Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
R. J. Noble Company - 2016-08-15
RECEIVED"BY: CITY CLERK RECEIPT COPY 1 Return DUPLICATE to yJ ' .7 _ City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: SUBJECT: Bond Acceptance I have received the bonds for QSY A)d,6f :- I (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) Performance Bond No. Payment Bond (Labor and Materials) Bond No. Warranty or Maintenance Bond No. e r 7 -4!- TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved (CouncilrA,p al Date) CC No. Agenda Item No. MSC No. City Clerk Vault No. 1600. �M Other No. SIRE System ID No. 61-/„ g:/forms/bond transmittal to treasurer CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION DATE: 5/1 1/2017 TO: THOSE LISTED HEREON FROM: John Griffin, PW Contract Administrator SUBJECT: Retention Release Payment - PO#22148 OJ Supplier#18195 Co. #100 MAIN-TALBERT-HEIL-ST. REHABILITATION, Project#CC-1527 Contractor's Name: R.J. Noble Co- Orange Address: 15505 E. Lincoln Avenue City, State and Zip Code: Orange, CA 92856 Phone Number: 7146371550 City Business License Number: A005420 Notice of Completion (Date by City Clerk): 2/8/2017 The conformed copy of the Notice of Completion for the above contract has been filed. The thirty-five (35) day waiting period has elapsed or will elapse before payment is made. Processing of the retention payment is recommended so long as no stop notices or outstanding invoices are on file with the City. I certify that no stop notices are on file. Date Travis K. Hopkins, Director of Public Works I certify that there are no outstanding invoices on file. h-y--I I I o t-_ ) I"dc;_ Date J yce Zack-s, Deputy City Treasurer I certify that no stop notices are on file, and that a guaranty bond has been filed with the City Clerk's Office. Date Robin Estanislau, City Clerk Attachments ,0 1. Notice of Completion � 2. Maintenance Bond 3. Certificate of Compliance with Prevailing Wage Laws 4. Contractor's Certificate 5. Certificate of Compliance with Title VI of the Civil Rights Act and Equal Employment Opportunity Act of 1972 6. Consent for Release letter from the Surety Company Certification of Compliance with Prevailing Wage Laws To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Prevailing Wage Laws Contract: CC-1527 Project: MAIN-TA LBERT-HEIL STREET REHABILITATION The undersigned contractor on the above-referenced project("Project') hereby certifies that all laborers; mechanics, apprentices, trainees, watchmen and guards employed by him or by any subcontractor performing work under the contract for the Project have been paid pursuant to the minimum wage and bona fide fringe benefit requirements specified for each particular classification of work, as set forth in the wage-rate determinations of the State of California, Department of Industrial Relations, and/or the United States Department of Labor. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this 13TH day of MARCH 20 17 at ORANGE , California. (Contractor Xame)effVE MENDOZA,SECRETARY APPROVF,D ASJO FORM By: Miehael E. Gates City Attorney I CONTRACTOR'S OR'S CERTIFICATE I STEVE MENDOZA , state and certify that: (Name of'Declarant) l R.J. NOBLE COMPANY is the general contractor to the City of Huntington Beach ("City") on Contract No. 1527 (the"Contract") for the construction of the public work of improvement entitled: MAIN-TALBERT-HEIL STREET REHABILITATION (the"Project"). 2. All work to be performed pursuant to the Contract has been completed in accordance with the Contract Documents (as such term is defined in the Contract). 3. Except for the claims listed below and the disputed claims listed in paragraph five (5), all persons supplying labor, services, materials and equipment to the Project, including all claims against the contractor arising from the performance of the Contract, have been paid and satisfied(list unpaid debts and claims; if none, write "NONE"): NONE 4. Attached hereto are the lien waivers required by the Contract Documents, which lien waivers have been executed by all persons who performed work on or supplied labor, services, materials, and/or equipment for use at the Project. 5. Set forth below is a list of disputed claims or claims that are the subject of a Notice to Withhold filed pursuant to the Civil Code of the State of California(list all disputed claims; if none, write "NONE"). I declare under penalty of perjury udder the laws of the State of California that the foregoing is true and correct. Executed at 15505 E. LINCOLN AVE., ORANGE,C nn this day of MARCH 20 17 x (Signature of Declarant) APPROVED AS T.Of'0RM f STEVE MENDOZA, SECRETARY Michael E. Gates City Attorney 1 Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 To: City of Huntington Beach Department of Public Works 2000 Main Street/P.O. Box 190 Huntington Beach, CA 92648 Re: Certification of Compliance with Title VII of the Civil Rights Act and Equal Employment Opportunity Act of 1972 Contract: CC-1527 Project: MAIN-TALBERT-HEIL STREET REHABILITATION The undersigned contractor on the above-referenced project("Project") hereby certifies that it has complied with title VII of the Civil Rights Act, the Equal Opportunity Act of 1972 and Executive Order 11246, and has not discriminated against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity,national origin, age or disability. The undersigned contractor also certifies that it has not maintained any segregated facilities at its establishments on the basis of race, color,religion, sex, sexual orientation, gender identity, national origin, age or disability (with the exception of access for the disabled). I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed this 13TH day of MARCH 20 17 , at ORANGE , California. x (Contractor wame) L/E MENDOZA,SECRETARY APPROVED AS,T6 FORMS Michael E. Gates City Attorney 1 RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) Ire CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: �— SUBJECT: Bond Acceptance 1 have received the bonds for OlAd (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) Performance Bond No. Payment Bond (Labor and Materials) Bond No. p Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved (Counc" A pro al Date) CC No. � � Agenda Item No. MSC No. City Clerk Vault No. 600, S-0 Other No. SIRE System ID No. _ � g:/forms/bond transmittal to treasurer Bond No.58738356M MAINTENANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: That R.J.NOBLE COMPANY (contractor's name) 15505 E. LINCOLN AVENUE,ORANGE,CA 92865 (contractor's street address, city and state and zip code) as Principal (hereinafter called Contractor), and: Westem Surety Company (surety's name) 915 Wilshire Blvd.,Suite 1650,Los Angeles CA 90017 (surety's street address, city and state and zip code) a corporation organized and existing under the laws of the State of South Dakota with its principal office in the City of Sioux Falls as Surety(hereinafter called Surety), are held firmly bound unto CITY OF HUNTINGTON BEACH as Obligee (hereinafter called Owner), in the amount of * Dollars ($ 2,603,187.04 ), equivalent to the entire contract amount including all change orders, for the payment whereof Contractor and Surety bind themselves, their heirs,executors, administrators,successors, and assigns,jointly and severally, firmly by these presents, *two million six hundred