Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Sully-Miller Contracting Company - 1967-08-03
pnolv5508 PAGAG7 199STR NOTICE OF COMPMTION NOTICE IS HEREBY GIVEN that the contract heretofore awarded by the City Council of the City of Huntington Beach, California, to Sull -llil.ler Contracting Cam any who was the company thereon for doing the following work to-wit: Reconstruction, surfacing , and improvement of Golden- west Street , between Summit Avenue and Talbert Avenue , in said City of Huntington Beach. BOGK5508 PAGE G7 RECORDED AT REQUEST OF �•` MTY or IIUNII mou DEAcH IN OFFICIAL 11EGot- 7S ur ORANrE (•OUN:'Y, CALIF. 9:05 AM NOV 14 1960 RUBY McFARLAND,Count! Recorder FREE That said work was completL-d by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that eaid work was accepted by -the City Council of the City of Huntington Beach at a regular meeting thereof held on the r November 71 1960 r■-.rr.+�r That upon said contract the Federal Insurance_ Companyr�.__ was surety for the bond given by the said company as required by lair o Dated -at- Huntington Beach, California, this the 10th day of "November 1960 City- er an e pfficio Ole of the City Co it of the City of Huntington Beach, California STATE OF CL LIFOUTA County of Orange Be : City of Huntington Beach I . Paul. C . Jones , the duly elected , qualified and acting City Clerk and ex—offieio Clerk of the City Council of the City of Huntington Beach, Ca'l.fornia, do hereby certify that I have read the foregoing NOTICE OF COMPLETION and know the contents thereof and that same is true cf my ovn knowledge , and that said 110TICE OF COMPLa jION was duly and regularly ordered tc be recorded in the Office of the ,County•. Recorder of Orange County by said City Council . ' DATED at Huntington Beach, California, this the loth day of Novembef" 1900 City Clerk and -off cio Cl.er of the City Co ail. of the City Of Huntingtcn beach , California j AGREEMM THIS AGBEMiT p made and entered into an of the ,„_,,,day of 19ka °„_,,,,,,,fl by and BETWEM CITY- OF HUNTINGTON BEACH, a Municipal corporation,, hereinafter called CM AND SULLY-MILLER CONTRACTING CO. Heroin ter called COETRACTOR WI M ESSETB: WHEPMASiv the 'City Council of the City of Huntington Beach, County of Oranges State of California, pursuant to statut:;;: In such cases made and provided, dkX,y and regularly caused a notice to be publi,shedp palling for bids for labors material, tools and equipment for the reconstruction, surfacing, and improvement of Goldenwest Street, between Summit Avenue and Talbert Avenue, In eaid City of R ,, tington Beach,, California, said work to be construoted R--4ozAAm$' to pawns, specificatious and special l rovi.sions for same on file in the office of the City Engineer axed ariopted by the City Council of said City of Huntington Beach on tba .�„ �th dray of IMF. 19 by to which eaid pl�ews D specifieatione and special provisions reference i a hereby made s and by such reter- once they are made a part of this contract as if herein aet out in full, and SAS, the City Council at a ragnIar meeting thereof and at the time and place appointed tharefor opened the bids eubmi.tted by the reapective bidders for the aonstructior and completion of the above mentioned workp and after careful consideration of all bids submitted the City Council awarded the contract therefor to the Contraotar .herein named at the prioes eet forth in its bidR it being the lowest and beat bid received by the ®aid City Council, HOW in consideration of the covenants and agremtnts herein, oontainedp being done and performed by the parties hereto, it Is hereby agreed as followa: b� to The Contractor, under the direotion and to the satisfaction of the City Engineer of the City of MmUngton Beaohs acting as its agents shall and will provide all fsterials and perform all work mentioned in the specifications and special provisions or shown on the plane for the construction of the work herein- above referred to and more particularly set out in said planes specifications and apscial provielonos except as hereinafter stated. 2. t:`.) alteration or addition shall be made i^ the work shorn or des- cribed by the draw-l.ngs, specifications or speoi&l provisions. go extra work shall be performed or paid for unless the City of Rmtiugton Beach shall bave fssueds prior to the beginning thereof, its written order therefor. 3. SU UNLU : tie Contractor shall give his personal attention to the fulfillment of this contracts Aare subr-oontreotors sre engaged on the works they will be recognized only an employeea of the Contractors and no aub-contractor shall. under any circumstances relieve the Contraotor or surety of their liabilities and obligations under this contract„ and all transactions with the City Council ehs12 be through the Contractor herein named 4. �. ,.. , .MOM=i The Contrao+#- , at its own coot and charges shall fah the neceseary applianveao implmzutaa tooles, molds, ways and mews and all necoeeary conveniences for the transfer of the material to its proper place in the work, and Acid City shall• not be hold responsible for the care or protec- tion of any materiel or parts of the work, except an in the specifications or apeoial provisions expres©Ij provided, 5L ,,, EREWATU-N.. ,.ZWS Should it appear that the work herein con•- teaplated, or air of the mattors relative theretos are not sufficiently detailed or erplailmed in said specifications or speoial provi.sioney the Contractor shall apply to the City Engineer for such further explanations as may be necessary and shall conform to the same an part of this contracts ao far as may be consistent with the original specifications, emd special provisions bo The work is to j commenced within 15 days after approval of the oontwaot to to fo"ms by the Citlr Attorney of said City acid is to be diligently proeeouted to completion in suoh order and manner of progress as the City Fngineer =W from time to time prescribe 7. SAMMI.St1� if any person employed by the Contractor shall appear to the City Engineer to be faoompetert or to act in a disorderly or improper manner9 he shall be diechaarged immediately on the requisition of said City 2. &igineer# and auoh persau aball not again be employed on the works 0•. gWMRMgP OF CQ, wirer the Contractor in not present on any port of the work where it my be dead to give direction, orders will be given by the City Engineer and shall be received and obeyed by the superintendent or foreman who may have charge of the particular work is referenoe to which the orders axe given. 91 DFTC1' RIMAM OF CONMG : if tb%a Contractor should be adjudged bankrupts or if It should makes a general assignment for the benefit of creditorao or if a receiver should be appointed on account of his insolvency, or if Contractor should persistently or repeatedly refuaeo or should fail, Mwept in canaR ^)r which extensioh of time j.a provided9 to supply enough. Properly skil- led workmmzi or proper meter-alai or if he should fad to make prompt po ment for mateelal or labor# or persistently disregard lawaq ordinances or the instructions of the Ci♦.