Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
C.K. Pump and Dewatering Corporation - 1985-12-16 (8)
ti r f.S'tI" 11Y WHEN RECORDED MAIL TO: � 86-216616 4k-6835 I � "�rA '"t Rocco" CI iY OF HUNTINGTON BEACH Office. o1 " r►ty Clerk P. 0. [lox 190 Hunlinvion Be.ich Calif. 92f;AF EXEMPT C6 NOTICE Of COMPLETION •11!9AM OW27V 00 cG NOTICE IS HEREBY GIVEN that the contract heretofore awarded by the City Council of the City of Huntington Beach, California to C. 1 K. pumo An4_QS. i t.Ot CR!"P ona Re ch. California who was the company thereon for doing the following work to -wit: For the furnishing and installing of 4590 L.F. of 12" asbestos cement pipe and appurtanences Complete in Pacific Coast Highway from 9th Street to Goldenwest Street and 340 L. F. of B" asbestos -cement pipe and 135 L.F. of 6" asbestos cement pipe in adjacent streets in the City of Huntington Beach. That said work was completed by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach at a regular meeting thereof held on May 19 , 1986 That upon said contract the Reliance Insurance Company was surety for the bond given by the said company as required by law. Dated at Huntington Beach, California, this 22nd� day of May1986. STATE OF CALIFORNIA j County of Orange ) ss: City of Huntington Beach ) Alicia M. Wentaorth may` Clerk and ex-o ic'lo MR of the City Council of the City of Hu tington Beach, California Connie A. Brockway, I, ALICIA M. WENTWORTH, the duly elected and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beach, California do hereby certify under penalty of perjury, that the foregoing NOTICE OF COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Orange County by said City Council. Dated at Huntington Beach, California, this 22nd day of May —, 1986. This doom ont is solely for the 'flietal business or the City of Huntington Poach, as CShtM&- plated under Covell nt Cade Sec. $103 and sbould be ►*cordei Preo or ebar". 1.1 Ly 4 i erk � ex -of 1. I erk of the City Council of the City of Huntington Beach, California . Coanntr b . 4rot i v+n y , 11 Irv, WEN RECORDED MAIL TO: PFORNED COPY' _ b mom n ,w oi+r PF :" ; i tr i t h Original or aW" c;Q,rrt,► c�cr o ry tit 14UN I INGTON HLACN Office 0 lbe City Clerk EXEMPT 86-216618 `11 �0 AM W 27 K 0. 1101( 140 C6 I htnlmviun lir.ir l r Ca if WCAP NOTICU Or COWLLT104 NOTICE IS HEREBY GIVEN that the contrart heretofore awarded by the City Council of the City of Huntington Beach, California to G4_ 'i�.'31�tR_.�Rli._.QCN a�er..n.9_GQrp• who was the ccxnpany thereon for doing the following work to -wit: rni- the furnishing and installing of 4590 L.F. of 12" asbestos cement pipe and appurtanences complete in Pacific Coast llighway from 9th Street to Goldenwest Street and 340 L. F. of a" asbestos -cement pipe and 135 L.F. of 6" asbestos cement pipe in adjacent streets in the City of lluntington Beach. That said work was completed by said company according to plans and specifications and to the satisfaction of the City Engineer of the. City of Huntington Beach and that said work was accepted by the City Council of the City of flu-tington Beach at a regular meeting thereof held on Maur.,19,_._1p8.f'________.___.____________._ That upon said contract the Penance. Insuranre Comnanv was surety for the bond given by the said company as required by law. Dated at Huntington Peach, California. this nd day of May 19811 STATE OF CALIFORNIA ORNIA ) County of Orange City of Huntington Beach ) Alicia M. Wentworth c �-0 C rl � C r ty er=k and• ex-p of the City Council of the City of Hu tington Beach. California Connie A. Brockway. D puty I. ALICIA M. WENTWORTH, the duly e.leeter! and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington death, California do hereby certify under pepAlty of perjury, that the fores,)ing NOTICE OF COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County ;recorder of Orange County by said City Council. Crated at Huntington Beach, California, this 22nd day of May ____., 19 R6. This decuront is sololy ter the of'fletAl buslns93 or the Clw of Hwtfn!ton Beach, As contew- 014%04 unaor Gove- v nt Co40 S*c . 6103 mW Owu 1 e be roe a rd od Pny * at ellrrrne. n- i-lrrkian ex'.'oFhmc r Cleric' of the City Council of the City of Huntington f3leich. Cal fforn!a fonniC A. ltrnr:lway, ()uty REQUE:.T FOR CITY GOUNA. ACTION Dee "A' 91 19 86 Submitted to: Ibmrab1e Angor aml Ci t•/ Counei 1 Submitted by: Charles 7hcnpson, Cit- y Arininistratnr` t'�;, `— /•t� " Prepared by: Paul Cbok, Director of Pub l i s Vobrxs Water Main Installation Along Pacific Cb lqt, ilighw y Sub jict: 9 th and Go 1 dmues t Streets; QC-6 8 5 • , , ,�_. Consistent with Council Policy? (X) Yes ( ! Now Policy or Exception Statemm t of Issue, Recommendation. Analysis, Fundinq Source, Alternative Actions, Attachments: J;W" Statt3nett of Issue: C. K. Construction has caalActed the installation of a twx lve ineti water line along Pacific Chas t l l i gi way between 9 th an-1 rb l r1erTwc--, t. S t rw +.s . Ft<amr-nxlation : Accept the irpro:cments arri authorise the Ci t,- Cle:* to file the !bticv of 0xVletion. F,nalysis : On Deeezrbtx-r 16, 1985, the Ci t l Cour-ci l aaaried a contrw. t to C.K. Ctrs t.n+ctian for the installation of a inch water line alonn Px i fie Cbrmit Hic#rway beti-ven 9th and rn` ' -wGSt Streets . lbe conit zvetion of tlh.ose inprrntre►nts is ricow con-lr-tv, l}er the �. ? nl��n,/sncri fic�zt ions, -m! t.herr.forc: , t1le Di rector of Public hbn:ii recr.mmmh .)tarre of the prvirti.t ant zo;cja,t s that thr. 'btice o! ConfAct_ivn be filed tr; Clerk. 'fie iollowirv; i , a ;>�m-az�;� of Contract Wst, : Contract 4-ount : Corr.,truction Cbnt.in :�cie~: !-cy yinci 1 S--W)A,40r).00 15, 5g5.0� :metal S31n,non .nn $297, A5.00" 4,568.9 ** 15 )()l,s13.9 7 *F,ctual fielrt quantitie-; for •'h(, irv,allat ion of bored in !)lace were ,Treater than t at ecI . «« Construction chary- or -,!ern irx-1:riizt c-hxnc7irr7 rore of the pipelino m- tei-ia'_s, valves an-i fittings to A.C. rather than step-1 anI excatating around oil lines prior to installin:-1 water ser'.-ic-r laterals. F unii !N Source: F1imis of 5310,000 were tn:irieted in fiscal account 923634 (Tri ,mission (bast.) Alterrsati�e Action: %4 VA A tt actumants : ;bne r ore: rlx: Dm: lw Flo C" .r. CITY OF H UNTIN TON BEACH 2000 MAIN STREET CALIFORNIA 92648 OFFICE of THE CITY CLERK January 15, 1986 C. K. Puhp b Dewatering Corp. 2841 Gardena Avenue Signal Hill , CA 908C6 RE: Furnishing S installaticn of eater train S appurtenances an Pacific Coast hovy. and adiacent streets, between 9th Street and Goldenwest Street, Proipct CC-E63 Enclosed is your --id :.ondj 3 copy 3f the eAeca%ed contr34' with t^e Citj of Huntington ?each and 3 Certifiu to of Corii;ance form. The C roliance Fort must be sinned at the ccmCleticn of wcrr and retirned to this office. In addition, the following iterns must also ce cn file, with this of,"ice, before :he C4ty can release an;: retention f:^;;. 1. A warranty brand guaranteeing the final 3munt of mork and -material; for one year, ,f your ,erfor-nance band Cces not include soeWic wording for a one year warranty, V,-- n a rider or separate bond 1 -7ust be submitted. 2. An affidavit stating that all work„1en and persons employed, all firm.; SV Plri^g materials, and all subcontractors have teen acid in full and tnat tnere are no outstanding c1iims against this rrC ect. Should you have 3ny q,;estions or ccncerns reca*ding _he enclosures or that must be on file in this office prior to release of ra:en-.ion please call Dcr, ;icy l e, Cantr3ct Ac mi ni s tr3 tor, 5-6-;44 i . Alicia u. '.:entwcrtn City Cler+; AMW:bt CC: Don !:oble, Public 'forks peat. Enclosures: Bid Bond Cash Contract Certificate of Corpliance (TMmpw.m: 7146311-6 ':1 •,,t, CITY Off' M�Jt' TIN BEACH 2M MAIN STREET CALIFORNIA 9264 OFFICE Of THE CITY CLERK January 15, 1986 G. R. McKeevey, Inc. P. 0. Sox 19093 Irvine, CA 92713 We are returning your Did bond which was submitted with your proposal for the furnishing and installation of water amain and appurtenances on Pacific Coast Highway and adjacent streets, between 9th Street and Goidenwest Street, Project CC-585, in the City of Huntington Beach. The contract for this job was awarded to C. K. Pump and Dewatering of Signal Hill. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk W,W:bt Enclosure fTaspho r: 7144364LWI CrrY OF HUr#Jr1NL*--j ON BEACH ��Li�11A� w�riw.wlll Isr nA�...�i�1i�1 �w�r���nnwY� U�ir��� ��IIw 2000 MAIN STREET CALIFORNIA OF'ICE OF THE CITY CLERK January 15, 1986 Peter C. David Company '3831 Newhope Avenue Garden Grove, CA 92643 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of water main and appurtenances on Pacific Coast Highway and adjacent streets, between 9th Street and Goldenwest Street, Project CC-685. in the City of Huntington Beach. The contract for this job was awarded to C. K. Pump and Dewatering Company of Signal Hills. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk AMW:bt Enclosure (TWOOMw: 71$4364 li 1 rwwwmmmmw 0 '�, i'i"' 'CIS I�Ji'V'r'll'�JLo-i C 1Y BEACH 'R 2OW MAIN STREET CALIFORNIA 9264 OFFICE Of THE CITY CLERK January 15, 1986 John T. Malloy 606 N. Larchmont Blvd. Los Angeles, CA 90004-1359 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of waiter main and appurtenances on Pacific Coast Highway and adjacent streets. between 9th Street and Goldenwest Street, Project CC-6E5, in the City of Huntington Beach. The contract for this job was awarded to •". K. Pumo and Cewatering of Signal Hills. We would like to take this copor,unity to thank you for your interest in submitting 3 proposal. Alicia M. Wentworth City Clerk All: b t Enclosure (T&%6 w *- 7164004 ) 11 .A.6 CITY OF HUNTINLs-t-ON BEACH 14 2000 MAIN STREET CALIFORNIA 92" OFFICE OF THE CITY CLERK January 15, 19E6 Nick Tomovich b 11,on, Inc. 926 Ourfee Avenue South E1 Monte, CA 91133 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of water main and appurtenances on Pacific Coast Highway and adjacent streets, between 9th Street and uoldenwest Street, Project CC-635, in the City of Huntington Beach. The contract for this job was awarded to C. K. Pimp and aewatering of Signal Hill. We would like to take this opportunity to thank you for your interest in submittirg a proposal. Alicia ?1. Wentworth City Clerk AMW : b t Enclosure (TOmpN wr. 71449MI ) a 0 1 CITY OF HUNTINLa-t ON BEACH JIM 2000 MAIN STREET CALIFORNIAl�Q� OFFICE OF THE CITY CLINK January 15, 1985 Macco Constructors, Inc. P. 0. Box 257 Paramount, CA 90723 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of water main and appurtenances on Pacific Coast Highway and adjacEnt streets, between 9th Street and Goldenwest Street, Project CC-685, in the City of Huntington Beach. The contract for this jot was awardea to C. K. Pumo and DQwatering of Signal Hill. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk AKW:bt Enclosure tTdophow. 11443&001 0 # 0 j, "gp CITY OF HUNTINU-t-CXY BEACH 4T 20DO MAIN STREET CALIFORNIA 9264 OFFICE OF THE CITY CLERK January 15, 1986 Bobco Construction Company, Inc. P. 0. Box 59004 Norwalk, CA 90650 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of water main and appurtenances on Pacific Coast Highway and adjacent streets, between 9th Street and Goldenwest Street, Project CC-685, in the City of Huntington Beach. The contract for this job was awarded to C. K. Pump and Dewatering of Signal Hill. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk AXW : b L Enclosure (TrWONw: 1144Mr l FMCITY OF HUNTING uON BEACH 2000 MAIN .",TREE? CALIFORNIA 9264 OFFICE Of THE CITE' CLERK January 15, 1986 Doty Brothers Equipment Co. 11232 E. Firestone Blvd. Norwalk, CA 90650 We are returning your bid bond which was submitted with your proposal for the furnishing and installation of hater main and appurtenances on Pacific Coast highway and adjacent streets, between 9th Street and Goldenwest Street, project CC-685, in the City of Huntington Beach. The contract for this job was awarded to C. K. Pimp and Dewatering of Signal Hill. We would 1 i ke to t.1ke this opportuni ty to thank you for your interest in submittifri a proposal. Alicia M. Wentworth City Clerk AMW: bt Enclosure Cr.koftw:71446MG 1 NcJ T IUL INVI TING SEALKI) BIDS CC-FH5 Notice is hereby given that the L:ty Council of the City of Huntington Beach, California will receive sealed bids for the furni� sWng And installing 4590 L.F. of 12" a3bestos-cerr.ent pipe rand 2Muurtenatices complete in Pacific Coiisi Highwriy from 9th Street to Goldenwest r Street and 340 L.F. of 8" astiestos-cementpil)v and 135 L.t . of G" asbestos cenwnt pipe In adjacent streets in the Laity of Huntington Beacl,, t_'alifurnis in accordance with the plans and sp'eci is tons and special provisions on file in the office of Vie Director of Public Works. Doruments will be: available unNov 8, 19M. A charge of $10.00, not refutnctable. will be required for each scat of specifications and Accompanying drawings. DI> L-C' Tt )E : LJF P11HIAC ►'it JRKS LSTIMATf. Work Item I. Furnish . install l [" ashestos-c:rinent pipe.' and appurt imances 2. Furnish h Install H" i1SUPstcts-ce•Mehl. ;nn(J appurtenances 3. Boring using 2U" V stcel the (srrsnuth) VI/3118" thick wall with 12" 1 i)i;ri . s t ee l c v; . cat-rier piry 4. Boriny using 10" steel pipe ;smooth) w/318" thick wall with u" A X . cirri er pi l-x- `). E uritish as►tt mn,tall h" asbestus-ceinvi,t pirie ant) appurterl arece (,luantity 4,590 L.F. 340 L.r. 95 L.F. 82 l.. F. 155 L.F. In accordance with the 1,rtivistims of ')e: *Liwi 1771 ut the• Labor 1:ode, the State: of California, Director of the t.epartrr.ent tit InOustrtyl Relations shall determine the general prevailim) rates of wntles, apalicrnhle• to the worn it, be• 11cme; copit,s of the latest general wage rate determinatic.ns are oti fil(- at the offivo of the t- it) Clerl and the office of th,' Director of Public Works tit the r'it> of ► itintintitor► fivach, California. Plans an#J Zpecifirations, toc;ether w.