILITY INSIDE AND OUT; (30) CONSTRUCTION OF EXTERIOR RAMP 12 REFERENCED NEW DETAIL 1A/SP-1 ADDED BOXED NOTES CALLING FOR ELECTRICAL RECEPTACLE AND SWITCH HEIGHTS TO CONFORM TO ACCESSIBIITY REQUIREMENTS 13 THROUGHOUT THE FACILITY IDENTIFIED ON GN-3 AND ELECTRICAL NOTES ON SHT. A-5. ADDED ACCESSIBLE PATH OF TRAVEL AND ASSOCIATED WALKS FROM 14 THE NORTH AND WEST SIDES COMING FROM THE STREET _ 15 ADDED NEW EXTERIOR CONCRETE RAMP AND RAILINGS 16 REVISED CLEAR DIMENSION OF INTERIOR RAMP TO 4'-0" _ 17 ADDED3 CLARIFYING DIMENSIONS AT RESTROOMS 1 REVISED NOTE 1 TO COVER NEW DOOR WORK 2 ADDED NOTES 5 & 6 1 A-2 _ SHOWED NEW RAILINGS AT ALL ELEVATIONS WITH CLARIFYING 3 DIMENSIONS 4 SHOWED NEW RAMP SECTION AT SOUTH ELEVATION �� � k ➢S .. 3� ,:: � ... S.H �", -: S,rRC^f R.., $ � d� � ,G �k .'„s' � e�:' .„p"c'? 1 REVISED CLEAR RAMP REQUIREMENT AT INTERIOR RAMP-DTL 1 2 CLARIFIED FRAMING MEMBER AT INTERIOR RAMP AS RIPPED 6X 1 A-3 REVISED DETAILS 5,6 & 7 COMPLETELY -- CLARIFIED DIMENSIONS AT DTL 4, GALVANIZING REQUIREMENT FOR ALL 3 STEEL MEMBERS, AND HANDRAIL ADDITION TO GUARDRAIL CONDITIONS _.4 A-4 dx,' : .: 1 �•v"ITq '. s ,Zy R i J it ;.1 C. ADDED TOILET ACCESSORY SCHEDULE AND DETAIL 6 1 2 CLARIFIED TITLE OF DETAIL 4 1 A-5 1 ADDED DETAIL 4 VENDOR Hondo Company Inc VENDOR GTA Construction Inc VENDOR Caltec Corp VENDOR W E Oneil Construct Bid #08-0321 7141434-0104 714/256-1985 714/717-1638 310/643-7900 Lakeview Clubhouse NAME Bob Lloyd NAME Quyen Trinh NAME Hamid Ahghari NAME James Surdyk Improvements #MSC-439 TERMS: TERMS: TERMS: TERMS: DELIVERY DELIVERY DELIVERY DELIVERY �� [TEMyRESCR ION�ryf 5 - � � . , ; _ . - . .UNI7 COST ,., , � :. , � =-: �t�� .T.OTAL ,�-�����-,, �::- �,UNIT,�CQST� • _ .w �� � � - �� ^�.'_-�,. ..OTAL� =� y.zr. .� a NI`f^C .iJ �.._ OS �,,_ '�_ �•_, ...._ - _-��.. ®_:.v _ .._ _ .-...�-- .... �'. _. _ 1 Furnish/Install Restroom Appurt 34100.00 21000.00 37000.00 19804.00 2 Furnish/Install Kitchen Appurt 16800.00 19000.00 14000.00 8000.00 3 Furnish/Install Facets 28200.00 11000.00 8500.00 3250.00 4 Furnish/Install Handrails/Guardrails 7800.00 5000.00 33000.00 19400.00 5 Furnish/Install Concrete Areas 34400.00 35000.00 39500.00 34885.00 6 Furnish/Install Si na e & Markings 2500.00 5000.00 10500.00 3800.00 7 0.00 0.00 0.00 0.00 8 Bid Schedule Total 123800.00 96000.00 142500.00 89139.00 9 Lump Sum with Addendums 123800.00 129000.00 184000.00 196553.00 101 0.00 0.00 0.00 0.00 Hondo Com an Inc is low bid 0.00 0.00 0.00 0.00 over-all. I s oke with Bob Llo d 0.00 0.00 0.00 0.00 at Hondo re ardin lum sums 0.00 0.00 0.00 0.00 on bid schedule, Item #3 is hi h 0.00 0.00 0.00 0.00 P com ared to other vendors. 0.00 0.00 0.00 0.00 His addendums are included 0.00 0.00 0.00 0.00 in bid schedule. If we do decide 0.00 0.00 0.00 0.00 to only do partial Jobs we would 0.00 0.00 0.00 0.00 191 need to talk to Hondo before 0.00 0.00 0.00 0.00 20 awarding bid. 0.00 0.00 0.00 0.00 211 0.00 0.00 0.00 0.00 221 0.001 0.001 0.00 0.00 State of California Secretary of State ON. STATEMENT OF INFORMATION (Domestic Stock and Agricultural Cooperative Corporations) FEES (Filing and Disclosure): $25.00. If amendment, see instructions. IMPORTANT — READ INSTRUCTIONS BEFORE COMPLETING THIS FORM This Space For Filing Use Only 1. CORPORATE NAME (Please do not alter if name is preprinted.) S C0878545 HONDO COMPANY, INC. 2121 SOUTH LYON STREET SANTA ANA, CA 92705 DUE DATE: COMPLETE ADDRESSES FOR THE FOLLOWING (Do not abbreviate the name of the city. Items 2 and 3 cannot be P.O. Boxes.) 