Loading...
HomeMy WebLinkAboutSancon Engineering, Inc. - 2011-08-15 RECEIVED'BY- l r CITY CLERK RECEIPT COPY Return DUPLICATE to 41, City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: —S-hari-Freidenr4eh, City Treasurer FROM: q V,�,3 j/r DATE: /13 111,L, SUBJECT: Bond Acceptance I have received the bonds for (Company Name) Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. 7 -7 -Z Guarantee and Warranty Bond No. Re: Tract No. CC No. MSC No. Approved 0// Agenda Item No. Z71 (Counci l Date) City Clerk Vault No. /=P, #27 g1followup/bondletler.doc ®�d City Of Huntington Beach INTER-DEPARTMENT COIVIIIIIMUNICATION HUNTINGTON BEACH TO: THOSE LISTED HEREON FROM: David Verone ✓1 DATE: 12/10/12 SUBJECT: Retention Release Payment Company Name: Sancon Engineering, Inc Address: 5841 Engineer Drive City, State and Zip Code: Huntington Beach, CA 92649 Phone Number: (714) 891-2323 Business License Number:A200298 Local Address: Same Notice of Completion Date:2/01/12 Contract Purpose: Sewer Relining The conformed copy of the Notice of Completion for the above contract has been filed. The thirty-five (35) day waiting period has elapsed or will elapse before payment is made. Processing of the retention payment is recommended so long as no stop notices or outstanding invoices are on file with the City. I certify that no stop notices are on file on the subject at this 'me. �Z- � Date Wravis K. Hopk s, Public Works Director I certify that there are no outstanding invoices on file. � a//a1 /,�- Date Joyce ack , D pu City Treasurer I certify that no stop notices are on file on the subject contrac , and that a guaranty bond has been filed with this office. bat Jon lynn, City lerk Retention_Release_Payment.doc 12/10/2012 9:15:00 AM Certification of Compliance with Prevailing Wage Laws To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Prevailing Wage Laws Contract: L Project: The undersigned contractor on the above-referenced project ("Project") hereby certifies that all laborers, mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor performing work under the contract for the Project have been paid pursuant to the minimum wage and bona fide fringe benefit -requirements specified for each particular classification of work, as set forth in the wage-rate determinations of the State of California, Department of Industrial Relations, and/or the United States Department of Labor. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this � ` day of oL oLe_r , 2012—,at California. (Type Contractor Name) By: Name: [Type Name] Title: [Type Title] Gh'-r's DiAene-d e-Ho i�b A'T°l'C3RNgY 1 snsax. --CONTRACTOR'S CERTIFICATE___-- _ ... .. I, P 5 ,state and certify that: (Name of Declarant) is the general contractor to the City of Huntington Beach ("Ci ') on Vontract No. _ c-G- •- (I 9 (the "Contract") for the construction of the public work of improvement entitled: (the"Project"). 2. All work to be performed pursuant to the Contract has been completed in accordance with the Contract Documents (as such term is defined in the Contract). 3. Except for the claims listed.below and the disputed claims listed in paragraph five(5), all persons supplying labor, services, materials and equipment to the Project, including all claims against the Contractor arising from the performance of the Contract, have been paid and satisfied(list unpaid debts and claims;if none, write"NONE"): 4, Attached hereto are the lien waivers required by the Contract Documents, which lien waivers have been executed by all persons who performed work on or supplied labor, services,materials, and/or equipment for use at the Project. 5, Set forth below is a list of disputed claims or claims that are the subject of a Notice to Withhold filed pursuant to the Civil Code of the State of California (list all disputed claims;if none,write"NONE"): I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. / Executed at �lc.aiiT% tG� �-;� on this (O� day of c> �' , 20 1-1- (Signature of Declarant) APPROVED AS TO FORM By: S1 -7/6 _AJ 3• Zo•Ot.e Name: [Type Name] 'title: [Type Title] 1 245914.1 Certification of Compliance with Title VII of-the Civil Rights Act and Equal Employment Opportunity Act of 1972 To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O.Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Contract: Project: The undersigned contractor on the above-referenced project ("Project") hereby certifies that it has complied with Title VII of the Civil Rights Act, the Equal Opportunity Act of 1972 and Executive Order 11246, and has not discriminated against any employee or applicant for employment because of race, creed, color, sex, national origin, age or disability. The undersigned contractor also certifies that it has not maintained any segregated facilities at its establishments on the basis of race, creed, color, sex, national origin, age or disability (with the exception of access for the disabled). I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this�Q ,day of 20 L.9,at California. GA(D o 1� {Type Contractor Nam By: Name: [Type Name] Title: [Type Title] A RURNEX Chris ®i�er�car S t 2459t1_t , MAINTENANCEBOND No. 1973 777-M KNOW ALL MEN BY THESE PRESENTS: That: Sancon Engineering Inc _ [contractor's narnei 5841 Engineer Dr, Huntington Beach,. CA 92649 [contractor's sorest address,qty and state and zip wdel as Principal(hereinafter called Contractor),and: HANOVER INSURANCE COMPANY fsurety's name] 2 MacArthur P1, 2nd Floor, Santa Ana, CA 92707 [surety's street address,city and state and zip code] a corporation organized and existing under the laws of the State of New Hampshire with Its principal office in the City of Worchester, MA as Surety (hereinafter called Surety), are held firmly bound unto CITY OF HUNTINGTON BEACH as Obligee(hereinafter called Owner), In the amount of One hundred six thousand, nine hundred forty three dollars, and two cents Dollars /@ 106 , 943 . 02 � for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors, and assigns,jointly and severally,firmly by these.presents, WHEREAS,Contactor has by written agreement dated August 15th, 2 O 11 entered into a contract withOwnerforthe Sewer Rehabilitation Project CC-1396 in accordance with drawings and specifications prepared by City of Huntington Beach which contract is by reference made a part hereof(hereinafter referred to as the Contract);and WHEREAS,the Contract provides that the principal will guarantee, for a period of one year, the work performed as part of the Contract from and against all defects In materials and workmanship;and WHEREAS,the Contract also provides that the Contractor shall secure Contractor's obligations during the one- year period with a bond executed by a surety duly admitted in the state of California;and WHEREAS, the Contract has been completed, and the Owner, Contractor and Surety agree that the commencement date for this Guarantee and Bond shall be January 31 s t , 2d 12. NOW,THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Contractor shall, for a period of one year from and after the date of completion and acceptance of the Contract by Owner,repair and/or replace any and all defects arising in the Work, whether resulting from defective materials or defective workmanship, then this obligation shall be null and void;otherwise it will remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. Whenever Contractor shall be,.and declared by Owner to be In default under the Contract, the Surety shalt, within thirty (30)following Owner's written notice of default, either: (a)remedy the default, or(b)shall promptly complete the Contract in accordance with its terms and conditions. Surety shall save the Owner harmless from any claims,judgments, liens or losses arising from the Surety's failure to either remedy the default or to complete the Contract in accordance with its terms and conditions in a timely manner. Whenever the Principal shall be, and declared by the Owner to be in default under the Contract, which shall Include without limitation,any breach or default of the Contract,then, after written notice from the Owner to the Surety, as provided for below, the Surety shall either: (a)remedy the default or breach by the Principal; or(b) shall promptly and faithfully take chMe of the Work and complete thev,;Work in accordance with the requirements of the Contract with a contractor other than the Principal,at its own expense, and make available 1 10 2567/50593 as work progresses sufficient funds to pay the cost of completion less the unpaid balance of the Contract -- —including-other-nests-and-damages-formihWh-the.-sung-may-be-liable-hereunder,-proWded,-howeuerAat-the------ ---`- procedure by which the Surety undertakes to discharge its obligations under this Bond shall be subject to the advance written approval of the Owner. Within thirty(30)days after Surety's receipt of a written notice from Owner of the failure of performance of the Contract by the Principal, it shall be the duty of the Surety to give to the Owner a notice, in writing, of the Surety's election to (a) remedy the defaults) of the Principal promptly, or(b) arrange for performance of the Contract promptly by a contractor other than the Principal,time being of essence to this Bond. In said Notice of Election, the Surety shall state the date of commencement of its cure or remedy of the Principal's default(s)or its performance of the Contract. The Surety's obligations for cure or remedy, include but are not limited to: correction of defective work and completion of the Contract, additional legal, design professional and delay costs arising from Surety's actions or failure to act; and liquidated damages (or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non- performance by the Principal). The Surety shall give prompt written notice to the Owner upon completion of the cure or remedy of the PdnapW's defaults)of its performance of the Contract. If the Surety does issue its Notice of Election and does not proceed to cure or remedy the Prfnapal's default(s) of its performance of the Work within thirty(30)days after receipt of a written notice from Owner, Surety shall be deemed to be in default on this bond,and the Owner shall be entitled to enforce any remedy available to Owner. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the successors of Owner. Signed and sealed this loth day of October 20 12 Principal Raised Corporate Seal Sancon Engineering, Inc. [MUST BE AFFIXED] (Contractor Name) By: (Seal) Principal Raised Corporate Seal ���d5 �i .nede7Y-P [(BUST BE AFFIXED] (Tifle) r Hanover Insurance Company (Surety Name) By: eal ,f Michael R. Langan, Attor ey in Fact NOTES: 1. Admowledgments must be completed and otruoed as part of the bond. =7COYAUD11MY 2Raised Corporate Seals are mandatory. 3. Please attach Power of Attorney. 2 10-2567/50583 CALIFORNIA ALL=PURPOSE ACKNOWLEDGIMENT — — — — — - — — State of California County of LOS ANGELES On Oct- 10�2012_ before me, her�dra Michelle hoots , I�iotary Public . Date Here Insert Name and Title of the Officer personally appeared Michael R Langan Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(60 whose name(j is/6p subscribed to the - --- - -- within instrument and acknowledged to me that ----_. i K BOOTS executed the same in hisP40Zftir authorized COit m. # 1.951463 < capacity(i�), and that by his signature an the cn m� . }�= NOfARV PUBLIC -CALIFORNIA (D instrument the person(g), or the entity upon behalf of LOS ANGELES COUNTY which the person(Q acted, executed the instrument. my Comm.Expires Oct 7,2015 . ... I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct- WITNESS my nd and official seal. Signat r Sf the of Public Place Notary Sea!Aboven ¢� O TzO{�f AL 7hough the information below is not required by lava it may prove valuable to persons retying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Maj,ntenance:: Bond Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Michael R. Langan Signer's Name: Individual individual :_i Corporate Officer—Title(s): Corporate Officer—Title(s): Partner—0 Limited r<General =Partner—_Limited ❑General >rl R. - X Attorneyin Fact L Attorney in Fact Trustee Top of thumb here r—I Top of thumb here 0 Guardian or Conservator `Guardian or Conservator 0 Other: 0 Other: Signer Is Representing- Signer Is Representing: NAT MZER TN.GURANEE C MPANY AN MASSA ,i a �V � .-. .,. ,- _>„ti..-✓.✓� .1— :._,;.�{;;�'�:,:�:._'.;�::t�-C:-%J�:A�`:.:�:>'`%:'�--•.:-::-.:'-:L`--1:•'---� __ _'.��-_.rt -��>{.`-a..'+%`-si=ti"C%",-`'f., 18o�8766t?27 ®20D7NarronalNotary Assoaation•935DDe Soto Ave-P_aB=2402-Chatsrmrih,CA91 31 3-2402-tWjMNafionaINotary em- org Item AderCANTall-rr� THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITIZENS INSURANCE COMPANY OF AMERICA POWERS OF ATTORNEY CERTIFIED COPY KNOW ALL MEN BY THESE PRESENTS: That THE HANOVER INSURANCE COMPANY and MASSACHUSETTS BAY INSURANCE COMPANY, both being corporations organized and existing under the laws of the State of New Hampshire, and CITIZENS INSURANCE COMPANY OF AMERICA,a corporation organized and existing under the laws of the State of Michigan,do hereby constitute and appoint MICHAEL R.LANGAN Of Pasadena,CA and each is a true and lawful Attomey(s)-in-fact to sign,execute,seal,acknowledge and deliver for,and on its behalf, and as its act and deed any place within the United States,or,if the following line be filled in, only within the area therein designated any and all bonds,recognizances,undertakings,contracts of indemnity or other writings obligatory in the nature thereof,as follows: Any such obligations in the United States,not to exceed Ten Million and No/100($10,000,000)in any single instance and said companies hereby ratify and confirm all and whatsoever said Attorney(s)-in-fact may lawfully do in the premises by virtue of these presents. These appointments are made under and by authority of the following Resolution passed by the Board of Directors of said Companies which resolutions are still in effect: "RESOLVED, That the President or any Vice President, in conjunction with any Assistant Vice President, be and they are hereby authorized and empowered to appoint Attomeys-in-fact of the Company,in its name and as its acts,to execute and acknowledge for and on its behalf as Surety any and all bonds,recognizances,contracts of indemnity,waivers of citation and all other writings obligatory in the nature thereof,with power to attach thereto the seal of the Company.Any such writings so executed by such Attomeys-in-fact shall be as binding upon the Company as if they had been duly executed and acknowledged by the regularly elected officers of the Company in their own proper persons."(Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14,1982—Massachusetts Bay Insurance Company;Adopted September 7,2001-Citizens Insurance Company of America) IN WITNESS WHEREOF, THE HANOVER INSURANCE COMPANY, MASSACHUSETTS BAY INSURANCE COMPANY and CITIZENS INSURANCE COMPANY OF AMERICA have caused these presents to be sealed with their respective corporate seals, duly attested by a Vice President and an Assistant Vice President,this 12th day of July, 2010. THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITIZEN"SURANCE COMPANY OF AMERICA SEAt_f a�a 1974 Mary Jeanne Anderson,Ulce President Robert K.Grennan.Assistan ice President THE COMMONWEALTH OF MASSACHUSETTS ) COUNTY OF WORCESTER )ss. On this 12th day of July, 2010 before me came the above named Vice President and Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, to me personally known to be the individuals and officers described herein, and acknowledged that the seals affixed to the preceding instrument are the corporate seals of The Hanover Insurance Company Massachusetts Bay Insurance Company and Citizens Insurance Company of America, respectively, and that the said corporate seals and their signatures as officers were duly affixed and subscribed to said instrument by the authority and direction of said Corporations. c a Pdof&-/Public �gCaamren�woi, My commission expires on November 3,2011 1, the undersigned Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, hereby certify that the above and foregoing is a full, true and correct copy of the Original Power of Attorney issued by said Companies,and do hereby further certify that the said Powers of Attorney are still in force and effect. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of The Hanover Insurance Company,Massachusetts Bay Insurance Company and Citizens Insurance Company of America. "RESOLVED,That any and all Powers of Attorney and Certified Copies of such Powers of Attorney and certification in respect thereto, granted and executed by the President or any Vice President in conjunction with any Assistant Vice President of the Company,shall be binding on the Company to the same extent as If all signatures therein were manually affixed, even though one or more of any such signatures thereon may be facsimile." (Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14, 1982 Massachusetts Bay Insurance Company;Adopted September 7, 2001 - Citizens Insurance Company of America) GIVEN under my hand and the seals of said Companies,at Worcester,Massachusetts,this J&h day of 49�—­T, ,20 1 Z THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITI S INSU CE COMPANY 7;__RICA L 4 Ste2�1t.Braui, ssistant Vice Pres7e6nt CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 State of California County of aRanl(-e On tol 18 1 12_ before me, CE.pn��s t3. l�Asis�a S r�arr�ny Date Here Insert Name and Title of the Officer personally appeared C-K(L.s -p' Trtc, Name(s)of Signer(s) e who proved to me on the basis of satisfactory evidence to be the person(g) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/shy/Wey executed the same in his/hak/th,6ir authorized capacity(io), and that by CHARLES B. PARSONS his/her/thincir signature(,$) on the instrument the Commission # 1943036 z person(), or the entity upon behalf of which the z ;-.a Notary Public California D person(t) acted, executed the instrument. z % Orange County My Comm.Expires Jul 30,2015 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand 9 0=' Signature: Place Notary Seal Above Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer — Title(s): ❑Corporate Officer — Title(s): ❑ Individual ❑ Individual . 11 ❑ Partner— ❑Limited ❑General Top of thumb here ❑Partner — ❑ Limited ❑General Top of thumb here ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: ©2010 National Notary Association•NationalNotary.org•1-800-US NOTARY(1-800-876-6827) Item#5907 RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) 0A.A CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: �S V DATE: SUBJECT: Bond Acceptance have received the bonds for + , tV (Company Name) Faithful Performance Bond No. Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. MSC No. Z-/Approved Agenda Item No. (Coup Il Appr6val Date) City Clerk Vault No. #27 g:/tollowup/bondletter.doc This Document was electronically recorded by PLEASE COMPLETE THIS INFORMATION City of Huntington Beach RECORDING REQUESTED BY: Recorded in Official Records, Orange County Tom Daly, Clerk-Recorder Illlllllllfffllllflll1111111111111111111111111111111111111111111 NO FEE 2012000060073 11:28am 02/01/12 WHEN RECORDED MAIL TO: 93 401 N12 1 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 CITY OF HUNTINGTON BEACH Attn: David Verone P.O. Box 190—2000 Main Street Huntington Beach, CA 92648 THIS SPACE FOR RECORDER'S USE ONLY TITLE OF DOCUMENT NOTICE OF COMPLETION NOTICE IS HEREBY GIVEN by the City of Huntington Beach, owner in fee, 2000 Main Street, Huntington Beach, CA 92648, that the contract heretofore awarded to Sancon Engineering, Inc. who was the company thereon for doing the following work to-wit: SEWER REHABILITATION, CONSTRUCTION CONTRACT-1396 That said work was completed January 25, 2012 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the Director of Public Works on January 31, 2012, per City Council Resolution No. 2003-70 adopted October 6,2003. That upon said contract Hanover Insurance Company was surety for the bond given by the said company as required by law. This document is solely for the official business of the City of Huntington Beach, as contemplated under Government Code Section 6103 and should be recorded free of charge. Dated at Huntington Beach, California,this January 31, 2012. A0, OLDirector of Putt c orks or City Engineer ity of HuntirAton Beach, California STATE OF CALIFORNIA) County of Orange )ss: City of Huntington Beach ) I, the undersigned, say: I am an Agent of the City of Huntington Beach, owner in fee, in the foregoing NOTICE OF COMPLETION. I have read said NOTICE OF COMPLETION and know the contents thereof; the same is true of my knowledge. I declare under penalty of perjury that the foregoing is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of,0 ange County. Dated at Huntington Beach, California,this January 31, 2012. / ,1 f D: ector of Publi Works or City Engineer This document is solely the official business of �i City of Huntington Beach, California the City of Huntington Beach, as contemplated under Government code section. 6103 and should be recorded free of charge. THIS PAGE IS ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION (Additional recording fee applies) RECEIVED BY': CITY CLERK RECEIPT COPY i� Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) f �. CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: Shari=Freidenrteh, City Treasurer FROM: e171-1 C__ l---A,v' DATE: SUBJECT: Bond Acceptance 1 have received the bonds for (Company Name) d Faithful Performance Bond No. J T 7 Labor and Material Bond No. Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. MSC No. Approved �' �i f l / Agenda Item No. pp 9 (Council Approval Date) City Clerk Vault No. #27 g1followup/bondletter.doc CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND SANCON ENGINEERING, INC. FOR SEWER REHABILITATION PROJECT CC-1396 TABLE OF CONTENTS Page No. 1. STATE OF WORK;ACCEPTANCE OF RISK 1 2. ACCEPTANCE OF CONDITIONS OF WORK;PLANS 2 3. COMPENSATION 4 4. COMMENCEMENT OF PROJECT 4 5. TIME OF THE ESSENCE 4 6. CHANGES 5 7. NOTICE TO PROCEED 6 8. BONDS 6 9. WARRANTIES 7 10. INDEPENDENT CONTRACTOR 7 l 1. LIQUIDATED DAMAGES/DELAYS 7 12. DIFFERING SITE CONDITIONS 9 13. VARIATIONS IN ESTIMATED QUANTITIES 10 14. PROGRESS PAYMENTS 11 15, WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES 11 16. AFFIDAVITS OF SATISFACTION OF CLAIMS 12 17. WAIVER OF CLAIMS 12 18. INDEMNIFICATION,DEFENSE,HOLD HARMLESS 12 19. WORKERS' COMPENSATION INSURANCE 13 20. INSURANCE 14 21, CERTIFICATES OF INSURANCE; ADDITIONAL INSURED 14 22. NOTICE OF THIRD PARTY CLAIM 15 23. DEFAULT&TERMINATION 16 24. TERMINATION FOR CONVENIENCE 16 25. DISPOSITION OF PLANS,ESTIMATES AND OTHER 17 26. NON-ASSIGNABILITY 17 27. CITY EMPLOYEES AND OFFICIALS 17 28. STOP NOTICES 17 29. NOTICES 18 30. SECTION HEADINGS 18 31, IMMIGRATION 19 32. LEGAL SERVICES SUBCONTRACTING PROHIBITED 19 33. ATTORNEY'S FEES 19 34 INTERPRETATION OF THIS AGREEMENT 19 35. GOVERNING LAW 20 36. DUPLICATE ORIGINAL 21 37, CONSENT 21 38. SURVIVAL 21 39, MODIFICATION 21 40. SIGNATORIES 21 41, ENTIRETY 21 CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND SANCON ENGINEERING, INC. FOR SEWER REHABILITATION PROJECT CC-1396 THIS AGREEMENT ("Agreement") made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and Sancon Engineering, a California corporation, hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as Sewer Rehabilitation Project, CC-1396 in the City of Huntington Beach; and CONTRACTOR has been selected to perfonn said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities. and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or glagrec/sur(nctICityc Oil st I of 22 5,10 be encountered in the prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; g/agree/surinet/cityconst 2 of 22 i/10 C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council, and any revisions, amendments or addenda thereto; D. The current edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 10801 National Boulevard, Los Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as 1%all ItCisu,-e1et/CityC0„St 3 of 22 5/10 "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed Sixty One Thousand, Eighty Dollars and Thirty Four cents Dollars ($61,080.34), as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within Thirty (30) consecutive working days from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. e/M-'rcc/suriiict C1tyc011st 4 of 22 5/10 CONTRACTOR shall prepare and obtain. approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6 CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the aRrce/surt1)C1'Cityconsl S Of 22 5,10 changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final contract price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within ten (10) days of filing of the Notice of Completion. /a11red urfnet/citvconst 6 of 22 5/10 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, g agrcc'swtnet/cityconst 7 of 22 S/10 the sum of five hundred Dollars ($500.00) per day for each and every working day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless DPW shall grant a further period of time), notify DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting g/agrec'surlhet/cityconst 8 of 22 5/10 from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors, will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DIFFERING SITE CONDITIONS A. Notice: CONTRACTOR shall promptly, and before such conditions are disturbed, notify DPW in writing of: (1) Subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents; or (2) Unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of g/agree/surinet/cityconst 9 of 22 5/10 such conditions, an equitable adjustment shall be made and the agreement modified in writing accordingly. B. Time Extension: No claim of CONTRACTOR under this Section shall be allowed unless CONTRACTOR has given the notice required hereunder provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. glagicc/surfnct/cityconst 10 of 22 5/10 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (10%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined in its sole discretion by DPW, less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payinent to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as a acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the 1,11'eC/SUI-rl,eveItyC01ISt 11 of 22 51110 substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items, if any, to be set forth in CONTRACTOR's affidavit covering disputed claims, or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION DEFENSE HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all, claims, damages, losses, expenses, judgments, demands defense costs, and consequential damage or liability of any kind or nature, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone g/agree'surfnet/citvconst 12 of 22 5/10 directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to ,be provided by CONTRACTOR. 19. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. g/agree/,urtfineUcityconsl 13 of 72 5/10 20. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend, hold harmless and indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than One Million Dollars ($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees, agents, and volunteers as Additional Insureds, and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary. Under no circumstances shall said above-mentioned insurance contain a self- insured retention without the express written consent of CITY; however an insurance policy"deductible" of$5,000.00 is permitted. 21. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney g%agreelsurfnet'cityconst 14 of 22 5110 evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. provide the name and policy number of each carrier and policy; 2. state that the policy is currently in force; and 3. promise to provide that such policies will not be canceled or modified without thirty(30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional hlsureds, to the City Attorney for approval prior to any payment hereunder. 22. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten (10) days of receipt of such claim or claims. g;agrce�surl�,et�cityco„st 15 of 22 5no 23. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to tenninate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, tenninate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's tennination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 24 and any damages shall be assessed as set forth in Section 24. 24. TERMINATION FOR CONVENIENCE CITY may tenninate this Agreement for convenience at any time with or without cause, and whether or not PROJECT is fully complete upon seven (7) calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience, the CONTRACTOR shall be entitled to receive payment for work executed, -%agree/surhiet!city coils t 16 of 22 5/10 and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 25. DISPOSITION OF PLANS ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 26. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety. 27. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 28. STOP NOTICES; RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of e/am'cdswfneUcityamA 17 of 22 5;10 One Hundred Dollars ($100) for every Stop Notice filed in excess of two (2), regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 29. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices, certificates or other communications will be sent by notifying the other party via personal delivery, reputable overnight carrier or U. S. certified mail-return receipt requested: TO CITY: TO CONTRACTOR: City of Huntington Beach Sancon Engineering, Inc ATTN: David Verone Attn: 2000 Main Street C3ai�►-° �� Huntington Beach, CA 92648 5841 Engineer Drive Huntington Beach, CA.92649 30. SECTION HEADINGS The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions, and do not interpret, define, limit or i Fl_"ICC/SLIII71Ct/CItyCOIISt 18 o1 22 5/10 describe, or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 31. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 32. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 33. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terns and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorneys fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non-prevailing party. 34. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction gt,grcc surrncUdtyconst 19 of 22 5i10 to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 35. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 36. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. -w, tiict/cityCOIIM 20 of 22 5/10 37. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 38. SURVIVAL Terms and conditions of this Agreement, which by their sense and context survive the expiration or termination of this Agreement shall so survive. 39. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 40. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact,held by the signatory or is withdrawn. 41. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiation, and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements, promises, agreements or warranties, oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement, c���=�cc;surr„ct�c;tyco„st 21 of 22 5/10 promise, agreement, warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers on lJ� 20 CONTRACTOR CITY OF HUNTINGTON BEACH, a municipal co on o e State of California Sancon Engineering, Inc ° M or By: CKvw- ►�*eso,�s Clerk C1 �I print name ITS: (circle one) Chairman/President/. ice Presiden INITIATED AND APPROVED: I AND Director of bli orks By: j� B'8 REVIE AVD APPROVED: print name ITS: (circle one) Secretary/Chief Financial Officer/Asst. Secretary Treasurer i Manager APPROVED AS TO FORM: 2A 3 1'01/ ity Attorney � �1 �J�g�rc surli,et/crtya�„�� 22 of 22 5/10 W1 EWINE.EN DRIVE tAXrMTON OLVACA E SECTION C PROPOSAL for the SEWER REHABILITATION PROJECT CC No. 1396 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 30 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid,unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find 13 ova in the amount of$ /a A61-1 which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or"Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature C-2 SECTION C PROJECT BID SCHEDULE INDEX SEWED REHABILITATION PROJECT CC NO. 1396 The three sewer line reaches are (1)Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac, and (3)Cliff Drive from Brookhurst Street to Spindrift Lane. PROJECT BASE BID: Basis of Award SEWER REHABILITATION PROJECT C-2.2 to C-2.3 BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES; $ /10030 � BASE BID WILL BE THE BASIS OF AWARD C-3 ADDENDUM NO. 1- PROJECT BID SCHEDULE CC-1396 SEVER LINING :: s ana D ate D•.. H.....iiii:3D' eel' feon:•: :::•:•:•:•:•::::-:•:•:•:•:•::•:.... d ::: :::{:• es .P.. in. 1 1 Mobilization/Demobilization LS $ 5�U $ — 2 1 Furnish Traffic Control 00 LS $ / , U $ D11 3 2545 Clean and inspect 8"sewer main LF $ 4 2545 Install liner and post inspect 8"sewer main LF $ � $5 D 5 58 Grind and re-open sewer service lateral EA $ 26 6 1 Prepare Construction Traffic Control Plans LS $ O $ Total Amount Bid in Figures: $ C Total Amount Bid in Words: : S>c� Alvt-'. - Y_�E���•�e s _ 3 C-2.3 G BASIS OF AWARD PROJECT BID SEWER REHABILITATION CC NO. 1396 C-4 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class of Work Number By submission of this proposal, the Bidder certifies; 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-5 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange ead�/A 111.,-Q� obi , being first duly sworn, deposes and says that he orA19 is ®-r of cPjw "&y A, rA the party making the foregoing bid th t the bid is not made in the interest of, or on th b half of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Name of Bidder Signature of Bidder _44� Address of Bidder C•¢ 7;6 arg Subscribed and sworn to before me this2 i day of 2011 . �z� l 2!c C COMMON*1939M Notary Public-Calitoornia IS Omnos County Comm.F Jul 2 201 NOTARY PUBLIC NOTARY SEAL C-6 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the SEWER REHABILITATION PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term"Qualified Person"is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: Aperson who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Contractor By Title Date: C-7 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? �/ ❑ Yes I� No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-8 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. . I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. .S ff4/G0IV 14/�rW1 fgie t a/v Contractor r ' By Title Date: Z S- H C-9 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name y A. Business Address City, State Zip (�L% ) Pg1- a 3 23 Telephone Number State Contractor's License No. and Class /®-• y -- l f f,T Original Date Issued /- 3/- )13 Expiration Date The work site was inspected by Tcsibi ) m/a4,u l of our office on �uw. `�- , 2011 . The following are persons, firms, and corporations having a principal interest in this proposal: AetcK oar t�er.sarn fir!! ��� BOG �d�Lt�✓9.rtA.dr�i� so a• Vrva✓ s�s�.vL�.9,- T��S. C-10 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. S,9/✓GO/✓ 1=�or•v"�''��2 r�,� /•tea Company/Name/, Signature of Bidder �d:gxvvo,e/'t Printed or Typed Signature Subscribed and sworn to before me thivI day of V4 201 L. rAl!% P.SCAMION Cortunission*1939762 Le Notary Public-California Orange County .• .-*Comm.Expires Jul 2 2115 NOTARY PUBLIC AaVCA777� I - - - - - - --- NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: 1. loal*n too Ml�D , s3` 4,,l �!► �A ✓ M ')3 Name and Address of Public Agency Name and Telephone No. of Project Manager: '' wg Contract Amount Type of Work Date Completed 2. of /67C< 6�5-D M 11-&j J�Yl- him-17A -PAI Aw//e '•o-52 Name and Address of Public Agency Name and Telephone No. of Project Manager: 1414S I-IWP Contract Amount Type of Work Date Completed 3. �61O &4Y SMv9'GE /7i i 'Ct�J G�/i 1 � �A�` LA dam► Co �,4 2 5"/ Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed C-11 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax(714) 374-1573 ADDENDUM U for the construction of SEWER REHABILITATION PROJECT CC No. 1396 July 18,2011 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: NEW BID SCHEDULE INCLUDE: 1. NEW Item No.6 "Prepare Construction Traffic Control Plans" ....1 LS 2. Revised Bid Item No.2 to Read"Furnish Traffic Control" SPECIFICATIONS REVISIONS TO INCLUDE: 1. Replace in Bid Documents Section 7-5 PERMITS on Pages E-1'I and Section 740 PUBLIC CONVENIENCE on Panes E-15 with New Section 7-5 and 740 in Addendum No.1 2. A Caltrans Encroachment Permit Application pulled by Agency is attached to Addendum No. 1. Contractor must submit to Caltrans Water Pollution Control Provisions and Construction Traffic Control Plan for review and approval,along with the application for a rider to the Encroachment Permit. Bidders shall submit SECTION C with the most current revisions and bid schedule, Page C-2.3 "Addendum No. 1-Project Bid Schedule CC-1396 SEINER LINING". Award will be based on most current revised Bid Schedule and Specifcation revisions. This is to acknowledge receipt and review of Addendum Number 1,dated July 18,2011. Company Name By Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Joseph Fuentes at(714)536-5431. AAALLMERICA FINANCIAL The Hanover Insurance Company Citizens Insurance Company CITIZENS INSURANCE Massachusetts Bay Insurance Company of America HANOVER INSURANCE" 440 Lincoln Street 645 West Grand River Worcester, MA 01653 Howell, MI 48843 BID BOND NUMBER 145 65 66 KNOW ALL MEN BY THESE PRESENTS, that we,the undersigned, SANCON ENGINEERING, INC. hereinafter called Principal, and THE HANOVER INSURANCE COMPANY, a corporation established under the laws of the State of New Hampshire, and/or MASSACHUSETTS BAY INSURANCE COMPANY, a corporation established under the laws of the State of New Hampshire and having their principal office in Worcester, Massachusetts, as Surety, hereinafter called Surety, are held and firmly bound unto CITY OF HUNTINGTON BEACH, CA as Obligee, in the penal sum of TEN PERCENT (10%) OF THE TOTAL AMOUNT OF THE BID IN----- Dollars for the payment of which, well and truly to be made, we hereby jointly and severally bind ourselves, our heirs, executors, administrators, successors and assigns. The condition of the above obligation is such that whereas the Principal has submitted to the CITY OF HUNTINGTON BEACH CA a certain Bid, attached hereto and hereby made a part hereof, to enter into a contract in writing for SEWER REHABILITATON PROJECT NOW,THEREFORE, (a) If said Bid shall be rejected, or in the alternate (b) If said Bid shall be accepted and the Principal shall execute and deliver a contract in the Form of Contract attached hereto (properly completed in accordance with said Bid) and shall fumish a bond for his faithful performance of said contract, and for the payment of all persons performing labor or furnishing materials in connection therewith, and shall in all other respects perform the agreement created by the acceptance of said Bid, Then this obligation shall be void, otherwise the same shall remain in force and effect; it being expressly understood and agreed that the liability of the Surety for any and all claims hereunder shall, in no event, exceed the penal amount of this obligation as herein stated. The Surety, for value received, hereby stipulates and agrees that the obligations of said Surety and its bond shall be in no way impaired or affected by an extension of the time within which the Owner may accept such Bid; and Surety does hereby waive notice of any such extension. SIGNED, SEALED AND DATED this 8th day of JULY, 2011 SANCON ENGINEERING,INC. 5841 Engineer Drive, Huntington Beach, CA 92649 (Principal) BY S'�- (Seal) N HANOVER INSURANCE CO PANY 2 MacArthur Placd.2nd Floor.S to Ana CA 92707 BY 11'i A 1 (Seal) Michael R.Langan r orney-initajcl 141-0787(10/04) CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of os Ancreles _ On 5 3` ! before me, Kendra Michelle Boots, Notary Public Date Here Insert Name and Title of the Officer personally appeared Michael R. Langan Name(s)of Signer(s) e who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/a* subscribed to the ----------------------------------------------------0............. within instrument and acknowledged to me that KENDRA MICHELLE BOOTS he/gbWX4x*executed the same in his! authorized U) COMM. #k 1766750 < capacity( ), and that by his/bkAysk signature(g) on the Cr: • '' , NOTARY PUBLIC CALIFORNIA instrument the person(so, or the entity upon behalf of LOS ANGELES COUNTY which the person(s) acted, executed the instrument. L.-.....•.........