►# or otherwise be guilty of a substantial violation of any provision of the eontraot i then the City upon the certificate of the City Engineer of the City of Hu xiti ngton Bewh that sufficient owmQ exists to justify such notion, W without pro juAIoo to say other idght or remedy,, and after giving the Contractor fifteen (15) dam �� ten notice9 terminate the employment of Contractor and take possession of the •premist)s and of all materialop tools# and appliances thereon, cad finish the work by whatever method it may deem expedient. In such vase the Contractor shall not to entitled to reoely� any further payment until the work is finished. If +Jio unpaid ba3ance of the contract price hall exceed the expense of fininhing the work, including compensation for additional mar. a1 and admini- strative work or servicea# such ezcoos shall be paid to the Contractor. If such expense shall a4oeed such unpaid balance„ tho Contractor shall pay the difference to the City. The expense incurred by the City ea herein providedp and the damage incurred through the Contraotorle defaults shall be certified by the City sneer of the City of. Huratington Beach„ 10.2 LAWS TO BE OBSFRM: (a) The Gantraotor shall keep himself fully informed of all exis~ing and future State and Federal laws and n unicipal ordinances sous regulations in any manner affecting those engaged or employed in the work, or the materials used in the work, or in any wear affecting the conduct of the works ar ' all such orders and decrees of bodies or tribunals having any juri.ediotion or autho- ty over the same. If any discrepancy or inoonBistency is discovered in the planes drawingsp specifications or special provisioner or contract for i:.Ide work in rylation to any ©arch laws, ordinenoeop, regulations order or decree, he shall iortlav2ih s©wort tho -- -•o Lo the Ci Gy I= stx'1Ling<, Se o .Z1 gL Ei12 LimQO h1ID�l4�S 30 ubserve and comply wi.thq and shall cause all his agents and Mployeee to ©::serve ;red comply wi-% all such existing and future lawns ordinsncesp regulation, orders and de creee, and sl all protect and indemnify the said City, the City Council and City &gIneers and its and their officers, agents and servants against any claim or liability arising Prom or based on the violation of any such law* ordinencep regulat�.on, order or decree whether by itself or ita employees. (b) The Contractor a'zeil, before entering on the performance of the work herein provided, furnish u bond in the cum of fifty (50) per cent of the con- tract pric-+. ae .required by the terms of Sections 4200�4205 of the Government Code of the State of 0aiifoavj.a,, (c) zn the employment of labor the Contractor shall give preference,, other 1;lOnga being equal* to honorable discharged coldliers eail.ore and marlines, and resident laborers, but in ©uoh connection there shall be' no other preference or dieorimintiori among of 4iz4n of the United States. n o MP3A'fMl' OF s Pursuant to tho provisions of the Labor Code of the State of Californiia, no persons firm, partnership,, association or eorpomtionj or agent thereof, doirg any work as a contractor or sub-oontraotor upon ply public work being done for or under the authority of this Stater or any offi.Qer or department thereof, o•,� for or under the authority of any county9 oity and county,' city, towug townships district or wq other polittoal nubd:• ision thereof,; or any officer or department `11%tireofq shall kno%ingl.y employ or osaee or cLUow to be employed thereon' any mien - meaning thereby any person not born or fully' iatura.31zed citizen of the United States a except in oases of e'xtrsordina7 emergency caused by firma f Zaod or danger to life or propertyp- or e=oent- to work ripon public military or naval defeneeu or xorko in time of war; provided, norevert that wit1da W�-V (30) days aftor air alien is' permitted to work thereon: due to extra6anary emergency, the Contractor doing the work or hie authorized egaut ehan file with the officer or' public body awarding the aontrsiot a reporto irerified: by hior bath, setting forth this nature of the said emergew)y and containing the name of the said mien and each data he was permitted to work, And failure to file said �-mport within' said time shall be' prima Ya,ci a evidence that no eubh exira6rd.3nary em6rganey exietedo Such Contis3otor and each sub-contractor shall ales- keep, or cause to be. kept, an accurate record showing the name and cit;zenabip of all workers amployed by himp in connection with the said public work9 which retard shall be open' at all reasonable hours to :he inspection' of the offioer or. public awarding the cr►ntract, his or its deputies and agent43 and to the Chief of the Division of Labor Statinti.os and Law Fo-torcctsment9 his deputies and agents., 4, It is further understood and agreed that for each violation of the above stipulation, said Contraotor shall forfeit to the City as a per.-,lty, the sum of Ten (310.00) Dollar® for ©a►oh day or portion thereof during which each such 91'can is fa:owingly employed in the exeoution of thio Weem ent, b,- said Contractor or by any sub-contraotor under Him, in Aolati.on of this stipulation and the provision d of the Labor Code of the state of California. 12. That in the performance of this agreement, prices, fitness and quality beJmg equal,, the Contractor agrees that he will use supplies end mat- er-'al.s grown, manufactured and produced in the State of California and that sub- Jeot to the above provision he agraes :.a the perfor.,,-A=e cf the work contemp- lated hereunder to use only such ur"anufacturad materials as have been produced in the United States, and only such manufactured materials an have been r�anu- faotured in the United States, substantially a31 from materials produoed in the Vnitted States 13, F"Ll1: CONVENIENCE AND SAFM t (a) The Contractor mist arrange to take crre of the existing Ling traffic, no as to inconvenience the general public an little as possible. Residents along the road met be provided for as far as practicable. Temporary approanhes to crossinge or inter:;ecting highways must be provided and kept in good condition where required by the City sneer. (b) The Contractor shall provide and mmintain suoh fenced, barriers, signsp redlighke and watchmen and other means as may be necessary to prevent acci- dents to the publ.io. It shall be necessary that the plane at the points desig. nated by the City Enginear such warming signs as ray he d.esignated. !,.y the said City Engineer, and he shall provide white lights as soy be ne;essaxy for i. i ng the said nignao (a) The Contractor shall care for publio traffic, an required and dir. ected by the City Engineers Detours used by the Contractor emolu.sively for haul- f :Lug materials and equipment shall be constructed and maintainer: by him at his ©xpeneeo 14. FFBESER.VATION 013 PROPERTY: The Contractor ehallp at his awn expense, preserve and prntect from injury the roadside trees by covering the trunks vrith bur- lap or drive stake& around then when required by the City *W_*ueer. 15. FMPOW31B aTr RR DAMGE: The City of Huntington Beach, the City Councils and the City Engineer will not in any manner be answerable or accountable for any lose or damage that shall or may happen to the said work or any part there.