Loading...
HomeMy WebLinkAboutJohn L. Meek Construction Company, Inc - 1986-07-10' Mowl. � B DED PUBLIC WORKS CONTRACT AIRS TO THE MUNIC [Z] 0 ,THIS AGREEMENT is made and entered into on this IQA day of , �Ad 19„_y6 , by and between the CITY OF HUNTINGTON le BEACH, a municipal corporation of the State of California, herein- after referred to as 'CITY,' and JOHN L. MEEK CONSTRUCTION CO., INC., a California corporation, hereinafter referred to as 'CONTRACTOR.` WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as 'PROJECT,* more fully described as the repair of storm damage to the Municipal Pier, in the City of Huntington Beach, and C014TRACTOR has been selected and is to perform said work; NOW, THEREFORE, in consideration of the pronises and agreements hereinafter made and exchanged, the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTA14CE OF RISK CONTRACTOR shall furnish, at its own expense, all labor, plant, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to asaume the risk of all loss or dam -age arising out of the nature of the PROJECT, during its progress or prior to acceptance, from the action of the elements, from any unforseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any 1. description connected with the work, including, but not limited ` to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY under them for the compensation set forth in the accepted bid proposal. However, the total compensation to be paid is to be computed on the basis of the units of work as it is actually performed, in accordance with the stipulated prices named in the Bid Sheet(s). 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND � SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as hereinafter defined), the location of the sob site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its investigation of all such e,atters and is relying :n no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that 'CONTRACTOR and its subcontractors, if any, shall be hound by said Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. 2. 'Contract Documents' as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY'S standard Plans and Specifications and special contractual provisions, including those on file in the office of the Director of Public Works of CITY and adopted by the City Council of CITY, and any revisions, amendments or addenda thereto; D. The 1985 edition of Standard Specifications for Public Works Construction, published by Builder's News, Inc., 3055 overland Avenue, Los Angeles, California 90034, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the Ca nia Joint Cooperative Committee; E. Bid documents including the Notice Inviting Bids, thf; Special Instructir).;s to Bidders and the Contractor's Proposal (i.ttached hereto as Exhibit 'A"); F. The particular plans, specifications, special provisions and addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in thn Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of discrepancy between any plans, specifications, special provisions, or addenda, the matter shall be immediately submitted by CONTRACTOR to the Department of Public Works of CITY (hereinafter referred to as 'DPW'), without whose decision said 3. discrepancy shall not be adjusted by CONTRACTOR, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the yid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of said bid or proposal which is in conflict herewith. 3. COMPENSATION CITY agrees to hay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions mane under the provisions of this Agreement or the Contract Documents, a sum of one hun,"Ifed forty-four thousand four hundred dollars ($144,400), as set forts) in the Contract Documents, to be paid as provided for in Sections 1, 61 13 and 14 herein. 4. COMMENCEMEINT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after notice to proceed is issued and shall diligently prosecute, PROJECT to completion within one hun'+red eighty (160) calendar aays from the day the 'Notice to Proceed• is isr:ued by Department of Public Works, excluding delays provided for in Section 11 herein. 5. TIME OF THE ESSENCE: The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. 4. • CONTRACTOR shall prepare and obtain approval as required b•j the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to tht prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors and CITY forces working on the PROJECT, in a manner that will facilitate the efficient completion of the PROJECT and in accordance wic:h Section 4 herein. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, subcontractors and CITY forces and, in general, all matters concerning the timely and orderly ccnduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrur. is authori4e4 in writing by the DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as the DPW -nay require in Writing. Under no condition shall CONTRACTOR make any changes without the writter. order of the DPW, and CITY shall nt+t pay any extra Charges made by CONTRACTOR that have not been agrted upon in writing by the DPW. When directed to change the work, CONTRACTOR shall submit immediately to the DPW a written cost proposal reflecting the 5. effect of th•a change. Should the DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by the DPW and the proper coat thereof shall be negotiated by the parties upon cost and pricing data submitted by the CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to the CONTRACTOR by CITY. CITY does not warrant that the work site will be available on the date the Notice to Proceed is issued. In event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to the CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 8. BONDS CONTRACTOR shall, prior to entering upon the performance of this Agreement, firnish the following bonds approved by the City Attorney: One in the amount of one hundred percecit of the contract price to guarantee the CONTRACTOR'S faithful performance of the work and to warrant: Such performance for a period of one (1) year after CITY'S acceptance thereof, and one in the amount of fifty percent (50♦) of the contract price to guarantee payment of all claims for labor and materials furnished. b. • 9. WARRANTIES The CONTRACTOR unconditionally guarantees all work done under this Ayreement including, but not limited to, any workstan- ship, installation, fabrication, material or structural facilities constructed. CONTRACTOk, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then Crake appropriate repair or replacement at CONTRACTOR'S rink anj expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that the CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not as an employee of CITY. CONTRACTOR. shall secure, at its expense, and be responsible for zny and all payment of income tax, social security, state disability inaurance compensation, unemployment compensation and other payroll deductions for CONTRACTOR and its officers, agents and ^mployees, and all business licenses, if any, in connection with the PROJECT. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in casf• the tot -al work called for hereunder is not in all parts and requirements finished or completed within the numner of working/calendar days as set forth in Section 4 herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay; it is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated 7. 9. WARRANTIES The CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workman- ship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) diya after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or itens. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR'S risk and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that the CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not as an er pluyee of CI'fY. CONTRACTOR shali secure, bt its expense, and be responsible for any and all payment of income tax, social security, state disability insurance compensation, unemployment compensation and otter payroll deductiion, for CONTRACTOR and its officers, agents and employees, and all business licenses, if any, in connection with the PROJECT. 11. LI2UIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished ur completed within the number of working/calendar days as set forth in Section 4 herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of ouch delay; it is, therefore, agreed that CONTRACTOF will pay to CITY, an liquidated 7. damages and not as a penalty, the sum of two hundred fifty dollars ($250) per day for each and every working day's delay in completing the work in excess of th.. number of working/calendar days set forth in Section A herein, which sum represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable losses CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay said damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies clue or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will noc. be assessed damages for any portion of the delay in completion of the work due to unforsee-abler causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not restricted to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR snsll, within fifteen (15) days from the beginning of any such delay (unless the DPW shall grant a further period of time prior to the date of fin,:! settlement of the. Agreement), notify the DPW in writing of the cause of the delay and CITY shall extend the titre for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of the DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed wailing for materials required by 8. this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in nowise caused by or resulting frog, default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days the CONTRACTOR has thus been delayed; but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of material by CITY or delays by other contractors or subcontractors, will be allowed and said extension of tire for completion shall be the sole remedy of CONTRACTOR. 