+th prolmisal It►rttt, t►tu%r he obtame•d tit the officr of the Director of Put-ilic Work,, ( itr t iaelf, i iuritintjtim !tem.11, s 'allforma. No bid will be received unless it is ms(le on a Dkink for,li furnished by the Director of Public Werks. The special attentnt►n kit prospective hidden is called to the proposal requirements, set forth in the %pecificatmiis, for full Oirectsons a% to the biddint). N- I 0 1 7 The above quantities are siptiroxi► ate only, br_itig el►ven :es a basis for the compitriwwi of b►.d% end the City of Huntin(ltan l'encl► does teat express or by implirations agree that t4e actual atsiour►t of work will corresptrul therewith but reserves the rioht to increase or decreave the amount of any class or portion of the work, Ob (i►tay be deenwed r ceuAry or expedient by the Director of Public Works. All bids will be compared on the basics of the Director of Public Works a atimate of the quariLities of work to he done. Substitution of securities for any monies withheld by the: City to ii+sure performance shall be permit';ed in accordance with provi5inna Of thv California Governeiwnt Code, Section 4590. Each bid shall be made uut oii a form to be: obtained at the of f ive of tim U►resctur of Public: Works, Development Wii:q, 2000 Main Street, Huntington Beach, California; shall tie sealed and filed with the City '1--dark at the Civic Center, 5eZo(id Floor A dininist ration Building, 2000 Main Street, i-iuntington beach, California, on or before i0:00 A.M. of We S , 1965, and shall oee olmneed by a committeecoenposecl of the City Clerk, the City Attorney and Director of public Works or their nuthoritead representative and the results of said bidding will h reported to th(e ( *ity C otAic:il of said Cit-. of Huntington Beach at their rcqular meetim) to he hold on Mondry, the T)L%C 16 , 1985, at the hour of 7:30 P.M. in the City Council Cha(i►beers in the (.:ivic I -enters of said City of Huntington Beach, rind shall he acted upon by said City Council at the regular n►r•et:nq of Tk►C 16 , 1985. The City of Huntington ileeach, (-ahforma reserves the ri(lht to reject am. or ull bids, end to aced.: the bid deemed for tnee hest interest of tht- City of a (untingUin Beach, California. icy ardor of the C.►ty Council of the Pity of I luntioultue► Beach, C alifurr►ice this _an. 7 , 1985. (43 TEST: Alicia Wentworth _ City Clerk N-1 00 MWPUAL FROM C K Fia'm G Dowater-i r:.I CorM-vrYrtion F*m Maw. To dw MNr aft Meyw vid Cory CMaooii, Chy ot Mrriw>ll s m". Ceiifwsit: tw M will► t Mli� iMraillrr� Hai �ro�rwM� tlw t*ra I. -I I rn i s h i ng and Installing 4 590 L.F. of 12" Asbestos -Cement Pipe and Appurtenance,; Complete in Ricific Coast Highway from 9th Street to Goldenwest Street and 340 L.F. of 8" Asbestos - Cement Pipe and 135 L.F. of 6" Asbestos --Cement Pipe in Adjacent Streets in the City of Huntington Beech, California. CC 685. 1 IrW861 r►OOM wri WOO to MKM ilrt• a Wtttal to PrtwM dw wsrk Weis imiied o W 1r ftaaz#wA tM elele Wb ftgoeir MMWdk% to 1k. phow, 100aifW8tiMM and Ne1M prood wr for the aid wwtt lid 1M the Intl —11 is d Oi WdW tiro imp -- I i i a of dw DkWW of h6kc Wwks of rid My of MMtivgseo lemkCelifwow. The wakripW km mot ovespUd my bid how owy er wcwWme OM* my bias dopos%Wy, on by•lwrat, nth w i Videtkin rf ~ pohM w peowl dw ow el"10 ffes ool&OW@r* My bW how my iA& w i N MIME h "t P"WO % t1wevo OW bid iepolm W. At wbiA pmv N may errbe>MtNrt M1 MIIA1i►iiaaoa fmo Maifte to oar Wever r Who do" Mat tree a1 Iooiiw" of W •errpt burr hem w dww* ad bit ii}oWtwy. f�sr ttw hrrNi�irirr� e� � klbreT, w�rtiRtt re�i e�li i r,Mrt, eal ed eii ialriiep>�d rlarla laese�erlyr � irMaer oil 11r iw its O of 1 is Mrict with tb t I hft ir, o "own Bad spew pvmi@ MN file is 111e of t o 1Mwtuu City of i�eeia, C VOtaie, I ptyM~ rod Wn to take hd ry woot 1lrwr m at the Noss l q twit Wim, to snit: ITEM A"RCXIMATE ITEw1 Wily u►vIT PRICE UNIT NO OUANTITY WRI11fF1 fk Wonos PRICE TOTAL Furnish and Install 1 ?" A,,b `s e nt I 45gO- Pi;w a Apptirtviiances for �� � ��0�✓ � r l'urni sh and Install S' A;hest o,�-C nt � t 2 340- L.F. Pipe and k rtenancer far ,, 2.�p�,�,. Boring using 0" P 1/h" Wall 1,teel � 3 95' L.F. Casing and 12" if 1. •el k' •1 Carr r 'ipt, tor Baring using; M" 0 8" W-111 :steel 4 82L.F. Cnsi � d •" ►.�; • art r Pipe for ` rcr 1. Ti-e IIYTiT(c Furnish and Install 6" A,hrstos Ce nt 5 1351 I..F. Pi r' d put cnances for r Tinr.n I;Iit F-1 4 �± ' . F -. � .� 1 a� � , � , a �. 'y r t 0 er It is wrdwitoorf &od syrow that the approx5mete gwntttres show~ in the fwo"rq propew sd odnl# we "" IN the PWOM of hrWfttirq the cot~ wis" of bids and that thl coots" a's ie wqw i two make GMrs*WW apes the mess of do low 40 rrEft M in dw 6000etod erork, srhothw Hr#y be "we w for "" shays $ban hwwrt of the Meat pane►, Rita in the prspmol selok s. 'fire --aft MndorttW* the coRtrart time limit MWt#d fa the eenttact It 90 crt i enda r M semi dw I o or, tfre rrrderovald hw*y sprM to OF sir! aorrtroct &nd frtrtrisM the "am I kart& wi" ton (101 lb" of des WArd of MW coeb t, wrest to re& wwk wiitirt in (10 doyen from the do% of ipp wtl of do me. trust by taro My of Iltrndrtgt" Mods, CNifwtoie. TIw i nk si acd hos trtct►tstirrod onfolly the site of fhs week Gontiomplatsd, tU pions &ad sprtaihotion, osrd tiro propori IMW trotrtrec't fortsrs skeeter. The w6wis4o of a bid stroll be coodusiw evidence %Mot rho bii w hest anreetipsW steed ie ogefierl oe is the aNlitierst to be emoli twed, as to the clrirWx, gouty, &nd mope of work is be por*mW, tfre grrwrddu of woftiok to be fwnWmd, arrtf as to the regoirnrrerrts of the propswil. /Mom. qwWwt . orrd the a~. Ammpeagitrl this proposl is I'la NOTICE: haslet the molds "Cash," "CartNierl Chod," w "b"w's homy" as tk case newt► be. in an onrwat agwoi to of isms 11 poroorrt of the tot~ bill price, poyorle to dK City of Nrntkgtoo isK%. Tiro wrdorsipW deposits the &Mare trmW socwity as a proposi porasty arrd arm resat n !half re forfetted to tfro City of ff~a &M A as ligaidatad dowatstt ill coss this propeal is aeoopted by the City and 412 * 1 kl ip i *Nl fait to examma eootractfw de4q sid wwk and to far*M pod sod wffx:i wt roofs in eft# form stet fortis ire 60 sonOW66 rat swoo+*M drNestrrtwj of dw City with srr►#ty wtirrfactory to the City widrie 1s days otter tiro bidder Mfrs rowill writton Win of taro award of tiro co~: othsrwin aid acuity **N be ►etwwd to tho wrt#ar:spM. liornMd in most 6r" with an art pr"irq for the rerstrot►on of aRtract t i"M No. 5 ",9 rrrsire s Addles :,� . ' �� '::•, , , • - RM of laridesta DOW ties dey of * . - ,, • r- , 1! bddw steak *nify rempt of all Addends hoe. if any AddsWein Me. Onto Pacaired P-- 3 "WI Srpgature page ED INFORMATION REWIRED OF DIDOERS Tfw liirriar* M rerfssirnsl ks sup>�r tisa follvwe+rsS infornwtion. Addrtiawf aheeq my be om rl d if may. 1. lrirrR fMMrsa• G' �: F'tc^.;� � ~t'L�i1 tc.'r•irt;t CAt'C'�^t`�1 t i �►t t Aitkrat ...89? (.�t�:ic•►tot ,�c'�>� :�:;�rt,zi hf.t ?, r':. ."'.3; y.".E-jw 3. Talephom +. Typ of firm — irmik kol, ponrowship, at corporation: '" C>1Tote. L {c►: S. Owls woOm orpnized under the laws of the State of IL cbrArsew's u9snaa Nurnba: . Ck*Wfkvtio+s of Contractor's License 7. S. !. 10. 11. Lht the nartwrt w%j sddreaats cri oil memban of the firm or narrwi and titles of all officers of the awporstbn: Numar ber of yes expar*we as a contractor in eorsstructson work: .: •'' tt't� Litt at loess six projects omitted as of recent date: (Contract amt.I (Class of warkl 10ate Corrspietedl 1140'tw usd addraas of Owrwr ) U• . � � �z • � LiSJ •'' ' Li:.� ■..Z - - l - {....M.i.�'.ri+ lip • - -• -- ... f......i..� �' ,� } / • rrrt..r.���ri ri 4 rl i:i�.R i�'u'L Ltst the warrw of the pe►uor who rnsoe"ad than sttr of the proposed work tot your firm Dote of inspoctson If red wod by the City, the b•dder shall fwnish a notatrtad financial statrmant, frnancral data. or other irsfo►nrtPon and rafworm" wfficreff"y sbrnproNer4la to prrrrsit on appraisal of his current fwm%oial oprwl~him •P--41 • , . . . 0% 40 DESIGNATION OF SUBCONTRACTORS In am"Plimce with the "Subletting oral Subcontroctrrrf Fair Practices Act" bei#4 Sections 4100.4113 of the b're?IIRs"m Caro 14 the We of Califtrwaio, mad say swnopdoomn thereto. mch Wd" %lull m forth below the mme and WoUse of the ltlem of bmineu of cock mkoffliedw who *9 perform Wmk w isiror or rendor Wvice to the Prime AA• "Utor im or obwt On eonmoetion of the *ph ee impro"awat m as "Mat M ,avm% of WN- otf (YI) of o+re P0apt 11%? of the Wioro aarr oom's total bid, and droll forthw cot froth tiro potion of the «reek wtrich will be do" by sect wbm- ttwtor. Only on whantndor for ae►ch potion :bolt be listed. If the aatrectw foils to Wily a submetroctor low any Portion of thv wak to be perfWarsd wader the t:ontract, he shalt be door W to hove ogsoed to Perfmm " Portion hi md. and he sawn set be permitted to u6contract that portion of the wont exeW rwdor the eoodit4m hereiaoh" sot forth. Sublettiag of wbtentrectiag of any portion of the work to which at wbcatrtractor was dV$iiWted in the orillinol bid *43 only be permitted in rases of public ettrtrpocy or trov"my, awd then only after a firedierg rodVew to rwitkq at a public record of the teoktivt Body of the owner. PORTt[NV STATE LICINU Of "ORK SU$CONTRAC►OR'S NAME AND ADDRESS NU "[A CLASS Py submission of the proposal, the contractor certilles: 1. That he is able to and wdi petfornr the balance of all work which is corerrd in the rebore subcontractor 1111 ►). 2. That the City wdf be forwnhird csPKs of all sob cnntrscts entered nrto and bonds franished by subcontractor for this proirm. p -5 REQUE��I' FOR CITY CdUNCO ACTION Deft December 5, 1985 Submitted to: Honorable Mayor and City Council APPROVED DY CITY COUNCIL Submitte+ti by: Charles W. Thompson, City Administrator C--.._.. _..12r..�:��� t Preprred by: Paul E. Cook, Director of Public Works TY CLi:" Subject: Furnishing and installing 4590 L.F. of 12" Asbestos-C wnt Pipe and'A4p tenances Cc plete in Pacific Coast Highway from 9th St. to Goldenwest St. CC 685 Consistent �;rith Council Policy? (X1 Yes ( I New Policy or Exception Ststenrrent of issue, Recommendation, Analysis, Fundinq Source, Alternative Actions, Attadimmtz: STATEMENT OF ISSUE: Pursuant to City Council approval on August 6, 1985, bids were received on December 5, 1985 for Pacific Coast Highway 12" Water Main Construction project. RECOMMENDATION: .'Accept the low bid of C.K. Pump and Dewatering and authorize the Mayor and City Clerk to execute an appropriate contract in the amount of $294,405.00. ANALYSIS: On August 6, 1985 the City Council rejected a sin le bid by Mncco Contractors which exceeded the Engineers Estimate by $51,390. 0 for Phase I. Phase I & II were then combined and Council authorized the Citv Clerk to advertise and invite sealed bids. Bids were then received and opened on December 5, 1985. The bids reviewed by staff and are summarized bc-! ow. CONTRACTOR BIt) 1. C.K. Pump b Dewatering $2940405.00 2. Peter C. David Co. 310,965.00 3. Macco Construction 3169378.00 4. Bobco Construction Co. 339,630.00 5. G.R. MrKervey Inc. 34?,865.00 6. John T. iial loy Inc. 381 ,870.00 7. Nick Tcrnovich & Son Inc. 394,630.00 8. Doty Bros. Equipt. Co. 453,155.00 FUNDING SOURCE Constraictioi~ amount: Construction Contingencies: Project Account #923--634 - Engineer's Estimate tLTERNATIVF. ACTION: Reject all bids and cost. CWT:PEC:EAE:ek PI C 444 $2949405.00 15 595.00 $3101000.00 Transmission and Construction for $310,000.00. for this project was $300,000.00. forego project until it later (into at possible higher ®r DATE: Decanter 5, 1985 Y ENGINEER'S ESTIMATE: _lW, GOO JOB AND CC NUMBER: 685 fa41110005POpplip, vs� — / 2//G�dsr BIDDERS NAME TOTAL DID AMOUNT Chaming Times Ent. Multi- Construction / tld Construction, Inc. p, 3 78' Tv-- Stoddard CarWy Mardon Susco Dixon Construction G.R. Mc Ke Inc. may}' ............. 7 3q Monarch f7cn—*_lz*"tlon of frame Doty Faros. Flluipne t ✓✓ Cx P rrp 6 Dewatering Corp. 1 qq, ' o Ri LSewer IM. La Peer Ompany, Inc. Dorf w. (x mt uctican Oonpa ty, Inc. DATT:1. -Decerber-51 1985 ow is ENGINEER'S ESTIMATE: 300j 000 Pace 2 JOB AND CC NUMBER: 685 BIDDERS NAPE TOTAL BID AMOUNT R T Bquipmnt T nnyson Pipeline Cc,►tpany Taylor - Jett Ccnpany Parksan Pipeline Materials Bobco Construction 3 3? 630 South Coast Boring Ni&. Tunvvich Inc. . 9 �, d 30 JdM T. malloj, Inc. gi i gel Peter C. David CaT ny .r / � g�► t•. 11i► S%operior Court fit 1►u +"1'ATF: (►F' 1'.%I.IFt►I(ti1.1 In and fist the I'tn1n1% •.! I ItanCr CITY OF HUNTINGTON BEACH CITY CLERK �tAtr • ; 1'�Ilf.anlA 1 ('.K1nt7r 11�Ilrattl'r 1M DARLENE H. MALONE The I am and Al A,I ;In1r. t.• if 1r I711 nt l.,ln.1 •..^ . ..1;1.' ! the ('nllmi �lAtr••. •I'..t the Air .t t1.••n!. t.r ,1 .t!• ♦t, t. tI I am n.•t a (lark t., rwr Intrrr.lr•t :r ttv .•t. r1,t,t;r.! that I am the lint), I(•,tl 1 I.'r1 1 tt.. ; r,1 1r • .! it.- HUNTINGTON BEACH IND. A REV. A neMe(y(1rt ••1,;rt1. fAI 1 tfl1l{.1t1.,•: I..tn,•h.•.! `f.• t. ! HUNTINGTON BEACH ('immIN . 1 I Iraner An.l ah,. h hru.I.n;+r ;. ,ta..f,.•1 I r it., 111+rm In At r..r1 ..1 1.- Ai n.'M- An•t ir �i j. n• r .1 ►. rlr!.4 • t,.,r 4, trt Anil Wh1. h 11r10i•(.A(.rr It 11; !,rr • . t.1 Ft t. P,r r111--1 r-•t t.,/ t anti still ha• A t..n,$ t../r . 