••......My Camm:Expires Oct.7,2011 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my and and o icial sea Signatur Place Notary Seal Above p q/ Signature of Notary Public OPTIONAL Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Bid Bond Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Michael R. Langan Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Partner—❑ Limited ❑ General _ _ ❑ Partner—❑ Limited ❑ General 9 Attorney in Fact ❑Attorney in Fact ❑ Trustee Top of thumb here ❑Trustee Top of thumb here ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Re resentingg: Sigg�ner Is Representing: THE Representing:- TN_�U� CE :C014PA Y AND / 01 MASSACHUSETTS BAY 1ASURANCE COMPANY 02007 Nafionall Notary Association•9350 De Soto Ave.,P.O.Box 2402•Chatsworth,CA 91313-2402•www.NafionalNotary.org Item#5907 Reorder:Call Toll-Free 1-800-876-6827 THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITIZENS INSURANCE COMPANY OF AMERICA POWERS OF ATTORNEY CERTIFIED COPY KNOW ALL MEN BY THESE PRESENTS: That THE HANOVER INSURANCE COMPANY and MASSACHUSETTS BAY INSURANCE COMPANY, both being corporations organized and existing under the laws of the State of New Hampshire, and CITIZENS INSURANCE COMPANY OF AMERICA,a corporation organized and existing under the laws of the State of Michigan,do hereby constitute and appoint MICHAEL R.LANGAN Of Pasadena,CA and each is a true and lawful Attorney(s)-in-fact to sign,execute,seal,acknowledge and deliver for,and on its behalf, and as its act and deed any place within the United States,or, if the following line be filled in, only within the area therein designated any and all bonds,recognizances,undertakings,contracts of indemnity or other writings obligatory in the nature thereof,as follows: Any such obligations in the United States,not to exceed Ten Million and Noll 00($10,000,000)in any single instance and said companies hereby ratify and confirm all and whatsoever said Attorney(s)-in-fact may lawfully do in the premises by virtue of tt$ese presents. These appointments are made under and by authority of the following Resolution passed by the Board of Directors of said Companies which resolutions are still in effect: "RESOLVED, That the President or any Vice President, in conjunction with any Assistant Vice President, be and they are hereby authorized and empowered to appoint Attorneys-in-fact of the Company,in its name and as its acts,to execute and acknowledge for and on its behalf as Surety any and all bonds,recognizances,contracts of indemnity,waivers of citation and all other writings obligatory in the nature thereof,with power to attach thereto the seal of the Company.Any such writings so executed by such Attomeys-in-fact shall be as binding upon the Company as if they had been duly executed and acknowledged by the regularly elected officers of the Company in their own proper persons."(Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14,1982-Massachusetts Bay Insurance Company;Adopted September 7,2001-Citizens Insurance Company of America) IN WITNESS WHEREOF, THE HANOVER INSURANCE COMPANY, MASSACHUSETTS BAY INSURANCE COMPANY and CITIZENS INSURANCE COMPANY OF AMERICA have caused these presents to be sealed with their respective corporate seals, duly attested by a Vice President and an Assistant Vice President,this 12th day of July, 2010. THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY uwo, I I`" CITIZEN SURANCE COMPANY OF AMERICA - 1974 ( -� Mary Jeanne der on, ice Presiae t Robert K.Grennan,Assistan ice President THE COMMONWEALTH OF MASSACHUSETTS ) COUNTY OF WORCESTER )ss. On this 12th day of July, 2010 before me came the above named Vice President and Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, to me personally known to be the individuals and officers described herein, and acknowledged that the seals affixed to the preceding instrument are the corporate seals of The Hanover Insurance Company Massachusetts Bay Insurance Company and Citizens Insurance Company of America, respectively, and that the said corporate seals and their signatures as officers were duly affixed and subscribed to said instrument by the authority and direction of said Corporations. rr , srvmo l c ea �1 �!?c- C ;_ .X if m v�o m Nolefy Public ege�.mer�a My commission expires on November 3,2011 I, the undersigned Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, hereby certify that the above and foregoing is a full, true and correct copy of the Original Power of Attorney issued by said Companies,and do hereby further certify that the said Powers of Attorney are still in force and effect. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of The Hanover Insurance Company,Massachusetts Bay Insurance Company and Citizens Insurance Company of America. "RESOLVED, That any and all Powers of Attorney and Certified Copies of such Powers of Attorney and certification in respect thereto, granted and executed by the President or any Vice President in conjunction with any Assistant Vice President of the Company,shall be binding on the Company to the same extent as if all signatures therein were manually affixed, even though one or more of any such signatures thereon may be facsimile." (Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14, 1982 Massachusetts Bay Insurance Company;Adopted September 7,2001 - Citizens Insurance Company of America) Q-tk GIVEN under my hand and the seals of said Companies,at Worcester, Massachusetts,this ! day of 20 C f - THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITI S INSU CE COMPANY OF AMERICA SteVBraul, ssistant Vice Pres nt ENGINEERING INC. 5841 Engineer Drive, Huntington Beach, CA 92649 - (714) 891-2323 an, ,I NU Mak MOO owl V ,ma PEW a$ 4 R, imp Mims WOO= 4 ON% A AMR%X V"! ��4�Dxk U00 "3 N�,V V W WE BW N_ 4, Oim�n ............ T ma its allot sTAWN IWO WOK'm AF -N,n, v, WS mg gwyn- AMfw.So am A; as F",p In moy M." 1 "A W.WX A "ITS a 1.yy -J,I"too CIA i�? "in-moo to 7-7", D JQ I X MAC FEN MOO I was 7� �d "id "J A City ®f Huntington Beach 2000 Main Street e Huntington Beach, CA 92648 (714) 536-522'7 ® www.huntingtonbeachca.gov Office of the City Clerk B ` Joan L. Flynn, City Cleric September 19, 2011 SanCon Engineering, Inc. Attn: Bob Hollingsworth 5841 Engineer Drive Huntington Beach, CA 92649 Re: Sewer Rehabilitation Project—CC-1396 The City Council awarded the bid to your company for the above referenced project. Enclosed is a copy of the executed contract with the City of Huntington Beach. A Certification of Compliance with Title VII of the Civil Rights Act, Certification of Compliance with Prevailing Wage Laws and Contractor's Certificate form must be returned to this office after the project is completed but prior to the release of retention funds. In addition, the following item must also be on file, with this office before the City can release any retention funds: A warranty bond guaranteeing the final amount of work and materials for one year. If your performance bond does not include specific wording for a one-year warranty, then a rider or separate bond must be submitted. Should you have any questions or concerns regarding the enclosures or items that must be on file in this office prior to release of retention funds, please call the Public Works Department at 536-5437. Sincerely, J !LtInn, CMC City Clerk J F:pe Enclosures: Copy of Contract including Proposal Copies of insurance/bonds Contractor's Certificate Certificate of Compliances Bid Bond (original) gS.d*sA90(aT t\Aa*rJapazo# Waitakere, New Zealand Certification of Compliance with Prevailing Wage Laws To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Prevailing Wage Laws Contract: Project: The undersigned contractor on the above-referenced project ("Project") hereby certifies that all laborers, mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor performing work under the contract for the Project have been paid pursuant to the minimum wage and bona fide fringe benefit 'requirements specified for each particular classification of work, as set forth in the wage-rate determinations of the State of California, Department of Industrial Relations, and/or the United States Department of Labor. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this day of , 20_, at , California. (Type Contractor Name) By: Name: [Type Name] Title: [Type Title] ` Q Ivic�rltA i Jl Yet, CITY ATPORNEY 1 247542-1 Certification of Compliance with'Title VU of the Civil Rights Act and Equal Employment Opportunity Act of 1972 To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Contract: Project: The undersigned contractor on the above-referenced project ("Project") hereby certifies that it has complied with Title VH of the Civil Rights Act, the Equal Opportunity Act of 1972 and Executive Order 11246, and has not discriminated against any employee or applicant for employment because of race, creed, color, sex, national origin, age or disability. The undersigned contractor also certifies that it has not maintained any segregated facilities at its establishments on the basis of race, creed, color, sex, national origin, age or disability (with the exception of access for the disabled). I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this day of 120 at , California. (Type Contractor Name) By: Name: [Type Name] Title: [Type Title] E IF R c(; �- 'Y_ • A c7RNEY J 3 - 26- Cep 1 245911 1 CONTRACTOR'S CER`IMCAT'E state and certify that: (Name of Declarant) l. is the general contractor to the City of Huntington Beach ("City") on Contract No. (the "Contract") for the construction of the public work of improvement entitled: (the"Project"). 2. All work to be performed pursuant to the Contract has been completed in accordance with the Contract Documents (as such term is defined in the Contract). 3. Except for the claims listed.below and the disputed claims listed in paragraph five(5), all persons supplying labor, services, materials and equipment to the Project, including all claims against the Contractor arising from the performance of the Contract, have been paid and satisfied(list unpaid debts and claims; if none, write"NONE"): 4. Attached hereto are the lien waivers required by the Contract Documents, which lien waivers have been executed by all persons who performed work on or supplied labor, services,materials, and/or equipment for use at the Project. 5. Set forth below is a list of disputed claims or claims that are the subject of a Notice to Withhold filed pursuant to the Civil Code of the State of California (list all disputed claims; if none, write"NONE"): 1 declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed at on this day of 120 (Signature of Declarant) APPROVED AS TO FORM By: Name: [Type Name] Title: [Type Title] 1 2459141 RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNT NG TON REACH INTERDEPARTMENTAL COIVIn/UNICAT1ON TO: , City Treasurer /? } FROM: DATE: SUBJECT: Bond Acceptance I have received the bonds for ='�=t%t� � 11� 1t� (Company Name) Faithful Performance Bond No. �`7 j", �1 7 Labor and Material Bond No. �`7 � Monument Bond No. Maintenance Bond No. Guarantee and Warranty Bond No. Re: Tract No. CC No. �� MSC No. Approved Agenda Item No. (Co6nc#Approval Date) City Clerk Vault No. #27 g1followup/bondletter.doc Bond No. PERFORMANCE BOND #1973 777 • KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS,City of Huntington Beach(hereinafter referred to as"City")has,by written agreement dated 20 entered into a contract with SANCON ENGINEERING, INC. 5841 ENGINEER DRIVE, HUNTINGTON BEACH, CA 92649 (name and address of Contractor) thereinafter referred to as"Principal"),for performance of the work described as follows: SEWER REHABILITATION PROJECT, CC-1396 IN THE CITY OF HUNTINGTON BEACH, CA (Project Title) WHEREAS, said contract,and all documents referenced therein(hereinafter collectively "Contract"), are incorporated herein by this reference made a part hereof as though set forth herein in full. WHEREAS, said Principal is required under the terms of the Contract to fumish a bond guaranteeing the prompt, full and faithful performance of said Contract. NOW THEREFORE,we, the undersigned, as Principal, and THE HANOVER INSURANCE COMPANY 2 MacArthur Place, Santa Ana, CA 92707 (name and address of Surety) (a duly admitted surety insurer under the laws of the State of Califomia and hereinafter referred to as "Surety"), as Surety, are held and firmly bound unto City in the penal sum of SIXTY ONE 111011SLND ETC T4TY AND -44 f1 n0 T)nT.T.ARS Dollars($ ),this amount being not less than one hundred percent of the price set forth in the Contract,in lawful money of the United States,for the payment of which sum,well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the Principal shall promptly, fully and faithfully perform each and all of the covenants,obligations and things to be done and performed by the Principal in strict accordance with the terms of the Contract as said contract may be altered,amended or modified from time to time; and if the Principal shall indemnify and save harmless City and all of City's officers,agents and employees(hereinafter collectively referred to as"Obligees°)from any and all losses, liability and damages,claims,judgments, stop notices,fees and costs of every description, whether imposed by law or in equity,which may be incurred by the Obiigees by reason of the failure or default on the part of the Principal in the performance of any or all of the terms or the obligations of the — Contract, including all alterations, amendments and modifications thereto, and any warranties or guarantees required thereunder, then this obligation shall be void; otherwise, it shall be and shall remain in full force and effect. Surety stipulates and agrees,for value received,that no adjustment of the time or price in the Contract or any alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, shall in any way affect, limit, restrict, impair or release the obligations of the Surety under this Bond. Surety waives notice of any adjustment of contract time or contract price,and 27759L.I PERFORMANCE BOND Page 1 of 2 Bond No. 1973 777 any other alteration, change,deletion,addition or other modification to the Contract,or the work to be performed thereunder, and agrees to automatically adjust the penal sum of this Bond to reflect such adjustments,alterations,changes,deletions,additions or other modifications. Surety agrees to provide written confirmation of such adjustments-in the penal sum to City on not less than a quarterly basis. Surety also waives the provisions of Civil Code§§2845 and 2849. The obligations of this Bond shall survive the completion of the work described in the Contract as to all obligations and liabilities of the Principal which survive completion of the work. IN WITNESS WHEREOF, each parry represents and warrants that this Instrument has been duty executed by Principal and Surety,on the date set forth below,that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety,by execution of this bond, waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: AUGUST 23 , 2011 ATTEST C�L .474`W SANCON ENGINEERING, INC. (Corporate Seal) (Principal Name) By: Name: Title-. (' -E i ATTEST THE HANOVER INSURANCE COMPANY (Corporate Seal) (Surety ameJ41 1 By-_ A 4,4:Alf_� Name: Mib ael 9. L an (Signature of Attorney-in-Fact for Surety) (Attach Attomey-in-Fact Certificate) tom-415-3 8 0 0 (Area Code&Telephone Number of Surety) APPROVED AS TO FORM: CITY 0 UNTINGTON BEACH e By ennifer McGirath ) f$L ity Attorney Note: This bond must be executed in duplicate and dated,all signatures must be notarized,and evidence of the authod ly of any person signing as attomey-in-fact must be attached. 277591.1 PERFORMANCE BOND Page 2 of 2 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT_ State of California County of iLOS ANGELES. On At before me, Kendra Michelle Boots , Rotary Public , Date Here Insert Name and Title ofthe Officer personally appeared Michael R. Langan Name(s)of Signer(s) e who proved to me on the basis of satisfactory evidence to be the person(*) whose name(d) is/Va subscribed to the --.••...................... within instrument and acknowledged to me that KENDRA MICHELLE BOOTS ' he/MUV#W executed the same in his/ authorized .sh COMM, # 1766750 capacity( ), and that by his/ tltdaear signature(g) on the it -s<: NOTARY PUBLIC • CALIFORNIA (n instrument the erson or the entity upon behalf of :;�4 LOB ANGEire COUNTY which the person(!A acted, executed the instrument. i My Comm.Expires Oct.7,2011 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my nd and official sea Signatur Place Notary Seal Above Signature of Notary Public OPTIONAL n ItlfHL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: FAITHFUL PZR470RIXANCE BOND Document Date: Number of Pages: Signer(s)Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Michael R. Langan Signer's Name: Individual ❑ Individual ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Partner—❑ Limited ❑General _ _ ❑Partner—❑ Limited ❑ General .0 Attorney in Fact e - ❑Attorney in Fact 0 ❑ Trustee Top of thumb here ❑Trustee Top of thumb here ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: HPANMTEA. 'TNS1JR�NC'F �n P? ,.NY' ,AND OR PIf ©2007 National Notary Association•9350De Soto Ave.,P.O.Box 2402•Chatsworth,CA 91313-2402-www.NationalNotaryorg Item#5907 Reorder.Call Toll-Free 1-800-876-6827 THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITIZENS INSURANCE COMPANY OF AMERICA POWERS OF ATTORNEY CERTIFIED COPY KNOW ALL MEN BY THESE PRESENTS:That THE HANOVER INSURANCE COMPANY and MASSACHUSETTS BAY INSURANCE COMPANY, both being corporations organized and existing under the laws of the State of New Hampshire, and CITIZENS INSURANCE COMPANY OF AMERICA,a corporation organized and existing under the laws of the State of Michigan,do hereby constitute and appoint MICHAEL R.LANGAN Of Pasadena,CA and each is a true and lawful Attomey(s)-in-fact to sign,execute,seal,acknowledge and deliver for,and on its behalf, and as its act and deed any place within the United States,or,if the following line be filled in,only within the area therein designated any and all bonds,recognizances,undertakings,contracts of indemnity or other writings obligatory in the nature thereof,as follows: Any such obligations in the United States,not to exceed Ten Million and Nof100($10,000,000)in any single instance and said companies hereby ratify and confirm all and whatsoever said Attomey(s)-in-fad may lawfully do in the premises by virtue of these presents. These appointments are made under and by authority of the following Resolution passed by the Board of Directors of said Companies which resolutions are still in effect: "RESOLVED, That the President or any Vice President, in conjunction with any Assistant Vice President, be and they are hereby authorized and empowered to appoint Attomeys-in-fact of the Company,in its name and as its acts,to execute and acknowledge for and on its behalf as Surety any and all bonds,recognizances,contracts of indemnity,waivers of citation and all other writings obligatory in the nature thereof,with power to attach thereto the seal of the Company.Any such writings so executed by such Attomeys-in-fact shall be as binding upon the Company as if they had been duly executed and acknowledged by the regularly elected officers of the Company in their own proper persons."(Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14,1982—Massachusetts Bay Insurance Company;Adopted September 7,2001-Citizens Insurance Company of America) IN WITNESS WHEREOF, THE HANOVER INSURANCE COMPANY, MASSACHUSETTS BAY INSURANCE COMPANY and CITIZENS INSURANCE COMPANY OF AMERICA have caused these presents to be sealed with their respective corporate seals, duty attested by a Vice President and an Assistant Vice President,this 12th day of July, 2010. THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY a wu e CITIZE117SURANCE COMPANY OF AMERICA Mary Jeanne defson.Vice Preaiae t vi Robert K.Grennan.Assistan ce President THE COMMONWEALTH OF MASSACHUSETTS ) COUNTY OF WORCESTER )SS. Qt On this 12th day of July, 2010 before me came the above named Vice President and Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, to me personally known to be the individuals and officers described herein, and acknowledged that the seals affixed to the preceding instrument are the corporate seals of The Hanover Insurance Company Massachusetts Bay Insurance Company and Citizens Insurance Company of America, respectively, and that the said corporate seals and their signatures as officers were duly affixed and subscribed to said instrument by the authority and direction of said Corporations. a�arr.r orr NaW y PubH,- r�ert.e�.a My commission expires on November 3,2011 I, the undersigned Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, hereby certify that the above and foregoing is a full, true and correct copy of the Original Power of Attomey issued by said Companies,and do hereby further certify that the said Powers of Attorney are still in force and effect. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of The Hanover Insurance Company,Massachusetts Bay Insurance Company and Citizens Insurance Company of America. "RESOLVED, That any and all Powers of Attorney and Certified Copies of such Powers of Attorney and certification in respect thereto, granted and executed by the President or any Vice President in conjunction with any Assistant Vice President of the Company,shall be binding on the Company to the same extent as if all signatures therein were manually affixed,even though one or more of any such signatures thereon may be facsimile."(Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14, 1982 Massachusetts Bay Insurance Company;Adopted September 7,2001 - Citizens Insurance Company of America) GIVEN under my hand and the seals of said Companies,at Worcester,Massachusetts,this day of Li, {,�� 20 ('. THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITI7S INSU CE COMPANY OF ERICA Ste,p6. .Brain, ssistan-s nl t Bond No. 1973 777 PAYMENT BOND (LABOR ANDMATERIALS) KNOW ALL PERSONS BY THESE PRESENTS that: WHEREAS, the City of Huntington Beach (hereinafter referred to as"City")has awarded to SANCON ENGINEERING, INC. DRIVE, HUNTINGTON BEACH, 92649 (name and address of Contractor) (hereinafter referred to as"Principal"),a contract("Contract")for the work described as follows: SEWER REHABILITATION PROJECT, CC-1396 IN THE CITY OF HUNTINGTON BEACH CA (project titre) WHEREAS, Principal is required under the terms of the Contract and the California Civil Code to secure the payment of claims of laborers, mechanics, materialmen,and other persons as provided by law. NOW THEREFORE, we, the undersigned Principal, and THE HANOVER INSURANCE COMPANY 2 MacArthur Place, Santa Ana, CA 92707 (name and address of Surety) (a duly admitted surety Insurer under the laws of the State of California and hereinafter referred to as"Surety"), as Surety,are held and firmly bound unto City in the penal sum of SIXTY ONE THOUSAND, EIGHTY AND 34/100 DOLLARS dollars, ($ 61, 080 . 34 ), this amount being not less than one hundred percent(100°l0)of the total price set forth in the Contract, in lawful money of the United States of America, for the payment of which sum, well and truly to be made, we bind ourselves, and each of our heirs, executors, administrators, successors, and assigns, jointly and severalty,firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the Principal, his, her, or its heirs, executors, administrators, successors or assigns, or subcontractors shall fail to pay any of the persons named in Section 3181 of the Califomla Civil Code("Claimants") for alil labor,materials or services used or reasonably required for use in performance of the work described in the Contract, or any amounts due under the Unemployment Insurance Code with respect to work,or labor performed by any such Claimant, or prevailing wages due and penalties incurred pursuant to Sections 1774, 1775, 1813 or 1815 of the Labor Code, or any amounts required to be deducted, withheld and paid over to the Employment Development Department from the wages of employees of the Principal and Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to the work or labor performed under the Contract, Surety will pay for the same, in an amount not exceeding the penal sum specified in this bond; otherwise,this obligation shall be null and void. This bond shall inure to the benefit of any of the persons named in Section 3181 of the Califomia Civil Code so as to give a right of action to such persons or their assigns. In case any action Is brought upon this bond, Surety further agrees to pay all court costs and a reasonable attomey's fee in an amount fixed by the court. Surety stipulates and agrees, for value received, that no change, extension of time, alteration, addition or modification to the terms of the Contract, or any contract document or any work to be performed thereunder, whether made after notice or not, shall In any way affect, Impair or release the obligations of Surety under this bond. Surety hereby waives notice of any such change, 2"SS9.1 PAYMENT BOND Page I of 2 Bond No. 1973 777 extension of time, alteration, addition, or modification to the terms of the Contract~ the contract documents or the work thereunder. Surety also waives the provisions of California Civil Code §§ 2845 and 2849. IN WITNESS WHEROF, each party represents and warrants that this instrument has been duly executed by Principal and Surety,on the date set forth below,that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this. instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond,waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: AUG. 23, 2011 ATTEST Oa O/A✓V SANCON ENGINEERING, INC. (Corporate Seal) (Principal Name) By: le�— I Name: 230$ AfoL c a G,.S`cA A-1 Its: : ATTEST THE HANOVER INSURANCE COMPANY (Corporate Seal) (Sur17- mej By: k Ati Name: Mi hael R. L an (Signature of Attorney-in-Fact for Surety) t714) 415-3800 (Attach Attomey-in-Fact Certificate) (Area Code&Telephone Number of Surety) APPROVED AS TO FORM: CITY OF HUNTINGTON BEACH By14ennifer a rath Attomey �l,sjob Note: This bond must be executed in duprkate and dated,all signatures must be notarized,and evidence of the authority of any person sfgnfng as attomey-fn-fact must be attached. 277589.1 PAYMENT BOND Page 2 of 2 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of _ Lot Angeles On ✓ before me, Kendra Michelle Bootp, Notary Public D Here Insert Name and Title of the Officer personally appeared Michael R. Langan Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to •--•--------- - -•--••-••-•-••••••••••••••••••'•.I be the person(f) whose name(o is/aFe subscribed to the i KENDRA MICHELLE BOOTS , within instrument and acknowledged to me that ''� COMM. 01766750 cn :� � -'= X he/�y-executed the same in his/Nxtbeicauthorized *%. c" NOTARY PUBLIC - CALIFORNIA U) > _,�,� LOS ANGELES COUNTY N capacity(OM), and that by his/tear signature(s) on the '' My Comm.Expires Oct.7,2011 E instrument the person(, or the entity upon behalf of ------•-•-••••-•••----.................................. which the person((,) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my ha d and official seal. Signature Place Notary Seal Above OPTIONAL Signature of Notary Public Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: LABOR AND MATERIALS PAYMENT BOND Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Michael R. Langan Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Partner—❑ Limited ❑ General _ _ _ ❑ Partner—❑ Limited ❑ General R Attorney in Fact - ElAttorney in Fact ElTrustee Top of thumb here ❑Trustee Top of thumb here ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representin Signer Is Representing: HANOVER ZNSU N E ANY AND OR MMSAEMUSEM PW 02007 National Notary Association•9350 De Soto Ave.,P.O.Box 2402•Chatsworth,CA 91313-2402•wvM.NationalNotaryorg Item#5907 Reorder:Call Toll-Free 1-800-876-6827 THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CITIZENS INSURANCE COMPANY OF AMERICA POWERS OF ATTORNEY CERTIFIED COPY KNOW ALL MEN BY THESE PRESENTS: That THE HANOVER INSURANCE COMPANY and MASSACHUSETTS BAY INSURANCE COMPANY, both being corporations organized and existing under the laws of the State of New Hampshire, and CITIZENS INSURANCE COMPANY OF AMERICA,a corporation organized and existing under the laws of the State of Michigan,do hereby constitute and appoint MICHAEL R.LANGAN Of Pasadena,CA and each is a true and lawful Attorney(s)-in-fact to sign,execute,seal,acknowledge and deliver for,and on its behalf, and as its act and deed any place within the United States,or, if the following line be filled in, only within the area therein designated any and all bonds, recognizances, undertakings,contracts of indemnity or other writings obligatory in the nature thereof,as follows: Any such obligations in the United States,not to exceed Ten Million and No/100($10,000,000)in any single instance and said companies hereby ratify and confirm all and whatsoever said Attorney(s)-in-fact may lawfully do in the premises by virtue of these presents. These appointments are made under and by authority of the following Resolution passed by the Board of Directors of said Companies which resolutions are still in effect: "RESOLVED, That the President or any Vice President, in conjunction with any Assistant Vice President, be and they are hereby authorized and empowered to appoint Attorneys-in-fact of the Company,in its name and as its acts,to execute and acknowledge for and on its behalf as Surety any and all bonds,recognizances,contracts of indemnity,waivers of citation and all other writings obligatory in the nature thereof,with power to attach thereto the seal of the Company.Any such writings so executed by such Attorneys-in-fact shall be as binding upon the Company as if they had been duly executed and acknowledged by the regularly elected officers of the Company in their own proper persons."(Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14,1982—Massachusetts Bay Insurance Company;Adopted September 7,2001-Citizens Insurance Company of America) IN WITNESS WHEREOF, THE HANOVER INSURANCE COMPANY, MASSACHUSETTS BAY INSURANCE COMPANY and CITIZENS INSURANCE COMPANY OF AMERICA have caused these presents to be sealed with their respective corporate seals, duly attested by a Vice President and an Assistant Vice President,this 12th day of July, 2010. THE HANOVER INSURANCE COMPANY MASSACHUSETTS SAY INSURANCE COMPANY CITIZEN,"SURANCE COMPANY OF AMERICA Qaze Mary Jeanne p—�ev6on.'vice Preside it Qx d' Robert K.Grennan,Assistan ,ice President THE COMMONWEALTH OF MASSACHUSETTS ) COUNTY OF WORCESTER )SS. On this 12th day of July, 2010 before me came the above named Vice President and Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, to me personally known to be the individuals and officers described herein, and acknowledged that the seals affixed to the preceding instrument are the corporate seals of The Hanover Insurance Company Massachusetts Bay Insurance Company and Citizens Insurance Company of America, respectively, and that the said corporate seals and their signatures as officers were duly affixed and subscribed to said instrument by the authority and direction of said Corporations. enaeAau ae ac c MMMON&m Notary Publfc ronmwsGoolcommawnr 1 My commission expires on November 3;2011 1, the undersigned Assistant Vice President of The Hanover Insurance Company, Massachusetts Bay Insurance Company and Citizens Insurance Company of America, hereby certify that the above and foregoing is a full, true and correct copy of the Original Power of Attorney issued by said Companies,and do hereby further certify that the said Powers of Attorney are still in force and effect. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of The Hanover Insurance Company,Massachusetts Bay Insurance Company and Citizens Insurance Company of America. "RESOLVED,That any and all Powers of Attorney and Certified Copies of such Powers of Attorney and certification in respect thereto, granted and executed by the President or any Vice President in conjunction with any Assistant Vice President of the Company,shall be binding on the Company to the same extent as if all signatures therein were manually affixed, even though one or more of any such signatures thereon may be facsimile." (Adopted October 7, 1981 -The Hanover Insurance Company;Adopted April 14, 1982 Massachusetts Bay Insurance Company;Adopted September 7, 2001 - Citizens Insurance Company of America) GIVEN under my hand and the seals of said Companies,at.Worcester,Massachusetts,this day of ` l�S 201 >,. THE HANOVER INSURANCE COMPANY MASSACHUSETTS BAY INSURANCE COMPANY CIT IN NCE COMPANY OF ERICA z Stepp Sraul,A"ssistant Vice Pres7a'r�t �r ® DATE(MMIDDYYY) A /Y CERTIFICATE F LIABILITY INSURANCE 9/28/2010 PROD IER (800)578-8802 FAX: (818)449-9321 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Poms & Associates Insurance Brokers, Inc. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR CA License #0814733 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. �)0 Canoga Ave. #400 Py h�odland Hills CA 91367 INSURERS AFFORDING COVERAGE NAIC# INSURED INSURER A:Travelers Insurance Companies 25647 Sancon Engineering, Inc. INSURER B:Starr Indemnity & Liab. Co. 38318 5841 Engineer Drive INSURER C: Huntington Beach, CA 92649 -INSURER D: INSURER E: COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OFSUCH POLICIES.AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADD'LI POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS LTR NSRD' TYPE OF INSURANCE DATE MM/DD/YYYY DATE MM/DD GENERAL LIABILITY EACH OCCURRENCE $ 1 000 000 DAMAGE TO RENTE—D X COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) $ 300,000 A CLAIMS MADE 7XI OCCUR TE-CO-9181R93A-TIL-10 10/1/2010 10/l/2011 MED EXP(Any one person) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG $ 2,000,000 X POLICY PRO- LOC JECT AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT X ANY AUTO (Ea accident) $ 1,000,000 A ALL OWNED AUTOS T-810-9181R93A-TCT-10 10/1/2010 10/1/2011 BODILY INJURY $ SCHEDULED AUTOS (Per person) X HIRED AUTOS BODILY INJURY X NON-OWNED AUTOS (Per accident) $ y PROPERTY DAMAGE $ (Per accident) A' VA GARAGE LIABILITY d AUTO ONLY-EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ 1�IIFEt CG _AT s Cl 0 AUTO ONLY: AGG $ EXCESS/UMBRELLA LIABILITY (� EACH OCCURRENCE $ 4,000,000 X OCCUR CLAIMS MADE AGGREGATE $ 4,000,00 A DEDUCTIBLE TSM-CUP9181R93A-TIL-10 10/1/2010 10/l/2011 $ X RETENTION $ 10,000 $ A WORKERS COMPENSATION TORY LIMITS O R AND EMPLOYERS'LIABILITY YIN ANY PROPRIETORIPARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICERIMEMBER EXCLUDED? (Mandatory in NH) TJ-UB-9818R93A-10 10/1/2010 10/l/2011 E.L.DISEASE-EA EMPLOYE $ 1,000,000 If yes,describe under SPECIAL PROVISIONS below E.L.DISEASE-POLICY LIMIT I$ 1,000,000 B OTHERCONTRACTOR'S SISIEIL70061310 10/1/2010 10/1/2012 LIMITS PER OCC: $2,000,000 POLLUTION LIABILITY AGGREGATE LIMIT $2,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT!SPECIAL PROVISIONS Re: All Operations It is agreed that the City of Huntington Beach, its agents, officers and employees are named as Additional Insured per the attached endorsement. Waiver of Subrogation applies to Workers' Compensation per endorsement attached. *10 Days notice of cancellation shall apply for non-payment of premium. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,THE ISSUING INSURER WILL AAK&VMXMAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, City of Huntington Beach A6 > 11 ( Q ` Attn: Christine Mendoza uYu. P.O. Box 190 Huntington Beach, CA 92648 AUTHORIZED REPRESENTATIVE Mary Healy Pavlo/NARY ACORD 25(2009/01) 01988-2009 ACORD CORPORATION. All rights reserved. INS025(200901).01 The ACORD name and logo are registered marks of ACORD Sancon Engineering, Inc. COMMERCIAL GENERAL LIABILITY Travelers Property Casualty Company of America Policy No. DTE-CO-9181R93A-TIL-10 10/1/10 - 11 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY BLANKET ADDITIONALINSURED (CONTRACTORS) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART 1. WHO IS AN INSURED -(Section II) is amended c) The insurance provided to the additional in- to include any person or organization that you sured does not apply to "bodily Injury" or agree in a "written contract requiring insurance" "property damage" caused by "your work" to Include as an additional insured on this Cover- and included in the "products-completed op- age Part, but: erations hazard" unless the "written contract a) Only with respect to liability for"bodily injury", requiring insurance" specifically requires you "property damage"or"personal injury"; and to provide such coverage for that additional insured, and then the insurance provided to b) If, and only to the extent that, the injury or the additional insured applies only to such damage is caused by acts or omissions of "bodily injury" or "property damage" that oc- you or your subcontractor in the performance curs before the end of the period of time for of "your work" to which the "written contract which the "written contract requiring insur- requiring insurance" applies. The person or ance" requires you to provide such coverage organization does not qualify as an additional or the.end of the policy period, whichever is insured with respect to the independent acts earlier. or omissions of such person or organization. 3. The insurance provided to the additional insured 2. The insurance provided to the additional insured by this endorsement is excess over any valid and by this endorsement is limited as follows: collectible "other insurance", whether primary, a) In the event that the Limits of Insurance of excess, contingent or on any other basis, that is this Coverage Part shown in the Declarations available to the additional insured for a loss we exceed the limits of liability required by the cover under this endorsement. However, if the "written contract requiring insurance", the in- "written contract requiring insurance" specifically surance provided to the additional insured requires that this Insurance apply on a primary shall be limited to the limits of liability re- basis or a primary and non-contributory basis, quired by that "written contract requiring in- this insurance is primary to 'other insurance" surance . This endorsement shall not in- available to the additional insured which covers crease the limits of insurance described in that person or organization as a named insured Section III-Limits Of insurance. for such loss, and we will not share with that b) The insurance provided to the additional in- other insurance". But the insurance provided to sured does not apply to"bodily injury", "prop- the additional insured by this endorsement still is erty damage" or "personal injury" arising out excess over any valid and collectible other in- of the rendering of, or failure to render, any surance", whether primary, excess, contingent or professional architectural, engineering or sur- on any other basis, that is available to the addi- tional insured when that person or organization is veying services, including: an additional insured under such 'other insur- 1. The preparing, approving, or failing to ance". prepare or approve, maps, shop draw- q, As a condition of coverage provided to the ings, opinions, reports, surveys, field or- additional insured by this endorsement: ders or change orders, or the preparing, approving, or failing to prepare or ap- a) The additional insured must give us written prove, drawings and specifications;and notice as soon as practicable of an "occur- II. Supervisory, inspection, architectural or rence" or an offense which may result in a engineering activities. claim. To the extent possible, such notice should include: CG D2 46 08 05 0 2005 The St. Paul Travelers Companies, Inc. Page 1 of 2 COMMERCIAL GENERAL LIABILITY 1. How, when and where the 'occurrence" any provider of'other insurance"which would or offense took place; cover the additional insured for a loss we ii. The names and addresses of any injured cover under this endorsement. However, this persons and witnesses;and condition does not affect whether the insur- ance provided to the additional insured by III. The nature and location of any injury or this endorsement is primary to 'other insur- damage arising out of the 'occurrence"or ance" available to the additional insured offense. which covers that person or organization as a b) If a claim is made or"suit' is brought against named insured as described in paragraph 3. the additional insured, the additional insured above. must: 5. The following definition is added to SECTION V. 1. Immediately record the specifics of the —DEFINITIONS: claim or"suit'and the date received; and "Written contract requiring insurance" means II. Notify us as soon as practicable. that part of any written contract or agreement The additional insured must see to it that we under which you are required to include a receive written notice of the claim or"suit'as person or organization as an additional in- soon as practicable, sured on this Coverage Part, provided that the bodily injury and property damage oc- c) The additional insured must immediately curs and the"personal injury" is caused by an send us copies of all legal papers received in offense committed: connection with the claim or"suit", cooperate a. After the signing and execution of the with us in the investigation or settlement of the claim or defense against the "suit', and contract or agreement by you; otherwise comply with all policy conditions. b. While that part of the contract or d) The additional insured must tender the de- agreement is In effect; and fense and indemnity of any claim or "suit"to c. Before the end of the policy period. The City of Huntington Beach, its officers, elected and appointed officials, employees, agents and volunteers are named as Additionally Insured" . Page 2 of 2 0 2005 The St. Paul Travelers Companies, Inc. CG D2 46 08 05 CONTRACTOR'S OR'S SWORN ORN STATEMENT AND WARRANTY REGARDING CONTINUING INSURANCE OBLIGATIONS FROM: sA�'Ce�n� �iVC�/n`���nll�:�N� PROACT: c G Skmt-& (Contractor Name) (Street Address) (City,state and zipj TO: CM OF HUNTINGTON BEACH ®EiCL RATION Attached hereto is a true and correct copy of the current Certificate of Insurance and Additional Insured Endorsement CG 2010 1185, which Certificate complies with the insurance requirements of the Contract by and between the City of Huntington Beach("City)and the above-named Contractor("Contractor")for the above-described project("ProjectJ. I declare under penalty of perjury under the laws of the State of California that the above statement Is true and correct Signedon 2!Z 20t1 at &ln CW,,l SA'CW G-k. (Date) (City,state) (Signature of Individual W% is Making Declaration) WARRANTY Contractor hereby warrants and agrees to maintain Products and Completed Operations Insurance in compliance with the Insurance requirements of the Contract for the Project. Said Insurance shall be maintained through and until the expiration of all Warranties provided by Contractor. Said insurance shall contain Additional Insured Endorsement CG 2010 1185,naming City as an additional insured. Contractor shall supply to City,on at least an annual basis,a Certificate of Insurance and the aforementioned Endorsement evidencing continued coverage which meets the Contract requirements. ,h Signed on Ap,�ws'r :21 20�// at Vniya,71V 'G'X. (Date) (City,State) CONTRACTOR: f Name; (��,,✓ /�/ /� er1i�, { x/ti'`� Name: B 0 0 )i.,L1^' u"`�i✓/� �-�.,—�,_..... Title: z7962i.2 Company Profile Page 1 of 2 COMPANY PROFILE Company Profile Company Search Company Information Company Search Results Company HANOVER INSURANCE COMPANY(THE) Information 440 LINCOLN STREET Old Company WORCHESTER, MA 01653 Names 800-955-8850 Agent for Service Reference Old Company Names Effective Date Information NAIC Group List back to top Lines of Business Financial Statements Agent For Service PDF's Annual Statements NANCY FLORES C/O CT CORPORATION SYSTEM Quarterly 818 WEST SEVENTH STREET Statements LOS ANGELES CA 90017 CA Supplements Company Complaint back to top Company Performance& Reference Information Comparison Data Company NAIC #: 22292 Enforcement Action Composite California Company ID #: 2097 4 Complaints Studies Additional Info Date Authorized in California: O1/O1/1973 Find A Company License Status: UNLIMITED-NORMAL Representative In Your Area Company Type: Property&Casualty View Financial Disclaimer ate of Domicile: NEW HAMPSHIRE St back to top NAIC Group List NAIC Group #: 0088 The Hanover Ins Grp back to top Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary. AIRCRAFT AUTOMOBILE BOILER AND MACHINERY BURGLARY COMMON CARRIER LIABILITY CREDIT DISABILITY http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPro... 9/7/2011 7r-; . 