12. DIFFERING SITE CONDITIONS (1) Notice The CONTRACTOR shall promptly, and before such conditions are disturbed, notify the DPW in writing of: (a) sabsurtace or latent physical conditions at the job site differing materially from, those indicated in this Agreement or the Contract Documents: or, (b) unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the character to be performed under this Agreement. The DPW shall promptly investigate the conditions and if it finds that such conditions do materially so differ and cause an increase or 9. I decrease in the time required for performance of any part of the work under this Agreement, whether or not changed as a result of such conditions, an equitable adjustment shall be wade and the Agreement modified in writing accordingly; (2) Time Extension No claim of the CONTRACTOR under this Section shall be allowed unless the CONTRACTOR has given the notice required hereunder, provided, however, the time prescribed therefor may be extended by CITY. 13. VARIATIONS IN ESTIMATED_ QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to the CONTRACTOR will be made only for the Factual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail sub3ect to the provisions of this Section. The DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to the CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable ad3ustment in price or time for completion shall be allewed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, the DPW shall ascertain the facts and circur_:tances and make such adjustment for extending the completion date as in its judgment the findings warrant. 10. • 14. PROGRESS PAYMENTS Each month the DPW will make an estimate in wr;ting of the work performed by CONTRACTOR and the value thereof. From each progress estimate, ten percent (let) will be deducted and retained by CITY and the remainder, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of the DPW, faithfully executed fifty percent (50•) or more of the value of the work as determined from the Laid schedule, and if the DPW finds; that satisfactory progress; has been and is being made, the CONTRACTOR may be paid such su;n as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined by DPW, less all previous payments and less all previour retained amounts. The final payment, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the fil:.ng of a Notice of Completion by CITY. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by the DPW, affirming that the wor► for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate i5 due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 11. Ll 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and expense of CONTRACTOR, who shall retain beneficial ownerxhip and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under Section 13 of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with the DPW its affidavit stating that all workers and persons employed, all firms supplying Materials and all Poibcontractors upon PROJECT have been paid in full and that there are no claims outstanding against PROJECT for either labor or material, except certain items, if any, to be set forth in an affidavit covering disputed claims, or items in connection with Notices to Withhold which have been filed under the provisions of the statute: of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. 18. INDEMNIFICATIONt DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold and nave harmless CITY, its officers, agents and employees against any and all, liability, claims, judgments, �,osts and demands, however caused, including those resulting from death or injury to CONTRACTOR'S empl-lyeea and damage to property, arising directly or indirectly out of the obligations herein 12. 9 • undertaken by CONTRACTOR, or out of the operations conducted by CONTRACTOR, regardless of the active or passive nature of any negligence by CITY, save and except those which arise out of the sole negligence or sole willful misconduct of CITY. CONTRACTOR will defend any such suits at the sole cost and expense of CONTRACTOR when requested by CITY, and any costs of defense or attorney's fees incurred by CITY in enforcing this obligation will be reimbursed to CITY or may be awarded to CITY by a court of competent jurisdiction. 19. WORKERS' COMPENSATION INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowl-?:'ges awareness of Section 3700 et seq. of said code, which requirNs every employer to be insured against liability for worlters' compensation; CONTRACTOR covenants that it will comply with such provision: prior to commencing performance of the work hereunder. CONTRACTOR shall maintain such Workers' Compensation Insurance in an amount of not leas than One -hundred Thousand Dollars t$100,000), at all times incident hereto, in forms and underwritten by insurancQ companies satisfactory to CITY; and CONTRACTOR shall, prior to commencinj performance of the Work i hereunder, furnish to CITY, on a form approved by the City Attorney, a certificate evidencing such insurance; said certificate shall include a provision that the insurer shall notify CITY at least thirty (30) days prior to any cancellation or modification of said insurance policy; and CONTRACTOR shall notify CITY at least thirty (30) days prior to any cancellation or 13. r E modification of such policy. Said insurance shall not derogate from the provisions for indemnification of CITY by CONTRACTOR under Section 18 of this Agreement. CONTRACTOR shall require all subcontractors to provide such Workers' Compensation Insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the Workers= Compensation Insurance and CONTRACTOR shall similarly require all subcontractors to %+aive subrogation. 10. INSURANCE CONTRACTOR shall carry at all times incident hereto, on all operations to be performed hereunder, bodily injury and property damage liability insurance policies including automotive bodily injury damage liability insurance, underwritten by insur- ance companies in forms satisfactory to CITY for all operations, subcontract work, contractual obligations, product or completed operations and all owned vehicles and non -owned vehicles. Said insurance policies shall name the CITY, its officers, agents and employees and all public agencies as determined by the CITY as Additional Insureds. CONTRACTOR shall subscribe for and maintain said insurance policies in full force and effect during the life of this Agreement, in an amount of not less than One -Million pollars ($1,000,0000) combined single limit coverage. CONTRACTOR shall require its insurer to waive its subrogation rights agai::Rt CITY and agrees to provide certificates evidencing the same. 14. Before CONTRACTOR performs any work at, or prepares or delivers Materials to the site of conztrvction, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages; said certificates shall provide the name and policy number of each carrier and policy, and snall state that the policy is currently in force and will not be cancelled without thirty (30) uays written notice to CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accep�ed by CITY. The requirement for carrying the foregoing insurance shall not derogate froL. the provisions for indemnification of CITY by CONTRACTOR under Section 18 of this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all said policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. 21. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the Work 'within the time specified, or is adjudged a bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate 15. this Agreement upon the expiratio)n of that time. Upon such default by CONTRACTOR, CITY may elect Aot to t*rminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. 22. DISPOSITIOh F FLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertjiining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 23. NON -ASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any aright or duty created herein, without the prior written consent of CITY and the surety. 24. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of California Government Code Sections 1090 et seq. 25. ATTORNEY'S FEES If any action of law or in equity becomes necessary to enforce or interpret the terms of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees, costs, and 16. necessary disbursements in addition to any other relief to which that party may be entitled. If any action is brought against CONTRACTOR or any subcontractor to enforce a Stop Notice or Notice to withhold which names CITY as a party to said action or by reason of which CITY incurs expenses, CITY shall be entitled to reaannable adm W.strative and attorney's fees, costs and necessary disbursements arising out of the processing of said Stop Notices, Notices to Withhold, or any similar legal document necessary to the prosecution of such action. Said obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One -hundred Dollars ($100) for every Stop Notice filed in excess of two, regardless of whether or not CITY is named in an action. CITY may set off any unreimbursed cost or expense so incurred against any sum or suns owed by CITY to CONTRACTOR under this Agreement. 26. NOTICES All notices required or permitted hereunder shall be delivered in person or by re�istered or certified mail to an authorized representative of the party to whom delivery is to be made, at the place of busines:> of such party, or to any other place designated in writing by such party. 27. CAPTIONS Captions of the Sections of this Agreement are for convenience and reference only, and :he words contained therein shall in no way be held to explain, modify, amplify oc Aid in the interpretation, construction or meaning of the provisions of this Agreement. 17. 28. ENTIRETY The foregoing represents the entire Agreemen?, between the parties. IN WITNESS WHEREOFO the parties hereto have caused this Agreement to be executed by and through their authorized officers the day, month and year first above written. CONTRACTOR: JOHN L MEEK CONST�LICTI,O CO. ,.--Joan L. Meek, President ..F,�t a--Krei�; S Trras. �7'tNpRh OSS� /Y�oRT, �ssT..s�c•, ATTEST: City clerk REVIEWED AND APPROVED: City Administrator' 0428L 18. CITY OF HUNTINGTON BEACH 4--a vo. Mayor APPROVED AS TO FORM: ty Attorney INITIATED AND APPROVED: i �. 1..�•�-fir-' .. Director of Public Wo!