2. STREET ADDRESS OF PRINCIPAL EXECUTIVE OFFICE CITY STATE ZIP CODE 2121 SOUTH LYON STREET SANTA ANA, CA 92705 3. STREET ADDRESS OF PRINCIPAL BUSINESS OFFICE IN CALIFORNIA, IF ANY CITY STATE ZIP CODE 2121 SOUTH LYON STREET SANTA ANA, CA 92705 4. MAILING ADDRESS OF THE CORPORATION, IF DIFFERENT THAN ITEM 2 CITY STATE ZIP CODE 2121 SOUTH LYON STREET SANTA ANA, CA 92705 NAMES AND COMPLETE ADDRESSES OF THE FOLLOWING OFFICERS (The corporation must have these three officers. A comparable title for the specific officer may be added; however, the preprinted titles on this form must not be altered. 5. CHIEF EXECUTIVE OFFICER/ PRESIDENT ADDRESS CITY STATE ZIP CODE ROBERT LLOYD 2121 SOUTH LYON STREET SANTA ANA, CA 92705 6. SECRETARY/ ADDRESS CITY STATE ZIP CODE ROBERT LLOYD 2121 SOUTH LYON STREET SANTA ANA, CA 92705 7. CHIEF FINANCIAL OFFICER/ ADDRESS CITY STATE ZIP CODE ROBERT LLOYD 2121 SOUTH LYON STREET SANTA ANA, CA 92705 NAMES AND COMPLETE ADDRESSES OF ALL DIRECTORS, INCLUDING DIRECTORS WHO ARE ALSO OFFICERS (The corporation must have at least one director. Attach additional pages, if necessary.) 8. NAME ADDRESS CITY STATE ZIP CODE ROBERT LLOYD 2121 SOUTH LYON STREET SANTA ANA, CA 92705 9. NAME ADDRESS CITY STATE ZIP CODE 10. NAME ADDRESS CITY STATE ZIP CODE 11. NUMBER OF VACANCIES ON THE BOARD OF DIRECTORS, IF ANY: AGENT FOR SERVICE OF PROCESS (If the agent is an individual, the agent must reside in California and Item 13 must be completed with a California street address (a P.O. Box address is not acceptable). If the agent is another corporation, the agent must have on file with the California Secretary of State a certificate pursuant to Corporations Code section 1505 and Item 13 must be left blank.) 12. NAME OF AGENT FOR SERVICE OF PROCESS 13. STREET ADDRESS OF AGENT FOR SERVICE OF PROCESS IN CALIFORNIA, IF AN INDIVIDUAL CITY STATE ZIP CODE CA TYPE OF BUSINESS 14. DESCRIBE THE TYPE OF BUSINESS OF THE CORPORATION GENERAL ENGINEERING CONTRACTORS 15. BY SUBMITTING THIS STATEMENT OF INFORMATION TO THE CALIFORNIA SECRETARY OF STATE, THE CORPOR ION C TIRES THE INFORMATION CONTAINED HEREIN, INCLUDING ANY ATTACHMENTS, IS TRUE AND CORRECT. 7/01/08 ROBERT LLOYD PRESIDENT r DATE TYPE/PRINT NAME OF PERSON COMPLETING FORM TITLE IGNATURE SI-200 C (REV 01/2008) V APPR VED BY SECRETARY OF STATE ACTION BY SOLE DIRECTOR OF HONDO COMPANY, INC. The undersigned is the sole Member of the Board of Directors of Hondo Company, Inc., a California corporation ("Corporation"). The following action is hereby taken by resolution of the sole director, without meeting, and with respect to the following facts and circumstances: WHEREAS the Corporation had two shareholders since its inception; and WHEREAS the two shareholders were Michael Woods and Robert Lloyd; and WHEREAS the Corporation and Michael Woods are currently in negotiations for the Corporation to purchase and for Michael Woods to sell all of the shares in the Corporation owned by Michael Woods; and WHEREAS Michael Woods has resigned as the President and Member of the Board of Directors of the Corporation; and WHEREAS Robert Lloyd is the sole remaining director of the Corporation; NOW therefore the following action is hereby taken by Robert Lloyd as the sole Director of the Corporation: RESOLVED that the officers of