'tC �J Council/Agency Meeting Held: Deferred/Continued to: Appved ❑ ❑Conditionally Approved Denied ol� ''/Cit ro Cler s Sign re Council Meeting Date: August 15, 2011 Departme4t ID Number: PW 11-045 CITY OF HUNTINGTON BEACH REQUEST FOR CITY COUNCIL ACTION SUBMITTED TO: Honorable Mayor and City Council Members SUBMITTED BY: Fred A. Wilson, City Manager PREPARED BY: Travis K. Hopkins, PE, Director of Public Works SUBJECT: Approve Project Plans and Specifications and Award Construction Contract in the Amount of$61,080.34 to Sancon Engineering, Inc. for the Sewer Lining Project at Beach Boulevard, Clarkdale Drive, and Cliff Drive, CC 1396 Statement of Issue: On July 26, 2011, bids were opened for the Sewer Rehabilitation Project CC-1396 for the Sewer Lining Project at Beach Boulevard, Clarkdale Drive, and Cliff Drive, CC 1396. City Council Action is requested to award the construction contract to Sancon Engineering, Inc., the lowest responsive and responsible bidder. Financial Impact: Funds in the amount of $75,000 are available in the Sewer Service Charge Fund, Sewer Lining, Account No. 51189002. Recommended Action: Motion to: A. Approve the project plans and specifications for the Sewer Lining Project at Beach Boulevard, Clarkdale Drive, and Cliff Drive, CC 1396; B. Accept the lowest responsive and responsible bid submitted by Sancon Engineering, Inc. in the amount of $61,080.34; and C. Authorize the Mayor and City Clerk to execute a construction contract in a form approved by the City Attorney. Alternative Action(s): Reject all bids and provide staff with an alternative direction. HB -57- Item 4. - I REQUEST FOR COUNCIL ACTION MEETING DATE: 8/15/2011 DEPARTMENT ID NUMBER: PW 11-045 Analysis: The project consists primarily of lining 2,545 lineal feet of deteriorated sewer main lines within the sewer line reaches (1) Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac, and (3) Cliff Drive from Brookhurst Street to Spindrift Lane. A complete set of plans and specifications are available for review at the Public Works counter during regular working hours. The bids were publically opened on July 26, 2011. The verified bid amounts are listed below: Bidding Contractor Bid Amount Submitted Verified (Amount Read at Bid Total Bid Opening) Amount Sancon Engineering, Inc. $61,080.34 $61,080.34 Insituform Tech. $79,064.00 $79,064.00 Southwest Pipeline $83,865.00 $83,865.00 Repipe $97,775.00 $97,775.00 Staff recommends award of the construction contract to Sancon Engineering, Inc. in the amount of $61,080.34. Sancon Engineering, Inc. has performed successfully on similar projects. The total estimated project cost is $75,000.00 which includes the construction contract, project management, contingencies, and 5% supplementals. Public Works Commission Action: The Public Works Commission reviewed and approved the project on June 15, 2011, with a vote of 7-0-0. Environmental Status: The project is categorically exempt pursuant to Class 1, Section 15301(c) of California Environmental Quality Act. Strategic Plan Goal: Maintain, improve and obtain funding for infrastructure and equipment Attachment(s): o s - o . 1. Location Ma Item 4. - 2 xB -58- ATTACHMENT # 1 IL- nB„9 Item a. - t i • a 5 d ii■WN III INCOME f �`" •,� 04 �R a IN 2011 SEWER LINING LOCATION MAP CC- 1396 I I _ el ,t •1.V�ilaitti[� tau;la_p i 7�N:�JIIJ�N; Z � I � � I i ai • 11+ i CITY OF HUNTINGTON BEACH Sewer Rehabilitation Project C.C. NO. 1396 BID OPENING DATE: July 26, 2011 TIME: 2:00 PM ENGINEER'S ESTIMATE: $100,000 BIDS SUBMITTED (AS READ AT OPENING) No. BIDDER'S NAME RANK APPARENT BID AMOUNT 1 Insituform, Fullerton 2 SAK Construction of CA, Whittier 3 Sancon Engineering, Huntington Beach I 0 � 4 Southwest Pipeline, Gardena CPR. `�� 6 7 8 9 10 11 12 13 14 15 16 17 CC 1396 Bid Opening Worksheet.xlsx 7/26/2011 10:03 AM L-z 00 J 9 z -ifir I I oz NOTICE INVITING SEALED BIDS for the SEWER REHABILITATION PROTECT CC No. 1396 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated project and will receive such bids in the office of the City Clerk, Second Floor, 2000 Main Street, Huntington . Beach, California 92648, up to the hour of 2:00 P.M. on Tuesday, July 26, 2011. Bids will be publicly open in the Council Chambers unless otherwise posted. Copies of the Plans, Specifications, and contract documents are available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $25.00 nonrefundable fee if picked up, or payment of a $40.00 nonrefundable fee if sent by UPS ground delivery (bidder shall pay additional costs for special delivery). Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders. The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a -1 State Contractor's License Class A at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. Installation of the sewer lining shall be performed by a Contractor licensed by the manufacturer owner of the process. Bidders are required to submit a copy of such license with their bid. If the cony of such license is not included with the bid proposal, the bid shall be considered non- responsive. The minimum liner's wall thickness shall be verified as calculated per ASTM F 1216 (ASTM Appendix XI). The physical properties listed below shall be used in the ASTM F 1216 calculations. The Contractor shall submit with the bid, one clear, accurate, and legible copy of the calculations, signed by a registered Civil Engineer in the State of California. Unless otherwise demonstrated by the calculations (CIPP only) the minimum liner wall thickness allowed shall be 0.225 inches for 8 inch, 0.280 inches for 10 inch, 0.336 inches for 12 inch, and 0.420 inches for 15 inch. If the calculations are not included with the bid proposal, the bid shall be considered non- responsive. Project Description: The project consists primarily of lining 2,545 lineal feet of deteriorated sewer main lines within three residential tracts. The three sewer line reaches are (1) Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac, and (3) Cliff Drive from Brookhurst Street to Spindrift Lane. e The contract shall allow the Contractor 30 working days to complete the contract for lining 2,545 linear feet of deteriorated sewer main lines, the basis of Award. • The engineer's estimate of probable construction cost for the work included in the basis of award is $100,000. The AGENCY reserves the right to reject any or all bids, to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH, CALIFORNIA, the 20th day of September 2010, by Resolution No. 2010-69. Attest: Joan L. Flynn CITY CLERK OF THE CITY OF HUNTINGTON BEACH A-2 Ross, Rebecca From: Wagner, Jim Sent: Thursday, June 30, 2011 2:00 PM To: Ross, Rebecca Cc: Flynn, Joan; Esparza, Patty; Fuentes, Joe; Charlonne, Eric; Birchfield, Mark; McElroy, Dorien Subject: CC-1396 Sewer Rehabilitation Project NISB Attachments: CC-1396 NISB Transmital To Clerk.pdf; Notice Inviting Sealed Bids CC-1396.doc Please find attached the Notice Inviting Sealed Bids for advertisement on 7/7/11, 7/14/11 and 7/21/11. The bid opening is scheduled for 7/26/11 at 2:00 PM. (We will also be opening CC-1394 Streets immediately after) If you have any questions regarding the enclosed attachment, feel free to contact me at iwagneransurfcity-hb.orq or(714) 536-5467 or Joseph Fuentes at extension 5259. This is the only notice that you will receive, please request a copy of the original if you would like it. THX Jirn Wagner,FF I CITY OF H B Public Works Dept.,First Floor 2000 Main Street Huntington Beach,CA 92648 714-536-5467 1 CITY OF HUNTINGTON BEACH PUBLIC WORKS DEPARTMENT 2000 Main Street P . O Box 190 Huntington Beach , CA 92648 LETTER OF TRANSMITTAL Fax (714) 374-1573 Attention: Joan L. Flynn Date: June 30,2011 To: City Clerk's Office ProjectlC.C. No.: CC No. 1396 2000 Main Street Regarding: Sewer RehabilgationProiect Huntington Beach, CA 92648 (1)Beach Boulevard from Edinger Avenue to Stark Avenue (2)Clarkdate Drive from Edgewood Lane to the end of the cul-de-sac (3)Clfff Drive from Brookhurst Street to Spindrift Ln. ® We are sending you: ❑ By Mail ❑ By Fax Mail(Number of pages including this shoot:) ❑ We are hand delivering: ❑ Attached ❑ Under a separate cover via the following items: ❑ Shop drawings ❑ Prints ❑ Plans ❑ Samples ❑ Specifications ❑ Copy of letter ❑ Change Order ❑ Other: Item#. Copies Pages Description 1 1 2 Notice Inviting Sealed Bids for CC-1396, Sewer Rehabilitation Project These are transmitted as checked below: ❑ For approval ❑ Approved as submitted ❑ Resubmit copies for approval ® For your action ❑ Approved as noted ❑ Submit copies for distribution ❑ As requested ❑ Returned for corrections ❑ Return corrected prints ❑ For reviewicomment ❑ Other: Remarks: Per Resolution 2010-69 (adopted on 9/20/10), the City Council authorized the advertisement of the above listed sewer rehabilitation project. Please find attached the Notice Inviting Sealed Bids for advertisement on 717/11, 7/14/11 and 7/21/11. The bid opening is scheduled for 7/26111 at 2:00 PM. (We will also be opening CC-1394 Streets immediately after) If you have any questions regarding the enclosed attachment,feel free to contact me at iwagner surfcity-hb.org or(714)536-5467 or Joseph Fuentes at extension 5259. c: file B Jim Wagner,PE,Senior Civil ngineer GAConstruction Contracts(CCs)\CC1396 Sewer Rehailitation Project\CC1396 NISB\CC-1394 NISB Transmital To C1erk.docx r 1 NOTICE INVITING SEALED BIDS for the SEWER REHABILITATION PROJECT CC No. 1396 ' i in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated project and will receive such bids in the office of the City Clerk, Second Floor, 2000 Main Street, Huntington Beach, California 92648, up to the hour of 2:00 P.M. on Tuesday, July 26, 2011. Bids will be publicly open in the Council Chambers unless otherwise posted. Copies of the Plans, Specifications, and contract documents are available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $25.00 nonrefundable fee if picked up, or payment of a $40.00 nonrefundable fee if sent by UPS ground delivery (bidder shall pay additional costs for special delivery). Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office . of the Director of Public Works,2000 Main Street,Huntington Beach, CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders. The bid must be accompanied by a i certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a f F t Ross, Rebecca From: Ross, Rebecca Sent: Thursday, June 30, 2011 4:04 PM To: 'Arretche, Daniel' Cc: Esparza, Patty Subject: CC-1396 Sewer Rehabilitation Project NISB Attachments: Notice Inviting Sealed Bids CC-1396.doc Hi Daniel, Please find attached the Notice Inviting Sealed Bids for advertisement on 7/7/1.1, 7/14/11 and 7/21/11. Please confirm receipt of this request. Thanks! Rebecca Ross, CMC Senior Deputy City Clerk City of Huntington Beach 714.53f.5209 www.huntingtonbeachca.gov Apply for your passport in the City Clerk's Office! Keep America Beautiful! Reduce-Reuse-Recycle 1 c pass 1 Fi E a r'�r�:� �r'� `[ Doll Plot WHYNot ADVERTISING � y by:0 i3et Cia�atnino un�0,2b11;4" pm H,B.I. `Salesperson: H.B.I. Phone: Ad#34422640 llccouritlntormatfon == Adfnformatton ice-- ;hb Vi 7t4'53(i�5227 ` f ( ) $taridate. 07-07 11 _ Sze 2x i 13.550 Name CITY OF HUNTINGTON BEACH Stopdate 07-21-11 Billed size 11.50 TCN inch r r Address: P.O.BOX 784 irlsertlons 3 Keywtlyd'j HUNTINGTON BEACH,CA 92648 Rateco+3e B�Legal Huntington Beach Ad#ype�Liner u 3 Taken by 0622 Daniel Arretche cct# 4 277391004 # C - t Notices .• At � e lalssification 13(100 L�a ; wit Putrltcatio_ris TCNHBf Ctient CLERK_SOFFICE-CITYHUNTING- }s ( F: TO BEACH Placedby Rebecca Ross j Fax#e(714)374-1557 Ad Copy: NOTICE INVITING SEALED BIDS for the SEWER REHABILITATION PROJECT CC No.1396 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated protect and Will receive such bids in the office of the City Clerk, Second Floor, 2000 Main Street, Huntington Beach, California 92648, up to the hour of 2:00 P.M. on Tuesday, July 26, 2011. Bids will be publicly open in the Council Chambers unless otherwise posted. Copies of the Plans,Specifications,and contract documents are available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $25.00 nonrefundable fee if picked up, or payment of a $40.00 nonrefundable fee if sent by UPS ground delivery (bidder shall pay additional costs for special delivery), Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000 Main Street,Huntington Beach,CA 92648. The AGENCY will deduct a 10% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the California Government Code, Section 4590. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders. The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State Contractor's License Class A at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. Installation of the sewer lining shall be performed by a Contractor licensed by the manufacturer owner of the --- ad proof pg.1 --- aHyPflot AavER-rrsii ` Da fly it Not rinitfeti' y R Oe riciaGa no _ _ JunN6�fi�Salesperson: (' • • i 1�.9A0 f Phone: Ad#34422 stib"M a copy of'auci I cerise vv�fh +eirf o copy of such license is not included with rho bid proposal, the bid shall be considered non- responsive. Me minimum liners wall thickness shall be verified as calculated per ASTM F 1216(ASTM Appendix XI), The Physical properties listed below shall he used in the ASTM F 1216 -calculations. The Contractor shall submit with the bid, one clear, accurate, and legible copy,of the calculations, signed by a registered Civil Engineer in the State of California.Unless otherwise demonstrated by the calculations(CIPP only) the minimum liner wall thickness allowed shall ba 0,225 Inches for 8 inch,0.280 inches for 10 inch.0.336 inches for 12 Inch, and 0.420 inches for 15 inch. ff tho calculations aro not included with the. bid proposal, the bid shall be considered non- rocpensive.' Projocs Doscriptian:The project consisispfimarily of lining-2,545 lineal feet of deteriorated sewer I ain fines within three residential tracts.The three sewer line reaches are(1)Beach Boulevard from Edinger Avenue.fo Stark Avenue, (2) Clarkdale Drive from.Edgewood Lane to the end of the eul- do-sac,and(3)Cliff Drive from Brookhurst Street to Spindrift Lana, 4D The contract shall allow the Contractor 30 working days to complete the contract for fining 2.545 linear feet'of'deteriarated sewer main lines, the basis of Award. i The engineer's estimate of probable construction cost for the work included in the basis of award is$100,000. The AGENCY reserves the right to reject any or all bids,to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH. CACIFORNIA, the 20th day of September 2010.by Resolution No,20M69. Att sC Joan L.Fl nn CII T Ut.• ITY OF HUNTINGTON BEACH Published Huntington Beach Independent July), 14.and 21,201I --- ad proof pg.2 CITY OF IIUNTINGTON BEACH Sewer Rehabilitation Project C.C. NO. 1396 BID OPENING DATE: July 26, 2011 TIME: 2:00 PM ENGINEER'S ESTIMATE: $100,000 BIDS SUBMITTED (AS DEAD AT OPENING) No. BIDDER'S NAME RANK APPARENT BID AMOUNT 1 Insituform, Futlerton i�66 '"A ..� �f , t 2 SAK Construction of CA, Whittier 3 Sancon Engineering, Huntington Beach � �, ) , 4 Southwest Pipeline, Gardena 60 5 �: i r 6 7 8 9 10 11 12 13 14 15 16 17 CC 1396 Bid Opening Worksheet.xlsx 7/26/2011 10:03 AM UNSUCCESSFUL BIDS CC- 13 96 Sewer Rehab Project City ®f Huntington Beach e 2000 Main Street o Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeacbca.gov iI in.V, ® ®Bice of the City Clerk Joan L. Flynn, City Clerk September 30, 2011 Insituform Technologies, Inc. 17988 Edison Ave. Chesterfield, MO 63005 RE: CC-1396— Sewer Rehab Project Enclosed please find your original bid bond for CC-1396. Sincerely, t Joan L. Flynn, CIVIC City Clerk JF:pe enclosure g9&bw0 iewnt*mPJtt o* Waitakere,New Zealand .. ryry(` t : .',, n [_ q_ `_. ' pip gyp. fo r Technologies, Inc. SEALED BID FOR: SEINER REHABILITATION PROJECT CC NO. 1396 Bidder: INSITUFORM TECHNOLOGIES,INC. 17988 EDISON AVE. CHESTERFIELD,MO 63006 California Contractor's License No.: 768411 Class A Deliver To: CITY OF rHUNTINGTON BEACH OFFICE OF THE CITY CLERIC 2N® FLOOR, 2000 MAIN STREET HUNTINGT®N BEACH, CA 92648 BID DUE Date: 7/26/2011 Tim 2:00 PM SECTION C PROPOSAL for the SEWER REHABILITATION PROJECT CC No. 1396 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 30 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifcations, Instructions to Bidders and all other contract documents. if this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. if at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-t If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER,the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may,at the AGENCY'S option,be considered null and void. bid Accompanying this proposal of bid, find Bidders Bond in the amount of$ io 0 of amount�Vhich said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check",or"Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here,if any: Addenda No. Date eceiyed Bidder's Signature ?/r C-2 ADDENDUM NO. 1- PROJECT BID SCHEDULE CC-1396 SEVER LINING �m l t t. ::' xte," e :: �.:::. rii: ''' ':i fedn: :::::::::::::::::::::::::::::: >Ecct. e.....escr P 1 1 Mobil ization/Demobilization LS $ S,(000.0o $ 51&C0.00 2 1 Furnish Traffic Control LS $ 3,60b .06 $ '3�.0 3 2545 Clean and inspect 8"sewer main LF $ 1.10 $ �p5y, 00 4 2545 Install liner and post inspect 8"sewer main LF $ 2 OU $ .00 5 58 Grind and re-open sewer service lateral EA $ DO 6 1 Prepare Construction Traffic Control Plans LS $ b�10•�o $ 010.d- Total Amount Bid in Figures: $ dO Tot ..................................................... ----------------------------------------- �r�.lEr� NtnJF rJi s X ICU -•--Nt C-2.3 i? is SECTION C PROJECT BID SCHEDULE INDEX SEWER REHABILITATION PROJECT CC NO. 1396 The three sewer line reaches are(1)Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac, and(3)Cliff Drive from Brookhurst Street to Spindrift Lane, PROJECT BASE BID: Basis of Award SEWER REHABILITATION PROJECT C-2.2 to C-2.3 BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: 9 C ) BASE BID WILL BE THE BASIS OF AWARD C-3 BASIS OF AWARD PROJECT BID SEWED REHABILITATION CC NO. 1396 G4 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class of Work Number Xe&RMP,'JC'C-_ G y2_ #b2 `( 10 w A�. mil 8 L Nti C-- 2 By submission of this proposal,the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-5 NONCOLLUSION AFFIDAVIT TO BE EXECUTED DX BIDDER AND SUBMITTED WITH BID State Of GRIM 4 Missouri ss. County of(W&iff St. Louis H. Douglas Thomas , being first duly sworn, deposes and says that he or she is VP-Global Procurement/Operations Suppcof Insituform Technologies, Inc. the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation,partnership, company association,organization,bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Insituform Technologies, Inc. Name of Bidder Signature o d�H. Douglas Thomas VP-Global Procurement/operations Support 17988 Edison Ave. Chesterfield, MO 63005 Address of Bidder Subscribed and sworn to before me this 26 day of July 201 1 DENISE L.CRROLL Nottaaryry Public-Notary Seal STATE OF MISSOUR! NOTARY PUBLIC �,f',� o ? Pike Coun / mission x '✓ Commission= 11, � C-6 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH,CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract,known as the SEWER REHABILITATION PROJECT, (1)(we)(it)will employ and utilize only qualified persons, as hereinafter defined,to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8,California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Insituform Technologies, Inc. Contractor i n. ouglas Thomas VP-Global Procurement/Operations Support Title Date: July 26, 2011 C-7 DISQUALIIF'ICA'TION QUESTIONNAIRE In accordance with Government Code Section 1431 d.5, the Bidder shall complete, under penalty of perjury,the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified,removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes El No If the answer is yes,explain the circumstances in the space provided. N/A Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-8 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Insituform Technologies, INc. Contractor By H. Douglas Thomas VP-Global Procurement/Operations Support Title July 26, 2011 Date: C-9 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Insituform Technologies, Inc. Bidder Name 17988 Edsion Ave. Business Address Chesterfield MO 63005 City, State Zip 636 1 530-8000 Telephone Number 758411 Class A State Contractor's License No. and Class 1/26/99 Original Date Issued' 1/31/2013 Expiration Date The work site was inspected by L6NN�/ L Av6(-4 of our office on 2-7 2011 . The following are persons, firms, and corporations having a principal interest in this proposal: See Attached list of officers C-10 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Insituform Technologies, Inc. Company Name Signatur. Bidder H. Douglas Thomas, VP-Global Procurement/Operations Support Printed or Typed Signature Subscribed and sworn to before me this 26 day of July � 201 I ` ,�� DtEaryNISE L,CARRpLL NOTARY PUBLIC / �'� G� �STA publiE 0 c-Not�rY�l My Cotn ( �4�91��L fires: c,5,2013 Commission#09309892 Listed below are the names, address and telephone numbers for three public agencies or i the bidder has performed similar work within the past two years: 1. Please See Attached Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 2. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 3. Name and Address of Public Agency Name and Telephone No. of Project Manager.- Contract Amount Type of Work Date Completed C-11 1-N, Sl tJRr*i TECHNOWGIES,INC, Assistant SecretaWs Certificate .. The undersigned, being the Assistant Secretary of Insituform Technologies, Inc., a Delaware corporation(the"Corporation"),hereby certifies that: t, The following is a true and correct.excerpt ttom the lay=laws of the Corporation: Chief-vecutive Officer Appointn+ents The Chief Executive Officer may froin time to time appoint such officers of operating divisions,and such contracting and attesting officers,of the . Corporation as the Chief Executive Officer may deem proper,who shall have such authority,subject to the control of the Board,as the Chief Executive Officer may from time.to time prescribe. 2 The Chief Executive Officer of the Corporation has, pursuart to the above authority, duly appointed H. Douglas Thomas, Vice President -Global ProcuremendOperations Support,and has appointed Joann Smith, Denise.L. Ca.rroll,.Debra Jasper, Jana Lause acid Diane Partridge as Contracting and Attesting Officers of the Corporation. Each of the foregoing have been fully authorized and empowered by the Chief Executive Ofjfioer of the Corporation:"(i)to certify and to attest the signature of any officer of the Corporation, (ii)to enter into and to Bind the Corporation to perform pipeline rehabilitation activities of the Corporation and all matters related thereto, including the maintenance of one or more offices and facilities of the Corporation, (iii)to execute and to deliver documents on behallf of the Corporation.and(iv)to take such other action.as is orb may be necessary and appropriate to eany out the projects,activities and work of the Corporation." IN WITNESS WHEREOF, I have hereunto affixed my name as Assistant Secretary,this 25thday of March,2010. INSITUkOIZM TECHNOLOGIES,INC. Fay: April A 'reec Assistant Secretary Irs®tuf®rm 1kh-nolaghe .lna INSITUFORM TECHNOLOGIES,INC. OFFICERS AND DIRECTORS CURRENT AS OF FEBRUARY 1,2011 _DIRECTORS,, i J.Joseph Burgess Director Stephen P. Cortinovis Director Stephanie A.Cuskley Director John P.Dubinsky Director Charles R. Gordon Director Juanita H.Hinshaw Director M.Richard Smith Director Alfred L.Woods Chairman of the Board 4 7a =, OFFICERS'' J.Joseph Burgess President and Chief Executive Officer David F.Morris Senior Vice President, General Counsel,Chief Administrative Officer and Secretary David A.Martin Senior Vice President and Chief Financial Officer Brian J. Clarke Senior Vice President—Business Integration Kenneth L.Young Vice President and Treasurer Holly S. Sharp Vice President—Human Resources and Environmental,Health and Safety Tod O'Donoghue Assistant Secretary Lori Knudson Assistant Secretary April A. Greer Assistant Secretary Business Address for Officers and Directors: 17988 Edison Avenue Chesterfield,MO 63005 ins tuform _ - W.'rrrldwide Pipatine 17988 Edison Avenue Tel. (636)530-800b RMahilatatio;n Chesterfield,MO 83005 Fax: (636)530 8744 � �v.��r.isitu`orm:ccivn ' March lb. `'009 RE: INSTAL.LE CERTIFICATION ro Whom It lvlav Concern; 'lease be advised that.lnsituform Technologies Inc is a vertically integrated pipeline rehabilitation c6mpanY. As such, Insituform is not o lv the manufacturer of the cared-in- 4 place pipeline rehabilitation system of the; §arne name, but also offer,the benefits of a full research and development department, licensed engineers on staff for design of-products to suit each individual situation.rind regional contracting offices that perform all field si r0ces including installation. This letter shall serve to certify that Insituforrn Technologies, Inc. is authorized to install Insituform products supplied by Insituform Technologies.Inc. Sincerely. INSITUFOR-IM TECHNOLOGIES, INC. . i Charles F:Voltz:: r Senior Vice'Presid'nt North American Rehabilitation i �l S`fATE OF MISSOU RI COUNTY OF S`I".CH RLE.S Subscribed and sworn- before me on March 16, i009. o i. 0rs° Pub is - � - CITY OF HUNINGTON BEACH THREE CERTIFIED LABORATORIES Insituform Technologies, Inc. Ramtech Laboratories 14104 Orange Avenue Paramount, CA 90723 562-633-4824 Radco Labs 3220 E. 59, St Long Beach, CA 90805 562-272-7231 SGS U. S. Testing Labs 5555 Telegraph Road Los Angeles, Ca 90040 Jay Gorhale State JobNumber Owner/Contractor Job Classification Cnt/Fini Amount Project Description Project Location Comp. CA 200139 Tierra Contracting 75 L F,of 24 IN. MM $85,803.75 Fielding Graduate University Storm Santa Barbara,CA In Process 0 L,F.of IN. MM Drain Rehab 5484 Overpass Road $0.00 0 L.F.of IN, MM 0 L.F.of IN. MM Goleta CA 93111 0 L F.of IN. MM 0 L F-of IN. MM SC's: Randy Douglas 0 L.F.of IN, MM MH's: 805-964-8747 0 L.F.of IN. MM CA 200140 Buena Sanitation District 1465 L F of 8 IN, MM $126,841,00 Gravity Main Dutile Iron Pipe Rehab Vista CA in 191 LF of 15 IN, MIA 600 Eucalyptus Ave $0.00 0 L.F.of IN. MM 0 L F,of IN. MM Vista CA 92084-6240 0 L.F.of IN, MM 0 L.F.of IN, MM SC's'. Mark Sullivan,P.E. 0 L F.of IN MM MH's: 0 760-726-1340 0 L.F,of IN, MM G'A 200 141 Buena Sanitation District 350 L F.of 30 IN MM $142.096.90 Outfall Emergency Sewer Lining Vista,CA In flfocvs 0 L.F,of IN. MM Project 600 Eucalyptus Ave. 0 L F.of IN, MM $0.00 0 L.F.of IN. MM Vista, CA 92064 0 L.F.of IN MM 0 L.F of IN. MM SC's: Mark Sullivan 0 L F of IN. MM MH's: 0 760-726-1340 0 L.F.of IN. MM CA 200142 City of Buena Park 3543 L.F.of 8 IN. MM $88,918.60 Lining of Existing Sewer Mains Buena Park,CA I-,rrocess 0 L•F.of IN. MM 6650 Beach Blvd $0.00 0 L.F.of IN. MM 0 L.F.of IN. MM Buena Park CA 90622 0 L.F.of IN. MM 0 L F.of IN. MM SC's-' Linda Long 0 L F,of IN. MM MH's: 0 714-562-3750 0 L.F.of K MM State JobNumber Owner/Contractor Job Classification Cnt/Fini Amount Proiect Description Project Location �C CA ?00134 snutil Coast Water District 2216 L.F.of 6 IN, MM $193,921.00 Sewer Lining Repairs Dana Point and Laguna In Process 3783 L.F of 8 1W MM Beach 31S02\Nest Strc-ot $0,00 175 L F.of to IN.. MM 0 L,F.of IN, MM Laguna Beach CA 92651 0 L.F.of K MIA 0 L.F.of W. MM SC's: Joseph N.McDivitt 0 L,F.of IN. MM MH's: 0 949-499-4555 0 L F.of IN, MM CA 200135 South Coast Water District 1318 L F,of 15 IN, MM $108,543.00 Lift Station#6 Gravity Main Lining Dana Point,CA In proc':"ss 0 L.F,of IN, MM Repairs 31592 West Street $0.00 0 L F of IN MM 0 L.F.of IN, MM Laquria Beach CA 92651 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: Joseph N.McDivitt 0 L.F.of IN, MM MH's.' 3 949-499-4,`55 o L F,of IN. MM CA 200136 UMVERSI I-Y OF CALIFORNIA 700 L.F of 1 G1 IN, mm $49,350.00 EAST CAMPUS OFFICE BUILDING, LA JOLLA,CA IN 0 L F,of IN. MM INSTALL CIPP,PROJECT#A4M- PROGRESS 10280 NORTH TORREY PINES RD,SURL 466 $0.00 970/4419 0 L.F.of IN MM 0 L.F.of IN MM 1 AJOLLA CA 92ufI3-0916 0 L.F.of IN. MM 0 L F.of IN, MM SC's: THOMAS WILSON 0 L.F.of IN, MM MH's: 0 858 534 19qI 0 L.F.of IN, MM CA 2001,57 Charies King Company 12715 L.F.of 8 IN. MM $365,270.00 Sewer Rehab Project Chula Vista,CA In Process 660 L.F.of 18 IN. MM 2841 Gardens Ave $0.00 0 L.F.of IN. MM 0 L.F.of IN. MM Signal HO CA 97055 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: Debi Hawkins 0 L F.of IN. MM MH's: 0 562 426 2974 0 L.F.of IN. MM CA 900133 City of"San Diego 4932 L.F of 27 IN. MM $1,547,178.93 Trunk Sewer Rehab San Diego,CA In Process 3229 L,F,of 30 IN. MM 1200 1 hifd Ave Suite 200 $0.00 0 L.F of IN. MM 0 L F.of IN. MM S,nr,Diego CA 92101 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: Darmvm Singleton 0 L.F,of IN. MM MH's: 36.6000 0 L F.of IN, MM State JobNurnber Owner/Contractor Job Classification Cil Amount Project Description Project Location pomp. CA 200128 Charles King Company,Inc. 558 L.F.of 12 IN. MM $412,357.60 Trunk Sewer Line Rehab Simi Valley,CA In Praces" 375 L.F of 24 IN. MM 2841 Gardena Ave. $0.00 492 L F.of 30 IN. MM 514 L F.of 36 IN. MM Signal Hill CA 90755 310 L.F.of 39 IN, MM 0 L.F.of IN. MM SC's: Steve Radaich 0 L F,of IN. MM MH's: 0 562-426-2974 L I-.of IN, MM CA 200129 Ramona.Inc 5208 L.F of 8 IN MM $164,655.10 Contract#2010-02 SSRP H26B Los Angeles CA In P'cuss 0 1 F,of IN. MM 111 Main St PO Box 660219 $0.00 0 L.F.of IN. MM 0 L.F.of IN. MM Los Angeles CA 91006 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: Kathy Bradley 0 L.F,of IN. MM MH's: 0 626-355-1350 0 L.F.of IN. MM CA 200130, MNR Construction Inc 1376 L.F,of 8 IN, MM $86,556.00 Secondary Sewer Renewal SSRP Los Angeles,CA In rroccso 15 L.F.of 662 IN. MM Grand Ave&58th Street 1051 Calle Ortega $0.00 0 L.F.of IN. MM 0 L,F,of IN. MM San Dimas CA 91773 0 L.F,of IN. MM 0 L.F.of IN. MM SC's! Elizabeth Torrez 0 L.F.of IN. MM MH's: 0 909-592-2760 0 L.F.of IN. MM 200132 Lash Construction,Inc 2580 L.F.of 15 IN, MM $555,120.00 Fariview Ave Sewer Replacement Goleta,CA In pnocpp's 7 L.F.of 18 IN. MM and Relocation 721 Carpinteria St. $0.00 2470 L.F.of 30 IN. MM 0 L.F.of IN. MM Santa Barbara CA 93140 C L.F.of IN. MM 0 L.F.of IN. MM SC's: Edward Deras 0 L.F.of IN. MM MH's: 0 805-963-3553 0 L.F.of IN, MM CA 201113 Mathew and Stewart Company,Inc, 3241 L.F.of 8 IN. MM $131,027.00 SSRP Marmion Way&Figueroa St. Los Angeles,CA In Pro rw<as 407 L.F.of 12 IN. MM 2841 Gardena Ave $0.00 0 L.F,of IN. MM 0 L.F.of IN, MM Signal Hill CA 90755 0 L.F of IN. Mr1A 0 L.F.of IN. MM SC's: Steve Radalch 0 L.F.of IN. MM MH's: 0 562-595-5471 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Fini Amount Proiect Description Project Location Comp. CA 200123 City of Beverly Hills 800 L.F.of 6 IN MM $1,265,390.00 SEWER PIPELINE AND MANHOLE BEVERLY HILLS,CA IN PROCESS 33000 L.F.of 8 IN MM REHAB 455 N.Rexford Drive $0.00 3100 L.F.of 10 IN. MM 0 L.F.of IN MM Beverly Hills CA 90210 0 L.F.of IN. MM 0 L.F.of IN. MM sc's. 0 L.F.of IN. MM MH's: 0 0 L.F.of IN, MM CA 24 Charles King Company 330 L.F.of 18 IN IVIM $263,349,00 California Bowl Sewer Lining Rehab Long Beach,CA 2925 L.F.of 21 IN, MM 2841 Gardena Ave $0.00 0 L F,of IN. MM 0 L,F,of IN, MM Signal Hill CA 90755 0 L.F.of IN. MM 0 L,F of IN. MM SC's: Steve Radaich 0 L.F.of IN. MM MH's: 0 909-336-7100 0 L.F.of IN. MM CA 200125 University of California SO 1.75 L.F.of 18 IN. MM $40,950.00 East of Keck Sewer Lining San Diego,CA 0 8!'-A 0 10 0 L.F.of IN. MM 10280 North Torrey Pines Road $40,950-00 0 L,F,of IN, MM 0 L,F.of IN. MM La Jolla CA 92093-0916 0 L.F,of IN VIM SC's 0 L.F.of IN. MM Thomas Wilson 0 L,F,of IN. MM MH's: 0 658-534-1991 0 L.F.of IN MM CA 200126 Irvine Ranch Water District 106 L.F.of 6 IN. MM $2,585,897.75 Lake Forest Woods Sewer Rehab Irvine,CA in Process 15600 Sand Canyon Ave. 29586 L.F.of 8 IN. MM $0.00 5701 L.F.of 10 IN. MM 1939 L.F.of 12 IN, MM Irvine, CA 92619 2113 L.F.of 15 IN, MM 0 L.F of IN MM SC's: Paul D.Jones 0 L.F of IN, MM MH's: 0 949-453-5300 0 L.F.of IN. MM CA 20,0127 Utah Pacific Construction Company 2091 L.F.of 27 IN, MM $239,542.50 Contract No SE0601-A-R Holt Blvd Ontario,CA 402 L.F.of 30 IN. MM Trunk Sewer Repair 40940 Eleanora Way $248,600.00 0 L.F.of IN. MM 0 L.F.of IN. MM Murrieta CA 92562 5946 0 L.F.of IN MM 0 L F,of IN MM SC's: 0 Jason Rr'mt 0 L.F.of IN MM MH's: 0 954-677-9876 0 L.F.of IN MM State JobNumber Owner/Contractor Job Classification CnVFini Amount Project Description Project Location g2m CA 200118 County of Los Angeles Dept Public Works 274 L.F.of 18 IN. MM $436,260.00 Corrugated Metal Pipe Lining Los Angeles In Prx(�"Ss 550 L.F.of 24 IN. MM 900 South Freemont Ave $0,00 60 L.F.of 30 IN. MM 98 L.F.of 36 IN. MM Alhambra CA 91803-1331 2664 L.F.of 42 IN. MM 0 L.F.of IN. MM SC's: Irma Serna 0 L.F.of IN, MM MH's: 0 (326-4 58-4 9-,1 0 L.F.of IN. MM CA 2C.01 19 Long Pv;�a(-.W\Nater Departn'�ent 2510 LT of 8 IN. MM $317,039.00 Sewer Pipe Rehab Long Beach,CA In rlrar-'e'ss 0 L.F.of IN. MM 1800 F.Wardlow Road $0.00 0 L.F.of IN. MM 0 L F of IN. MM Long Beach CA 90807-4931 0 L-F of IN. MM 0 L.F.of IN. MM SG's: Robert J,Verceles P.E 0 L-F of IN. MM MH's: 0 562-570-2337 0 L.F.of IN. MM CA 100120' Charles King Company 145 L.F,of 10 IN, MM $282,475,50 Strathearn Place Sewer Rehab Simi Valley,CA In ProcpsF� 960 L.F.of 27 IN. MM 2841 Gardena Ave $0.00 150 L.F.of 30 IN. MM 192 L,F of 33 IN. MM Signal Hill CA 90755 0 L.F.of IN. MM 0 L.F,of IN. MM sc's: Steve Radaich 0 L.F.of IN. MM MH's: 0 562-426-2974 0 L.F.of IN. MM CA 2C0 121 Matthew And Stewart Co.Iqc, 4102 L.F.of 8 IN. MM $195,402,80 City of Los Angeles SSRP H04B 3rd Los Angeles,CA In Flroce s 330 L.F.of 10 IN, MM St.&La Cienega 2841 Gardena Ave. $0.00 692 L.F.of 12 IN. MM 450 L.F.of 15 IN. MM Signal Hill, CA 90755 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: Steve Radaich 0 L.F.of IN. MM MH's: 0 562-426-2974 0 L.F.of IN, MM "A 200122 Lake Arrowhead Community Services 500 LT of 8 IN MM $1,766,131.00 Rocky PT&SmIthport slip lining& Lake Arrowhead,CA N1 F�Oces"" 2900 L.F.of 10 IN, MM manhole rehab 28200 State Highway 189 $0.00 6300 L.F.of 12 IN. MM 1200 L.F.of 18 IN. MM Lake Arrowhead CA 92352 600 L.F.of 21 IN. MM 1900 L.F.of 24 IN. MM SC's: Aida Hercules-Dodaro 0 L.F.of IN, MM MH's: 0 909-336-7100 0 L.F.of IN. MM State JohiNumber Owner/Contractor Job Classification Cnt/Fini Amount Project Description Project Location Cann CA 200113 City of Arradia 2450 L.F.of 3 IN. MM $56,900.00 Sewer Refining Project#33856610 Arcadia,CA 06104,110 0 L.F.of IN. MM 11300 Goldring Road 0 L.F.of IN, MM $56,900.00 0 L.F.of IN MM Arcadia CA 9 1 GAO 0 L.F.of IN. MM 0 L.F.of 4 MM SC'S' 54 Jacquelyn Betancourt 0 L.F.of IN. MM MH's: 0 626-256-6594 0 L.F.of IN, MM CA 7,00114 R.J,Noble Company 346 L.F.of 24 IN MM $q7,145 Or) Stofni Suwof CA ram. 12-OP5105 LF Habra,CA In DrOCeSr, 83 L.F.of 30 IN MM 15505 E.Lincoln Ave, $0,00 0 L.F,at IN MM 0 L.F.of IN. MM coang(", CA 92865 0 L.F.of IN MM 0 L.F.of IN. MM sc's: ]`Evan Overman 0 L.F.of IN, MM MH's: 0 314-637-155C 0 L.F.of K MM CA 20011 Mladem Buntich 23510 L.F,of 6 IN. MM $1,749,849.00 Wastewater and Water Return Malibu CA In Process 0 L.F-of IN. MM 1500 W,W1 St, $0,00 0 L.F.of IN. MM o L.F,of IN, MM Upland CA 9178b 0 L.F.of IN. MM 0 L.F of IN, MM SC'Sn Lee Roesner 0 L.F.of K MM MH's: 0 818-370-8038 0 L.F of IN MM CA 200116 Drill Tech Drilling&Shoring Inc 175 L.F.of 18 K MM $11,750.00 Storm Drain Lining San Deign,CA 08/02,'10 0 L.F.of IN. MM 22223 Forest Boundary Road $11,750.00 o L.F.of IN. MM 0 L.F.of IN. MM Corona CA 92883 0 L.F,of IN. MM 0 L.F.of IN. MM SC's, Corey J'arnagor, 0 L.F.of IN MM MH's: 0 951 4-77-9700 0 L,F.of IN, MM (;1 200117 City of Srni VnHey 1403 L.F.of 18 IN, MM $323,466.50 Loas Angeles Ave Metrolink Sewer 3ini Vailcy,CA in[)Ocp,s 482 L.F.of 24 IN, MM Line Rehab 500 VY Un Angeles Avr: $0.00 0 L.F.of IN. MM 0 L.F.of IN. MM Simi Valley CA 93065-1644 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: Marlon Villarama 0 L.F.of IN. MM MH's: 0 805-583-6408 0 L,F.of IN. MM State JohiNumber Owner/Contractor Job Classification Cnt/Fini Amount Proiect Description Project Location gqmp. CA 200105 City of Son Marino 2620 L.F.of 8 IN. MM U7,648 00 Sanitary Sewer Rehabilitation various San Marino,CA 06/0 111 0 L F.of IN. MM locations 2200 Huntington Drive $113,300.25 0 L.F.of IN. MM G L.F.of IN. MM San Marino CA 91108-2691 0 L.F.of IN. MM 0 L.F.of IN. MM SC's; 42 Maral Lazarian 0 L.F.of IN, MM MH's: 0 636-300-0700 0 L.F.of IN. MIA CA 200106 City of Duarte 555 L.F.of 42 IN- MM $116,490.00 Crestleld Storm Drain Rehab Duarte,CA '08"10/10 0 L.F of IN. MM 1600 Huntington Drive $120,005.00 0 L.F.of IN. MM 0 L.F.of IN, MM Duarte CA 91010-2592 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: Darrell J George 0 L.F of IN. MrV1 MH's: 0 626-357-7931 0 L.F.of IN MM CFr 2001 Oq City of Villa Park 9505 L.F.of 8 IN, MM $211,21390 2009-10 Sewer Rehab Pjt Villa Park CA 0511 S/I U 613 L.F of 12 IN MM 17855 Santiago Blvd 0 L.F,of IN. MM $238.079,60 0 L.F,of IN. MM Villa Park CA 92861-4187 0 L.F.of IN MM 0 L.F.of IN, MM SC's: 172 Jarad Hildenbrand 0 L.F.of IN. MM MH's: 0 714-998-1500 0 L.F,of IN, MM CA 200109 City of Barstow 295 L.F,of 6 IN MM $437,225.00 City of Barstow Barstow,CA In pfocess 10990 L.F.of 8 IN, MM 220 East Mountain View Street Suite A $0.00 207 L.F.of 10 IN, MIA 193 L.F.of 12 IN, MM Barstow CA 92311-2839 0 L.F.of IN. MM 0 L.F.of IN. MM SUS, Domingo D.Gonzales 0 L.F.of IN. MM MH's: 0 760-255-5156 0 L.F.of IN. MM CA 2001 l,,' South Coast Water District 2236 L.F.of 6 IN, MM $129,221,00 Sewer Lining Repairs Laguna Beach,CA 910 1 120 1 0 287 L.F.of 8 IN. MM 31592 West Street $127,271.00 545 L.F.of 10 IN. MM 309 L.F.of 12 IN. MM Laguna Beach CA 92651 0 L.F.of IN MM 0 L.F.of IN. MM SC's: 1D2 Joseph N.McDivitt 0 L.F.of IN, MM MH's: 949-499-4555 0 L.F.of IN. MM State JohlNumber Owner/Contractor Job Classification Cnt/Fini Amount Project Description Project Location Comp. CA 200099 Charles King Company 4245 L.F.of 39 IN, MM $812,252.50 Spring Valley Outfalt Sewer Manholes San Diego,CA 04/06/10 0 L.F.of IN MM 2841 Gardena Ave $812,25250 0 L.F,of IN MM 0 L.F.of U MM Signal Hill, CA 90755 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 1 Steve Radaich 0 L.F.of IN, MM MH's: 0 562-426-2974 0 L.F.of IN, MM CA 200100 South Coast Water District 760 L.F.of 8 IN MM $113,686-00 Beach Road Lining Repairs Laauna Bo',ch 0610100 2482 L F.of 12 IN, MM 31592 West Street $113 686-00 0 L.F.of IN MM , 0 L.F.of IN MM Laguna Beach CA 92651 0 L.F.of IN MM 0 L.F.of IN. MM SC's-. 