three thousand one hundred eighty seven&4/100 WHEREAS,Surety is a duly admitted surety insurer under the laws of the State of California; and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and able to provide proof of bonding limitation shown in said circular is sufficient to provide bonds in the amount required by said Contract; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's, Standard & Poor's,to validate that Surety has positive ratings of being secure or stable; and Surety is registered and listed with the California Department of Insurance; and Contractor has by written agreement dated OA 20 (jV,,entered into a contract with Owner for the Main-Talbert-Heil-St Rehabilitation.Project#CC-1527 in accordance with drawings and specifications prepared by which contract is by reference made a part hereof(hereinafter referred to as the Contract); and The Contract provides that the principal will guarantee, for a period of one year, the work performed as part of the Contract from and against all defects in materials and workmanship; and The Contract also provides that the Contractor shall secure Contractor's obligations during the one-year period with a bond executed by a surety duly admitted in the state of California; and The Contract has been completed, and the Owner, Contractor and Surety agree that the commencement date for this Guarantee and Bond shall be March 2 2017, NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Contractor shall, for a period of one year from and after the date of completion and acceptance of the Contract by Owner, repair and/or replace any and all defects arising in the Work, whether resulting from defective materials or defective workmanship, then this obligation shall be null and void; otherwise it will remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner, Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Surety shall, within thirty (30) days following Owner's written notice of default, either: (a) remedy the default, or (b) shall promptly complete the Contract in accordance with its terms and conditions. Surety shall save the Owner harmless from any claims,judgments, liens or losses arising from the Surety's failure to either remedy the default or to complete the Contract in accordance with its terms and conditions in a timely manner. 154584/118138 1 Whenever the Principal shall be, and declared by the Owner to be in default under the Contract,which shall include without limitation, any breach or default of the Contract, then, after written notice from the Owner to the Surety, as provided for below,the Surety shall either: (a)remedy the default or breach by the Principal;or(b)shall promptly and faithfully take charge of the Work and complete the Work in accordance with the requirements of the Contract with a contractor other than the Principal,at its own expense,and make available as work progresses sufficient funds to pay the cost of completion less the unpaid balance of the Contract including other costs and damages for which the surety may be(fable hereunder, provided,however, that the procedure by which the Surety undertakes to discharge its obligations under this Bond shall be subject to the advance written approval of the Owner. Within thirty (30) days after Surety's receipt of a written notice from Owner of the failure of performance of the Contract by the Principal, it shall be the duty of the Surety to give to the Owner a notice, in writing, of the Surety's election to(a)remedy the default(s)of the Principal promptly,or(b)arrange for performance of the Contract promptly by a contractor other than the Principal, time being of essence to this Bond. In said Notice of Election, the Surety shall state the date of commencement of its cure or remedy of the Principal's default(s) or its performance of the Contract. The Surety's obligations for cure or remedy,include but are not limited to: correction of defective work and completion of the Contract, additional legal, design professional and delay costs arising from Surety's actions or failure to act; and liquidated damages (or if no liquidated damages are specified in the Contract, actual damages caused by delayed performance or non-performance by the Principal). The Surety shall give.prompt written notice to the owner upon completion of the cure or remedy of the Principal'a default(s)of its performance of the Contract. If the Surety does issue its Notice of Election and does not proceed to cure or remedy the Principal's default(s) of its performance of the Work within thirty (30)days after receipt of a written notice from Owner, Surety shall be deemed to be in default on this bond,and the Owner shall be entitled to enforce any remedy available to Owner. No right of action shall accrue on this bond to or for the use of any person or corporation other than the owner narned herein or the successors of Owner. Signed and sealed this 19 day of May 20 17 Principal Raised Corporate Seal R.J.NOBLE COMPANY [MUST BE AFFIXED] (Contractor Name) By: X 01� 1 (Seal) STEVE ME�t�ZA,SEC ETARY i Principal Raised Corporate Seal [MUST BE AFFIXED] (Title) Western Surety CwEpany {S am BY: r Seal) J o� a a,di,Attorney-in-Fact APPROVED AS F{T3RM;,.- - BY, NOTES: Michael E. Ga es, City Attomey 1. Acknowledgments must be completed and returned t as part of the bond. 2. Raised Corporate Seals are mandatory. l 3. Please attach Power of Attorney. 15-458411 18138 2 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 -- -- -- -- - --- - - - A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California } County of ORANGE } On oS/22/17 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persons} whose names} is/are- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/her/their authorized capacity(ies}, and that by his/her/their signature(s}on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and off'cial al. J. DE IONGH Commission # 2128504 a :_ Notary Public -California v Signature Z Orange County` %• o S4i1 Sign �r6Notary Public My Comm.Expires Oct 28,20�19�f J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑ Other: ❑ Other: Signer Is Representing: Signer Is Representing: - = - - - -`�c�;c,cc.�:c.�e.•c=c.,e;zsc_zr:c:c_z:sz:�c��,�r,�z,�c :ec..- - _ - - - - - -`�-z,�.x�e�zsu.ccx_=c.•c<cr 02014 National Notary Association - www.NationalNotary.org - 1-800-US NOTARY(1-800-876-6827) Item#5907 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange ) On May 19, 2017 before me, Lauren Emily Bierman, A Notary Public (insert name and title of the officer) personally appeared James Scott Salandi, Attorney-in-Fact who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/aIX subscribed to the within instrument and acknowledged to me that he/gbse" executed the same in his/herAhak authorized capacity(ie*, and that by his/herAhek signature(%) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. .6�`oF' a. LAUREN EMILY BIERMAN N ,0 COMM.