11.•, t1(,I. r, n1 ..t i..1, .1.i And whlth r1rs,(M;.rr h... I.I.•. ..!At,1..!+.•; ;+r,t.tr•7 rf ^ ;•v 1 Inhrrl at rrv1.l.•r .n!r ri At. .: 1! . •n1•t ,_, + • • t ltal , r (1r11.01 r1fr"1111r ,n. ...r tt,..! t/.. r.t„1 At—t !h• annetrr! 1. A (.nnft.! ,,.t . /,.t. 1,. n +.,,r ..r.r•, ! r ft. C And entire 1uU. —, •.U! r:1 rI Ihrrn-1 -.r1 t•1. 1• 4.• av•j !.'. • �.• Oct. 31t Nov. 7+ 1983 I 1. • .I.. . • 1 1, .- . . , , ' , . ltrt' 1. tr+Ir 4111 , ••rir•. t Garden Grove I A1111d11Yr th.• 7 .1n1 , tic v. I. e 5 DARLENE H. MALONE '.,•:A! If' qkw w 1'11(,M W f)f I!'UBL,ICATI(Iti SEALLD BIDS CC-685 uwl.:'+1e�lurrrwlrl+c�+w�ww• ' t 1 r� ill' 6 att.nl titnliiM17i1W 41106 40 JKLA l t i Ir pi�rlll wlf�'Mi1+•% ar �.. /. • rdrMr�i 1 rt.ati tlwrt+t�llt t+llr +++Ir► atMtl t .r�af r�ww►rr�� t�ltdA.-�t� f�tt1. tart �wwlAtllMtrlaa � � �� Ad AR no" Mullis a 1011111M Alt • IW@ft Pdht WOW Tbp w rw owiffin• it M r a ow, xk fM %ft ister w.a aid dt III(Iwr;et,.C tye pwonft .t v r+.rt~ as +�► 4kiwu� twtlaw� � 7 f �tr via L -1000 Avow fi I l � w W aattrtlt ■ rat/ ..a w.. lawww � ��"(Aakt �Illk�w � dW w lib OM Arlw11�R 0 it cAgm ad AV" at. .o.rt rf 00 014 a!1111wdtow 1 r 11� �► ut� � Ra. t , .: r NOTICE INVITING SEALED BIOS CC-685 Notice is hereby given that the City Council of the City of Huntington BeacN California will receive sealed bids for the furnishing and installing 459G L.F. of 12" asbestos -cement pi a and apeurten,ances complete in Pacific Coast Hiigh,waXfrom 9th Street to Goldenwest ti"eest and 340 L.F. of 8" asoestos-cement pipe ano 135 L.F. of 6" asbestos os cement pip! in adjacent streets in the City of Huntington Beach, California in accordance witn the plans and specifications and special provisions on file in the office of the Directo: of Public Works.. Documents -Mill be available on yov 8, 1985. A charge of $10.00, not resfunaable, will be required fer each set, of specifications and accompanying drawings. DIRECTiDR OF PUBLICyyCRKS ESTIMATE Work Stem 1. Furnish & install 12" asrarstos-cement pipe and appurtenances 2. Furnizh & install V ast)estos-cerrent pine ar,a appurtenances 3. Boring using, 20" ) steel pipe (snwnthj w1'3/6" thick wall wtCh t2" 'a 10ga. sl eet cv, . carr{.er. piYe 49. Boring using 10" 3teel ploe ; Stncutn) w j 3 j8" thick wail :ri:h -'4" A.C. .:arrter pipe 5. Furnish and install !)" dMe 3tcs-cent ent Aire anO apourtenarce ruantity 1%, 5 90 L.F. 3.+0 L.F. 95 L.F . 12 L-F- 155 L.F. ;n accorJar.ce with the provisions of Section 1773 of Vie Lacer Code, the State of California, Director of the Department of Industrial Relations snail determine the gerpral prevailing r3te of wages, apoitc it,le to tthe mark to be ccne; cnpiex of the latest general wage rate ��eterminatiors are of, file at the office of the City C;erk and the office of the Director of Public 'N%:r�ts o` the City of eear. -,jhfornia. Plans and svectficat:ons, togerner with ;,ecpasal forin, ma.. be actained at Me office of the :7trector of Punitc 'hw'As, :it. Hall, F�t,r,ttn;�tun '?c'acn. California. I"tio bid will be receive„ Carless it is mace on a bank form furnished by the Direct.r of Public Works. The special attention of prospective wccers is called to the pr posal requirements, set forth in the 3pectfications, for full directions as to the bidding. i`4-1 The above quantitias are approximate only, being given as a basis for the comparison of bids, and the City of Ht;ntiNton Beach dots not express or by implicstiuns agree that the actual amount of work will correspond therewith but reserves the right to increase or decrease the smcunt of any class or portion of the wcrk, as may be deemtd necessary or expedient by the Director of Public Works. All bids will be compared on the basis of the Director of Public Works estimate of the quantities of vicrk to be done. Substitution of securities for any monies withheld by the City to insure performance shall be permitted in accordance with provisions of the California Government Code, Section 4590. Each bid shall be made out on a form to be obtained at the office of tie Dtrwor of Public Works, Development Wing, 2000 Main Street, Huntirgton Beach, California; shall be sealed and filer) wcth the City Clerk at the Civic Center, Second Floor Administration Building, 7-O00 Main Street, Hur,tirt3tan Beach, California, on or t:efore 10:00 A.M. of Dec 5 , 1985, and shall oe opened ny a committee coec posed of the. City Clerk, the City Attorney and Director of Pt-blic Works or their authorized representative wid the results of said bidding will be reported to the City Council of said City cf Huntington Beach at their regular meeting to be held on Monday, the Vic 16 1985, at the hci-r of 7:30 P..M. in the Cite COLncil Char-rers in the Cive: Center of said Ca j of Hejr!ington Beach, and snali be acted upon by sae(j C,ty Council at the regular :reeting of tie-;. !6 , 1985. The :ety of Huntington Beach, California reserves the ri;rt to reject any sr all olds, ant; to accept the bid deemed for t;ir best interest of the :-"ity of Hue1cingtoii 9eac'I, Califutfua. By or.er of tee: City Courcil of ;he Car of Huntington Brjch, C:.Iiefcrnts this Jar. 7 .9•,.,.G.r 1995. -�J ATTEST: Alicia Went^arth City Cle3ri► N•2 2000 MAIN STREET Paul E. Cook Director To City Clerk: ..Notice Inviting Sealed Bids #0 / 1-3 / /�f/7 UNTUY NEI ON ACH P. 0. SOX 190 CALIFORNIA Pub k Works Drprwtrr�rnt (714) $38401 Publication in Huntington Beach News on , - 0 _. Remarks: Authorization from City Council to advertise -C.- Bid fining Date Time i Engineer's Estimate-_--, -= w.: rrvM�r `.� �Ir. ■ yerruly ur ,. Cook Director of Public works PEC:JFM:lw 7 ►RE QUeZ� if FOR CITY CDUN ACTION Date July 24, 1985 Submitted to: Honorable Mayor and City Council Charles W. Thom son Ciy or ►: � Administrator Submitted by: ha r � Prepared by: rk75, Paul E. Cook, Director of Public CKA Su 12" Watermain, 11acif is Coast Highway, 9th St . to 14th St (Phase 1) .. y .. Consktent with Council Policy? (X) Yes ( J Now Policy or Exception Statement of Issue, Recommendation, Analysis, Fundinq Source, Alternative Actions, AtW*vvwnts: STATEMENT OF ISSUE: Pursuant to Council approval on January 7, 1985, bids were received July 23, 1985. RECOMMENDATION: Reject single bid which exceeds the Engineer's Estimate. Combine Phase I in Phase II plans and authorize and direct City Clark to advertise and in- vite sealed bids as soon as the State Permit for Phase II is issued. ANALYSIS: Singl` bid: 1. Hacco Constructors, Inc. $144,390.00 The Engineer's Estimate is $93,000•00. FUNDING SOURCE: Water Division Capital Outlav Account No,. 920942. ALTERNATIVE. AC"PION: Accept single bid at high cast. CWT:PEC:EAE:ek I r rro eaee ►.7 �.: ' JUly 23, 1"S _r • r wr r w err 1• � 'Fitt, mo. 41 '� '� • "• =` ::C':•ir3:',r. 12" WAt4mv& n P.C.H. 9th St. to 14th St. "r: S TOTAL B I3 hMP%O%VNT j Duty Bmthw me= cona � � �/ ; 7 0 trtc Inc. G • R. MCge-- y, Inc. Pa --kson Pixlis* ' R i L Sees F ju]y 23, 1"S 9!,«rs. r►1G�':l:t:i?' , ESTIMATE: $93,000.90 ,r� ors t'C t�L218F.T:. 12" watmain P.C.H. - 9th St. to loth St. IBnErS NAME j TOTAL ETD MOVNT Doty Hrothex's C Mecroo omtruction, Inc i � /�� G. R. McKerM, Inc. Parkson Pipeline R 6 L Se4ers J ftecl" CITY Ma • C 1" IF - - ---wgN7i�gTOM tiCACM• C A! ;F• JuL 23 10 01 AM '95 W D�•V�ZI� NOTICE dNVITING SEALED BIDS CC -685 Notice is hereby given that the City Council of the City of Huntington Beach, California will receive waled bids for the furnishi and installi 1670 L.F. of 12" asbestos -cement i and appurtenances com leta in Pacific Coast Hi nwav from 9th Street to lath Street and l82 L.F. of 8" asbestos-cement-Zil2e and ap urtenances complete in 9tN !0t Ill 12th, l th, and 14th Streets in the City of Huntington t3eact4 California in accordance with the plans and specifications and special provisions on file in the office of the Director of Public Works. Documents will be available on July It 1985. A charge of $25.00, not refundable, will be required for each set of specifications and accompanying drawings. DIRECTOR OF Pt F-LIC WORKS ESTIMATE Itiark Item Quantity I. Furnish & install 1 ?," asbestos -cement. pipe and aDoLrtenar.ces l -i0 L.F. ?. Furnisn ,5 install 8" asbestos-ceinert otpe arc: appurtenances 1821 L.F. 3. Boring using 2L" ) steel pipe ;smooth; W,;3, 8" thick hall 95 LF. In accordance with t:,%e provisions of Section 1773 of the Laoor Code. the State of California, Director of the Department of Industrial Ftelaticns shall determine tt-e general prevailing rate of wages, applicable to the work to ae clone; copies of the latest general ovage rate determinations are on file at the office of the Cit. Clerk and the office of the Director of Public Works of the r-ity of H-untinrton 3each, California. Plans and specifications, together *tth proposal form, may oe cataired at the office of the Director of Public ',14ork% City nail, `"Lntington 3eacn. CalIVOtnia. No bid will be received unless it is mace on a 1larK form furnished b fr the Director of Public ':forks. The special attenticn of prospective nic cers is called to the proposal requirements, set forth in the specifications, fzr full airectiors as to the bidding. The above quantities are approximate anly, beirg givers as a basis for the c:orrparison of Aids, and the City of r"untinrton Beacn dies rot express or ay implicaticns agree that the actual amount of work will correspond therewith aut reserves the right to increase or cecrease the amount of any class or portion of the .ark, as may be deemed necessary or expedient by the Director sf Public '.Vcrka, ,4 ; All bids will be compared on the basis of the, Director of Public Works estimate of the quantities of work to be done. Substitution of securities for any monies wi:hhel4 by the City to insure performance shall be permitted in accordance with provisions of the California Government Code, Section 459O. Each bid shall be made out on a form to be obtained at the office of the Director of Public Works, Development Wing, 2000 Main Street, Huntington Beach, California; shall be sealed and filed with the City Clerk at the Civic Center, Second Floor Administration Building, 2000 plain Street, Huntington Beach California, on or before IWO A.M. of July 23, 1985, and shall be opened by a committee composed of the City Cleric, the City Attorney and Director of Public Works or their authorized representative and the results of said bidding will be reported to the City Council of said City of Huntington Beach at their regular meeting to be held on UAW, the 6th of August, 19051, at the hour of 1s30 P.M. !n the City Council Chambers in the Civic Center of said City of Funtington Beach, and shall be acted upon by said City Council at the regular meeting of August 6, 1965. The City of Huntington Beach, California reserves the right to reject any or all bids, and to accept the bid deemed for the best interest of the City of Huntington Beach, California. By order of the City Council of the City of Huntington Beach, California this 7tn of Jan., 1935. ATTEST: Alicia Wentworth City Cleru 0 N-2 FCITY OF HUNTINLa i IOLV 2000 MAIN STREET P.O. Box Igo CALIFORNIA Paul E. Cook Director To City Clerk: V Notice Inviting Sealed Bids Public Works Dep Sffwwm (714) 636t1 XPublication in Huntington Beach Netr!s on 442 Remarks: Authorization from City Council to advertise 110hiij-4 Bid Opening DatejJ4'�+ " ' Time Engineer's Estimate er ruly ur , C Ps 1 E. Cook Director of Public Works PEC: JP'I: lw REQUE..T FOR CITY COUNC I'. ACTION Date June 5 , 198 5 Submitted to, Honorable Mayor and Council �PUVED eY CITY COUNCIL Submittad by- Charles W. Thompson, City Administrator �., ¢-1�19 Prepwud by: Paul E . Cook, Director of Public Works 7��-t'��-------��--==---� cirY cl.rauc Subject: Furnishing & Installing 1766 L.F. of 12" ACP in Pacific Coast Hwy from 9th St. to 14th St. b 205 L.F. of 8" ACP in 9th, 10th, llth, 12th, 1 kh b 14th St. Consistint with Council Policy? (XI Yes ( ) New Policy or ExcWion cc -.CBS' Statement of Issue, R9comnwrndation, Analysis, Fundinq Source, Ahernative Actions. AttidNnwrnes: T / STATEMENT OF ISSUE: Pursuant to Council approval on January 7, 1985, bids were received May 30, 1985. RECOMMENDATION: *Au t 8" bid- ecause they exceed the Engine-er's Estimate. Also, the bid o r. a ow bidder Thiidn Construction Co. �ws found to ae il roper. rize and di meet City C' car to re -advertise and i»vite sealed b ds. ANALYSIS: Bids were as follows: I. Thibido Construction $99,322.00 Dabco Construction $12-3,571.00 3. Changing Tinrs Enterprises $124,784.00 4. Sinich Construction Co. $130,350.40 5. John 1' . Malloy S152,860.00 The Engineer's Estimate is $93,000.00. FUNDING SOURCE: : Water Division Capital Outlay Account No. 920-94:1. ALTERNATIVE ACTION: Delay construction to a later date which will result in a higher cost. CWf:PEC:EAE:ek Mo4sa s Submitted to: Submitted by: Pretmvd by: REQUEC " FOR CITY COUNCO ACTION Dete December 26, 1984 Honorable Mayor and City Council Charles W. Thompson, City Administrato Paul E. Cook, Director of Public Works Sut�ject: Furnishing arrl installing 1766 lineal feet of 12" FAlO%'iU UY GITY 66UNCIL r 19. �ey CITY CLrR _ water main it eafeet of 8" water main in Pacific Coast Highway from 9th St. to 14th. St. CC 685 Corawtent with Council Pu+icy7 Dq Yap ( ) Nm Policy or Exc+Mion Stake elnt of Isww, Aecommerxietion, And:, Fundioq Source, Altw7wdw Acts, AttadhM m: STATEMENT OF ISSUE: Council approvRI is sought to solicit bids for the furnishing and installing of 1766 lineal feet of 1.2" water main and 205 lineal feet of 8" water main in Pacific Coat Highway from 9th St. to 14th St, and adjacent streets, also, to bore ac.rosn Pacific Coast 'Pighway at 9th St. RECOMMENDATION: 1. p rove pins and specifications. 