the Corporation are as follows: Robert Lloyd — President Robert Lloyd — Secretary/Treasurer a Dated: July 7 , 2008 Pile MAI r r RESIGNATION OF MICHAEL WOODS AS A MEMBER OF THE BOARD OF DIRECTORS AND PRESIDENT OF HONDO COMPANY, INC., A CALIFORNIA CORPORATION I, Michael Woods, hereby resign as a Member of the Board of Directors of Hondo Company, Inc., and I hereby further resign my office as its President, effective immediately. Dated: July tl, 2008 ICHAEL WOODS File MUM HONDCOM-01 HIJE AC®RD CERTIFICATE OF LIABILITY INSURANCE DATE (M a" 6/25/2008YY, 2008 PRODUCER (888) 825-4322 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Bowermaster & Associates ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE P.O. Box 6026 HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. 10805 Holder Street -Suite 350 Cypress, CA 90630 INSURERS AFFORDING COVERAGE NAIC # INSURED Hondo Company, Inc. V _ INSURERA: Landmark American Insurance Co. 2121 South Lyon Street INSURER B: Golden Eagle Insurance Corporation Santa Ana, CA 92705- INSURER c: RSUI Indemnity Company INSURER D: COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSIR ADIYL POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATIONLTR INSRr. TYPE OF INSURANCE I LIMITS GENERAL LIABILITY EACH OCCURRENCE $ 1,000,00 A X X COMMERCIAL GENERAL LIABILITY CLAIMS MADE I-R] OCCUR LHA133136 6/1/2008 6/1/2009 pDRFMISES Ea oavrence $ 50,00 MED EXP (Any one person) $ 5,00 PERSONAL & ADV INJURY $ 1,000,00 GENERAL AGGREGATE $ 2,000,00 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMPIOP AGG $ 2,000,00 X7 POLICY X PRO- LOC B AUTOMOBILE X LIABILITY ANY AUTO BA8286843 6/1 /2008 6/1 /2009 COMBINED SINGLE LIMIT (Ea accdent) $ 1,000,00 BODILY INJURY (Per persOn) $ ALL OWNED AUTOS SCHEDULED AUTOS X BODILY INJURY (Per accident) $ HIRED AUTOS NON -OWNED AUTOS APP ED AS F X PROPERTY DAMAGE (Per accdent) $ GARAGE LIABILITY f 1,1 I IJR AUTO ONLY - EA ACCIDENT $ OTHER THAN EA ACC $ ANY AUTO $ AUTO ONLY: AGG EXCESSIUMBRELLA LIABILITY EACH OCCURRENCE $ 2,000,00 C X OCCUR CLAIMS MADE NHA221589 6/1/2006 6/1/2009 AGGREGATE $ 2,000,00 $ $ DEDUCTIBLE RETENTION WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETORIPARTNEWEXECUTIVE TT RYTAMTU- OTH- E.L. EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYEE u� $ OFFICEWMEMBER EXCLUDED? UN yes,descrihe under SPECIAL PROVISIONS below E.L. DISEASE - POLICY LIMIT , $ OTHER E l DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS 10 day notice of cancellation due to non payment of premium Re: Lake View Clubhouse City of Huntington Beach, its officers, elected or appointed officials, employees, agents, and volunteers are additional insured with respect to general liability per attached RSG15017 0307 (1185) form and in respects to Automobile Liability per form CA 20480299. City of Huntington Beach 2000 Main Street, Huntington Beach, CA 92684- SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATIO DATE THEREOF, THE ISSUING INSURER WILJWI Y8ft MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, N=XKKKJ=LL AUTHORIZED REPRESENTATIVE OCnRn w; l9nnitrim © ACORD CORPORATION 1988 HONDCOM-01 HIJE IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or after the coverage afforded by the policies listed thereon. ACORD 25 (2001108) LANDMARK AMERICAN INSURANCE COMPANY This Endorsement Changes The Policy. Please Read It Carefully - ADDITIONAL INSURED BLANKET - PRIMARY AND