63 Joseph N.McDivitt 0 L.F.of IN, MM MH's: 949-499-4555 0 L.F.of IN, MM CA 200101 City of Poway 160 L.F.of 24 IN. MM $41,12000 Corrugated Metal Pipe Repair Poway,CA 03/11/10 0 L.F,of IN. MM 13325 Civic Center Drive $41,120-00 0 L.F,of IN MM 0 L.F.of IN, MM Poway CA 92074 0 L.F.of IN, MM 0 L,F.of IN, MM SC's: 2 Pat Phelps 0 L.F.of IN, MM MH's 0 858-668-4400 0 L.F.of IN. MM CA 200103 California DOT 550 L.F.of 18 IN, MM $134,820.00 Cent#12-OK5004 State Hwy Dept Irvine,CA 4 procr�s'�" 400 L.F.of 24 IN MM Route 5 1727 30th Street JS 43 $0.00 0 L.F.of IN. MM 0 L.F.of IN MM Sacramento CA 95816 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: Jesse Flores 0 L.F of IN MM MH's: 0 858-668-4400 0 L.F.of IN, MM C'A 200104 City of Poway 380 L.F,of 42 IN. MM $95,760,00 Strom Drain Rehab Poway,CA 0510115110 0 L.F.of IN, MM PO Box 769 $95,760.00 0 L.F.of IN. MM 0 L.F.of IN. MM Poway CA 92074 0 L.F,of IN, MM 0 U.of IN, MM SUS: 0 Pat Ryan 0 L.F.of IN. MM MH's: 0 858-668-4717 0 L.F.of IN MM State JobNumber Owner/Contractor Job Classification Cnt/Fini Amount Project Description Project Location Comp. CA 200094 County Sanitation District#21 668 L.F.of 20 IN MM $62,370.00 Tri-Cities Outfall Trunk Sewer Pomona,CA 11/16/10 0 LT.of IN. MM Protection Between Manholes 609& 1955 Workman Mill Road $62,370.00 608 0 L.F.of IN. MM 0 L.F.of IN. MM Whittier, CA 90601-1400 0 L.F.of IN. MM 0 L,F.of IN, MM SC's: 3 Kimberly S.Compton 0 L.F.of IN. MM MH's: 0 0 L.F of IN MM CA 200095 DFB C()%,STRUCTION.INC 300 L F.of 39 IN, MM $74,700.00 HOAG SOUND WALL NEV'VP0R`l 8-ACH,CA 08,14t09 2230 e Winston Road 0 L F of IN MM $75,260.00 0 L,F of IN, MM 0 LT of IN, MM Anaheim CA 92806-5536 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: 1 Andrea Veliqueete 0 L.F.of IN, MM MH's. 0 714-632-6680 0 L.F of IN, MM CA 20209r3 Sundt Construction,Inc 308 L.F.of 24 IN MM $58,289.00 Scripps Mercy Hospital Parking San Diego,CA 12/11,i!09 0 L.F.of IN, MM Garage 1660 Hotel Circle Dr North Suite 400 $58,234.00 0 L.F.of IN. MM 0 L.F.of IN MM San Diego CA 92108 0 L,F.of IN. MM 0 L.F.of IN MM SC's: 2 Chris Geilenfiledt 0 L.F.of IN, MM MH's: 0 0 L.F.of IN, MM CA 200097 Charles Kmg Company,Inc 1004 L.F of 14 IN. MM $165,487.50 Broadway Trunk Sewer Replacement Long Beach,CA 03/28/10 2293 L.F.of 18 IN, MM 2841 Gardena Ave $203,429-50 0 L.F.of IN. MM 0 L.F.of IN. MIA Signal Hill CA 90755 0 L.F.of IN. MIA 0 L.F.of IN, MM SC's: 9 Steve Radaich 0 L.F.of IN. MM MH's: 0 0 L.F.of IN, MM CA 20098 1 lolondale(-"ommAm�ty 13orviccs District 795 L F of 30 IN. MM $147,055.00 Sewer Rehab Project Helendale.CA 0L71 211 C 0 LT of IN. MM 207'l0 Astir Road Ste 3 $147,455,00 0 L F.of IN. MM 0 L,F.of IN, MM Helendale CA 92342 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 5 Kimberlv Cox 0 L.F of IN. MM MH's: 0 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Project Description Project Location Camp. CA 200089 Vandenberg Village Community Services 644 L.F.of 6 IN MM $127,238.50 Sewer Line Rehab Vandenberg Village 011<U09 2331 L.F.of 8 IN MM Lompoc,CA 3757 Constellation Road $181,067 50 0 L.F.of IN: MM 0 L.F.of IN. MM Vandenberg Village,Lam CA 93436 0 L.F.of IN MM 0 L,F.of IN MM SC's: 25 Joe Barget 0 L.F of IN. MM MH's: 0 808-733-2475 0 L.F.of IN. MM CA 20,3090 Lake Arrowhead Community Services District 1465 L F.of 8 IN. MM $978,329,00 2009 Sewer Slip Lining and Manhole Lskf:0kriowhnnd,CA OJ1�'J1109 352 L F,of t3 IN. MM Rehab 28200 State Highway 169 Bldg 03 Suite 160 $870,854.75 4823 LF.of 12 IN, MM 0 L.F.of IN MM Lake Arrowhead CA 92352 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 54 Aida Hercules 0 L.F.of IN. MM MH's; 0 909-336-7100 0 LT,of IN. MM CA 200091 Charles King Co.,Inc. 1693 L.F.of 96 IN. MM $2,644,900.00 San Diego County Regional Airport San Diego CA 1012 3>09 0 L.F.of IN- MM Sewer Pipe Liner 2841 Gardena Avc $2,856,594.82 0 L.F.of IN. MM 0 L.F of IN MM Signal Hill CA 90755 0 L.F.of IN. MM 0 L.F of IN. MM SC's: 0 Butch King 0 L.F.of IN. MM MH's: 0 562-426-2974 0 L.F,of IN. MM CA 200092 County Sanitation District#1 232 L.F.of 18 IN. MM $68,640 00 Holmes Willowbrook Sewer Rehab Los Angeles CA 01113i1 CJ 0 L.F.of IN. MM 1955 Workman Mill Road $68,640,00 0 L.F.of IN. MM 0 L.F.of IN MM Whittier CA 90601-1400 0 L.F_of IN MM 0 L.F of IN. MM SC's: 3 Kimberly S Compton 0 L.F.of IN. MM MH's: 0 562-699-7411 0 L.F.of IN MM CA 000 9113 Bu tech Pipeline 293 L.F.of 3 IN. MM $19,890.00 P.O.#2009-006-3.1,Oleander Dr. San Diego,CA 0 L.F.of IN. MM Accelerated Sewer 102 Second Street $19,175.00 0 L.F.of IN. MM 0 L.F.of IN. MM Encinitas CA 92024 0 L F.of IN. MM 0 L.F.of IN, MM SC's: 1 Buddy Burtech 0 L.F.of IN. MM MH's: 0 760-634-2822 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Project Description Proiect Location Comp. CA 200084 City of West Hollywood 5613 L.F,of 8 IN, MM $418,298.25 Sewer Repair and Rehab West Hollywood,CA 04130109 844 L.F,of 12 IN MM 8300 Santa Monica Blvd $437,442.17 806 LR of 15 IN. MM 0 L.F.of K MM West Hollywood CA 90069-6216 0 L.F.of IN. MM 0 L,F,of IN, MM SC's: 189 323-848-6383 0 L.F,of K MM MH's: 0 0 L.F.of IN. MM 200i765 Burtech Pipelines Inc 4445 L.F of 8 IN MIA $195,885 00 Biftech Pipeline,Inc Chula Vista,CA 102 Second St 250 L,F.of 10 IN, MM $155,257.60 0 L.F.of IN. MM 0 L F of IN. MM Encinitas CA 92024 0 L F.of IN. MM 0 LF-of IN. MM SC's: 146 Buddy Aquino D L.F.of IN. MIA MH's: 0 760-634-2822 0 L.F.of IN. MM CA 200086 CITY OF FULLERTON 18870 L F.of 8 IN, MM $933,376.00 STORM SEWER DRAIN LINING FULLERTON,CA 06/1191109 303 WEST COMMONWEALTH AVE 5491 L.F.of 10 IN, MM $909,526.50 188 L.F.of 15 IN. MM 155 L,F.of 18 IN.. MM FULLERTON CA 92832-1772 476 L.F.of 24 1 N MM 250 L.F.of 30 IN, MM SC's: 413 531 L.F.of 42 IN. MM MH's: 0 714-738-6322 154 L F;of 48 IN. MM CA 200(18;• Vadnais Corporation 150 L.F.of 10 IN, MM $122,286.00 University of California San Diego San Diego 9164 Recho Road 147 L.F.of 12 IN, MM $108,751.37 30 L.F.of 15 IN, MM 405 L.F.of 18 IN., MM San Diego CA 92121 0 L.F.of IN MM 0 L.F.of IN, MM SC's: 0 Jeff Anderson 0 L.F.of K MM MH's: 0 858 550-1460 0 L.F.of IN, MM CA 20E=088 Southwest Civil Contracting 1610 L F.of 8 IN, MM $66,200.00 Caltrans Meadowbrook,Sewer Rehab Santee CA 0 L.F.of IN MM 228 Navajo Street 0 L F.of IN MM $05,200.00 0 L.F.of IN, MM San Marcos, CA 92078 0 L.F.of IN MM 0 L.F.of IN. MM SC's: 2 Debi Hawkins 0 L.F.of IN, mm MH's: 0 760-736-9990 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification CnVFinl Amount Project Description Project Location Comp. CA 200079 County Sanitation Dist 1&2 311 L F.of 12 IN MM $2,078,733.00 Mountain View Belle Vernon Trunk Los Angeles,CA 03/25/10 3284 L.F.of 15 K MM Sewer Rehab 1955 Workman Mill Road $2,057,682,79 2118 L.F.of 18 IN, MM 827 L.F,of 21 IN, MM Whittier CA 90601 6440 L.F.of 24 IN, MM 0 L.F of IN. MM SC's: 135 0 L.F.of IN. MM MH's: 0 0 L.F.of K MM CA 200,060, South Coast Water District 2517 L.F,of 12 IN. MM $121,943.00 Beach Road Sewer Lining Repairs Dana Point,CA /2CVG 2 0 L.F of IN, MM PO Box 30205 $121,943.00 0 L.F.of IN. MM 0 L F,of IN MM Laguna Niguel CA 92651 0 L.F.of IN MM 0 L.F.of IN MM SC's: 72 Joseph McDivitt 0 L.F.of IN, MM MH's: 0 949 499-4555 0 L.F.of IN MM CA 200081 California State Parks 850 L.F.of 3 IN MM $69,452.00 California State Parks 8"Sewer Silver Lake CA 12,4cM,'Ckl 0 L.F.of IN MM Rehab Silverwood Lake 17801 Lake Perris Dr $72,325.00 0 L.F,of IN. MM 0 L.F.of IN, MM Perris CA 92571-9293 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: 1 0 L.F.of IN. MM MH's: 0 0 L.F.of IN, MM CA 200082 FCl/Flour/Parsons 530 L.F.of 45 IN MM $539,040,00 Mid City Exposition Light Rail Transit Los Angeles,CA 71�09 L.F.of IN. MM Project 707 Wilshire Blvd Suite 3400 0 L.F.of IN. MM 0 L.F.of IN. MM Los Angeles CA 90017 0 L-F,of IN. MM 0 L.F.of IN. MM SC's: 4 0 L.F.of IN. MM MH's; 0 0 L.F.of IN. MM ,',A 200033 Running Springs Water District 125 L.F.of 8 IN, MM $23,650.00 sanitary sewer rehab Running Spring 0 1 s09!09 0 L.F.of IN MM 31242 Hilltop Blvd PC Box 2206 $23,850.00 0 L.F.of K MM 0 L.F.of IN. MM Running Springs CA 92382 0 L.F.of IN. MM 0 L.F.of IN MM SC's: 2 0 L.F.Of IN. MM MH's: 0 0 L F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Fini Amount Project Description Project Location Camp.. ca 200074 COUNTY SANITATION DISTRICT NO 2 38 L.F.of 12 IN. MM $161,154.00 COUNTY SANITATION DISTRICT CARSON CA 107?33 552 L.F.of 18 IN. MM NO,2 1955 WORKMAN MILL ROAD $172,039.00 395 L.F,of 24 IN MM 0 L.F.of IN. MM WHITTIER CA 90607 0 L.F,of IN. MM 0 L F.of IN. MM SC's: 140 CHERYL SHEA 0 L F.of 1N. MM MH's: 0 562-699-7411 0 L.F.of IN. MM ca 200075 SOUTHERN CALIFORNIA PIPELINE 812 L.F of 6 IN rV1M $209,408.00 CITY OF PLACENTIA PLACENTIA,CA 1 V04108 2164 L.F,of 8 IN. MM 1100 IRVINE BLVD $203,478.00 934 L.F.of 10 IN, MM 308 L.F.of 12 IN, MM TUSTIN CA 92780 0 L,F.of IN. MM 0 L.F.of IN. MM SC's: 0 L.F.of IN. MM MH's: 0 L.F.of IN. MM CA 200076 CITY OF FULLERTON 0 L.F.of 6 IN. MM $1,15B,732.50 SEWER LINING PROJECT 2007- Fullerton,CA 031`0iol¢ 19906 L.F.of 8 IN, MM 08 CITY OF FULLERTON 303 WEST COMMONWEALTH AVE $1,110,685.50 455 L.F.of 10 IN. MM 1021 L.F.of 12 IN, MM FULLERTON CA 92832-1775 3655 L.F.of 15 IN. MM 25 L.F of 18 IN, MM SC's: 406 987 L.F.of 30 IN. MM MH's: 0 0 L.F of IN. MM CA 200077 URS Corporation 170 L.F.of 18 IN. MM $155,000.00 Goodrich Aerostructures Chula Vista,CA 10129i08 540 L.F.of 30 IN. MM 1615 Murray Canyon Road $145,954.00 L.F.of IN. MM 0 L.F.of IN. MM San Diego CA 92108 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 Robert K Scott 0 L.F.of IN. MM MH's: 0 619-294-9400 0 L.F.of IN. MM CA 200078 TC Construction Company 285 L.F.of 60 IN MM $178,125.00 Cured in Place Storm Drain San Diego,CA 11101''03 0 L.F.of IN. MM 10540 Prospect AVE $178 125,00 0 L.F.of IN. MM 0 L F.of IN. MM Santee CA 92071 0 L.F-of IN. MM 0 L.F.of IN. MM SC's: 3 Kelly Nielsen 0 L.F.of IN. MM MH's: D 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification CnVFinl Amount Project Description Project Location Comp, CA 200068 COUNTY SANITATION DISTRICT NO.1 306 L.F.of 24 IN, MM $119,340,00 HUNTINGTON PARK RELIEF SOUTH GATE,CA 04122109 0 L.F.of IN. MM EXTENSION TRUNK SEWER 1955 WORKMAN MILL RD PO BOX 4998 $125,971 30 REHABILITATION.2008 0 L.F.of IN. MM 0 L F.of IN MM WHITTIER CA 90601 0 L.F.of IN MM 0 L.F,of IN mm SC's: 0 0 L.F.of IN, MM MH's: 0 562-699-7411 0 L.F.of IN, MM CA 2000fi9 COUNTY SANITATION DISTRICTS 329 L F.of 21 IN, Mm $104,29300 MAIN STREET TRUNK SEWER CARSON,CA 11s<.1L 8 0 LT.of IN. MM REHABILITATION-2008 1955 WORKMAN MILL ROAD $104,293.00 0 L.F.of 1W MM 0 L F.of IN mm WHITTIER CA 90601 0 L.F.of IN. MM 0 L.F.of IN, MM SC's: 0 0 L.F.of IN. MM MH's., 0 562-699-7411 0 L.F.of IN MM CA 1 THE COACHELLA VALLEY HOUSING COALITIO 0 L F.of IN, MM $54250.00 HUTERA DE MECCA-TRACT MECCA,CA 0710"Xil 402 L F.of 10 IN. MM 31027 P.O.ORDER NO.HUERTA 45-701 MONROE ST.,STE.G 0 L.F.of IN. MM $36,500.00 DE MECCA 451 0 L.F.of IN. MM INDIO CA 92201 0 L.F,of IN, MM 0 L F.of IN, MM SC's: 0 0 L.F.of IN. MM MH's: 0 0 L.F of IN. MM CA 200072 TRAUTWEtN CONSTRUCTION 1821 L F.of 21 IN. MM $410,558.00 WEST SIDE RELIEF TRUNK LANCATER,CA OljUZQ�, 407 L.F of 18 IN. MM SEWER-LACSD 19792 EL RIVINO ROAD $404,552.28 0 L,F.of IN. MM 0 L.F,of IN, MM RIVERSIDE CA 92509 0 L.F,of IN. MM 0 L.F.of IN, MM SC's: 0 0 L.F,of IN. MM MH's: 909-369-8901 0 L.F.of IN. MM CA 200073 IRVINE RANCH WATER DISTRICT 8628 L F.of 24 IN. MM $1,884,000.00 CULVER DRIVE AND HARVARD IRIVNE,CA 06;0 1109 72 L F.of 60 IN. MM AVE SEWER MAINTENANCE AND 155000 SAND CANYON AVE $2,236,960.62 REHAB PROJECT#20278 0 -T,of IN. MM 0 L.F of IN. MM IRVINE CA 92619 0 L F.of IN. MM 0 L.F.of IN. MM SC's: 1 0 L.F.of IN. MM MH's: 0 949-453-5854 0 L.F of IN. MM State JobNumber Owner/Contractor Job Classification CntlFinl Amount Project Description Project Location Comp. CA 200 362 0SLB,tNCORPORATED 6324 L.F.of B IN, MM $317,584.00 SSRP H30A HOLLYWOOD LOS ANGELES,CA C9/18110 0 L.F.of 10 IN mm FREEWAY AND VINE ST W.O. 1443',CAN rAANA AVE PO BOX 3 10004 L.F.of IN. MM $362,943.72 SZC11620 L.F.of IN. mm FONTANA CA 92331 L.F.of IN MM L.F.of IN. Mrvl SC's: 217 L.F.of IN, MM MH's: (909)434-0226 L.F.of IN, mm "A 200064 C I'l Y()I:POViAY 4136 L.F.of 8 IN mm $146,076.00 ST ANDREWS DRIVE SEWER FO`AJAY,GA 0 1 06101 119 LT.of 18 IN. MM REHABILITATION 13325 CIVIC CFN TI-R,DRIVE $176,781.00 0 L.F.of IN. mm 0 L.F.of IN. mm POWAY CA 92074 0 L.F.of IN. mm 0 L.F.of IN. mm SC's: 86 0 L+ of IN. mm MH's: 0 858-668-4400 0 L.F.of IN, mm CA 20006b CITY OF LOS ANGELES 1100 L,F.of 15 IN. mm $1,135,866.00 NORTH BROADWAY SEWER LOS ANGELES,CA 3,"2/013 235 L.F.of 18 IN. MM REHABII-ITATI ON-W.O. PO BOX 512599 0 L.F of IN. MM $987,410.00 #SZC11521 0 L F.of IN, mm LOS ANGELES CA 90051 0 L.F.of IN. mm 0 L.F.of IN, mm sc's: 61 0 L F.of IN. mm MH's: 0 213 6219533 0 L.F,or IN mrvi CA 2DO066 LOS ANGFLES COUNTY 304 L.F.of 25 IN. MM $1,323,481.00 PROJECT ID NO FCCO001 030 LOS LOS CERRITOS,CA 0f)A)7109 1932 L.F.of 42 IN. MM CERRITOS DRAINAGE SYSTEM 1400 SOUTH FREMONTAVENUE 2546 L.F.of 48 IN. MM $1,26B4O91.00 ECKLESON LATERAL 0 L F.of IN, mm ALHAMBRA CA 91803 0 L.F.of IN, mm 0 L.F.of IN, MM sc's: 0 0 L.F.of IN mto MH's: 0 626 458-5100 0 L.F,of IN, mm CA 200z937 COUN FY SANITATION DISTRI(A S 348 L.F.of 10 IN, mm $51,208.00 MARINA TRUNK SEWER LONG BEACH,CA 02/20A39 0 L.F.of IN, mm REHABILITATION-2008 1<'55 VJ0RKfvlf\N M111.ROAD $51.208,00 0 L.F.of IN. MM o L.F.of IN. mm WHIT`IER CA 90601 0 L.F of IN, mm 0 L.F.of IN. MM SC's: 4 0 L.F.of IN. mm MH's: 0 562-699-7411 0 L.F.of IN MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Project Location Comp` CA 200058 CITY OF PASADENA 227 L.F.of 12 IN. MM $175,000.00 2008 RELINING OF CMP STORM PASADENA,CA 1212310" 89 L F.of 15 IN. MM DRAIN 100 NORTH GARFIELD AVE $194,821A0 971 L.F.of 18 IN, MM 0 L.F.of IN. MM PASADENA CA 91109 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 STEPHEN WALKER 0 L.F.of IN- MM MH's: 0 626-744-4191 0 L.F.of IN. MM CA 20005rw+ DLSB,INC 3879 LF,of 8 IN. MM $187,429,00 SSRP P03A GOLDEN STATE AND LOS ANGELES,CA OS1;2E31C 5� 542 L.F,of 15 IN. MM 10 FbVY W.O.SZC116071SSRP 14435 SANTA ANA AVE PO BOX 310004 $196,019.50 P03B SOTO ST AND 10 FWY 0 L.F.of IN MM W.O.SZC11608 0 L.F.of IN. MM FONTANA CA 92331 0 L.F.of IN MM 0 L.F,of M. MM SC's: 111 BRANIMIR KOVAC 0 L.F.of IN. MM MH's: 0 909-434-0226 0 L.F.of IN. MM CA 200060 CITY OF SAN CLEMENTE 1632 L.F.of 8 IN. MM $313,369,00 SEWER SYSTEM REHAB CITY SAN CLEMENTO,CA 071 9108 67 L.F.of 15 IN, MM PJ#24200,STORM DRAIN REHAB, 910 CALLS NEGOCIO,SUITE 100 $321,137.90 224-226 AVENIDA PALIZADA, 331 L.F.of 18 IN, MM PJ#18003&PJ#26001 0 L.F.of IN. MM SAN CLEMENTE CA 92673 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 46 KEN KNATZ 0 L.F.of IN. MM MH's: 0 949-361-6139 0 L.F.of IN. MM CA 200061 RAMONA,INC. 9172 L.F.of 8 IN. MM $484,609.50 SSRP C09B SUNSET BLVD.& LOS ANGELES,CA 3iD9/09 2069 L.F.of 10 IN. MM AMALFI DRIVE 111 MAIN STREET,P.O.BOX 660219 $483,907.00 227 L.F.of 15 IN. MM 0 L.F.of IN. MM ARCADIA CA 91006 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 267 KATHY BRADLEY 0 L.F.of IN. MM MH's: 0 626-355-1350 0 L.F.of IN. MM CA 200062 DLSB,INC 4464 L.F.of 8 IN MM $193,195,00 SSRP H30B SANTA MONICA LOS ANGELES.CA I V24i0'4 326 L.F.of 12 IN. MM BOULEVARD AND GOWER 14435 SANTA ANA AVE PO BOX 310004 0 L.F.of IN. MM $209,137.93 STREET W,O.SZC11621 0 L.F.of IN. MM LOS ANGELES CA 92331 0 L.F.of IN. MM 0 L.F.of IN MM SC's: 186 0 L.F.of IN. MM MH's: 0 (909)434-0226 0 L.F.of IN. MM State JobNum_ber Owner/Contractor Job Classification Cnt/Fini Amount Proiect Description Proiect Location Comp. CA 200053 SCHEIDEL CONTRAXTING$ENGINEERING IN 120 LT.of 24 IN. MM $35,640-00 MINOR STORM DRAIN SAN DIEGO.CA 04/17/08 0 L.F.of IN. MM IMPROVEMENTS FONTAINE ST PO BOX 1796 $35,640,00 STORM DRAIN REPAIR PH 2 0 L.F.of IN. MM T.O.#GRCMSD204 0 L.F.of IN. MM LA MESA CA 91944-1796 0 LF,of IN MM 0 L.F,of IN. MM SC's: 0 CAROLYN SCHEIDEL 0 L.F.of IN. MM MH's: 0 619-593-8704 0 L.F.of IN. MM CA 200054 SSG CONSTRUCTION,INC 980 L F of 54 IN. MM $922,660.00 LOS ALAMITOS PUMP STATION LOS ALAMITOS..CA IN 245 L F.of 12 IN MM FACILITY COI P31 AND PROGRESS 2073 RAILROAD STREET $0.00 RETARDING BASIN 0 L F.of IN. MM 0 L.F.of IN- MM CORONA CA 92880 0 LT,of IN, MM 0 L,F.of IN, MM SC's: VICKI VROBEL ' 0 L.F.of IN. MM MH's: 0 951.275-1177 0 L.F,of IN, MM CA 200055 CITY OF SANTA BARBARA 20340 L.F.of 6 IN. MM $1,692.434.00 SMALL DIAMETER SANTA BARBARA,CA 4122109 17387 L.F.of 8 IN. MM REHABILITATION PROJECT 630 GARDEN STREET $2,041,962.56 FISCAL YR 2008,BID#3521 240 LF.of 12 IN. MM 258 L F.of 4 IN. MM SANTA BARBARA CA 93102 0 L.F.of IN. MM 0 L.F.of IN MM SC's: 621 AMANDAFLESSE 0 L.F.of IN. MM MH's: 0 805-564-5424 0 L.F.of IN. MM CA 200056 WEKA,INC 310 L.F.of 10 IN. MM $42,470.00 PO JOB#055,HIGHWAY 215 SAN BERNARDINO, 10i25108 0 L.F,of IN MM BRIDGE CA 826 BROOKSIDE AVE,CTE G $42,470.00 0 L.F.of IN, MM 0 L.F of IN. MM REDLANDS CA 92373 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 L F.of IN MM MH's: 0 909-798-3221 0 L.F.of IN. MM CA 200057 VASILJ,INC DBA IVANKO 3991 L.F.of 8 IN. MM $181:661,00 SSRP C04,ROSE AVE& LOS ANGELES.CA 03125/10 163 L.F.of 10 IN. MM WASHINGTON BLVD. (W.O. 15531 ARROW HWY, $192,803.96 SZC11585) 236 L.F.of 12 IN, MM 0 L.F.of IN, MM IRWINDALE CA 91706 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 159 JOHN W.GAVIGAN 0 L.F.of IN. MM MH's: 0 626-480-1442 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Project Location Comp• CA 200048 IRVINE RACH WATER DISTRICT 371 L.F.of 8 IN MM $44,750.00 PELICAN HILLS GOLF COURSE NEWPORT BEACH,CA 02/13108 0 L.F.of IN. MM PO#112034 PO BOX 57000 $44,750.00 0 L.F.of IN. MM 0 L.F.of IN, MM IRVINE CA 92619-7000 0 LF.of IN. MM 0 L F.of IN. MM SC's: MARY HASSETT 0 L.F.of IN. MM MH's: 0 949-453-5712 0 L.F.of IN. MM CA 200049 CRESTLINE SANITATION DISTRICT 1262 L.F of 8 IN. MM $113,126.50 CIPP SEWER PROJECT PHASE 3 CRESTLINE,CA 04/21/08 0 L F.of IN, MM 157 W.5TH STREET,2ND FLOOR $109,012.50 0 L.F.of IN, MM 0 L.F.of IN. MM SAN BERNARDINO CA 92415 0 L.F.of IN. MM 0 L.F,of IN. MM SC's: 26 GARY MARTIN 0 L.F.of IN. MM MH's: 0 909-387-5964 0 L.F.of IN. MM CA 200050 SOUTH COAST WATER DISTRICT 252 L,F,of 6 IN. MM S126,235.00 2007/08 SEWER LINING PROJECT DANA POINT& 04/21/08 600 L.F.of 8 IN. MM CONTRACT#08-01-0026 LAGUNA BEACH,CA 31592 WEST STREET $122,175.00 0 L.F.of IN. MM 0 L.F.of IN MM LAGUNA BEACH CA 92651 0 LF.of IN. MM 0 L.F.of IN. MM SC's: 14 JOSEPH MCDIVITT 0 L.F,of IN MM MH's: 0 949-499-4555 0 L.F.of IN. MM CA 200051 CITY OF BEVERLY HILLS 763 L.F.of 12 IN. MM $69,164.00 SEWER REHABILITATION IN BEVERLY HILLS,CA 06/01108 0 L.F.of IN. MM BEVERLY DR FROM COLDWATER 455 N REXFORD DR 0 L.F.of IN MM $70,066.00 CAYON DR TO 1052 BEVERLY DR 0 L.F.of IN. MM BEVERLY HILLS CA 90210 0 L.F.of IN. MM 0 L.F,of IN. MM SC's: 6 0 LF,of IN. MM MH's: 0 714-278-1900 0 L.F.of IN. MM CA 200052 SOUTH COST WATER DISTRICT 350 L,F.of 8 IN. MM $12,960.00 LAGUNA SUR EASEMENT 8" LAGUNA BEACH;CA a'3/13,`J8 0 L,F.of IN. MM SEWER LINING REPAIRS ON ST, 31592 WEST STREET 0 L.F.of IN. MM $12,96o.00 TROPEZ,PO#9904 0 L.F.of IN. MM LAGUNA BEACH CA 92651 0 L.F.of IN, MM 0 L.F.of IN. MM SC's: 360 JOSEPH MCDIVITT 0 L.F.of IN. MM MH's: 0 949-499-4555 0 L.F,of IN. MM State JobNumber Owner/Contractor Job Classification CntlFinl Amount Project Description Proiect Location Comp, CA 200043 WILLIAMS PIPELINE CONTRACTORS,INC 5769 L F.of 8 IN: MM $232,044.50 CITY OF LOS ANGELES-SSRP LOS ANGELES,CA 08/27/08 760 L.F.of 10 IN. MM H27A-BARHAM BLVD AND 4864 MARKET STREET CUITE C $232,044.50 CAHUENGA TERRACE 0 L.F.of IN. MM WO#SZC11579 o L,F.of IN MM VENTURA CA 93003 0 L.F.of IN; MM 0 L.F.of IN. MM SC's: 165 JOHN WILLIAMS 0 L F.of IN, MM MH's: 0 805-644-1277 0 L.F.of IN. MM CA 200044 VASILJ INC dba IVANKO 2651 L,F,of 8 IN. MM $93,265 00 NE WILSHIRE AREA CEMENT LOS ANGELS.CA 05M5,'08 0 L F.of IN. MM SEWER RENEWAL PROGRAM 15531 ARROW HWY $94,765,00 (CSRP)UNIT 5 0 L.F-of IN. MM 0 L.F.of IN. MM IRWINDALE CA 91706 0 L.F.of IN MM 0 L,F-of IN. MM SC's: 57 JOHN GAVIGAN 0 L.F.of IN. MM MH's: 0 626-480-1442 0 L.F of IN. MM CA 200045 TOBO CONSTRUCTION,INC 250 L.F.of 42 IN. MM $73,750.00 JOC 0704-010 SAN GABRIEL AZUSA,CA 0112 108 0 L.F.of IN. MM CANYON SPREADING GROUND 500 SHATTO PLACE SUTIE 320 $73,750.00 0 L.F.of IN. MM 0 L F.of IN. MM LOS ANGELES CA 90020 0 L.F.of IN. MM 0 L F.of IN. MM SC's: 0 0 L_F.of IN. MM MH's: 0 0 L.F,of IN. MM CA 200046 NEW CENTURY CONSTRUCTION,INC 182 L.F,of 36 IN. MM $74,750.00 STORM DRAIN LA MESA,CA 02/29/08 0 L.F,of IN. MM REPLACEMENT/REHAB PROJECT 9119 EMERALD GROVE AVE $73.150.00 @ VARIOUS LOCATIONS BID#07-11 0 L.F.of IN. MM 0 L.F.of IN. MM LAKESIDE CA 92040 0 L.F.of IN- MM 0 L.F of IN MM SC's: 1 SUSAN LEGGITT 0 L.F,of IN. MM MH's: 0 619-390-3300 0 L.F.of IN. MM CA 200047 CITY OF BAKERSFIELD 3837 L.F.of 33 IN. MM $987,548.00 "0"STREET SEWER BAKERSFIELD.CA 09/02108 0 L.F.of IN. MM REHABILITATION BETWEEN BNSF 1501 TRUXTUN AVE $988.173.67 RAILROAD AND 26TH STREET 0 L F.of IN. MM 0 L.F.of IN. MM BAKERSFIELD CA 93301 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 2 MARIA PERALEZ 0 L.F.of IN, MM MH's; 0 661-326-3724 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Proiect Location Comp. CA 200039 MONTECITO SANTARY DISTRICT 171 L.F.of 8 IN. MM $11,450.00 BUENA VISTA PO#2310 MONTECITO,CA 11/09/07 0 L F.of IN MM 1042 MONTE CRISTO LANE $11,450.00 0 L F.of IN. MM 0 L,F.of IN MM SANTA BARBARA CA 93108 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: f 0 L F of IN. MM MH's: 0 805-969-4200 0 L F.of IN, MM CA 200040 SECURITY PAVING COMPANY,INC 1847 L,F.of 30 IN, MM $1,916,000,00 JOB#201-12 CITY PROJECT SANTA CLARITA CA L1311:9/08 0 L.E.of IN, MM #S1003 MAGIC MTN PKWY PHASE 9050 NORRIS $2,028,642,88 2 0 L F.of IN. MM 0 L.F.of IN, MM SUN VALLEY CA 91352 0 L.F of IN. MM 0 L.F.of IN. MM SC's: 2 JULIA SARKIS 0 L.F.of IN. MM MH's: 0 818-767-8418 0 L.F.of IN. MM CA 200041 STEVE BUBALO CONSTRUCTION 132 L.F.of 30 IN. MM $138,772 00 COLORADO OCEAN RELIEF SANTA MONICA,CA 0 /131019 369 L.F.of 33 IN, MM SEWER PROJECT 128 E.LIVE OAK AVE PO BOX 1048 $139,112.63 0 L.F.of IN. MM 0 L.F.of IN. MM MONROVIA CA 91017 0 L.F.of IN MM 0 L.F.of IN. MM SC's: 4 0 L.F.of IN. MM MH's: C. 626-574-7570 0 L F.of IN, MM CA 200041 STEVE BUBALO CONSTRUCTION 132 L.F.of 30 IN. MM $138,772.00 COLORADO OCEAN RELIEF SANTA MONICA,CA 02f04j09 369 L.F.of 33 IN, MM SEWER PROJECT PO BOX 1048 $140,072.05 0 L.F.of IN. MM 0 L.F.of IN. MM MONROVIA CA 91017 0 L.F.of IN. MM 0 L F.of IN. MM SC's: 4 0 L.F.of IN. MM MH's: 0 626-574.7570 0 L_F.of IN. MM CA 200042 CITY OF SANTA ANA 930 LF.of 6 IN. MM $66,600.00 17TH STREET SEWER LINING SANTA ANA,CA 01/04/08 0 L.F.of IN. MM PROJECT#07-3517 220 S.DAISY AVENUE $102,835.00 0 L.F.of IN, MM 0 L F.of IN. MM SANTA ANA CA 92702 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 14 BRIAN IGE 0 L.F.of IN. MM MH's: 0 714-647-3385 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Project Description Project Location Comp' CA 200034 LAKE ARROWHEAD COMMUNITY SERVICES DI 5149 L.F.of 12 IN. MM $942,845.00 LAKE EASEMENT SLIP LINKING LAKE ARROWHEAD, 07/29/08 L.F.of IN. MM PROJECT#317 CA 201 CUMBERLAND $758,136.64 0 L.F..of IN MM 0 L.F.of IN. MM LAKE ARROWHEAD CA 92352 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 44 RYAN GROSS 0 L.F.of IN. MM MH's: 0 909-337-8555 0 L,F.of IN. MM CA 200035 COUNTY SANITATION DISTRICT OF L..OS ANGE 206 LF.of 15 IN. MM $42,819.00 WILCOX AVE TRUNK EXTENTION CUDAHY,CA 12,113/08 0 L.F.of IN. MM NO.1 SEWER REHAB 2007 1055 WORKMAN BILL ROAD $42,8%00 0 L F.of IN. MM 0 L.F.of IN MM WHITTER CA 906101 1400 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 1 0 L.F.of IN. MM MH's: 0 0 L.F.of IN. MM CA 200036 WILLIAMS PIPELINE CONTRACTORS,INC 310 L.F of 8 IN. MM $57,770.00 SANITARY SEWER LONG BEACH,CA 12/27107 1698 L.F.of 10 IN. MM IMPROVEMENTS 10TH STREET/ 4864 MARKET STREET SUITE C $86,322.00 LINE AVE AND 15TH STREET/ 0 L.F.of IN. MM GARDENIAAVE 0 L F.of IN. MM VENTURA CA 93003 0 L.F.of IN. MM 0 L,F,of IN. MM SC's: 42 JOHN WILLIAMS 0 L,F.of IN. MM MH's: 0 B05-644-1277 0 L F of IN. MM CA 200037 FYDAQ COMPANY INC 1115 L.F.of 8 IN. MM $177,548.00 ARMSTRONG AVE TRUNK SEWER .I.US.I"IN,CA 1110607 2519 L.F,of 15 IN. MM REHAB 301 1/2 S RICHMAN AVE $183,246.00 0 L.F.of IN. MM 0 L:F.of IN. MM FULLERTON CA 92832 0 L.F.of IN. MM 0 L F.of IN. MM SC's: 0 L,F,of IN MM MH's: 0 714-447-9760 0 L.F.of IN: MM CA 200038 MONTECITO SANITARY DISTRICT 274 L.F.of 8 IN. MM $13,800.00 GLEN OAKS DRIVE PO#2308 MONTECITO,CA 11108/07 0 L.F.of IN. MM 1042 MONTE CRISTO LANE $13,800.00 0 L.F.of IN. MM 0 L,F.of IN. MM SANTA BARBARA CA 93108 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 0 L.F.of IN. MM MH's: 0 805-969-4200 0 L.F,of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Proiect Location Comp. CA 200029 CITY OF THOUSAND OAKS 771 L.F.of 8 W. mm $92,564.00 Cl 8028 WASTEWATER LINE CIPP THOUSAND OAKS,CA 10/12/07 0 L.F.of IN. MM LINING PROJECT 2100 THOUSAND OAKS BLVD $72,141.72 0 L.F.of IN, mm 0 L.F.of IN. mm THOUSAND OAKS CA 91362-2903 0 L.F.of IN. mm 0 L.F.of IN. MM SC's: 0 L.F.of IN. mm MH's: 0 605-449-2400 0 1-+-of IN, MM CA 200030 CITY OF SANTA BARBARA 473 L.F.of 12 IN, MM $90,050,00 CLIFF DRIVE&LAS OLAS AVE SANTA BARBARA,CA 10123/07 380 L.F.of 30 IN, mm PO#378189 630 GARDEN STREET PO BOX 1990 $97,721.69 0 L.F,of IN. mm 0 L-F.of IN. mm SANTA BARBARA CA 93102-1990 0 L.F.of IN, MM SC's: 2 0 L.F.of IN- mm 0 L.F.of IN mm MH's: 0 805-564-5377 0 L.F.of IN. mm CA 200031 LOS ANGELES COUNTY SANITATION DIST#18 475 L.F.of 15 IN, mm $73,625.00 FLORENCE AVE TRUNK SEWER SANTA FE SPRINGS, 10111107 0 L.F.of IN. mm REHAB 2007 CA 1955 WORKMAN MILL ROAD PO BOX 4998 $73,625.00 0 L.F.of IN. MM 0 L.F.of IN. mm WHITTIER CA 00601-4998 0 L.F.of IN. mm 0 L.F.of IN. mm SC's: 0 0 L.F.of IN MM MH's: 0 562 699-7,111 0 L.F.of IN. mm CA 200032 COUNTY SANITATION DISTRICTS#22 OF LOS 284 L.F.of 10 IN, mm $224,253.00 DISTRICT#22 TRUNK SEWER LOS ANGELES 12i15/07 1348 L.F.of 12 IN, MM REHABILITIATON-2007 COUNTY,CA 1955 WORKMAN MILL ROAD $224,253.00 113 L.F.of 18 IN, MM 0 L.F.of IN. MM WHITTNER CA 90601-1400 0 L.F.of IN. MM 0 L.F.of IN, MM SC's.' 7 0 L.F.of IN, mm MH's: 0 562-699-7411 0 L.F.of IN. mm CA 20,0033 LENNAR ORANGE COAST LAND SIVISION 66 L.F.or 8 IN. mm $19.72500 IRVINE RANCH WATER DITRICT- IRVINE,CA 09/lA107 0 L.F.of IN, mm MICHELSON DRIVE 8'*SEWER 25 ENTERPRISE SUITE 500 0 L.F.of IN. MM $19,725.00 REHABILITATION 0 L.F.of IN. mm ALISO VIEJO CA 92656 0 L.F.of IN. mm 0 L.F.of IN. mm SC's: 0 0 L.F.of IN. MM MH's: 0 949-349-8159 0 L.F.of IN. mm ------ ----I--,.---,------- State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Project Description Project Location Comp. CA 200024 CARPINTERIA SANITARY DISTRICT 7464 L.F.of 8 IN. MM $888,173.00 CASH CONTRACT NO 331, CARPINTERIA,CA 01122106 3528 L.F.of 10 IN, MM COLLECTION SYSTEM 5300 SIXTH STREET 1367 LF.of 15 IN_ MM $1,217.792.20 REHABILITATION PHASE 1 720 L.F.of 21 IN, MM CARPINTERIA CA 93013 0 L.F.of IN MM 0 L.F.of IN. MM SC's: 205 CRAIG M MURRAY 0 L F.of IN. MM MH's: o 805-684-7214 0 L.F.of IN. MM CA 200025 CITY OF CHULA VISTA 146 L.F.of 36 IN MM $55,000 00 EMERGENCY STORM DRAIN CHULA VISTA,CA 05r15107 0 L,F.of IN. MM REPAIR 1544AND 1542 1800MAXWELL ROAD $55,000.00 OLEANDER AVE#CDR176 0 L.F.of IN. MM 0 L.F of IN. MM CHULA VISTA CA 91911 0 L.F.of IN. MM 0 L.F,of IN. MM SC's: o 0 L.F.of IN. MM MH's: 0 0 L.F.of IN. MM CA 200026 SOUTH COAST WATER DISTRICT 662 L.F.of 6 IN. MM $56.942.00 PO#9469 FULL LENGTH SEWER LAGUNA BEACH,CA 06127?07 1387 L.F.of 8 IN. MM LINING REPAIRS PO BOX 30205 $92,161.00 D L F,of IN. MM 0 LF,of IN. MM LAGUNA NIGUEL CA 92607-0205 0 L,F.of IN. MM 0 L.F.of IN. MM SC's: 30 0 L.F.of IN. MM MH's: 0 0 L..F.of IN. MM CA 200027 CITY OF UPLAND 31267 LT,of 8 IN. MM $692,778.75 BID NO.2006-18,PROJECT#9302 UPLAND,CA 09I25107 2184 L.F.of 10 IN. MM 460 NORTH EUCLID AVE $719,681.57 0 L.F..of IN. MM 0 L.F.of IN. MM UPLAND CA 91786-4732 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 596 STEPHANIE MENDENHALL 0 L,F.of IN, MM MH's: 0 909-931-4100 0 L.F.of IN. MM CA 200026 CITY OF PASADENIA 109 L.F.of 54 IN. MM $259,000,00 2007 RELINING STORM DRAIN AT PASADENA,CA 10/19f07 202 L.F.of 72 IN. MM ROSEMEAD BLVD 117 E.COLORADO BLVD 6TH FLOOR $237,614,00 0 L.F.of IN. MM 0 L.F.of IN. MM PASADENA CA 91109 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 1 0 L.F.of IN. MM MH's: 0 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Proiect Location Comp: CA 200019 CDM CONSTRUCTORS INC 3518 L.F.of 8 IN. MM $378,490.00 CDM CONSTRUCTORS INC- CAMP PENDELTON, 1/31/2008 892 L F.of 10 IN, MM CONTRACT#N68711-04-DS110 CA 9220 CLEVELAND AVE SUITE 100 $317,045 95 D00012 535 L.F.of 12 IN. MM 424 L.F.of 15 IN. MM RANCHO CUCAMONGA CA 91730 L.F.of IN. MM L.F,of IN. MM SC's: 19 L.F.of IN. MM MH's: 0 909-579-3500 L.F.of IN. MM CA 200020 CDM CONSTRUCTORS INC 842 L.F.of 8 IN. MM $65,117,00 CDM CONSTRUCTORS INC- CAMP PENDELTON I'1,'0710r 417 L.F.of 12 IN, MM CONTRACT#N68711-04-DS110 CA 9220 CLEVELAND AVE SUITE 100 $70,02220 D00013 0 L.F,of IN. MM 0 L.F.of IN. MM RANCHO CUCAMONGA CA 91730 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 11 D L.F.of IN. MM MH's: 0 909-579-3500 0 L.F.of IN. MM CA 200021 WEST COAST UNDERGROUND 150 L.F,of 36 IN. MM $76,825.00 36"STORM DRAIN EL CAMINO CARLSBAD,CA 05111J07 0 L.F.of IN. MM REAL 7929 SILVERTON AVE SUITE 613 $76,825,00 0 L.F.of IN. MM 0 L F.of IN. MM SAN DIEGO CA 92126 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 EMILY BANNER 0 L.F,of IN. MM MH's: 0 858-689-7900 0 L.F.of IN. MM CA 200022 COUNTY OF LOS ANGELES DEPT OF PUBLIC 67 L.F,of 18 IN, MM $126,647.00 LA COUNTY FLOOD CONTORL SANTA CLARITA,CA 07/27/07 40 L.F.of 30 IN. MM DISTRICT FCCOD01009 CDR525- 900 SOUTH FREMONT AVE 183 L.F.of 36 IN. MM $157,733.00 UPRADE CMPIPE 237 L.F.of 42 IN. MM ALHAMBRA CA 91803-1331 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: JAMES SPARKS 0 L.F.of IN. MM MH's: 0 626-458-5100 0 L.F.of IN, MM CA 200023 CITY OF PASADENA 6106 LF.of 8 IN. MM $261,000.00 2007 SEWER RELINING IN THE PASADENA,CA 10/16i07 450 L.F.of 10 IN. MM CITY OF PASADENA 117 E.COLORADO BLVD,STE 430 $239,576.50 371 L.F.of 16 IN MM 0 LF of IN. MM PASADENA CA 91109 0 L.F.of IN, MM 0 L.F.of IN. MM SC's: 195 MIRIAM SCUDDER 0 L.F,of IN. MM MH's: 0 626-7444191 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Project Location Coma. CA 200013 CITY OF FULLERTON 861 L F.of 48 IN. MM $81,879,00 CITY OF FULLERTON:MISC FULLERTON,CA 11127106 0 L,F.of IN MM STORM DRAIN FY 2006-07 303 WEST COMMONWEALTH AVE $138,520.00 0 L.F.of IN. MM 0 L.F.of IN. MM FULLERTON CA 92832 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 7 0 L.F.of IN. MM MH's: 0 0 L.F.of IN MM CA 200014 CITY OF BREA 130 L.F.of 36 IN MM $53,940.00 CITY OF BREA,CP AT JR HIGH BREA,CA 11108!06 0 L,F,of IN. MM PARK-AUG 2006 P0900063617 1 CIVIC CENTER CIRCLE $53,940.00 0 LF.of IN. MM 0 L.F.of IN, MM BREA CA 92621-5732 0 L-F.of IN. MM 0 L.F.of IN MM SC's: 2 0 L.F.of IN. MM MH's: 0 714-990-7600 0 L.F.of IN. MM CA 200015 MURRAY COMPANY 230 L.F.of 18 IN. MM $42,700.00 20TH CENTURY FOX PARKING LOS ANGELES,CA 11102,'06 0 L F.of IN. MM STRUCTURE SITE 2919 E VICTORIA STREET $42.700.00 0 L,F.of IN. MM 0 L.F.of IN. MM RANCHO DOMINGUEZ CA 90221 0 L F.of IN. MM 0 L,F.of IN. MM SC's: 0 0 L.F.of IN. MM MH's: 0 310-637-1500 0 L.F.of IN. MM CA 200017 COUNTY SANITATION DISTRICT NO 5 OF LOS 862 L.F.of 18 IN. MM $190,502.00 GARDENA PUMP TRUNK SEWER GARDENA,CA 03/31/07 0 L.F.of IN. MM REHABILITATION-2006 1955 WORKMAN MILL ROAD $196,263.00 0 L.F.of IN. MM 0 L.F.of IN. MM WHITTIER CA 90607-4998 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 0 L.F.of IN- MM MH's: 0 562-669-7411 0 L.F.of IN. MM CA 200018 BIG BEAR AREA REGIONAL WASTEWATER AG 1154 L.F.of 18 IN. MM $161,902.00 S;TRUNK EMERGENCY 18" BIG BEAR,CA 212107 0 L.F.of IN. MM SEWER REHAB PO#802252 PO BOX 517 $163,252,00 0 L.F.of IN. MM 0 L.F.of IN. MM BIG BEAR CITY CA 92314 0 L,F.of IN. MM 0 L F.of IN. MM SC's: 36 0 L.F.of IN. MM MH's: 0 909-585-5578 0 L.F.of IN. MM City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax(714) 374-1573 ADDENDUM NUMBER ONE for the construction of SEWER REHABILITATION PROJECT CC No. 1396 July 18,2011 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: NEW BID SCHEDULE INCLUDE: 1. NEW Item No.6 "Prepare Construction Traffic Control Plans".... 1 LS 2. Revised Bid Item No.2 to Read"Furnish Traffic Control" SPECIFICATIONS REVISIONS TO INCLUDE: 1. Replace in Bid Documents Section 7-5 PERMITS on Pages E-11 and Section 7-10 PUBLIC CONVENIENCE on Pages E-15 with New Section 7-6 and 7-10 in Addendum No.1 2. A Caltrans Encroachment Permit Application pulled by Agency is attached to Addendum No. 1. Contractor must submit to Caltrans Water Pollution Control Provisions and Construction Traffic Control Plan for review and approval,along with the application for a rider to the Encroachment Permit. Bidders shall submit SECTION C with the most current revisions and bid schedule, Page C-2.3 "Addendum No. 1-Project Bid Schedule CC-1396 SEWER LINING". Award will be based on most current revised Bid Schedule and Specification revisions. This is to acknowledge receipt and review of Addendum Number 1,dated July 18,2011. Insituform Technologies, Inc. Company Name H. Dou omas, vice President July 26, 2011 Global Procurement/Operations support Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Joseph Fuentes at(714)636-5431. is ADDENDUM NO. I- PROJECT BID SCHEDULE CC-1396 SEVER LINING s �at>~ #era e i =Z�.... eser :.::•:•.....•:•. ............... ...P.,.•................ ......::::::....::::::::=:=::::::::................................... I>�t t• '>r>�c�•:•: :::: ulna t::: 1 1 Mobilization/Demobilization LS $ $ 2 1 Furnish Traffic Control LS $ $ 3 2545 Clean and inspect 8"sewer main LF $ $ 4 2545 Install liner and post inspect 8"sewer main LF $ $ 5 58 Grind and re-open sewer service lateral EA $ $ 6 1 Prepare Construction Traffic Control Plans LS $ $ Total Amount Bid in Figures: $ Total Amount Bid in Words: r i C-2.3 is 7-5 PERMIT'S [Delete the entire subsection and replace with the following:]. Prior to the start of any work, the Contractor shall take out the applicable AGENCY permits and make arrangements for AGENCY inspections. The AGENCY will issue the permits at no charge to the Contractor. The Contractor and all subcontractors shall each obtain an AGENCY business license, and shall be licensed in accordance with State Business and Professions Code. The Contractor, at no additional cost to the AGENCY, shall also obtain any and all other permits, licenses, inspections, certificates, or authorizations required by any governing body or entity. The contractor is responsible to manage the construction site in accordance with the city's National Pollutant Discharge Elimination System (NPDES) Permit and Municipal Code Chapter 14.25 - Stormwater and Urban Runoff Management ordinance. The purpose of the NPDES permit and ordinance is the improvement of water quality through the control of pollutants. Without exception, discharges of stormwater from a construction site into the storm drain system (gutter) or a receiving waterbody are prohibited if the discharge contains pollutants that have not been reduced to the maximum extent practicable through the implementation of BMPs. It is the contractor's responsibility to implement a combination of BMPs to control erosion and sediment transport, and pollutants from materials and waste management storage and activities. Full compensation for obtaining and conforming to the requirements of this section shall be included in other items of work and no additional compensation will be made therefore. No separate or additional compensation will be made for AGENCY permit and 'inspections, nor Rermits, licenses, inspections, certificates, or authorizations required by any other governing body or entity. The Contractor is hereby notified that specific construction practices in the Caltrans Standard Specifications, Section 7, "Responsibilities of the Contractor," are considered to be the Best Management Practices. Applicable construction practices in the Standard Specifications shall be incorporated into the WPCP. Additionally, the Contractor's work will be in compliance with the National Pollution Discharge Elimination System (NPDES) Permit for Storm Water Discharges for the State of California Department of Transportation (Caltrans) Properties, Facilities, and Activities, Order No.99-06-DWQ, CAS000003. Included within these specifications,for the Contractor's information, is a copy of the attachment to the Encroachment Permit (Water Pollution Control Provisions). An electronic copy of the Caltrans Storm Water Quality Handbook, Construction Contractor's Guide and Specifications Section 3, "Preparing a Water Pollution Control Program (WPCP)" can be found at http://Nv vxv.dot.ca_ og v/hq/construc/stolinwater/SWPPP Prep Manual 3 03.pdf Prior to the start of any work within Caltrans right-of-way, the AGENCY will obtain a Caltrans Encroachment Permit for work in the State right-of-way(see Addendum No. 1). Application fee and site inspection costs, due at the time of application are estimated at $820. The Contractor, within seven (7) days of award of the contract, must submit to Caltrans a WPCP and a Constniction Traffic Control Plan for review and approval, along with the application for a rider to the Encroachment Permit at the following Caltrans office: ADDENDUM NO. I CC-1396 SPECIFICATION REVISION PAGE 1 of 6 CALTRANS DISTRICT 12 Mory Mohtashami,District Permit Engineer 3347 Michelson Drive, Suite 100 Irvine, CA 926 1 2-1 692 At the time of the pre-construction meeting the Contractor must have the WPCP and a Construction Traffic Control Plan completed and approved by Caltrans. The Contractor shall be responsible for conducting all required monitoring inspections and shall file copies of the inspections and all other reports, certifications or records as required by the WPCP with the lead agency. All fines levied as a result of the Contractor's failure to comply with the requirements of the Permit Rider and the WPCP, shall be the Contractor's responsibility. Time extensions will not be allowed for any suspension of work as a result of the Contractor's noncompliance with the Permit Rider or WPCP. 7-10 PUBLIC CONVENIENCE AND SAFETY 7-10.1 Traffic and Access [Add the following,]. All traffic control shall be in accordance with the latest edition of the following documentation: Caltrans Manual on Uniform Traffic Control Devices (MUTCD); Sian Specifications, Standard Plans, and Standard Specifications; American Public Works Association Southern California Chapter—Work Area Traffic Control Handbook. Within 30 calendar days after notification of award, the Contractor shall submit, for review and approval by the Engineer, a Traffic Control Plan. The Traffic Control Plan shall be signed and stamped by a civil engineer familiar with the preparation of traffic control plans and licensed by the State of California. The plans shall incorporate, as a minimum, the following requirements of Section 7-10.3. Upon approval of the Traffic Control Plan by the City, approval of the Contractor's schedule by the City and execution of the Contract documents by both parties, the City will issue a Notice to Proceed specifying the Contract start date(.first day of work). The Contractor shall provide, to the Engineer, a telephone number at which the Contractor's representatives can be reached, at any hour, should an emergency occur requiring replacement or relocation of the required traffic control devices. Prior to the start of construction, the Contractor shall inform the AGENCY's Police and Fire departments of the project location, approximate starting date, completion date, and the name and telephone number of contractor representatives who may be contacted at any hour in the event of an emergency. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 2 of 6 POLICE DEPARTMENT: Watch Commander @ (714) 960-8809 )FIRE DEPARTMENT: Battalion Chief/Development @ (714) 536-5411 Information signs shall be required on all arterial streets one week prior to beginning of roadway construction projects. The Contractor shall adhere to applicable sections of California Administrative Code, Title S, concerning electrical and construction safety standards and practices. Contractor shall require that an approved safety vest be worn by all personnel who are working at this project site. Any worker without a vest may be ordered off the job by the Inspector until such apparel is acquired. Questions as to approved vests shall be directed to the Engineer. Any relocation of travel lanes longer than three calendar days shall be delineated by removing the existing striping and legends by wet sandblasting and placing new striping and legends as required. Upon completion of the work and the restoration of the road surface to its final condition,the Contractor shall remove temporary striping by wet sandblasting. If the traffic cones or portable delineators are damaged, displaced or are not in an upright position, for any reason, the contractor shall immediately replace or restore to their original location, in an upright position,the cones or portable delineators. The Contractor shall provide and maintain all signs, barricades, flashers, delineators and other necessary facilities for the protection of the motoring public within the limits of the construction area. He shall also post proper signs to notify the public regarding detours and conditions of the roadway, all in accordance with the provisions of the Vehicle Code, the current State of California Department of Transportation "Manual of Traffic Controls for Construction and Maintenance Work Zones", and the State of California Department of Transportation Standard Plans and the current City of Huntington Beach Maintenance Work Traffic Control Manual. The Contractor shall furnish such flagmen and equipment as are necessary to give adequate f warning to traffic or to the public of any dangerous conditions in accordance with the current Department of Transportation"Instructions to Flagmen". All existing traffic signs and street signs shall be maintained in visible locations during construction. Signs designated for removal shall be salvaged and delivered to the AGENCY s Yard or disposed of as directed by the AGENCY. Warning Signs 4 R Adequate warning signs for motorists shall be placed and maintained throughout all applicable phases of the work including speed limit reduction, loose gravel, fresh oil, and open trench. Signs shall be 36" X 36" in size; shall be on site ready for placement prior to start of the applicable phase of work and shall be placed in advance on all streets approaching the work zone. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 3 of 6 " 7-10.3 Street Closures,Detours,Barricades [Add the following:]. Construction Traffic Control Plans shall be prepared in accordance with the AGENCY's latest Traffic Control Plan Preparation Guidelines and shall be reviewed and approved by the Engineer. The Contractor shall submit the plans to the Engineer for approval or correction at least 10 working days before approved plans will be required for conunencing the work. IF MORE THAN ONE SEGMENT ADD: Separate traffic control plans shall be prepared for each segment and each stage of the work. The Construction Traffic Control Plans (CTCP) shall be prepared under the supervision of a registered professional. Civil Engineer licensed to practice in the State of California. Each sheet of the CTCP shall have the name, address, and telephone number of the engineer or engineering firm that prepared the CTCP, and the professional engineer's stamp and expiration date, and the professional engineer's signature and signature date. Approval of the plans by the Engineer shall not relieve the Contractor from the responsibility for errors or omissions in the plans or from deviations 'fi-om the Contract Documents. This traffic control plan shall provide pedestrian access throughout the construction area. The appropriate signing,barricades, etc.,shall be included on the plan. This pedestrian access shall comply with the accessibility:requirements contained within the American with Disabilities Act(ADA). The contractor shall install a barricade mounted 18" x 36" C42 sign "SIDEWALK CLOSED CROSS HERE" at the nearest crossings leading to the closure when the sidewalk width is reduced to less than 36"or at the discretion.of the Engineer. The Contractor shall be responsible for the correctness of the plans and for the results obtained by the use of such plans. Full compensation for Construction Traffic Control Plan and furnishing Traffic Control shall be paid for on a ltunp suns bid price under each of their respective lump sum bid items and no additional compensation will be allowed therefor. Street closures will not be allowed except as permitted by the Engineer. The following minimwn lane requirements shall be provided at all times, subject to time of day restrictions as established by Section 6-7.2 and this Section. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 4 of 6 Arterials All lane closures are restricted to the hours of 9:00 AM to 3:00 PM,Monday through Friday. Beach Blvd.: All project work on Beach Boulevard: The Contractor shall construct this project per the approved Traffic Control Plan. Lane closure shall be restricted to no more than 4 total working days; if working days are sequential, the lane closure must be removed by 3:00 PM every day. The Contractor shall coordinate all work with the Caltrans and Agency Inspector. A copy of the Caltrans Encroachment Permit is in Addendum of these specifications. Beach Blvd. at Edinger Ave.: Maintain 2 southbound right turn lanes, 2 southbound through lanes, and 2 left southbound lanes at all times. No other lane closures will be allowed on Beach Blvd. 7 Edinger Ave. at Beach Blvd.: Maintain 2 eastbound left turn lanes and 1. eastbound through lane at all times. No other lane closures will be allowed on Edinger Ave. Beach Blvd, at Aldrich Ave.: Maintain 2 southbound through lanes and two southbound left turn lanes at all times. No northbound closures will be allowed on Beach Blvd. Aldrich Ave. at Beach. Blvd.: Maintain 1 through late in each direction at all times. No northbound closures will be allowed on Beach BIvd. Beach Blvd. at Stark Ave.: Maintain 2 southbound through lanes at all times. No northbound closures will be allowed on Beach Blvd, Stark Ave. at Beach Blvd.: Maintain 1 through late in each direction at all times. No northbound closures will be allowed on Beach Blvd. Local Streets(all streets not identified above as arterials) Maintain one two-way travel lane with flagger control. s 7-10.5 ]Protection of the Public [Add Subsection in total and replace with the following:]. It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor shall use foresight and shall take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the work which will require that immediate and unusual provisions be made to protect the public from danger or loss, or damage to life and property, due directly or indirectly to prosecution of work under this contract. ADDENDUM NO. I CC-1396 SPECIFICATION REVISION PAGE 5 of 6 Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer, immediate action shall be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation, the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as may be necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, shall be borne by the Contractor. All expenses incurred by the AGENCY for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. However, if the AGENCY does not take such remedial measures,the Contractor is not relieved of the full responsibility for public safety. i ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 6 of 6 3 4AT FCALIFORNIA-DEPARTMENTOFTRANSPORTATION Page1of4 DARD ENCROACHMENT PERMIT APPLICATION ott3LTFta,N$t(REV.0712007) PERMIT NO. Permission is requested to encroach on the State Highway right-of-way as follows: DISTICO/RTE/PM (Complete-.all I;OXES.j"wrfte NIA if not applicable]) L— ✓y.w 3 # i This application is not complete until all requirements have been approved. SIMPLEX STAMP s 1.COUNTY 2.ROUTE 3.POSTMILE s ORA 39 5.63 12 6-3 4.ADDRESSOR STREET NAME 5.CITY Edinger Ave Huntington Beach 6.CROSS STREET(Distance and direc5on from site) 7.PORTION OF RIGHT-OF-WAY DATE OF SIMPLEX STAMP Beach Boulevard Pavement z1 S.WORK TO BE PERFORMED BY 9.EST.START DATE 10.EST.COMPLETION DATE ❑OWN FORCES ® CONTRACTOR September 26, 2011 October 28, 2011 11. MAX.DEPTH AVG.DEPTH AVG.WIDTH LENGTH SURFACE TYPE EXCAVATION NA NA NA NA Pavement 12.EST.COSTIN STATE HIGHWAY RIGHT-OF-WAY FUNDING SOURCE(S) N/A ❑FEDERAL 0 STATE ®LOCAL ❑ PRIVATE 13. PRODUCT TYPE DIAMETER VOLTAGE/PS1G 14.CAL•TRANS PROJECT E.A.NUMBER PIPES CIPPOR PVC SEWER LINER INEXISINOvcp 811 N/A N/A " 1 15. ❑ Double Permit Parent Permit Number Applicant's Reference Number! Utility Work Order Number CC-1396;Sewer Rehabilitation 16. Have your plans been reviewed by another Caltrans Branch? ® NO ❑ YES (If"YES") Who? 17. Completely describe work to be done within STATE highway right-of-way Attach 6 complete sets of FOLDED plans(folded 8.5"x 11"),and any applicable specifications,calculations,maps,etc. All dimensions shall be in U.S.Customary(English)Units. The sewer line reach of approximately 870 feet begins from manhole at Southwesterly intersection of Beach Blvd. and Edinger Avenue'to the manhole at intersectoin of Beach Blvd. and Stark Avenue, The result of sewer lining wilfrequire traffic control within Caltrans Right-of-Way. Traffic Control Plan will be submitted by Contractor. 1a.Is a city, county, or other agency Involved in the approval of this project? ® YES (if"YES",check type of project and attach environmental documentation and conditions of approval.J ❑COMMERCIAL DEVELOPMENT ❑BUILDING ❑GRADING ❑OTHER ®CATEGORICALLYEXEMPT ❑NEGATIVE DECLARATION ❑ENVIRONMENTAL IMPACT REPORT ❑OTHER ❑ NO (If"NO,please check the category below which best describes the project;and complete page 4 of this application.) E3 DRIVEWAY OR ROAD APPROACH,RECONSTRUCTION,MAINTENANCE,OR RESURFACING ❑ FENCE ❑ PUBLIC UTILITY MODIFICATIONS,EXTENSIONS.HOOKUPS ❑ MAILBOX ❑FLAGS,SIGNS,BANNERS,DECORATIONS.PARADES AND CELEBRATIONS ❑ EROSION CONTROL ❑ OTHER ❑ LANDSCAPING 19.Will this project cause a substantial change in the significance of a historical resource(45 years or older),or cultural resource? [:]YES ®NO (If"YES",provide a description) 20.is this project on an existing highway or street where the activity involves removal of a scenic resource including a significant tree or stand of trees,a rock outcropping or a historic building?❑ YES m NO (If"YES",provide a description) e 21.Is work being done on applicants property? ❑ YES ® NO (If"YES",attach site and grading plans.) ADA NOTICE:For individuals with senwry disabilities,this document is available in alternate formats.For information call(916)654-6410 or TDD(916)654-3880 or n write to Records and Folms Management,1120 N Street,MS-89,Sacramento,CA 95814 h 5 STATE OF CALIFORNIA-DEPARTMENTOFTRANSPORTATION Page 2 of STANDARD ENCROACHMENT PERMIT APPLICATION PERMIT NO. TR-0100 (REV.07/2007) 22.Will this proposed project require the disturbance of soil? l]YES ONO i If"YES",estimate the area M[iIjAn State Highway right-of-way in square feet AND acres: (W)AND (acres) ! estimate the area outside of State Highway right-of-way in square feet AND acres: (W)AND (acres) I 23.Will this proposed project require dewatering? YES ©NO If"YES",estimate total gallons AND gallons/month. (gallons)AND (gallons/month) SOURCE': ❑STORM WATER ❑NON-STORM WATER ('See Caltrans SWMP for definitions of non-storm water discharge: http:ttwww.dot,ra.gov/hq/envfstormwater/index,htm) 24.How will any storm water or ground water be disposed of from within or near the limits of this proposed project? ®Storm Drain System 0 Combined Sewer/Storm System Storm Water Retention Basin Other(explain): PLEA SE RE AD THE FOLLO WING CLAUSES PR10RTO SIGNING THIS ENCROACH M ENT PF.RNIITAPPLICATION. The applicant,understands and herein agrees to that an encroachment permit can be denied,and/or a bond requiredfornon-paymentofpriororpresentencroachmentpermitfees.EncroachmentPermit fees maystillbe due when an application is withdrawn or denied,and that a denial may be appealed,in accordance with the California Streets and Highways Code,Section 671.5.All workshall be done in accordance with Caltrans rules and regulations subjec t to inspection and approval. The applicant,understands and herein agrees to thegeneral provisions,special provisions and conditions ofthe encroachmentpermit,and to indemnifyand hold harmless the State,its officers,directors,agents,employees andeach ofthem(Indemnitees)from and againstanyandallclaims,demands,causes ofaction,damages,costs, expenses,actualattomeys'fees,judgments,losses and liabilities ofeverykind andnature whatsoever(Claims) arising out ofOrin connection with the issuance andloruse of this encroachment permitand the placementand subsequent operation and maintenance of said encroachment for. 1)bodily injury and/or death to persons including but not limited to the Applicant, the State and its officers, directors, agents and employees, the Indemnities,andthepublic;and2)damage topropertyofanyone.Except asprovidedbylaw,the indemnification provisions statedaboveshallapplyregardless of the existence ordegree offaultoflndemnities. TheApplicant, however,shall notbe obligated to indemnifylndemnities for Claims arising from the sole negligence and willful misconductof State,its officers,directors,agents oremployees. DISCHARGES OFSTORM WATER AND NON-STORM WATER:Work within State Highway right-of wayshall be conducted in compliance with all applicable requirements of the National Pollutant Discharge Elimination System(NPDES)permitissued to the Department of Transportation(Department),to govern the discharge ofstorm waterandnon-stormwaterfrom its properties.Work shallalsobein compliance with all otherapplicableFederal, State and Locallaws and regulations,and with the Department's EncroachmentPermits Manual and encroachment permit.Compliance with the Departments NPDES permit requires amongst other things,the preparation and submission ofa Storm Water Pollution Protection Plan(SWPPP),ora WaterPollution Control Program(WPCP), and the approval of same by the appropriate reviewing authority prior to the start of any work.information on the requirements mayalso be reviewed on the Department's Construction Website at: http.11www.dot.ca.govlhcticonstruc/stormwa terlstormwaterl.htm 25.NAME of APPLICANT or ORGANIZATION (PrintorType) E-MAILADDRESS City of Huntington Beach jwagner@surfcity-hb.org ADDRESS of APPLICANT or ORGANIZATION WHERE PERMIT IS TO BE MAILED (Include City and Zip Code) Public Works, 2000 Main Street, Huntington Beach, CA 92648 PHONE NUMBER FAX NUMBER 714-536-5431 714-374-1573 26.NAME of AUTHORIZED AGENT/ENGINEER(Print or Type) IS LETTER OF AUTHORIZATION ED?J E-MAIL ADDRESS Joseph Fuentes p YES [3 NO Same as above ADDRESS of AUTHORIZED AGENT/ENGINEER(include City and Zip Code) same as above PHONE NUMBER FAX NUMBER 714-536-5259 same as above 27.SE ATUREof PP,VrNTor AUTHORIZED AGENT 29.PRINT OR TYPE NAME 29.T1TLE 30.DATE Joseph Fuentes Civil Engineering Assistant i; STATE OF CALIFORNIA•DEPARTMENTOFTRANSPORTATION Page 3 of 4 STANDARD ENCROACHMENT PERMIT APPLICATION PERMIT NO. _ - : ... . ..........:..... ... . TR-0100 (REV.0712007) WORK ORDERIREFERENCE NUMBER FEE CALCULATION -- FOR CALTRANS USE ❑ CASH ❑ CREDITCARD NAME ON CARD PHONENUMBER ❑ CHECK NUMBER NAMEONCHECK PHONENUMBER ❑ EXEMPT ❑ PROJECT EA _—____ ❑ DEFERRED BILLING(Utility) CALCULATED BY (1} (2) REVIEW 1.FEE/DEPOSIT DATE 2.FEE/DEPOSIT DATE TOTAL FEE I DEPOSIT 1. HOURS @ $ $ $ 2. HOURS @ $ $ $ INSPECTION 1.FEE I DEPOSIT DATE 2.FEE/DEPOSIT DATE TOTAL FEE I DEPOSIT 1. HOURS @ $ $ $ 2. HOURS @ $ $ $ FIELDWORK HOURS @ $ $ $ $ DEPOSIT DATE DEPOSIT DATE DEPOSIT EQUIPMENT&MATERIALS $ $ $ CASH DEPOSIT IN LIEU OF BOND $ $ $ TOTAL COLLECTED $ $ CASHIER'S INITIALS $ *The current hourly rate is set annually by Headquarters Accounting. District Office staff do not have authority to modify this rate. PERFORMANCEBOND ❑ DATE MOUNT DATE AMOUNT PAYMENTSOND [] $ AMOUNT LIABILITY INSURANCE REQUIRED? ❑ YES ❑ NO $ i STATE OF CALIFORNIA-DEPARTMENT OFTRANSPORTATION Page 4 of 4 STANDARD ENCROACHMENT PERMIT APPLICATION IRMITNO. TR-0100 (REV.0712007) INSTRUCTIONS for completing page 4 This page needs to be completed when the proposed project DOES NOT involve a City,County or other public agency. Your answers tothese questions will assist departmental staff in identifying any physical,biological,social oreconomic resources that maybe affected by your proposed projectwithin the State highway right-of-way.And,to determine which type of environmental studies maybe required to approve your application for an encroachment permit It is the applicant's responsibility for the production of all required environmental documentation and supporting studies,in some cases this may be costly a nd time-consuming.If possible,attach photographs of the location of the proposed project Please answer these questions to the best of your ability.Provide a description of any"YES"answers(type,name,number,etc.) 1. Will any existing vegetation and/or landscaping within the highway right-of-way be disturbed? 2. Are there waterways (e.g. river, creek, pond, natural pool or dry streambed) adjacent to or within the limits of the project or highway right-of-way? 3. Is the proposed project located within five miles of the coast line? 4. Will the proposed project generate construction noise levels greater than 86 dBA (e.g. jack-hammering, pile driving)? 5. Will the proposed project incorporate land from a public park, recreation area or wildlife refuge open to the public? 6. Are there any recreational trails or paths within the limits of the proposed project or highway right-of-way? 7. Will the proposed project impact any structures, buildings, rail lines, or bridges within highway right-of-way? B. Will the proposed project impact access to any businesses or residences? 9. Will the proposed project impact any existing public utilities or public services? 10, Will the proposed project impact existing pedestrian facilities, such as sidewalks, crosswalks, or overcrossings? i 11. Will new lighting be constructed within or adjacent to highway right-of-way? i i I I i i i State JobiUumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Project Location Comp. CA 200008 LAS VIRGENES WATER DISTRICT 1431 L.F.of 21 IN. MM $553,290.00 U2-U1 GRAVITY SEWER SYSTEM CALABASAS.CA 10/30106 0 L.F of IN. MM REHABILITATION 4232 LAS VIRGENES ROAS $612,140.00 0 L F.of IN. MM 0 L.F.of IN- MM CALABASAS CA 91302-1994 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 0 0 L.F.of IN. MM MH's: 0 818-251.2100 0 L.F.of IN. MM GA 200009 W.A.RASIC CONSTRUCTION 1030 L.F of 8 IN, MM $348,900.00 DIVISION STREET SANITARY LONG BEACH,CA 05121107 2768 L.F.of 10 IN. MM SEWER IMPROVEMENTS 7314 SCOUT AVENUE $317,185.61 PROJECT PO#6PCO03-02 3863 L-F.of 12 IN. MM 1040 L F.of 16 IN. MM BELL GARDENS CA 90201 0 L.F-of IN. MM 0 L.F.of IN. MM SC's: 50 ZORKITA PASCHALL 0 L.F,of IN. MM MH's: 0 562-928-6111 0 L.F.of IN. MM CA 200010 MONTECITO SANITARY DISTRICT 410 L.F.of 6 IN. MM $526,200.00 FISCAL YEARS 2006-2007 SEWER SANTA BARBARA,CA 0610 ,107 19348 L.F.of 8 IN. MM MAIN REHABILITATTON PROJECT 1042 MONTE CRISTO LANE $676,180.00 0 L.F-of 1N. MM 0 L.F of IN. MM SANTA BARBARA VA 93108 0 L.F.of IN. MM 0 L.F of IN. MM SC's: 160 MICHAEL MCCALEB 0 L.F.of IN. MM MH's: 0 805-969-4200 X-103 0 L F.Of IN, MM CA 200011 CITY OF SANTA BARBARA PUBLIC WORKS 13165 L.F.of 6 IN, MM $1,739,827.00 SEWER MAIN IMPROVEMENT F.Y. SANTA BARBARA,CA 02104i08 9401 L.F.of 8 IN. MM 2005-2006 BID NO,3426 630 GARDEN STREET $2,018,303.94 1062 L.F-of 10 IN. MM 500 LF.of 12 IN. MM SANTA BARBARA CA 93102-1990 558 L.F.of 18 IN. MM 192 L.F.of 30 IN. MM SC's: 420 TIMOTHY GAASCH 470 L.F.of 33 IN. MM MH's: 0 805-897-2502 0 L.F.of IN. MM CA 200012 STATE OF CALIFORNIA DEPARTMENT OF TRA 61 L.F,of 42 IN. MM $343,550.00 STATE OF CA DOT CONTRACT STATE OF 10104107 L.F.of IN. MM #05-ON7604 MONTEREY&SAN CALIFORNIA 3230 RIVERSIDE AVE SUITE 130 184 L.F.of 72 IN. MM S343,255.70 LUIS OBISPO COUNTIES 0 L.F.of IN. MM PASO ROBLES CA 93446 0 L.F.of IN. MM 0 L.F.of IN. MM sc's: 0 RICH 0 L.F.of IN. MM MH's: 0 805-471-2102 0 L.F.of IN. MM State JobNumber Owner/Contractor Job Classification Cnt/Finl Amount Proiect Description Project Location Comp. CA 200003 TEMCO 419 L.F.of 22 IN. MM $485,839.00 TEMCO-LACSD ALHAMBRA JNT LOS ANGELES,CA 10/13/06 147 L.F.of 26 IN. MM FAL BG-NEW DES NUMBER 2440 WALNUT STREET SUITE C-100 $495.527.00 190613;WAS JOB#192014 332 L.F.of 30 IN. MM 454 L.F.of 36 IN. MM NEWHALL CA 91321 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 3 0 L.F.of IN. MM MH's: 0 661-291-1932 0 L.F.of IN- MM CA 2CO004 BEADOR CONSTRUCTION COMPANY,INC 6903 L.F.of 8 IN. MM $437,672.00 BEADOR CONSTRUCTION NEWPORT BEACH,CA 04/10;07 1056 L.F.of 12 IN MM CONTRACT#3562 SEWER MAIN 26320 LESTER CIRCLE $414.383.50 REPLACEMENT/BiG CANYON 116 L.F.of 15 IN, MM TRUNK SEWER„WAS JOB#192028 0 L.F.of IN. MM &190670 CORONA CA 92883 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 200 0 L.F,of IN. MM MH's: 0 (951)674-7352 0 L.F.of IN. MM CA 200005 CITY BIG BIG BEAR LAKE 339 L.F.of 8 IN. MM $433,301.50 SEWER RELINE PROJECT 2006- BIG BEAR LAKE,CA 08I28106 7954 L.F.of 8 IN. MM 2007;WAS FORMALLY JOB 39707 BIG BEAR BLVD $449,072.25 #192034 0 L.F.of IN. MM 0 L.F.of IN. MM BIG BEAR LAKE CA 92315 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 124 JACKIE HEULE 0 L.F,of IN, MM MH's: 0 909-866-5831 0 L.F.of IN. MM CA 200006 LOS ANGELES COUNTY SANITATION DISTRIC 1090 L.F,of 15 IN. MM $53,275.00 LOMITA TRUNK SEWER LOS ANGELES,CA 11/12106 0 L.F.of IN. MM EXTENSION NO.2 1955 WORKMAN MILL ROAD $53,775.00 REHABILITATION-2006;WAS JOB 0 L.F.of IN. MM #192036 0 L.F.of IN. MM WHITTIER CA 90601 0 L.F.of IN. MM 0 L.F.of W. MM SC's: 8 ALMA HORVATH 0 L.F.of IN, MM MH's: 0 562-699-7411 0 L.F.of IN. MM CA 200007 COUNTY SANITATION DISTRICTS OF LOS ANG 585 L.F.of 10 IN. MM $1,469,875.00 DOWNEY-BELLFLOWER TRUNK LOS ANGELES,CA J3/23,'O"T 832 L.F.of 24 IN. MM SEWER REHABILITATION;WAS 1955 WORKMAN MILL ROAD PO BOX 4998 3573 L F.of 27 IN. MM $1,403,121.00 JOB#192035 0 L.F.of IN. MM WHITTIER CA 90607-4998 0 L.F.of IN. MM 0 L.F.of IN. MM SC's: 106 JAMES STAHL 0 L.F.of IN. MM MH's: 0 562-699-7411 0 L.F.of IN. MM THE AMEI2ICAN INSTITUTE OF ARCHITECTS ALA Document A310 Bid Bond KNOW ALL MEN BY 'THESE PRESENT'S,that we INSITUFORM TECHNOLOGIES,INC. 17988 EDISON AVENUE CHESTERFIELD,MO 63005 (Here insert full name,and address or legal title of Contractor) as Principal,hereinafter called the Principal,and TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA ONE TOWER SQUARE HARTFORD,CT 06183 a corporation duly organized under the laws of the State of CT as Surety,hereinafter called the Surety,are held and firmly bound unto CITY OF HUNTINGTON BEACH 2000 MAIN STREET HUNTINGTON BEACH,CA 92648 (Here insert full name,and address or legal title of Owner) as Obligee,hereinafter called the Obligee,in the sum of Ten Percent of Amount Bid---------------Dollars ($ 10% of Amount Bid), for the payment of which sum well and truly to be made,the said Principal and the said Surety,bind ourselves,our heirs,executors, administrators, successors and assigns,jointly and severally,firmly by these presents. WHEREAS,the Principal has submitted a bid for Sewer Rehabilitation Project,CC No. 1396 in the City of Huntington Beach (Here insert full name.address and description of prgject) NOW,THEREFORE,if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof,or in the event of the failure of the Principal to enter such Contract and give such bond or bonds,if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid then this obligation shall be null and void,otherwise to remain in full force and effect. Signed and sealed this 26th day of July,2011 r I INSITUFORM TECHNOLOGIES,INC. / (Principal) (Seal) Title (�VitneSS�`?� �� (� ( VP_Global H.Douglas Thomas Support �j � TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA (Surety) (Sea (Witness)Salena Wood '(Title Barbara B li,o d, , orney-In-Fact AIA DOCUMENT A310 BID BOND AIA® FEBRUARY 1970 ED THE AME INSTITUTE OF ARCHITECTS,1735 N.Y.AVE.,N.W.WASHINGTON,D.C. 20006 1 WARNING: Unlicensed photocopying violates U.S.copyright laws and is subject to legal prosecution. CALIFORNI[A ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT State of Ealiferfl:ia Missouri County of St.Louis On July 26,2011 before me, Salena Wood,Notary Public _ (Here insert name and title of the officer) personally appeared Barbara Buchhold,Attorney-In-Fact who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s)is/are subscribed to the within instrument and acknowledged to me thai-br,/she/they executed the same in+Lis/her/theirr authorized capacity(ies),.and that by4ik/Iaer/tkeir-sigaature(s)on the instrument the person(s),or the entity upon behalf of which the person(s)acted,executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. SALENA WOOD FNotary Public-Notary Sea{ VJTI'NESS my hand and off1 -al seal. STATE OF MISSOURI St.Louis County mission Expires: July 17,2015 Commieeian#11129i05 _. Signature of Notary Public Salena Wood,Notary Public ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM DESCRIPTION OF THE ATTACHED DOCUMENT Arv'acknowledgment corpleted in California nucst conrain verbiage,axocllv as appears above In the notary section ar a separate aclatowladgmern form must be properly completed and attached to that document. 17te only exception is if a Bid Bond doctunertl is to be recorded outside of California In sitch instances,and,alternative (Title or desedption of attached document) acknowleda cent verbiage as pray be printed on such a document so long at the verbiage does not require fire notary to do something that is illegal for a notary in California(i.e.certifying the authoreed capatd0 of the signer).Please check the (Title oI desmiption of attached document continued) docrortarct carefidlyforpropa-notarial wording and attach this form ifregairad, Number of Pages 1 Document Date 7/26/11 State and County information must be the State and County where the document signer(s)personally appeared before the notary public for acknowledgment. Travelers Casualty and Surety Company of America Dare of notarization must be the date that the signer(s)personalty appeared (Additional information which must also be the same date the acknowledgment is completed. ° The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title(notary public). • Print the name(s)of document signer(s)who personally appear at the time of CAPACITY CLAIMED BY THE SIGNER notarization. indicate the correct singular or plural forms by crossing off incorrect forms(i e. Individual(s) he ishelthep;is/are)or circling the correct forms.Failure to correctly indicate this information may lead to rejection of document recording. FjCorporate Officer The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines.If seal impression smudges,re-seal if a sufficient area permits,otherwise complete a different acknowledgment form. (Title) Signature of the notary public must match the signature on file with the office of Partners) the county clerk. ® Attorney-in-Fact ❖Additional information is not required but could help to ensure this S acknowledgment is not misused or attached to a different document. Trustee () Indicate title or type of atracbed document,number.of pages and date. Other Indicate the capacity claimed by the signer.If the claimed capacity is a corporate officer,indicate the title(i.e.CEO,CFO,Secretary). • Securely attach this document to the signed document 2008 Version CAPA V12.10.07 800-973-9865 www.NotaryClasses.com S-4067/GE 9/09 XDP State of Missouri County of St. Louis On 7/26/2011 before me, a Notary Public in and for said County and State, residing therein, duly commissioned and sworn,personally appeared Barbara Buchhold known to me to be Attorney-in-Fact of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA the corporation described in and that executed the within and foregoing instrument, and known to me to be the person who executed the said instrument in behalf of said corporation, and he duly acknowledged to me that such corporation executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal,the day and year stated in this certificate above. SALENA WOOD Notary Public-Notary Seal STATE OF MISSOURI St.Louis County My Commission Expires: July 17,2015 G®mtttiMrinn#111291A� My Commission Expires Salena Wood, Notary Public WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER I POWER OF ATTORNEY TRAVELERSRAVELERS J Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company Attorney-In Fact No. 223577 Certificate No. 0 Q 44:.t d 4 4©4 KNOW ALL MEN BY THESE PRESENTS:ThatSt.Paul Fire and Marine Insurance Company,St.Paul Guardian Insurance Company and St.Paul Mercury Insurance Company are corporations duly organized under the laws of the State of Minnesota,that Farmington Casualty Company,Travelers Casualty and Surety Company,and Travelers Casualty and Surety Company of America are corporations duly organized under the laws of the State of Connecticut,that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland,that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa,and that Fidelity and Guaranty Insurance Underwriters,Inc.,is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the"Companies"),and that the Companies do hereby make,constitute and appoint Andrew P.Thome, Dana A.Dragoy, Kristan L. Lucas, Peter J.Mohs,Helen A.Antoine,Salena Wood,Debra A.Woodard,and Barbara Buchhold of the City of Chesterfield State of Missouri their true and lawful Attomey(s)-in-Fact, each in their separate capacity if more than one is named above,to sign,execute,seal and acknowledge any and all bonds,recognizances,conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or.proceedings allowed by law. 13th IN WITNESS WHEREOF,the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this day of May 2011 Farmington Casualty Company St.Paul Mercury Insurance Company Fidelity and Guaranty Insurance Company ` Travelers Casualty and Surety Company Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company St.Paul Guardian Insurance Company pA5o[nIA� F\REg4W. \RN.INfG }+C',��NSUR J>,ITY ANO N@w9lJY FT"Y Or C�•?`'YT�' it - �P Q'RPQR � IL', •,'tiC'x 4P L Cny�t . go r 1 9A W o BCCNPORATEp m i t'm 3.W i.con f�, S• a � � ;a: --_ s a rwflrhnflo, < mtnn0. 1896 n. �; EAL 'o CONN. o CONK. $ N 5 a 1951 ;o; '-o:SBA f State of Connecticut By: City of Hartford ss. Georg Thompson, enior ice President On this the 13th day of May 2011 before me personally appeared George W.Thompson,who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters, Inc.,St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company,and that he,as such,being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof,I hereunto set my hand and official seal. My Commission expires the 30th day of June,2011. e Mane C.Tetreault,Notary Public 58440-4-09 Printed in U.S.A. WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER CALIFORNIA ALL-PURPOSE CERTIFICATE OF ACKNOWLEDGMENT MSSau t-1 State of eahfarnia County of -- tk,,s On July 26, 2011 before me, Denise Carroll (Here insert name and title o e officer) personally appeared H. Douglas Thomas , who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s)is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies),and that by his/her/their signature(s) on the instrument the person(s),or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is b3le and correct. DENISE L.CA RR pL i No Public-Nosy Sari WI my han4,�kOofficial s STATE OF MISSOURI j � Pike County Ally Commission Expires: Dee.5,2013 mission#09399892 Signature of Notary Public ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM DESCRIPTION OF THE ATTACHED DOCUMENT Any acknowledgment completed in California must contain verbiage exactly as appears above in the notary section or a separate acknowledgment form mist be properly completed and attached to that document. The only exception is if a BID BOND document is to be recorded outside of California.In such instances,any alternative acknowledgment verbiage as may be printed an such a document so long as the (Title or description of attached document) verbiage does not require the notary to do something that is illegal for a notary in California(i.e.certifying the authorized capacity of the signer).Please check the (Title or description of attached document continued) document carefidly,for proper notarial wording and attach this form if required. Number of Pages Document Date 7/2 6/11 - State and County information must be the State and County where the document Insituform Technologies, Inc. signer(s)personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s)personally appeared (Additional information) _ 4 which must also be the same date the acknowledgment is completed, • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title(notary public). • Print the name(s)of document signer(s)who personally appear at the time of CAPACITY CLAIMED BY THE SIGNER notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms(i.e. ❑ Individual(s) he/she/tier; is;/are)or circling the correct forms.Failure to correctly indicate this information may lead to rejection of document recording. ® Corporate Officer • The notary seal impression must be clear and photographically reproducible. VP—Global Procurement/Operations Impression must not cover text or lines.If seat impression smudges,re-seal if a (Title) Support r t • sufficient area permits,otherwise complete a different acknowledgment form. P P Signature of the notary public must match the signature on file with the office of ❑ Partner(s) the county clerk. ❑ Attorney-in-Fact ❖Additional information is not required but could help to ensure this H TruSte S acknowledgment is not misused or attached to a different document. � ) •,•Indicate title or type of attached document,number of pages and date. Other ❖Indicate the capacity claimed by the signer.If the claimed capacity is a corporate officer,indicate the title(i.e.CEO,CFO,Secretary), • Securely attach this document to the signed document 2008 Version CAPA v12,10.07 800-873-9965 www.NotaryClasses.com S4067/GE 9/09 XDP City ®f Huntington Beach 2000 Main Street ® Huntington Beach, CA 92648 (714) 536-5227 ® www.huntingtonbeachca.gov ®Mice ®f the City Clerk 17 7909 e Joan L. Flynn, City Cleric September 30, 2011 Repipe 5525 E. Gibraltar St. Ontario, CA 91764 RE: CC-1396—Sewer Rehab Project Enclosed please find your original bid bond for CC-1396. Sincerely, Joan L. Flynn, CIVIC City Clerk JF:pe enclosure t@vuoiWbsontkgjo0b o* Waitakere, New Zealand _,'x.-., r a ,Y'^ F,Mr r-*n 5,-. �r ,„�;C,,� „.^"'.:' -'t74:.+°& ,tS^ „$. r;,,^4 *,, r ;7,txx?',�x - r'"" a +vtazi,... ap.�,...Y, fz°•a '?s;..s".•i. .:� `<"x.';v. " , .::z; y, t ,� ! r''~.r ,Ik ,.,... k ,,.. m° .r rkd..°:? d fA;;S a:.1. , 3.:9n., ,.... I,9 `: ,v' "€= ;3 4' --x; x E. v i- L' ,;',-la"',Y,4' :t"' .m.,":..: t ;t,,:a. K; .: ., f; ,, r X' "` ^2 a ,it :,; ,., aF. r n- ;.,.-''4�",. ,i,,, rn:'4"H"' :,.. -t .",,.:, ,, �Arrh aX '§ '� E A t tM. �':� ^" ��'^ ,.avr Sr''' e: d +'i kll s r ""F S"`.2. p »;°''� sw""`k m 4, "-x.t, e. !���,-,zl' � r .:, a t*"y ;ea', _r, ,' s'# 34q �n : `§p -i: ,�,� `-G*'f`ti e to, yF'. "lg" M -ve;,h F rE, v' L rs, 7 's *d t` f M REFIRE ,y. :i A N I PR COMPANY 11 ' 8,tr' .y T F ! 4 :` p sr ah '` K 'tw ''""- s+v. '1. ' } Y 1 r'<'',8 �, {Yl Sr '.''^ *: ':pit: 5+",w s C*:k^~r ?w a„2.i' ':ro t ,rp tt:? ""4 S a: az „,'l a 7 A 4'.i'.. r, ; "uw_ - w( „` va r ,�,, „„� .�, t,v;.,?S, < R •a'� t+`tw,t ah.;, a r {� ;a. ,tr NI„u ' ' fir.+sw ! »wm. ''rr a :.». Ii 5525 E.Gibraltar St. ti - " y;'� _ :I`i , , -. Ontario, CA 91764 _ � 4 "� �u e n *' , -4 - ', 7 �j9f -1,1 .Y �" 4z,sq '€ ", V .r^1 } ,.. `, S3 P ,h'�F F TFS' V"-i I Y T N.r `n "5' a§r ,y •kh 7 . ir,'- r a,:';�+ r a. :G.,f t`yY ! -.i''�5 .,, 'x r.r.4 rt T d ;s,.`•" w-:r;` ''s , ,.,., 1 " fi...., .^„ ,.f.. .-I :.. „ „x„°u:':..: „ ,x, ..r,r t,, 4..c .0 , ,,�F, v..„.. ',,. :., ..rM7 ap„ .-E .,5 :4 ,a. .Str ,.r. -,!: .5*' Sr. - 7 t. ,.,,..,,a. .,v, ,.,ram' < -:d`., .. : L"`tw"rT. .. ",..>,.,. _.,... S,. 5. .`k d' m. ',,.� :�, :,.. , u a.. ....ti 'S., ',,: d ka, r:.,.s.,,k 1'. �.. e ,,..rt„ ,.. b'§.„ ,1 „r: ,r, ,. .4,: 8 r_., k , .'C:a v.. ri, , i.k::::n.. :...<,. Sr. ;,i,` . r � Via.„- rrr t _ , . �n t :_..vt .-.^r" ;.,., .r'„ ... ,.,, .w�,_ 4. .....r.., ,.,::- ,,:$,-. ,. ..,..« 9. ,.:iE.. '.h ".;ate, MS.., "'+N. a- "ov a�,...;.. t ru': s•'' a;;:k ; ..n.,w'.mi.,r. `�, -°a.ra,.. ___ .s+ -. '^* :,_,,: : .} 4 - 'tiu .: ,.,,�.. -, ..., t �,,x'„ z<;-, S a:,:t_ a ::--?a ".x , _b-:,,.�.:. g'x,- ;;... .x,.._,_. :` -.:,* ,._,. '.'S,5- :-,r ::�.f ,-;.Kv' i.,.,w - -!r„,:+3c .. yx_ �+qw,x,w...: G' a P,- -,,..;'- ;" - -2' y,x -Y..,....,t - C .•'%p rtP # ii 11 1--, '. r S;^,.,.. .j-:, a. .: .-,r A r �ti,,. "x. T, - f5€'1 ` + >: ,-�a x s«..>.x,.. ,` .,,, F.. .a.: -,.�. ,.,_ - - -,ems:,. i ,,. "r- ,,... , ,w. . . , ..� ..!dY•rn"�". .,,... . ,h / . ,., .." ...c._ ,,. .r,.� „ -' f/��% ~d4 iw, {�" !.. :. �y,� ,.., , ! '. -r,r.rrU a ,><... .. t 3.. �^."r; ,J, .,. 4 „'k ,,,.. w 'Jv .3 ,," -,A :., t - ."'„-wf °k h€, d ,u, a F ,."2 .,,..d .,...,. ,,.."C - ",,, .r a ':.a ,. ,.r ,- .w w4 ,» nv"LL*.a.;' JJh^ ,.,... , ry w +H , �. �, :,.-., h u, ,.u._, .,o, ,- A„.. I '':, 1: -.m ,+Ot.,:,. , ,M' tH .Y.",- 4 x..'a, ..,'S., ,.�, St"k': ,r _. vs ,. ,.,. .,o.:,.s t _:'s'v!.. z,.v.. ,t .„...: ,:�,.: ,r M,v`t., Y. r r _5'3?'; A., ::Y .,:... ! ,„ - ,, .. .�ll,.ur „t. *. n ... .. ...',k' r. i „., a",..W '?L. �'.!M:h"t +, r5 ,u� ": I .w«,,., a,*!:..,i. -e - ., ... , �„-P ,,, ., .., -s. .. ,,.. .., »...,.. f..x '.+: .:,,x 's r.. .:.v,A M.c t:„ st"E'.:., �,- r:.,d r, ,,.f' .r'.,., r.;sr,'•.,,..fix 3 . .. _k w,.... ,... _.. �,..4 -..i:.n ..::.._.....sw ..., k,.'.'_:.:. _.d.-.,„ ..,s._,. .. -.,,, _ - _ K -, -1 3 "E ti x yr:. _;-:f. :r.r..-,... ,:.'„',2.,;..as.w,,,_ tc"y>>~:".,...z.�" v..... :- :.. „•r `xs-+ - -`�'. + '1 { 4 -»�"'4 _ :gin �' 1, 1 T.4 3 »T. 'i. t i - - ,'.f-, 'S } F- .'i -win' .. , - > ,,. t.. ,., s +.... _ ,. -, t �,:. P :..,,,.,,v..::m` xr :c 1,. #r r ,,., ., ,..$.. .. ?PE".,.. .. .,`w' ,. ..� ..,,,r .,.,. n t .".-y_,.. ,a, .&; t. .t '.., '+,�... . '- .., :.,e .,:1$`.F kR r., ,r,rµ I,kr ,r.r.,. " . 7n, .:'t..fra. .. t<'T„. ,.,,;: ,:'t f W .. w:,: -. ., 'd .. , .?,, :a.,�: ..a Z.ut. rr .,:.ar.: r~, d,,. ,". ! § <,,1J }::r a 5. .k ,, ,:. - , .,`it'd. ,w,,,. .r. ?,, .. _'.'ft 7, r. .,, t y ;.:: a 55 'i::. §' e.. ,�,x r�_,e p; rr„ .X'^ a . x,,s, ..� .,. , v... ,,.x .+.' °+W'.;,yy. r .+ny.n x d ,_ .a.., .,,.. ,:a, ,s .J;k`. ;...:.„ v,,,, :j,+ g, tr t_ f, :a'.' .M. ,'f".^1, a J.,.., a. ,.,: ,,r,: ,IF-s, "5,. :,s?, ,t:a.+,..� -. ., '... '.e..e r� 4' ..a '1,. ,, t a. w,, _. :.a1� ,:x.n}�^., .<�'::_ :e„ ";:,- ,»r; .<J -.,,.: -,, ..a,:..,- .is-,.-. . ..e., ,t. ? �'+' ',.v>'ra:" R. ,. 3, d".. lct* +„,.. }a,..„.- 4r�a!h.'n a. ';,s ,., r,.,, .,r N ;,2 tt - r MC r.cr4. .4,.-....y 's r ..w�. .+r.. ?...s....b..:;-�' y.?"'. .,_a .ri. -_; :a..u. -'-� -ems ":3 I _ ..5:-z , a:' rr-. I .�' ',,,.:� •i,, `" t .r,' -, ,.. ''. ,y s 7 "..7.., it r ..,..., ,1T; ,> ., ,*�• , a. (..,-,a„ ,., a a.., .. ,.. r.v: ,kM.,. ... .,..,, n'. x ....,.. c.. ,w u.,.. a. ,:m <., t r i at a 6 c "',..:'4' F,_: ,., V,.YM ,✓ r._a t4 ,h ,::'.r .-r ..r ,,..,,.. y ,,5 Ks ,,.»n -a ,. - ,a..., -a, t'r ,.,-, 1° .- A w, < ,;_, ..r al5.... . ..r. .t,.~4t, 'a .. .,r x,* :r?...:[ a, <mr. a' rco-. f y-: r„,. ,,,:w .. .;,..F e,.0 ,,. .,,•• 5' b K t ,'}. n,. ,*... ,."? rs r.+: r.wi° ,,x. .:,,...,, m ,,a... .:. ,t, p.,., ..,� «. } r «ar .,', ;, Y ,..«. ,.':e 7 -: .r .. t §r ai w ..�;h ..r:"- ..:.: :t:-z" - .. '•r: *_..<,,.:,41 ,k `.x-y "-:r �;q..r„ 5: » ';.,:: .tF vI. ,'- t. :ii �'Sr L, t- ".4:,.,.rt ..,.A:.,a. .l, 'k.,. y .....,.7'. .I k., 5t ,..-:�' i- r' +;�- l° ,:.3 -.F i, "w _FYt .'..:."-,- sue, ,.,, _ . wf .. .>.. -.. I €. ':s. ...:. t .�.,- -,<. ,; ,t r-2 X .i.-.X •w. raS z; _ ;*1 „f +,M1 y'. -z. "1. --'Y` ,"', d .t:. l d �:at"<K �t 42, r• - t -, 4 ,., --...: ',as ... a.. <,. .-z'` .- 1. .[. a. s,.. ,.''S` .:r+ a,. 'i ry✓,yW„ '..h,;:, ,,,,.;r .. :%.,, .� .,,!, i,,';r- ..r v.' -.i _: 'P ..5.. -� 5.i t Ci F.,,F.„,..Lro� .`Fyn„ 4 .+ r m-,,.«, -?r ., .. ...., I „•.4,µ.. C ."1" .d.. 9 a, ,n-;; N c,.r-.Pp.-1 k x T..... ° ,.,. ,v ,,, ;+ .Y". ,,. - r'.0:,�, 4 .'wi ," Y p,a 'w 3`�.1.,v.,.._ v,v h. .,-fie.P" -v+., ul r,,,+Y. .., rt; ,.N.A I w. l:. n,k r, ,,y 'i:, ,.: 1 ,. f ",a ,. N, f t, f .w, .» .. , 'v c9' v:.: ' .... }u 3. Y.,.,n,. .,...,.tr.„.(,,. , ,.4'.. „ «7 ,,..,... A. .:. .f p:x .,-..3,.- + ,.,,, i.^ :d. ed~ ".,ra•. "4, ::''4. +t t. .�r. .a ,,.._:t xa' _ ,,,a 11',,,::-..r t,',+:,v ",,,e, .< .,, hs K,e v,r �; >, ,t.•r , ,,,, `K. :` !,:...," w t 4..a - r t t <,. - b � �° ,� '.:''a,_ ;r' -i'fi''t �:».., F a rr. 6 5 -.,y.>x, .I. , ,y "y k a = S Y 2 x "x' �` ' -� _Y. ,N .1., -.-. r x.,. ,. - - fi , v!tiv„:C' ^fir a4 d ,,:,,,r:i t ,: ..; t' :. % I ', 1, ,w .,h �. :, c,.: ,.,.. ,:u,.,. ,y. r .,rd .ns ..,.+ �r.:,.i: % :.9.. "Y .,r;:.r'<� Y ].:: t�' 1 f.�„ r,. sr'^ ,. :';, ... ..,,. t ! r ,4 ..:. t r s y"• ,5 3Nr. ,q w:7 -~t- r f` "T 1• tj. + ry x r,n, ', l '` .. s- o _r _.,_ _- .. .. _ .. - ° 1 t S ,w Y T v a 4 '"�„�$9'p''�'P'hn rr ',a'' i f', ! !% � r 'r a :a fi "Sealed Bid"For: �,�,� � s r o- i i r %f xT , SEWER REHABILITATION PROJECT j �: 'I` CC-1396 in the CITY Off'HUNTINGTON �' ,'`i r 'L 5t a` a y{`x �r , 4 BEACH % S y h 4x r a :i IKX.` °s � ao d L i F "Do Not Open With Regular Mail" , ,r ' 7 "__ To: City Of Huntington Beach - 'I Office of the City Clerk I Second Floor 2000 Main Street Huntington Beach, CA 92648 _ .1 ,�t Bid Date: Tuesday July 26, 2011 @ 2:00 pm , , ,. _ . . - -- - - ,, :._ ,' _„ : <, , . „ _: �. , . - , J. , . . f a SECTION C PROPOSAL for the SEWER REHABILITATION PROJECT CC No. 1396 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 30 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 T r If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER,the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find BincEis Bo-jo in the amount of$ /o Z 4*W-76,owhich said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature C-2 e SECTION C PROJECT BID SCHEDULE INDEX SEWER REHABILITATION PROJECT CC NO. 1396 The three sewer line reaches are (I)Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac,-and (3) Cliff Drive,from Brookhurst Street to Spindrift Lane. PROJECT BASE BID: Basis of Award SEWER REHABILITATION PROJECT C-2.2 to C-2.3 BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: $ q°7,1-75 . o0 BASE BID WILL BE THE BASIS OF AWARD C-3 A BASIS OF AWARD PROJECT BID SEWED REHABILITATION CC NO. 1396 C-4 r ADDENDUM NO. 1- PROJECT DID SCHEDULE CC-1396 SEWER LINING did teii. eseri" fion: ::::::::::::::::::::::::::::::::::::::::::::: t3' �:� ..-.•.�l`I>�I[In�l'ric��:�:�•:�:�:�:;�xla,�anf:.:�:� .............................. 1 1 Mobil ization/Demobilization LS $ Z,Soo.00 $21 Soo.00 2 1 Furnish Traffic Control LS $ 1,200.0o $ 1,200,0 3 2545 Clean and inspect 8"sewer main LF $ 1.00 $215,45.0 4 2545 Install liner and post inspect 8"sewer main LF $,34.00 $8G,530•0 5 58 Grind and re-open sewer service lateral EA $ SO.00 $ 2,g 0o.o 6 1 Prepare Construction Traffic Control Plans LS $ 11 800.00 $ Soo.o0 Total Amount Bid in Figures: $ -7 S•00 :_ ___TotalAmountBidinWords: 11�jNdEB�{.SgveAl 7?40wfo-N4 SEVEN_N✓wa&"_-.._ SEVEN r PIG 00(/A14S 140 .Acors u !T C C-2.3 t i t PROJECT BID SCHEDULE CC-1396 SEWER LINING �E��SED �� p,op+�•� :::. sat :::: ::: xt>"�i:e.: =: := �te�: ..... .f.off.:::::::::::::::::::::::::::. : ::::::: <: +io:: aiaat `: :•:•:•>:::•:>: := :•:•:•:< .... rye.:•:••:<•:•:Amot><int: l Mobilization/Demobilization LS S 2 1 Traffic Control LS $ $ 3 2545 Clean and inspect 8"sewer main LF $ $ i 4 2545 Install liner and post inspect 8"se r main LF $ $ 5 58 Grind and re-open sew service lateral EA $ $ Total Amount Bid in Figures: $ Total Amount Bid in Words: I f LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class o Work Number CGEAN�ro4 i CCTV PE9F0 AVCC Pl EL/NE f ECNhfiG06/0-S 82-5 629 C-42. By submission of this proposal,the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-5 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of Orange THOMA's Lyo.J , being first duly sworn, deposes and says that he or she is Ass)sra„+r SEcacrAa�( of Re P,pe- rNc. the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Re P p e- CAC 1 t 02M'A , QnIC . Name of Bidder Signature of Bidder i KoN«s cyoN- ASsr. SFciecrA*y 652S E. <j e#LA C TAR ST. OAITAO 10 C A q/?(,t� Address of Bidder Subscribed and sworn to before me this 25 rA day of Suc , 201 NOTARY PUBLIC % NOTARY SEAL C-6 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 State of California County of j Oni, AW30 before me, O a 0�fAk 6 M[(-e Date Here /Insert tName and Title of the officer y"I personally appeared I Y l�Yv t�S o Name(p of gneroA , who proved to me on the basis of satisfactory evidence to be the person(,$') whose names) is/ye subscribed to the within instrument and acknowledged to me that he/stye/thdy executed the same in WONNE MCLELIAN his/hed/their authorized capacity(io), and that by Commission#1798268 his/h9t/thpfr signature($) on the instrument the Notary Public-California > person(, , or the entity upon behalf of which the San Bernardino County MV Comm.Exres May 16,2 2 person(sl acted, executed the instrument. 