2. Direct the city Clerk of publish Notice Inviting Sealed Bids. ANALYSIS: SIs the first of a three phase project to complete a water main loop ito phis area of the city. It is necessary to improve the circulation and to r provide fire flows. The Engineer's Estimate is $93,000.00. This project was approved in the Five-year Capital Improvement Plan. v FUNDING SOUKCE: Water givislon Capital Outlay Account No. 920-942 $93,000.00 le,viing a balance of $82,000.00 in this account. ALTERNATIVE ACTION: Delay construction to a later data which will result in a higher cost. CWT : PEC : E:AE : ERC : pa Attachment Flo -SM G' � 1 SECTIONAL DISTRICT MAP 10-6-II CITY OF HUNTINGTON BEACH A ORANGY: COUNTY, CALIFORNIA USE OF PROPERTY MAP PwojEcu LOCAU10V i tt�+1t'tirn� �i X !71 PAU, CITY1'" i-�UNT11�1C�iY ON ..,AkCH 2000 MAIN STREET P. O. BOx 190 CALIFORNIA 9" Paul E. Cook Dkector To City Clerk: 0 Notice Inviting Sealed Bids Public Works D*partn % (714) 536.6431 ® Publication in Huntington Beach News on �A . S . &,,,P,t , Remarks: Authorization from City Council to advertise 1-7-85 • Bid Opening Date 5-30-85 Time 10.00am . Engineer's Estimate 393t000.00 . yer ruly ur , Pa 1. E E. Cook Direr, --or of Public Works PEC:JFM:1w NOTICE INVITING SEALED BIDS CC-665 Notice is hereby given that the City Council of the City of Huntington Beatty California will receive sealed bids for the furnishiN and installs 17" L.F. of 12" asbestos -cement pipe and appurtenances complete In scific Coast Highway from 9th Street to qt Meat and Zg5 L.F. of 8" asbestos -cement oioe and Waurtenances cofrwlete In 9th. 10th. I ith. 12th, 13th., and 14th Streets in the City of Huntington Beach, California In accordance with the plans and specifications and special ,provisions on file in t1w office of the Director of Public Works. Documents will be available on May 16 1985. A charge of 5.00, not refundable, will be required for each set of specifications a d accompanying drawings. DIRECTOR OF PUBLIC WCRKS ESTIMATE Work Item 1. Furnish & install 12" asbestos-cemr:nt pipe and appurtenancer. 2. Furnish h install 8" asbestos -cement pipe and appurtenances 3. Baring using 20" P steed pipe (sillooth) W/3/8" thick wall 4. Replace A.C. pavement Quantiq 1,766 L.F. 205 L.F. 70 L.F. 3,85n S.F. In accoroance with the provisions of Section 1773 of, the Labor Code, the State of California, Director of the Department of Industrial Relation• shall determine the general prevailing rate of wages, applicable iz-) the work to be done; copies of true latest general wage rate determintions are on file at thr office of the City Clerk and the office, of the Director of Public Works i,f the City of Huntington 13each, California. Plan^ and ortimificatiorts, together with proposal form, may be obtained at the office of the Director of Public Work -a, City Hali, Huntington Beach, California. No bid will be received unless it is made on a blank form furnished by the Director of Public WnAt . The special attention of pra%4)ective bidders is called to the proposal requirement% set forth in the specifications, for full directions as to the bidding. The above quantities are approximate only, being given as a basis for the comparison of bids, and the City of Huntington Beach does not esxpross or by implications agree that the actual ;mount of work will correspond therewith but reset,ves the right to incruaere or decrease the amount of any class or portion of the work, as may be deemed nec:ewary or expedient by the Director of Public Works. N-1 0 _ -1 0 All bids w!U be compared on the basis of the Director of Public Works estimate of Um quantities of work to be done.. Substitution of securities for any monies withheld by the City to insure performance shall be permitted in accordance with provisions of the California Government Coda, Section 4590. Each bid shall be made out on a forts to be obtained at the office of the Director of Public Works. Development Wing, 2000 Main Street, Huntington Beady California; shall be sealed and :filed with the City Clerk at the Civic Center, Second Floor Administratimi Building, 2000 Main Street, Huntington BeacN California, on or before IOs00 A.M. of May 30, 1985, and shall be opened by a committee composed of the City Cleric, the City Attorney and Director of (public Works or their authorized representaLU've ,od ►,!.s results of said bidding will be reported to the City Council of sa:d City of Huntington Beach at their regular meeting to be held on Monday, the 17th of .}use, 19859 at tt4e hour of 7:30 P.M. in the City Council Chambers in the Civic Center of said City of Huntington Beach, and shall be acted upon by said City Council at the regular meeting of June 17, 1985. The City of Huntington Beach, California reserves the right to rejact any or all bids, and to accept tho bid cleertied for the bast interest of the City of Huntington Beach, California. By order of the City Council of the City of Huntington beach. California this 7th of Jan., 1985. ATTEST: Alicia Wentworth City Clerk N-2 IN rnt Superior Court or THI STATE OFCALIFORNIA In and feu the Counts of Orange CITY OF HUNTINGTON BEACH CITY CLERK State of "Ifornea I County of Orange ra" DARLENE H. MALONE That I am and at 411 time herrtn mrnttt•nr%f %a• a r ittirn rA the United States, mer the age off/twent% erne -ev% and that I am not a party w, txor tnter"teri In tho a!■r%r rntrtle.t nrAlter that I am the principal clerk if the prtntrt r,f the Huntington Beach Ind. & Rev. a newspaper of general cttcufatt m p.rhltahe.l In the C.t► .J Huntington Beach Ctrtnty to( Orange and nhich rw*% al.rr is i,001sh—i It,( the dwmtn&%A,n of Weal new► arui rntelittrn. r if a trnera! charm ter, and which nrwspatter at a!) ttmrs torte.-1 men,-n-1 ha.I and still has a N-na fide sul...crtptu-n list .rf l.atarta slibu-rtr.rrs ar.d which nra.paprr has turn ratwhli%t,r1 hrtnint and pub ltshed at regular intemala to the said t'-atnt. A thanjr f„r s -aervad ♦-rtt-cdtng one year that the n-due ref at-h thf annexed is a printed clop•., ha,• I'..n lrut-ltahed in the retutar at.d entire L"ur of twrf newstoat: • and ".it in an% anplrlement ther"4. on the (oil-rl lug tint". to art rila r 16, 23, 1985 .er•.f% tr.t d#4Ia•►r I - ter IWtIn! r r ./t., the t,Ns IIt$ to trur aIml (reef, t lintetiat GArden Grove CSJ14nus, this , "23 dad r,► ' Mow,, II1UMOE �. "ALONE Signature 7� PROOF OF YuH1.iCATluu BID CC-685 - - aawat Abli +,ht,�' t a -Mint, txatrrar at tfw >arptawr+Nt d DIY ItiR a qWo tAn/ tteeaaitr seer of go" MIW4 4 ttie� aq� a►iit �w�t 1 aKaatat wee waft �saerassaalaaa an etW at a r ate ��► ta. tttt�sra � errs. tit.. -tat a,f 1ira,tatswawr ter ,... *r r+.o �. �i rf t11. trraaw w • �u W pant wi his wrrw./ 9*0 ! IS &A& rs c WDS'061%stj 1� 1 tin t� eta Wit►1W �r aNa Mnl tN• welyd� inla ON airless ea ■ { tawrttw tin ►alit to laaas at frwcatrr t o d aaa ter --rear Mtn I" be dwand am am 5 of ansIo al win 6tttta at at tltirtAr r! 1ia of thud M it Tura awe 111111111 iac •aaerinntn W& fft%b* ► M iri.l lei t wd W r raalda saga ee in w Kh", in 1Aoalrrs at3aidaat.�tanlI�ut yjty� i it as tr tart- iMlp w/ ilw i1 >NR sari 1r w Novi earl �-.�i a rarer �trrtr�r att� �tt�w ItfiMit awwtratr teat rb . rii 'lr tlw l � inttttrarana am* i iwr rs � a brs�ytr� `ter w UtiMo at tat►1010 at tip r .t..rA iRear+ at ft CIO of N ft�a- tar asld aarrl C�ttr saner to uw .te a w+�W �ntt wrrrrtw at to (Ze M6�et�.o ft .A t .�iti�*a,ar TM�� .tar, c7t, ce,anr-: r. c;a, d N..yrgaa+ �,�, Giir..r tMa ?IA +�it1a �ti:+t.w�r I1411 � 1� t,t Oka assi , ia5 a the aft ,�.. USTIMAT : CC-685 tas CMnt Pipe,/PCH frm 9th to 14th TOP A*W CC NV?•lBrF.: Is122 00c) BIDDERS NAME John T. Mallay Marden Susm Parkson, R t L Sewers S imich Construct -ion CarpaM, TOTAL BID AMOUNT i $ $ /.A2. I 8 n 1.3 0/ 3 VO 4 fC? nAbodo ConstruCtjOA cfi7 Superior Court r le r11 t In and f,•r thr 1•4Htnt% 0 I Irma}, CITt OF HUNTINGTON BEACH State td /'alit„miA DARLENE H. MALONE ThAl I Am •n•t it .II Ilrur• h.r, I r., . r,.•t r, • r the I ntlfr! Stat,•• •%#-? thr .;r trrr r . :. ., ,r• , , t..' 1 ani and a 1%4►t% I- r.•,r Itlirrr.l,•.1 -r'. Ili, .,t. �. , r,•.. •••. the: I Am thr term. q,11 • (rt1 "I th, rir•rr'• • ' 'r•. HUNTINGTON BEACH IND. A REV. a nrriilwtvr A grrlrrA; , in ,I,e', j• .1 .!•....t .. r HUNTINGTON BEACH 1':.41rlti, ,.1 1 IrIr,;. ♦r t rh„ t. , rr.t,..;.. . 1.,,,., , , , ..., r11•4-minat,..n • f , -,,I nrv.• Ar•.t u,r, :•�. • ,, , , ,, n• .. irr And -a hi. tr T,l,A j,:,j,rr 4t ,�. I.• ... r.. r..• , ail,: •t,11 hA• 1 fll nn Arld shah nrw.l..rl.t t.i• lry l' ,.!A t. .. r., •. •.•.•' + ' , t• IIs, hr+t At ►rf!viAt r.}rf. i.• . r• 't.r .�,.} r r ,• •.y r r IM•rl.rt air rr .t,ne ..n, .,mot 'h., ". 4ntic tart 1• A j•►rr,l,+t ,..1.� ,,,. •rr•• I .+ .. ,,. •,.r r•;.. �.•• and rr,tlr,• 1••U, ,f •.1 i.t •rr•f.•Ij. ,•i. •' , 1. . their, .1 -- tt,r t ,i••.► r •t.tr. July 4, 11, Po' till: r• tf•It r},•1 art. I 3jrdcr; Grove 12 July 1 . 65 t 411f,Ifi1 thl• . DARLENE 4. MALONE•.; •,AI ,tr I'll. a ►r' I_If' Ill 141.1C Wit„ BID CC-685 Air.t Aw � iti � aAtttfriTtlr #'�i IRA Att Jt k I. OW A A it 216ft ow plt '• AYrrltAtltt stf t %at iiAll I �i ous lr re604womme pipwr i 1 lttraln! ♦ fibril r ffl"tet4 alt6 pp mck :l�,�,� IN" W 0 .iMt P" bore WAR' 1 (1�.. ), Mii IS *16 aird��>A tI S t,! dt 5,111wr i' r#A A- tat. l owsw a do Irul rAAnAw d Hldttuf %Wd 4111110 ` E arr+,.rat pro^% wte aft$ is Rlma rasrtlf MW Mg &%PMWIMtfM 40 is Ab di wI+ for aA G 94 * ** Pftvm r(Nuk µebot i3tlt d lltteAlll�I! Na W .4l Ir odwom'1 wlta It r OR • Iltw�ft tat fhi•Atr i1lAAllr 'f Ott arettal�tall ql �tltt{Iae1pa11 eaittMewAl11I, Mft tltl�it fr ifs+ tyar%�ttti�tr, sett i�1k11Ar to to V"ww" 08 Mae to "Mow� trlA m anAt fm � Stan" ►>f 04PAW A! lilt � r Ord w t� itfltr fftf Yltf►OL' of We d "tof•to do& If +Iraillt fltA.tl eetl( etIallMe Ltwfi m Iem «� rAAl ltittyl.o ok Ifni lM�t#4 W amb or m IF Omit is Is aif N&A M an son w IrtrC M wr1�1•1111f�tde�, i�iM6���(,�1jNirt�y�Ir MAen.r tf >fr 1l at a+e(1 1MI.:�fi tii iltLb=ua. �Moot Ms6 eta taty C r)tl Arlrrllr 1ktAeeite 14i,11re a/� A w li tf tttwAlA t�etl ltrfi�ilMpl ve rN1etIF.A.r to " at an wa.141r.raw 31 fdtt' ~ +r Agf'+S. Ittlt:, a ►!r bptrr ./ I.7t11 r>1► It Mft / •tlttttarr k w w d err+ f d t*tww+mirrAl,, "rA " to (rl(II V wd wo k& OWw �m ilr 4i1te IrMM�! IMt1i1P► �� • t N c" lywA d of C* of Mltlliwe bwk cahaoft,ft dAAN,Ift ArrW.. II'a (to* M. Z, It, it. (i1R K A ilfts's swab kid Ntw I" lb Mi-OLA-ANCE INMER-A1444 COMPAWY HGA0 OFFICE, PHILADELPHIA. PENNSYLVANIA PMVER OF ATTORNEY KNOW ALL MEN •Y THE;E tAEEENTL, Thal the RELIANCE INSURANCE COMPANY, is dirftr o►pomved Itrtdeor Itte fans$ of Ito Sq M a �rlRFtf edttte• OpNiotav me**. conotrtwtt erlfi apmtnt E.S. A BR.SCHT , JR • of LOS ZGELSS , CA.LTF7,�.1.t71A--- Its true and sawtfuf Attot Wt4f►Fon. to rttoko, execute. eaaP and CWMW tttt slid on bit boftall, and ee its art mind Jaed ANY AND ALL BOi S A.',*J UNDE1.17A ING'`'i OF SUP. TTSHwP------ WWI* blind the RELIANCE INSURANCE COMPANY thressy et Islay and to" Sartts olnP.wt so of w•xn bonM alsd uOUNV litnq/ and other eteserr is oblyatory in the nature tharoof rwro t•gAod by an Extvultw Otf,aots al this RELIANCE INSURANCE CCNPANY a.,t+wed bnd atteltoq tw orxs srtott of such officers. +.rd hetetty ratrfrea and confrrrta oft that its old Anornerfit).n-Fes R*-! d* in puttwnct/ Aerrol. This Poaxsr of Ateorney is granted undfr and by sutttorrt of Annie V11 of tFA BV.UM%of RELIANCE INSURA14CC CCMAANY ftbim %%nowrwt effective Septeeno r ). 1978. whrtdt rRovrttoes are nave on ful; fatal and often. roo4.nu as I7+k ywl AnTICLE Vtt .. EXECUTIOU Of NONOS AND UNDERTAK114G3 1. The 1204r4 of OrrocYors, the 1"resraertt, iM r.210rfttrtn of the Board. any SaCrrat V•= 1i►tn.cfrot, any Via Prtsarrsont of A4ustent Vt<s A*snlert fa when offtan desrgnatod by the Board of Drteaors spelt Rave Oowrer and outhottiv to (41 &ppo:nt Attotnays.n•100 and to ewhortttt them to exec Is afn behalf of the Company. bones and unlartaitngs, faccsgrrtartesrs, contracts If lindetratity ehd Days wM-t•c+gs ooluptlMy on the natYte I"of.and 1b) W rantgve any tuck Altorneyan•F*ct in any tine and rewcap the Iroviver Ind mahptrty 04um to torso. 2. Attormys•tn4sct tall have Or -wow and outhwity. subsea lit• the Minis and 1~Strons at IPW potter of attorney +slued to 1Mtw, tV ellacwto Slid I$MrvM on N"d of the Car mmny. boon4s wid urtderts,'iwega, retmWi4ontat Coniretcts of tttalenttt.tr end othw wwrtutgr 006-oeto v tr► the psta+re tlwt"(. 7)K• Corporate twee to not nootarwy for the validity of any IMIKN old ratz""rta•ces. contract) of snommottnrty arrd rids wrrrlw4l ob+grtory b the nature thereof. 3. Anorneyrttt•Fact thall hat* pnwev 4+t4 awhorlty to ant;(vt1 4114a's is to-,h.traO to tw artoctwd 49 bonom. tootgnrta,vvt. CoAtrf -is of indent null or otter =ondttronal or ablrpatruy unaettax once end they Shell Na love troval and awInwily to comity flan I.ryrK,Ll fteleir"ll of the Cotr4nnr and to copra of the By•I.awe of the Co.