- GP, or for any of the materials or other things used or employed in finishing and completing the work; or for the injury to any person or personn s either, workmen or the publics .for dema-Ve to 641 joining property from W cause zhieh mf'jftt have been prevented by the Contraot-or or his workmen, or by any one employed by hims agai.nat all of whioh injuries or damages to persons and property the Contractor must properly guard zmd must make good all demages from any cause whatever, being strictly reepomlbl.e for any damage to W. person or property resulting from defeats or obstruction, or from W cause w-ha-tsoevex, during the progress of the worm or at any time before the completion =d final acceptance thereof, and that sad Contractor will indemnify and save hajmless the said City, the City Counci" and the City Engineer from all si*.te or actions of every name and description brought for or on aocoui:t of any injuries or damages reevivei or sustained by any person or persons by or from said Contractors its servants or agents, in the con- struction of said works or by or in oonseauenoe of ery negligence in guarding the es=D in improper materWa used in its congtraotion, or by or on r-ccovnt of any act or rs.xioaion of the Paid Contractor or WLs agentep and the ssid Contractor further agrees at all times to carry publio liability, property damaged firep earth- quako and aorkmang a compeneation innurenoe satisfactory to the City Engineero eov. eeing all work being done under this contract, and for any lose to the Contractor by any oausez The City of Huntington Beachp the City Counoil, and the City Engineer wiIl not under any circumstances be answerable or accountable The Contractor shall furnish to the City of Huntington beach oerti.ficate and evidence of all such comp3.anoe b nth before said work IM begun and dur+I g its performaneo, 16. L-DiES AED GRAMS z 17he Contractor is to furnish,, free of c harge p ail labor neceess ry for marking and m Antaining points and linen gi von by the City Engineer and is to give the City Eagineer such facilities and labor for giving said lines are, points as he may require, whioh said marks Faust be carefully pre. served. 17 o TESTS OR , lls x All tests of ma-terials furnished by the Contracts aball be wade by the City ErSineer in accordance with euoh methode as he may from time to time adopt. 18o �,UA = OF MATERIMS; All materials used sn the work shall meet ..._..._�. ...,..v..m... the requ3.xements of sold specifications;! and no materials shall be used until it h&-a the approval of the City Engineers Samples will be secured and tested when nea- eaaay to determine the quality of materials. Laboratory tests will be made as promptly as possible so as not to inconvenience the Contraotor. 19. ST4itAGE OF BdATE IE?-ter'lals oha-11 be stored eo as to insure the preservation of their and fitness for the work, Suoh stored materialb shall be located so as to facilitate prop._: inal .otion, M 20, MB=IOA: The City Engineer emd hie authorized assistants shall at 01 times have aehese to the cork during i,ta construction and shall be fur- nisbi-d with every reasonable facility for aso©rtaining that the stock and mater- ials used and employed,; and tho workmanshipq are in aocordanoe with the require- melts and intentions of this contraoU All work done and all materials furnished taail be subject to the inspection end approval of the City Engineer, J . 210 DES TIVE TALR AND WORKS (a} ThP i mpection of the work shall not relievo the Contractor of any of hin obligations to fulfill his contract as herein preavri.bedn and defective work shall be made goodp and all unsuitable mater- isle may be rejected, no terl.thatanding that such defective rort and materials have been Drevioualy overlooked by the City Eng-, -teen and aocet ted or estimatel for pay- ments, If the work or any poi~ thereof .shall be found defective at any time before final acceptance of the whole work, the Contractor shall forthwith sake good zuah defeat in IL manner skt;' iefaotory to the City '.engineer, (o) The Contractor shall, after receiving written notice from the City &4rineer to that effect, proceed to remove to a sati sfaotrry distance f=hi the work all materials condemned by the uaid City Engineery Whether worked or unworked} and remove all �i.ona of the work whioh the said City Engineer shall condom as unsound, improper, or as in any way failing to oonform to the specificati.ans and shall urver, protect and exercise due diligence to so-.ure the work from ix►�usy, All damage happenir_g to the cane shall be mado good by the Contractor. 22-0 01SOING UP: (a) After tno completion of said wari: the Contractor shall remove all temporary otractureo built by it and all surplus materials of all kinds from this site of the work and leave the whole clean and vr©©entable., (a) If ordered by the City Engineor, the br,. -A and other oombua-bible debris sbaU be pilod in thecenter of the roadway or other clearing and buzued. 230 7-M OF COTLE`I'ION An LIQUI.DATM DAtGES: (a) It in agreed that in the event all wor'; oallod for imda�r nand contran t in all. parte and re:lPi re.. mente is no; comnletod before the oxpiral;.ion -)f 30 a (Sunday© and holidays exolunivo) .from of execution of this contract as tpproved by the City Attorney of oaid City of Huntington Beacha damage will be sustained by the said City,, and that it is and will be difficult to ascertain and determine the actual damage which paid City will auntain in the event of and by reason of such delay; and it is therefore agreed that said Contractor vi.l,l pay the 7- fe auAd City tho ©um of Fi Y ($50. 00) Dollars per Any for earth and every day's delay beyond the time herein prescribed in finiW ng the said woz c, In case said liquidated damages are nA paid by saie actor. said city Council may deduct the amount therefor from any money due or tha; may beoome due Said Contractor under thin contract (b) It in further agreed that in case Whole work called for under this contrarot is not finished and -lompleted in all parts and requirements witty a the time heceinbefore apeeified9 ©sic City Coumill shell have the right to extend the time for completion, if shall seem beat to serve the interest of the Cityp and should ea ft City council decide to extend the time limit for completion of thjl© contreotp it shall further have the right to charge to the Contractor, its hoirep assigns or sureties, and deduct from the final payment for the Torkp &U or any part,; an it shall deem proper, of the actual cost of engineLrings inspection,, superintendence and inoidental overhead expenses which are directly chargeable to euor extension and which accrue during the period of such extension. 