YOUR WORK This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM -- --- SCHEDULE Name of Person or Organization: The City of Huntington Beach, Its Officers, elected or appointed officials, (employees, agents and volunteers A. SECTION 11 - WHO IS AN INSURED is amended to include as an additional insured the person(s) or organization(s) shown in the SCHEDULE, but only with respect to liability for "bodily Injury', 'property damage" or "personal and advertising injury" caused, in whole or in part, by: .1. Your acts or omissions; or Z, The acts or omissions of those acting on your behalf; in the performance of your ongoing operations or "your worts' for the additional insured(s) designated above. B. If you are required by a written contract to provide primary insurance, this policy shall be primary and SECTION IV — COMMERCIAL GENERAL LIABILITY CONDITIONS. 4. Other Insurance does not apply, but only with respect to coverage provided by this policy. This endorsement effective 6/1l08 forms part of Policy Number LHA133136 issued to HONDO COMPANY, INC. by Landmark American Insurance Company Endorsement No.: 01 RSG 15017 0307 Includes copyrighted material of Insurance Services Office, Inc. 1984 (1185) with its permission POLICY NUMBER: BA8286843 COMMERCIAL AUTO CA 20 48 02 99 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.' DESIGNATE® INSURED This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM GARAGE COVERAGE FORM MOTOR CARRIER COVERAGE FORM TRUCKERS COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modi- fied by this endorsement. This endorsement identifies person(s) or organization(s) who are "insureds" under the Who Is An Insured Provi- sion of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Endorsement Effective: Countersign y: 6/1 /08 Named Insured: Hondo Company, Inc. A ized Re sentative SCHEDULE Vame of Person(s) or Organization(s)_ "he City of Huntington Beach, its officers, electedlappointed officials, employees, agents & volunteers (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to the endorsement.) Each person or organization shown in the Schedule is an "insured" for Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured Provision contained in Section If of the Coverage Form. CA 20 48 02 99. Copyright, Insurance Services Office, Inc., 1998 Page 1 of 1 13 ATTACHMENT #2 City of Huntington Beach �, a f�a j ,� � � �;, f �•LL Project# MSC-439 RFQ# 08-0321 Bid Proposal — Original Submitted By: _ : WE. O'Neil Construction Co. of California 909 N. Sepulveda Boulevard, Suite 400 El Segundo, CA 90245 (310) 643-7900 TABLE OF CONTENTS SECTION 1 Request for Quotation SECTION 2 Appendix I — Bid Schedule Qualifications SECTION 3 Similar Project Experience �W-E!01NEI City of Huntington Beach Lakeview Clubhouse Improvements Project No. MSC-439 RFQ# 08-0321 Request for Quotation PURCHASING DEPARTMENT City CITY OF HUNTINGTON BEACH 2000 MAIN STREET HUNTINGTON BEACH, CA 92648-2702 «Company» W.E. O'Neil Construction Co. of California «Address» 909 N. Sepulveda Blvd., Suite 400 cCitystzip» El Segundo, CA 90245 «Attn» ATTN: BRYAN PAVALKO 08-0321 Show this number on outside of your envelope. Date: January 28, 2008 Bids will be received until 4:00pm March 21, 2008 at the office of the Purchasing Division. Sharon Griffin sgriffin(a)su rfcity-hb.orq QUANTITY UNIT DESCRIPTION UNIT PRICE AMOUNT The City of Huntington Beach is accepting