01 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: ��- q, 0,1 e (a_ Place Notary Seal Above OPTIONAL Signature of Notary Public Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: 1 Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Individual ❑ Individual ❑ Partner—❑Limited ❑General Top of thumb here ❑ Partner—❑ Limited ❑General Top of thumb here ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: ©2010 National Notary Association•NationalNotary.org•1-800-US NOTARY(1-800-876-6827) Item#5907 i UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL, CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract,known as the SEWER REHABILITATION PROJECT, (I)(we)(it)will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. R . P,pF— Contractor By —IVGfAAS Lyo,.l ASSt5TANT SECACTAPEY Title Date: 7-2S- II C-7 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury,the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ® Yes �No If the answer is yes, explain the circumstances in the space provided. hi 1/A Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-8 y COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. R� Plp�- G<►GtFo�-N�A� �N�. Contractor By j Ha--its Gyo�J ASSISTn,-Jt SfcoeETR0-Y Title Date: C-9 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: R� P(PE- CAG/P'oenttp 1/VC , Bidder Name SS2S E. G169-At rtaa STp-cer Business Address ON Ap-f 0 CA 9/76z/ City, State Zip ( 909 ) 291 -j(0 5 0 Telephone Number c9/y3o3 A State Contractor's License No. and Class le-31- 02- Original Date Issued /o - 31- l2. Expiration Date The work site was inspected by JOQGE ISELMAd of our office on 7- ZZ. , 2011. The following are persons, firms, and corporations having a principal interest in this proposal: Re P(pE- 4fA(-tt=o2nl1Aj INC. SEE RTr A CHE p 5EegG7T-A A-)(t5 CER-rtFICraT 1P C-10 The undersigned is prepared to satisfy the Council of the City.of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. tqe PtpE - CaGr,Fo&NIA , INC. Company Name Signature of Bidder TUOMAS i-V ed AssISTANT 56«STAQ Y Printed or Typed Signature Subscribed and sworn to before me this ZS'dday of su�-J , 2011 . NOTARY PUBLIC r� NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: # .$EE 4Ti A es4dV REFS &vcs ANb 10&,TEc? GisTS. 1. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 2. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed C-11 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§1189 c State of California County of G�► 1 ,l Y�Y V 1�'l�'`� �� On A (l", i'v i before me, , Date ( Inse Name and Title of the Officer personally appeared 1h..Here Nameto of SignerJsf who proved to me on the basis of satisfactory evidence to be the persono whose name(s) is/aI6 subscribed to the within instrument and acknowledged to me that he/sVe/thdy executed the same in his/4r/o6ir authorized capacity(irg), and that by YVONNE MCLELLAN his/hpdr/tVir signatureA on the instrument the Commission#1798268 person , County or the entity upon behalf of which the No tary Public-C 9 person( 'acted, executed the instrument. San Bernardino County r My Comm.Expires May 16.2012 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: /otll ,w tv, L/ Place Notary Seal Above Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Individual ❑ Individual ❑ Partner—❑Limited ❑General Top of thumb here ❑ Partner—❑Limited ❑General Top of thumb here ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: 0 2010 National Notary Association-NationaiNotary.org-1-800-US NOTARY(1-800-876-6827) Item#5907 STATE OF CALIFORNIA DEPARTMENT OF INSURANCE N4 07800 SAN FRANCISCO Amended Certificate of Authority THIS IS TO CERTIFY THAT,Pursuant to the insurance Code of the State of California, Arch Insurance Company Of Kansas City, Missouri organized under the laws of Missouri subject to its Articles of Incorporation or other fundamental organizational documents,is hereby authorized to transact within the State,subject to all provisions of this Certificate,the following classes of insurance: Fire, Marine, Surety, Disability, Liability, Workers' Compensation, Common Carrier Liability, Boiler and Machinery, Burglary, Team and Vehicle, and Automobile as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all,and not in violation of any,of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable,and as such laws and requirements now are,or may hereafter be changed or amended. IN.WITNESSWHEREOF,effective asofthe 15th day of December 2003 ,Ihavehereunto set my hand and caused my official seal to be affixed this 15th day Of December 2003 Joh G amPndi t Commissioner By tAsst a Z 1ef eputyNOTICE:Qualification with the Secretary of State must he accomplished as required by the Califoons Code promptly after issuance of this Certificate of Authority.Failure to do so will be a violation of Insurance Code Section 701 and will be grounds for revoking this Certificate of Authority pursuant to the convenants made in the application therefor and the conditions contained hereia VORM ce-3 gm OSP 00 3941 ARCH INSURANCE COMPANY STATEMENT OF FINANCIAL CONDITION December 31, 2010 Assets Cash in Banks $ 89,745,338 Bonds owned 1,055,658,067 Stocks 367,171,766 Premiums in course of collection 146,978,596 Accrued interest and other assets 268,448,878 Total Assets $ 1,928,002,645 Liabilities Reserve for losses and adjustment expenses $ 681,380,653 Reserve for unearned premiums 139,311,239 Ceded reinsurance premiums payable 92,726,263 Amounts withheld or retained by company for account of others 143,242,640 Reserve for taxes, expenses and other liabilities 255,558,983 Total Liabilities 1,312,219,778 Surplus as regards policyholders 615,782,867 Total Surplus and Liabilities $ 1,928,002,645 By: Attest: Senior Vice President, Chief rnd Vi President, Secretary Financial Officer and Treasurer en ral Counsel State of New York ) SS County of Nassau ) Thomas James Ahern and Martin John Nilsen, being duly sworn, say that they are Senior Vice President and Chief Financial Officer and Secretary, respectively, of ARCH INSURANCE COMPANY, Missouri; and that the foregoing is a true and correct statement of financial condition of said company, as of December 31, 2010. Subscribed and sworn to before me, this V4 day of March, 2011 Notary Public BRYAN D.KOHLBECKE R IC#2403903 NOTARY MM CF ,JMS£Y � �114ti�16 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE for the construction of SEWER REHABILITATION PROJECT CC No. 1396 July 18,2011 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: NEW BID SCHEDULE INCLUDE: 1. NEW Item No.6 "Prepare Construction Traffic Control Plans" ....1 LS 2. Revised Bid Item No.2 to Read"Furnish Traffic Control" SPECIFICATIONS REVISIONS TO INCLUDE: 1. Replace in Bid Documents Section 7-5 PERMITS on Pages E-11 and Section 7-10 PUBLIC CONVENIENCE on Pages E-15 with New Section 7-5 and 7-10 in Addendum No.1 2. A Caltrans Encroachment Permit Application pulled by Agency is attached to Addendum No. 1. Contractor must submit to Caltrans Water Pollution Control Provisions and Construction Traffic Control Plan for review and approval,along with the application for a rider to the Encroachment Permit. Bidders shall submit SECTION C with the most current revisions and bid schedule, Page C-2.3 "Addendum No. 1-Project Bid Schedule CC-1396 SEWER LINING". Award will be based on most current revised Bid Schedule and Specification revisions. This is to acknowledge receipt and review of Addendum Number 1, dated July 18,2011. REPipe- CAe-1b&N1A , OVel. - Company Name By 7H®A1As Lyo,i - AssesrA it SEX46-rA ty 7-2s-!! Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Joseph Fuentes at(714)536-5431. rePipe-Cafi6ornia, Inc, 5525 E. Gibraltar St. Ontario, CA 91764 ADDENDUM NO. 1- PROJECT BID SCHEDULE CC-1396 SEWER LINING .'.i:'.'.':':'.'.':' :'.':':':':'.'::':'.'::•:• '• I{- 8St?l' I P. ::: ::• ': : Ili #='rac 1 1 Mobilization/Demobilization LS $ 2 1 Furnish Traffic Control LS $ $ 3 2545 Clean and inspect 8"sewer main LF $ $ 4 2545 Install liner and post inspect 8"sewer main LF $ $ 5 58 Grind and re-open sewer service lateral EA $ $ 6 1 Prepare Construction Traffic Control Plans LS $ $ Total Amount Bid in Figures: $ Total Amount Bid in Words: } L C-2.3 j' 7-5 PERMITS [Delete the entire subsection and replace with the following:]. Prior to the start of any work, the Contractor shall take out the applicable AGENCY permits and make arrangements for AGENCY inspections. The AGENCY will issue the permits at no charge to the Contractor. The Contractor and all subcontractors shall each obtain an AGENCY business license, and shall be licensed in accordance with State Business and Professions Code. The Contractor, at no additional cost to the AGENCY, shall also obtain any and all other permits, licenses, inspections, certificates, or authorizations required by any governing body or entity. The contractor is responsible to manage the construction site in accordance with the city's National Pollutant Discharge Elimination System (NPDES) Permit and Municipal Code Chapter 14.25 - Stormwater and Urban Runoff Management ordinance. The purpose of the NPDES permit and ordinance is the improvement of water quality through the control of pollutants. Without exception, discharges of stormwater from a construction site into the storm drain system (gutter) or a receiving waterbody are prohibited if the discharge contains pollutants that have not been reduced to the maximum extent practicable through the implementation of BMPs. It is the contractor's responsibility to implement a combination of BMPs to control erosion and sediment transport, and pollutants from materials and waste management storage and activities. Full compensation for obtaining and conforming to the requirements of this section shall be included in other items of work and no additional compensation will be made therefore. No separate or additional compensation will be made for AGENCY permit and inspections, nor permits, licenses, inspections, certificates, or authorizations required by any other governing body or entity. The Contractor is hereby notified that specific construction practices in the Caltrans Standard Specifications, Section 7, "Responsibilities of the Contractor," are considered to be the Best Management Practices. Applicable construction practices in the Standard Specifications shall be incorporated into the WPCP. Additionally, the Contractor's work will be in compliance with the National Pollution Discharge Elimination System (NPDES) Permit for Storm Water Discharges for the State of California Department of Transportation (Caltrans) Properties, Facilities, and Activities, Order No.99-06-DWQ, CAS000003. Included within these specifications, for the Contractor's information, is a copy of the attachment to the Encroachment Permit (Water Pollution Control Provisions). An electronic copy of the Caltrans Storm Water Quality Handbook, Construction Contractor's Guide and Specifications Section 3, "Preparing a Water Pollution Control Program (WPCP)" can be found at http://Nvww.dot.ca.goy/hq/construe/stoi-inwater/SWPPP Prep Manual 3 03.pdf Prior to the start of any work within Caltrans right-of-way, the AGENCY will obtain a Caltrans Encroachment Permit for work in the State right-of-way(see Addendum No. 1). Application fee and site inspection costs, due at the time of application are estimated at $820. The Contractor, within seven (7) days of award of the contract, must submit to Caltrans a WPCP and a Constniction Traffic Control Plan for review and approval, along with the application for a rider to the Encroachment Permit at the following Caltrans office: ADDENDUM NO. I CC-1396 SPECIFICATION REVISION PAGE 1 of 6 CALTRANS DISTRICT 12 Mory Mohtashami,District Permit Engineer 3347 Michelson Drive, Suite 100 Irvine, CA 926 1 2-1 692 At the time of the pre-construction meeting the Contractor must have the WPCP and a Construction Traffic Control Plan completed and approved by Caltrans. The Contractor shall be responsible for conducting all required monitoring inspections and shall file copies of the inspections and all other reports, certifications or records as required by the WPCP with the lead agency. All fines levied as a result of the Contractor's failure to comply with the requirements of the Permit Rider and the WPCP, shall be the Contractor's responsibility. Time extensions will not be allowed for any suspension of work as a result of the Contractor's noncompliance with the Permit Rider or WPCP. 7-10 PUBLIC CONVENIENCE AND SAFETY 7-10.1 Traffic and Access [Add the following:]. All traffic control shall be in accordance with the latest edition of the following documentation: Caltrans Manual on Uniform Traffic Control Devices (M UTCD); Sign Specifications, Standard Plans, and Standard Specifications; American Public Works Association Southern California Chapter—Work Area Traffic Control Handbook. Within 30 calendar days after notification of award, the Contractor shall submit, for review and approval by the Engineer, a Traffic Control Plan. The Traffic Control Plan shall be signed and stamped by a civil engineer familiar with.the preparation of traffic control plans and licensed by the State of California. The plans shall incorporate, as a minimum, the following requirements of Section 7-10.3. Upon approval of the Traffic Control Plan by the City, approval of the Contractor's schedule by the City and execution of the Contract documents by both parties, the City will issue a Notice to Proceed specifying the Contract start date(first day of work). The Contractor shall provide, to the Engineer, a telephone number at which the Contractor's representatives can be reached, at any hour, should an emergency occur requiring replacement or relocation of the required traffic control devices. Prior to the start of construction, the Contractor shall inform the AGENCY's Police and hire departments of the project location, approximate starting date, completion date, and the name and telephone number of contractor representatives who may be contacted at any hour in the event of an emergency. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 2 of 6 POLICE DEPARTMENT: Watch Commander @ (714) 960-8809 FIRE DEPARTMENT: Battalion Chief/Development @ (714) 536-5411 Information signs shall be required on all arterial streets one week prior to beginning of roadway construction projects. The Contractor shall adhere to applicable sections of California Administrative Code, Title 8, concerning electrical and construction safety standards and practices. Contractor shall require that an approved safety vest be worn by all personnel who are working at this project site. Any worker without a vest may be ordered off the job by the Inspector until such apparel is acquired. Questions as to approved vests shall be directed to the Engineer. Any relocation of travel lanes longer than three calendar days shall be delineated by removing the existing striping and legends by wet sandblasting and placing new striping and legends as required. Upon completion of the work and the restoration of the road surface to its final condition, the Contractor shall remove temporary striping by wet sandblasting. If the traffic cones or portable delineators are damaged, displaced or are not in an upright position, for any reason, the contractor shall immediately replace or restore to their original location, in an upright position,the cones or portable delineators. The Contractor shall provide and maintain all signs, barricades, flashers, delineators and other 3 necessary facilities for the protection of the motoring public within the limits of the construction area. He shall also post proper signs to notify the public regarding detours and conditions of the roadway, all in accordance with the provisions of the Vehicle Code, the current State of California Department of Transportation "Manual of Traffic Controls for Construction and Maintenance Work Zones", and the State of California Department of Transportation Standard Plans and the current City of Huntington Beach Maintenance Work Traffic Control Manual. The Contractor shall furnish such flagmen and equipment as are necessary to give adequate warning to traffic or to the public of any dangerous conditions in accordance with the current Department of Transportation "Instructions to Flagmen". All existing traffic signs and street signs shall be maintained in visible locations during construction. Signs designated for removal shall be salvaged and delivered to the AGENCY Yard or disposed of as directed by the AGENCY. Warning Signs R Adequate warning signs for motorists shall be placed and maintained throughout all applicable phases of the work including speed limit reduction, loose gravel, fresh oil, and open trench. Signs shall be 36" X 36" in size; shall be on site ready for placement prior to start of the i applicable phase of work and shall be placed in advance on all streets approaching the work zone. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 3 of 6 " 7-10.3 Street Closures,Detours,Barricades [Add the following:]. Construction Traffic Control Plans shall be prepared in accordance with the AGENCY's latest Traffic Control Plaza Preparation Guidelines and shall be reviewed and approved by the Engineer. The Contractor shall submit the plans to the Engineer for approval or correction at Ieast 10 working days before approved plans will be required for commencing the work. IF MORE THAN ONE SEGMENT ADD: Separate traffic control plans shall be prepared for each segment and each stage of the work, The Construction Traffic Control Plans (CTCP) shall be prepared under the supervision of a registered professional. Civil. Engineer licensed to practice in the State of California. Each sheet of the CTCP shall have the name, address, and telephone number of the engineer or engineering firm that prepared -lie CTCP, and the professional engineer's stamp and expiration date, and the professional engineer's signature and signature date. Approval of the plans by the .Engineer shall riot relieve the Contractor from the responsibility for errors or omissions in the plans or from deviations -om the Contract Documents. This traffic control plan shall provide pedestrian access throughout the construction area. The appropriate signing,barricades, etc.,shall be included on the plan. This pedestrian access shall comply with the accessibility requirements contained within the American with Disabilities Act(ADA). The contractor shall install a barricade mounted 18" x 36" C42 sign "SIDEWALK CLOSED CROSS HERE" at the nearest crossings leading to the closure when the sidewalk width is reduced to less than 36"or at the discretion of the Engineer. The Contractor shall be responsible for the correctness of the plans and for the results obtained by the use of such plans. Full compensation for Construction Traffic Control Plan and furnishing Traffic Control shall be paid for on a Iunip sum bid price under each of their respective lump sum bid items and no additional compensation will be allowed therefor. Street closures will not be allowed except as permitted by the Engineer. The following rninirnuin lane requirements shall be provided at all times, subject to time of day restrictions as established by Section 6-7.2 and this Section. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 4 of 6 Arterials All lane closures are restricted to the hours of 9:00 AM to 3:00 PM,Monday through Friday. Beach Blvd.: All project work on Beach Boulevard: The Contractor shall construct this project per the approved Traffic Control Plan. Lane closure shall be restricted to no more than 4 total working days; if working days are sequential, the lane closure must be removed by 3:00 PM every day. The Contractor shall coordinate all work with the Caltrans and Agency Inspector. A copy of the Caltrans Encroachment Permit is in Addendum of these specifications. Beach Blvd. at Edinger Ave.: Maintain 2 southbound right turn lanes, 2 southbound through lanes, and 2 left southbound lanes at all times. No other lane closures will be allowed on Beach Blvd. Edinger Ave. at Beach Blvd.: Maintain 2 eastbound left turn lanes and 1. eastbound through lane at all times. No other lane closures will be allowed on Edinger Ave. Beach Blvd. at Aldrich Ave.: Maintain 2 southbound through lanes and ttivo southbound left turn lanes at all times. No northbound closures will be allowed on Beach Blvd. Aldrich Ave. at :Beach. Blvd.: Maintain 1 through late in each direction at all times. No northbound closures will be allowed on Beach Blvd. Beach Blvd. at Stark Ave.: Maintain 2 southbound through lanes at all times. No northbound closures will be allowed on Beach Blvd, Stark Ave. at Beach Blvd.: Maintain 1 through late in each direction at all times. No northbound closures will be allowed on Beach Blvd. Local Streets fall streets not identified above as arterials) Maintain one two-way travel lane with flagger control. 7-10.5 ]Protection of the Public [Add Subsection in total and replace with the following:]. It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor shall use foresight and shall take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the work which will require that immediate and unusual provisions be made to protect the public from danger or loss, or damage to life and property, due directly or indirectly to prosecution of work under this contract. ADDENDUM NO. I CC-1396 SPECIFICATION REVISION PAGE 5 of 6 Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer, immediate action shall be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation, the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as may be necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, shall be borne by the Contractor. All expenses incurred by the AGENCY for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. However, if the AGENCY does not take such remedial measures,the Contractor is not relieved of the full responsibility for public safety. ADDENDUM NO. 1 CC-1396 SPECIFICATION REVISION PAGE 6 of 6 Page I of 4 4AT:-OFCALIFORNIA-DEPARTMENTOFTPANSPORTATION C T T �.._F R: INDARD ENCROACHMENT PERMIT APPLICATION 0 Z7LTF"s..5sF77= -0 (REV.0712007) -PERMIT NO. fto Pernission is requested to encroach on the State Highway right-of-way as follows: /DIST/CO/RTE!PM>_- (COmplete,.all 80)(ES.(write NIA if not applicable]) This application is not complete until all requirements have been approved. SIMPLEX STAMP 1.COUhrl7Y 2.ROUTE 3,POSTMILE ORA 39 5.63 12 6 4.ADDRESS OR STREET NAME S.CITY Edinger Ave Huntington Beach 6.CROSS STREET(Distance and direction from site) 7.PORTION OF RIGHT-OF-WAY DATE OF SIMPLEX STAMP Beach Boulevard Pavement L, 8.WORK TO BE PERFORMED BY 9.EST.START DATE 10.EST.COMPLETION DATE El OWN FORCES 0 CONTRACTOR September 26, 2011 October 28, 2011 11. MAX.DEPTH JAVG.DEPTH AVG.WIDTH LENGTH SURFACE TYPE EXCAVATION NA NA NA NA Pavement 12.EST.COSTIN STATE HIGHWAY RIGHT-OF-WAY FUNDING SOURCE(S) N/A [:]FEDERAL ❑STATE LOCAL ❑ PRIVATE 13. ER VOLTAGE/PSJG PROJECT E.A.NUM13ER PIPE [14 PIPES PRODUCT TYPE 14.CALTRANS FxIsnNdvcP DIAMETER 0PP OR PVC SEWER LINER IN N/A N/A 15. 0 Double Permit Parent Permit Number Applicant's Reference Number/ Utility Work Order Number CC-1 396;Sewer Rehabilitption 16. Have your plans been reviewed by another Caltrans branch? 91 NO E] YES (If"YES") Who? 17. Completely describe work to be done within STATE highway right-of-way Attach 6 complete sets of FOLDED plans(folded 8.5"x 1 V),and any applicable specifications,calculations,maps,etc. All dimensions shall be in U.S.Customary(English)Units. The sewer line reach of approximately 870 feet begins from manhole at Southwesterly intersection of Beach Blvd. and Edinger Avenue'to the manhole at intersectoin of Beach Blvd. and Stark Avenue, The result of sewer lining will require traffic control within Caltrans Right-of-Way. Traffic Control Plan will be submitted by Contractor. 18.Is a city, county, or other agency Involved In the approval of this project? Rl YES (If"M,check"a of-project and attach environmental documentation and conditions of approval.) 0 COMMERCIAL DEVELOPMENT 0 BUILDING DGRADING OOTHER OCATEGORICALLYEXEMPT [I NEGATIVE DECLARATION ❑ENVIRONMENTAL IMPACT REPORT E]OTHER [I NO (1i"NO',please check the category below which best describes the proje&-4 and complete page 4 of this application) [3 DRIVEWAY OR ROAD APPROACH,RECONSTRUCTION,MAINTENANCE,OR RESURFACING ❑ FENCE El PUBLIC UTILITY MODIFICATIONS,EXTENSION$,HOOKUPS ❑ MAILBOX [3FLAGS,SIGNS,BANNERS,DECORATION$,PARADES AND CELEBRATIONS [3EROSION CONTROL OOTHER [3 LANDSCAPING IS.Will this project cause a substantial change in the significance of a historical resource(45 years or older),or cultural resource? []YES NO (if"YES",provide a description) 20.Is this project on an existing highway or street where the activity involves removal of a scenic resource including a significant tree or stand of trees,a rock outcropping or a historic building?❑ YES m NO (If"YES',provide a description) 21.Is work being done on applicants property? ❑ YES NO (if-YES",attach site and grading plans.) ADA NOTICE:For individuals with sensory disabilities,this document is available in alternate formats.For information call(916)654-6410 or TDD(916)654-3880 or write to Records and Forms Management,1120 N Street,MS-89,Sacramento,CA 95814 ... ......... STATE OF CALIFORNIA-DEPARTMENTOFTRANSPORTATION Page 2 of 4 STANDARD ENCROACHMENT PERMIT APPLICATION pERMITNO. TR-0100 (REV.0712007) 22.Will this proposed project require the disturbance of soil? [:]YES ®NO if"YES",estimate the area i hi State Highway right-of-way in square feel AND acres: �� 9 Y 9 Y q (ft=)AND (acres) i estimate the area outside of State Highway right-of-way in square feet AND acres: (W)AND (acres) 23.Will this proposed project require dewatering? iJ YES ©NO If"YES',estimate total gallons AND gallons/month- (gallons)AND (gallonstmonth) I SOURCE': E]STORMWATER NON-STORM WATER ('See Caltrans SWMP for definitions of non-storm water discharge: http:/Iwww.dot.ca.gov/hq/env/stormwaterlindex.htrn) 24.How will any storm water or groundwater be disposed of from within or near the limits of this proposed project? ®Storm Drain System Combined Sewer I Storm System F1 Storm Water Retention Basin ❑Other(explain): PLEASE READ THE FOLLO WING CLAUSES PRIOR TO SIGNING THIS ENCROACH MENTPERMITAPPLICATION. The applicant, understands and herein agrees to that an encroachment permit can be denied,and/or a bond requiredfornon-paymentofpriororpresent encroachmentpermit fees.EncroachmentPermit fees maystillbe due when an application is withdrawn or denied,and that a denial may be appealed,in accordance with the California Streets and Highways Code,Section 671.5.All workshall be done in accordance with Caltrans rules and regulations subject to inspection and approval. The applicant,understands and herein agrees to the general provisions,special provisions andconditions ofthe encroachmentpermit,and to indemnifyand holdharmless the State,its officers,directors,agents,employees and each of them(lndemnitees)from and againstanyand all claims,demands,causes ofaction,damages,costs, expenses,actual attorneys'fees,judgments,losses and liabilities ofeverykind andnature whatsoever(Claims) arising outoforin connection with the issuance and/oruse ofthis encroachmentpermitand the placementand subsequent operation and maintenance of said encroachment for. 1)bodily injury and/or death to persons including but not limited to the Applicant, the State and its officers, directors, agents and employees, the Indemnities,and the public;and2)damage to property ofanyone.Exceptas provided bylaw,the indemnification provisions statedaboveshallapply regardless ofthe existence ordegreeoffaultoflndemnities. The Applicant, however,shall notbe obligated to indemnifylndemnities for Claims arising from the sole negligence and willful misconduct of State,its officers,directors,agents or employees. DISCHARGES OFSTORM WATER AND NON-STORM WATER:Work within State Highwayright-of-wayshall be conducted in compliance with all applicable requirements of the National Pollutant Discharge Elimination System(NPDES)permitissued to the DepartmentofTransportation(Department),to govern the discharge ofstorm waterandnon-storm waterfrom its properties.Work shallalso be in compliance with all otherapplicable Federal, State and Locallaws and regulations,and with theDepartmenf's Encroachment Permits Manualand encroachment permit.Compliance with the Departments NPDES permit requires amongst other things,the preparation and submission ofa Storm WaterPollution Protection Plan(SWPPP),ora Water Pollution Control Program(WPCP), and the approval ofsame by the appropriate reviewing authority prior to the start of any work.Information on the requirements mayalso be reviewed on the Department's Construction Website at: http.*Ilwww.dot.ca.govlhqlconstruclstormwaterlstorrnwaterl.htm 25,NAME of APPLICANT or ORGANIZATION (PrinforType) E-MAILADDRESS City of Huntington Beach jwagner@surfcity-hb.org ADDRESS of APPLICANT or ORGANIZATION WHERE PERMIT IS TO BE MAILED (Include City and Zip Code) Public Works, 2000 Main Street, Huntington Beach, CA 92648 PHONE NUMBER FAX NUMBER 714-536-5431 714-374-1573 26.NAME of AUTHORIZED AGENT 1 ENGINEER(Print or Type) IS LETTER OF AUTHORIZATION -MAILADDRESS Joseph Fuentes p YES ® No Same as above ADDRESS of AUTHORIZED AGENT/ENGINEER(include City and Zip Code) same as above PHONE NUMBER FAX NUMBER 714-536-5259 same as above 27. 30. A'T Fuentes Civil EnglnceringAssistant STATE OF CALIFORNIA•DEPARTMENTOFTRANSPORTATION Page 3 of 4 STANDARD ENCROACHMENT PERMIT APPLICATION PERMITNO. TR-010 (REV.07l2007) WORK ORDERIREFERENCE:NUMBER FEE CALCULATION -- FOR CALTRANS USE ❑ CASH ❑ CREDITCARD NAME ON CARD PHONENUMBER ❑ CHECK NUMBER NAMEONCHECK PHONENUMBER ❑ ECEMPT ❑ PROJECT EA _—`___ ❑ DEFERRED BILLING(UGlity) CALCULATED BY (1) (2) REVIEW 1.FEE i DEPOSIT DATE 2.FEE 1 DEPOSIT DATE TOTAL FEE I DEPOSIT 1. HOURS @ $ $ $ 2. HOURS @ $ $ $ INSPECTION 1.FEE!DEPOSIT DATE 2.FEE!DEPOSIT DATE TOTAL FEE I DEPOSIT 1. HOURS @ $ $ $ 2. HOURS @ $ $ $ FIELDWORK HOURS @ $ $ $ $ DEPOSIT DATE DEPOSIT DATE DEPOSIT EQUIPMENT&MATERIALS CASH DEPOSIT IN LIEU OF BOND $ $ $ TOTAL COLLECTED $ $ CASHIER'S INITIALS $ 'The current hourly rate is set annually by Headquarters Accounting. District Office staff do not have authority to modify this rate. PERFORMANCEBOND ❑ DATE MOUNT DATE AMOUNT PAYMENTSOND ❑ $ AMOUNT LIABILITY INSURANCE REQUIRED? ❑ YES NO $ STATE OF CALIFORNIA-DEPARTMENT OFTRANSPORTATION Page 4 of 4 STANDARD ENCROACHMENT PERMIT APPLICATION IT NO. TR-0100 (REV.07/2007) INSTRUCTIONS for completing page 4 This page needs to be completed when the proposed project DOES NOT involve a City,County or other public agency. Your answers to these questions will assist departmental staff in identifying any physical,biological,social oreconomic resources that maybe affected by your proposed projectwithin the State highway right-of-way.And,to determine which type of environmental studies maybe required to approve yourapplication foran encroachment permit. It is the applicants responsibility forthe production of all required environmental documentation and supporting studies,in some cases this maybe costly and time-consuming.If possible,attach photographs of the location of the proposed project Please answer these questions to the best of your ability.Provide a description of any"YES"answers(type,name,number,etc.) 1. Will any existing vegetation and/or landscaping within the highway right-of-way be disturbed? 2. Are there waterways (e.g. river, creek, pond, natural pool or dry streambed) adjacent to or within the limits of the project or highway right-of-way? 3. Is the proposed project located within five miles of the coast line? 4. Will the proposed project generate construction noise levels greater than 86 dBA (e.g. jack-hammering, pile driving)? 5. Will the proposed project incorporate land from a public park, recreation area or wildlife refuge open to the public? 6. Are there any recreational trails or paths within the limits of the proposed project or highway right-of-way? 7. Will the proposed project impact any structures, buildings, rail lines, or bridges within highway right-of-way? 8. Will the proposed project impact access to any businesses or residences? 9. Will the proposed project impact any existing public utilities or public services? 10. Will the proposed project impact existing pedestrian facilities, such as sidewalks, crosswalks, or overcrossings? 11. Will new lighting be constructed within or adjacent to highway right-of-way? i I I t 1 i I' t' l t i SECRETARY'S CERTIFICATE OF REPIPE CALIFORNIA,INC. (the "Company") The undersigned hereby certifies, on behalf of the Company, as follows: 1. He is the duly elected and qualified Assistant Secretary of the Company. 2. The following individuals are the duly elected and qualified officers of the Company, ( each an "Officer," and collectively the "Officers") elected by the Board of Directors of the Company on October 28, 2010, occupying the positions set forth next to their respective names below: Name Office Joe Cutillo President& Chief Executive Officer Dave Hiemstra Chief Financial Officer, Secretary/Treasurer Michael Vellano Vice President Mark Neumann Vice President Craig Strawbridge Corporate Controller,Assistant Secretary Thomas Lyon Assistant Secretary 3. Each of the Officers is duly authorized, on behalf of the Company, to bid upon and enter into any competitive contract (each a"Bid" and collectively the `Bids") related to the Company's business, and is hereby authorized, on behalf of the Company, to execute and deliver any contracts, agreements or documents required in connection with any such Bid (such authority conferred on the Officers the Board of Directors of the Company effective October 28,2010). 0611se It: BECKY JEAN WALDRON Notary f ublie.,$We of Texas Craig Strawbridge, Assista Secretary Ei'res Dated: January 3, 2011 INQ 1972464,1 '"REPIRE Truncated Reference List Name and Address of Owner Project Name Pipe Size Lengths Liner System Completed City of Los Angeles Various ASRP Projects 8,10,12,15,18 276,531 National Liner CIPP 2003-7 1149 S.Broadway SSRP S02A&S02B 8,10 21,486 National Liner CIPP 2007 Los Angeles,CA 90014 SSRP C04A Rose Ave 8,10,12 4,665 National Liner CIPP 2008 Contact:Iftekhar Ahmed SSRP U04A Beverlywood 8 9,053 National Liner CIPP 2008 Phone:(213)485-5875 SSRP H27B Melrose Ave 8,10,12 1,287 National Liner CIPP 2008 CSRP Harbor Area Unit 4 8 7,055 National Liner CIPP 2008 SSRP H01 Olympic Blvd 8,10 13,247 National Liner CIPP 2008 SSRP H28A Willow Glen 8 8,818, National Liner CIPP 2008 SSRP H28B Franklin 8,10 8,168 National Liner CIPP 2008 SSRP H28C Sunset 8,10,12,15 10,011 National Liner CIPP 2008 SSRP S09 Imerial Hwy 8,10,12 20,119 National Liner CIPP 2008 SSRP H32A Canyon&Spring 8 4,913 National Liner CIPP 2008 SSRP H29A Laurel&Mulholland 8 13,691 National Liner CIPP 2008 SSRP U19A Rochester Ave 8 18,997 National Liner CIPP 2009 SSRP U18B Verteran Ave 8,10 11,075 National Liner CIPP 2009 SSRP U18A Roscomare Rd 8 16,410 National Liner CIPP 2009 SSRP U 24 Robertson Blvd 8,12 7,887 National Liner CIPP 2010 _ Total Footage Installed 453,413 LA County Sanitation Dist South Park Trunk Swr. 18 713 Novapipe CIPP 2003 1755 Workman Mill Road Artesia Blvd.Trunk Swr. 18 332 Novapipe CIPP 2003 Whittier,CA 90601 Joint Outfall"C"Unit 3F 18 490 Masterliner CIPP 2005 Contact:Rich Julio District 29 Phase II 8,10,12 6,572 Masterliner CIPP 2006 Phone: (562)699-7411 ext.1607 Storm Drain Rehab at WW Plant 18 540 Masterliner CIPP 2006 Belvedere Trunk Sewer 10,12,15 864 Masterliner CIPP 2006 Lincoln Ave Trunk Sewer 8 1,305 Masterliner CIPP 2006 Western Ave Trunk Sewer 10 3,180 Masterliner CIPP 2006 Inglewood Trunk Sewer 8,10,12,15,18 22,443 National Liner CIPP 2007 _ Total Footage Installed 36,439 City of Moses Lake Sewer Lining Project 2006 8,10,12 30,829 National Liner CIPP 2006 321 South Balsam St Sewer Lining Project 2008 8 37,300 Ribloc EX 2008 Moses Lake,WA 98837 Contact:Shawn O'Brian Phone:(509)766-9217 Total Footage Installed 68,129 Goleta West Sanitary District Phase II Sewer Rehab. 6 7,719 Novapipe CIPP 2004 P.O.Box 4 Phase II Sewer Rehab. 6,8,10,12,15 10,413 Ribloc EX 2004 Goleta,CA 93116 Phase III Sewer Rehab. 6 5,212 Masterliner CIPP 2005 Contact:Mark Nation Phase III Sewer Rehab. 6,8,10 12,993 Ribloc EX 2005 Phone:(805)968-2617 Phase IV Sewer Rehab 6,8,10,12,15,18 22,053 National Liner CIPP 2010 Total Footage Installed 58,390 City of Burbank City of Burbank Sewer Rehab 8,12 36,955 Ribloc EX 2001 275 East Olive Ave Phase 6-Rehab of EQ Damaged Sewer 8,10 3,560 Ribloc EX 2002 Burbank,CA 91510 Sanitary Sewer Hazard Mitigation Prig. 8,10 4,060 Ribloc EX -2004 Contact:Matt Rutowski Phone:(818)238-3930 _ Total Footage Installed 44,575 _ LA County Dept.of Public Works Kern Ave. 8 6,345 Ribloc EX 2000 900 S.Fremont Ave. Ford Ave. 8 6,677 Ribloc EX 2000 Alhambra,CA 91803 Poplar Place 8,12 15,601 Ribloc EX 2001 Contact:Keith Lehto 89th Street 8 17,268 Ribloc EX 2001 Phone:(626)300-3304 Lanfranco St. 8 10,398 Ribloc EX 2002 Contact:Harry Cong 101th St. 8 8,018 Ribloc EX 2002 Phone:(626)458-3157 Triggs St. 8 9,577 Ribloc EX .2003 Service St 8 17,208 Ribloc EX 2003 Herbert Ave. 8 14,218 Ribloc EX 2004 Arizona Ave. 8 17,658 Ribloc EX 2004 Walnut Drive 8 12,199 Ribloc EX 2005 Los Angeles River Side Inlets 12,18,21,24,27,30,36 3,467 National Liner CIPP 2006 First Street 8 16,862 Ribloc EX 2007 Flower Street 8 8,069 Ribloc EX 2007 Hammel Street 8 9,970 Ribloc EX 2007 McBride Street 8 15,846 Ribloc EX 2007 Marina Del Rey 8,10,12,15,18 17,242 Ribloc EX 2008 Michigan Ave 8 15,197 Ribloc EX 2008 Clela Ave 8 14,203 Ribloc EX 2008 Olympic Ave 8,10 9,368 Ribloc EX 2008 CDR Phase 1C 12,15,18,21,24,36 9,092 National Liner CIPP 2008 Amalia Ave 8,10 10,277 Ribloc EX 2008 Fisher Street 8 13,200 Ribloc EX 2009 Dozier Street 8 23,461 Ribloc EX 2009 CDR 438 Phase II 18,21,24,27,30 2,265 National Liner CIPP 2009 _ Total Footage Installed 303,686 City of San Diego Wastewater Div. Sewer Group 90 6,8 5,891 Ribloc EX 2003 Contact:Jon Cady ROW&Easement Phase B 8,10 40,215 Ribloc EX 2004 Phone:(619)482-2076 ROW&Easement Phase C 6,8 61,052 Ribloc EX 2006 Contact:Margaret Llagas ROW&Easement Phase F 8 44439 Ribloc EX 2009 Phone:(858)654-4494 Total Footage Installed 151,597 _ rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner LA County Sanitation Dist South Park Trunk Swr. CIPP 18 713 $98,261 2003 LA County Sanitation Dist Artesia Blvd.Trunk Swr. 18 332 $53,995 2003 1755 Workman Mill Road Whittier,CA 90601 Contact:Margott Hinostroza Phone: (562)699-7411 ext.6811 City of Santa Monica Ocean Ave&Main St CIPP 30 1,337 $436,508 2003 City of Santa Monica 33 367 1685 Main Street 39 696 Santa Monica,Ca 90401 Contact:Eugenia Chusid Phone:(310)434-2618 City of Los Angeles ASRP Unit 314&315 CIPP 8 13,220 $897,259 2003 City of Los Angeles 1149 S. Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 369&373 CIPP 8 12,861 $461,715 2004 City of Los Angeles 10 282 1149 S. Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of San Diego Sewer Rehab Phase B Ribloc 8 39,685 $895,588 2004 City of San Diego 10 876 9192 Topaz Way San Diego,CA 92123 Contact:Craig Whittimore Phone:(858)292-6471 City of Chula Vista CMP Rehab.(DR-163) CIPP 24 463 $136,700 2004 City of Chula Vista 30 83 276 Fourth Avenue Chula Vista,CA Contact:Cesar Magbuhat Phone:(619)397-6114 City of San Bernardino 'E"Street Rehabilitation CIPP 8 750 $95,200 2004 City of San Bernardino 10 1,300 300 North"D"Street San Bernardino,CA 92418 Contact:Al Pagani Phone:(909)384-5167 City of Upland City Wide Trenchless No.8661 CIPP 8 11,506 $296,369 2004 City of Upland 1370 N.Benson Avenue Upland,CA 91786 Contact:Eddie Rhee Phone:(909)931-4273 Goleta West Sanitary District Phase 11 Sewer Rehab. CIPP 6 5,642 $214,326 2004 Goleta West Sanitary District 8 1,848 P.O.Box Goleta,CA 93116 Contact:Mark Nation Phone:(805)968-2617 LA County Dept.of Public Works Herbert Ave Ribloc 8 14,218 $366,585 2004 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 1 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles ASRP Unit 299&300 CIPP 8 6,960 $418,805 2005 City of Los Angeles + 12 304 1149 S.Broadway 15 817 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 283&340 CIPP 8 8,006 $296,102 2005 City of Los Angeles 10 391 1149 S.Broadway 12 306 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Bell Sanitary Sewer Rehab FY 04-05 CIPP 8 1,424 $50,102 2005 City of Bell 10 183 6330 Pine Ave Bell,CA 90201 LA County Dept.of Public Works Arizona Ave Ribloc 8 17,658 $466,959 2005 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Los Angeles ASRP Unit 291&292&295 CIPP 8 14,054 $446,314 2005 City of Los Angeles 15 385 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 293&294 CIPP 8 12,476 $382,209 2005 City of Los Angeles 10 219 1149 S.Broadway 15 111 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Sanitation Dist Joint Outfall"C"Unit 3F CIPP 18 456 $75,570 2005 LA County Sanitation Dist 1755 Workman Mill Road Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611 City of Los Angeles N.E.Wilshire Area Swr. CIPP 16 319 $936,318 2005 City of Los Angeles 20 385 650 S.Spring Street 22 775 Los Angeles,CA 90012 Contact:Kevin Schrock Phone:(213)847-8910 LA County Dept.of Public Works Walnut Street Ribloc 8 12,199 $335,000 2005 LA County Dept.of Public Works 900 S. Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Los Angeles ASRP Unit 354 CIPP 8 2,943 $292,660 2005 City of Los Angeles 10 226 1149 S.Broadway 30 142 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 2 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles ASRP Unit 316&320 CIPP 8 26,580 $1,383,930 2005 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 338039 CIPP 8 4,843 $340,444 2005 City of Los Angeles 10 2,636 1149 S.Broadway 12 927 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Bell Sanitary Sewer Rehab FY 04-05 CIPP 8 7,971 $238,774 2005 City of Bell No.32-525-7007-0925 6330 Pine Ave Bell,CA 90201 Contact:Carlos Alvarado Phone:(323)588-6211 Goleta West Sanitary District Phase III Sewer Rehab. CIPP 6 5,212 $762,139 2005 Goleta West Sanitary District Ribloc 8 2,925 P.O.Box 10 1,135 Goleta,CA 93116 Contact:Mark Nation Phone:(805)968-2617 City of Los Angeles ASRP Unit 296004 CIPP 8 17,200 $713,201 2005 City of Los Angeles 27 367 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Whiteside Street Ribloc 8 4,742 $324,805 2006 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Torrance Downtown Sewer Rehab CIPP 6 2,900 $656,677 2006 City of Torrance 8 3,900 3031 Torrance Blvd. 10 265 Torrance,CA 90503 12 1,700 Contact:Sandy Cohen 14 420 Phone:(310)618-3057 City of Los Angeles ASRP Unit 334&335 CIPP 8 11,500 $588,150 2006 City of Los Angeles 10 546 1149 S.Broadway 16 795 Los Angeles,CA 90014 18 272 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 305 CIPP 8 8,300 $263,712 2006 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 306&307 CIPP 8 21,686 $673,485 2006 City of Los Angeles 10 326 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 3 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles Lincoln Blvd.and 83rd Street CIPP 8 1,820 $75,000 2006 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Concord Sewer Rehabilitation Phase II Ribloc 21 4,181 $2,475,369 2006 LA County Sanitation Dist 24 867 1755 Workman Mill Road 27 2,369 Whittier,CA 90601 30 1,718 Contact:Mike Tatalovich Phone: (310)638-1611 LA County Sanitation Dist District 29 Phase II CIPP 8 5,850 $399,310 2006 LA County Sanitation Dist 10 148 1755 Workman Mill Road 12 574 Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611 LA County Sanitation Dist Storm Drain Rehab at WW Plant CIPP 18 540 $62,910 2006 LA County Sanitation Dist 1755 Workman Mill Road Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611 LA County Dept.of Public Works First Street Ribloc 8 16,862 $435,441 2006 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Los Angeles ASRP Unit 308010 CIPP 8 18,000 $556,343 2006 City of Los Angeles 12 349 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Flower Street Ribloc 8 8,069 $211,741 2006 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 LA County Sanitation Dist Belvedere Trunk Sewer CIPP 10 284 $79,880 2006 LA County Sanitation Dist 12 280 1755 Workman Mill Road 15 300 Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611. LA County Sanitation Dist Lincoln Ave Trunk Sewer CIPP 8 1,305 $77,295 2006 LA County Sanitation Dist 1755 Workman Mill Road Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611 City of San Diego Sewer Rehab Phase F Ribloc 8 61,052 $1,414,634 2006 City of San Diego 9192 Topaz Way San Diego,CA 92123 Contact:Craig Whittimore Phone:(858)292-6471 4 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles ASRP Unit 333&374 CIPP 8 12,161 $454,578 2006 City of Los Angeles 10 1,665 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Hammel Street Ribloc 8 9,970 $213,090 2007 LA County Dept.of Public Works 900 S. Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 LA County Sanitation Dist Western Ave Trunk Sewer CIPP 10 3,180 $262,133 2007 LA County Sanitation Dist 1755 Workman Mill Road Whittier,CA 90601 Contact:Mike Tatalovich Phone: (310)638-1611 City of Los Angeles ASRP Unit 309&311 CIPP 8 11,908 $388,974 2007 City of Los Angeles 12 289 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Los Angeles River Side Inlets CIPP 10 125 $705,372 2007 LA County Dept.of Public Works 12 799 900 S.Fremont Ave 15 50 Alhambra,CA 91803 18 887 Contact:Harout Kassabian 21 141 Phone:(626)458-4967 24 646 27 46 30 349 36 424 City of Moses Lake Sewer Lining Project 2006 CIPP 8 27,473 $612,260 2007 City of Moses Lake 10 2,490 321 South Balsam St 12 832 Moses Lake,WA 98837 Contact:Shawn O'Brian Phone:(509)766-9217 LA County Dept.of Public Works McBride Street Ribloc 8 15,846 $382,840 2007 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Concord Phase II Rehabilitation CIPP 27 1,765 $1,343,289 2007 City of Concord 30 2,141 1950 Parkside Drive 33 3,265 Concord,CA 94519 Contact:Qumar Kahn Phone:(925)671-3231 -----_----wkn-g---------===-----------------------------------a--------------------------------------------------------------------------------------------------------------------------------- City of Los Angeles ASRP Unit 336&337 CIPP 8 7,061 $667,223 2007 City of Los Angeles 10 541 1149 S.Broadway 12 3,897 Los Angeles,CA 90014 15 864 Contact:Iftekhar Ahmed 16 790 Phone:(213)485-5875 5 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles ASRP Unit 357 CIPP 8 5,507 $236,827 2007 City of Los Angeles 10 659 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Bell Sanitary Sewer Rehab FY 06-07 CIPP 8 3,092 $77,749 2007 City of Bell 6330 Pine Ave Bell,CA 90201 Contact:Carlos Alvarado Phone:(323)588-6211 City of Los Angeles ASRP Unit 312013 CIPP 8 18,507 $655,847 2007 City of Los Angeles 10 834 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Sanitation Dist Inglewood Trunk Sewer Rehab. CIPP 8 8,360 $1,898,983 2007 LA County Sanitation Dist 10 3,778 1755 Workman Mill Road 12 5,306 Whittier,CA 90601 15 3,461 Contact:Rich Julio 18 1,538 Phone:(562)699-7411 ext.1607 City of Los Angeles ASRP Unit 286&287 CIPP 8 10,821 $372,713 2007 City of Los Angeles 10 284 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles ASRP Unit 288&297 CIPP 8 14,796 $541,830 2007 City of Los Angeles 10 1,243 1149 S. Broadway 12 272 Los Angeles,CA 90014 15 396 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP S02A&S02B CIPP 8 20,690 $669,830 2007 City of Los Angeles 10 796 1149 S. Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Covina Sewer Rehab.Phase I S-0615 CIPP 8 5,105 $149,670 2007 City of Covina 10 270 125 E.College Street Covina,CA 91723 Contact: Phone:(626)858-7251 LA County Dept.of Public Works Los Cerritos/CDR 235 CIPP 18 1,115 $408,816 2007 LA County Dept.of Public Works 24 419 900 S.Fremont St 30 387 Alhambra,CA 91803 54 224 Contact:Norm Cortez Phone:(626)300-3388 LA County Dept.of Public Works Marina Del Rey Ribloc 8 7,246 $1,064,010 2007 LA County Dept.of Public Works 10 2,171 900 S.Fremont St 12 3,092 Alhambra,CA 91803 15 2,770 Contact:Norm Cortez 18 1,963 Phone:(626)300-3388 6 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles Harbor Area CSRP Unit 4 CIPP 8 6,500 $226,600 2007 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works CDR 146 CIPP 18 142 $183,313 2007 LA County Dept.of Public Works 21 136 900 S.Fremont St 24 179 Alhambra,CA 91803 30 67 Contact:Norm Cortez 36 375 Phone:(626)300-3388 City of Pasadena Green Street Ribloc 8 6,700 $422,075 2007 City of Pasadena 12 3,800 100 N.Garfield Ave Pasadena,CA 91109 Contact:Yannie Wu Phone:(626)744-3762 LA County Dept.of Public Works CDR 232 CIPP 16 124 $408,306 2007 LA County Dept.of Public Works 18 1,539 900 S.Fremont St 21 328 Alhambra,CA 91803 24 247 Contact:Norm Cortez 30 92 Phone:(626)300-3388 36 301 LA County Dept.of Public Works CDR 241 &CDR 445 CIPP 21 80 $156,984 2007 LA County Dept.of Public Works 24 324 900 S.Fremont St 36 340 Alhambra,CA 91803 Contact:Norm Cortez Phone:(626)300-3388 City of Los Angeles San Pedro CSRP CIPP 8 8,190 $429,894 2007 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Michigan Ave Ribloc 8 15,197 $490,939 2007 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Fullerton Sewer Lining 2007 CIPP 8 15,000 $733,324 2007 City of Fullerton 12 25 303 Commonwealth 18 537 Fullerton,CA 92832 24 165 Contact:Vincent Oseguera Phone:(714)738-6851 City of Villa Park 2006-7 Sewer Rehab Project CIPP 8 4,574 $300,840 2007 City of Villa Park 10 1,297 17855 Santiago Blvd. 12 598 Villa Park,CA 92861 Contact:Buddy Hines Phone:(714)973-2230 City of Pasadena Green Street Ribloc 8 4,235 $422,075 2008 City of Los Angeles 12 881 1149 S.Broadway 16 110 Los Angeles,CA 90014 Contact:Iftekhar Ahmed 7 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner Phone:(213)485-5875 8 rePipe-California Project List ' Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Los Angeles SSRP C04 Rose CIPP 8 4,266 $180,923 2008 City of Los Angeles 10 163 1149 S.Broadway 12 236 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP U04A Beverlywood CIPP 8 9,053 $304,720 2008 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 LA County Dept.of Public Works Clela Ave Ribloc 8 14,203 $422,311 2008 LA County Dept.of Public Works 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Big Bear Lake 2007-2008 Sewer Reline CIPP 8 7,747 $320,508 2008 City of Big Bear Lake 39707 Big Bear Blvd. Big Bear Lake,CA 92315 Contact:Joe Cylwick Phone:(909)866-5831 City of Los Angeles SSRP H27B Melrose CIPP 8 1,000 $75,647 2008 City of Los Angeles 10 272 1149 S.Broadway 12 15 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of San Bernardino Sewer Liner Rehabilitation CIPP 8 5,254 $219,400 2008 City of San Bernardino 10 2,216 300 North"D"Street San Bernardino,CA 92418 Contact: Phone: City of Los Angeles CSRP Harbor Area Unit4 CIPP 8 7,055 $289,859 2008 City of Los Angeles 1149 S. Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP H01 Olympic CIPP 8 12,700 $459,612 2008 City of Los Angeles 10 547 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP H28A Willow Glen CIPP 8 8,818 $304,896 2008 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP H28B Franklin CIPP 8 7,535 $329,572 2008 City of Los Angeles 10 633 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 9 a rePipe-California Project List ' Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner City of Moses Lake Sewer Lining Project 2008 Ribloc 8 37,300 $884,564 2008 City of Moses Lake 321 South Balsam St Moses Lake,WA 98837 Contact:Shawn O'Brian Phone:(509)766-9217 City of Los Angeles SSRP H28C Sunset CIPP 8 7,204 $443,943 2008 City of Los Angeles 10 1,649 1149 S.Broadway 12 228 Los Angeles,CA 90014 15 930 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRTP S09 Imperial Hwy CIPP 8 17,509 $792,014 2009 City of Los Angeles 10 1,352 1149 S.Broadway 12 1,258 Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Los Angeles SSRP H32A Canyon CIPP 8 4,913 $218,628 2008 City of Los Angeles 1149 S. Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Chula Vista Sewer Rehab Program Phase 1 CIPP 15 600 $138,490 2008 City of Chula Vista 276 Fourth Avenue Chula Vista,CA 91910 Contact: Phone: LA County Dept.of Public Works Olympic Ave Ribloc 8 9,224 $269,980 2008 LA County Dept.of Public Works 10 144 900 S.Fremont Ave. Alhambra,CA 91803 Contact: Keith Lehto Phone:(626)300-3304 City of Los Angeles SSRP H29A Laurel Canyon CIPP 8 13,691 $517,641 2008 City of Los Angeles 1149 S.Broadway Los Angeles,CA 90014 Contact:Iftekhar Ahmed Phone:(213)485-5875 City of Villa Park 2007-8 Sewer Lining CIPP 8 7,377 $358,689 2008 City of Villa Park 10 391 17855 Santiago Blvd. 12 49 Villa Park,CA 92861 21 30 Contact:Buddy Hines Phone:(714)973-2230 City of Rancho Palos Verdes 2008 Storm Drain Lining CIPP 18 1,649 $273,663 2008 City of Rancho Palos Verdes 24 422 30940 Hawthorne Blvd. 36 110 Rancho Palos Verdes,CA 90275 42 96 Contact:Ron Dragoo 54 60 Phone:(310)544-5250 LA County Dept.of Public Works CDR 438 CIPP 12 122 $108,058 2008 LA County Dept.of Public Works 15 149 900 S.Fremont Ave. 18 509 Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 10 rePipe-California Project List Name of Owner Project Name Lining Method Pipe Size Lengths Contract Value Completed Name and Address of Owner h City of Seal Beach SWR 100 Sewer Rehab CIPP 8 2,650 $243,425 2008 City of Seal Beach 211 8th Street Seal Beach,CA 90740 Contact:Michael Ho Phone:(562)431-2527 LA County Sanitation Dist California Ave CIPP 12 371 $41,331 2008 LA County Sanitation Dist 1755 Workman Mill Road Whittier,CA 90601 Contact:Rich Julio Phone:(562)699-7411 ext.1607 City of Thousand Oaks CIPP Lining Phase 2 CIPP 8 454 $238,882 2008 City of Thousand Oaks 10 1,951 2100 Thousand Oaks Blvd. Thousand Oaks,CA 91362 Contact:Roner Castillo Phone:(805)449-2400 LA County Dept.of Public Works Amalia Ave Ribloc 8 10,109 $335,321 2008 LA County Dept.of Public Works 15 168 900 S.Fremont Ave. Alhambra,CA 91803 Contact:Keith Lehto Phone:(626)300-3304 City of Richland 2008 Sanitary Sewer Trenchless CIPP 6 4,215 $837,677 2008 City of Richland 8 20,224 505 Swift Blvd. 10 1,689 Richland,WA 99352 12 316 Contact:Sheldon Williams Phone:(509)942-7492 City of Big Bear Lake Sewer Reline Project 2008 CIPP 8 5,835 $258,889 2008 City of Big Bear Lake 12 540 39707 Big Bear Blvd. Big Bear Lake,CA 92315 Contact:Joe Cylwick Phone:(909)866-5831 City of San Diego Sewer Rehab Phase F Ribloc 8 44,439 $1,058,856 2009 City of San Diego 10 2,088 9192 Topaz Way San Diego,CA 92123 Contact:Craig Whittimore Phone:(858)292-6471 LA County Dept.of Public Works CMP Lining Phase 1C CIPP 12 937 $1,097,086 2009 LA County Dept.of Public Works 15 398 900 S.Fremont Ave. 18 4,123 Alhambra,CA91803 21 544 Contact:Keith Lehto 24 1,553 Phone:(626)300-3304 36 1,537 Running totals 1,038,244 $ 45,290,748 11 NationalOLiner Cured-In-Place Pipe(CIPP)Wall Thickness Design and Hydraulic Capacity Calculations Project:Sewer Rehabilitation Project CC No.1396 ref le-C,ralifornia, Inc. Location:Huntington Beach,CA 2 Owner:City of Huntington Beach 5525 E.Gibraltar St. Line Segment(s):8-inch Ontario,CA 91764 Design Assumptions: Condition of host pipe FD PD=partially deteriorated,FD=fully deteriorated Inside diameter of host pipe(in) D= 8 Ovality of host pipe(%) q= 2.0 Default value is 2%;range=0%-10 Slope of host pipe(ft/ft) S= 0.190 Host pipe Manning's roughness(dimensionless) n;= 0.015 varies from 0.013-0.030(dependent on existing pipe material,geometry,diameter and condition) CIPP Manning's roughness(dimensionless) of= 0.010 varies from 0.009-0.013 Constrained soil modulus of native soil in the pipe zone(psi) Man= 1,000 See table below for recommended values From Table 5.6 of AWWA Manual of Water Practices M45,Second Edition a- Cohesive Native Soils ® `� Granular Native Soils Unconfined compressive Ma„ R�4y��t. strength(q„) Description n+a Blows/ft(per ASTM - - -D1586) /�6� Description tons/sf kPa psi MPa I� ,Q I10.43781 Lfl >0-1 e very.jqqse 0-0.125 0-13 ve ve soft 50 0.3 1-.2................................very loose....................0.125..-.0.25 13-25 ve soft.................:200 1.4 :} /.7r.'I f'? Li'� .............................. ...........................................................U.'...... ............................................... .+ 2-a o.zs-o.so zs-so Soft 70o Exp. 4-8 loose .................._0.0..'_�:0................_`50..-._100..............._medium.............................................._10.3.... ............. ..................... 100.-200..._._.........._stiff...-................._3,000............_ZO:�........ �i't a \_ l .5-..30 compact ......... 2 0 4.0 200-.400 very stiff ...... .._5 000 34 5 - S 30 50 dense 4 0 6 0 400 600 hard 10 000 >50 very dense 6.0 600 very hard 20,000 1 138.0 Flexural modulus of Elasticity of CIPP,initial(psi) E 250,000 Minimum value Is 250,000 psi per ASTM F1216 Long-term retention of mechanical properties(%) - 50% Determined from flexural creep modulus testing extrapolated to proposed design life(such as 50 years),h Flexural modulus of elasticity of CIPP,long-term(psi) EL= 125,000 Determined from flexural creep modulus testing extrapolated to proposed design life(such as 50 years) Design safety factor N= 2 Default value is 2.0 Unit weight of soil(pcf) as= 120 Applies to fully deteriorated designs only Unit weight of water(pco 4= 62.4 - Depth of cover(ft) H= 10.0 Measured from ground surface to top of pipe - Height of groundwater(it) Hw= 7.0 Measured from top of pipe;Note:If water table is below top of pipe,input a negative number! Internal vacuum pressure(psi) P„= 0.0 Default value is 0 Internal pressure(psi) - P= 0.0 Pressure pipe applications only! If no pressure,input 0 Diameter of hole or opening in original pipe wall(in) d= 0.000 Pressure pipe applications only! If no pressure,input 0 Poisson's ratio of CIPP v= 0.30 Average value for CIPP per ASTM F1216 Flexural strength of CIPP,initial(psi) a;= 4,500 Minimum value is 4,500 psi per ASTM F1216 Flexural strength of CIPP,time-weighted(psi) aL= 4,500 At buckling the time-weighted flexural strength is equal to the lower 95%confidence value of the short-teri Tensile strength of CIPP,initial(psi) aT= 3,000 Pressure pipe applications only! Tensile strength of CIPP,long-term(psi) CTL= 1,500 Determined from long-term tensile strength testing. Enhancement factor(dimensionless) K= 7.0 Minimum value recommended per ASTM F1216 Surface live loading condition H2O H2O,E80 or airport H2O Calculations(Highway Loadsl Impact factor for traffic load(dimensionless) Ir= 1.0 From AASHTO Standard Specifications for Highway Bridges,12th Edition Distributed load area over pipe at depth H(ft2) ALL, LL= 517.4 See table and figures below Total applied surface wheel load(Ib) PLfv= 48,000 Based on critical loading configuration(see table below) H2O live load transferred to pipe at depth H(psi) wLH= 0.6 wL=IF IFYO 44 ALL) Critical Loading Configurations for H2O loads(per AASHTO) Condition H,ft P,lbs ALL,ft 1 H<1.33 16,000 0.83+1.75H 1.67+1.75H _ 2 1.33<_H<4.10 32,000 0.83+1.75H 5.67+1.75H 3 4.10<_H 48,000 (4.83+1.75H)(5.67+1.75H) 0-1 Wh I L d A,% p Wheel Load A-110 °ate 1 7/ \ Khee Lead Area wheel Load Ar \6�- /�/ \ Wheel l d A ��6� h, 'H y =-0 iY++Outed load Area gjas pinnb-dLail Arve piatribut-M Load Area Condition 1.Distributed Load Area-Single Dual Wheel Condition 2.Distributed Load Area-Two H2O Trucks Passing Condition 3.Distributed Load Area-Alternate Loads in Passing Mode E80 Calculations(Railway Loadsl E80 live load transferred to pipe at depth H(psi) wLa= 0.00 from graph below E80 Live Loads on Pipe Installed Under Railroads (From Concrete Pipe Handbook,5th Edition) - - 0 0000 0000o O000 0000 0 0000 00000.---- -- `o o g000 00000 0000 0CR C:t 00!bper 0 0000 N NNN O OOJOOO-�NNN a 35 -.rt7j ' sr m m m m rn o m m m w .n Lo rn I l n ft 30 25 > 20 L V`7`,9 2551nCY}+27 469 .11 I 15 a i 15 8' 5'5'5' 9' S 6'5' 8' 8 5'5'5' 9'5'6'5'5' oa 16 0 10 20 30 Load(psi) -Figure 4.30. Spacing of Wheel Loads Per Axle for a Unit rn - (P ) - Cooper E 80 Design Loading. x CIPP Design Template _ 7/25/2011 - NEK i270 Nkirth Frec:mV,Si:ite 490 1 �l lt_31 <1 it b; LL.C. 28 1__874-0333 Fax anuTT ,"< Re. rational Liners Certification of-Compliance To Whom It Nlay Concern: The fnllcart1ing is in support ci#cjualificatioii and to certify compliance W'ith'the recluirein0its for the installation of Cured-ln-Place Pips(C'IPPI iitilizini the?rational Liner CIPP rehabilitation piocess.7he National Liner CIPP;.prtaduct is,desioned via tine requirements of STM F-1216 and the installed product fully exceeds all the requirements of ASTM F-121€. National Liner L.L C., liceiysor of the National Liner CIPP p cessl is true of the ni,Aidr izastallets ofCIPP in the U.S. and,Canada,ihrough its approved network of licensees, The National Liner process has been used 0.;install over 13,000,000 feet since use begaia operations in 1994. Our protects ha4e ian:;ed ficam six-izacli(6).diame#er tinin s to eighty,fbU inch (8 }diameter linings' including rese.rvicing thousands of lateraIs. Inland Pipe Rehabilitation LLC: and its subsidiary €mpa.mes, which includes'rePi CA, Inc., are authorized licensed:installers ha�•�in�;fulfilled all necessary training requirements to be proficient in the installation of National Liner CIPP product. The Inland Pipe Rehabilitation LLC companies have installed in excess of 5,9 million feet ctf National Liner CIPP since 1995 ,HOC isophthalic polyester,and r.inyl ester resins used.with,Applied Felts_irac"polyester felt liners are the components for Ma u'facturing National Liner CIPP, The,resin is specifically{ formulated for use in rehabilitation of°sewer lines and has excellent corrosion resistanee- The resin has been tested according to dII ASTM test procedurefi outlined iri ASTM F-121 , inclusive of ASTM D-5813 and ASTI�I D-543 test methods. 1`lae quality control prcagrains in place at emery:At�C niarn 'acturit foci,I v have been certifiod as meeting ISO 9,002 standards. In Addition,Applied Felts lining,materials fully meet the requirements of Section.5,1 of ASTM F-1216. A, pplie€1 Felts operate quality syste s'Complyisa r�ith 1SO 9002 and all materials are tested to ensure suitability to CIPP applications, Each liner is typically tested in 28 different ways allowing for traceable test data for any particular liner, In summary, National Liner L.L.C:, books forward to supplying a c�onanieicially acceptable CIPP rehabilitation technology rue are eery pre}ud of Regard , I24; 1,Pavlic Director ofMark-etingg ref'ip+e®Ca ornia, Inc; 5525 E, Gibra{tar St: 0 tario, CJ5; 917r4 Nat.ionalon diner Cured-In-Place Pipe(CIPP)Wall Thickness Design and Hydraulic Capacity Calculations Project:Sewer Rehabilitation Project CC No.1396 rePipe-California, Inc. Location:Huntington Beach,CA Owner:City of Huntington Beach 5525 E.Gibraltar St. Line Segment(s):8-inch _ - _ Ontario,CA 91764 Design Assumptions: Condition of host pipe FD PD=partially deteriorated,FD=fully deteriorated - Inside diameter of host pipe(in) D= 8 Ovality of host pipe(%) q= 2.0 Default value is 2%;range=0%-10 Slope of host pipe(fUft) S= 0.190 - Host pipe Manning's roughness(dimensionless) n;= 0.015 varies from 0.013-0.030(dependent on existing pipe material,geometry,diameter and condition) CIPP Manning's roughness(dimensionless) nr= 0.010 varies from 0.009-0.013 - - - Constrained soil modulus of native soil in the pipe zone(psi) Ms„= 1,000 See table below for recommended values - From Table 5.6 of AWWA Manual of Water Practices M45,Second Edition Cohesive Native Soils Granular Native Soils Unconfined compressive - Msn strength(q„) Description- Blows (per ASTM D , 1588) Description tonslsf kPa psi MPa No.43701 ve ve loose >0-0.125 0-13 ve ve soft 50 0.3 ry_......so ... 1-2 ve loose 0.125-0.25 0 1.4 T:, 13-25 ve soft -20 ,��-a ...................2._.4................. .............. 0.25-0.50 .........._25-50 soft 700........._......4.8......... �3" I� 4-8 loose 0.50-1.0 50-106 medium 10.3 ............................................................... h0y compact..,.-,,,,, 10-2.0 100-200 stiff 3,000 20.7 ... ............ .. ... ......1­2-0,000 .... .15 30 compact 2.0-4.0 200-400 verystlff 5,000 34 5 - ',4 - U.. ... .. 30-50 dense 4.0-6.0 400-600 hard 10,000 ...... ..................................ry........-........................ ..... ......................................................................... ........._................................................38........... ............................. >50 ve dense 6.0 >600 yethard 138.0 Flexural modulus of Elasticityof CIPP,initial(psi) E= 250,000 Minimum value is 250,000 psi per ASTM F1216 Long-term retention of mechanical properties(%) 50% Determined from flexural creep modulus testing extrapolated to proposed design life(such as50 years),t, Flexural modulus of elasticity of CIPP,long-term(psi) EL= 125,000 Determined from flexural creep modulus testing extrapolated to proposed design life(such as 50 years) Design safety factor N= 2 Default value is 2.0 Unit weight of soil(pcf) - 8s= 120 Applies to fully deteriorated designs only Unit weight of water(pcf) - 8.= 62.4 - Depth of cover(it) H= 10.0 Measured from ground surface to top of pipe - Height of groundwater(ft) HW= 7.0 Measured from top of pipe;Note:If water table is below top of pipe,input a negative number) Internal vacuum pressure(psi) P„= 0.0 Default value is 0 Internal pressure(psi) P= 0.0 Pressure pipe applications only! If no pressure,input 0 Diameter of hole or opening in original pipe wall(in) d= 0.000 Pressure pipe applications only! If no pressure,input 0 - Poisson's ratio of CIPP v= 0.30 Average value for CIPP per ASTM F1216 - Flexural strength of CIPP,initial(psi) a;= 4,500 Minimum value is 4,500 psi per ASTM F1216 Flexural strength of CIPP,time-weighted(psi) _- aL= 4,500 At buckling the time-weighted flexural strength is equal to the lower 95%confidence value of the short-ten Tensile strength of CIPP,initial(psi) ar= 3,000 Pressure pipe applications only! - Tensile strength of CIPP,long-term(psi) arL= 1,500 Determined from long-term tensile strength testing. Enhancement factor(dimensionless) K= 7.0 Minimum value recommended per ASTM F1216 Surface live loading condition H2O H2O,E80 or airport - H2O Calculations(Highway Loads) --- - Impact factor for traffic load(dimensionless) Ir= �O6 From AA SHTO Standard Specifications for Highway Bridges,12th Edition - Distributed load area over pipe at depth H(it') ALL= See table and figures below - - Total applied surface wheel load(lb) PLw= Based on critical loading configuration(see table below) -- H20 live load transferred to pipe at depth H(psi) wLR- wL=(PId/(144Au) Critical Loading Configurations for H2O loads(per AASHTO) - Condition H,ft P,Ibs ALL,ft - 1 H<1.33 16,000 0.83+1.75H)(1.67+1.75H - - - 2 32,000 0.83+1.75H 5.67+1.75H ' 3 4.10<-H 48,000 (4.83+1.75H)(5.67+1.75H) - - Yih i L d A- wheel Lad An. Oar ♦6 t�.� \ice. kp\\�.: \�1 tt,:. "�%h�a .. Ap\ .�t6"it .\ A�F! \� wh Loud A- w I Lox^_A,e \�_ �l - Wheel L d A O,,ui1, ed L d Ana gist,b 0 Load Area � �OiSt huc.J Laatl Area - Condition 1.Distributed Load Area-Single Dual Wheel Condition 2.Distributed Load Area-Two H2O Trucks Passing Condition 3.Distributed Load Area-Alternate Loads in Passing Mode- - E80 Calculations(Railway Loads) - - - - - E80 live load transferred to pipe at depth H(psi) wLR= 0.00 from graph below - - - E80 Live Loads on Pipe Installed Under Railroads (From Concrete Pipe Handbook,5th Edition) - - - a 0000 -o oaoo-oaoo 0000 - a 0000 -o oaoo 0000 0000 - 0 0 ocsoo 0000- 0000 0000$,000lbpar 35 O OOOON NNO 0 !IO tt 000-.NNNi+t 30 - v mcomm rn in coromco rn�.n u-. _ 25 � T t I-) "'Cl t r .r;� C ti > 20 - 8 MA n x rt 2fi 469 ;'- OF C=.e 46 - - I 15 a i 10 �' $ 5'5'S' 9' S`$ 5' $ $'S'S'5' 9.5'6'5'5' > - 5- 0 0 10 20 30 - t Unit Load(psi). - Figure 4.30. Spacing of Wheel Loads Per Axle for a rn .: - - - Cooper E 80 Design Loading. CIPP Design Template - - 7/25/2011 - - NEK -- Airport Loads Modulus of elasticity of concrete(psi) E�= 4,000,000 default value is 4,000,000 Poisson's ratio of concrete(dimensionless) N= 0.15 -- default value is 0.15 CALIFORNIA BEARING RATIO,CBS Modulus of subgrade reaction(lb/in') k= 250 see adjacent figure - 4 5 6 7.8 910 15 20 25.30 40 50 60 7080 0 Thickness of concrete pavement(in) h= 12 • Depth of cover,top of pipe to bottom of slab(it) H= 9.0 UNIFIED SOIL CLASSIFICATION Horizontal distance from pipe centerline(ft) X= 0 assumed=0(worst case) Corps of Engineers U.S.Army and s U.S._ Bureau of Reclamation Radius of stiffness of the rigid pavement(ft) R.= 3.27 Re= 11 71TI, 0 12---1 F-Ehµ2 Wheel load(Ibs) Pam= 90,000 AASHTO SOIL LCLASSIFICATION Federal Highway Administration - Worst-case loading scenario is for 2 loads spaced 0.8R,apart and is calculated below.For alternate loading conditions,see Concrete Pipe Handbook,5th Edition Pressure Coefficient(C)for XIRs=0 2 loads 0.8 as- apart along - FEDERAL AVIATION AGENCY ; I .- - - Sail ClassificationI 0.25 axis of e -- : o° s pr y=-0090�5x3 0:0101xz-0.D756x 0.2 !- r H X ( t RESISTANCE VALUE,IR 0.15gl- 01 = t = - ___ '€ =a MODULUS O F SUBG RAGE REACTION, psi per mch ro a �"-�` z ia� we a aoo • crap 0.0 iyP wzi rrcl§1 I H ( iI BEARI5 ,= 5 G VALUE,psi I C= 0.074 I (30-in.diameter plate 0[-in.deflect � � w o n. m 0 2 4 6 8 10 CALIFORNIA BEARING RATIQ C8R - H/Rs 9O 1Qp Airport live load transferred to pipe at depth H(psi) w,= 0.00 wu,=CP/R,z Wall Thickness Design Partially Deteriorated Gravity Pipe Condition s _ 1-q/100 Ovality reduction factor(dimensionless) C= 0.84 C ([l,q/100T External hydrostatic pressure from groundwater(psi) P„,= 3.32 P.„=7_(H,v+D/12)/144 D Minimum thickness required,hydrostatic buckling tt= 0.13 In t,- ASTM F1216,Equation X1.1 3.21 mm �[F 2'K'ECMinimum thickness required,ovality check is= 0.05 m 1.5. . 1+- SDRF-0.5- 1+ q-).SDR- =0 ASTM F1216,Equation X1.2 q r q 1 = 1.36 mm 100 l 100) 100 P-N SDRz= 150 If P„.=0,default SDR=100 Quadratic factors for Eq.X1.2 a= 0.0306 _ used to solve for SDRz and t2: b= -0.510 c= -677.258 Fully Deteriorated Gravity Pipe Condition Total live load transferred to pipe at depth H(psi)= W.= 0.64 From live load calculations Water buoyancy factor(dimensionless) R.= 0.77 Rw=1-0.33(H„/H) (min.value=0.67) Note:If Hw<O,use H.=0 in this calculation Total external pressure on pipe(psi) qt= 10.37 qt=0.433Hw+a5,HR.„/144+W, Note:If Hw<O,use H.=0 in this calculation Coefficient of elastic support(in-lb) B'= 0.324 B'=1/(1+4e-00e5") See Note X1.3 of ASTM F1216 Minimum thickness required,Luscher's buckling equation is= 0.15 lin t= (Arq, 'D'.12 ASTM F1216,Equation X1.3 = 3.73 mm [32 R,,.•13MmEt. C, _ Minimum thickness required,pipe stiffness t4= 0.13 in 3.35 Imm t=(D3.0.093 12/E)113 ASTM F1216,Equation X1.4 Partially Deteriorated Pressure Pipe Condition - Minimum thickness required to withstand internal pressure tp,= 0.00 in ter=D/([(D/d)3(5.33-ar/PN)]12+1) ASTM F1216,Equation X1.6 in spanning across any holes in the original pipe wall - d/D= 0.00 If d/D>1.83(tp,/D)4,ASTM F1216,Equation X1.5,then liner is in ring tension or hoop stress 1.83(tp,/D)1n= 0.00 and fully deteriorated pressure pipe condition applies(ASTM F1216,Equation X1.7) Minimum thickness required by design check tert= 0.00 in 0.00 mm Fully Deteriorated Pressure Pipe Condition Minimum thickness required to withstand all external tp,3= 0.00 in tea=D/((2'-TI/PN)+2) ASTM F1216,Equation X1.7 loads and the full internal pressure - = 0.00 mm CIPP Wall Thickness Design Summary Host pipe condition Fully Deteriorated _ CIPP end use application Gravity Flow CIPP outside diameter(host pipe inside diameter) - D= 81 in Minimum CIPP thickness calculated t-_ 0.15 in Greatest value calculated from ASTM F1216 Equations X1.1,X1.2,X1.3 and X1.4(gravity = 3.73 mm flow)or greatest of X1.1,X1.2,X1.3,X1.4 and X1.7(pressure pipe) Minimum CIPP thickness recommended tmim= 0.15 in Based on a maximum SDR=100 3.73 mm Nominal CIPP thickness to be supplied tc-= 4.5 mm Rounded up to the nearest 1.5 mm to reflect standard CIPP thicknesses supplied SDR­= 45 SDR=D/t Maximum recommended SDR for CIPP is 100 per ASTM F1216 CIPP Design Template - 7/25/2011 - NEK - Hydraulic Calculations CIPP inside diameter(in) Di= 7.6 Flow area of host pipe(ft) A;= 0.35 Flow area of CIPP(ft�) Ar= 0.32 Capacity of host pipe(cfs) Q;= 4.57 Q=1.486 A RH S112 (Manning's Equation) Capacity of CIPP(cfs) Qr= 6.07 where RH=hydraulic radius=D/4 for pipe flowing full increase/decrease in Flow Capacity AQ= = 33%t CIPP Design Template 7/25/2011 - NEK _ 5525 E.Gibraltar Street Ontario, Ca.91764 Ph:909-291-4050 REPH E Fax:909-291-4070 AN tPR. COMPANY List of three certified laboratories that can perform the required ASTM testing. Laboratory number 1: Name: IRAOA -Fer-z4 LAz55 Address' Iel/o q C>e-A,,,fc-f AVE. ,+�,4�.r��r.►-r c,a- 9a723 Telephone number- (srz) (,3_3-1¢az,q Contact person: r,N1Fe Laboratory number.2_ Name: j i?_ Afe Address: j_ 1 D3 '' t1tiSz^d� Z"2x s Telephone number. (.7 f3) (Old� -"i'3�� Contact person Mc- Laboratory; r 3: Name. �� S 'l.rC-40 bA Address: q 750 lllcc37-r.`�i t z so f �le2,Co �3o� U?"lf (!N!� Telephone number: -29 G�2o,�✓1 G�ut „r�«' r� •73Y-96oA j Contact parson: EQUAL OPPORTUNITY EMPLOYER THE AME ICAN INSTITUTE ITUTE OF ARCHITECT'S AIA Document A310 Bad Bond KNOW ALL MEN BY THESE PRESENTS, THAT WE RePipe-California, Inc. 5525 E. Gibraltar St., Ontario CA 91764 as Principal, hereinafter called the Principal, and Arch Insurance Company 3 Parkway Philadelphia, PA 19102 a corporation duly organized under the laws of the State of MO as Surety, hereinafter called the Surety, are held and firmly bound unto City of Huntington Beach 2000 Main Street, Huntington Beach, CA 92648 as Obligee, hereinafter called the Obligee, in the sum of Ten Percent of Amount Bid Dollars ($ 10% ), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators,successors and assigns,jointly and severally,firmly by these presents. WHEREAS,the Principal has submitted a bid for Sewer Rehabilitation Project CC No. 1396, Huntington Beach, California NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and materials furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or,bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 19th day of July 2011 \ W,11!I'ii RePi e-California, Inc. uj i"d'i A - (Principal)(VVI fness) �r S B : '�� = 0)'i72 TttAMAt C-Ye�+� /4SSrsTANT SEGQET�`r A)N�a,��•° Arch Insurance Company (Surety) (Seal) i (witnes) B VIM Attor-in-Fact Joann Dombrowski (Title) AIA DOCUMENT A310®BID BONI)•AIA®FEBRUARY 1970 ED.®THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE.,N.V.,`VASHINGTON,D.C.20006 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§1189 State of California County of (, r f On LL�i ���I before me, '(�� Date Here Insert Name and Tittle of he officer personally appeared Name(,Wof Signer who proved to me on the basis of satisfactory F evidence to be the person(s) whose nameW is/ark subscribed to the within instrument and acknowledged to me that he/she/thy executed the same in his/*AhOir authorized capacity(io), and that by YVONNE MCLELLAN his/h#r/thgir signature(,'] on the instrument the Commission s 1798268 z person ), or the entity upon behalf of which the Notary Public-California a San Bernardino County a person(,sr acted, executed the instrument. Mv Comm.E ires Ma 16,2012 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: Place Notary Seal Above Signature of Notary Public OPTION)IL I Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Individual ❑Individual M. o • ❑ Partner—❑Limited ❑General Top of thumb here ❑ Partner—❑Limited ❑General Top of thumb here F ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Conservator ❑Guardian or Conservator ❑ Other: ❑Other: ( Signer Is Representing: Signer Is Representing: 0 2010 National Notary Association•NationalNotary.org•1-800-US NOTARY(1-800-876-6827) Item#5907 Surety Acknowledgement State of Connecticut County of Hartford On this 19th day of July, 2011 before me personally appeared Joann Dombrowski To me know, who being by me duly sworn did depose and say that he/she is the Attorney-in-Fact of Arch Insurance Company The Corporation described in and which executed the above instrument; that he/she knows the seal of said Corporation, and that he/she signed his/her name thereto by like order. Notary Public: Marion R. Vail My Commission Expires: November 30, 2015 POWER OF ATTORNEY Know All Men By These Presents: That the Arch Insurance Company,a corporation organized and existing under the laws of the State of Missouri,having its principal office in Kansas City, Missouri(hereinafter referred to as the"Company")does hereby appoint Russell M. Canterbury, Joann Dombrowski, Marion R.Vail and Susan E. Deak of Farmington, CT(EACH) -its true and lawful Attomey(s)-in-Fact;tci make, execute,seal,and deliver from the date of issuance of this power for and on its behalf as surety,and as'rts act and deed: Any and all bonds and undertakings EXCEPTION: NO AUTHORITY is granted to make, execute,seal. and deliver bonds or undertakings that guarantee the payment or collection of any promissory note,check,draft or letter of credit; This authority does not permit the same obligation to be split into two or more bonds in order to bring each.such.bond Within the dollar limit-of authority as set forth herein. The Company may revoke this appointment at any time. The execution of such bonds and undertakings in. pursuance of these preserits.'•$hali be as binding upon the. said Company as fully and amply to all intents and purposes, as if the same had been duly executed and acknowledged by its regularly elected officers at its principal office in Kansas City, MlssourF: This Power of Attorney is executed by authority of resolutions adopted by unanimous consent of the Board of Directors of the Company on March 3,2003,true and accurate copies of which are hereinafiter set.forth and are hereby certified to by the undersigned Secretary as being.in full force and effect: "VOTED,That the Chairman of the Board,the President;or any Vice President;or their appointees designated in-writing and filed with the Secretary, or the-Secretary shall have the.power and authority to appoint agents and attorneys-in-fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings, recognizances, contracts-of indemnity and other writings, obligatory in the nature.thereof; and any, such officers of the Company may appoint.agents for acceptance of process:" This Power of Attorney is signed, sealed and certified by facsimile under and by authority of the following resolution adopted by the unanimous consent of the Board of Directors of the Company on March 3,2003: VOTED, That the signature of the Chairman of the Board; the President; or any Vice President, or their appointees designated in writing and filed with the Secretary, and the signature of the Secretary, the seal of the Company,.and certifications by the Secretary, may be affixed by facsimile on..any power of attorney or bond executed pursuant to the resolution adopted by the Board of Directors on March 3, 2003, and any such power so executed, sealed and tartified with respect to any band or undertaking to which it is attached,shall continue to be valid and binding upon the Conipahy. 00ML0013 00 03 03 Page 1 of 2 Printed in U.S.A. City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 e www.huntingtonbeachca.gov Office of the City Clerk FB:l) 7909,P O 8 ` Joan L. Flynn, City Clerk September 30, 2011 Southwest Pipeline & Trenchless Corp. 539 W. 140th St. Gardena, CA 90248 RE: CC-1396—Sewer Rehab Project Enclosed please find your original bid bond for CC-1396. Sincerely, Joan L. Flynn, CMC City Clerk J F:pe Enclosure g9Ww6iI &,rQntASopAh"off Waitakere, New Zealand �. ._;.:a:--:".` ..`' T_:,� r--,:. "a;�`' .,.-�', _�, sg`:,`� ,�. .,::r gip. -•,a_,: '4...,_ r .,�4 F"s"" � �T.c�"".n.'7"" �r- !.r I Southwest Pipeline & Trenchless, Corp. 539 W. 140th Street !t ' t pp Gardena, Ca. 90248 773862A "SEALED BID" For SEWER REHABILITATION PROJECT CC-1396 In the u CITY OF HUNTINGTON BEACH - DO NOT OPEN WITH REGLAR MAIL 2000 MAIN STREET SECOND FLOOR HUNTINGTON BEACH, CA. , ,, ___ .., �t -.<,,.:. ,w,• :,�• •tp: -:..r-ire Yam': :- t -wm,�,u,-s - -.- -c .._,v-.ua:, . .s :' -3� :i;� w: �rsa,;rr.- r -.'s�w .z; '�'.. .. -,. „�_.-. ,".., �,..,,.a�z.., , �K zz„ .,�'. "5.s F -..r A"'7. ,� -v,_�x. � -n...F... 'r 3t'}v,w'- .:v.., ..xm�- �."''W" *" .�, •r+ _,�•. a,. k. xL ,�.,.,'. �t�. "¢. � �•.'d: ."�ri. .:_.�:�.,. a� „ ......:y .. >�--.:._ -� �....:.. .�- ,g„ ^.,..,-.-._._-« -._�>'. ._, ,. �x,.. �,°:. -fad. 3-». ✓'.�.x--:�,,.+-� --3'- -}� ."-t' �� s `-�•k. - -.:,_ .. ., ,f.,, ter,_ ,.2.-".'_,u:- ., i- _. .s:, %*ate`. .-. _, e";- ._..w ... ., _:...._:,`"- --�.<,. "^,. a3. .-!•e`-.. z= *k';. ''= _. ' ,a... , ..,�3.» a yam. ,.,. .. ._ ...-. ,3 -�k. , .. x. '_'t+.,. :.. �.�,..r•.,... ... 2 :..�k-h+-* r.. _»s• .z _ „u .... :v. .� .: ,-, a -` -:e ::?nw=.•p . dr r:. gt'�W. >,.yr '€...:..,. "' ,;,:, , `t,�a, .ty:'�•f''^�. ._...... ... x R'.i .,a .� '.. _ r�,- .. +.p .,. a , „t€ ..a ��..> ., r„r, , t � ..,. s .t. m:: x 'enk'w ro � RV. .,:. ,,. .2-r'.c, ,..,.,t4..,� . , ., .^r..: $. rt•e h. ,... .,,. bd'` t .. wSx.r,n .. !$:, ... .'�.. ....v A...,.,... ',-... r,a.x.U. .,.> ,.. .,, -. <. h � r.... .� ., ,,..,.- ..d -,f .:R:. •3 .f•,_ .. �t .,r.�'w. �� ' : .,.�...d r.. _�. � .a.. �.�. .z., ,^`� ,.{ y�„ ,-r�.>�,. �F,� ,v- t, "`r� � °� t;,.-:`--. .s�.:. * Yx,. r•:'7 .fie, '3-"a�d'l f�* > .., :r;;;_.., .,�.,:� :.ri,_.--` .-r ,:,r�t .. �-..,..,-:_ i,�.. G-a4•. �..,v -:.,;,,`-?f.„�v... ,. .: - .. „y:" r,. .'�i cr t s ,r �.. �-i z ,n '�--' k rs -,_-al X .>.. ,..,,-., x➢> ^ ,T ._�_- .x .s xt, �... t 4 3 ..,q -d' # .p}:. .A' :t+. �.... �•' .. .�' „'�h� <-. .. .„. .. �.. .:... _. .,.. ...,.. ,.,...,. .,, ,,. �#:,. M.. �"•;, ..,.d..6r, .. ..:,. ,.. .�'•.,,., .a .. ..„,;." .. ra ram, ,,3.,na -".'�,�,,,�,. ..+ , :.,,..�. r•.,ce,. ,r,... x .. x. ., r .-, sla,ys, , ,, ,._ r, ... a ..., 'm.�'. `- .`�«..0 ,1 ,x„'+ri,,:r7 ,r 'Y, :,a,;;; .a.-. ,�.>'.. _ ,, I _ , r� , ;--x^sr�. �`" ,k , v. � , :r, a�,.,,t,.. '...r^' >. ..r �r „., _. a .,�.�n �'�.w.•. �,s � a e *�•„..,.w. x «-., ;�. � ,«..d.., 3,.- .r >�^.�,, r>» .a u,o .>x. ?,, w :.�, 'd r '. Mis. ar� t' �Sw' :':,d, �� :,�,, . ...�,.. ,..r f ,' :;,,. M.0 n.. F.-€.._ .n« .f, s,-::- :r..,- -, L �' "3,t.,. :s 5'i.,. :....M->1^'w 7.E j. .g:,• `^P''s•. "z`� �,^ ':^:1f-t s :. `.- N.-w -A - -5,. - .. .. ,, - S c> �. y z .:, w �r b , - n.. , ta_ ..- ,. ,. „ ,.-..., .:r, �. :� .k ..: �, --,::i:. 1'� M... ~ '>.- .:u`ir emu.•: �.:' .. .t ..�a ._ .r>u.,. '7`.. .,.. ^s�,"s�, ,x .. .: a ^r•w- S .,: x'r « 'x ,,.,,a,..... , -„ .,,. ...w� -w..r ,>f � w,.,. �k>a•,r,. , . ,s. .�. r ,. •a'�3•. e �. r,t� .,x. : "3tA 7 �, � ,',..: ., ,.. , �>: � �* r.r._. � r:,�. .:. :ya, .,, ,.w..1...,.. �- ,. ,�._.... ,.<�...: - ,,,6l. ,.e.z..x �� .M.�•a-"t>'� :... ... ..... ,. ...., ,.. •, n •�.,„,. :... � �'..., �n. r„ .-..,,: �' ..: -�. !� a<„t.k �>x .- rd.-»., :.__''.`,w`'T .,l;+c:., ::- :6 �� �wr .•*',!„ r,-. „r�., ""r .� '..". �' .. .max•..-,e�',. va. a,..�.v,....a... .,�'.v>Yr�'d`r"w3.,..,.. 4 ,r ,..,::.:,ti., !�. .r. „«.,,:�,. -. � .'�, ?. h� >n. ..__ ... ,.... rP. r_ o... ...:...r _._�• A"x -<�^�,#tre� r.. rz - ..b ..v... -te. 5.., ",:.+h`+�'t+ "Y:'� ,.cc'� .w.Y 3 rF�"^£r.:-:r nx - :-:.:.„:a -�..,.. .-�'`s,--,e,,.:-a ,k:rn, ,w.y. `s, e.,.. _., ,.....}.•., �-,..,, _. ..:�. � .:�.5> .t?-. .��` ;d »<a. ...;�._ �'= u"����=Ta ;;:.... ,,.^-.�...,m,.:.� :z� ,✓,.. ..�.k-,. �..,,,w...x',''... �'-x.,,��,x. �"S—..:. r?,.,m. 3•'".•,.� -.�-� t(![&p� �,-. :.t;.. �''.. _�,._r .. �_;�-� ,�. <-ter:-•,- .,.,a ,:s - ri:�:•i' >d. r-..' _ ,..a/': r -Y 4.._X .e. i'•7. }: .. . , _- �. 4 .v.. a. ,-' .. .rN E F' ._ -,:'t n.., c _..+ 9-., �• :'�;.. "' * , ,., .,'":�+ ..�, r, �'�, - ? ..a,.. ,'.... s»t`'Kt °io' , x.. ..�,. „,7 :�':.. t. :d.�.,, ��•,. ,c, ,a t ,.,.. ,. .... _.. x mx �. �r - ..< , .- �,. .,� x.:�.,.. .. «,#� '......o.. 'x b -..,,♦.� r.. ',d ,r ..n,,,:. .:C' a, #� :. �..- n„ ,�.v ..�. - _,. ..... -.,. ,x '4^�'k�.,.. "'r. ,�-,. t__, x, aa• �"a'•.�"+"wF .,..., ,_n. '� a �r...., ,.+,:... y.,,,,'... . t .kf o� d xAl , i - �.. .,: ri -�.•:,r a, v".I.:"^s ->+�•,'„F. n$"'' :,:. � � +s o., - c`s->.i.. d. -k .V''., t' i�•;.• 2 -,v}, K"`^.rx.-r,. � -Es.... t.� _'�=,...,, , p -4�'-c- ... .. .,. _....i3_ �'--3 '�_....,'�-� _ 'v*�•`'�r._,v". F.:- ..*e - c- -, �. .a � �;?'=t :.,r.:�sE,..«. ;vR:.. ., ,,>_- ,. , •R;#' ..:,.. 't - ., . ,... '*e �� ,.. -. ».. .,. .,, :"7`a Y,.