*9 ATrMNEY IN FACT ACKNOWLEDGMENT r ' STATE Of CAlJi M*dA Cwtt at CRAME sa. (M th» 5th- . _ dot t1( Augu3[ in the text 1986 beta -we one. a timer, Public to end for mod C*uANM Ctvunl► . %late trl C'altforntw. rettdtns thtrem. duly c(ttnmtstkmed mW st►on. perumMy apptrnrted ._. - C. E. - _Frey. 75 ps %imo,rf known so me. 0 pose 10 n(e.s the Imma♦ s, of -.— — IJ, f to be the perum %hose ryes s+ tut unbrd to thst inttnsment at the scanner-f mfatt of- _1tL��.�,��.�i417v_111surSaiiiscG_ rto and ackmlettlMed to me thas � Q ti Me e sukttcrtb*ed the name td FiIZrMANts rM . I?�.F�If5hi�l_COMPANT. sommy. and (3Na ❑ Met own name as sttameY to fact I*l WITtif.YS WHERFOU, I have hereunto set mt harm and afh%cd mt a0k-tail %cal. the day and veer %tatetl to IN% cettsflcsrte sb(we. �i� L RWA5 Vnts►y Etibilc pOMM trlf" • CAOI skM mft cwg;oC[ IN Alt colwoR►stxrl etpre• _ _ _ .-----_-._-- . txnsas—t 40 � CDOWSWO upon may 2c INS 1. "FCln'ED %TRIPLICATE 1 �- PXYfll M BOND--- PUBLIC WGR1`1"•- CAN — I 1i f 1 1 M'OW ALL MEN SY THESE F RE -SLUM BMWfpv�_209 8245 Premium Included in Performance Mond '1 ..wtw.h% t.iwt. ,ws..w�..t.l c^rr►w. ••.2 •rt.•'C•w .•'.%UN&•.Ct t(zwI•w. •J�^t a •ih •4C•trhi/• (/.�►-1w�•.,lw f •..f►•• •w •�•4rA�y1 •.�_w►wtt CI(YIIw. d ! ..•.Y. (.of Ice Iw►•IC•Yto LA,r `,, Cf,.�i .ram `r•' ��' i �.- TMt we. John L. Meek Construction Company as Principal. and Firetttan's Fund Insurance Company !n.?:rr.•,:r.!»3 ,:..mot ►;. :TrJ ,:; l::c (:tr.lt c! Cal ifornia and m:thc.r.:.d to eve ','e ! nis ani u7i.•rt'Iis-1 rj:. L":f• ._•rty i- •a:.y a—M al pm::.na nc .O'J :tl CQ::!(-!n.0 C:Y:. C:•ir j•`'t:C: 21 '�'. :r' :5..^.1 !. ZS ....t : (•n j. J . Ll vporat:_n tS the ' f;,;r*'JUiv total of Seventy Two Thousand Two Hundred amid no/100--_____.._.._______________72,200.00 J• !z): the ;Xly::en- Ta':;r.:. .. .*,.. . ", . . ( ... . :*­ . . ':,; :. :: .. their h—.. . ' and cuign... 'a;r!iy ..... se's.. ,.y .. .:..y L, O:••.i, D c`.x t'.... !l.-. 'l T' .. . I ..- _ .:r:. I• l:. T twitej 13 woh th• tz do tho rJc.t'c. I: w t Repair of storm damage to the Htinicipal Pier 3la tz rn r c, .. rr..... ..'3• . ,.. .. . _ .' ... .. .. .. L'r.er-;;•..•y: <•.• Iaauta::-r C�-moo �.:•►.. .;. .. �. . t .. ::. :. ... L . .r _•. .. r, . •.... ,.,y ..,., ..... .. a:. ,r-;(..., t ..�� .•t:.•t' .. .•, j. .. .t; .. - .�. I .... . .. '�. 7 ... .r ... MVy 7 let k l'. -t: xF'3.: :.. .. I1 .. ••. t�.n ;:�. , �.. .Cl 5... ... .. .:rY .,., . .. T• .:II •' S' .. r.. l.Q::� s,..t. -h.n r,_rd _...a ..,? . • . . , 7• r ;-! . . ! C ;l• ! •Sir ,' 1,7 . . S • ST t;) a:Y0 a n jnt c:l :3:!... .. .. .. _ ..y:3• • .. any T.. I . I: -. •i;.. . 1�1: ... 'T rJT• .^. .. .. � .j rI • .. ; .R .. t. .r ; .. ... ,..'• .,1':It• ... .. 't::�'.. .. t.2a .S6A.:J.',.Itt'l %b. S;gnei 'ITA -t:e ! th:s St h 0 360099 -- 1.71 w d:r. ..I august .19 86 � f .-John-1 ,. Cek. nstruct i�a �CO�r jvt -.'- J1* P1remn's Fund Insurhnce Company. icy. C. E. Frek,:; _ Att r.ej tr. V;� I t k.,'mits li''lJm IMMANM COMI 041 ILAIW AN. lilts Oil TNRIIt MNtK +IV T1w FIRIEMAN'S FUND INSURANCE COMPANY. a CNITorattoa twlf or iced rw1 etwom aeelet or ►Tors td d r !)wile IN CWi emia, tt111d Itaviv in piotcipW Ilff'iice Toll title City alai Cam) of 510 FtaaToCM0. oft awed State. ha% wi aoaat'trOW AppWW4. sari 4m by d�lwo prwons ftaalke. ce+ltTotiouk aari 8111011110101114 -----E. E. FREY••••- its trill MTV Zswful Atturee0il}io•Fact. with (TIN pwe► and authority heteby cotifferrtd in os maw. place and %lead. to eaecwe. Total. "Ltwr►hidger ewd *hvrr any a lilt silts broods. wrWenAmp.:ecagiusanice% or olhtt afit ten t>Maptwnt% M the natwe thirrelil .. •« •• •..•• r.. •• •. r•• rr r• • TTW to bits/ dw Ca tatrort theteb) as full) anti 10 the %ansc c%lr.tf lit of such bufWS were u,ntd h) the Pteudrnt. waled with the corpralc veal 4 tlrr CotptWIAW ► stab iTod) attested b) Its swctw). hcrch) ratlfy!"s awd confitaLtn4 Jtt tbei Ow ward AlforM)t%1•rn•FKt Ma) do in tk prgwww► Tltisp 4fof afWW) is /ranted plter"Mal to AMKI- VHS. Sectwn 10and it of R)-laws of FIREMAN'S FUND INSURANCE COMPANY nat. to fvH farce Clad )Alen -Article VIII. Aprrptfttmentand 4uthorrrs 4.++tu%t or,tr►artrt and 4ttorrlrt •In la.t and 4frntt toa:tcpf f cpii? Pi,x or, -and %fair 4rprJNn.vt Section 10. Appointment The Chairman of the Roard of Utte.lott. rile Pte%tdcnl, an. %.;r•Pre%Itienr tot all, ellirl rrl%n.t aulhtvl/td lit the >L Id Of Director%, lk Chairman of Iht Ooa►d of Doe lot%. the Irrr.rftnl ,it ant %I.r Prt.•dtnr, mat item tlrr,e to Ilrr e sjrNmt 11t%tdtltl A.•r.i/nl Str.fttaltt% wad Atfotet)s•tn.fact to rtrownt and a.t for JrJ on br ,0 of the I o rporswan 8,10 Mlrr it, J..rr trial r+t,,r, and mall Jrrfalan.r. lot J"j an hthalf of Ike C arronatlo-1 swiQn 11, 4vfhorNl the Aulhettrt 'Lit •t..h Ite-0tril 4r.trtalle. 41tolne++ to IA.. and Arent. .hall he J+ •n the 'loluthrill tsldtnctng their appointment and ant su:h apratntrf.tnl srJ All t'YIhG1tlt% Jointed tt,ef O, fiJv tt fr•ttJ at ar, lint h. Iht tt.+J1.1 If t)Lrcot•r• t)r fl an) ptfton cmpo+nrd to male such arpotnlmcR. This poser of attotne) is sqftd and rtaltd under and h� the sul-hitwtit of the following Resotulron adopted bt the SAW4 of Mirector%of FIREMAN S FUND INSURANCE COMPANY aI a matt+n6 dui. called a:ud held im Ow Isth ds) of Jul% Isis And and R %,r4wokm has new tsttn amended .►t twow —RESOLVED that the %Ifnalu,I of an% VOct•trtWenl 4taaarif Secrelars and Re%dent A%vtlanl Sccrelarll of flit. Ctsrrttttals..n nerd the vial of this Corp etelm )nay be JA%ed or pr-mcd on ant 1'atrrt ('if unwise/ rf+ alllo Iesaalovft of en) por,ef at anoints to Ott ans cert►Ncate reiatiltg thetemo M facuff"k. low w. rower of eftotrnt) ant, n fut(KalH.of ant linear of alttttnts tv ,tttlkstt twarow .MTh (a.a,n m4c %t/tyrt or factunik %cal 4WI he valid and btadrn, wpm The Capntalnn IN WITNESS YIMERFOF FIRF1644% S Ft 'tit) I%SI R A%CI l (IMPAtiI her• c/u•ed rhr.e l+tewfil. 1s tv wined h► ltt l ice i'rc.rdeslt and Ill cofmale seal to tore helevn:0 srfl,rd � 3.Ld_. .. d/t of _.....�Ltjjltlt _._-.________._ tv -AL U��: "•f iiTATIE t)F C4LIFUIRAI4. ' b Cm A40 COUlti-7 ' ai 54% FR 4%CVFA' 1 I fiata4% SIt tinl%st R4r.CI (7011/ 4%1 o On This 3 rd da) of August __ . IQ 81 Nrt•rr me prt.onat!t .sTc Richard V1 i I Isms _ to me mown, who. bon; bs me dul% 1u,oln did dtsv%e a/t: •/+ that he t. %Af Pit -rani of 111111 %1 A%'S I i • 1) 1W tl Awl I t I . Ihs ( ht ptatllan dt%etibtd to •red wht.:h c%r►utnl the aMtt +n.leumenl. Ills' he knout Iht ,tail of arJ (etNplAlA►rt. 111/' the Cal Jfl.tht I., the .alJ /n.tfumCt. n s1Jch ClaltV4W8lt teal 1441 It wort, t.o affntd bt ardrt et the &'lard of Oltrtlt.t• of ya t tNrt1fa19tn AFW thJt he .y-rd hr. f1J"W rhrrvo b► Itit .trJlt IN WITNESS 'A III REOF. I hair? rfcvrolo.tl m% Rand snJ afford mt otlt. vl .Cal the dal al%J,tat Aran lit aN',r roller. OFFIaAL SEAL L• w. '^�"�in:� of Wal = Is IN ..__..._.__ tIq corm►~ t■prtts tuft, 11 144 CI'.ATTFX:4Tf ivTATEaCAI.!!MggA. CITY 1' AND COILN OF SAINT! fiC 20411C 0 I a 1. ft vatdersiped. Itnuk-Al A%%nlanr 'SCCftlar) of I IREA14ti'S FV%U 1'uSl R4%Ct C()%1P4%%. a Cot If OR%14 C *rl.lvallon, WIT NE at 61 CERTIFY dye lht fort$*,%, and attairmd FOIL EX OI ATTOR%.E1 Ilttrfa►nt to full Iot.c zrsd Itat not brat healed. and lutrhrrmurr lfwat ♦lr..tr %III. Stet om 30 and 31 of the 110ast of the C*Itelaltern. and the Rtutlactoe►.ol the iclatd 0 ENtntors. rot (mill in the Foil" of tlntunrt. off nos to force 4 / 1) 4inM and sealed at Ilrc Cn) ailed Cla,tnt> of Sat+ ira+rctao Ualtd the I ties of �3' I • J� � ty •1 � . . tiso= "•.r t . •t�Irn, A..,.rar+ ir.Irtlrt Mht*P4W AIT MNEY IN FACT ACK14OWLF- GME1r}T STATi :X CAIM a Carl! M OR tln+ of Augurm at flee year l�Sb t+efutr tne. a t�iatrry hbotc M aarl ssaf Llt roam Y. Slate L4 CAI*kwww. rt:--W"V tbtse•w. glair, sawl swam, penoadly ' Lam.__ EitY _ • -- -- - -._ .. _ . -- _ . to me. M tar m lk si of mooft im I wwdi j to ►c the perwo wbnw aawrr i* >Atb+st�ad to th" wun w m 24 gate mwvr eY��lat-- 4! 1 V�M ik� �► _ mid ackweo W"d to at ttat 16 to Q tfe sdwcrt2+si It* "a* .i .. �ERI`1.:14i'!'$_ �.�10. �5��..GQ�__ __. �tttanete as awety. aad� icit Q itar � ror� as attorwry at txt. . is wrm 4 WHFItFt�, i have bcf vma set int hoW oftd affixed my efbc-.4 Deal. (Se afar swd tsat wawd m tlKs ca utcan abo". Of nc&4t Sit - �. _ _ . _ � _4►_-_ , ` tt RASA L RWAS / iIOgJU► P%"" • C414DrA 11 xY 1'1�iic F%uoopK OFF= Of , -------__-..- r ExEct m ""' TRIPLICATE /IitoAM 1 IV•r0 rra�yA•Mrt C�•r11rr• INA AwrrrC.M rwalroAMCt CPae•..♦ MA/rDAr•l aVMIt Cd&~6*6O00 •ANCrAtAD Aft"brrrw C040100M•r.r ft AM1hC•M •61aJA•4S1 Carr•b. 0 Bond No Prealtux: S2,079.00 r.awt pr to u.r rw•rc,aco t•. •ro•+.• 1 • '•i _t •y PERFONMAMa 301 D KNOW AU. MEN BY THESE PRESENTS That tee, John L. Meek Conntruc.iton Ccapiny fhwte;wftef a3llf►d "Princtpal ! It Prrncgv::1 nr.•1 Firem-ints Fund Insurance Company cr.rrixratv�: ,2rta :•f S a ct Ca I forni� n nr•t •7..th"'rl�i !r•7♦�I'7c9 l' r1.'flr 'h• `,r r•r• Marl anti •::thrq •rr.le-► the r��ra �f the "1 r 1 • (hetalm!1er CnIle••f F'.rety ' •11 S .rely n+• h.•;'l f'+•-rl► t+c ,r; t v' City of I{tlnt ingt on Seawh (hefelnatler tooled C!Lhgee 1 r1. „ t•, j..r,2! r.'• cl Onv Hundred %forty —Four Four Hundred and no/100------.........._...____.._...__.•.-__---- ______._...._------...,__- _.._----'.'---•------------ ._____.._....___...._ ltidUa►a tt 144.400.00 7.,i ..t .2.'.. ..,., , ,).r r!'.'r! .'')'•: A .er ) # • 10'.0 ;.1) -f ,.:--% ..•'l )•.s ••." Mr M-11'. we kw. t u. r11pr ..r ..I r)e•-. •� r . •0r 1- ! .e•t.r ] .r !. -;r t r r!,. 1. ;,01r• ,i Slpned Sa►alw•1 r1n•! :-)reef +t: r StIt 12, 1August "r Kh Whfro-a 'he 'It., ,Of, I. . . p .e •: ♦ 7t,� .. . r ^ S .mot , •r,. i 71ot 6,w -I IV -! Repair of storm damage to tht, Minic"ipgl Pier whr<,h rr;, r': r r.rr�t 1 ... ::. r ;•. r r r r j NOW THEIO.1 r -kl ltil truly t"I, ,Ir ,)• S ;r .t. .. JtI t. 2' .. . 7: ) .• 1 r'. i S .. r.. r. .r. tj� ' I t by ISO- - :r♦. Qtv%t r)P1.1 !r .'1 / C11 the p.t•1 +.,! �) J ;1r. j•)i .tie. .). � -t r' It, t' S f rh*rw, er r t ♦ 1•.S r• Si• • .• ;e ! •.nr, John L. ' Meel: f" onst rue. t tin (lomp!iny Fireman'" Fund insurance Co:spany Surly f Ar 1! ctal --6.97 Ar1tt>w N" F7i ��AN'S F VND INW ANCE COMI Ov KIIM ALL.110M a TI41RtltrRIUMM That FIRFMAN'S FUND INSURANCE (IMPANY. a Car anion dw t0tttll cat= WNW alit �Saft ref Chi otais. MW M vWq as pmc�i affect M the City alb Ctrwat, of Sail Ftttwcr►cu. �n wed &apt . Mi m cm+t mswd aw ice. don Ilt"!m1'M tttiakt. ceM davit aatrl Opp!) "I -----C. E. FRE ----- its trine laid b*IWt th"Orowil 0-in- Fact. vodk for, bower and authmety hettttry ccmtcrrd M its mine. plat:t mad wad. to tarsv*. wal, a Am-abdipt awl /itittrtr asr atfd ad binds. trwtitrtaktpP. 