uotations for the Lakeview Clubhouse Improvements MSC-439per the following specifications. SEE APPENDIX I All Labor must be based upon prevailing wage. Bid Schedule must be submitted with bid. There will be a Job Walk on Wednesday, February 6, 2008 8:00 a.m. Prospective bidders will meet at the Lakeview Clubhouse, 17461 Zeider Lane, Huntington Beach. Any questions will be answered at this time. Any questions regarding the specification, exceptions or approved equals must be put in writing to the above buyer. if the bidder is responding from our Website you must notify the appropriate buyer, which is listed on the front page of the RFQ. This is to notify the bidder of any addendums that may occur during the bidding process. Quotations are requested for furnishing the items described in accordance with terms set forth herein. All quotations must be F.O.B. delivered. The detailed specifications or brand names or numbers given herein is descriptive and indicates quality and style of item required. Offer to supply articles substantially the same as those described herein will be considered provided the articles offered are equal in quality, durability, and fitness for the purpose intended. Acceptability of alternates will be determined solely by the City of Huntington Beach Delivery to be made on or before: within working or 40 days from receipt of order. Address you reply to: Purchasing Division City of Huntington Beach 2000 Main Street Huntington Beach CA 92648-2702 (714) 536-5221 All quiAations mus signed %ig ture James E. Surdyk Print Name Title Vice President Date March 21, 2008 Phone Number (310) 643-7900 THIS IS NOT AN ORDER Total $196,553.00 SalesTax included Total $196,553.00 Terms net % 30 days Email: bpavalko@weoneil.com EMAIL AND FAXED BIDS ARE NOT ACCEPTED 1tV PURCHASING DEPARTMENT CITY OF HUNTINGTON BEACH 2000 MAIN STREET HUNTINGTON BEACH, CA 92648-2702 tim acn.. REQUEST FOR QUOTATION «RFQ» 08-0321 QUOTATION NUMBER VENDOR NAME «Company» W.E. O'Neil Construction Co. of California QUANTITY I UNIT I DESCRIPTION I UNIT PRICE I AMOUNT Page 2 City of Huntington Beach Lakeview Clubhouse Improvements Project No. MSC-439 RFQ# 08-0321 Appendix I - Bid Schedule W.E. O'Neil Construction Co. of California Appendix Bid Schedule Refer to Plans 1. 1 L.S. Furnish and Install All Restroom Appurtenances (Include Door Widening) At $19,804.00 Per L.S. $12.38/sq.ft. $19,804.00 2. 1 L.S. Furnish and Install All Kitchen Appurtenances At $ 8,000.00 Per L.S. $ 8,000.00/ea. $ 8,000.00 3. 1 L.S. Furnish and Install Facets Relevant to the Raised Floor At $ 3,250.00 Per L.S. $ 3,250.00/ea. $ 3,250.00 4. 1 L.S. Furnish and Install All Handrails: Handrails/Guardrails $50.0011A. Guarddrails: At $19,400.00 Per L.S. $11omxft. $19,400.00 5. 1 L.S. Furnish and Install All Concrete Areas (Include Reapirs to Landscaping) At $34,885.00 Per L.S. $26.73/sq.ft. $34,885.00 6. 