#2097240 �s NOTARY FUBLIGCAI.IFORNIA ORANGE COUNTY 11 Signature (Seal) MY COMM.EXP.JAN 15,2019 Document-2794160-Page-1 Page 1 of 1 Recorded in Official Records,Orange County Hugh Nguyen,Clerk-Recorder 4 NO FEE PLEASE COMPLETE THIS INFORMATION $ R 0 0 0 9 0 5 6 4 1 7 $ 2017000058638 2:02 pm 02/09/17 RECORDING REQUESTED BY: 63 406 N12 F13 1 j 0.00 0.00 0.00 0.00 0.00 0.00 0.00 0.00 i i ' I i WHEN RECORDED MAIL TO: I CITY OF HUNTINGTON BEACH PUBLIC WORKS DEPARTMENT i Attn John Griffin i P.O.Box 190—2000 Main Street I Huntington Beach,CA 92648 THIS SPACE FOR RECORDER'S USE ONLY TITLE OF DOCUMENT I � I NOTICE OF COMPLETION i NOTICE IS HEREBY GIVEN by the City of Huntington Beach,owner in fee,2000 Main Street,Huntington Beach,CA 92648,that the contract heretofore awarded to R.J.Noble Co-Orange,who was the company thereon for doing the following work to-wit: MAIN-TALBERT-HEIL-ST.REHABILITATION,Project#CC-1527 j i That said work was completed 02/07/2017 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the Director of Public Works on 02/07/2017,per City I Council Resolution No.2003-70 adopted October 6,2003. I � I That upon said contract Western Surety Company,was surety for the bond given by the said company as required by law. I This document is solely for the official business of the City of Huntington Beach,as contemplated under Government Code Section 6103 and should be recorded free of charge. i I -7 j Dire or of orks or City Engineer Oate pi City of Huntington Beach,California I i STATE OF CALIFORNIA) 1 County of Orange )ss: City of Huntington Beach ) 3 I,the undersigned,say: I am an Agent of the City of Huntington Beach,owner in fee,in the foregoing NOTICE OF COMPLETION. I have read said NOTICE OF COMPLETION and know the contents thereof;the same is true of my knowledge. I declare under penalty of perjury that the foregoing is true and correct,and that said NOTICE OF COMPLETION was duly and 3 regularly ordered to be recorded in the Office of the County Recorder of Orange County. ! This document is solely the official business of �7 the City of Huntington Beach,as contemplated under Government code section.6103 and f Pub or s or City Engineer Date should be recorded free of charge. City of Huntington Beach,California j d THIS PAGE IS ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION pi (Additional recording fee applies) i ) ( about:blank 2/9/2017 RECEIVED BY: / CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating f (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk f DATE: SUBJECT: Bond Acceptance I have received the bonds for A /�✓�� �=� f (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) r� Performance Bond No. Payment Bond (Labor and Materials) Bond No. �r� �3 Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved (Council Approval Date) CC No. /��`-.�- - Agenda Item No. 7� MSC No. City Clerk Vault No. AT90 • �� Other No. SIRE System ID No: g1forms/bond transmittal to treasurer y e CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND R.,, Aldo E evAirAn/Y FOR fl vjwv1F RE AlAb°tq 1rg7iory TEzf-ec /%-27 THIS AGREEMENT("Agreement") is made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as 9.7:A4®6t f C91MA01My "CITY," and , a f corporation, hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as 0 in the City of Huntington Beach; and AlA w sfga7, 7,q&9ERr♦vuva(f, NCit ANEA114 Ir-l7.,&4 CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and 1 16-5195/city-funded-construed on-co ntract.doe-revised 04/2016 for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms, conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), has inspected the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Department of Public Works of CITY, and any revisions, amendments or addenda thereto; D. The edition of Standard Specifications for Public Works Construction, published by Builders' News, Inc., 10801 National Boulevard, Los 2 16-5195/city-funded-construction-contract.doc—revised 04/2016 Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee as specified in the particular Plans, Specifications, Special Provisions and Addendum applicable to the Project; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Director of Public Works of CITY or his or her written designee (hereinafter referred to as "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3 16-5195/city-funded-construct ion-co ntract.doe—revised 04/2016 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed TG/c/�Icb�on� 7-'VA F A4V'40AEV Fi4NYyJeVFv TNayl4wo, ®NF Ner WAP YN#Rr%p-rW* JO&LAAF ClFwf Dollars ($ ), as set forth in the Contract Documents, to be paid as provided 9,���,i�Z.�o in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10) working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion withiriff4ory( 0® ) consecutive Working days from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, 4 16-5195/city-funded-construction-contract.doe—revised 04/2016 subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason, relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 5 16-5195/city-funded-construction-contract.doc—revised 04/2016 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final contract price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within ten (10) days of filing of the Notice of Completion. 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other 6 16-5195/city-funded-construction-contract.doc—revised 04/2016 payroll deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to FIVE#11AIMd F9 49041,411s CITY, as liquidated damages and not as a penalty, the sum of 1 ($5-04 o) per each calendar day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay (unless DPW shall grant a further period of time), notify DPW in writing of the cause of the delay and CITY shall extend the time for completing the work if, in its judgment, the 7 16-5195/city-funded-construction-contract.doc—revised 04/2016 findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed, but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DEMANDS FOR ADDITIONAL TIME OR MONEY. A. Definitions. (1) "Change Order" means a document signed by the CONTRACTOR and CITY which authorizes an addition, deletion or revision in the work, or an adjustment in the Compensation under Section 3, or the Completion Time specified at Section 4. (2) "Demand" means a written demand for a Change Order by the CONTRACTOR for any of the following: (a) A time extension; 8 16-5195/city-funded-construction-contract.doc—revised 04/2016 (b) Payment of money or damages arising from work done by, or on behalf of, the CONTRACTOR pursuant to this Agreement and payment of which is not expressly permitted pursuant to Section 3 of this Agreement; (c) Payment of an amount the CITY disputes; (d) Any disputes and other matters relating to the acceptability of the work performed or the interpretation of the Contract Documents; (e) A request for a time extension or additional payment based upon differing site conditions, such as subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents, or unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the PROJECT; or (0 A request for a time extension or additional payment based upon acts of neglect by CITY or due to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. B. A Demand for a time extension or payment of money or damages may only be granted by a Change Order. C. No Change Order may be granted except where the Contractor has submitted a Demand to the DPW (or his or her written designee). All Demands shall be submitted promptly, but in no event later than thirty (30) days after the occurrence of the event giving rise to the Demand. The Demand shall be in writing and include all documents necessary to substantiate the Demand. The DPW shall act on the Demand within