1111CO WIsnces or whir "ripen ctbirratatNak M INC arrtWt tAntof .•..-• •--•�• -•�-- •-•-•-�• mW to bin% dw t altton Ulntreb) as fulf) and to the M&ww t%ICnI as if Muck hOnth '.tit hiked b) 1Mt Ptg$eitrll. SCOW+Itk IMe corptarslt Wal Of slit Cet,/errtiwt awd Iriy sltcu d b► its 5ecretar%. herth) ratifying; and carnlltrr►r"s all dial the %W Altormos►•tn•Fact ON) do on tbt Nre"Itt TM %ptet o of atwttnnty is gr/ntd purummi to Article VIII. Secttat .Ito and 1t Of of FINEMA►'tf'S FVND INSURAW. F. COMPAMY auo M too lard antl ItAtd "llttrcleVill.Appototmentanc'4uahcvtrt 49tr%ranr4nrriatrtt andtoa..rrtfgall'rtsr�•andsfaL,r.4rr+rarJn.r� Seetann M. Apporntrr it The t; hattman of the 9oatJ of f)tte.tott. Iht Irtr.tdtrtl. ant \ Ke Cie%IJr►tt M an. nt►ttt I+tisor. aurhottm! Itt the Illoard gl Dirtctork, the Chapman of the award Of U:+r�tort, thr PrrWent rt ant \ ae•P.r.tdent mat, from ttmc tr Itnle. art+otnt Rt•alrnt M..r.tartt ShrtrarK• amd Attotnt)s•tn•FA;I IA refttt%tn' and a.t lot and on behalf nl the ( otrotatrttn and Alen?% to a,.rr- te1J' rfc.sr— end stilt arrfatan.-, for and on behalf of tht Corporation Section )I. 4Whortr% The Authottt. of .a.►` Itr•.Jrnt ttt,retarte. Altrtnrtt :n IA.: o+tJ Alent. ,hi'r nr a• r'c-.t PttJ ,n IN--ttunttat t+tdt»ctnb -het, sppotntmrm. and an% tuch erro-trnrrt and ail autt oo- vanted ts- vet% n:a% t•r retAt.1 Al *, the Kj4'J 01 Of t% an) parson entro•%ntd io male t-h arrotnttnfr This tr of attxne► Is M d and sealtd undo- ant !t► the suthtrt.t► of the follo•rV Restrlutom ad(V4td h) the R.v14 of thre"a" of FIRFMA%*S FUND INSURANCE COMPANY at a nxetrnb dull cx:lcd andd htW on Ihr Isth dal of lull 19W and Ma+d Kr"4wt+w+ ha• " hrsn anstrnrkd of rcttakd "RESOLVED that the tgrs Lure of ant V►ct Ptts.dent A —mint k;retart and ResoJew A►uttant Sectttat% ill thtt ('tw"Sttttn and the wal trf lard Cottporalnon Map he Af tto uM prtnt.d on ant rtt.trr of ono -net On ant tern►atrc.w (of ant rower of atttwfw% tx on an-. ctnsll4att telattnj thertio. I % ►Ksttntit,"an) power, of atnorites ant rr.trtattan Of ant rt•urr of atttwt+et rr (rrttk-att tvarrry a.tt► (at.•ttwtk atpnatutt to fres+rndt Kat thail Pe *sled and bndrnt; upon the Coep.rration 1% WITNESS'AHERF0 FIRE v44% It f l 'ND 1%st R A`('I a OMP-r,tir hat ►au%rd 4W%,f rerstnt. Iry 4deerl pit tt. \..r P•f.Klent attd its cotpofatr seal to"htrtNnto alt;tr.; 9". �Id _._ da,--_lGhlljuSZ-_. �_ ._ , to AL FIRI M Ak, sit %D I%St R A%(I C04PA%N .STATE Of V4LAriw*4IA. � CM AND cot" 4"n UST SA♦ rR 4\Cti+C'l► I On this 3rd dad of August 'Y_ t• 81 Nitre r.•r rtt . att%.a*n. -Richard Williams to time kpoun. who, being bt nt dust .-born dal denote anJ •a% flat he t. \ wt ple"dint of 1 lRl"A` ti 11 %D'"t It A`t 1 (11\lp"l L IN (rt poratmm aewribtd to anJ %high tieruted the ah+%e tntttumrr.t that ar ►nnu- Ike .tat of .&%J tMtvNatK-n that the •sal aff,trtf tr tr,e .a•J •n..runtcni is swch c(arporaIet. Meal, that to wit ►U afltstd bt ofdr of the M.ia0 rI Di, C.Iot% nl tawf t OfI-, tat«+%' an+! that ht .t#nrd it , na-rtc tSir, tto rt hke ofJrr Iy 'M 11MESS wHER101' I hs%f hertunto %el m% hand an.: afli.n1 rtt offbias •tra' tht dot anJ %trot heret•t Intl ahNtr ++oiler, OFFICIAL SEAL�� SM IL GEM �.CO litft COMMttAow ItePen l Nov try t#ra l'1f01T1fi('ATi 111TATE W CALHIIIR94A. CtTv AMP MWn 0 F "14 FW♦bM*0 1 to 1. th.t tttadrrugfaed. Rtu* I Assivant S+ marl of 111lEAIA%S IL lot) 1%%L'RA%Lt tUAIP*.%I. at AL IIOR%1A (ofrottatton DO N1.RI UI CERTIFY that Ihrt forrsol"I and attached ROM ER Of ATIOR%1.1 rttnatn-4 to full lot%c &nJ ka• tiot h ma ttroked. and Iwriltnrru.te that Atilt, It It Ili %tenons 10 aid 31 of the Be 3 us of it►t Cotmatran. and Iht Rttnanttett of the 111061d Cl Uttf.tan. 'AM Itulh In the Poser of An:rntr art ilia or forcf SIVWd ca4 w&Ird ar Itir Coop ta:nd Couse) of San f vmit.o Uatrtd the me dot of a -OF n'-"0-40� 609 Ar"dtret 14~400kr meat #1' 4V-" S%TATEf�--- COMPONSATION 1NSURANCIR FUND r 117S MARK" STREET j SAN FRA"CISM. CA $4103.1410 ::%•.r','r`a �'�' ':.4 rig .�a; +r:vti�+.t. ; ,. ,•; .. t I /IL►Lr' A[/tA TOE Noy NGIVE A �; PARTMENT ,T •1+71 Qy, �y,�'� �.� {J ?F"•?..f" ' •. !. . :r« y�,,,. �s V . ir,4.1 Il �.i5 t.' ..i �: • , �`.+ li. •`N♦•N77�M71 CA "Q2647, . .. �''�` �1141� � '. •L `4. }';f• .�r• �iv ,j.. • v .1 [ �• � �. •, r•' �U'., [.'� , it =CA`• ` MISER» •1'fy',. �•.'� �. Ci Y'✓• 1y,'�'y.• 1 • .. `. �4aJ,,i'rl '� t'{y ,L♦ Iw" .i" •11' ,ty� .',7 ..• � ;�• �^ �Y' ,•4;• 'i !� � '':' u'��1%"» �•` .t ;�.. . , . ,� L:�y ` •.r� r1 i '. .i. ^TtT^,r'.�I.a i. �✓ 4 •� A. , _ •y •♦v •r i..l' •• � ;'iY ••' ,+• r',i} •� �.Ij-p. Y '`' �}'i• ;•.^i` .. .. •..r f°... ,' .j .[..?j. ntr •t •� .•. Z =a: •• t .. '.► . •t,4���!+• y �•,,. 1•. .:.�` .��r��,gi ►.• .y•Y.�:r�.r=,'r�, wo- �iyti�'�7'1•i'�'''•t� � 'T'CS"' ,�' i:« s �t. 1 +�til �� •.+r; �♦ •��. �.. � ... � . �'•• : y..rr �r 4 l� �?! r• .. 'r .• 1. •. f �. � � .'•i4 "�•., iT�1}},, t'. ' - i This is to certify that State Compensation Insurance Fund has ' issued insurance policy number L&H ont aI to MEEK CONSTRUCTION,.. Effective Date 1032 VEST C .STREE? Ex ' ' kI LMINGTCIN,. CA 9014�+ ` Expiration Date_ Policy provides coverage against liability.under the United States Longshore i Harborworkers' Compensation A::t. Midterm cancellation of policy' initiated 'by� State Fund is subject to 30•days notice. ` 'Additional endorsements and coverages apply asJ•indicated below ,•�•. �,. r�r t `•' 1rt • •;w. .%;'� _y, .7`•• r r t11t.. .F'fi4 t 'iX••if�a:.1 :i N'l `A �![��"�!.!..� .•',.'.t • .i' , 'jY,�.: b %``!' '; •�` ,.FY' :`THIS �IS NOT -A CERT FTCATE OF COMPLIANCE• I t!r4 ��' [� :1''t� ��• �• � Kf ♦. 4 + '•• : •.. ,i .'s� -. '•;• r . rt >+.S'.,. �:',�titi• ��'ti•iyw`*' ,t•Y • 1 � � 1[f '. . o Documentation of this coverage should be available from the ; Department of Labor, Longshore Division, office of Workers' Compensation Programs, 300 S. Ferry, Room 2525, Terminal Island, California by 6-9-86 • Sincerely `Martin Grove 1. t , • ; ,� Manager., , w• !­ VSLiH Insarance All 4 r ,', �_,. , :+,J,,[." .r .J .a, ,,..•, jF: v1 +✓, .� •.1`1•.,•ti .{ath .,y[ �` •Y+'.'1"h ..�' y" $�ri"• r.PA . t.y.:d , ♦'M'-'• ... .. w•r:,i - ., +1t. ► y •. i'i;r� I.f.7 �r• .. ?•'�� 41. , slc+r 11001arv. !-Sal MAIL ADDRESS P.O. BOX $07 • SAN FRANCISCO. CA 94101-0807 40 f PFIODUCE I+ ANDERSON AND ANDF.RSON INSURANCE BROKERS, INC. 2495 CAMPUS DRIVE IRVINE, CA 92715 TEL- (714) 752.2255 u�SU%7ED JOHN L . 1 1EEK CONSTRUCT I OI! CO., INC. 1032 WEST "C" STREET WIL1.1INGTOt4, CA 90744 i r �'Vt uu;,, M 8-29-86/kb THIS CEPTWICATE tS TTaSVO AS A MAMA 01F INFOAMATY.)N OKA Y AND C040EP4 1#0 RIGHTS UPON YHE CERT,FICATE HOIOEA TNtS CERT'IFK_ATE DCAS NOT A.MtNil EATEHG CA ALTER THE COV'EgAGE AFF000(0 By THE POLKAS SILO* COMPANIES AFFORDING COVERAGE WIA,• I•�t►1 A ILLINOIS INSURANCE EXCHANGE A►., t 8 INSURANCE C0:4PANY OF THE NEST ,FFtI C VNITED 11ATI011AL INSURAKE CO, ...i.,, . ID THIS tS 10CERTIFY THAT POLICIES Of I►tSURANC.E 11ST£D BIA 0* I/AVF BEEN ISSUED To T04 "tSM.D hAAF(0 A OvE FOR THE POLICY PER*OwD,[-ATty NOTWTTHSTANDWG ANY REOUIREMENT. TERM C I C0#vD+TK)N CIF ANY CONTRACT 00 QTI.Cq DlrtiCUWfhT WTTH RESPf:CT TO I HALM TWS C FTNICATE MAY BE ISSUED OA MAY PERTAYN THE iNSURAhC[ A►FCInO[tr ,o•. I-( I'.h C IS DtSC),,tU0 o4fn[th SUSJ[C1 T(I Al L THT TERMS FACIUS00"s AND Cows TOOINS OF SUCH POL►C:ES T G� " r.. . .,� i .....� I.n • , IN TMOUSANOL , �... • 1 i a, w .d 9 .4 ` 1 GENERAL LiAR-1117 v � A X. DOI. 02818 12-17-85 12-17-86 Is X' :I.,L, , .. . .5 _ . X- •,• :. •, ~' (Subject to any self -insured ,.. • '`" ' i --�'..� retenti m or deductible nn . . • ,, .. this polic); ' :., ... 150, S 300, ;;' . •,. ..... S Incl . AUT(ifilO 'F '. AFI•i , U 11VT 16349;' 11-23-85 11-2.3-86 1 X' t ,,. i "FaCfSSLIAL04 .5 ,.... c 1, 000, �..._.� - ._... -, 13;'•.?.; 12- 17 ;;5 12-17-,','6 ;, •, c 350, c 700, C'x' .. W0 0RI RS COMPENSA',kA ANO g 4 , �•, •., 4A. :If , •,, . I i 4'- r:.' • •• L ' ' , ' , City of Huntington Beach, its City Council, and/or ' all f�iiy CouaciI appointed gt-oup$, coffglittees, Gprmissions, b9ards and an� other City Council appo nted bo y, and/oT• exec rve & appointive officers, servants or ernplo es of the City of fluntington Beach to be nailed Additional Insured as respect, operations o the Named Insured. CITY OF HUNTINGTON BEACH SMCxxO ANY C# THE AAQVE ExSC:R%VfJ P(XA:Ks t!E CANC.ELLEQ N,[FORL T►ItE Et Office r."A T�y7]j�7, DATE TH[REAF THE ISSUING COMPANT WILL XX*WIMML1 XN Ins. & Den. MAIL �+y DAYS W01TT[N MOTICI To TN[ C[RYWIr F HCJLUfq N►M[[0 TO T►1C d n RnY 191) 1fIl aft T + ". r • O1'�IL OM To RONKRT L VkANZq Chief From ACCOUN77NG f kKCOKIA AdraWatrative Sa vievu IMpertenent Q' :%r *MI 10% Ret"tion Dee �� '�` ' cc a_ The Conformed Qapy of the Notice of Completion for the abM o(MUWt has been fi%d. 'tire thirty-five day waiting peerW has olap" Payment of the 10% retention payment is recommended so Iwq as no stop notices or outstanding invokes are on file with the City. an , too :ce 1 certify that no stop notices are on rile on the "Ject *%mtract at this time. Date: Paul Cvok, toe' PubUc Wa ks Department l certify that no Atop notices are an tilt an the subject contract and that a guaranty Mond has be" filed. DrltttAS Sd- u- A-1-A Aa- - entwortho City Clerk O'er r 1 certify that there are no outstandirg inw;via on fi PP, I . I ISTj �,w ATTORNEY IN FACT ACKNOWLEDGMEW t STA3t OF CALMPOWNA t� camoy of on &V of __. __-- _ in the rear ._ __.`_ -_. _�-- -• before wte, a Noury rt"c to MW for +aid RAW_. County, State tit Caldnrrws. ream therctn. duty coitw%%%iowtd aW spore. peraawily t — � — _ . _ .- • -- _ _ _-- _ _ __ - _ jpr woaly has iw ttaa. ❑ tirwar iN � w dw b=b of fa- Ib - 3r cciiwee to he the pefww www ttrtatye ' ssttsac to this instrttexwt as the r&�atopprlwv ill fact d_ �1►� �p�1�+� JRA= COMM and io M duw j M o tar svkmM ed the xww al .1 i[ltL .[ Fit%_ 313���m�scria. SNJaI� t7e7 _� iMrlW is owe r. baba• ❑ km w* -up as onarrw r in fact. IN Wt7TiM VMEMEGuF. t how hertttwto set my hand wQ &Mscd my ofk-W is the day awd year s!atad iw this cvstAcafe abewc. Qi f tttAl St 4i: Musa Lu;sa R. AlukaW"IART KNUC-MOOWAT 4011wy --- Piitt#C-.PAL Oft'wL" M E}RAttff COUNTY My corrarus"on c=rireig ttTt Cm1:iSvm "InsfS f". 