1 L.S. Furnish and Install Signage and Markings for Accessibility At $ 3,800.00 Per L.S. $ 100.00/ea. $ 3,800.00 City of Huntington Beach Lakeview Clubhouse Improvements Project No. MSC-439 RFQ# 08-0321 Qualifications W.E. O°NEIL CONSTRUCTION Qualifications (310)643-7900 Certified Payroll and Prevailing Wage will apply. ................................. Con'cri'fi Specialties Builder's Risk Insurance is not included in this proposal. Performance/payment bond is not included in this proposal. New flooring at Restrooms - no finish schedule or specifications. Date Printed: 3/21/2008 at 12:21 PM Page 1 of 1 pages City of Huntington Beach Lakeview Clubhouse Improvements Project No. MSC-439 RFQ# 08-0321 Similar Project Experience �W-E-O'Ntl .L SIMILAR PROJECT EXPERIENCE CITY OF HUNTINGTON BEACH Lakeview Clubhouse Improvements Katie Wheeler Library Irvine, California Tommy Cochran 1501 E. St. Andrew Place Santa Ana, CA 714 566-3025 Description: New construction and site work of a new public library replicated after an old Irvine family ranch house. The library is a 11,250 sf building is a wood framed structure with steel moment frames and a concrete basement. The interior surfaces include tile fire places, granite counter tops, and millwork to match the workmanship and finishes of the original house. Contract: $6,200,000 2. MTA Transportation Building Division 9 El Monte, California Tim Lindholm One Gate Way Plaza Los Angeles, CA 90012 213 922-7297 Description: 45,000 sf three story, office and transportation building for Los Angeles Metropolitan Transportation Authority. The building is comprised of structural steel framework and an aluminum composite and glass wall panel systems. The lobby includes a structural glass curtain wall system. Contract: $13,000,000 3. Harrah's Rincon Event Center San Diego, California George Ouimet One Harrah's Court Las Vegas, NV 89119 702 494-4275 Description: 8100 sf TI on 2nd Floor for event dub in occupied hotel facility Contract: $1,300,000 A • INITIATING DEPARTMENT: Community Services SUBJECT: Approve Standard CDBG Construction Document for ADA Improvements to Lake View Clubhouse COUNCIL MEETING DATE: August 18, 2008 RCA ATTACHMENTS STATUS Ordinance (w/exhibits & legislative draft if applicable) Attached ❑ Not Applicable X Resolution (w/exhibits & legislative draft if applicable) Attached ❑ Not Applicable X Tract Map, Location Map and/or other Exhibits Attached ❑ Not Applicable X Contract/Agreement (w/exhibits if applicable) Attached X (Signed in full by the City Attorney) Not Applicable ❑ Subleases, Third Party Agreements, etc. Attached ❑ (Approved as to form by City Attorne) Not Applicable X Certificates of Insurance (Approved by the City Attorney) Attached X Not Applicable ❑ Fiscal Impact Statement (Unbudgeted, over $5,000) Attached ❑ Not Ap licable X Bonds (If applicable) Attached ❑ Not Applicable X Staff Report (If applicable) Attached ❑ Not Applicable X Commission, Board or Committee Report (if applicable) Attached ❑ Not Applicable X Findings/Conditions for Approval and/or Denial Attached ❑ Not Applicable X EXPLANATI H FOR ISSING ATTACHMEHTS REVIEWED RETORNED FOR A DED Administrative Staff ( ) Assistant City Administrator Initial City Administrator Initial City Clerk ( ) PLANATION FOR RETURN OF ITEM: RCA Author: M.Loadsman City of Huntington Beach 2000 Main Street • Huntington Beach, CA 92648 OFFICE OF THE CITY CLERK JOAN L. FLYNN CITY CLERK August 21, 2008 Hondo Company, Inc. Attn: Bob Lloyd 2121 South Lyon Street Santa Ana, CA 92705 Dear Mr. Lloyd: Enclosed for your records is a copy of the Federally Funded Community Development Block Grant Construction Contract between the City of Huntington Beach and Hondo Company, Inc. for ADA Improvements to Lake View Park Clubhouse. Sincerely, JF:pe Enclosure: Agreement G:followup:agrmtltr Sister Cities: Anjo, Japan • Waitakere, New Zealand ( Telephone: 714-536-5227)