fifteen (15) days after receipt, including by requesting additional information from the CONTRACTOR to determine whether to approve the Change Order the Demand seeks. The DPW shall act on the Demand 9 16-5195/city-funded-construction-contract.doe—revised 04/2016 within fifteen (15) days after receipt of the additional information or within a period of time no greater than the time the CONTRACTOR took to produce the additional information requested, whichever is greater. D. Notwithstanding the thirty (30) days to submit a Demand under Subparagraph C, in the case of differing or unknown site conditions, immediately upon encountering the conditions, CONTRACTOR shall notify the DPW in writing of the conditions, so that the CITY may promptly investigate the conditions. E. If the CONTRACTOR disputes the DPW's written response on the Demand, or the CITY fails to respond within the time prescribed, the CONTRACTOR may so notify the City Engineer, in writing, either within fifteen (15) days of receipt of the City Engineer's response or within fifteen (15) days of the DPW's failure to respond within the time prescribed, respectively, and request an informal conference to meet and confer for settlement of the Demand. Upon the CONTRACTOR's request, the DPW shall schedule a meet and confer conference within thirty (30) days to seek to resolve. F. CITY and CONTRACTOR shall execute appropriate Change Orders covering changes to the time or price by executing the Change Order by mutual agreement. If the CITY and CONTRACTOR are unable to reach a mutual agreement, then the City Engineer shall issue a written decision on the claim within a reasonable time. G. Following the meet and confer conference, if the Demand remains in dispute, the CONTRACTOR may file a claim with the City as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the 10 16-5195/city-funded-construction-contract.doc—revised 04/2016 CONTRACTOR submits his or her Demand until the Demand is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, five percent (5%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such 11 16-5195/city-funded-construction-contract.doc—revised 04/2016 sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT, as determined in its sole discretion by DPW, less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR, if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Provided, however, that in the event of a dispute between CITY and CONTRACTOR, CITY may withhold from the final payment an amount not to exceed 150 percent of the value of any disputed amount of work. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR, who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items, if any, to be set forth in CONTRACTOR's affidavit covering disputed 12 16-5195/city-funded-construction-contract.doe—revised 04/2016 claims, or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 18. CALIFORNIA PREVAILING WAGE LAW A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by 13 16-5195/city-funded-construction-contract.doc—revised 04/2016 resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 19. CALIFORNIA EIGHT-HOUR LAW A. California Labor Code, Sections 1810 et seq, shall apply to the performance of this Agreement; thereunder, not more than eight (8) hours shall constitute one day's work and CONTRACTOR and each subcontractor employed by its hereunder, shall not require more than eight (8) hours of labor per day or forty (40) hours per week from any one person employed by it hereunder, except as stipulated in California Labor Code Section 1815. CONTRACTOR and each subcontractor employed by it hereunder shall, in accordance with California Labor Code Section 1812, keep an accurate record, open to inspection at all reasonable hours, showing the name and actual hours worked each calendar day and each calendar week by each worker employed in connection with the PROJECT. B. Pursuant to this Agreement and in accordance with California Labor Code Section 1813, CONTRACTOR shall, as a penalty to CITY, forfeit twenty-five dollars ($25) for each worker employed hereunder by CONTRACTOR or any subcontractor for each calendar day during which such worker is required or permitted to work more than eight (8) hours in any 14 16-5195/city-funded-construction-contract.doc—revised 04/2016 one (1) calendar day or forty (40) hours in any one (1) calendar week in violation of California Labor Code Section 1815. 20. PAYMENT OF TRAVEL AND SUBSISTENCE ALLOWANCE Section 1773.8 of the California Labor Code, regarding the payment of travel and subsistence allowance is applicable to this PROJECT. 21. EMPLOYMENT OF APPRENTICES Section 1777.5 of the California Labor Code, regarding the employment of apprentices is applicable to this PROJECT. 22. PAYROLL RECORDS CONTRACTOR agrees to keep accurate payroll record showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice or worker employed by it in connection with the PROJECT and agrees to require each of its subcontractors to do the same. CONTRACTOR further agrees that its payroll records and those of its subcontractors, if any, shall be available at all reasonable times to the CITY, and the employee or his representative, and the Division of Labor Standards Enforcement and the Division of Apprenticeship Standards, and to comply with all of the provisions of California Labor Code Section 1776, in general. 23. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all claims, damages, losses, expenses, judgments, demands, defense costs, and consequential damage or liability of any kind or nature, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's 15 16-5195/city-funded-construction-contract.doc—revised 04/2016 property, arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY, its officers, elected or appointed officials, employees, agents, and volunteers. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 24. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terns of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 16 16-5195/city-funded-construction-contract.doc—revised 04/2016 25. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend, hold harmless and indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit, the aggregate limit must be no less than One Million Dollars ($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees, agents, and volunteers (the "Additionally Insured Parties") as Additional Insureds, and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary and non-contributory with any other valid and collectible insurance or self-insurance available to the Additionally Insured Parties. Any available insurance proceeds in excess of the minimum coverage amount specified herein shall be available to the Additionally Insured Parties. All coverage available to CONTRACTOR shall also be available to the Additionally Insured Parties. Under no circumstances shall said above-mentioned insurance contain a self-insured retention without the express written consent of CITY; however an insurance policy "deductible" of Five Thousand Dollars ($5,000.00) is permitted. CONTRACTOR shall be responsible for causing all Subcontractors to maintain the same types and limits of insurance coverage as that required of CONTRACTOR by this Agreement. 17 16-5195/city-funded-construction-contract.doc—revised 04/2016 26. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: l. Provide the name and policy number of each carrier and policy; 2. State that the policy is currently in force; and 3. Promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 27. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction 18 16-5195/city-funded-construction-contract.doc—revised 04/2016 which arises out of performance of this agreement within ten (10) days of receipt of such claim or claims. 28. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten (10) days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 29 and any damages shall be assessed as set forth in Section 29. 29. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause, and whether or not PROJECT is fully complete upon seven (7) calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience, the CONTRACTOR shall be entitled to receive payment for work executed, and costs incurred by 19 16-5195/city-funded-construction-contract.doc—revised 04/2016 reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 30. DISPOSITION OF PLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 31. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement, or any part hereof, or any right or duty created herein, without the prior written consent of CITY and the surety. 32. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 33, STOP NOTICES; RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($I 00) for every Stop Notice filed in excess of two (2), regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or 20 16-5 1 95/city-funded-construction-contract.doc—revised 04/2016 expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 34. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant, or by enclosing the same in a sealed envelope, postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices, certificates or other communications will be sent by notifying the other party via personal delivery, reputable overnight carrier or U. S. certified mail-return receipt requested: TO CITY: TO CONTRACTOR: ®NA/e�PublicWorks o City of Hun tington ATTN: ATTN: 1<6al Pmrm 2000 Main Street /5rof e, 611VICO&.11 Ave-We Huntington Beach, CA 92648 0"#V E, CA 4Z956 35. SECTION HEADINGS The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions, and do not interpret, define, limit or describe, or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 21 16-5195/city-funded-construction-contract.doc—revised 04/2016 36. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 37. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 38. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non-prevailing party. 39. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other 22 16-5195/city-funded-construction-contract.doc—revised 04/2016 whenever the context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 40. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 41. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. 42. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 43. SURVIVAL Terms and conditions of this Agreement, which by their sense and context survive the expiration or termination of this Agreement shall so survive. 44. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 23 16-5 1 95/city-funded-construction-contract.doe—revised 04/2016 45. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact, held by the signatory or is withdrawn. 46. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiation, and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements, promises, agreements or warranties, oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement, promise, agreement, warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof. 24 16-5195/city-funded-construction-contract.doc—revised 04/2016 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers oib4l�), 20 1� . CONTRACTOR:R.J. NOBLE COMPANY CITY OF HUNTINGTON BEACH, a municipal corporaticy1f the State of California By:x � 6� � Aa#.A_ P4&e44 CRAIG FORTER,)ACE PRESIDENT a (print name) ITS: Chairman /President/Vice-President City Clerk (circle one) INITIATED AND APPROV D: AND By: x — Director of Pub c Works STEVE ME OZA, ECRETARY (print name) ITS: Secretary/Chief Financial Officer REVIE PPROVED: Asst. Secretary /Treasurer (circle one) ity Manager APPROVED O City Attorney 25 16-5195/city-funded-construction-contract.doe—revised 04/2016 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of ORANGE ) On 09/01/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared CRAIG PORTER Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(sy whose names} Ware- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/her/their authorized capacity(ies}, and that by his/her/their signature(s}on the instrument the person(s); or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. J. DE IONGIi Commission #2128504 Z WITNESS my hand and o ial s :-m Notary Public- California zD , i - Orange County My Comm. Exnires Oct 28,2019 Signature - ;.;Owl of Notary Public J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Partner — ❑ Limited ❑General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑ Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: ©2014 National Notary Association •www.NationalNotary.org • 1-800-US NOTARY(1-800-876-6827) Item#5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of Califomia ) County of ORANGE ) On 09/01/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s} whose name* Ware- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/her/their authorized capacity(ies}, and that by hisAier/their signature(s}on the instrument the person(s); or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of Califomia that the foregoing paragraph is true and correct. J. of loNCI� WITNESS my and an official seal. 15 Commission #2128504 a =.; Notary Public - California z �5 z ' - Orange County ' Signatur My Comm.Expires Oct 28.2019 J Signature of Notary Public J. DE Ell Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attomey in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator El Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02014 National Notary Association •www.Nationa]Notary.org • 1-800-US NOTARY(1-800-876-6827) Item#5907 SECTION C PROPOSAL for the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 80 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C- REVISED BID SCHEDULE (1 Sheet) Replace one page entitled "Project Bid Schedule— Heil (Edwards—Goldenwest) C- 2.14"with "Revised Project Bid Schedule—Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22" to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Number One, dated July 19, 2016. R.J. NOBLE COMPANY X � � �---- Company Name By STEVE IONDOtA, SECRETARY JULY 19, 2016 Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at(714) 536-5467 within 24 hours of posting. If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find 10% BIDDER'S BOND in the amount of-------------------which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond for_% ", as the case may be) Any standard Surety Bid Bond form is acceptable. Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature NO. 1 07/19/2016 X O��.