26. 1901 SO@~-. a 4a Iyaiaair • • aM raraMutlrA Msu ` . • �•. MR • •.1> y.a'r •r.* try �Mw�%M M�WfWti fta~ �. • .......M.YI Miit�. »� ���IM�'h Mi�f�rllrM awes Stowe w ►e"ft " s.tre+e"la DUPLICATE -ORIGINAL sand No SCR 709 8245" APPPOVF•D AS TO FORK: KNOW ALL baN BY TIMSE MOO MS: GALL HUTTON, City AttOMOY JOW L. MEEK CONSTRIXTIONB&JP &ty City Attorney, tr hitral�.d, EjkLIFMIA ewCALIFOR ial A� ore 1rw at irf #krwr •� _ r,..a►nd ewdwus d 1► dt+ • uwatT le tila irtla �......�..�.- ........ a. 54"rr, all bow and hmify bound agile be MY TY ix it, T_ l"jTQ___r1 KM....,..�..�. �..�....�.._,.,.. to M $us FOTY_ FOUR MUNDIMED AMNO/i00TMS---------- _.._...�-.....,._�.�....�.-,.�_..�ii 1III�►y�.�0_..�. at err UW*d 3M t of Assn a. !a dw ralrsant of wltidt WAS waD asrd W%ft 10 be 00". wM bW water hoL aw bobs. osom are, adntlrMwator*. fuaceeows and aai gra. Wnt3T and ""gimpy. Errol bt tlrarre f omou SMED with our ovok and dated thfa...-_ S E P T E M B F R 2 8, 1 9 8 7 WHEAELS. on die SEPTEMER 10, 1986 so New J" L, WEE CMTRj9:j IONS WAVY a wntmc . enw ed into a contract ia. REPAIR OF STMi D►*"E TO THE M.)hl! C 1 PAL PIER kv fbe sum a, Off Fi ORED FIFTY C I G*ff Trf0U5A O EIGHT ► gftp SISTY EIGlff &D lfiigal �S 4--W4262_ 1sb ). and. _ %VHEAEAS, µndw tine ►erfae of tic► "aficat,ors for paid wcrl Ow owd J" L • MEEK CONSTRi1CT ION COWANY tr Mqubod to tp*► a bond ix ONE HJORED FORTY FOUR THCXWM. EGM tU RM AM 01100IMSmu■= _J. to prowel dw _101M t so mule of faulty wawncfk w wartmarslsrp iar a pe-lod of awe yo= host and atw dw deft al 60 e—phroon asrd aec pkoft ai asaa, NOW. THERITCHtE. u ow pa—J" L. WEK COIS1 RUCT IM COWA N1Y b a penod el on* rues kar card altar #b* do* el aw aaapkhen and acceptance of same dy REACH - - - _ ....__,._ —japfiaw any aad ale delecu wu.nd If. aa.d wark whothe-. m ifunp hoc defect*► Maw sou Of M!er:t++! aatssawdCo. own ow @bow* ablr4aUn M be acrid viw-►wt to rvLa:ri ir hub krrs and of on w &40017-..A." JOM L. FLEK CONSTRUCT109 C0~ T. r"4/0 F I RM4' S FIFA IMURANCE CO PPAW CA a MY, -14 FACT _— -,. .... I— I.., .... ... .--.,, . ... i..: =z .. 1� • • F? ~ MAWS FM 1?G3URAWE �Y Kftit)M ALL MLA $V TWK MLW%-n: Tit l FIRI 110%N-S FUND INSURANCE COMPANY. a of ft(etattaft �1) Cerprit"d and enlstW4 un&f the late% of Iflt Sett of Caflf0mia a-101sa.int lit► plrncylal offlct in the Coll, and Count) o1 San Fraticluo. M t,atd S1atf. has Rwk Consllluted 24J appvinted Mild does iII) loose presorts r4kc tttnwnulf ind awtnl -----C. E. FREY----- tee true and laic ful AlIcrne)ts) in Fart. Mill" full PCt*•tt SOW authorit) hatter, conferred in tit name place and stead. 10 taecwr sea' a(int,aledge art.4 deli\et ar) and art bonds undNlakInp ttcrihrranrft of other urltitrt ON11,61'Orm In little nature Ihtrrof -- +r •--�-• ►. r-�.� --- and I(` INtfd the Corpmatlott thelell) a% ful;t and It• the mint t\ttrti as If %WCh t"'. uric tt#rMd 1+) fill P1e\ident. Kakd etllh the eoeporate seal of the Cofpowimcn and du) attested t) it- Strrelat) httrP) ratifying and confirming all that the mod Alto"wipiti-in Facl tna) do in the ptent,tt\ This powet of atiorM) it granted pursuant to Arl1:K 1'lll. Section X1 and I I of Ry ta• to of FiREMAIN S FU%D iwSL'RAtiC•E CO%tIPANY n.,t• in full fcxct and Corn -Atn:ot %Ill. Aph'tr►men. anJ Aur1h'rt•t 4..1.1int or,Pr►a',r, anJ Atr.•rni t 1r, I a. i and 41fnr• rna.trpr f tral Pto.r.. and %fair 41p+ra,in.r• Serttlon 10. 4rN-sr.mrr: Tt'r ( to *r-jr- 4•1 it Board C' Moe. tilt 1►tt P,r•idtn' an. %t.t P•r•dtnl let an' (,lhtr I•f►%rf, au•AJ'uc: 1`6 Il•t dtiird 1i1 ❑t1t►It" I. The lhaitrr:a1. 0 1he B.'r.! of Oof. l:.'. It,( Pit Ili (n1 C. ar, %1.e P1evitfI efI. iIPlr. IMe IC, IIP,r arr''stRi Ae'alrnt A--iarr St.#rivoi- an: *tirtf►e)t•in Fs:1 .: rtjre•1-- ar: A., fn• Ind of t't�a" �' IN ( o-rc •a,tpn ar,: Alt111• It' a.tfr'I ieiii r,t.►•• are Rile In• it'll t+r t,thaa . ,,the Corretatlor St.1--1 11. 4ulhc'r:'t It Aii1t•t -,..t i,f•..'tr, A...tart St. or, /•tr. r,•, rrt., t^ Ia, and asrr•..Ib!: t•+ a' floc..-rej .- the e,tdfe:iti tl,t • srr-r men, a^,' a'.. I...• a r.eler, and a" a...,., . i•a' t: 1krttr er.a. t•t stilt: a' al 11n., t. The isOa'J or U.t;..1•t. t.. r. an. pet►on rrrl, r. ere: In mast tu: • ar?('in' m1 r T1+ls +.el of ancttnee i• it nee and sealyd unlit' and FI Iht atlhr,ty P! tht follot,on$ RettelulKen adopted t,} tM tloardof DatCtotto! rip Ftt14oN S F1'I- lNSL•R�1tiC[ CO% PAtii al a meellri d,,l, Ca•IrC an; held nr the felt da! of lull 11aM and •.-a=d Af%-4uIKw sue f.nt Alen smenJrd elf rtptakd RESOLVF-D It4; Iht t,gnalwe of art %,.t P/re,der, A.t,tla,t' Soctria,t a'•.: Rr,.,Jtf%t Aetitirnl Swels-% rf tht• 0wIlor-stun. and the \tal rl ih,. Cc»r-si3Or rr:;,t Its aI'litiled of p•tnied or. at+, i-'t.r, (if a'!it•r'ft iif, a-t ret/1al•:•^ of ant rv"'C' of a110thtt e•- t•tt art ill0Catf rtlattn= Ihetelll I'% fatsltntit and Jett pouet Of alarm, 81 'f t,t.a' ✓• t�• •^t It'-er c'f a't^-r•e, h' (elli/t;alf hta►.'s tuCt fa,%chile Upatytf of Ia:"*It{t \eat \hull K \all« ane t, ndlrg uTv- the C*c-;%r*al..'- 1% % iT%LCAS %k HI R I OF FIRI %14% S f t `ti► 1\S; ii +(til i ( nw a %1 hot. . o.•re ihc%c rte•en!. I,, h %.gro *e its vke f4te.4t^, a't: it•.t+tr•••a t try' 1- Pt yr•r.r r I11,trJ • lrjj. - _. ..._ ;•- • -- 1,. —Al- U. f IRf bit Aet, 5 Ft *%D I'l.SI k AM F C7NP4%1 P _ __ t Or tt t 3rd da' of -Au .,! t_ 1� 1 fc'. r r r r,tr`•`ral' Richard Vi 11 is-s IC rtf Irp•r. shc• pet.il !' Mt Ct', J•: Jr-'. -f t•.: 'a, t.a •r 1..r f' r•.,tr r' (IRf \I%♦ el I %0 IVIt lit 4%(i: t eNi{'A�1 t, t r('ta•t(`• de,:'it'fC cr an: tt t,;t fell. rtC t*. sr: f .I,. •.nfr t•a 'i 6' ... 10• .ta rt .at: ( o,r.••a ,.'r ita iht Ka' s'',et t• 0l y i• •' J 1' I.1:1 (orr!'•a•e efa'.1t.a''! at, e. a, .f: r C•:r, (`. Inc ltCa•: "1)'1 , .a .• t (.. ..i, tic i••..11hJ' it -INt: 0—t.4"`. i• t•,:t� I", ttl I1\FSS M HE NEC%f 1 !.a.t 1rr_ r ►a►: a•: )'' 'f! - 't a •Ch •Lr dl. a-: •fl• l'ftr• if -•r+t, t.Mta+�t+Ie�IaaaMnrsNetttNNllttlNflaawt , OFFICIAL SEAL ,a 10TUT P= - (A"M tit" a cow v 0 WA Ir4A."D Mt Cr*t•"tt-o- Fees+ ts. 17 Iola ('t R.TIFI( ♦Tt IS'F An Olt C A angst 4. CM 4"CO N-n OF S4A FSA%CPA 01 ~ 1. File wrt4i1►Igned Rrvden atel-•ta+ s4oll's•• o' 11111MIA S It "el.) I%SI ItA"1'Ct (()%IP4%1. a CALIFOR%14 Ce•r`•a'�.• Cltl NLRI h: CERTIFi rta! the (COCI:++n` ar..' a'1a:ht: P(lv t R r%I AY10111M 1 It"Am. In full fP•.r a�C ha, nCl leftr letoted. ar►d (u'1►ttR t it.,). At..,lr % i17. Sr;t,ra }0l an. )t of the 1 iaa' 01 ihr ( 01rotat int. anj It,.t Rt.t''rill. PI the Board of i),tr.iott ter Wilt to the 1''oulif 0 4•tt'ttr, a•r n0v Io►: t Still: and halt: it the C 11) and C04.-', 01 U- IIa"i".0 Dated Iht _ j ,,._ do of Ill U - �.-...... -..... Rl.,rt*, 4tew+(Frt t1+t.tetate� >1 ri l.lrt lit" ' ENDO MWENT w This End0MmeM, Nlee hm DECEKBER 17, 1986 (12fl1 s.rM. sHu► 0(d h""). k rfw a Pert Of Poky I rOL 0 9 2 7 5 Immnd To: JOHN L . MEEK CONSTRUCTION CO. , fly: ILLINOIS INSURANCE EXCHANGE INC. The paragraphs marked "yes" below apply to such :r_sureince as is afforded by this policy. A. B. [ x) yam, t ] no. ADDITIOM r_ VJM: Subject to all its terms, conditions mid wxJor ts, such insurance as Is afforded by the policy shall. also apply to the following entity as an additional insured but only as respects liability arising free (1) pre dwA owned by or occupied by the Named Insured, (2) the contract entered into by the Nwed Insured, or (3) the work or business activities perforned by or for the Named Lzsur©d as specified under 'as respects" below. Additional Insured E ntitV City of Huntington reach Ins, & bon. Office P.O. Box 190 'Huntington Beach, CA 92648 f ) yes, [X) no. CATION: As ReS, All operations insured. of the named Any policy condit-.ion or agreement relating to cancellation (Paragraph A. of C>~mnon Policy Conditions 1CSI10, Condition 11 of Camm Policy Tans, Clausem and Conditions 1 CSI07 and wherever found a tw-re else in the policy) is deleted in its entirety and the follming cWliess instead: This policy my only be cancelled by the moved Insured by ,,,sailing to the Cccpany or its representatives and to the additional insured ,sham in A above, written notice stating not less K: a—n days U'wxesafter such cancellation shall be effective. Ms poHiij my only be cnanop l led by the CamWy by ssrmi 1 ing to the Hared Insured at the address shown in this policy and to the additional insured shown in A abowe written notice stating m— not Mis days to such cancellation shall be effective, the n+r� ^0 nno�t.ice as aforesaid sha I l be suf f 3 cient prroof of notice. The effective date and hour of cancellation ztated in the notice "11 beowe the end of the policy period. Delivery, with remipt, of such wr: tten ncytic es either by the Named In surr'd or by the Ccsspany shall be equivalent to mailing. If the N nxl Lisurvd cancela, earned prssaniun shall oe ccn;Futesd in accordance with the cost nary shirt rate table arxi procmchue. If the Cw;auny ceuxxls, eanxvJ pernium shill be ccnputed pro rate, prw4um ad juuxtnnit may be vade either at the time cancellation is effected or as sswi as practicable after cancells.tim beoanm effective, but paywenr or texuder of mearnad pewdua i,-s nnct a amlition of auxellation. All oViet terms sod condrlw* of the Pc4+cy r0m4n unthaneed En"i mrwo • 21 " t of 2 sj 4/22/67 CS142-I/06 r1 Additional Insure i The Nwed Insured understands that this notice of cancellation clause. my hx in conflict with any premium finance agreements signed or irteetidec' to be signed but that as respects this ;olicy's terms, Agri ltso conditions and cov+era", this clause shall ly,-evail. C. ( id yea, ( l no. W IVER cr SuaFW.