�. .s. . n :. .r., w,. € �:,4,w ,.,.� ,y..d'•• ,a'3rs,..:� � -,'�w s.., Cb �^ •�:.'�'�ti:'sV"M�. :•ra.., .sr ��. .. , .�..t €,a ,•',a'�r ,, '! ,..�.,._,,� :..sy"«n* ra, ,., d:`. ,. .: �..xr.#w' s•,:� ,«'�. � - .<. va* rs'3.. ... .>. .,, .>'r' r.:: .).....�s-.,r, - :': ,z ?,. ,.•S.� ,.�. .'a -_ -r ,. �-. �'� ,.. . - >s� •n,. a,�n a.zw h. .;:: *. a.sai •f" x .,:; ,a_ ...U. .,.r, ..>.> _.. ,.. t. � m..'..b . . ..y-..s a- `Y°' s ��a .- s,..,,:>�- ..r,.y+.�,r R� ,^,<#:, .�- ,:'•�; .�%z,aa` �3w^t:,-+.. �r._�:.�w �_;:�:"'�,. »x� ->. 3,.. .. .,,�.. r . , ,.r..m:.*d _�_:,. .-, '.. �,-a _ �;���" ,..,a.n .�+, ,.�"=;=>a;,_h .. -� ,x.. ,.k.,-.. .•,.., s�.. .:, .,. .. r-_ :s ..a. )-.. t �- -r 1 S- m,..�=:v...4.. ��:-r. ,. -=T,c' ,.r.. ,,, r ...<..•,ter .- .' -,,._.:.a-.. �.a.,. ...3'..,,.'':� T-`.•,w ,t• .,,�..5}.. :,. ;r•;. r~ --x,Lr.. .v- _ i-?.,. ..._.;�' �4�.,_,.. ;`. ixu-. � ,�.`,- ..,a:• r�:x�.--"`-^ xx rr-y. _ r:..r*. -.:. -:a.... >7=..' .....- .,--aC .,<. ." _... .zr-"•.-�^c-. -,c..,- „, .,,, z•.• 'fix.. .�...., , ,.. .. ,. ,-,. ,.,.. ,F.. a .. a .._.., ., ., ,-.r_ .v ,,s,, ..�- v: - ,. .>�"�.� �<-.. .. .. .-a^•. �,. ,. .. r.:, ,.a: :..:- wYk.„!.v� , vM1Fn..�ta ...... , -� �..,,....,: �n....n ..x t'„.^c.. , ,. „. .:•.,. q .. ,. ,: ','.;:�.. +. ,cr ,,, ,:� �., a•,�,F. ^r� t°°�S Y,„ .e ,,� �.. v•�.. ... .. ,.„ ....... • ry x .,G.�.r +. ,. -.Y+.t.� 4 4,. ... .. ,:.. .v's'x .k., k n.''m':. .V'S kv., -. ,r.� y :�k ..�i ?��v^f x�" :...,+�a xr Y � .. --°sr< :',,* �va... ,.a -;,s-+ a.. -�.. .R.v,r s,.L��,.„^n. v. .�z.,r�,w.• �-.,r ..,::'. :k v3..r a... z a., t ...-F'r. . -_:,,... P .-,,: K.�... ... ... .... ... ! -.•. . �rtan.'r:"Y�.�� ri.,. .+ � r:,x;.�.a.*n .;2fi, ., wk -:<I. ,<„e. �. -z- -+r�[i.:$... ,. :, ,..•.,. �-F '�;.:J....1 ._.ri: ,..,�Nro- .,: -.s.-,?« _ c. ...t, ..., r. a .r:..2. - .t ., -..,,.,- .,.,5x ka. �,.. .,,,,,,w. - „..3. •:r.,,,,t, «,s -a.r�"i _...=_v ,. %.. ....Y .w ox r ._ < «a '...._t.. ... .-.d°:.kt�,..�-..r -f{:, �2. -a�,kro':. 3' +1- S.],'}�?�.r :r"± n�`� .Y, '..`i:4# �e'.^,i.� .uTa i-.-'•M.. �#''k..ar . ._-, :°��,+, ..»; .„ . ..�- ' ,. �,- �_ _.,,., �"�•.-,«....._._ .-_ .."_�. -.~.,,.[,_ >.,2z', -, --, <� # .,,�-- .� ..,r- :._, r.,_ � -y ';. ,t. '� � ,ass_ u .,_.,,.-. '�" -..<..' ,r..,rv�.. -•,»,. .s, >. ,- r-""•^..>.T,.�-..,.,....,,s-. ..,r'�,. ,.:,_�;.x. ,�. ., < ,. .aF,'m >,• - '� .`A,w_. z�.. '--i:' �' .�'�z,."t3' s?�':..:- ..'..a€�.,.;d,?�-. r€•_.c« ,.. r,- `� _-_"�._ � ,w gin., ,�*s--�:.�_..-. .�-. r. .., .,rc,.�,:..-. ., �. .,..,,_. >, .� .z•. M .. .�'•- -."i?�' r �x,- .-,aus�y :;�.`®.:.:•t�.:,.,u; „r: .rc., •,f.. ?r, '��.der�,mu r 'Sd$ vY^�i."r ,.:.:?,,.?:ew ?tom-r ^ds 'v (�. x r.�' F�,:. ,z �.tY -� :n'�'.,, ..,�r... .,.5 s .'»c;.,+ h.,rh'Pt s.`�J,::. „":'!k. •r, .ev:.w,.,, :,n., ,ra v�:^, ,c�.:,.,.rc :ff'4s. - t SECTION C PROPOSAL for the . SEWER REHABILITATION PR03ECT CC No. 1396 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 30 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option,be considered null and void. Accompanying this proposal of bid, find in the amount of$ /,ate er�G�ich said amount is not less than 10% of the aggrega e o he total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond", as the case may be). Bidder shall signify receipt of all Addenda here,if any: Addenda IV Date.Reeeived Bidder's Signature C-2 SECTION C PROJECT BID SCHEDULE INDEX SEWER REHABILITATION PROJECT CC NO. 1396 The three sewer line reaches are(1)Beach Boulevard from Edinger Avenue to Stark Avenue, (2) Clarkdale Drive from Edgewood Lane to the end of the cul-de-sac, and(3) Cliff Drive from Brookhurst Street to Spindrift Lane. PROJECT BASE BID: Basis of Award SEWER REHABILITATION PROJECT C-2.2 to C-2.3 BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: $ g_S 0 g�-5 BASE BID WILL BE THE BASIS OF AWARD C-3 BASIS OF AWARD PROJECT BID SEWER REHABILITATION CC NO. 1396 C-4 ADDENDUM NO. I- PROJECT BID SCHEDULE CC-1396 SEWED LINING t &i(tti♦ : xtei�.e ieiiii:D...c�i`'tafl:;:: ::::.:.:.':.:=:;:�:.:::::::;:�:: ::::<.:::.:<::�:�:�:�>:::�::::�:::�::::::::::.:::::.:::.:::.::::::::.: .es....-.P................................ ... sa'�to:> aratit�tty: ::<:<:: .:.:.:.:.. ;:>: tlt:Pkkk 1 1 Mobilization/Demobilization � Oo LS 7 ,vacs. 2 1 Fumish Traffic Control LS $ 2 t 5cx-)o0 3 2545 Clean and inspect 8"sewer main LF $ 2 $ 4 2545 Install liner and post inspect 8"sewer main LF $ L ."o $ 5 58 Grind and re-open sewer service lateral EA $ $y O(w, 6 1 Prepare Construction Traffic Control Plans LS $ + ?00,a $ 500�fl Total Amount Bid in Figures: $ 23 1?6 Total Amount Bid in Words: , . .......... ................... .. ....... 'j.......!n-r @Q----- s._s. ................ 'V C-2.3 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Portion Name and Address of Subcontractor State License Class of-Work Number CteuMf n ; 1" CA 1?-6 4 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-5 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ss. County of OrwTe Sr�rip�/ X 1/0/ ssl*e'Vey' , being first duly sworn, deposes and says that he or she is l',Z B5�Jc>/ .�/i— of SOUTHWEST PIPELINE AND the party making the foregoing bid that the bid is not made in the Tff* t5 the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. SO T�REST�wL ESSP LIINE AND b39 WEST TH STREET �D�C 9(1M Name of Bid r Signature of Bidder PRESIDENT/TREASURER SOUTHWEST PIPELINE D TRENCHLESS CORP. Address of Bidder Subscribed and sworn to before me this,;:PC- day of 201 / NOTARY PUBLIC e A e e�?y�,.l, NOTARY SEAL C-6 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Zc:;'5 /5271A-<_45 On 7 26�!t before me, �0 6�c QO(yju at . . �a IY-�ti 1���1►�� Date t e Insert Name and Title of the Officer personally appeared � �✓�.�, VZ> /y)e.-cr Name(s)of Signer(s) , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by R08ERT BOt GER JR. his/her/their signature(s) on the instrument the COnlmisSlOn 1883724 person(s), or the entity upon behalf of which the R Los Angeles County WY Public-California D person(s) acted, executed the instrument. LIDLos Comm.Ex fires Mar 21,2014.. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: r , Place Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number o ages: Signer(s) Other Than Named Above: Capacity(les) Claimed by Signer(s) Signer's Name: rier's Name: ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): ❑ Individual ❑ Individual ❑ Partner—❑Limited ❑General Top fhumb here ❑ Partner—❑Limited ❑General Top of thumb here ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Conservat ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: ©2008 National Notary Association-9350 De Soto Ave.,P.O.Box 2402-Chatsworth,CA 91313-2402-www.NationaiNotary.org Item#5907 Reorder:Call Tall-Free 1-800-876-6827 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract,known as the SEWER REHABILITATION PROJECT, (I)(we)(it)will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. SOUTHWEST PIPELINE AND TRENCHLESS CORP. Contractor By STEVEN R.VOSSMEYER PRESIDENT/TREASURER SOUTHWEST PIPELINE AND TRENCHLESS CORP. Title Date: C-7 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 14310.5, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-8 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. SOUTHWEST PIPELINE AND TRENCHLESS CORP. Contractor C� By STEVEN R.VOSSMEYER p PRESIDENT/TREASURER Je t rrl iWEST IRE6I�AND Title TRENCHLESS CORP. Date: C-9 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name SOUTHWEST PIPELINE AND TRENCHLESS CORP_ Business Address 539 WEST 140TH STREET GARDENA,CA 90248 City, State Zip (51pe ) --7199 -- -P7/7 Telephone Number 7�-? Of State Contractor's License No. and Class Original Date Issued - -3 f- ® Expiration Date The work site was inspected by of our office on 5�\ Z , 2011. The following are persons, firms, and corporations having a principal interest in this proposal: S 9c-"rec� C-10 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. SOUTHWEST PIPELINE AND TRENC'HI ESS CORP Company Na Signature of Bidder S7EVEPI R.VOSSMEYER PRESIDENT/TREASURER SOUTHWEST PIPELINE AND Printed or Typed Signature Subscribed and sworn to before me this day of , 201/. NOTARY PUBLIC S2t -��C,���, er� /`tG�c ,•� .� G,tge n.e--4-- NOTARY SEAL Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past two years: I. 5 ,-,r? Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 2. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed C-1 I ti CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT a State of California County of "Vn07:r,s,5 On before me, iCa6er Date Here ert Name and Title of the Officer personally appeared S� e v e, /c, 11,ofsn � Name(s)of ner(s) , F who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in ROBERT BOLGER JR. his/her/their authorized capacity(ies), and that by Commission# 1883724 Z his/her/their signature(s) on the instrument the S Notary Public-California a z Los Angeles County >+ person(s), or the entity upon behalf of which the Comm.Ex Tres Mar 21,2014 person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. I WITNESS my hand and official seal. Signature: Place Notary Seal and/or Stamp Above Signature of Nota lic OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document ' Title or Type of Document: Document Date: Number of-Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Si er's Name: ❑ Corporate Officer—Title(s): Corporate Officer—Title(s): ❑ Individual ❑ Individual ❑ Partner—❑Limited ❑General Top o. umb here ❑ Partner—❑ Limited ❑General Top of thumb here ❑ Attorney in Fact ❑Attorney in Fact ❑ Trustee ❑Trustee ❑ Guardian or Consery r ❑Guardian or Conservator ❑ Other: ❑Other: Signer Is Representing: Signer Is Representing: 02008 National Notary Association•9350 De Soto Ave.,P.O.Box 2402•Chatsworth,CA 91313-2402•www.NationalNotary.org Item#5907 Reorder:Call Toll-Free 1-600-876-6827 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax(714) 374-1573 ADDENDUM NUMBER ONE for the construction of SEWER REHABILITATION PROJECT CC No. 1396 July 18,2011 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: NEW BID SCHEDULE INCLUDE: 1. NEW Item No.6 "Prepare Construction Traffic Control Plans" ....1 LS 2. Revised Bid Item No.2 to Read"Furnish Traffic Control' SPECIFICATIONS REVISIONS TO INCLUDE: 1. Replace in Bid Documents Section 7-5 PERMITS on Pages E-11 and Section 7-10 PUBLIC CONVENIENCE on Pages E-15 with New Section 7-5 and 7-10 in Addendum No.1 2. A Caltrans Encroachment Permit Application pulled by Agency is attached to Addendum No. 1. Contractor must submit to Caltrans Water Pollution Control Provisions and Construction Traffic Control Plan for review and approval,along with the application for a rider to the Encroachment Permit. Bidders shall submit SECTION C with the most current revisions and bid schedule, Page C-2.3 "Addendum No. 1-Project Bid Schedule CC-1396 SEWER LINING". Award will be based on most current revised Bid Schedule and Specification revisions. This is^�toua E ST Pdge,N %and review of Addendum Number 1,date ly 1 2011. TRENCHLE PPSSEELLC.ORP. Company Name Y SMIEN R.VOSSMEYER PRESIQENTl PE AN SOUTHWEST PIPELINELINE AND T- TRENCHLESS CORP. Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call Joseph Fuentes at(714)536-5431. l r SOUTHWEST PIPELINE AND TRENCHLESS CORP. Trenchless Pipeline Reconstruction License No. A-773862 COMPANY INFORMATION Southwest Pipeline and Trenchless Corp., a California Corporation No. 2150248,was organized on November 10, 1999. Federal ID No: 95-4768595 California Contractors License: 773862-A, exp. 01/31/2012 In November, 2002 Southwest Pipeline &Trenchless Corp. assumed operations of U-Liner West and National Liner West, formerly divisions of ZZ Liner, Inc., which was formed in 1992 under related ownership. Personnel from Southwest Pipeline and Trenchless Corp. have extensive experience in the underground construction industry and rehabilitation of sewer lines and storm drains. We are certified licensees of the Cosmic Top Hat SystemsTM Lateral Connection Sealing System and both HDPE and CIPP as well as Spiral Wound PVC/HDPE methods of pipeline rehabilitation. OFFICERS AND DIRECTORS President and Treasurer: Steven R. Vossmeyer Secretary: Justin Duchaineau Directors: John M. Colich and Janine T. Colich 539 West 14001 Street --c- Gardena, CA 90248 -,-(310)329-8717 t-, Fax(310)329-0981 BOARD OF DIRECTORS RESQLtfI`1 N somwEST MPEL NE AND TRERCHLESS CORP. APRIL 20,2009 The undersigned being all of the nwmbt rs of do Board of Directors of Southwest Pipeline and Tmnahless Corp.,a California C nmration,certify dot the Bylaws of do corporation authorize the d4ectm to act by unanimous coma Pursuant to Section 307(b)of the California Caenenl Corporation Law and the Bylaws ofdw corpomdon,dw undersigned admewl continuing consent to adoption of the following resolution as the oct of the Board of Directors ofthe C,arpeotation RESOLVED.that Steven R.Vourn!~yu is audaaa ed as prmidenN'1'>tessure r pursueatt to the Bylaws of the cm poeation to sign any and all contras%bid bonds, paynnent boods,and other peMnmt dmmmts of a nature,for sod on bdoWer Pipeline and Trenchless Corp.This resolution hn been effective since July 24,2007 ad it tattains in full force and effect for pertinent rhos is signed heaea . RESOLVED,that Justin P.Duchaineau is atuthmind as Sem tary to the Bylaw of the corporation to sign any and all contracts,bid bonds,pufamarme bonds,payment bonds,mad other pertinent doamraents of a nature,for and on b&WofSom&wed Pipeline and Trenchless Corp.Thais roolution Ices ban effective since April 20 2009 and it remains in full force and affect for peartinent documents signed launfier. aloe M.Couch.INenabaer of Baar+d of D#nectora banim T.Cdkh,MeMer o of Directors State Of California CONTRACTORS STATE LICENSE BOARD ACTIVE LICENSE fumuwcr .\(fairs 773862 E,, CORP SOUTHWEST PIPELINE AND TRENCHLESS CORP A �. F r.-.0- 01/31/2012 Southwest Pipeline and Trenchless Corp.,License No.773862-A including U-Liner West and National Liner West Divisions Modified Standard Form 254 PROFILE JOB# CODE PROJECT NAME&LOCATION OWNER and/or GENERAL CONTRACTOR CONTACT INFO. CONTRACT AMOUNT START COMPLETE 587 6 SSRP U19B Prosser Ave.&Olympic Blvd. Vasilj,Inc.for City of Los Angeles W.O.SZC11786 562,999.05 Rehab by CIPP 4500'8", 1156'10", 1023'12",4310'15" 15531 Arrow Hwy,Irwindale,Ca. 91706 626-480-1442 588 3 Golden Valley,Mn. Visu-Sewer&Clean&Seal,Inc. Keith Alexander 37,700.00 10/10 41 Top Hats W230 N4855 Betker Dr., Pewaukee,Wi. 53072 262-695-2340 589 6,3 Sewer Group Job 734 Franklin Ave.,Pardee Place,Florence St. Burtech Pipeline Buddy 2010-013-3.6 23,320.00 1/11 1/11 503'6"CIPP,2 Top Hats 102 Second St.,Encinitas,CA 92024 760-634-2822 590 2010-2011 Sewer Rehabilitation Project City of Redwood City Joel B.Evora 537,275.00 1/11 1/11 5050'6"lining, 130 Top Hats 1017 Middlefield Road,Redwood City,Ca.94064 650-7820-7328 East Canyon Utility Remediation UCSD Medical Center- 591 6 Hillcrest Cass Construction,Inc. Kyle P.Nelson 15,255.00 12/10 12/10 Rehab 113'12"RCP Storm Drain by CIPP P.O.Box 309,El Cajon,Ca. 92022 619-590-0929 592 3 2009 Sanitary Sewer Pipeline Replacement PR 09-593-52-211 D'Arcy&Harty Construction,Inc. Maeve Tuite 58,900.00 11/10 41 Top Hats,San Leandro,Ca. 1300 Carroll Ave,San Francisco,Ca. 94124 415-822-5200 593 6 3500 Golden Gate,Los Angeles Valverde Construction Mike Valverde 14,960.00 11/10 W.O.SWC01565 138'8"liner 10918 Shoemaker,Santa Fe Springs,Ca. 562-906-1826 594 3 City of Sacramento Basin 55 I&I Reduction Project Pacific Liners Pipeline Rehabilitation Douglas R.Sanders P.L.#2385CP 187,500.00 100 Top Hats 70 Union Way.Vacaville Ca. 95687 7071446-8222 595 6,3 City of San Diego Sewer&Water Grp.730 T.C.Construction Co.,Inc. Donna Kemp #10018-03 87,840.00 1276'CIPP 6",2 top hats 10540 Prospect Ave,Santee,Ca. 92071 619/448-4560 Ext 136 596 Sewer Grp.729 T.C.Construction Co.Inc. 619-448-4560 10019-04 22,845.00 San Diego 10540 Prospect Ave.,Santee,Ca. 597 50 E Green Street Sewer Lateral Y.K.A.Industries(for City of Pasadena) Joseph Krayndler P.O.8002 6,000.00 11/10 6103 Tyrone Ave.,Van Nuys,Ca. 91401 818-787-9216 598 Misc.Sewer Rehabilitation,NW Quadrant City of Carlsbad Kevin Davis 5503-1 219,850.00 1635 Faraday Ave.,Carlsbad,Ca. 92008 760-60202466 599 6 Secondary Sewer Renewal Program(SSRP)N09 Mike Prlich&Sons,Inc.for City of Los Angeles Fresno St.and Oregon St. W.O.SZC11739 5103 Elton Street,Baldwin Park,Ca. 91706 626-813-1700 755-01 26,002.75 600 6,3 Sewer Group Job 750 Burtech Pipeline,Inc. 760-634-2822 P.O.2010-016-3.7 15,480.00 264'6"lining,2 Top Hats 102 Second St.,Encinitas,Ca. 92024 601 6,3 Top Hats and Short Liner Contract Costa Mesa Sanitary District 949-468-9840 8,450.00 1/11 1/11 Costa Mesa 234 E. 17th St.,Costa Mesa,Ca. 92627 Yefin Tsalyuk GRAND TOTAL 2010 $ 13,113,993.06 2011 602 6,3 Sewer Group 739 Ortiz Construction 619-434-7925 WBS#13-00349 193,844.45 1/11 Rehab 2891'8"sewer,65 Top Hats 2000 McKinley Ave,National City,Ca.91950 Lucy Ortiz 603 6,3 Water Group 748 Ortiz Construction 619-434-7925 WBS#B-00356 30,155.00 1/11 Rehab 673'8"sewer,4 Top Hats 2000 McKinley Ave,National City,Ca.91950 Lucy Ortiz 13 X\Sharon FarmehSouthwest Pipeline and Trenchless Corp1SW 254 2005-Present xlsx Southwest Pipeline and Trenchless Corp.,License No.773862-A including U-Liner West and National Liner West Divisions Modified Standard Form 254 PROFILE JOB# CODE PROJECT NAME&LOCATION OWNER and/or GENERAL CONTRACTOR CONTACT INFO. CONTRACT AMOUNT START COMPLETE 604 3 Sewer Main Spot Repairs City of Carlsbad Kevin Davis PWM11-29UTIL 10,000.00 2111 1635 Faraday Ave.,Carlsbad,Ca. 92008 760-60202466 605 6,3 Sewer Group Job 745 Burtech Pipeline,Inc. 760-634-2822 P.O.2010-001 -103 54,125.00 2/11 2/11 895'6"lining,14 Top Hats 102 Second St.,Encinitas,Ca. 92024 606 6 Remove 150'8"HDPE City of Burbank Lifan Xu DPO#125578 6,470.00 2/11 2/11 275 East Olive Ave,Burbank,Ca. 91510 81823873932 607 3 San Diego Phase D-2 KTA.Construction,Inc. Shawn Moine KTA Job#09-10 2,600.00 2111 2/11 2 Top Hats 1920 Cordell Court#105, El Cajon,Ca.92020 619-562-9464 608 9 Link Pipe Removal(21 San Antoinio Trunk) County Sanitation Districts of Los Angeles County Bill Balas, Darrell Hatch Eastwater Collection Systems Section 10/909-3964,562/857-581 P.O.#R72604 3,000.00 2/11 2111 609 3 SSRP PI Marmion Way&Figueroa St. Mathew&Stewart Co.for City of Los Angeles Steve Radaich City of Los Angeles SZC11850 6 Top Hats on 8" 2841 Gardena Ave.,Signal Hills,Ca. 90755 562-595-5471 P.O.#1008 7,200.00 2/11 2111 610 3 City of Columbia Heights,MN 55421 Visu-Sewer&Clean&Seal,Inc- Keith Alexander 39,000.00 2/11 5/11 40 Top Hats in 8" W230 N4855 Betker Dr.,Pewaukee,Wi. 53072 262-695-2340 611 6 Sewer Repair&Rehabilitation East Side City of West Hollywood Sharon Perlstein,P.E. CIP 1104 1,564,387.60 3/11 24,310'8",354'12"CIPP Lining 8300 Santa Monica Blvd.,West Hollywood,Ca.90069 323-848-6383 612 6 Otay Mesa Spot Repair Underground Utilities,Inc. Valerie Murphy 2,500.00 3/11 3/11 9102 Harness St.#B,Spring Valley,Ca. 619-461-9500 613 10 Ocean Meadows Golf Course Trunk Sewer Rehab Proj 10-03 Goleta West Sanitary District P.O.Box4,Goleta,Ca. 93116 805-968-2617 422,500.00 614 6 SSRP N13 Cesar Chavez&Alameda W.O.SZC11848 SND Construction,Inc.for City of Los Angeles Lance Laven SZC11848 124,861.75 Rehab 3473'8"&12"sewer 2516 S.4th Ave.,Arcadia,Ca.91005 626-294-0558 615 6 Cast Iron Lining Phase II Project#S-22-S-098 Union Sanitary District John Stiggins P.O. 10000965 145,500.00 5072 Benson Road,Union City,Ca. 94587 510-477-7500 616 6 SSRP P10 Avenue 43 and Marmion Way W.O.SZC11847 John T.Malloy for City of Los Angeles SZC11847 154,971.50 4189'8"lining 3032 Bandino Blvd.,Los Angeles,Ca. 90023 323-780-9942 617 6 SSRP H04A Sunset Plaza Dr.&Rising Blen Road Mathew&Stewart Co.Inc.for City of Los Angeles Steve Radaich SZC11873 386,090.60 Reh 25,395'8"&10"sewer City of Los Angeles 2841 Gardena Ave.,Signal Hills,Ca. 90755 562-595-5471 618 3 Top Hats Charles King Co.Inc. Alden Dr.&Almont Dr. 2841 Gardena Blvd.,Signal Hill,Ca..90755 562-595-5471 14,400.00 4111 4/11 619 6 Sewer Rehabilitation Project No.3 Rancho Palos Verdes County of Los Angeles SMDAO0128 296,707.00 11456'11",989'10"sewer re-lining 900 South Frement Ave.,Alhambra,Ca.91803 626-45-4951 620 6 Cal Trans Hwy 16 Drainage Improvements 04-264904 Granite Rock dba Pavex Construction Division 4190-13 940,700.00 6280'18"-36"re-lining 120 Granite Rock Way,San Jose,Ca. 95136 408-574-1400 621 6 SSRP T03 Paseo Del Mar&Carolina Street-Re-bid MNR Construction for City of Los Angeles Robert Vasilj 201,236.75 not started 1051 Calle Ortega,San Dimas,Ca. 91773 622 3 2011 Pavement Management Project Visu-Sewer&Clean&Seal,Inc. Shaun Ritter 89,250.00 Golden Valley,MN 70 Top Hats W230 N4855 Betker Dr.,Pewaukee,Wi. 53072 262-695-2340 623 6 Wastewater Main Rehabilitation Project FY11,Bid No.4892 City of Santa Barbara Amanda Fleese 1,398,686.55 14 XASharon Farmer\Southwest Pipeline and Trenchless Corp\SW 254 2005-Present.x1sx Southwest Pipeline and Trenchless Corp.,License No.773862-A including U-Liner West and National Liner West Divisions Modified Standard Form 254 PROFILE JOB# CODE PROJECT NAME&LOCATION OWNER and/or GENERAL CONTRACTOR CONTACT INFO. CONTRACT AMOUNT START COMPLETE rehab 33,659'6"&8"sewer by lining 630 Garden Street.Santa Barbara,Ca. 83102 805-564-5424 624 6,3 Sewer&Water Group 780-City of San Diego Burtech Pipeline,Inc. 760-634-2822 45,160.00 rehab 170'10",320'6",12 Top Hats 102 Second St.,Encinitas,Ca. 92024 Buddy or Steve 625 3 Sewer Lateral Seal Repairs 2010-11 South Coast Water District 949-499-4555 39,740.00 30+Top Hats 31592 West Street,Laguna Beach,Ca. 92651 Joseph McDermit W.0.SZC1 1877, 626 3 SSRP E02 Ventrua Blvd.&Lankershim Blvd. Ramona,Inc,for City of Los Angeles 626-355-1350 W.O.SCZ12098 397,610.20 P.O.Box 660219,Arcadia,Ca. 96001 627 6,3 Sewer Maintenance/Repair Various Locations Cucamonga Valley Water District 909-987-2591 70,411.00 1924'relining 8"to 12",1 top hat 10440 Ashford Street,Rancho Cucamonga,Ca. Eduardo Espinosa,P.E. 628 5 SSRP P18B Verdugo Rd.&Ave.33 W.O.SZC11841 Ramona,Inc,for City of Los Angeles 626-355-1350 67,506.00 Rehab 1267'8",352'10"by lining P.O.Box 660219,Arcadia,Ca. 96001 629 3 SSRP H-04B Mathew&Stewart Co.for City of Los Angeles Steve Radaich 20,000.00 2841 Gardena Ave.,Signal Hills,Ca. 90755 562-595-5471 630 6 Year 2 Capital Improvement Project No.SF 620-2 Garcia Juarez Co, 951-657-3535 66,972.00 Fountain Valley 1812'8"-15"CIPP lining 4517 Wade Ave,Perris Ca.92571 631 6,3 Sewer&Water Group 740 Ortiz Construction 619-434-7925 18,440.00 Rehb by lining 240'8"sewer main,7 Top Hats 2000 McKinley Ave,National City,Ca.91950 Lucy Ortiz 632 3 Sanitary Sewer Improvements-2011 Visu-Sewer&Clean&Seal,Inc. 414-695-2340 315,675.00 207 top hats Corydon,Iowa W230 N4855 Betker Dr.,Pewaukee,Wi. 53072 Phillip S.Romagna 633 TC GRAND TOTAL 2011 $ 7,129,700.40 FURTHER INFORMATION WILL BE PROVIDED UPON REQUEST 1=sewer,2=storm drain,3=Top Hats,4=Sectional Liner Repairs,5=HDPE lining,6=CIPP lining,7=lnsitu Point Repairs,8=Channel line,9=Misc.10=Rib Loc 15 X:\Sharon FarmerlSouthwest Pipeline and Trenchless Corp4S W 254 2005-Present.x1sx ASTM TESTING LABORATORIES : Ramtech- 14104 Orange Ave., Paramount, CA 90273 Smith-Emery-791 E.Washington Blvd., Los Angeles, CA 90021 Twining- 2883 E. Spring St.#300, Long Beach, CA 90806 Cured-in-Plat Pipe(CIPP)Wall Thickness Design and Hydraulic Capacity ty p-- _ Project: City of Huntington Beach �T ra nr�l tlo Liner Location: Beach Blvd-Clarlkdale Dr.-Cliff al 6 a1 Drive Owner: City of Huntigton Beach Line Segment(s): Sewer Lining Area#1,#2,#3 Design Assumpf%ro F-1216 Shaded cells are user-defined Condition of host pipe FD PD=partially deteriorated,FD=fully deteriorated Inside diameter of host pipe(in) D= 8 Ovality of host pipe(%) q= 2.0 Default value is 2%;range=0%-10% Slope of host pipe(ft/ft) S= 0.000 Host pipe Manning's roughness(dimensionless) ni= 0.015 varies from 0.013-0.030(dependent on existing pipe material,geometry,diameter and condition) CIPP Manning's roughness(dimensionless) rp= 0.010 vanes from 0.009-0.013 Constrained soil modulus of native soil in the pipe zone(psi) M,,,= 1,000 See table below for recommended values From Table 5 6 of AWWA Manual of Water Practices M45,Second Edition Cohesive Native Soils Granular Native Soils Unconfined compressive M,,, F` strength(qu) Description BlowsiR(per ASTM '-_!y_...__.... ._._.._....__._..-_.__...._.......-._...._.__ 9'.._..lY..___._._ _._..............._ jr.�t„ 4�� C a D10 g21).. ve Vevecol se ---"-0:2500.25.._.__.. ._3-25._.._._ve yew soft_ft ..-2�_ ._..0.4 �n. Description tonsisf kPa psi kPa ............._....4__.a.................. .. 7..... .. ... ._......_...._.._.._...._-medium .._. ..---0.._.........'0........... ........................ . ...--- ---_.:I_.....---- --- -- _ ....__ .. �>� CQ58 38 2-4 0.25-0.50 25-50 soft __ 700 4 8 I l loose 0.50 1.0 50 100 50 3 .............__..........._.._.._........_--__......_......_.........._.......___...----.. _ ..__.___.._..__._._.._...----- .._. ...._.................._..... 8-15 sl' hU tom ct 1.0-2 0 100-200 stiff 3 000 20.7 .........._.1§._.34...._._.........._comps _...._......._....-_:�-_4:�. .200-.400----v_ery stiff._.-. 5_Q00....._...._34 5....... +. EXR 06130f/� ze•.� 30-50 dense 4.0-6.0 400-600 hard 10 000 89.0 >50 very dense >6.0 >600 ve hard 20,000 138.0 r, CMIII Flexural modulus of Eelasbctty of CIPP,initial(psi) E= 250000 Minimum value is 250,000 psi per ASTM F1216 Long-term retention of mechanical properties % 50% Default value is 50% OFt,-Au.,• r }�,, 1 Flexural modulus of elasticity of CIPP,long-tens(psi) EL= 1257000 Determined from long-tens retention% � // Design safety factor IN= 2 Default value is 2.0 .� Y� Unit weight of soil(pcf) 55= 120 Applies to fully deteriorated designs only 8 62.4 ,� Unit weight of water(pcf) .= Depth of cover(ft) H= 10.0 Measured from ground surface to top of pipe Height of groundwater(ft) H.= 7.0 Measured from top of pipe;Note:If water table is below top of pipe,input a negative number! Internal vacuum pressure(psi) P,= 0.0 Default value is 0 Internal pressure(psi) P= 0.0 Pressure pipe applications only! If no pressure,input 0 Diameter of hole or opening in original pipe wall(in) d= 0.0 Pressure pipe applications only! If no pressure,input 0 Poisson's ratio of CIPP v= 0.30 Average value for CIPP per ASTM F1216 Flexural strength of CIPP,initial(psi) a;= 4,500 Minimum value is 4,500 psi per ASTM F1216 Flexural strength of CIPP,long-term(psi) -L= 4,500 Determined from long-term retention% Tensile strength of CIPP,initial(psi) aT= 3,000 Pressure pipe applications only! Tensile strength of CIPP,long-term(psi) o,= 750 Determined from long-term retention% Enhancement factor(dimensionless) K=J 7.0 Minimum value recommended per ASTM F1216 Surface live loading condition H2O H2O,E80 or airport H2O Calculations(Highway Loads) Impact factor for traffic load(dimensionless) W= 1.0 From AASHTO Standard Specifications for Highway Bridges,12th Edition Distributed load area over pipe at depth H(ft") ALL= 517.4 See table and figures below Total applied surface wheel load(lb) PLw= 48 000 Based on critical loading configuration(see table below) H2O live load transferred to pipe at depth H(psi) wLa= 0.6 wL=(P-I,)/(144-Au) Critical Loading Configurations for H2O loads(per AASHTO) Condition H,R 1 P,Ito A_ 1 H<1.33 16 000 0.83+1 75H 1.67+1 75H 2 1.33 s H-4.10 1 32,000 0.83+1.75 5.67+1.75H 3 4.10 s H 1 48,000 4.83+1.75H)(5.67+1.75H) ° viaem Loaf A,ea W.,O Lm:e Ana, qm f `, _ -tvhed Lcad Aaa �" ?tihtei Lcnd A:eu. yf�\ v:eeua Laid a,em� t 1\ ! j 4�. Loea A ��.� N\tip L5e�5 .� ' `moo. ,r`� ) - "sa_+��>),•� . ..-�%,•-F:.�, ro f-- oiro-m�,w ,� B' VVII -D„nit�ied L-i Alm Condition 1.Distributed Load Area-Single Dual Wheel Condition 2.Distributed Load Area-Two H2O Trucks Passing Condition 3.Distributed Load Area-Alternate Loads in Passing Mode E80 Calculations(Railway Loads) E80 live load transferred to pipe at depth H(psi) WM= 0.00 from graph below E80 Live Loads on Pipe Installed Under Railroads (From Concrete Pipe Handbook 5th Edition) io 000o a000 0 0000 000a u ov woomaco 000 0u-,00,n Et 0.n 0v 0�0ao0w0co $ 0lb per C:ttin it i.. 25 I 1 , r,�1 s. 0 '1'". 20 m 5 8 5'5'5' 9' 5'6'5' 8' 8'5'5'5' 9'5'6'5'5' 'o n o a 0 10 211 30 6 Figure 4.30. Spacing of Wheel Loads Per Axle for a Unit Load(psi) Cooper E 80 Design Loading. 'm x CIPP Design Template 7/15/2011 NEK Airport Loads Modulus of elasticity of concrete(psi) Ee= 4,000,000 default value is 4,000,000 l Poisson's ratio of concrete(dimensionless) tr= 0.15 default value is 0.15 CALIFORNIA BEARING RATIO,CBR Modulus of subgrade reaction(lb/in) k= 250 see adjacent figure 2 3 5 6 7 8 910 15 20 25 30 40 50 60 7080 100 Thickness of concrete pavement(in) h= 12 Depth of cover,top of pipe to bottom of slab(it) H= 9.0 UNIFIED SOIL CLASSIFICATION Horizontal distance from pipe centerfine(ft) X= 0 assumed=0(worst case) Corps of Engineers U.S.Army Radius of stiffness of the rigid pavement ft F Eh a U.S.Bureau of Reclamation 121-µz � V 7� Wheel load(lbs) Pu= 18,000 ' AASHTO SOIL CLASSIFICATION Federal Highway Administration Worst-case loading scenario is for 2 loads spaced 0.8Re apart and is calculated below. I For alternate loading conditions,see Concrete Pipe Handbook,5th Edition Pressure Coefficient(C)for X(ft=0 2 loads 0.8 Rs I I 1 l t 1 apart along FEDERAL AVIATION AGENCY axis of pipe I Soil Classification 0.25 i y=-0.0005x3+0.O10lx2-0.0756x+0.2162 a. -..: ..- ,Fm, °•a I I I- It 02 -- -_-- N X 1 i i I 0.15 I RESISTANCE VALUE,R so �•o ao es� ao � to eo I w l 0.1 I MOO SOUS OF SUBC RAGE REACTION,k,psi per inch leol> 0.05 I I so H/R,= 2.756 I I BEARING VALUE.psi C= 0.074 00.in.diameter plate,0.Nn.deflertioo) w 0 0 2 4 6 8 10 s ! CA fit ORNIA BEARING RATIO,CBR ! I HIRs o a.-L Airport live load transferred to pipe at depth H(psi) -L.=F wu=CP/Rey Wall Thickness Design Partially Deteriorated Gravity Pipe Condition 3 C= 1-q/100 Ovality reduction factor(dimensionless) C= O.B4 [1+gl1OOP External hydrostatic pressure from groundwater(psi) P.= 3.32 P.=U.(H„+D/12)/144 D Minimum thickness required,hydrostatic buckling tt= 0.73 In t+= ASTM F1216,Equation X1.1 3.21 min [[V2 K E,,.0 +1 Minimum thickness required,ovality,check tz= 0.05 In 1.5 100(1+1��-SDR?-0.5-�1+1 �•SDR-P=0 ASTM F1216,Equation X1.2 1.36 mm SDR== 150 If P.=0,default SDR=100 Quadratic factors for Eq.X1.2 a= 0.0306 used to solve for SDR2 and t2: b= -0.510 c= -677.258 Fully Deferiorated Gravity Pepe Condition Total live load transferred to pipe at depth H(psi)= W.= 0.64 From live load calculations Water buoyancy factor(dimensionless) Ft.= 0.77 R„,=1-0.33(H„/H) (min.value=0.67) Note:8 HW<0,use H.=0 in this calculation Total external pressure on pipe(psi) Ch= 10.37 q,=0.433H„.+°S,HR„1144+W. Note:If H„<O,use H.=0 in this calculation Coefficient of elastic support(in-lb) B'= 0.324 B'=1/(1+4a'am") 1 See Note X1.3 regarding use of tunnel load 113 Minimum thickness required,Luschefs budding r q g equation t3= 0.15 in r_I (N9,) 'D''t 2 � ASTM F1216,Equation X1.3 min= 3.73 m 32.R,�B-M„.F,-C Minimum thickness required,pipe stiffness ti= 0.13 in =1 3.35 Imin t=D/(E/0.093-12)tn ASTM F1216,Equation X1.4 Partially Deteriorated Pressure Pipe Condition Minimum thickness required to withstand internal pressure tw=W000 in tr,=Dfq(D/d)2_(5.33 ac/PN))"�+1) ASTM F1216,Equation X1.6 in spanning across any holes in the original pipe wall d1= If d/D>1.83-(te,/D)'s,ASTM F1216,Equation X1.5,then liner is in ring tension or hoop stress 1.83(te,/D)"n= and fully deteriorated pressure pipe condition applies(ASTM F1216,Equation X1.7) Minimum thickness required by design check tent= in min Fully Deteriorated Pressure Pipe Condition Minimum thickness required to withstand all external t,= 0.00 in t�=D/((2an/PN)+2) ASTM F1216,Equation X1.7 loads and the full internal pressure = 0.00 mm CIPP Wall Thickness Design Summary Host pipe condition Fully Deteriorated CIPP end use application Gravity Flow CIPP outside diameter(host pipe inside diameter) D= 8 in Minimum CIPP thickness calculated t-= 0.15 in Greatest value calculated from ASTM F1216 Equations X1.1,X1.2,X1.3 and X1.4(gravity = 3.73 min flow)or greatest of X1.1,X1.2,X1.3,X1.4 and X1.7(pressure pipe) Minimum CIPP thickness recommended t„-= 0.15 in Based 3 min on a maximum SDR=100 Nominal CIPP thickness to be supplied tcvP= 4.5 mm Rounded up to the nearest 1.5 min to reflect standard CIPP thicknesses supplied SDRca,= 45 SDR=Dtt Maximum recommended SDR for CIPP is 100 per ASTM F1216 DESIGNED BY CHECKED BY CIPP Design Template 7/15/2011 NEK Document A310 TN° ® 2010 Conforms with The American Institute of Architects AIA Document 310 Bid Bond CONTRACTOR: SURETY: (blame, legal stcrtt(.v crud addrevv) (Maine,legal slants card principal place c f husiness) Safeco Insurance Company of America Southwest Pipeline and Trenchless Corp. 1001 Fourth Ave, Safeco Plaza 539 W. 140th Street Seattle, WA 98154 This document has important legal consequences.Consultation Gardena, CA 90248 Mailing Address for Notices with an attorney is encouraged with respect to its completion or OWNER: modification. (Xame,legal status and address) Any singular reference to City of Huntington Beach Contractor,Surety,Owner or 2000 Main Street other party shall be considered plural where applicable. Huntington Beach, CA 92648 BOND AMOUNT: $ 10% Ten Percent of Amount Bid PROJECT: (Xaine, location or address andProject number,ifm{i) CC-1396 Sewer Rehabilitation Project CC-1396 Huntington Beach, California The Contractor and Surety are bound to the Owner in the amount set forth above,for the payment of which the Contractor and Surety bind themselves,their licirs,executors,administrators,successors and assigns,jointly and severally,as provided herein.The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the tine specified in the bid documents,or within such tine period as may be agreed to by the Owner and Contractor,and the Contractor either(1)enters into a contract with the Owner in accordance with the terms of such bid,and gives such bond or bonds as may be specified in the bidding or Contract Documents,with a surety admitted in the jurisdiction of the 1'rgject and otherwise acceptable to the Owner,for the faithful performance of such Contract and for the prompt payment of labor and material furnished in die prosecution thereof,or(2)pays to the Owner the difference,not to exceed the amount of this Bond,between the aniount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work:covered by said bid,theft this obligation shall be hull and void,otherwise to remain in Bill lbrce and effect.The Surely hereby waives any notice ol'an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid.Waiver of notice by the Sorely shall not apply to any extension exceeding sixty(60)days in the aggregate beyond(lie lime for acceptance ol'bids specified in the bid documents,and the Owner and Contractor shall obtain the Surety's consent f r an extension beyond sixty(60)days. If this Bond is issued in connection iwith n subcontractor's bid to a Contractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been iiirnished to comply with a statutory or other legal requirement in the location ol'the Project,any provision ill this Bond conflicting with said statutory or legal requirement shall be deenied deleted herelrom and provisions conlornling to such statutory or other legal requirement shall be deemed incorporated herein.When so I'umished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. Sighed and scaled this 13th day of July, 2011 Southwest Pi eline and Trenchless Corp. (Principal) (Seal) STEVEN R.VOSSMEYER (!f'iuress) PRESIDENT(TREASURER HWEST PIPELINE AND rt e) I KtNUHIESS CORP. Safeco Insurance Company of America (!f itr tic Noe Quiroz y: itle) I a . o n on rney-In- ac S-0054/AS 8/10 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California ) ss County of Los Angeles ) On JUL 13 2011 , before me, Noemi Quiroz, Notary Public, personally appeared Lisa L. Thornton , who proved to me on the basis of satisfactory evidence to be the person{ whose name{&} is4F,- subscribed to the within instrument and acknowledged to me that he/she/44ey executed the same in #is/her#heiF authorized capacitv4e54, and that by 41s�herA*�;_4 signature{&} on the instrument the person{s�, or the entity upon behalf of which the person4&}acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature: (Seal) Noemi Quiroz, Notary Public ApEM1 AUIpOZ Commisslon 194 5 Notary Publle-Calftmia z Los Angeles County My Comm.Expires Jun 26,2015 THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. 4646644 This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. SAFECO INSURANCE COMPANY OF AMERICA SEATTLE,WASHINGTON POWER OF ATTORNEY KNOW ALL PERSONS BY THESE PRESENTS: That Safeco Insurance Company of America(the"Company'),a Washington stock insurance company, pursuant to and by authority of the By-law and Authorization hereinafter set forth,does hereby name,constitute and appoint E.S.ALBRECHT,JR., C.K.NAKAMURA,LISA L.THORNTON,ALL OF THE CITY OF LOS ANGELES,STATE OF CALIFORNIA................................................................................................... ................................................................................................................................................................................................................................................................................. ................................................................................................................................................................................................................................................................................. each individually if there be more than one named,its true and lawful attorney-in-fact to make,execute,seal,acknowledge and deliver,for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations in the penal sum not exceeding FIVE HUNDRED MILLION AND 00/100************************** DOLLARS($ 500,000,000.00**************************"* )each,and the execution of such undertakings, bonds,recognizances and other surety obligations,in pursuance of these presents,shall be as binding upon the Company as if they had been duly signed by the president and attested by the secretary of the Company in their own proper persons. That this power is made and executed pursuant to and by authority of the following By-law and Authorization: ARTICLE IV-Officers:Section 12.Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject to such limitations .O as the Chairman or the President may prescribe,shall appoint such attorneys-in-fact,as may be necessary to act in behalf of the Corporation to make, y execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Such attorneys-in- a fact,subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and c_ d executed,such instruments shall be as binding as if signed by the president and attested by the secretary. .N N +mod, By the following instrument the chairman or the president has authorized the officer or other official named therein to appoint attorneys-in-fact: _ � ea 15 Pursuant to Article IV, Section 12 of the By-laws, David M.Carey,Assistant Secretary of Safeco Insurance Company of America, is authorized to — C 2 appoint such attorneys-in-fact as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety v F-0 C any and all undertakings,bonds,recognizances and other surety obligations. d W c `m > That the By-law and the Authorization set forth above are true copies thereof and are now in full force and effect. 0 C. a IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Company and the corporate seal of ch Safeco Insurance Company of America has been affixed thereto in Plymouth Meeting,Pennsylvania this 15th dayof June O 1 0 2011 m.c L F?"`' ...... , SAFECO INSURANCE COMPANY OF AMERICA 3 cc ai 0. U �A<r� rr, a E Y {Q V! By , o IM rn David M.Carey,A rstant Secretary of i COMMONWEALTH OF PENNSYLVANIA ss 0 to COUNTY OF MONTGOMERY m 0= 'a� E 6 On this 15th day of June 2011 before me, a Notary Public, personally came David M. Carev, to me known, and d p acknowledged that he is an Assistant Secretary of Safeco Insurance Company of America; that he knows the seal of said corporation; and that he >.0 executed the above Power of Attorney and affixed the corporate seal of Safeco Insurance Company of America thereto with the authority and at the t C-qD 0 direction of said corporation. w'C4 > ` IN TESTIMONY WHEREO , vex subscribed my name and affixed my notarial seal at Plymouth Meetin , Pennsylvania, on the day and year h co M 0 first above written. �� ca € tanat seal o 0 Teresa Paste ia,Notary�uNio � /�'� RymnuW Twp.,Montgomery County By 0� OF my Commis .Expims rear.28:2013 Tere a Pastella,Notary Public F-�- CERTIFICATE hiembe;:Pennsy uaniaAs?ociat;or,at Uotaaes I,the undersigned,Vice Insurance Company of America,do hereby certify that the original power of attorney of which the foregoing is a full,true and correct cc orce and effect on the date of this certificate;and I do further certify that the officer or official who executed the said power of attorney is an Officer specially authorized by the chairman or the president to appoint attorneys-in-fact as provided in Article IV,Section 12 of the By-laws of Safeco Insurance Company of America. This certificate and the above power of attorney may be signed by facsimile or mechanically reproduced signatures under and by authority of the following vote of the board of directors of Safeco Insurance Company of America at a meeting duly called and held on the 18th day of September,2009. VOTED that the facsimile or mechanically reproduced signature of any assistant secretary of the company,wherever appearing upon a certified copy of any power of attorney issued by the company in connection with surety bonds,shall be valid and,binding upon the company with the same force and effect as though manually affixed. 1 IN TESTIMONY WHEREOF, I have hereunto subscribed my name affixed the corporate seal of the said company,this_1lli J 201day of 01i*fl �1 . O Gregory W.Davenport,Vice President