-rwny or any anKle ev settroo thereat. This power of xttorriery is %W" and tlalod by twitwlrle under and by whtfrrty of the foltownrM R000lutrltt allotted sty the Noard of Urreno•s at RELIANCE INSURANCE COMr'AN1r as a rrvwtrnp heed on the Eth airy 01 1VO4, 1979. et Wt•ot" a Q l0fWM nOt fkNenl and Nd Rerotul,gn Not AOI bran arnK•ded orrecweaad. "Ntrtolvrd. that the e#"nores of ►ueh droclo•t aftd eltScs.s and tree seat of Ike Contcony rney ter affuud to any suet+ power of xltoinay or any croriot t;atw reW lnq the►rte bir eat Mail. arw ani Such (Vlore+ of atlorMt' r/ CeridKAtt biWanq IWCN tK,rnula spr+aturn of laptnulo most shell be wlod fnd btftdW4 ws3r+ the Cortgaanl and any such Ifo+rw to eaac4tr4 eAd C:rn01e11 by feaartrrle str4tirree and fectrtrfrle sad toast be valid and brng.nq upon the C-10 000 y lit+ the future rrt,h rtttprcl to any bows! Or trndomArnd to tt'ltctt it is attacf+td .. IN WITNESS VO4E PEOF, the RELIANCE INSURANCE COMPANY has caevaed lhsr prernll to be I•gMd by oil VtCe ►rrs-dent. snd.rs oo'col •rts illµ to N hatelo eftnaJ, this 30th day 9f J=e I9 3 REL1ANCfr00URANC M►ANY ff v& :I VK.w iit'MOoni `4 1 PATE OF Wani, i rip', iCr', COUNTY OF King On this 3G4,h day of , •il1 a 19 bo1...%n4l1V POP* eted Charles B. .Sch-al: to me known to be shot V.ce p ers-loam of the ZE LIANCC INSURANCE COMPANY atoll schno"reopd shot he odrruttti ono sttisr-ya th• forrparq InRr"tnonf and Ofreed the trip of sold corporatasn t►.etata, end Mat AtIvOe VII, Settton 1. 2. and ] of the ly•I.eftt of m.4 Co+nOar►y and the Roalyt• Iron, aft forth Irtrtetn, ere still rt fun Inca. •; \` f ���� a» f* Cof otmemaA EVOra7 �.;:.t!� (,,.r•.'� ��L1r� �C��...IC. � :-s-44 July ZO , tip e6 Ntlorr ►writ: Cn sew l w ttata offta hI n .gon M/doV of Mil t a n 1. Chlrles J.. Falskow . Awtsrant Swevolety of the RELIANCE INSURANCE COMPANY. F.kt hoteby sends that Ikea%*" ashen Iwtlp,nq It a true ohd aeons" soh of a Power of Attooll," esotvlod try said RE LIANCE INSURANCE COV#AhIr. taOhtah ra e1.11 low frtfl $Draw 11100111111 veto". 22nd .lrinuary Ap IN WITNES.t WHIAEOK. I few /ettiw+o eve my paved a-ltd offl"M IM teal of $ad Came" I" d" of 1• }• Aarteawt Easlrtrsalr 60A'143I 14 eM � •...� " i 1 � i r • l..ly MAINTENANCE 9014D ��. mid ."O►. B53 39 •.17 (M) EXECUTED IN TR I PL ICAT'E '1%v Pyt$NhRJ c63'.r>ttd for rim rt;:At7 QPO"1CC ►r•rrLADELP►W,A, PENN9'r't,V"1,#. &Md 4 inc!r'-!, d in th.-'t d wwn at 16 Ptrl(Irraaatr fMd." KNOW ALL MEN BY THESE P9ESENTS, that we C K PUMP 6 DEWAT'ERINC CORPORATION Post Office aox 2800, Long Bear.h, CA 90801-----_-__--- -- _----_ asPrin.1pal, aid RELIANCE INSURANCE COMPANY, a Pennsylvania corporation, as Surety, art_' held and firmly bound onto CITY OF I(MrlNCTON BEACH di t ir)l ';vex i►-, the f'J11 anti lust SUM of 1%klo fiL`�T!kt:O hIh'F:Ti'--FOUR THOU5ANZ, FOUR 11MYN)FcED FIVE and !l0/ to0_..__.._.__--•-..---__--__-___._..----Dollars (S 29&,LU5.00------------ l for the p,`•r)ent of %vt1i h sure, welt and truiy tr', tx? nude, w" bind ourselvos, our heirs, executors. ad► inistra tors, sur..:esswr, and as;ntns, it) Iwly and svve,ahi ,-, ',rrri!y by thew vrc�pnts !WHEREAS. the sp(! Pr!r•.c:(()ll vrlt,i)(> t into ,i contract w%mi the CITY OF 11UN'TINGTOS BEACiI dated on or about .Jan. 151, 0 WATER MAIN INSTALLATION ON PACIFIC COAST HIGHWAY BETWEF.:1 NI'1T11 STREENT AND COt,TMZBEST STR.-FE ', III 1111: CITY t,�F HUNTIN(,'TON BEACH, CA WHERrIAS, S:I,C: ,',?►,t►",ct UlUvidt" that he Prin,:lpa' e•.(1} lJtnlsh a hOntf t(>ntiit►wnyj tt gc;:�r:�n.cx: for fh» (),Lno :i of 0?!E (1) yt--)0 l ,01w aoou. val of She final ust)mate un said jot.. by tho owlwr, agJinst ,311 in ti�'iJr� m.tn3hir ,ind i-illena! , vdn,.- ► nmv bi-orne ay.Varent during said Ivrrtxi, and WHEREAS, th•, -wid (�(irliror:t has hverl and %,.ras cm 6 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that ,t w!hin O`tF, yeky(s) from t►'t? chef, (t .i;:woval of the rwiJ rontra�:t. :hv work done wwJer the terrn5 of said contract shall (itsclose. 1)(Alr '.tirlri'rlltlrl;tl,',: ir.. ;fit? _%kx:,jt,on of s3i(f work. and ihN tatryinq oul of the t'lrr11s of v4)d contraCt, or it 1half r• ipt),jr tt,,lt nl. leri,)fs 4%.ot' ttlrn(shed tr�t��t'llrlc,}t'1 there "tlis obligation shalf remain In full torcoand Vlrillf i 111 �'r�'i la' rh�G rl sir tlr•11'n! shrill he wid S(gr.r>d 22nd day of January , 1()86 :ti'�tnr"sy C K VUH. P 6 DYWATERING COR1'OKATION c,/ / _ "1 Pr rx quo RELIANCE INSURANCE COMPANY A 4r +^ �r a C. S. Albrecht, Jr. BDR Z" ED. 7• i 1 �' rAnta of Colifornta. County of ....., __ I.r►s Anf;c•le►; 5S. On thrt _ A.A.Bf� __..__ . cf,ry ��t _ . Jan.... _ ___ __. In '11• year twfore rw Notary of Pubt.c personally arpearetl _ . _ __.._ E...:i._ al.aglr:cuz,._ �x.... _ _......_ ... _._ . 1*'urna11y kr►uwn, to me for wooed to my on the basis of sa rsfactary evt(iencr) It) be the Irwryni v::Use flame Is tutnrillml to th•s tr»ttument as the Attorney In Fart of RELIANCE INSURA?SCE COMPANY atwf, atkr-crw1e4IcwI Io me that RELIANCE 1NSUHANCE COMPANY executed the Instrvrrent. ,�+,�i! �e!► r,Y. � ii.✓.+'w! ��+i''r+.� � aid ?!'i'i!T.a� ✓ � �rrl • �w/ h1AR1A LUISA CHUA • j'� .. l• tM: �Ybl 1 11.. 1 1 �.I.K1{1A L Z ! tU_ • IU91tS iL ; % ti Y► L;,-1 ►t..l is;.fes J491+.1. My Commrtston eKperes __ BOR•1818 ED SAM ICALIF $ Pbvtary /uVic in and ra ad County r INTER -DEPARTMENT COMMUNICATION f�. fdUlfl":wr J. FRANZ, thief From ACCOUVIING dr RECURV6 Adminixtrative: Services I)epmrtment S1113jec:t 10% It en ion Ualc t ` �o 46 CC The conformed copy of the Notice of Completion for the at�ove contract has been f ikil. The thirty-f lvr:. day waiting period has eUpsed. Payment of the 10% retention payment is recommended so long as no stop notices or outstynding invoices are on file with the City. an yillella, irector o Finance I certify that no stop notices are on file on the subject contract at this time. Date: Paul Cook, Director Public works Department 1 certl.iy that no stop notices are on file on the subject contract ;and that a guaranty bond has been filed. Dvte: 7111 A cis Wentwoeth, City Clerk I certify that there are no outstanding invoices on file. 0 1 1ETJ City of Huntington Beach Department of Public Works P.O. Box 190 Huntington Beach, California 92648 Attention: Subject: Certification of Compliance with Title vri of the Civil Fights Act and Lqual Employment opportunity Act of 1972 Gentlemen: The undersigned, contractor on Project No. CC-685, Insured's Project N3. 89, installation of 12 inch watennain. roject o. Title + hereby certifies that all laborers, mechanics, apprent:.ces, trainees, watchmen and guards employed by hi.m or by any subcontractor perform- ing work under the contract can the pcoject have been paid wages at rater not less than those required by the contract provisions, and that the work performed by each such laborer, mechanic, apprentice or trainee conformed to the class if ications set forth in the contract or training program provisions applicable to the wage rate paid. Signature and Title Charles S. King IL •. President CITY PUKDED PUBLIC WORM Cf7E't" 1tACT BZMXK Situ CITY OF 1n=TIVQTOV BEACH AND C.K. PUMP & DEWATERING C+OVINMT10K FOR HATER MADI IMBTAIJ ATIOIi THIS AGREEMENT is made and entered into on this /S _ day of "s'""a';�� 19 r4 , by and between the CITY OF HUNTINGTON BEACH, a municipal corporation of the State of California, hereinafter referred to as "CITY," and C.K. Pump & Dewatering Corporation, a California -�:orporation, hereinafter referred to as "CONTRACTOR." %a, WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described an the furnishing and installation of water main and appurtenances on Pacific Coast Highway and adjacent streets, between 9th Street and Goldenwest Street in the City of Huntington, Beach, California; and, CONTRACTOR has been selected and is to perform said work; NOW, TuERE:FORE, in consideration of the promises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: 1. STATE:MEW OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall furnish, at its own expense, all labor, plant, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to assume the risk of all loss or damrge arising out of the nature of the PROJECT, during its progress or prior to acceptance, from the action of the elements, from any unforseen difficulties which may arise or be encountered in the prosecution of work, and for all other rinks of any description connected with the work, including, but not 1. limited to, all expenses incurred by or in consequence of the sutspension or: discontinuance of work, except such as are herein expressly stipulated to to borne by CITY, and for vroll and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY under them for the compensation set forth in the accepted bid proposal. However, the total compensation to be paid to to be computed on the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s). 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (ass hereinafter defined), the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such matters and is relying in no way upon any opinions or representations of. CITY. It is agreed that the Contract Documents are Incorporated into this Agreement by this reference, with the same force and effr-^t an if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by nail Contract Docu::onts insofar as they relate is: hart or in asny way, directly or indirectly, to the work covered by this Agreement. 'Contract Documents" as defined herein mean and include: A. 11his3 Agreement: B. Bonds covering the work herein agreed upon: C. The CITY'S standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Warks of CITY and adopt&d by the City Council of CITY, and any revisions, amondments or addenda theretot 2. D. The 1962 edition of Standard Specifications for Public Works Construction, published by Builder's News. Lnc., 3055 Overland Avenue, Los Angeles, California 90034, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Worka Association and the Southern California District Associated General Contractors of the California Joint Cooperative Commi*..•.tee, E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the Contractor's Proposal (attached hereto as Exhibit "A"), F. The particular plans, specifications, special provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like affect as if ;ndicated and mentioned in both. In case of discrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by COt7TR;'%CTOR to the Department of Public Works of CITY (hereinafter referred to as "DPW"), without whose decision said discrepancy shall not be adjunted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an ar_ceptance of the termR of said bid or prc. posal which is in conflict herewith. 3. COMPENSATION CITY agrees to pay and CONTRACTOR agreea to accept as full compensation for the faithful performance of thin Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, the sue of Tyro -hundred Ninety-four Thousand, Four -hundred and fire Dollars 14294,405.00) as set forth in the Contract Documents, to be paid as provided for in Sections 1, 6, 13 and 14 herein. 3. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after notice to proceed is issumd and shall diligently prosecute PROJECT to completion within ninety (90) calendar days from the execution of this Agreement by CITY, excluding delays provided for in Section 11 herein. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and eu•:ry provision of the Contract Documents. CONTRACTOR shall. prepare ar.-J obtain approval as required by the Contract Documents far all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progre$s schedule oet. forth in the Contract Documents. CONTRACTOR shall coo�,dinate its work with the work of all other contractors, subcontractors and CITY forces working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance with Section 4 herein. CITY shall have complete control of the premises on which the work is to he performed and shall have the right to decide the time and order in which the various portions of the wcrk shall be performed and the priority of the work of other r.,ontzactors, subcontractors and CITY forces and, in general, all matters concerning the tamely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by the DPW. CONTRACTOR agrees to crake any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as they UPW may require in writing. Under no condition nhall CONTRACTOR make any changes without the writtcn orcicr of the 4. DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by the DPW. When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the effect of the change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work site will be available on the date the notice to Proceed is issued. In event of a delay in commencement of the work due to unavailability o: the job site, for any reason, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. $. BONDS CONTRACTOR shall, prior to entering upor the performance of this Agreement, furnish the following bonds approved by the City Attorney: One in the amount of one hundred percent of the contract price to guarantee the CONTRACTOR'S faithful performance of the work and to warrant such performance for a period of one (1) year after CITY'S acceptance thereof, and one in the amount of fifty percent (501) of the contract price to guarantee payment of all claims for labor and materii,ls furnished. 5. 9. WARRANTIES The CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR„ within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective ite■ or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S risk and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that the CONTRACTOR. is, and shall be, acting at all times hereunder as an independent contractor and not as an employee of CITY. CONTRACTOR shall secure, at its expense, and be responsible for any and all payment of income tax, social security, state disability insurance compensation, unetnployrent corpensation and other payroll deductions for CONTRACTOR and its officers, agents and employees, and all business licenses, if any, in connection with the PROJECT. 