%;L orN: In the event of any payment under this policy, the C7agwy shall have no rights of recovery therefor against the Additional insured named in A ahvve. D. ( A yes, ( l no. i�►, ATION: Any Pali-.y eondit on or aft relating to cancellation (P'aragr%*, A. of Comm Policy Conditions 4CSI10, CcrAition :1 of Com on Policy 41ems, Clauses and O rditions i CSI07 and wherever found anywhere else in fhe policy) is deleted in its entirety and the following applies instead: This policy may be canarlled by the Naved Insured by r+al Ling to the Ccapany or its representatives wrri tten notice stating when thereafter such cancellation shall be effective. This policy may only be cancelled by the Ccupany by mailing to the Need Insured at the address steam in this policy and to the _additional_ insured shown _ in A a<bme, written notice stating when not less than t h 1t — (3o) days tbexeaf tex such cmxmI lation thill be effective, the wiling of notice as aforesaid stall be sufficient proof of notice. The effective date and hour of car>c+ellation stated in the notice Whall becamethae end of the policy period. Delivery, with zeaeipt, of such written notices either by the Nwed Insured or by the Cmpany shall be equivalent to mailing. If the Named 'Insured cwvaels, earned premium shall be oagst,ed in accordance with the customary short rate table and Sumdure. If the Cagxny canals, earned pervaun stall be owputed pro rats, pressciuss ad juuctment may be :wade either at the time cancellation is effected or as soon as practicable after cancellation bevy effective, but payment or tender of uneoxned premium is not a condition of cancellation. The Nm ned Insured urderst,an s that tkda notice of cancellation clause way be in conflict wi Cl any premium f in,wce its sigrmd or intandad to to signed but that as respecte this policy's terva, sgreeaa - , conditions and enwrmm this clause shall nrevv f l . 9 r 0 0-0 �;-i4qPOW - AWNWOrw%P w Page 2 of 2 aviorwmmt 1 21 Policy 1 DCL 09275 C8I42-1/86 City of Huntington Beach Department of Public works P.O. Box 190 Huntington Beach, California 92648 Attention: Subject: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Gentlemen: The undersigned, contractor on CC707 Municipal Pier Repairs �� 7cr ect N � 'ltT, e hereby certifies that all laborers, mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor perform- ing work under the contract on the project have been paid wages at rates not less than those required by the contract: provisions, and that the work performed by each such laborer, mechanic, apprentice or trainee conformed to the classifications set forth in the contract or training program provisions applicable to the wage rate paid. i Signature and Title JONN L. MEEK CONSTRUCTION CO., INC. no wit "C" stOrn JAM L most nuw rrt�rr Nor+. Grow" "w" 0 am Nowm . norm City of Huntington Beach Department of Public Works 11. 0. Box 190 Huntington Beach, CA 92646 Gentlemen: The undersigned, contractor on CC707 Municipal Pier Repairs Project No. Title hereby certifies that all wage] and invoices for the above project have been paid i� full, for labor, materials and equipment. ignature ►` Title President 0 )PULSTID 02Vra RECORDED 14A I L TO :q--�T U 7n 7 0 Y Of HUNTIN TON HEACH 001we of the City Ck-tk P.0.8" 1W Hauntinvion Beech. Caht. 9264P NOTICE IS HEREBY GIVEN that 875:-325267, [1-4tt" �- -3 i � PM Jill 9,87 NOTICE OF COMPLETION «4 the contract hcretofore awarded by the City Council of the City of Huntington Beach, California to JQHN.L. MEEK, 1032 West "C" Street Wilming ilifAi:nia 9Q744 who was the company thereon for doing the following work to -wit: Structural Repair of the Municipal Pier, Project CC-707, in the City of Huntington Beach, Project CC-707. That said work was completed by said company according to plans and specifications and to the satisfaction of tht City Engineer of the City of Huntington Beach and that said work was accepted by the City Council of the City of Huntington Beach .at a regular meeting thereof held on June 1,_1997 That upon said contract the FIREMANS FUND INSURANCL COMPANY was surety for the bond given by the said company as required by law. Dated at Huntington Beach, California, this 2nd STATE OF CALIFORNIA ) County of Orange ) ss: City of Huntington Beach ) day of June 19 07. LUCIA U. YIBD�QM � -city Clerk and ex-cfficG e—F of the City Council of the City of Huntington Beach, California r. I, ALICIA M. WENTWORTH, the duly elected and qualified City Clerk and ex-officio Clerk of the City Council of the City of Huntington Beech, California do hereby certify under penalty of per -jury, that the foregoing NOTICE or COMPLETION is true and correct, and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Orange County by ia!id City Council. Dated at Huntington Beach, California, this 2nd day of June—`—, 19 87. ThAs dovvmatt is soltlt► tar the •t'fiatal busift6as of •.fit CS%Y wL' MWtin!teo 4"Ch, At @onto** /:laud +err "werawat Co w ',Gt+la. 6100 and alrtnld bt r*cerdod ALIM M. li'Lt4IlAiaUTH City`MR "i6a— o ff i c-io`-Clerk of the City Council Cf tht: City of ntingtoii Beach. Cal i fornir may. !. �j` ." a j i • � CC-7n7 iNif:i RF.CUk:fED WAIL� i tarV IN' HUMTIRWOfi �H X�aIPi C,1 OK" of ohr CWy i tr+k C � P. (1. Powt 190 67-3252V W ' NOTICE OF COWL£jION y NOTICE IS NIREBY GIViN that the contrbct heretofore awarded by the City Council of n the City of Huntington Beach, California to _ JQ}MA. g K�,1032 West 'C' Street_. who way the company thereon for doing the following ►nrk to -wit: Structural Repair of the Nuniclpai Pier, Project CC-:37, in the City of i;i�rtingto+i lia ach, Project CC-707. -3 r io Phi &W 4 `87 That said war► was completed by sat(: co.i)ary sct.or6in7 to plans ins! Specifications and to tho satisfaction of the Cliy Engineer cif the C4ty rLjf Bract+ it. -I that said wort was accrpte•i }�y the City Council of the City :if runtington Peach it a regular noeting therp,,f held on ,,!u,�;� 1� that upon sett c^r,trdrt tt,o rlpjv.vj� r!+`•t' 111'i'::tiri f+2`"`Apr w s, surety for Ve bond given b., 0,1,r+ :old ccV'113n; At rr-ry•tirrtd by lam. Wed at Huntington Beach, California, this Zr.d day of .%ine _. 6 19 87.. ty C1rr a e�-o tic�io ..leri of the City Council of the City of45 ;iwn;lr,yl�rr fitia[h. .a{ilnrnla STATE Of CA11FJ;NIA i County of Orar,e 3 st City of Huntington Beach } 1, ALICIA N. HENTiJ ATH. the duly elected and quaitfiai t'ity Cirri eni w►K-officin C : c r k cf t1.v City :,w.rrl of ire City of ,luntingturr tivakh, LAii.or•n}a do hprtOy certify under penalty of perjury, that the foregoing MICE OF COWLS T10N is true and correct. and that said NOTICE OF CWLET1014 was duly and regularly ordered to be recorded in the Office of the County Recorder of Orang* County by said City Council. Rated at Huntington Beach, California. this 2nd _.—day of ­ :one ___. 19 87. Me &*80" rt It solely for the •rtlelal ►"froes or the ettt of AW►ttnotaM 9"Ch. its H*too- plerted WV"? O orsty rNrt CMt we. 6193 Md aMrl� lrw ri++t Pr++ nr glow»Nr. Al K1A Y ti;F1M`�ttN of thw city Council Of the City of tir►gion DQ4Ch, California RE.OULt FOR CiTY COON ACTION Submitted to: F,ionorable Mayor and City Council Submitted by: Charles W. Thompson, City Administrato4? Iy r C() ~:C;. Piered by: P4�ul E. Cook, nirtictor of Public Wnr4s �i APY nti'ED D Lt'rY rp Sub*l: Municipal Pier Repairs; CC-707 Consistent with Council Policy? [I y" I (;ITt.1 Fl it14,�._ I Now Policy or ExcepSon Statement of luw. Rwoommendation, Analysis, Funding Source, Alter M6" Auliom, Attmd4nents: iW Staternent of lsige: John L. Meek Construction hag completed ttv- stmetunil repair- of trr uir!r. Recommendation-. 1. Accept the, irnnmivi•rn"nts and i-it► iri7e the City Clerk to file the- t+'Aire of r-ompletion. 2. Authorize! the i..)irretnr of Finanve to t.ninsfor a total of $?'5W.30 from fiscal account 486447 (t.Liint-nttvrr) to the prolr•rt arrnunt as rrrniirrd to cover project inr.ihentai expr+nrlrtitr-s. The winter storn of Frt;ruaiv 1, 1 nHr, (timaged ttv! srx)t)nrt wid ferider pilinrla at the- end of the: Municipal Fier. Theses +;lirtis had to tiro reo nir' l to ri-mintnin the stni tural integrity of the t)ier siippnrtirvt the Cafe. Them-fnrn, on 1u1v 21, 1986, Courril awaMre' n coniract, for thes+! repaim, tc Jorin L. Meek (7-on-tnlrtion. The- construction of these repairs, per the. approved plans/acvecif icatiomi, is now cornplr-te and ttvirefnre, ttv, Director of Public Work3 revornme,rxis ar.reptancr, of t►kl pmlect and rf-rntests that the Wtic�- of Contfle.tion tv- filela by Or- City Clerk. The followiml is a surrtrtcriry of cnntrnr_t costs: i-n unr. i l A pprt)ve d Contract Amount j 144,40W10 Construction Cnntimenriees (Cliancie• (W. prg) 1.) incidentnli (project expenses other than these pe.ld to contractor) 2.) 7,500.00 Totals S i 67,n90.00 no Wn Actual Expenditure 14.4,400.00 14, 460.10 179504.99 1176,373.15 00Pk Request for Council Action Municipal Pier Repairs; CC-707 May 18, 1987 Page 2 I. Per resolution, the Director of Public Works is authorized to spend up to 10% of the contract amount, not to exceed $50,000, for construction change orrim. Because of the many unknowns In pier repair, staf f anticipated that the cost of change orders could exceed the 10% amount of $149440; therefore, the Directnr of Public Works requested the approval of $15,190.00. Final construction change orders, I istod below, did exceed I U% of the rontract nrnount but were less than anticipated. Construction Change Orders included installing supporting members between three replacement finder piles ($1,240.011), and reniovinq/reolncinq existing braces under the pier as required for instnlltion of new strtrctural beams ($1 3,228.16). It r;hould be noted that the coat of removirrl/repiracinq the braces could have been averted if the braces had been properly installed under contract work previously performed by art. Hrorn:ans General Engineerinq Contractor. The r"ity is tnkinrl motion agninst ttx+ warranty band posted by Art Broman. 2.) Proiect 'Incidentals" (expenses nt1w?r than tense paid to Ox- cnntractor) totraled $17,504.99. $7,500 wras pecificnily !)udgeted for the rr-pnir of da nmged sitility conduits, however; actual costs totaled M0,729.99. In addition, sprcialized incprction ancf engineering services-irnotinted Gi 96,775.(l(L Adequate unencumbered funds are availsable in fiscal raccotrnt 486447 (Ninint./Other); ttwre.forr., the Director of Public Works rrouests th?t the Director of Finance he authorized to transfer a total of $9,500 from this fiscal arco►sit into the prr►j,!,:t account 4H6637 'improvements/Pier, Struc.) FundiM Source: Funds off $107,090.00 were transferred from Ow- sxiappropriated Grfivral Ftnd balance to cover the Counril approved rupenditsrrr.r.. o:n nddittonal S9.1"")(1(l(I0 will be trrrrsferreri fmrn fiscal nccnsrit 486447 (Niaint./Ottier). Alternative Actions: Dery nnornvFal to transfer additior.