24. ,MUiAMT OF COHMCTs Whenevorp in the opinion of the City Council. the said work is negleoted by the said Contractor or the c;,,me is not prosecuted with the diligence and force specifi.edp meant and intended in any manner by the tesan of this contract, it shall be lawful for said City Council -to make a req. uieltion upon said Contractor for such additional specific forsze or such addit- ional material to be brought into the Rork under this contraotp or to remove improper material, from the grounds as,, in the judgment of said City Council9 this contract and its due and faithful fulfillment mV require. Due notice of ouoh action shall be served upon said Contractor or his agent, in writingq not Leas eAu five (5) days prior thereto, and if said Contractor fails to comply with such req- u sition within aaid five (5) deye, it 6"all be lawful, for said City Counoi.l to employ upon such work the additional force, or supply the materi. 13 as specifically required, as aforesaid. The amount of each aeAlti.onal foroe or materials shall be charged against the Contractor and be deducted from his neat or subsequent esti. caste and payment; or the ©ame or &V part thereof not. so deducted :may be recovered from udd Contractor or its sureties, Moreoverp if acid Contractor fails to comply with such requisition within five (5) days, the said City Counoil uiP.y dpolare this contract termi.nated9 and 1'i8y itself proceed to complete tho work herein specified, or msy engage any other per. son or persona to do the setts,. Upon completion of such work the City,, through its proper officer or officers, shall cause a atatement to be made of the Pxpensee properly incurred consequent and incidental to the default of aald Contractor, as aforesaidy and in completing the !!ork itself or by any ether pereon or personso 80 Should tl:e amount of ouch atatment be less than the amount which would have been dve to the Contractor upon the oompletiou of the work by its the di ri.�re -:ncr shall be paid by the City ts, the said Contractor. Should the amount of r►uoh' statement exceed the amount due the Contractor upon ,he completion of the work by its, the difference a W I be paid by the Contraotor to said City. 25n 7EAYBWT An RECORD OR MA.TERTAL ICED LABOR BILIZz (a) The Contraotor will pay all bills for labors ma e3hine hire, water'ale and supplies contracted for by him on account of the work herein contemplated when the same be+3one due and peyablep and he wi.l.l furnish to said City Council on or before the fifth (5th) defy of each month a sworn statement of all unpaid indebtedness contracted for on acco-ant of said work and of al clai= of private corporations or individuals for damage of any k.=.hd caused by the construction of said woark9 together with the L:a,tee of such bills and the names and addressee of such ored.itore o (b) The City Council, at its option and at any time, by written notice to the Contraotor upon the fafluxv of Contractor to furnish such statement, or upoh proof that contracted indebtedness is not being met when due, may declare thin contract terminated and may itself proceed to complete the work herein speci- fidds or mV enguage any other person or persons to do the seimeo (c) Said City Council m*r, at its option and at any timep retain cut of any amount due said Contraotor sum sufficient to --over any such unpaid c1a#me3 provided that sworn statements of said claims shall have been filed in the office of the City Clerk, and may Fw4 out of ©uoh mounts so retained any suoh utpaid ola o The City Council my x15;►, with the written consent of the Contractor, use any moneys in the possooision of the City of Huntington Beaoh belonging to the Contractor for the purpose of paying for both labor and materials for the work herein contempt tedo 26. P Thia contrhot shell provide that the City Cosrcil ehatl., once in each month,, cause an eati=te in writing to be made by the City inesr of the Itatal amount of work done to the time of such estimate g and the values thereof. Said City shall ret&Jn ten (10) per cent of such estimated value of the work as part security for the fulfillment of this contract by the Contraotor =d ahall monthly at a regular meeting of the C t.- Coun+cii peer to the Contractor,, while carrying on the work, the balance not reta:.zted; as aforesaid, after deducting therefrom all previous eats arA all sums to be kept or ret Aked under the prosislona of this contract, No such estimate or payment shall be req. 90 ui.red to be made vrhena in the judgment of the City Eigineerl, the work is not prIo. ceeding in accordance with the provisionb of this contraot or when9 in his jud& meat, the total value of the work done sine the last estimate amounts to lose thsi: T?hree Hundred (3300.00) Dollars. The City CounailQ if it deeme it expedient so to do, may amine estimate© -to be made more frequently than once in each months and it may camse payments to be made more freque. tly to the Contractor.. 27 a FOAL PAID?a (a) T'ue City Engi near sha ll F as soon as practicable after the completion of this contract v make a final estimate of the amount of work done thereunderg and the value thernofv and the said City of H.mtington Beach ©hall at wwh timep within b..�-•rty-fire (35) days from and after the daze of said estimate4 as the City Council moy, eleotg pay the entire sum so fo-and to be due hereunder➢ amo=ta to be retained under the pro'risiona of this contract. All prior partial ratimates and. payments shall be subject to norrections in the final estimate and payment, (b) It is hereby specified that nc certl"34;mte given or payment made under this contraat:t except the fins) certificate or final pWentp shall be con- �. blusive evideno0 of tho performanae of thin contracts either wholly or in part,, ags,xinst wy claim of the said City of Huntington Beaoha and then not until the lunge of thirty-rive (35) dp4e after acceptance of the work by the City Councils and no payment shall b3 construed to be an acaeptance of any defective work or improper materials, (c) The said Contraotor hereby fur'O'her agrees that the payment of the final amount due under this contract and the adjustment and payment of the bills ran-'lered for any work done in accordance with any alteration of the sameq shall release the City of Huntington Beach, the said City Counoi.l and the City &47ineer from any ant` all claims or liability on acoouitt of work performed under this con. tract, or any alterations thereof. 