11. LIQUIDAVED DAMAGES/DELAYS It is agreed by they parties hereto that in case the total work called for hereunder is not in all harts and requirements finished or completed within the number of calendar days as set forth in Section 4 herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay; It is, therefore. agreed that CONTRACTOR will pay to CITY, ns liquidated dairviges and riot an a pvrnalty, the num of three hundred dollars ($300) her (Jay for each and every working day's delay in completinq the work in exr_�fsn of they number of calendar days, set forth in Section 4 herein, which sum ret.iresentn a rensonahle endeavor by the pnrties hereto to estimate n fair G. compensation for the foreseeable losses CITY mould sustain in the event of and by reason of such delays and CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will b3 granted an extension of time and will not be assessed damages for any portion of the delay in completion of the work due to unforbeeable causes beyond the control and without the fault or negligence of CONTRACTOR., including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) daya from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of final settlement of the Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the tine for completing the work if, in its judgm!nt, the findings of fact thereon justify the delay; and the decision of the DPSJ shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed waiting for materials required by this Agreement to he furnished by CITY, or by damage caused by fire or other ensualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in nowise caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days the CONTRACTOR has thus been delayed, but no allowance or extension shall be rande unleus a claim therefor is preoented in writing to CITY within fifteen (15) days of the commenc.ement of such delay. i. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DIFFERING SITE CONDITIONS (1) Notice The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) subsurface or Intent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents: or, (b) unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized an inherent to work of the character to be performed under this Agreement. The DPW shall promptly investigate the conditions and if it finds that such conditions; do materially so differ and cause an increase or decrease in the time required for perforsmhnce of any part of the work under this Agreement, whether or not changed an a result of such conditions, an equitable adjustment shall be made and the Agreement modified in writing accordingly: (2) Time Extension No claim of the CONTRACTOR under this; Section shall be allowed unless; the COtiTNACiOR has given the notice required hereunder, provided, however, the time nreacribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities 1iated in the bid schedule will not govern final payment. Payment to the CONTRACTOR will be made only for tine actual quantities of contract itemn used in construction of the PROJECT, in accordance with the pl arin and specifications. Upon completion of the PROJECT, if the actual quantition used a. ,• are either more titan or less than the quantiCAP)a listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. The DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment un6er this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, the DPW shall ascertain the facts and circumstance; and make such adjustment for extending the completion date an in its judgment the findings warrant. 14. PROGRESS PAYMENTS Each month the DPW will rake an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (101) will be deducted and retained by CITY and the remainder, lees the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of the DPW, faithfully executed fifty percent (501) or more of the value of the work as determined from the bid schedule, and if the DPW finds that satisfactory progress has been and in being made, the CONTRACTOR may be paid such sum as will bring the payments of each month up to one hundred percent (1001) of the value of the work completed since the commencement of the PROJECT, as determined by DPW, less all previous payments and less all previous retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be nade thirty-five (35) days after the acceptance of the work and the filing of, a Notice of Completion by CITY. Payments shall be made on .,-Wmnnda drawn in tie manner required by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the work for 9. which payment in demanded has been performed Ja accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under Section 13 of this Agreement. 16. AFFIDAVITS OF SATISFACt'ION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with the DPW its affidavit stating that all workers and persons employed, .all firms supplying materials and all subcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PFOJECT for either labor or material, except certain items, if any, to be set forth in an affidavit covering disputed claims, or items in connection with Notices to Withhold which have been filed under the provisions of the statutes of the State of California. 17, WAIVER OF CUIMS The acceptance by CONTRACTOP of the Payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold and save harmless CITY, its officers, agents and employees against any and all liability, claims, judgments, costs and demands, however causes, including those reaulting from death or injury to CONTRACTOR'S employeen and (M.-mage to 10. '�...ry':VF!'!:�•!lw-,'ir:,'�'.....tiMty,%.a.,......rx::s�rri+elAM97�Rr - — ......� __. . property, arising directly or indirectly out of the obligations herein undertaken by CONTRACTOR, or out of the operations conducted by CONTRACTOR, regardless of the active or passive nature of any negligence by CITY, save and except those which arise out of the sole negligence or sole willful misconduct of CITY. CONTRACTOR will defend any such suits at the sole cost and expense of CONTRACTOR when requested by CITY, and any costs of defense or attorney's fees incurred by CITY in enforcing this obligation will be reimbursed to CITY or may be awarded to CITY by a court of competent jurisdiction. 19. WORKERS' COMPENSATION INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of said code, which requires every employer to be insured against liability for workers' compensation; CJNTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall c:aint.ain such Workers' Compensation Insurance in an amount of not less than One -hundred Thousand Dollars 3100,000), at all times incident hereto, in forms and underwritten by insurance companies satisfactory to CITY; and CONTRACTOR shall, prior to commencing performance of the work hereunder, furnish tc CITY, on a form approved by the City Attorney, a certificate evidencing such insurance: said certificate shall include a provision that the insurer shall notify CITY at least thirty (30) days prior to any cancellation or codification of said insurance Policy: and CONTRACTOR shall notify CITY a. leant thirty (30) days prior to any cancellation or modification of such policy. Said insurance shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under Section 18 of this Agreement. COI;TRJ.CTOR shall require all subcontractors, to provide such Workers' Compensation Insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY e I). certificate of waiver of subrogation under the terms of the Workers' Compensation Insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 20. INSURANCE A. CONTRACTOR shall carry at all times incident hereto, on all operations to be performed hereunder, bodily injury and property damage liability insurance policies including automotive bodily injury damage liability insurance, underwritten by insurance companies in forms satisfactory to CITY for all operations, subcontract work, contractual obligations, product or completed operations and all owned vehicles and non --owned vehicles. Said insurance policies shall name the CITY, its officers, agents and employees And all public agencies as determined by the CITY as Additional Insureds. CONTRACTOR shall subscribe for and maintain said insurance policies in full force and effect during the life of this Agreement, in an amount of not less than One -Million Dollars (t1,000,0000) combined single limit coverage. CONTRACTOR shall require its insurer to waive its subrogation rights against CITY and agrees to provide certificates evidencing the same. B. CONTRACTOR ohal.l acquire an errors and omissions insurance policy covering all. work performed by it bereunder. Said policy shall provide coverage for CONTRACTORS errors and omissions in an account of not less than $250,000. C. Before CONTRACTOR performs any work at, or prepares or delivers materials to the site of construction, CONTRAC'TC►R shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages; said certificates shall provide the name and policy number of each carrier and policy, and shall state that the policy is currently in farce and will not be cancellosd without thirty (30) daye written notice to CITY. CONTR.ACT,OR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and a^cepted by CITY. 12. r The requirement for carrying the foregoing insurance shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under Section 18 of this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all said policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. 21. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged a bankrupt or wakes an assignment for the benefit of creditors or becomes insolvent, or 11iolates any provision of this Agreement or the Contract Documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is curers within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to nny other remedy it may have, terminate this i",ireenent upon the expiration of that time. Upon such default by 'nNTRAC`I`OR, CITY may elect not to terminate this Agreement: in event CITY may make good the deficiency in which the default sets and deduct the resulting costs from the progress y,&y;-onts then or to become due to CONTRACTOR. 22. DISPOSITION OF PLANS, ESTIMATES AND 011-M R DOCUMENTS CONTRAC'TOP agrees that upon completion of the work to be performed hereunder, or upon earlier termination of thin Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement. shall be delivered to CITY and become its sole property at no further cast. 23. NON -ASSIGNABILITY CONTRACTOR shall not sei1, assign, transfer, convey or encumber this Agreement., or any Part hereof, or any right or 13. • duty created herein, without tht, prior written consent of CITY and the surety. 24. CITY ZMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of California Government Code Sections 1090 et seq. 25. ATTORNEY'S FEES If any action of law or in equity becomes necessary to enforce or interpret the terms of this Agreement, the prevailin-- party shall be entitled to reasonable attorney'G fees, costs, and necessary disbursements in addition to any other relief to which that party may be entitled. If any action is brought against CONTRACTOR of any subcontractor to enforce a Stop Notice. or Notice to Withhold which names CITY ass a party to said action or by reason of which CITY incurs expenses, CITY shall he entitled to reasonable administrative and attorney'ss fees, costs and necessary disbursements arising out of the processing of said Stop Notices, Notices to Withhold, or any similar legal document necessary to the prosecution of such action. Said obligation shall be provided for in the labor and materials payment fond required of CONTRACTOR. CITY may charge an administrative fee of pane -hundred Dollars (t10O) for every Stop Notice filed in excess of two, regardless; of whether or not CITY is naned in an action. CITY may not off any unreimbursed cost or expense so incurred against any our or s3ums owed by CITY to CONTRACTOR under this Agreement. 26. NOTICES All notices required or permitted isereunder shall be delivered in pert;on or by registered or certified mail to an tauthorizel representative of the Party to whose delivery its to be made, at the place of business of such party, or to any other place designated in writing by such party. 14. pr (REST OF PAGE NOT .I 15. r w o- r+ y, J7 I-v • SY j` 1 1 gyp7M, x �4'�,t' �'�� ,4k•1,�; � � 1 't'k trf��' a ,�"., .� T.7 40 �� �" � �� �) � �" , �, 1' 1 � �,.-�1 IS�,:rb,�{.�ltt�t � 't'� �1�'�;+�,h � Y }� r " "r r•. , f.y ,w• ���Y. � ..; t �" r r i'j" ..1 is I �','t '�f ��' .,y.\j4� x ��, � ,w 4 + i-,n '.I F, .. ilk' t• ,h'.• }_1��� tr y ' a +. ;Ai i,. i:1' };A `• * �'' r r,` 1 71 I, Y..� � i. - +.'�,.. .� c/. „ ,, ��� •, RN+" v, r t} �;`N u ���i '�� ',•il�� Pr „S ,,y„ ��* Mj , :+ 1. _ ,� � ; : • ay. � '_s ,,r // r a - n � f. ."MI � ` ' t` ,... '' •y,r � + 1'. �,. �i H r�r+ �`,.' , 1/. � J � .• ",i - s•,,r.Z,�, n.° i.. .r � ,�.. rK y+r � ��; '1 1 �.,�F .fir ' w ,� ,. a. l, " t', .. , : t#: fr:` � " ltN : ,'1{) +1 •1 �I `r , �.. -,' + .� .,. .( H.M.. }., f t: " _ r:1 '�IF rL '.1, 1 T 41AA ';.4 •yy�{'�'Y '� a Wf 1i;:'.y�;, rt,♦71. •. ,,l `1, ,. F t '� R. ' ,+,:� _',�' o �TI ..�. I.p1 ` 1 r,7�,' 46 ,.f"' 1 '� .s ti `s,ly�� '� '�., "�••.. 4 i -'`,'h . � V �,, �'r `t';il, ; **4l"v'�t, * � .k 1� �,, "n"� .. i + , i M • .M •' k; " .,Iw3 . * "F' t "' ��* + M 4, '".0 r r s 'a' q �+ s , - r 'ti, � - r ' /r ..4 A �11i1.jM4 �+. r t�'}('�'. . r. 7� � ".R j r W' .Y .-,} q � ' �r .