�,l fsrnd,; into trrzject txidnet fnim fiscal acvount 466447 and obtain nerritd r-vr4it.rsNa fro-ii ar.nthor iourre. Attachments: None. CW T:PEC:0R,+.iw 124 5q 04 s 0 . CITY 1"11,.�1'1�'1 INLo'°i-C 'V � �►► '' 200D MAIN STREET CALIFORNIA OFFICE OF THE CITY CLIRR Septarber 10, 1986 John L. Meek Construction Co:, Inc. 1032 W. "C" Street Wilmington, CA 90744 RE: Structural Repair of the Municipal Pier - CC-707 Enclosed is your bid bond, a copy of the executed contract with the City of Huntington &each and a Certificate of Cos:pliance form. The Compliance Form must be signed at the completion of work, and returned to this office. In addition, the following items must also be on file, with this office, before the City care release any retention funds. 1. A warranty bond guaranteeing T.he final amount of work and mterials for one year. If your perfoi,,+aance bond does not include specific wordi;rg for a one year warra:ty, then a ridor or separate bond must be submitted. 2. Pm affidavit stating that all workmen and persons employed, all firms supplying materials, and all subcontractors have been paid in full and that there are no outstanding claims against this project. Should you have any questions or concerns regarding the enclosures or items that must be an file in this office prior to release of retention funds, please call Don 14oble, Contract Administrator, 536-5441. Alicia M. Wentvorth Ci ty Clerk AMW: bt CC: Don Nrble,, Public Works Wpt. Enclosures: did Bond Cash Contract Certificate of Cbsoliance ffdq* W: TI640MVl 'a, CITY Off' ' LXYTI�'''N ""�'" 1! � "� MAIN 3TREEi' CALIFORNIAWOS OFFICE OF TM CITY CLERK September 10, 1986 Coviolly-Pacific Co. 1925 water Street Long Beach, CA 90802 We are returning -your Bid Bond which was submitted with your proposal for repair of Municipal Pier, Project CC-707, in the City of h.»ntington Beach. The contract for this job was awarded to John L. Meei of Long Beach. We would like to take this opportunity to thank you for your interest in submitting a proposal. Alicia M. Wentworth City Clerk AMW:bt Enclosure REQU FOR CITY (00UN A ACT N &Awwined ft: Honorable Mayor and City Couwcli �.. " by: Charles W. Thompson, City Administrator ('��� by: Paul V. Cook, Director of Public Works-....� �ULt,�•C: $yet: Munletpal Pier Repairs; CC-707 cmwi twt with coursdi Pollky r F) yea (I New Policy or Exawtkm Stnwtwnt of luud. Recom ion. Anelysa, Funding Source. Aftwm ive Actiottt, Att�t:lmmats: �,'l STATCMENT OF ISSUE: 01d, for the repair of the Municipal Pier were raceired on July 6, 986 and J fly 10, 1966. RE^OMMENDED ACTION., 1. Approve the low bid submitted by John L. Meek, for structural repairs, and 2athorl7e the Mayor and the City Clerk to execute an appropriate contract In the amount of $144,400.00. Z. Authorize staff to Issue a $7,500 Purchase Ord-tr to Cal West Electric for regal► of the utility conduits. 3. Direct staff to transfer $167,090 from the unappropriated General Fund balance. ANALYSIS: The winter storm of February 1, 1986 tiama ji�d the support and fender pilings at the and of the Municipal Piar. These pilings must be repaired to mainta.r. ti'ie viructural Integrity of the pier. Therefore, on June 16, 1985, stair solicited bias for the repair of the pier. kids as summarized below wire iacelred and opened on July A, 1986: Contractor laid Amount John L. Mock $1440400.00 Connolly - Pacific Co. SI47,000.00 lit addition to the piling repniri., damaged utility coodults roust also be replaced. On July 10, 1986 staff' obtained a bid of $7,500 from Cal -West Electric for this work. The combine.! cove of there repairs plus construction continligncles Is as follnark: Item Amount Structural Ropalrs of Pier Ijo*tn L. Meek) $1440400.00 Utlll4y Con4ult Repairs (Cal -West Electric) 7.S00.00 PWII SM A Construction Contingencies Subtotal Total Costs 40, $ l s 1, 900.00 1 5' 190so Staff has reviewed these bid proposals and recotnenends the acc4ptance of the Jahn L. Meek and Cal —West Electric bids. Funding Source: Funds of $167,090 must be transferred from the unappropriated General Fund balance to cover these Initial costs. Staff has filed a claim for these rusts with she boosding company representing Art Braman General Englneerlag Contractor. Alternative .Action: 1. Delay repairs of pier until monies are obtained from bonding company and thereby run the risk of additional structural damage. 2. Close down the end of pier, Including the r*staurant, to lessen potsibl(lty of additional structural damage until bonding monies ere obtained. A`rTACHMENTS: F .I.S. A FISCAL IMPACT STATEMENT MUNICIPAL PIER REPAIRS 1. Budget Status This project is uobudgeted. It is the result of unanticipated storm damage. 2. Total Costs a. direct: $167,090.00 as a one time expenditure from th(e General Fund. b . Indirect: Lose; of: earnings in these funds. 3. Fund i ncj Source a. Funds: General funds on deposit in Account A .101 (fund balanrei for transfer into expenditure account 06C37. b. Revenue Source: General Funds c. Alternative Fundinq Sources: None d. History: General funds have normally been used for this purpose in the past. . �� r � � � � �� ", - 1 � .. J.# i r � � � n � _ � � .+ .. � , - .. .... wM..' ...... ..• r..i.- .�.w. rNv. r..r.... �.. ..� ryY1N Ia 1, ^.i. � DATE: Jules 8, ..,1985� .... ENGINEER'S ESTIMATE: 25K JOB AND CC NUMBER: Pier M3aire; (.C-707 BIDDERS NAME TOTAL BID AMOUNT 1. oonnnllxPacifis 2. T`astener (briporation of W22 Beach 3. !%aly Tibbi is o ms trurtion C `Yv 4. J . L. .Seeks Gxu tiucti.on AY Y/ 4141 5. W. W. St, enson ESvpE , inwrporated Avt--- 19C '' Pit l /" Ac.wl s•^,an'1 ' al •.ntl1 ,nth.tl, puD+-c Ce, ic" a ti. -tr a �; 's ,s •, : y S•c'••^o•' +9t ` • A :49?' :a+mac " ...^• •see! S-A'E CF CAL,;:,-)taNiA a— a . t ze— -, ,)e ,h teC States and a •eslaent of t-,e a►; resa'C a- Cve► he age of eighteen ►ears anC ^oi a carir to or •nte►estec in the betow er't:vec —a!w air a :'err nt the -Orange _CaS' ^,AIL. P�L: �,tr, +►P Ct" S :�mC,r+pd +!)e NE.Nc.caESS a ^e*waver ,t yer�era Z,•cjtat,er ^•eC a s^e: •*,r 'r :osia Mesa 'a -ye S,arp --a ar-f: "la, a r ,-p -r.va Yesa •.ewC�•• Heac^ .,�..,^y'� 9ea�r=...'-ta,� .a�t� . ^e '• e S: �'^ � :ar>' _�,-.�L^ ''es arc _ag..�a Sea,:- ss, et sa j^R`.►r�. a: P• ;. I M:.. .c�se~:-t .e *eve 5 17 w ' '^e 4s. ft% �► �;e •ya oec!are ircer ;,ena!ty of ;�er;ury that the foreg3onr s true and correct Executed on 98 '. at Costa Mesa Caiifofma mf 1 Nu II0"m I 1' x Ow I! INS NOTME M WMQ SWALM SM O -7w Nowe fa h wept qww so Ow Clay Counts of slit Car M Mlw+a�r+�Mn 6";:h. Caaflarnia 040 -*Woe MaNd hiilit kw to Pow- Mefpq* M WOO CIP, ar Hurtl ogton I oso. O+tttt amia it a000rftW OM ilia pN" woIda umIpaNM1A t tad special ot*v M tv on ft to to 90m of UM OwwOw v1 roc Miorft< I re��J�tx WO be t� .a daWks an Am a / OW400 neC?fal� s s $ aaG # Mn not i drovAngtt. lrwtit Nissan tiwAflt►► litpo of PC+r►r a" i.wnp MMM On Ac=danao Wtth the PtPVWrotV of SOLO t 1773 of ttfw tab& Ccws. tM state of Camornia. Dw4elta of arse Otoat'lr mm" of rwairw Rack to w" date "WO tt» 0•r Mp w pr*Awwtale of "O"d. p so so � W be der». uapinrs d the bisat qVaral trap ►ate drarrr+NMOW t art an AM N 1M Offim of the Clty Caen arw 00 aff" of "w or+r W a f`y*ft w"ra of M Cay o4 l'for✓ZI-vton ifi"d Gftaio nw. Pwns " wpooftaks6c a. kvwv r waft WOPO l tenth, ffty be coww" " all the a'hca of 00 f Wnlor of Pubic¢ WnrU. City IUA, HvnVnVWn tfaodt Coufa'r161t No bW ww a rove"W t+ *" it to rr+adla on a We kwm fwtrfW" by VW tavettsr csf Pubk Watts. The spaW Nfer on of piresp o" MltMifatts is cased to un propoew r*4wltlfM xft "A h lh b1 wo aflwftoa 1M. IMr suit d+rWAV, 1s " to tra bxk" The abatis O"taliw are le only. IN" aY a bllaie shot ON "Wroirl"n of tAm. arw Ow CRY of ► k:mvgn U a i th own rm" aagms of by r.VUWA" agree "so we acbm arnau"t G trust we aptret vama a wvwnh l3•it m r'"ra "m rwd to Im i It or dMOryMY goaffAftwlf of am 011e it pataton at lt+e , sa rnt1 d trrt,4 ,wroaWy at as= K by situ Oweta of P%bat Wortcs. An fa-. i will be covowed an trr bath! of 04 Owwtfw of Pwbric WofU tntrrts;a of the man~ el tiros to bt dern Substitution of owwoise IV any Ilow au w+lfMby ale] Cary to N with performance V%mR be pafn>~tlas to acyco trace oftpropwo�re of ra Costar" Govw.vtw 1 t.GOa. iecwr► 4390. EKh bid VON bo macko trill t o a loml to be Welded at +ire aAflria id Ow Darecta a piton Wags. 7utNip wll tfrvlc I" Mom flares k teed+. CaasorrAL satiett be now and Owed waltz; wo CRY CaarA NNo Canto. Second Fk*t Adnwi+Mry Nor/ . O tketn *Owt, "uoftgW a,tdaehCwlorrAs. on or belom @ Oo 111 MN-4w and shuts be "W" by a oot+w,ltWe compowed at the City C A&*. We Ctly AAOtt%V WW VvgO ar of Put'k WO(Ila of vow alAtlow wad tweleinfe" afld ilti 16610111141 of No h•c",Owrp wit be - em wtf 1n arts at> " Up" O* C4v caom" of mod Cm, N ►*In11twl - tNa let ffta+r /ir1aa► rnwlM+� Mr tread M No lMr, fM 21iq car r! ,l. 'w. el Ow Hoar 01j l:iG t kl. In tfwr C" ti'+a�rlrm okwmmm in *0 C.v c Car"w of atoll Cny of Vbr+rwy/en @*@a, wo ItMN be acts upon btr arc C•tty CorenGM a1 ttte rec�rMr trtaollrq a ,fuly � f. t� The C41ty of 1Mlnbrtip on Macs+. Caltf w"M fialrsrtlata w "wr�1 •+w w abi s ro, WW Ito WOW Ws Mid dtiaOW Mir "m Mat WA~ M M Cf>w of Ilunw rn a so Cawarnm F+Ifwry of go Cif► Comm* a l Nos Cfr of t+Itmlw qWi tfilafwt. C ofto a tilts i w+. W80htulla Cft 01" p►lewtrird Of"" CO" DOW PWot Jura ". A* M. on frw+lr f NOTICE INVITING SEALED BIOS CC-707 Notice Is hereby given that the City Co:meil of the City of Huntingicr-. Beach, California will receive sealed bids for the Pier Reps in tho City of Himtingtor. Bench, California in accordance with the plans and specifications and special provisions on fi:a in the office of the Director of Publi^ Works. Documents will be available on June 1 & 198& A change of $10.00 not tefundable, will be required for each set of specifications arKi�accornp6nyi ng rTr n'gl. DIRECTOR OF PUBLIC'NORKS ESTIMATE Work Itern Repair of Existing Pony Bents 2urriti: Lump Burn In accordance with, the ptovisions of Section 1773 of the Labor Code, the State of California, Director of the Department of Industrial Relations shall determiner the general prevailing rate of wages, applicable to the work to be done; copies of the latest genaral wage rate determinations are on file at the office. of the City Cleric and the office of the Director of Public Wortcs of the City of �-iuntington Bench. California. Plum and specifications, together with proposal form, may be obtained at the office of the Director of Public Works, City !