28, PROPE-W RIGHT IB TF-RIAIS: it is furhter agreed that nothin;dn this contract shall be construed as vesting in the Contractor any right of property in the eateries uapll after they have been attached or affixed to the work or affixed to the soil g and a 1 such materials shall Q upon being• co attached or affixed beeore the property of the said City of Huntington Beach. 29, VO PERSONAL LTABILITYr It is further provided that no member of the said City Co-orcil or the City Engineer, or any other officer or authorized a::sistant of said City Engineer, or any other official of said Cityp shall be -�rsonally rse- ponaible for any liability arising under this oontrac-, 100 l 30. PglTEM PhMMBMNCE BOND: The Contractor shall furbish a common it-w bend for the faithful performanco of this contract in the sum e(uuual to Fif ty Obi ,der cent of the contest price. ...,.....a..�� �..., .11 CONTRACT PBICEs The tatwl amount of the contxa`:4 Price and the bid hereinzliefore referred to is the sum of $ 46 845. I5 Dollars. 324 P.. E SCALE: In accordance with the provisions of Section 1770 of the Labor Code Q the City Council of the City of Huntington Beaohp Californiag haz ascertained the general prevailing rate of wages applicable to the Rork cov- ered by this contract as more par*fji.ou?arty set forth in a resolution of the City Council of the City of Huntington Beaoh9 a certifiod of which zesoit;tion is hereto attached and mate a part hereof and dgaiF.cted ws Recolution No. 1425 entitleda A RESOLUTION OF THE CITY OF HUNTINGTON BEAC ESTALL?SHING VRE GEITERAI, PREVAILING RATE OF HOURLY WAGES FOR EACH CRAFT CAR TYPE OF WOR"AN OR ITECHANIC I EDEU FOR THE RECONSTRUCTIONS SURFACING. M D IMPROVUENT OF GOLDEN WEST STREET s BETWEEN SUMMIT AVENUE AND TALBERT A`EIVUIT3,s IN THE CITY OF HUNT I NGTON BEACH* CAL IFORNIA. 33Q SITED TO NIGEM (8) HOM PM DAY: That the time of aervioe of any person employed by the Con;pastor shall be liud,ted and .restricted to flight (8) hours during any calendar dayQ except in canes of extraordin z7 emergencyp caused by fire$. faooda or danger to life or property and Contractor or any sub -Contractor shall keep an accurate record showing the number of tactual hours worked by each wor)aaen employed by hips in connection with the cork here contemplated. Said rec- ord ahr►.l.l be kept open at all reasonable hours to inspection by the City and by the Divi©i.on of Labor Lear Enforcement. That th4 Contractor shall forfeit as a penalty to the City ten (10) dollarn for each Frorkmen empl.oyod in the execution r of the Contract by the Contractor or by any sub -Contractive for each calendar day duri.n�; which any workman is required or permitted to labor more than eight hours. 34, That the Contractor r3hall not asaign this Agreement without the con-. sent of the Cityp in wri,tiag9 first had and obtained., 35- BID PRICE: The aa.:d Contractor further gees to receive and accept the following prices as full compensation for furnishing all materials and for doing all the Rork contemplated end embraced in this agreement; also for all loss or damages, arising out of the nature of the Rork aforesaid, or from the action of the elementag or from any unforeseen difffculti.ee or obstructions whioh W arise or be encountered in the prosecution of the Tory uatl its acceptance by the City Counafl of Zlhe City of Huntington Beach q and for a3.i riuj_s of every description connected u:.th the cork; also for e.11 expenncs incu=ed by or in connequence of the n. auspension or discontinusnoe of work and f ^ well and faithfully completing the work, and the whole thereof,, in the manner and according to the pima and specEfi- ca+ions p and the requirements of the City 44yineerp under theme to wit: Approxi- mate # stem Quantity items with Unit Price Wri.ttev= unit in Words Price Total 1 99173 Cu. ids, Roadway Excavation a.: Fifty Cent3 per. cu. yd. 0. 50 49586. 50 2 19 ,346 Sq. Yds . Basement Material Compaction at Five Cents per. sq. yd. 0. 05 967 . 30 3 ' 49763 Cu. Yda . Imported Borrow at Fifty Cents per, cu. yd. 0. 50 29381 . 50 4 81231 Tons Aggregate Base at Two Dollars Twenty Five Cents ! per. ton ; 2 . 25 189519 . 75 t 5 310081 Tons Asphalt Concrete at � Five Dollars Sixty Cents per, ton 5. 60 179253. 60 j � 650 Lin. Ft. Asphalt Concrete I Dikes at Forty Cents per. j lin. ft. 1 0.40 260.00 14 7 13. 7 Tons prime coat at Thirty Dollars per, ton 30. 00 411.00 f 8 6 . 9 Tone PaLnt Binder at I Forty five Dollars per. ton � 45.00 310. 50 I 9 SO Lin, Ft. 3691 Dia, Corrugated + Metal Pie at Eighteen f Dollars i.fty Cents per. lire. ft . 18 . 50 15480. 00 10 j 50 Lin. Ft. 1$" x 29" Corrugated Metal Pipe at Eight Dollars Fifty Cents per. lin. ft. 8 . 50 425. 00 I 11 2 Each Corrugated Metal Pipe Downdrains at One Hundred r l ► Twenty Five Dollars each 125 .00 250.00 TOTAL BID , 14P,845. 15 120 It WITH .SS WHEMpr, tho City of E mtington Beach has caused its name and coal to be hereunto annexed by itn Nc4-or and City vlerkfl thereto duly authorizedg and the Contractor has set his hand h,irotop the day and year in this A&reemeut first above written, CITY OF HOTLI:CWON BEALE a Runi.oi-al Corporationv By Nay* ATTEST i Ci•by C1:#rk SULLY-MILLER VINTOnCTINC COMPAll Contractor Helen Carte.... Assistant-Secretary APFROVM AS TO FORs3 i City kt toraoy a. i FEDERAL INSURANCE COMPANY Into Wh:ck Has Been t ..gad (July, :939) UNITED STATES G U A R A N T E E COMPAMY e H u$a & SON* M w M A n t R z T j. go John Street, New York N.Y. 23922.58 8002--53-39 r.M�2.:ilt $.......... .............................. Bond No.- . ....-_... PUBLIC CONTRACT BOND CALIFORNIA FORM KNOW ALL MEN BY THESE PRESENTS: That we,.....................+.-..SULLY_FILLER COVTRACTING COMPANY - ... .................................._...... ............................................... ................................ ................ ................ ..............._................_................_..................................................._............... .........I................... .. .. . ... ............. .. . I.. ...... , .is Principal, and the FEDERAL INSURANCE COMPANY, a Corporation organized and existing under the laws of the State of New Jersey and authorized to transact surety business in the State of California, as Surety, are held and firmly bound unto....-....CT Y. Off' RUNTINGTON BEACfs, C AL. 0R�`tI A — ............................................. ................_......................--............-- ........... ..-.. -T v.IdTY—THF�E T HOUSA02 FOUR ........................................................ ......................................in the sum of............'-.... ................................. . HC' DRFID T14ENTY-TWO AND 58�100 Dollars ( .23...422•58........), lawful money of the ............................................................................................... .... United States of America, for the payment whereof, well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, successors and assigns, jointly:end severally, firmly by these presents. SIGNED, sealed with our seals, and dated this..............29t}a.....day of........... ....J.'I....Y. . 