�t'$♦ r. `,• `+„ ''"ar M It, • �y r f h .. . r � 7 4., µ ,. i .. � i 4 " 1Y,�Jn y� ' ySI j* t '. 4 y 1 Tk . rs ,t ; h �. .. �• _x ..rj" .x, l * ,M ��+ ,rx t i !•, �t• � y'ti �!!' '+, .•" • " 'f, * , f 7 + + ♦ /. it 'r a. h .1 • 28. ENTIRETY The foregoing represents the parties. • the entire Agreement betwoen IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorised officers the day, month and year fir,;•.' above written. CONTRACTOR: C.K. PUMP i DEWATERING CORPORATION, a California corporation Charles S. Kingre ident c Juliene J. King Secretary/Treasurer ATTEST: A1 ela Wentworth CITY CLERK REVII: D APPROVED: ar es oopa n CITY ADMINISTRATOR 1158L. 1/10/86 16. CITY OF HUNTINGTON BEACH, A municipal corporation of the State of California 4�-4 le. 4' o�rt P. Man c, r. APPROVED AS TO FORM: Gail Hutton. CITY ATTORNEY _,_jNITIATED AP APPROVED: Paul C;00K DIRECTOR OF PUBLIC WORKS 1 ] CONTRACt *"D—CAi.1P0Jt!'"1# OICAO O+PPICt. P4*LA0CLPKIA, I"P0ISYLVANIA KNOW AU. MEN BY THESE PffSEWM That w.,...... .0 K >CW! A'1[Z1tTIMc OOR!'tll1.AY'I011 ` A . . PIS) )! ]7 �91tYlMs �).S$1.OA C`AC'11I tN 3 OOM>l{RPAM J.66t. Off Im Iwo La" low-h0 CA 9NO1 as Principal, and Rl:1.iANCF 1NSI'RAti'CF. COMPANY, a corporation oricanized under the laws of the State of f enirr,ylvania, and duly authorized to transact business under the laws of the State of California :.+ Surety, are held and firmly tx,und unto CTlfT ..07 � 41*11 as obligee, in the just and full rum of TWO KUXDKED MIl1M—llMM THOUSAhl), VOCR FIVE and !00/100---- 0214,405.00) dollarq, for the payment wherehf will and truly to be made, said Principal and Surety bind thetn%elves, their heirs, exprutorm, administratrsr:e, succexurr% and ak.,iltns, jointly Andseverally. firmly by tho.*e presentf The Coadi6mm of the foregoing obligation is such, that whereas, the above bounden Principal ham entered into a contract of even date herewith, with the said oblixee to do and perform the following work, to wit: WATIR JVtJI': INSTALLATION aN PACIFIC COAST HIGHWAY I11Ma M. NUT H SikM AND (.=L^'MST STRM, IN THE CITY OF f;U!lTINCTON AIP ........ .. .. CALLlt3itl'iIl _ 1.. eery► as will more fully appear from said contract, reference to which is hereby made. Now, TbeereerAfort, if the above bounden Principal shall well and truly perform the work contrarted to he done ur.der said contract. then this obligation to be null and void, otherwise to remaln in full force and e;tlecL No right of action shill accrue under this bond to or for the use of any person other than the oblltee named herein. Signed and *ezled this ISt►h day of Ja sary► A. D., It 96 C r ?" i D tAY':RI]IC Ctlt?MI TICS \� 44 Priedpal RELIANCE INSURANCE COXPA.NY W1)" .2PI tri IVhc 1"M MALIF 1 r $i 10 o1 Caktornh, .. SS. cow,ty of On thrs (fey of _—_ aaa._ .... __ . in tthr yrar 1 ._, . . betoir me Notary of ?utrtrc personally Appeared _-- - • _---_. I■_..jr A-M& .. _ . I _ . ;wf%ottaIty 1 nown I tT,* 1a+ ;.twed to nre on the basis of 1dt)sfJctnry evrdrrcei to Iw tr)r c*'r:Un whose n-ime s tuIncrit►rd to t+r'1 +t•urnrnt a; !('r Aiturn" In Fact of RELIANCE INSURANCE COMPANY wwl. to mr t'+,o f)EI IANCF. I'N5UHANCE i;psiPANY e.rcul"I tr;e 111st►urTlent CIUCIAI. 7AL MAltiA. IUIrjUA ---� %AA l.(,r•�rnr•t rin r.;hsC1 lr3 �...._... _. . 1i*rt�•r R�t> �.,. I,v y.rl C�r..�.,.� 0 XLELr_ �LZTCZ I1qG UIFLA.24 C*=0M1=A-1q-T HEAD OFFICE. PHILADCLP041A. PENNSYLVANIA IX S C=rWAM Bond too. 553 � "ne h'e"4+n charged fnr fm PAYMENT BOWD tom! 6 Lic'.1.,2C1 b ".I shows CALIFORNIA —PUBLIC CONTRACT on t;M t'ccfo Aaace his." KNOW ALL '.1 E N BY THESE PRESENTS. t h.r t C 1 VM ; iplMTMI]IG lSlAxIOM tort Office *w 2$W 9 TAMS lrtacb , CA 9W 1 as Princijaal, and the RELIANCE INSURANCE COMPANY, a Penrsylvanla corporation authorized to execute bands in the State of California, as Surety, are held and Iirrnly bound unto CM., OF NUNTDMM 19"M as Qblinze. to the sum of (Mr. RD. ORED FOMY—SLT'CM T!ldC�J►Me M r* a�rd s©j100 __ .. Dollar, ($1i7,,202.30 y for which sum v.e bind ourselves, our txairs. exec,itor;, administrators. ,.:cmrAcifsand as. -signs. jointly and severally by these presents The C_,ndit(on of the ab , e obligation is ,ucn that. 11"nereas the Princlr,11 on day of 19 , entered into a contract with the OblK)-_d for IWATU PAM I]tSTAUATTCPN OIR PACIFIC CWJT NIC>MiiAT jjrrW :>!2I ltLlM STP. = AIM Oa[, FJW-ST S'tRM, ciTi of HUlf'fT. ICT(W BRACH, CAL1701NIA NOW. THEREFORE. it the> tbove -Niunder. Prim-irml of his subcontrac!ors fail to pay any of the D!fsons narned in Section 3181 of tt•e Civil Coda of the Sijv� of California. or amounts due under the Unemployment Ins;jran eCodev:ith res: ct p• l3b::r per1ofrr k1 by .iny such claimant, the Surety will pay fcr the same. in an amotint not exc ",zd,n,ii the s'1m soeCif.M in this nond. and also, in case suit, Is wrought ijoon this Mond. a reo?son,thla itt0'ney rtt+! 10 t:�., f itc*d by Me court This bond shkill inure to the bienelit of .3r,s' and all r-efwris •�ntit'«] to file claims .indet Sercvon V91. of the Cr.il Code of tte State ,,f California. 'z) CIS to g+:N a r,q; it of ," :;n to thert't or their awgns to dpv suit brought u0on 'his bond Signed Jnd sewed inns Isth �LIY of Jaawatj 19 86 C >K In" i DWATICI.M Ct VMT1%% RELIANCE INS RAN OMPANY 7. X. A16redit 0 Ife AtIM-ry F jkt 13DA-2" ED 5172 'CALIF.) »pan. a Wikwnia. Camcv of On this _ 15th _ d.y of _ Jan. 1l�6 in the yrar beforr rnr foldly of Pilhiic txrsorwlly +Pcx�artrt! -- ---- _- _-- •j.. •�---��.�_.._� --_ _ ._ _.._ __ __.._.. lo me on the haul of sat��factnry eviclence) to 1►0 thev►?rosr r>dme rt tul,ticr�t,M�tr thItly��trt ertt or. the Attorney�jn Fact of RELIANCE INSURANCE COMPANY anrf, jcknowjf4Jge,J to n5e that RELIANCE INSIJ14ANCE COMPANY e.Fc;jt.vl Itle instrument, -'r MARIA LU:-A CHUA "t Hnrr rrr.• f ;7 c, � � r , i� "t- - � lic�tl•� r��S..r s•.1 t, • t+�� Cnv,•� __..___ . , t, L•IANCE INSUTLAJNPE coo PA.NY HIAO OFFICE, P%It,AD1L `"IAA►1hh-7YLVA,!dIA POWER OF ATTORNEY KNOW ALL MEN by THESE PRESENTS. That "to RELIANCE Ift"ANCE COUVANY. a morpost.pn 040V wpsrr+tar timer low Mom of im & M 1"tho►►ve", done Ite4" probe. iiiihar1wto mW &"**"I E.S. ALBRECHT, JR. of LOS ACE' -ES, C/,L'L:OFV1A-_- Ili Shull artil lawful AttorRolry-tM1Fw. to Ittfkoo, owguit. Mspi Mid dtXeMr for !r/ on ill behalf, OW M it$ an ohd dM! AINY AND ALL BONDS A;iD L^.ii.FP:'n:..:iCS OF SU r:7S;iit�'-_--__ fld to bwd the RELIANCE INSURANCE COMPANY lftorobr os !wily and to the two Salmi at it ouch Emondt attd ter W omilltwle anti ether w OWsptoly to the nature thaeof owl SWWO by M Esectrl"w OIIKW of Ito RELIANCE INSURANCE COVPA%Y Soar trm*d and el1r1116d by Arta of ouch oll.cayo, and here" rottl►as and conf.rnto all that its wtd Attanophkw-Fact' mar Soo in tttsuarte hoes I. This room of Attorovr it W11-itad under and by w+thwetr of Anacte V13 of IM by•1awt of RELIANCE INSURANCE Cc�wANY vehrfl rlfoeltq Sepltylibeit 7. 1970l, wAtch protns-ont are now .n full force and NISLI, roadanr at 1041n 4. ARTICLE twill — EXECUTION OF BONDS AND UNDERTAKINGS 1. The Board of OitvaWs, the rrtwlewt, the Chew~ of the board. any Swag Vow helydonl, arty Vuce rrindrwt or Awslertt Voo himodont w whw oftrtaer daurmtod br the board of Directors Stoll have pov+rtt ewe authority to Sal a/tooa.nt Attorna".n-Fact and to autherate their" to voinm" on beftif of the Componr, bonds and urtdoeteatrgs, rettottatanaot, tannttectt of V4*0xutr a"d pfher 0WOW44 aoe.ee " to tfte nature thettael, artll Its$ N rertto.e any such Attorney..n.Fact at any lrnw a•td rrMitt the pO+ooft Sono rtwthwrtr r.yrn to hint. i. AttwMrt-w►-FM Shalt how power and awthwitr, s"69to t0 the ttrpou 000 MRMIatoom of this pO WW e►f a/Toone, rMWd to ?Won. to I WIMIN ared detour On boholf of the Co nOlIny, toonde and unOartaRtnw. Mow itantot, cofttreClt Of wa*er"n.tr end Oftwo emrt.nge OY1.9MOry to the tletwe ttettof. The COrpo+att Not n not naatalatr for this eeled.ty of any bonds and uraoen6gono a, teoOpr.afantat, opntrbcU Of .ndrgtnNp Md VIFW wrtt►ryt OQfhelory In the netwoe therect. I AnoeMyt- -Fact thall heve lrovw and authority to e1~41 aflydr.ntt ►eloomod to be eflacMd to boo taenlrocts of w„rer"- /dfY or at" Oondrt.ortal or obl.grtoty ur4ee/atoinp and thlr "it alto have powor atd swttornr to ttrufy Ina f.nenool netonhewt of tM Caffoony, ►04 M O 1014% Of the by•Lettn of the C.O. WAy Or any art.Ue ut leaven thereof T1v4 ooww of atlornar is 1"d and ae.alt?O by fact.t".Ir undo+ and br authority of the loltcwttq R►+wwtq.t adoWed by the bored of D.rtrtors, of RELIANCE INSURANCE COMPANY of a nle.etrne need On the 5101 day of Jtrrae, 1919. $h n%gfh a q.rwwo" .yet wM+nt. orw teed ftrwD.&WIaon has not tAv" offended or repealed. "RtsoIwed. Ihrt the "nafurft of each dot ect001 and aIf.ctwl arto the wet of the Coff4mnv nor tw e11,ee40 to air quo pomor of attorney of any cr►ttf,cwta totattrp thpflo by I"Ut9tow. and a^r suctr 00^41r J1 61101M1 a cttt.l.catf t7of614w7 tut" lZots.rntte e.Fnnirtw cr Iaotnu►e teal that) be veld and b•nd•nr woon the Co mflony aril any swth p0wrt so eeacr:tod aid cr►tnf.od by fats•rytrlt woriatHres and Ianarnab Saab shall to ♦slid and b4td.04 wMA Nta Con*Peny .n tM fwtwte •rtt% ta{pect 19 Mr bond of WWOnabuy to 9^01 It ro ottec"ed " IN WITNESS Wt•IEREOF, the RELIANCE INSURANCE CO4411"ANY hao awed their vrvwntl to be SHned by .to V.ce rroodfnf, and PIS t10omeete fetal to be hereto all.eed, that 3.0th day Of J=e 19 ; j RELIANCE, INSURANCE rANY / ram~\ �IJ� •/�►• • t �� ��! (�}.r7e — � VHetioe+tt r STATE OF 4fss:1: ng on COUNTY OF to a r. c O" thte 30tt der of .Tuna' , 19 33. p.roonau♦.�caatw t?:fYr:CS 9 SC::"'!1 141 r"e ►nowo to be the VrcePteudrm of tt+e gELIANCE INSUAANt:E CCMPANY and a'arattwiabMaf that he o■eCujsp! and &1101000 the fw099" iwfirrrMnl and aft.eed the fool of ae4 conpotataon thereto, and that Ar1,09 V11. $ee1r001 1. 2. ow J of the Mt -Loon of led Camporw etc the Resmw 1 Ita+rt, VI Ierlh thtlreirt, MI Hill an 1.411 lace ow - Mho CAwor oete" E me* ee ' 1: � 1 t C.••�-� / '�' � �-- � July 20.1s 86 Notaiy ►wb►.c in Sold lye State of as?a nr.t on Mettd•rq a1 M 1: t o n 1. ChYrlcs J. r elskvv . Ategtant Saeatri ry of the ALLIANCE INSURANCE CQMPAfyY. do Mrotry ■edify totm thoo*.Fee • erd fermwev so a true and mtteC1 Stogy of a ►o.wr of Attorney eovewled by errd RE LIANCE INSURANCE COWANY, n,rt.cn to ot.0 .w r„ol faeo rota Mfect . MIf "ITNESS 1lttlf[REOF. IN"* hrrevAto yet ht'iy head and off.•ed the faaf of teed Caw-ft" IAra 1501 goat' of January 1186. •l wRse .1.21 641 mi l A...owm ltwtr.Nrr..�r r _ • CONTRACT 11t1]ND--CAMPOMItA • HCAO OFF►CZ. P"tLAOI!LPP-A, PfNNSYLVANIA KNOW ALL MEN BY THESE PRESENTS C K PUMP 6 I)PATERING CORPOU-TION .+• I353 39 37 FMIUM: $3,533.00 EXECUTED IN 3 COLMEXPA.RTS ..Post Off l.ce BDx. 2800, Long peach, CA .•901901 as principal, and RELIANCE ItiSUItANCE, COMPANI', a corporation nrganized under the laws of the State of Pt-nnrylvania, and duty authorized to tran.art business under the laws of they State of California Surety, are held and firmly Ix,und unto CITY. OF. HUNTIt:i TON 13EACII sit oblig". in the just and full sum of TWO.f1UNDRE.D.►ZINM-FOUR TIIOLtSA.`IU, FOUR lll.';IURF.A FIVE and NO/100------- _--------- ------------------------------------------------------------- 0 794,!,05.00) dollar+, for the payment whereof will and truly to be made. said Principal and Surzty bind them"Nen. Owir heirs, executors, ariminiytratt►r:+. RurceS!Hlrs and xmigns, jointly and-wverally. firmly by thew prr.+rntr 7U Condidan of the foregoing obligatioa is such, that whereas, the above bounden Principal h&A entered into a contract of even date herewith, with the said obligee to do and perform the following work, to wit: i:ATER `tAI`, INWALLATION ON" PACIFIC: COAS11 HIGHWAY Y.E."IVEEN NIl:TH STRUT AND GOLDi:NVEST STREET. IN THE CIn OF 111.7;:TIN TON" BE.&CH, i..%LIFORNIA as will more fully ahlwar from said contract, reference to whir h is hereby made Now, 'M refore, if the above bounden Principal shall well and truly perform the work contracteti to be done tinder said contract, then this obligation to be n-ill and void, otherwise to remain in full forCV' and effect. No right of action shall accrue under this bona to or for the uses of any person other than the obllc'-i named herein. Si`ned and sealed this w041 MA)l ttt PU►N[ IWA'CALIF t 1501 day of January A. D., It 86 C K 7t.W _6 DEWATERING 5(S1RPORATIO`I XX Principal RELIANCE INSURANCE COMPANY E. S. Albrecht, Jr. Aeirrnertin•fsd. w slats of California, SS. County of Ott ih.i .._ _- i.��}1..._ . day of .1cit1. _ _.._ fn thr Y"dr 1986 _.. . hrtore (r►e Notary of Public personally dFn'alecS __._....__.�._.�,.^�_t. AI.BHFV1T., .,1H-- . tr.rwmalfy �'woNfs if) mr' lur i,rured !c, me on the t)Jsrs of f<dlisfactory evidence) to I,t flit irert(n-A11O%,) rlar`se N IU16ctobtrl it) tVrt ow,!rtJn:e•it s; tht• Attwr +y In F.Act of RELIANCE INSURANCE COMPANY ,r,NI. JLkrr,>r►Irt1y+*ci to the ttrlt RI"LIANCF INSUf ANCL COMPANy'!♦rc+itr^f it•t rn:trument. SLAL k, ti 7; 1♦fAii:A LUISA CNUA Wt My' l..ditlfli�{Snn rwiTrtAe ....... fi1117 +a'� c r: wt :.art paa►, ♦ Pit ♦"? on- w ' �.�LTC�Si Tf.�LT1�.A� f✓ar C��P.A.I�Y' EXECUTED IN 3 COUNTERPARTS or" rlrewtf " ehanH for dh load is included in that Aev e as die 1"WiWn..