�n''�� STEVE MADOZA, SECRETARY C-2 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 PROJECT BASE BID: Basis of Award Main Street Rehabilitation from Garfield Avenue to Delaware Street, Talbert Avenue Rehabilitation from Gothard Street to Newland Street, and Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street. . . . . . . . . C-2.2 to C-2.15 1. MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street $ 4u� 1/nl •- 0 2.TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street $ 1 1Z(41, ggs . ko 3. HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street $ to q �T01ti • U0 BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: ,(TOTAL FOR ITEMS 1, 2, & 3) BASIS OF AWARD C-2.1 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 MAIN STREET FROM GARFIELD AVENUE TO DELAWARE STREET CC NO. 1527 C-2.2 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR, (CASE SHOWN ON PLAN). 1 (INCLUDES ALL 2 EA $ 4,250.00 $ 8,500.00 APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16)WET PROCESS 2 3 OVERLAY PER TYPICAL 2,200 TN $ g010 $ Mau SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 4 EA $ 765.00 $ 3,060.00 GRADE. REPLACE WATER VALVE BOX 4 5 ASSEMBLY AND ADJUST TO 19 EA $ 815.00 $15,485.00 GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 5 6 PAVEMENT TO A DEPTH OF 171,300 SF $ 0.16 $ 27,408.00 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 6 6 A.C. BASE COURSE OVER 95% 2,200 TN $ 105.06 $ 3 COMPACTED SUBGRADE PRIOR TO 0.1 T ARHM OVERLAY, PER PLANS. C-2.3 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 7 8 SIGNALS AND LIGHTING 52 EA $ 210.00 $ 10,920.00 SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE AND RECONSTRUCT MEDIAN CURB PER HB STD PLAN 201 (CF=8"). (INCLUDES 8 9 SLOT PAVEMENT, AGGREGATE 50 LF $ 39.50 $ 1,975.00 BASE, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 9 10 (INCLUDES SLOT PAVEMENT, 30 LF $ 78.00 $ 2,340.00 AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DRIVEWAY CURB SECTION AS 10 11 MODIFIED PER DETAIL ON 50 SF $ 15.60 $ 780.00 SHEET 3. RAISE SURVEY WELL MONUMENT TO GRADE AND 11 12 PREPARE CORNER RECORD 1 EA $ 817.00 $ 817.00 (PRE-AND/OR POST- CONSTRUCTION). INSTALL TRUNCATED DOMES 12 13 TO EXISTING CURB ACCESS 8 EA $ 875.00 $ 7.000.00 RAMP PER CALTRANS STD. PLAN RSP A88A OR RSP A88B. C-2.4 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 13 14 EXISTING SLOPE, RELOCATING 600 SF $ 9.50 $ 5,700.00 IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 14 15 STAMPED CONCRETE PER HB 50 LF $ 47.00 $ 2,350.00 STD PLAN 711. 15 MOBILIZATION 1 LS $ 2,01000 $ 101 DO 16 TRAFFIC CONTROL PLAN 1 LS $ 1,040.00 $1,040.00 17 FURNISH PROJECT TRAFFIC 1 LS $ 1;00 $ D CONTROL 18 FURNISH AND INSTALL SIGNING 1 LS $ 11,000 $ 9,11000 AND STRIPING 19 PROJECT SPECIFIC SWPPP 1 LS $ 3,640.00 $ 3,640.00 FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY 20 APPROVED EQUAL COATING 2 LS $ SI- $ ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ LAU `l, Total Amount Bid in Words: fnw 4vvoW C-2.5 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 TALBERT AVENUE REHABILITATION FROM GOTHARD STREET TO NEWLAND STREET CC NO. 1527 C-2.6 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantitv Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). (INCLUDES ALL 1 1 APPURTENANCES, CURB 16 EA $ 300 $ 52,�00 GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT OAT FIBER REINFORCED ASPHALT 2 3 RUBBER HOT MIX(ARHM GG- 5,700 TN $ $0.00 $ 'ASU1000 Cl/2-'PG 64-16)WET PROCESS OVERLAY. ADJUST SEWER MANHOLE TO 3 4 GRADE. 21 EA $ 765.00 $ 16,065.00 ADJUST STORM DRAIN 765.00 6,665.00 4 5 MANHOLE TO GRADE. 9 EA $ $ REPLACE WATER VALVE BOX 5 6 ASSEMBLY AND ADJUST TO 60 EA $ 615.00 $ 48,900.00 GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 6 8 PAVEMENT TO A DEPTH OF 440,020 SF $ 0.13 $ 57,202.60 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 7 8 A.C. BASE COURSE OVER 95% 5,700 TN $ 63.50 $ 361,950.00 COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. INSTALL TRUNCATED DOMES TO EXISTING CURB ACCESS 8 10 RAMP AS REQUIRED PER 2 EA $ 675.00 $ 1,750.00 CALTRANS STD. PLAN RSP A88A. C-2.7 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). (INCLUDES SLOT PAVEMENT, 9 11 AGGREGATE BASE, LOT 245 LF $ 50.00 $ 1z,250.00 DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 10 12 EXISTING SLOPE, RELOCATING 6,300 SF $ S•S $ 3q .kp5D IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DEEPENED CURB AND GUTTER PER HB STD. PLAN 202(B) (CF=8"). (ITEM INCLUDES 11 13 REBAR, CLASS 560-C-3250 60 LF $ 99.00 $ 5,940.00 CONCRETE, SLOT PAVEMENT, .AGGREGATE BASE, AND LOT DRAIN IF PRESENT.) REMOVE AND RECONSTRUCT 12 14 DRIVEWAY CURB SECTION AS 45 LF $ 39.50 $ 1,777.50 MODIFIED PER DETAIL ON SHEET 5. REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP AND ROOTS TO 24" BELOW TOP as0.0o 3,220.00 13 15 OF SIDEWALK/GRADE. PULL 7 EA $ $ OUT ALL ROOTS WITHIN PROPOSEDIMPROVEMENTS. C-2.8 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 14 16 SIGNALS AND LIGHTING 61 EA $ 210.00 $ 12,810.00 SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE EXISTING RETAINING WALL WITHIN CITY RIGHT-OF- WAY AND CONSTRUCT NEW RETAINING WALL (OPTION 2) BEHIND CITY RIGHT-OF-WAY PER HB COMMUNITY DEVELOPMENT BUILDING DIVISION STD PLAN NO. 3 AND 15 17 DETAIL ON SHEET 5. (ITEM 1 LS $ M $ INCLUDES EXCAVATION AND/ OR BACKFILL, RE-GRADING, RELOCATING EXISTING IRRIGATION, RETURNING LANDSCAPE BEHIND WALL TO PRE-CONSTRUCTION CONDITIONS AND ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE.) REMOVE AND RECONSTRUCT LOCAL DEPRESSION PER HB STD PLAN 302. (INCLUDES SLOT 1s 18 PAVEMENT, AGGREGATE BASE, 180 SF $ 16.50 $ z,s�o.00 AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN G 17 19 205. (ITEM INCLUDES SLOT 41380 SF $ �to.1.G $ PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.9 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) LBid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount 18 MOBILIZATION 1 LS $ .3 000 $ 32�Abu 19 TRAFFIC CONTROL PLAN 1 LS $ 1,050.00 $ 1,050,00 FURNISH PROJECT TRAFFIC 20 CONTROL 1 LS $ 25,300.00 $ 25,300.00 21 FURNISH AND INSTALL SIGNING 1 LS $ 5 oto $ AND STRIPING 22 PROJECT SPECIFIC SWPPP 1 LS $ 4,200.00 $4,200.00 Total Amount Bid in Figures: $ `Z 5 Total Amount Bid in Words ��Q,, . . ,`......... ................................ ........... �, -QALLwa"&N�w J6 C-2.10 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 HEIL AVENUE REHABILITATION FROM EDWARDS STREET TO GOLDENWEST STREET CC NO. 1527 C-2.11 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 1 1 (INCLUDES ALL 9 EA $ _ $ ZGt �00 APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16)WET PROCESS 2 3 OVERLAY PER TYPICAL 1,970 TN $ SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 1 EA $ 765.00 $765.00 GRADE. ADJUST OCSD MANHOLE TO GRADE PER OCSD STD. PLAN S 053, S-054 AND S-055. 765.00 3,825.00 4 5 CONTRACTOR TO 5 $ $ COORDINATE WITH MIKE BOLSTER AT(714) 593-7645. ADJUST STORM DRAIN 765.0o 765.00 5 6 MANHOLE TO GRADE. 1 EA $ $ REPLACE WATER VALVE BOX 6 7 ASSEMBLY AND ADJUST TO 10 EA $ 820.00 $ 8,200.00 GRADE PER HB STD PLAN 612. C-2.12 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount COLD MILL EXISTING A.C. 7 8 PAVEMENT TO A DEPTH OF 153,310 SF $ 0.21 $ 32,195.10 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED A.C. BASE COURSE OVER 95% 69.00 135,930.00 8 8 COMPACTED SUBGRADE PRIOR 1,970 TN $ $ TO 0.17'ARHM OVERLAY, PER PLANS. REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 9 10 205. (ITEM INCLUDES SLOT 1,730 SF $ 1875 $ 32,437.50 PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 10 11 (INCLUDES SLOT PAVEMENT, 1,100 LF $ C)J'G5 $� AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS (p31305 NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 11 12 EXISTING SLOPE, RELOCATING 10,100 SF $ ln•?