6 ... .. The condition of the foregoing obligation is such that, whereas the above bounden Principal has en- tered into a contract dated.........J? Y............... . .. 60 CITY OF EUNTINGTOA 19............, with said. to do and perform the following work, to-wit: Reconstructing, surfacing and improvement of Goldenvest Street between Summit Ave=jr and Talbert Avenue. Resolution -41425 . ACKNOWLEDGMENT OF ANNEXED INSTRUMENT STATE OF CALIF RNIA COUNTY OF......... 9... $l �44.� ss" On this.....29:th..day of........July . in the year one thousand nine hundred and.................. 60 before me .......... Floranee Grsesmal �� ..����'.�.�....... sw, .. ......._...................................... .....,a Notary Publ c in and for the County of... 4. ..................................residing therein, duly comrnirsioned and sworn personally........ ...... .. ....... iK. S. Banks ................knows to me to be the......R. : nxxze ::: ,x�->;?a�. of FEDERAL INSURANCE COMPAINY, the Corporation that exerted the within ;nstrument, and alco known to to be the person........who executed the within inst:nment or. behalf of the Corporation therein named and acknowledged to me that much Corporation executed do same. IN WITNESS WHEREOF, I have hereunto set iry hand .aid affixed my o.Mcfal seat in the County of ..................... ................................................................the day and year in this certificate first above wFtitten. 41 tars ppW'n and for the raatq of pt . 19, 1960 ....Low ....... ...........State of California My Commission expires.........:....................................._........... •I•e70 PPIMTM IN U 5 A FEDERAL INSURANCE COMPANY Into Which Has Been I'lergrd (July, 1933) UNITED STATES GUARANTEE COM PANY C H U n D e SON* M A n A a e R s } 90 John Street, New York 30, N.Y. 23,422 .58 T 8002-53-39 .....................Amount ............. ........ Bond No.----.............................. _PUBLIC CONTRACT BOND CALIFORNIA FORM KNOW ALL :-MEN BY THESE PRESENTS: - SULLY- '4ILLER CONTRACTING COMPANY - That we,...... . ........ .............................. ........................._........ ........................................ .................................................. . ........... ........... .. . ... ........................._..............._...._................................................................................................... as Principal, and the FEDERAL INSURANCE COMPANY, a Corporation organized and existing under the laws of the State of New Jersey and authorized to transact surety business in the State of California, as Surety, -....are held and firmly bound unto.... CITY OF RUNTINGTON BEACH, C ALLFT ORNI A — ........................................................................................................................................................... in the sum of THOUSAND,FOUR ......................................................................._................................----. ................ .......»........................................................ HUl•?DR.D Tj�TEiIITY—TFO .AND . 58 100 — ( 23,422.58 1 y .. .............. ... . .. ... . .. ...... ........ ......... .... .............. ..Dollars , ....................... .. .. ............ lawful moue of the United States of America, for the payment whereof, well and truly to be made, we hereby bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. SIGNED, sealed with our seals, and dated this........... .29t.11......day of...............Jul.y.. ........... ............. . ., 1960.. . The condition of the foregoing obligation is such that, whereas the above bounden Principal has en- July GO CITY OF HUNTINGTON tered into a contract dated...... .............I..................... .... .......... ...............1 19............. with said. to do and perform the following work, to-wit: Reconstructing, surfacing and improvement of Goldenwest Street between Summit Aver_ ue and Talbert Aveme. Resolution -#41425 . NOW, THEREFORE, if the above bounden Principal shall we'll and truly perform, or cause to be per- formed, each and all of the requirements and obligations of said contract to be performed by said Principal, as in said contract set forth, then this bond shall be null and void; otherwise it shall remain in full force and effect. SULLY-MILLER CONTRACTING C01AP A- Y ............................__ ....».............._._................................................_......... f By ............ . . pri ci al ....... ._..._.. ,' '�►-�.'' Eolen -Q te,, Resistant-Secretary FEbER* S ' CE CO PANY Piemium $281.07 z , ..................f........... ..»y.. .y ................................_....... ........ M- S .Banks, Attorney-in-Fact .XECUTFID....I.N....DUPhICAT ........ ..... . . IMPSU7ED IN U. x. A. (2-98--ZM 824570) f FED E RA I& INS U R A N C E M PA NY Into Which Has Been Merged (July, 1933) U N : j E O STATES GUARANTEE COMPANY CHUMS 31 BON@ IMIANAOKQ4 go John Street, Naw York 3a, N.Y. r Amount $.23.1422.56 8002-53-39 Bond No..................................... LABOR AND MATERIAL PAYMENT BOND CALIFORNIA POLAR VI - PUBLIC WORK KNOW ALL MEN BY THESE PRESENTS: That we,................�.... STILLY.-MILLER 4ACTING COMPA1:lY__w........._........................................_..................... .. ...._...... ..............................................................._.................................... as Principal, and the FEDERAL INSURANCE COMPANY, a Corporation organized and Existing under the laws of the State of New Jersey and authorized to transact surety business in the State of California, as Surety, are held and firmly bound unto the State of California for the use and benefit of the State Treasurer as ex officio treasurer and custodian of the Unemployment Fund and any and all persons entitled to file claims —TI-IENTY—THREE under applicable sections of the Code of Civil Procedure, State of California, in the sum of..................................... VIOUSAND FOUR RUNDRED TI-TENTY-TWO AND5 0 �$. 3*4.22.58...__.. �� lawful money of the _... _......_._i..»...___ ._........ ..__................___.._._.....__......_....................__Dollars United States of America, for the payment whereof well and truly to be inade, we hereby- bind ourselves, our heirs; executors, administrators. successors and assigns, jointly and severally, firmly by these presents. SIGNED, sealed with our seals and dated this-_ ._day of _ ....._.......».--- ..., 19.6�. July ._.._.. The condition of the foregoing obligation is such that, whereas the Principal has entered into a con- tract _dated_...!?� ...._......................_...... ........ 195�.., with.....CITY OF .HUNTINGTON CALIFORNIA ..._......... 