« AGUL" MEAD OFFICE. P►1ILADELPHIA. PENNSYLVANIA PAYMENT SOND CALIFORNIA -PUBLIC CONTRACT Bond rIo. 353 39 37 KNOW! ALL'.1EIN 3Y THESE PRESEINTS. that C K PUMP b DEWATERING CORPORATION Post Office Box 2800, Long Bench, CA 90801 as Principal, and the RELIANCE INSURANCE COMPANY. a Pennsylvania corporation authorized to execute bonds In the State of California. as Surety. are held and firmly bound unto CITY OF HUNTINGTON BEACH as Obllywe, :n the s,.,rr of ONE IIUI,,DRFD FORTY-SEVEN 7110USAN'D, TWO IIL'N'DRED TWO and 50/ 100 ------------------------------------------------ Dul:ar, IS 147,202.50 1 for which sum Ke bind eurselve;, o,jr t-,tw j. exec,jOcrs. a vninlstra:ots.:uccr.s-rlrs and a.slgns. jointly and severally by these nrerpnts The Condition of t^,e abo.e obllratlon Is such that. Vo'hereas tr,e Prin,-iml on the day of 19 , en,ered Into a contract with the Oblgee for WATER MAIN INSTALLATIOn ON PACIFIC COAST HIGHWAY BETWEEN NIN`nI STREET AND GOLDEN16TST STREET, IN THE CITY OF IIl"TING'T0% 11F.AC11 , CALIFORNIA N01.4r, THEREPORE. It the abo.v bti ,jr'je*l Pr!nc,rol or his subconTraci ors fall to nay any of the persons narred In Section 3151 of the Civil Cod,! ^t the State of C:i'Itorn!a, ar amounts di;e under the Unemployr^en; Insurance Cede ::nth res ct to ►Vcir', 0, fall- ,r :s-rtrrmt-J by any such claimant. the Surety will pay fcr the same, in an amo:,nt not exceed,ng Ire ;;•�r_,t�t'd in this nand. and also.:n ca•.e SUIt Is bought it is COr.,f, a rP,3:= �ahl�� dt;C"+ey'S !c�,, 10 t:#' !iw'' by 10ie court This bond shall !nur., to the benefit of any and all refsons 6:ntltle!�j to fll., claims under S•utlun 3131 of thCivil Cocje of ;f a State of CallfIrno so is to yr:e a right Of ICI., on "I. them or thr?Ir 3s;1grS !n •Iny Suet upon ;h!s tW)rrvd. S!gnej and seal,tj "'!s 1501 kliv of January Iq 80 C K PUKE' 6 DEWATERING CORPORATION RELIANCE INSURANCE COMPANY r� It. S. Albrecht. Jr.... Alrar� c&, s 9or1.21W Ed 6n7 ICALIt: I Sun of Cali lane, Los Angeles SS. County of _ _._�.. On this 15th -- . tfa of Jan.-_.19H6 lt�rr y t y _ Irr.14e tart �r y Uf Pitt)trt personally appearedf __.E�.S._.Ai.Afli.CiiT.-JR..__ .. _..._ ... ._ . wtrrnail� .r,uyriti t:r T,r, it.r t,ro.r+f it) m,r on the baSiS Of %J11Sfac1O'y Cv,dtn"e) to he the !re'rs•)n Mlwe f1d,ne ,S subutil-ell 'o it,- wi!rr, nt-m rT, rr A4 omwy In Frtt of RELIANCE INSURANCE COMPANY aril• t() me that '► ELIANICF iN�iUPAP,I(;E (:0%!PA1JY rot-cutte2 t►'r instrument WOALSTAL 1AAkiA LU.; A CNUA f1rllrf fkii.t?!ti rJ!YtIfS rv►•v�+►+-rrw�M:r„r� if) l r«rts, r h.! • .t (C,.r List ci,vnr _ .... ICIT.I.ANCE INSUFLANCE COMPAN-Y HIAD OFFICE. /NILAVEL"IA. VENfOtZYLVANIA POWER OF ATTORNEY KNOW ALL MEN By THESE PItESFNTS. T%K (fee RELIANCE INSURANCE COWFANY, a WrfliMMSMO defy prpfsrwted won" If% tam 0t lose *%tom /t)mnrl.brrr, 40" l+afabY ffrte, 401101ltWit and Nllpint E.S. AURECir. " JR R. o f 1) ' ' .. t :..� r�..ttrL'....'.ar Ise I" &W 3&••1wt Attorft+ytt►Focs, to evoke. a.icwtt. 94e1 aftd dormer for "Oft Ott behalf. W11/ M Its off Sold Seed A.1i AND ALL BJ:I.:.S AND �r.l i�i:..•��": I1.y.: ��Va OF EI.R_r7v.w:i.F------ atd to hwnc the RELIANCE INSURANCE COMPANY tli MW at lwtly SOW 1b the Who ea"aM a$ of Mich WoRidt Sold wn4artatinfs and of" •urstirl*t OWtfletory On the nafwe thereof .tOrre sorted by on Eawwtrre f0f.err of Ih• hE LIANCE INSURANCE CCWFANY and twbd and etfMard sty owe darwit Of Duch OfeOearI, Rollo falls!" ►etlfiw and Confrfma an that IU Wed Atte+rOayttt.ol•iect rfoy 00 On p„r%pamn farwf. Vot rovar of Attorney is granted wrow and by outhotlty of Anrclo VIO of the 9w-Lovra of RELIANCE INSURANCE C04e/ANY which tooebov o offec"rve septafmta. 1. fg1ge Orrt' KA pons,ont are nosy in 1411 form SOW 011+0, rtta" as loltpwa ARTICLE VII — EXECUTION OF BONDS AND UNDERTAKINGS 1. The Board of Ormicork. the President, the Chswnrw of t►e ftwo. env SUtbor Vvm IrswOant, vow Vise Iivedb vt of Au,sforif Vies I4tttwiewt or Reuses officer osst"fad by the Board of OOeeC'YOts %ttatt have tower 4-0 Irwthfotty to Ul o pavesi Atto►neyv velo-Pon solid to f vV141, rlta f►wirrw to ttNiw♦ an behalf of the Company. bonds and urdaftattons, (600 OSaimm. Contra,"$ of tnwfttfOnv end Strew •tr,t,rve Rovagotoosy M the natwe thartret. sow ibl M remove any folfQt Atto►neti-sn-Fa:t at any tlnn so-W ►avoie the tao•wt and ewiftarfv B+.►n to Mow 2. Atfevneys-on•Fac" shelf he+e OoVv7r *no awthorrty, kAPP C" fo 11+e INIAN Sad amttetiota Of tAY oltMf Of etlorMlf rlewad tp 11101111. to eaae'trf• Sold detrrer on beftell of the Cootvtporev, banal and undertshw4p. to" tlisncas. Contra"$ of uld"rw+.ty end o:►w rwOf,t p 66i4clory en 1he nettire loswoof. 1%0 torytrfDie SW re rot niprvWv for the ve1946t, of any bor►d$ stead of w4own"14b end otow Valli 44 ob/yeotaNy In 111aa rrwre tl+/teol. 3. Anceney/1n•Fan oFell have povw and awthwny to eaatiute Srf,dev,ts rowred to be ettecned to tictit4tr. ►eyoeetrRanom contrans of wdwrr► MtY or other oondit,Onaf or obfgslory w+dattat.np and they shelf alto navt rotor •rvj •wthtw Oly to Miles, foie lefyf.nul tteteownt et tht rCr 'pe-if anj 16 Cobs" of the By•LAew of the CufViany or any artKte o• secl," lhre•cr That 00vver of attorney is I-Ine4 " saela,d by factonuic woldw and by owtf•w,ty of the foilo.-ne He+afuf.on •Sap1•d by the fioa•d of D,rectois of RELIANCE INSURANCE COMPANY of a moorteno nerd on the &tr+ Soy of A ^Q. 19It. S• Vrh{tl S o.fvrwen sego arelant. Sod b4 RVWWIMM has rat foeew M++r'dod a 0,110041104. "ROWIved, that the Se'natu,n of sweh CrMors *Ad Ott-c"I ••vd the we, of the CarnCUny tfley to off-load to Sty Stied% P*svvv Or SRorrwv or env crotsfKjta retatfng thereto Dr fac$tfttett, and •^t twsh pdyN+ of allprMy or vffifecate tro•rrnr 9wh fatsrMt►e p"twret a facawntie teal Merl be vlt,d and b•rdr4 i.00h t" c4ovonv Sod env svc% poa.et so eaacwtel and slnde•d by fect,enla s,pnatwes and fap,nrta teat Shalt be Voted and b•nd�hq vtoon 1140 rn Ina futwe ..+tn threes tG env purl cv wndartak,nq to rthich If h Sttadtird - IN rrITNESS WHEREOF, the RELIANCE INSURANCE COMPANY has mined 11,4w pretend to too vptad by at VKv ►itsed•nt, aa? etjCWMtSta old 10 far:»r►to 611.0e4, this 3Cth day of Jt:.nt- STATE OF uas::ingtcr, COUNTY OF $$ Ki^ Gov this 30th day of June to nee hro..n to be tM vicePtrtr4ant of the RELIA10E i0`1/1►umaAt Solid Reflood if # KM of wed coorpofotign M•rtto Isom, ►)I Ions Ihefe et, are "dl On fwti fact lMy c4ow"W"Oft E roe is Jury 20. it 86 q(L IAhIC fy INSl1RAtYCE�ih1'A1yY r �J 1 • Via lavotro"I 19 3?. v•an•o, .c,o.ared Char:ea B. 5c1:-3i: INSURANCF COMPANY Ind artww►r.>'Sed IhRt Pa eaadutod and sftelcod the fortrBS" and tool AffO[ta VII, Setl,nn t, 2. ar.i 3 of Iha By liwl of Wed COAVo tv a,v4 sere RtMMhr _f 40tt+y ►.ofK an and lot slate of wtl9ris$ rt^ff Resaderr 01 M1 _ t:. r. 1. C"11ries J. Falskcw . Arrovent Srsioory of the RELIANCE IOOISURA►aCE COWANY, die NertOy Rrrt,ty theat tweijupVe • Rr01 f0vs*Nt•1 is a trtta anti Option gulp- lot a ►never of Atternrt ••acwtad by Iced RELIANCE INSURANCE COWf ANY, aNt.CA lot s1.0.w tuts term one offes". Of 11fiT10SS VWFA(CW.I here horsoerste two t++y Hind rM aftOrad the Self of ve4 C ,)-pa" tare 15t h day N .f;Intta ry IE A fi IatOtr-sass to artfL.tr,t`�Ir$a- t A% .it I Imiling-ton Rear h Ill. A 11r11. 0frice 1' r I I t.. ► 19U Ilnn1mg-lion Heart. CA 92648 CERTIFICATE OF INSURANC 1-9 TO CITY OF HUNTINGTON 11ACH, CALIFORNIA. A W M1GIFAL CONORATIOM AeR1ww" en of Fwa 60 hewn. COT Aew" be: Tlwa is to certify drat Ira 061IMea all WwA9w* Ir slwet~ b*w ho Mm WOW Ira tM iosWW by Mre ttl WWR4lmd ad we IN 11,E+1e at This tonic. If then pokOw are/ Nladbi w dwapd is ttt111111 a IIIMIM *A"M a11iM rtil aMww a ft, dM iwrassr>M1 "l.*my S"M to yiw 22 prior wifliwl oWN. by =N. to Chy of NwWo Nall MA. F. 0. Mat 7 11. HlralietSlm Sft*. CoMety is M01. AL L ITEMS MUST •E COMPLETED. ANY 04LITWN OR CHAIM 14 THIS 1104w $MALL N SIOWD AND DATED NY AM AUTHORIZED REPRESENTATIVE 0W THE "dKXU NCE GAMY AND IIIIfT OE AIR*1KMD IN WRITING •Y THE CITY ATTORNEY. N"Mof Inrind C. K. PUHP G OEIIATERING CORPORATION As1/rM of Ilarssrsld Location oaf Work or Opw*1iioea /o Few pw1ev wI Pacific: Coast 11vy, from 9 th St. to C.oldensest St. C>wraifrtionotworkorQpara iieelw Project No. CC-605, Insured's Project 189, installation LI O in; Of UAWLITY ,~ MAIM Of OpBIPAMy oft"" POLICIES IN ►ONCE 111MICY no. Tle■r11111111111 OW fIME.I GENERAL LIAitHLITY COAA►11EHENSIVE fGAM GL42-0385 ti !I(ln_T.^_^^I�IL Western i'.mploye� KX PREINISEs--OPERATI6M>i 17203 3/l/85 3/1/86 E.areowr..ra++ Insurance Co. Kx EXPLODON AND COLLAPSE HAZARD KX UNDERGROUND NA2Ah0 KZ PPOOUICTS COMPLETED OPERATIONS HAZAAO KX CONTRACTUAL INSURANCE k.t BROAD FORM PROPERTY DAMAGE KY IWOEPENOENT CONTRACTORS k+ PERSONAL INJURY AUTOMOBILE LI"ILITr KX COMPREHENSIVE FORM 1A42-0385— 3/1/85 3/1/8C 500, 000 Vestern E+r^plo.�e Y.x OWNED s Crk Insurance Co. HIDED KI No+y-OWNED EXC[A LIABILITY UMBRELLA FORM „T Sf;F; Ai 1r.� , , 'T if:G l f.h� . ,., , f I(A.I. _ [I OTHER THAN UMBRELLA FORM WORK,EWCOM►EM+tTHiN 1C42—i»65 STATUTORY r "- •p Western , r e 1 .�_ OW IMPLOYERf LIASILITY 16479 3/1/ 85 3; 1/80 S2, 000, 000. Insurance Co. Additional Insured Erickwwment: The insurer agrees that the City of Huntington 84ach and its City Council, and/or all City Council appointed groups, corrwni"ees, commissions, boards and any other City Council appointed body, and/of Nectivr and appointive CtfiicM, twyants or employm of tt* Ory of Huntir►gton Beach. whin acting at wch are additxxW insured) hereunder, fa the sets of the Imurea, and such insursnwv shall be primary to any insurance of the City of Huntington Bch, as their interest may al' W. /, 00" 1 -)14 2 3 j a,5..r INBUIIMeCECOWANY Western Ernl_rs, Inc. ,,,,rw„111e 1400 14. Harbor Blvd Gar Fullerton, California 92635 By f A#j,,M • L_or. rnon 6 :r1iL',�. is S LAZ l+trp Pasadena, California 91101 191n) 746—TRAR ^%'* 7wn HMO HAhfI NUM AOIItEIthiSM'I' Corporation N±w "now bymane The ww+W • arm w paltlart. "rsd. katNw111111, a"' and h@M kW"d M 00 Chy Of H1111"WO a il+eettle th offni ". arm. awd emptlrryrM N w: awy N*w Iw. tllier P. Mrs, of 9"waa by seem s art awly oars ail fl **IV. win, da*Irw, dw wnda, jrlttglarassta Glad ossraw M attl a1oMlad by Mrwut his av1Mym, W" aw aver tlsrrrwlrl r err by awry than! Mrh ixiars+ VA ot1 M asirltrt�Ma al M1r pla'Iwwilaao of 1� e1►lirlfe « tealsiah ilia aitltrtiilliatll� 41 isw.erwa it lsrr+si�haal. 0111 SMa pmFiMo.lritp 1!f FloMtarlllip I41 O"w tlfa�al HMOr1ARiaLEtls fg1PM�: Ow WNW* WeXWO .Z TI111 � 1'e s i de n t fAN sat111 be ppeon1 e. appW b0ow Mist o,p,r omi fti Charles 5 . K i rug N■►rwl: T1Mr er C4111"WOw«. D'MIO OWMIN MAN el♦a. ar pmaw a oft eo ftgWA&MOM ea IW CrrM,gftn. r rs rs I l: 'q% CI► CERTIFICAY5 Of INSURAMC OA0000"astoFww. :Its �.PI lllrnlin-Avis &&rh TO Iiw Mwow.caly Ilr• ,� 11�r1.1)(fKr VTY Of HUNTINGTOM •EACH, CALIFORNIA 11. It. 's 190 W l lun'rul trm W-al-h. CA 9*411 A NUMOMAL COA1'9NATIOM This is 10 arWV 11101 *a pokto of baw wo M dnw*M 6111MIIIr A1w Iwrw hard st *4 WW M bV tote rN6010M sired ew in Owe at t%k three. If *w peNdes eve wwwMed wr ahmqpd is qaO a Measles d t WO sa1111sIt *A I IM. 00 W60110 aa+it nrtslOW open Iw VWV�1 W Pr6W Wrl"M ra"' 11y t+ilr W' is CW' o11%Odapis ansh, P. O. Oft 711. Oar ON46 i wrb 9WW ALL ITEMS MUST Of COIII UTIC. ANY DILETIOM OR CMAM44ie[ IN TIME POW SMALL 09 WAD AND OA- 1O NY AM AUTHORIZED 1111OR E NTATIVE OF THE COWANY AND MIST K AI"IONEII IN E11 VINI0 FEY THE CITY ATTOfIMEY. N"w of I oft" / C. X. PUMP i DI`WATERING CORPORATION Adkb" IMwsd P.O. Box 2800, LONG BEACH, CALIFORNIA 90801 Lecarlhm of Vk& w Opwndarml M be pw 00 a Pacific Coayt HEY, from 9t1i. St to Goldenwert St. w�.w�.. Vewrrip mofWork orOfrerl>'rjiwra Puie�ec---�t No.CC6854 Insured's Project f89, installation of PULICTICIATIM LMTi OF LIAMLfTY NAM OF CONP*AY Mnlhe R.Mius fto EillOVIN 1.11 Fop= POt XT 103. M The w" IMEEI "Mi 99MIRAL LIAMLITY I i COM►REMENSIVE FORM took OsftrWAS 1 1 PREMISES - OPERATIONS 1 1 E XPLOVON AND COLLAPSE HAZARD 1 1 UND#ROMOUND HAZARD I P"OOUCTS COMPLETED SEE ArTACHED CERTIFICArE OPERATIONS HAZARD II CONTRACTUAL INSURANCE 1 1 BROAD FOAM PROPERTY DAMAGE f 1 1NOFFENOEMT CONT14ACTORS I 1 PERSONAL INJURY AUT04MILE LIAi1LiTY i I COMPREHENSIVE PORM SEE A CIIE;; CE .TIFICATF. 1 I OWNED S tk 1 i MIRED 1 1 NON -OWNED (IXCIIIISLIASILITY IINDUSTPIAL INS. }.A UMORELL� FORA JUS04302 3/1/85 3/1/86 E 500, 000 CSI. OF IIAWAII 11 OTHER THAN xcess or $ 500, 000 Underlying for to tote UMBRELLA FORM W0911[Eiati C.t7MPEa1:AT10M ow SF.E :1ACHED ETZTIrICA E EMi°LOYEA# LIAAMLITY Additional Insured Endorsirr►nt: The inwrrf agrm that tht City of Huntington Beach and its City Council, and/or all City Council appointed groups. eo mitim. commAivons, boards " any Other City COurMI i apponted body. wWltx OleCtive and oppeintiys o"kws. servent3 or wnplayees of ttw Oty of Huntington Its;cf . vlrflan resting as such ass additional Insureds h@mrndtr, for the am of 9w insured. and such inwrence Shad be primary to any insurance of tf++r City of Hu"lington Beech. at their imeratt may appew. ewe 12/23/05 IMOl 010E lQdUstrigi Ins. Co. of Hawaii ph~ Asr...r coy ._.jr:'Z:aLaurat2 — -ga -4 0 91.2.._.r_,.._._...... w t OR C*v +,1 �rliala IIL��L_�.._YI�Ur YMrr JAIL) 7 9 6 .�..r88 .•.�..I.OX t . 3,O 0 HOLD HAWL1136 AQilwj5WXT _ -_-- Corporatfon fmin"now by_ w" T" W010 d • 011111 M sIr Pl+sltlnet. ti11%wA bnsiarrrrwy. !00. awd hqw Iwrlt w 00 City of Hrrrlatrlgeew ON* *1 #.Mom - masts, WW awlpls 0" ,'Who "T Ml Mft- hok ftwV', OWN- w wsresae bT MOO of MY OW all 1110110ilV. W47t sIbkas. dommok, im ftme nil WA eelreee of eagle al w"d by Wool* kh ww4 Alm. soma w WM r,rintrarftrs060 Or M'11 MIIY Perils /INAy IrilMwg eat of w M Pre "Nowo e of ** Elrlslww wm of GN wM er Iw nAlielt d* wsrWW awn of ills ou eye M %@wAlirl W. *Of soft W Arrsw111* IAi Otf "f Aa NOW I401tlt tee; my how"..� es rot IArI ewes OW M pro" w orw r...._..._,._..� w............, bubo awk a Charles $. King � twrsrr �.. TM if cw"w +•ur. VM Comma Kam a". w prrtarrr► 006=0 a.lAlgrl N"M ca a" wp wmk w. Co 1