-salt, ►-tintington Beach, California. No bid will be .eceivtd unless it is made on a blank form futnighed by the Director of Public Works. The special attention of prosciective bidders is called to `her proposal requirements„ set forth in the specifications, far full directions as to the b;ddin I. The above quantities are approximate only, being given as a basis for the comparison of bide. and the City of Huntington Beach does nht express or by implications agree that the actual amount of work will correspond therewith tut reserves the right to increase or decrease the amount of any class or portirn of the work, as may be deertcwd necessary or expedient by the Director of Public Works. All bids will be comoared on the basis of the Oin.-tor of Public Works estimate of the quantities of work to be done. Suhstitution of securities for any monies withheld by the City to insure performance shalt be permitted in accordance with provisions of the California Government Code, Section 4590. Each bid shall be made out on a form to be obtained at the office of the Director of Public Works, Development suing, 2000 Main Street, 1-bntington Beach, California; shall be sealed and filed Nith the City Clerk at the Civic Center, Secand Floor Adminiatrat.ion Building, 2000 Blain Street, F-Untingtcn Beach, California, on or before 2:0n. P.M. of Jul._.. y .% l 986, and shall be opened by a committee composed of the! City Clvr amity Attorney and Director of Public Works or their authorized repreinntative and the results of acid bidding will be re"rted tothe City Council of said City of Kmtlrigton Flewh at their regular meeting to be held on M4x-4ay, the 219t of Ju.IY1., 86, at the hour of 1:30 P.M. in the City Council Chambers in the Civic Center of aid City of Huntlrgton eeech„ and shall be acted upon by said City Council at the regular nosting of 3ulX to t 9(f6. N-1 c w • City of Huntington BeacN California reserves the At to reject an or all bide, and accept the bid deemed for the hest interest of the City of Huntington any California. By order of the City Council of the City of. Huntington B4ach, California this Fdbevs 3, 1986. ATTEST; Alicia Wentworth City Clark N•Z A 0 a� CW 0� INTER -DEPARTMENT COMMUNICATION To CHARLES W. THOMP.50N From ROBERT J. FRANZ, Chief City Administrator Administrative SerOmw Subiact APPROPRIATION FOR REPAIR Dote JULY 169 1986 TO MUNICIPAL PIER FIS 86-33 As requested under the authority of Resolution 4832, a Fiscal Impact Report has been prepared and submitted relative to the proposed structural repair to the municipal pier, incurred as a result of the February 1, 1986 winter storm. Anticipations by the requesting entity are that an appropriation of $167,090 would he adequate for this project. An affirmative response by the City Council will reduce the balance of the C'ity's unaudited, unappropriated General Fund to $1,706,705. 0 ROBERT J. Administrative Services Deva RJ1•:skd it .Pent 2657 j J (40 MO PPAPMI FROM OOHN L. ,MEEK CONSTRUCTION CO., MC. • lbrw slow, TO ON fl+wrl" fir twl fY CDOW. ft of iWdqft HMO. 0101 -1 : M 1r1�+ wMM 1M Mwi�'� wi MMI IWit repair 'of existing pony bents the Pier Restaurant. CC--707 hw* fob wW Wo is wwrr iaq a avow is prrfwm iM rwt Mover dwnb W ad in wry is weariMs Miry M yw OW raid for Mr sY wwk wry it Mr n of OW wd■r Nt • m ---1 IA f 48 of wwk# of ■M my of; d"M so* bwwfl t. TIe wmiwwrM ho m Irr M11 bid f m nary `— N xwwWm lhw4A wYhW d@VWW 1, IM by4rwN roles rt mpimM of WM* pebalt w passi it rr s"m km sm*k bl war bill km w t M irwriirw � wK �reMwrl drr�A trW bwi i�MMY, it wbii'n�t � �i�rr�� or w�rrrirlwM frow bWke to espy wave w *6* too on NM do flllilift of R mW halal km w dwwo =0 bii dooseftr i rFw *e fry of d bier, = rWk w1 owpmm. mW v mN WeWwW weft mewowy 1s #Wm d 6m i i�b w"Mlr M pew, M IN* wwww tv I" IM � love WNW Nrr►ri & M m0 w it rt *s OM ol. d Pfjbk �sl Cky of Mrs Mb, fy!�F*rm woe arty is tales f+M pjwerOWWWO n tw lelem wA prism to wk: F-I h is +rniws�i said rrrrM sbrt dMs r�pruciillrll ��� shrw iat dls hrs�ily prr'rsrf ssiMsi�to an ss� frc ills plrprws M IMMUft 1Mr ssMwywiwa sp Miis rmd drn' do is srsr�srssww" +ni�0 be srw�rlsrf r do Mswir rf #4 ow d "r■IlMilr it to "emplow mt, wMs" lkly to Ewe w b m *01Ys~ mi r bmilm at to snit p limm bd in do plrpul uk dNds. TM jgl�j jrjyswbMdmJb* &C fUg"SM"Wi�? 80 calendar o, rap, fill � dais w w ri soiii �ir�i m� waY�iwr'11rb r�irr Itll irys irr�a cif r ow loot by do My of limbilyliI be*. Odif w*. riper" Mrs womaked orrr uNy do sirs of tMr wwk , drs piew sad . lAw ds prIpsrsi sssj rrssAlrrt prnar dslrs�t. TM ssi�r s+! r ~' siril Mlt rrswrir�s swriirsrw irsr drs Mijirr Mr isrsw�M rlll is ss1YAw� rr tr tlrs a Mr ssrwlslAsrrli, w tm:q) sa -11 sr, 4Mty. rod s+ w at sr A "be prrl�r�snd„ me NIrs 1 of Now" " M 1fr"W. ssk r "ills s f p11w p Mood, iwddwmw*%;L monct min irkoo "Cwwad amok" w "idit's INV w do m my M. it s low is sR kW is pslrll.t d go WW w piw, pi yshb 1r So CRY of Msrd vism Instil. nr tlsr l dipeft drs risw wood now* us IriMw !mol1► ad Wm drat it doN M forlsissd a *e Ckll rf dIrlMids �ll 11rMi1 M M�iiirtrd � III dMY prrtprrsl M smmW My Ill Clay rlld its �sslisr*s ski " Sri a slslm r mom Irr do* mW wart oW is hlrllisM prod rill srb" is dw hm of *6 it ft wd ofto ftwooft if Os W, WO soy sr y to !Ill My iftim 116" shrr ft bdit be mm*W r1t*M oft of ft olsnnd of ft os w odw%iw oW a Ivv 60 be m r* tr Ill ankrsiprri. Uvw and is rssis *uw oft so rR praob %q fw doe rolftrsism sd tloswswR Clause Mr. WinsAftm 30.32 West C Stre-,!t Roses of p4mmeoms •' • . ` " , . •' Owrd Ws H /hr •1 --'10 Wj hide " mjOw m*pt of A AOioodo hen, 0 ory. Aidrairn %-. panto R400iroi ftmom 401 OMW r Wdoo'$ Harlon P-3 C MQWUD INFORMATION REQUIRED OF 1110DIERf TM bWdw it MWArsd to +s+M* do f *ow $q Milwstastirnt. A*01000tal Illu s Mary be sr-uiiad N err. 1. Ita Mionw: JOHN L. MEEK CONSTRMTION CO., INr_. 2. A&I : � 1032 W. C St., Wilmington,_ CA 90744 i 213-810-632 3 4.. Typg of firm •- irsdiciduai, pvtunhip. or owporadw* ff corpiration 5. Cwporodost wWIzd under firs laws of the SW# of C a 1 i forni FA i. or's Liw w plumber: 11297 ,,_._....�.. t5mWWvtkm of Contrt►ew's lkarm 8 1 -- A 7. Uat #w rums wwd ddrasisae of all moon n of the turn of rd mays turf dtias of all atfian of %*Q Morvarsf00": John L. Meek President 200 N. Layton Dr., Los Angeles. CA 90049 Patricit-i Mtr'ek Sc-c.-Trea. 200 N. L2yLon nr.1 Ir_�:, Angeles, CA 90049 John S. Meek Vice Pr► -i. .3 Surrey Lano, Rainchu Pales Verrlcs, CA 90274 0. Niurabw of'rars axporience at a contractor in construct►on wcrk- •. t' -t at local slu Cactaats oornpleted cs of ►scsM dats, (Contrsct amt.) ICkw of ww1d (Qats COMtt0 tedI (MWA artid t,..;Mu of Owns..) 13. Ust the namo of the pwKm .rho ►n:period the me of the pruptiaad rrr,M for ycrut fun► John L. W?v k ton _--_..__-_..._..T--. ._.�_._._. .� �..._.._... � .�_....... On" of 11. if requaatad by the Crty, the b►ddw "I fwnsth a murued finwxwl rwtwWAt. f►nwxial d2u, or c.thet to-lonrt Wn WW nrfvonCrMM'ihttnsl►e M par" trt owatrof of hti cwr► " ftnee+el sr3stdfowL .11-4 DESIGNATION OF SUKONTAACTURS CIA t tM 1� sod S�ti� 1 * PrecOm Act" " betwr 41641 t? of it IMrRM tf e1 i.�RMt t� ooilt trl�.+rrwlne4r .+� � worst er febor or ttnirr M to+� lllf w in w Am so www,,** W so wed w haprWAMA in so mew W own of ON" to of tM "ON { 010 p1m nomMem t'•rW Mil. Ind &A krft opt fw* to Nrft tit IM awk 90 to dt bY"1060W >Ill . Otl� m 1v6w;s+Ifttlt;'.w" pwo" tlrrM be Meld. N *► , w mWW tok to f m*V i Xqbommmyt fort ony Wda M two towk to k pm fla Sri rotor *6 MIL, he dwN k i i L bm /Orin le pnrfvm w* pefts kin*#, Mai Im" not M pu nkle l lavol W10#MP0003 of rwr rt�it railr�t wrir Mr MtMiitlorr Mr�ftor �t fob. I of orb—na of my owti" of tM work to %*A* " wia .Mr t+t+N iroiNrlN1 to too �rtjnM bid t rll ► W portnw is am of p+A►k smal " N mcniity, Mrs d" 0* Ow o %dioS thr*AW to wria" M • e rootw e. dw Lbw body of dw oww. PORTtAN XTA M L CI NK OF ""K VJ8C0W RACTQjk-C 1AMt ANti ALM Nl MAN"" C L A it Oy orinboa of tM MoNmw, the tonuit*tor mufMt 1. TUt M is obit to GvW will POWNa the balances of all r r►k wy„sfi is covw oil in Ov ¢bove tubcantimier 1m):-4. 2. T41 *@ CJ'tY will bo fulm" tapwa of Of tub-wriactt frn.c,—M rifo and Cr�r.�'t e4.a bpi c.:, ,o�a�►a+t.*.� IN this fit. P -6 • • CITY OF HUNT11"V BEACH 20M MAIM STREET CALIFORNIA WMO PwI E. Cook Director July 2, 1986 CONSTRUCTION OF MUNIrIPAL PIER REPAIRS CC-707 ADDFNDA NUMBER 1 Notice to Ali. Bidders: hiblic Wwks DepwmKrnt t71{l6"31 The following revisions and additions shall be made to the bits documents: Re: Drawing 3 of 3 is hereby revised to include reference bubblo. clarifications as noted. Sealed bids shall be filed with the City Clerk at they Civic Center, Second Floor Administration Buildinq, 2000 ?Rain S:rret, Huntington Beach, California, on or before 2:013 p.m. of July R, 19P6. You are requested to acknowledge this receipt of the addendum with your bid proposal. & r u l y -you r , Pau) F . C caok Directo.- of Public Work,-.; This .:; to acknowle(icle rec-cipt and review (-)' Addenda Nurd)er One, date(I July 2, 1986. It is unde3rstooki that the revilion of new docuwntr• sha11 be included in the .bic! dooumetne. � �\ h �., ,� 1 r L\" ti�11 l I.�..r\a r • Company Y. � t. a �1.._._ __....._...._.... ._. r�r DATE : July �re, 1906 r+r w��s�..r ENGINEER'S ESTIMATE: 25K JOB AND %.. NUKDER: Pier !mains; CC-707 BIDDERS NAM TOTAL DID AMOUNT 11.cDnrollx,-per fic 22mn I� 7 rcc, 2. Fas terwix Obiporation of IDT Bea& 3. Healy Titti t:s Wns traction C .. 4. J . L . Meeks C on*s tnicti on �� � �-� z • t CC . 5. W. W. Staticry3on arTy I n mgprat.oi S M E E T...._ OF._._. SK E E TE CITY OF MUNTIMGTOP4 SEACN.CALIF. IS ID SUMMARY SHEET FOR: _ Pic& i9Ri" J• _ DEPARTMENT OF PUSLIC WORKS SIDS OPENED JUL--Y' � . 19ENGINEERS ESTIMATE iziKeClo CCw. �t ANFP N. .......... 1 i ' BIDDERS ,t M ITEMS OF WORKQuArT*Tv uv1T PRICE AMOUNT ►RICK AMOUNT PRiC[ AMOUNT PRICE AMOUNT !� i� K i 1 TOTALS % Q7• rl 1rfC �.� .-