1�._ .__......._...._....... to do and perform the following work, to-wit: Reconstructing, surfacing and improvement of Goldenwes a Street between Siumnit Avenue and Talbert Avenue. Resolution 771425. ACKNOWLEDGMENT OF ANNEXED INSTRUMENT STATE OF CALIFO NIA • COUNTY OF.».._..».. 0 ..Iea. � On thin.-2ath...day ot........1U1y................._ in the year one thousand nine hundred and....... before me, .......».»F'lOrenCe. GrBeozel»»»w _..».........».........»»..»....�..»....»..»....»....».»,a Notary Public in and for tho County of...».� .._..::..:..: ' ...»............».».»..»...._rcaf din therein, duly co and sworn, M. S, S commissioned rn, personally appeared .............»...._......._... ... ..Banks..............»........»............._.........known to me to be the...Attorne7-in-Fact _ of FEDERfiy INSURANCE COMPANY, the Corporation that executed the within instrument, and also known to me to be the person..__.who executed the within instrument on behalf of the Corporation therein named and acknowledged to aye tl►9t such Corporation executed the lame. IN WITNESS WHEREOF, I have hereunto set my hand and a&Ixed my official seal in the County of ....................................................... ........................»...the day and year fn this certificate first above ttea. ,s .. Notary Pub 'n and for th ounty of..N.».» Lee e___. »»».State of California My Commission expires.....»�Pt.'_.»lg� lg�._..».......» .................n N/•670 rA�Hrrn uM u a • F E D E FAA INSURANCE E ODMPANY Into Which Has Been Merged (July, 1953) UNITED STATES GUARANTEE COMPANY CHu>sS a some MwNaoKlli j.` go John Street, Now Ycrk18, N.Y. Amount $.23..=�22..5$....................... $002-53--39_....... Bond No. LABOR AND MATERIAL PAYMENT. BOND - CALIFORNIA FORM PUBLIC WORK KNOW ALL MEN BY THESE PRESENTS: That we,.............. _SULLY-MILLER ...COVI T RACTING.. C014PA14Y_. ....................................................................... ................._....... ._...._..... _....._.. ...... .. ...._......._._...._............................_............_.............._......................................._....................................t as Principal, and the FEDERAL INSURANCE COMPANY, a Corporation organized and existing under the laws of the State of New Jersey and authorized to transact surety business in the State of California, as Surety, are held and firmly bound unto the State of California for the use and benefit of the State Treasurer as ex officio treasurer and custodian of the Unemployment Fund and any and all persons entitled to file claims under anp::cable sections of the Code of Civil Procedure, State of California, in the sum of.....—T....1•I.E....NT_. .v....—........THREE TROUSAND,FOUR �HU14DRED TWENTY—TWO AND5Do 100 2j 422�58 _ .. ._....._... w. ___.. .. ..._.._..._......._........._..... {$......._�. .........__...............), lawful money of the United States of America, for the payment whereof well and truly to be made, we hereby bind ourselves, our heirs; executors, administrators.successors and assigns, jointly and severally, firmly by these presents. SIGNED, sealed with our seals and dated this....._20t ......_day of............................... J�?�..__.......__, f9.s�.... The condition of the foregoing obligation is such that, whereas the Principal has entered into a con- tract 1960_, with...... CITY OF HUNTINGTON BEAC,..-.......... - CALIFORNIA - to do and perform the following work, to-wit: Reconstructing, surfacing and improvement of Goldenwes t, Street between Summit Avenue and Talbert Avenue. Resolution #1425. NOW, THEREFORE, if the Principal, or his or its sub-contractors, fail to pay for any materials, provisions, provender or other supplies or teams, used in, upon, for or about the performance of the work contracted to be done, or for any work or labor thereon of any kind, or for amounts due under the Unem- ployment Insurance Act with respect to such work or labor, the Surety will pay for same not exceeding the penalty hereof, in which event this obligation shall be void; in case suit is brought upon this bond, a reas- onable attorney's fee to be fixed by the Court and to be taxed as costs shall be included in any judgment rendered therein. SULLY-MILLER CONTRA CTl ILIG CO!.IP AI,IY .. .___.._._..._........_......... Ee3.ea_c rr e. ajas stant-Secret817 FEDER*L'V9 / CO ANY P r e.-.d.um I nc i ud ed ` - ...__........._..... ......................................... M.SB 'nks, Attorney-in-Fact LIr-700 PRIN790 IN U. 9 A. l5.55.2M 57061 I i .• a � RO AL I DEMNITY Cow 011.Y_ ►'� EXECUTIVE OFFICE : N;.ttlr YORK A NEW YOJtK CORPORATION F, ROYAL Y f r l� Terfifirutp of .3nourana r Date TM 2g., 10C,t} Issued at the request of CI'+'Y CI`' JPTMi}r'I'IC�7Y)ld ;Z; I=tI Address CITY i91L �► rf f LI 1 � ���'�r�`I.1��rT.)?I �SId C. F Cf',�t�'�}1�.'�� Z; W to In Grrfiftg lhat the insured named below is at this date insured with this Company as described in ` ;he following schedule. U'rmpant `} S ully--Miller - C ontractlks s he 6 ,�, and Contractors torte As p Name of insurett roducts Co. , Inc . and Valley Asphalt Sales Co. , cr as , Addresses nteres is Appear . 3000 L. South Street , Long Beach 5, California Locations Covered t ate of California fi. Job i'1,CU�i T�'JCTIOit, i,L�U '�+'.'.C;iI�iCrs NID IMNOVINWT OF G0LD01r-: "-.T 'STIM-11f ., Descriptior""QPMrk BETWEEN SMAUT 1'iD TPLBLRT AVE. r� JOB NO 51551. 4 LIMITS OF LIABILITY KIND OF POLICY EXPIRATION Bodily Injury Property Damage } i> a POLtCI' ivUM(IF.R DATE Lach Person ?Each Accident tEach Accident � AgFrtgatc S S $ f Workmen's As ptovided by Workmen's XXXX XXXX ;� Campenstticn CompensationLaver _ _ State of_ . Manulac:weri or Property Damage p Contractors' Liability +� age �� C�rness' or Contractors' Property Dam � -t Ptotective Liability f Property Uamage Uw�ncts'. Landlords' � +! and Tenants' Liability Automobile Liability — f +nsarmg: KXXX w' i# 1:] All Owned Vehicles ti KXX7: y ❑ Allsiired vehicles All Other Non-Owned i xxxx -r Vehicles i XXXX I] The following j 1 .chicicisl : sti •! tt +, a Ll Corcrtchensire Liabilit;: } ,c Comprehensive R P 1}-�I+620 until 2501000. JJ, 0CC. 107000. Xxxx F, ^� Automobile Cancelled a, R P t 44620 nt it 2 0, CCS a �C 000. 10 7 11, abdily .a;uzr , Comptehrasiee ��►7♦ ernerrl Cancelled 25 PMperry Damaic - + t Each occurrence as respects t p ctsFararly�l�TTITt�tyl ctnjr30P-Days Written :` otice The Company will mail to the party at whose request this certificate is issued a recoi rl of any material change in or cancellation of the said policy or policies. t R°Y, ELc' r/7 R20798C-75M- 7.59 By j 1 t (lextif acate of Nourante TO CITY OF t_'UYTINGTON BEACH CITY MALL I VITINTINGTON BFACtI, Ct.1JFUFtN1IP , ADDRESS: 1 This is to certify that we have placed with certain Underwriters at Lloyd's, J London and/or Companies in England through our London correspondents the following described Policy of Insurance:- CONTRACTING COMPANY AND CONTRACTORSriAME OE ASSUREJULLY—MILIJER SPHALT PRODUCTS CO INC . & VALIEY ASPHALT SALES CO . y OR AS INTERESTS APPi" 1 3000 EAST SOUTH STREET , LONG BEACH 5, CALIF, , CERTIFICATE NO. 1 ) L-63 550 2 ) L-63 551 4 Effective: 10-25--59 Expiring 10-1-62 COVERAGE: ` s , EXCESS COMPREIM-NSIVE GENERAL LIABILITY -- 1 COMBINED SII GLE LII�IIT BODILY INJURY &/-,r PRGPLRTY DAMAGE LIABILITY � { , LIMITS: ` $500,000.00 JOB: PTCOONS RUCTION , SURFACING, ND IK'i 0M1 ,T OF G0Lnt~*TT7',--7' !;TF 1' , B1,11'i'FET 7d al.IWIT PVE. AN-D TPUIERT AVE. j S --M JOB NO 515G1 I ` � + f 1 SUBJECT TO Cancellation Clause TEA) DAY WRITTEN OR A RECORD OF ANY I 1,01TERIAL CIU04GE IF THE SAID POLICY OR POLICIES WILL BE t-TAILED TO PARTY AT WHOSE REQUEST THIS CERTIFICATE IS ISSUED . DATE: ruLY ?S, 1960 9A J<&qfix' Seeley f i q'- oil a STATE C O E'EN SAT ;�.�e r ---L ION �. ,USA E FUND EXECUTIVE OFFICES - SAN FRANCISCO 1 LOS ANC.ELES DRANCH OFFICE • 000 SO. LAFAYETTE PARK PLACE • LOS ANGELES 84 • duly 28, 1960 City of Huntington Bleach CEP�TIFICATE OF WORKMEN'S City stall COMPENSATION INSURANCE Iuntinf_;ton iJoacl�., California • Pa:iicy 19954o--59 Policy Period: 10-1-59/' 0 THIS IS TO CERTIFY that we have issued a valid Workrylun's Compensation Insurance Policy in a farm approved by the Insurance Commissioner to the. Employer named below for the policy periled indicated. This Policy is not subject to cancellation by the Fund except upon ten drys' advance written iz()tice try the Employer. We will also give you TEN days' advance notice should this Policy be cancelled prior to its norinal expiration. By lir,r:si h Manager Employer / . ?f SULLy_: iILL� COI- 4C+IN CO:iPADY Re : '-,-)Le 4u rfacin- 3000 South Street : Imps. of Goldon St . beta. ri„iit :c TalbertLon : , H. B. eW =J1 �;aro BIDS FM THE FMHSTMGTION, `SMIF'ACINGp AND IE{PRM118NT OF GOIDEN WEST ST 'T, SOMEN SMQIITAVME AND TAM W AVE=* ITEM I En 2 z= 3 4 rfu 5 zxM 6 9,173 Cup Ydep 19,346 Sq, Mae 4,763 cu. Yds• 8d231 Tang *3,ofr Tom 650 JA o F j Ro sy Dawment Material Imported Aggregato Asf 3.t Acphal`►, &msav Lion GcMpaotion, Baran Buse Cowrgats .7 w�'M'f.Rr/,Ws'..a1�•wMM'�I'•'f'•Y�MN.!■■/'(IU Enginser's Estimate a L25 6 a+eO5 0� ,+3�� j��� 6 2o2O -,3D �� is{, ��a(7�5'`� 0 9674O $5o239d34 6,,3LR.'�O $1.53 "Oe>9 '^r 448 o5O wwr.. ■...+.,�y„r - -- - -- - wnn.M�Mw1.■w►rrr'LL+wPfY. Boack Paving 1035 N, Batavia, Omngeg -Calif . r+r rr.r.r r .w■ � I cala Construction Goo Ormm Calif. .. ( _ .. C(xr. Dros. Knott Ave• & Kate 1l3 Was ' Stanton, Calif Ca'iffith Cap. w Costa Pest, CaUf'o .�.. -we via ftmp 700 5th,StoP . _ Re Sa Noble abrle l Pa .Q• BOX 620 .f OrSAW. Calif' brlwY r Iw■r.iYrwq .�w�w+r+wti.Ir�YwrMr■Yr■■nrr — _ �_.�+.wrr- +.�w.r..w+ +.rYaN■rgM+rN f■r+1[+ErRf Banton A. Prock SarewR 1 CaW s WOw■�r+rrlw�■�rwwrrw+rswq , 1 Su74 W.I r Goutmting Goo 41 D(m IJ2- Orem, CaUJ.0 - - --- - July 3.6.9 IW..) rM 7 ITEM. 8 ITEEM 9 ITEM 10 I TE 9 3.1. TOTAL13a7 Tone 6.9 Tone � 80 UmPto 50 Lin. Ft 2 each Carr Pry Coat Paint B.x; 3er � r. M—im. Cor'.sgat6d Dire 18" x 29" Corr, Metral. Pipe }.fetal Pip& D=11draine _ 4 55.0a 6osoo 18,00 $ 94o 8740 S753450 41*440900 $475roo $174*00 $559 654*35 •.. � wrrrrrrrw..w� �+ �� w_f. rrr...+w.•wr�.�..�v...++..w... .Tw.s _ _ __ ...w.....�..._+.a w+lwe . .rr. .w+ __.r s ;'7CP0S._'.. TO St1b i J'r 1 OF 17LMN11N-__'0N, M-r' Gff tE� _ .. L�E���1'iJ 1 iLt3Cr1.LL+� .j S i t1.G ING. AM D'f..c M V iifl E l OF 7Ji S i'; SUMAIT AV M. M., Atru ALMN U L'I�iF, THCITOF i l,;iGKT �;: :� ACH C To . ,, Honor^.:ie "—1 C -ty CGS.-c 1.1' t.t..,V of ,..alUili...11g.i o:! a3C..c.t, 1✓..s�_l, .JS 1ii.c-.e nuhlishrd fiuri2r.�•.on Teach Fp.a En cc,�'i'J nce with ho $2`maxed aritiC Inc • ycp • _ *v. rALED Z im iting seZed p-�pn on ��.ye u e:� :r i:z::o r�r�c�v 'uo aeri'om iG'..7.ter1.als Lt;eT_fcz' 2!�`.:Q�: 1.Tit', ::r. f�a v on5 a:.d s_oesr:ia ^.:�l ;���ri.:T;: _s for Lai c id wori- a.,-d to thy saUls='action of z1.rsd itt•:,'.e he 'he u i:: ..ai._,-� of all -i�:�.:, m.t.,o?d.... ls r-nd and (_0 0.3-1. a �-:. y work 1Y cr!s. —. r to G;£•ii—v—,,r zzdl }!1 _ l,^%e ir. i,1;ic,ri in ;.11,riit C;o-,-if ;ti:J_`y :fi h -,ai2e ?)1a 13? t3 �ci.i`�.cations ._. � areci.al CTI31.0n.s, �n +'il�i It `1:6 A. Q1% City �T1�i.�4e`-.`o Ci.✓a' of .Tltlz+ rgil;oyi taach, r_)inpoce {.ITT ai�Z�© �`-Q Cyr., ' "-10 • � Atli a�is '.r u 'r '. :i UI' c"L is ��}1e f o3 2 o. ing unit �!ppl�cri-- � � cII'it i mitts Itr3ms with t�n.L Price } .yet :� in J'or:'.s 1 Pring T©�.-1. {. 92173 Cu. ''ds• F,oad�;�• Rm.,_tvatA.on at, yd 2 193346 Sq. Yd_o ?aamn-snt -Matar al Compactior ! � at —per. rp• yd= 4,763 Yds. i=orted Bormn at %-=rY G';-�•• _sue' p�r� cupyd s ✓ T%-no r -a gar B t se 3 081L Tons Asphalt Concrete at - /�'i` r. 'con 650 Lin. Ft. Asphalt Cow vote Dllms at J �R Appraxi. Unit .ten mate Items -,ith Unit Price Written in Words i'rice Total Quantity 7 33.7 Tona R-Mme Coat at vr. ton 6.9 Tons ?Lint Binder 41,4 per. ton 80 Ft.. 3611 P,=* . Corrugated 13-stal Pipe un. fit. 10 50 1J.n. rt, 18" z 293 GOTvaulted vbtal Voe, Un. ft._yer fault Cornor au gatod Fatal Pipe Dcmulrains at each ✓ Total Did 1f. awarded Villa cont-Tact I the under gmd hcraby agmes to sign said contract, and the nccesaarj bonds -Athin ten (20) days of tulve a-mard of said contractq apd to begin vioric wit,11hin ten (10) days from the date of a:'lppraml of the contract by the Git"i of Fluntl%t-on Beach, The undersigrwd has e--mmineed -the "lartation of the proposed work -,,nd Is familiar rith -'r-1 ie plans 1 1, , specifications and special provislons and the. loca2 -oivlitions at the p. -lee I e the work is to be dere. Accompanyino- t:it propowl is (NOTMIDE: Liscer, the -v7ozxls r-Cash -,n nGauhierls it ?mcxiW5 equ---,l to at lzaBt ten per cent of ths rorks fl. d Chock 17 or "rOidjf,::-r*-s Bond" a a s a nay b e. r,r'h-- 21' 41, - ; a s th c --ck nCorti -C Licensed in accor&anc-e Ath an "act providbig 1-Cox, the registration of Coaturact-Oors. JACense No. SIGH 77- - it f H RE EE Signato,-a 0? 131MO Adin us Buairv� Place of 1%siderno ,:Ol Bated this of 1960 RIQH"I OF UAY CERTIFICATION Me it Huntington hereby Beach y of by certified in connection Stith: the aright, of my for Fro j wt #39 Golden West Street that: 1. 3 1- ri-i-?nt af ;.ay has boen acquired., cr P-11 work is y right of within �.��. �1�'t:; l�i�;.it of 1:a and !10 additional 2 lio bu_lcUng mrovnment or uttty exist within the right of way area, or the fol3.cr in4 iUarovements (de nc ri a impr ov i-vents) exit, within tho ri cMt of Tray araa but ::i1.1 n©t interfere :zith construction. In :r3aicimy Vais cexti.f icat<ion, the City cf Hvmtingrton Boa.ch awes to hold the County harml-ess iroT any 1:Lab ty whic. Ira.; ariga by reason of t-:ie CQunty's re_.i ms upon tiii.s C:�rtifi.cnte and its use of said ri&is of •,;may. CII7 4F HUNTINGTON BEACH � J r- f jay ����-� �� ��`"y'z-£-��✓" i rrrr�.�.a�r.�rr.�r.r.■ rr� �i +.�rr 0rf CLERK D. te