� $ �03T IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.13 REVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ .r'Jd GRADE FROM WALK TO EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/ RESIDENTIAL DRIVEWAY("W"AND TYPE 12 14 SHOWN ON PLAN) PER STD 1,040 SF $ 16.50 $ 17,160.00 PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC SIGNALS AND LIGHTING 22 EA $ 210.00 $ 4,620.00 13 15 SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP AND ROOTS TO 24" BELOW TOP 470.00 6,580.00 14 16 OF SIDEWALK/GRADE WITHIN 14 EA $ $ PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) LBid Const. Contract Unit Extended No• Note Description Quantity Unit Price Amount ISAWCUT AND REMOVE EXISTING SIDEWALK AT EXISTING AND CONSTRUCT TREE WELL WITH SIDEWALK PER DETAIL ON SHEET 3. (ITEM INCLUDES REMOVAL OF 625.0o $ 2,soo.00 SIDEWALK, 6LF OF NEW 4 EA $ SIDEWALK, NON-CHEMICAL WEED CONTROL BARRIER TO BE DUPONT LANDSCAPE MAX OR AGENCY APPROVED EQUAL AND MULCH. 16 MOBILIZATION 1 LS $ 24,000 $ 11PIM 17 TRAFFIC CONTROL PLAN 1 LS $ 1,050.00 $ 1,050.00 18 FURNISH PROJECT TRAFFIC 1 LS $ 17,800.00 $ 17,800.00 CONTROL 19 FURNISH AND INSTALL SIGNING 1 LS $ 0 $196m AND STRIPING 20 PROJECT SPECIFIC SWPPP 1 LS $ 4,175.00 $ 4,175.00 FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY rr,, 21 APPROVED EQUAL COATING 4 LS $ ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ .UD Total Amount Bid in Words: C-2.15 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class DIR Dollar % of Item(s) Subcontractor License Number Amount Contract Number JM 1P22 q-l�►e, PO �vi� z ;1 1 t01 l0ooa(s�7 ins t� t$ PCB Z 21 3" U M b t LOTA ,D 0 3 Z ca� l00000st�� : Z° San GOYA 2= 22 5�q1 �r' 1311°1-7 P 10000034ZIS V[Mb 0.7090 �1 SM. T QeC�(� l °?• 2:• � I'{' a3g C ,IC4t a (44W NO 1000001(#10 42,7,WD CA- By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on 7/26/16 , at ORANGE CA Date City State STEVE MENDOZA , being first duly sworn, deposes and says that he is SECRETARY of R.J. NOBLE COMPANY the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. R.J. NOBLE COMPANY Name of Bidder X Signature of Bidder STEVE MENDOZA, SECRETARY 15505 E. LINCOLN AVENUE, ORANGE, CA 92865 Address of Bidder C-4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 - - .ti`E'.FxQe�.>".f�`.��Et>',L'<)�A.cKS�y^nC�•n�.-.n�tr��vo`1+��ct s�e—t-,c�R.sal`.L�Y'�.GCvL`ESL�eES�.til7iGYCSvs A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of ORANGE ) On 07/26/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persons} whose names} Ware- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/her/their authorized capacity(ies}, and that by his/her/th&signature(s}on the instrument the person(s); or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. J. DE IONGH WITNESS my hand and offici eal. Commission #2128504 z ;-m Notary Public -California z Z ' Orange County ' Signature My Comm. Expires Oct 28,2019 Signature to blic J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑Corporate Officer — Title(s): ❑Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑General ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02014 National Notary Association - www.NationaiNotary.org• 1-800-US NOTARY(1-800-876-6827) Item#5907 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the MAIN STREET REHABILITATION, TALBERT AVENUE REHABILITATION AND HEIL AVENUE REHABILITATION, PROJECT CC-1527, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. R.J. NOBLE COMPANY Contractor By U STEVE MENDOZA, SECRETARY Title Date: 7/26/2016 C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes ® No If the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. R.J. NOBLE COMPANY Contractor X o By ® (/ STEVE MENDOZA, SECRETARY Title Date: 7/26/2016 C-7 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: R.J. NOBLE COMPANY Bidder Name 15505 E. LINCOLN AVENUE Business Address ORANGE CA 92865 City, State Zip 714 ) 637-1550 Telephone Number 782908 CLASS A & C-12 State Contractor's License No. and Class AUGUST 2000 Original Date Issued AUGUST 31, 2016 Expiration Date The work site was inspected by STEVE MENDOZA of our office on 07/20 , 2016 . The following are persons, firms, and corporations having a principal interest in this proposal: R.J. NOBLE COMPANY A CALIFORNIA CORPORATION C-8 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. R.J. NOBLE COMPANY Company Name x ZWA- 41— Signature ofAidderU STEVE MENDOZA, SECRETARY Printed or Typed Signature Subscribed and sworn to before me this 26THday of JULY 2016 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of CALIFORNIA ) County of ORANGE ) On 07/26/2016 before me, J. DE IONGH, NOTARY PUBLIC Month, Day, and Year Insert Name and Title of Notary personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person)'whose nameXis/afe subscribed to the within instrument and acknowledged to me that he/shw/xhey�executed the same in his/ ff/1-heir authorized capacity(:ip�, and that by his/herAheir signatures) on the instrument the person4sr or the entity upon behalf of which the person( )'acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. J. DE IONGH WITNESS my hand and official seal. Commission #2128504 Z .�� Notary Public -California D Z ' )^ange County j' xPires Oct 28,2019 t Signature x Signature of otary Public (PLACE NOTARY SEAL ABOVE) J. DE IONGH C-9 Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work, specifically referencing the construction of {Describe specific work and experience necessary for project. For example, "Sanitary sewer line installation of at least of 1,000 of 8-inch and greater in public right-of-way. Sanitary sewer lift stations of similar size, proiect work within public streets, an area containing high ground water and pipeline construction in high ground water regions with trench depths of 8-feet to the invert."}. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: I. WALT DISNEY IMAGINEERING, 1401 FLOWER STREET,GLENDALED,CA 91221 Name and Address of Public Agency Name and Telephone No. of Project Manager: KENNETH DENSKI 714-284-6342 $4.1 MILLION GRADING, PAVING,STORM DRAINAGE AUGUST 2010 Contract Amount Type of Work Date Completed Provide additional project description to show similar work: WALT DISNEY IMAGINEERING SP-9 PARKING FACILITY GRADING&PAVING PARKING LOT RECONSTRUCTION WITH UNDERGROUND STORM DRAINAGE SYSTEMS INSTALLED 2. CITY OF TUSTIN, 300 CENTENNAIL WAY,TUSTIN,CA 92780 Name and Address of Public Agency Name and Telephone No. of Project Manager: BENNY TENKEAN 714-573-3161 $22.6 MILLION ROAD RECONSTRUCTION WITH STORM DRAIN IMPTS APRIL 2014 Contract Amount Type of Work Date Completed Provide additional project description to show similar work: TUSTIN RANCH ROAD RECONSTRUCTION WITH STORM DRAIN IMPROVEMENTS 3. CITY OF TUSTIN,300 CENTENNIAL WAY,TUSTIN,CA 92780 Name and Address of Public Agency Name and Telephone No. of Project Manager: BENNY TENKEAN 714-573-3161 $15.1 MILLION ROAD RECONSTRUCTION WITH STORM DRAIN IMPTS APRIL 2014 Contract Amount Type of Work Date Completed Provide additional project description to show similar work: BARRANCA ROAD RECONSTRUCTION WITH STORM DRAIN IMPTS C-10 Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager, and Superintendent. For each of these critical positions, please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project. Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. l. KORI PORTER, PROJECT MANAGER Name of proposed Project Manager Telephone No. of proposed Project Manager: 714-637-1550 ExT 359 CITY OF ORANGE,ANNUAL PAVEMENT MAINTENANCE$2.8 MILLION CLASS A WORK FEBRUARY 2014 Project Name & Contract Amount Type of Work Date Completed CITY OF COSTA MESA,2012-2013 STREET REHAB CITY PROJECT 13-01 $3.6 MILLION CLASS A WORK SEPT 2015 Project Name & Contract Amount Type of Work Date Completed CITY OF IRVINE,JAMBOREE ROAD PAVEMENT REHAB$1.1 MILLION CLASS A WORK FEBRUARY 2014 Project Name & Contract Amount Type of Work Date Completed 2. CHUCK SPIERS,GENERAL SUPERINTENDENT Name of proposed Superintendent Telephone No. of proposed Superintendent: 714-743-1383 CITY OF RIVERSIDE, MINOR STREET MAINTENANCE PHASE 1 $2.6 MILLION CLASS A WORK OCTOBER 2015 Project Name & Contract Amount Type of Work Date Completed COUNTY OF ORANGE,AC OVERLAY RESURFACING$5 MILLION CLASS A WORK MARCH 2O14 Project Name & Contract Amount Type of Work Date Completed CITY OF TUSTIN,ARMSTRONG AVE&WAGNER AVE$10 MILLION CLASS A WORK SEPTEMBER 2015 Project Name & Contract Amount Type of Work Date Completed C-11 CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)), passed by the California State Senate on June 20, 2014, established a new public works Contractor Registration Program, which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July 1 through June 30 state fiscal year) with the California Department of Industrial Relations (DIR). Currently the annual non-refundable registration fee for Contractors is $300. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT SHEET on SB 854 http://www.dir.ca.gov/DLSE/PublicWorks/SB854FactSheet 6.30.14.pdf DIR's Contractor Registration Link—Call (844) 522-6734 https:Hefiling.dir.ca.gov/P WCR/ActionServlet?action=displayP WCRegistrationForm DIR's Contractor Registration searchable database: https://efiling.dir.ca.gov/PWCR/Search.action I am aware and will comply with the provisions of Labor Code Section 1771.1(a) which states: "A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded." I furthermore will comply by providing proof of registration with DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. R.J. NOBLE COMPANY Contractor X By U STEVE MENDOZA,SECRETARY Title Date: 7/26/2016 DIR#: 1000004235 C-12 ti a Public Works Contractor(PWC)Registration Search 8' a n` rnl 110 aaWq W cwnm aro acaw PWc rogblrnwaR Pauaam to Dmaon 2.Pan 7.cnaWx I aommgRemo wNm:aom mo o111w caororma ueor coq.3 ' �a•rareastx±E•eam uaana+p aaaar xvw r•yc•r•aP�nnrxa ronvacwls�marcuwro>avaars. "�- � . - R.plabeuon r••r. �caumm F•cmv.,r 2O1611y�v " PWC RapiaVaOon Number: •aamPla:1234587890 Conboctor Lapel Nemo: JR.J.NOBLE COMPANY Contractor license sokup LIc•ane Nu mb•r. saaIVW:123656 county:Hebet County �v� ' , Ermnac Esser I-�,7 PCP S. Om re kstere s Om rep§NBeO comnctor rouRO.t WWI$Legal Nanro RaWaratbn,.County :11 -.R•WWauen 601allon Number DMs Deb Vlew R.J.NO818 COMPANY IONW4235 ORANGE ORANGE 06/16/2016 06/30/2012 .... Q2D160101 v z State Of Callfomia W-2-I .CONTRACT DIVE STATE UCENSE BOARD <:o"am AIr„la I -N,.1.,T829O8 «.CORP A�Iti�Nlitts R J NOBLE COMPANY orMrrwu A C 12 &~o. 08/3112016 www.cslb.ca.gov Ara diviV d bAness adder mum be reported ilo da Re mm etlMr 90 den TMe lle"m is net trarMemable,and WM be nftmad to to Reglepar Upon dwmnd whan suapandadr revoked.or Invabilismed for any resew. TWO poeket eerd to VOW through Vo expintlar dete only. It Pound,drop in any mailbwc Podnpe guerenteed by. ConE KVm Stain Lioenee Board P.O.BOX: SeereMMID CA 95828 Licensee Signature STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycle) RELIABLE CONTRACTOR DECLARATION CalRecycle 168(Revised 7/13) This form must be completed and submitted to the Department of Resources Recycling and Recovery(CalRecycle) prior to authorizing a contractor(s) to commence work. Failure to provide this documentation in a timely manner may result in nonpayment of funds to the contractor(s). This form is intended to help the CalRecycle's Grantees comply with the Unreliable List requirement of their Terms and Conditions. The Unreliable List provision requires the following: Prior to authorizing a contractor(s) to commence work under the Grant, the Grantee shall submit to CalRecycle a declaration signed under penalty of perjury by the contractor(s) stating that within the preceding three (3) years, none of the events listed in Section 17050 of Title 14, California Code of Regulations, Natural Resources, Division 7, has occurred with respect to the contractor(s). Please see the reverse of this page,or refer to www.calregs.com If any of the events listed in Section 17050 have occurred, disclosure is required but will not necessarily result in CalRecycle refusing to approve the contractor. A signed statement explaining the facts and circumstances of the events must be attached to and submitted with this form. Contractor: Complete the form and send original to the Grantee. Grantee: Scan the form and upload it to the grant in CalRecycle's Grant Management System (GMS). For further instruction about logging into GMS and uploading this form, reference the Procedures and Requirements. Retain the original form in your grant file. GRANTEE INFORMATION GRANTEE NAME: GRANT NUMBER: City of Huntington Beach TRP5, Grant ID 17197 PRIMARY CONTACT NAME: Thomas Herbel, City Engineer, 714-375-5077 CONTRACTOR INFORMATION CONTRACTOR NAME: R.J. NOBLE COMPANY AUTHORIZED CONTRACTOR REPRESENTATIVE NAME: STEVE MENDOZA, SECRETARY MAILING ADDRESS: P.O. BOX 620, ORANGE,CA 92865 As the authorized representative of the above identified contractor, I declare under penalty of perjury under the laws of the State of California that within the preceding three (3)years, none of the events listed in Section 17050 of Title 14, California Code of Regulations, Natural Resources, Division 7, has occurred with respect to the above identified contractor. Alternatively, as the authorized representative of the above identified contractor, I declare under penalty of perjury under the laws of the State of California that within the preceding three (3)years, if any of the events listed in Section 17050 of Title 14, California Code of Regulations, Natural Resources, Division 7, has occurred with respect to the above identified contractor, I have disclosed all such occurrences in an attached signed statement that explains the facts and circumstances of the listed events. Signature X r Date 7/26/2016 STEVE MEI�}DOZA, ECRETARY ((// C-13 STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycle) RELIABLE CONTRACTOR DECLARATION CalRecycle 168(Revised 7/13) Title 14 CCR,Division 7,Chapter 1 Article 5.Unreliable Contractors,Subcontractors,Borrowers and Grantees Section 17050. Grounds for Placement on Unreliable List The following are grounds for a finding that a contractor, any subcontractor that provides services for a CalRecycle agreement, grantee or borrower is unreliable and should be placed on the CalRecycle Unreliable Contractor, Subcontractor, Grantee or Borrower List ("Unreliable List"). The presence of one of these grounds shall not automatically result in placement on the Unreliable List. A finding must be made by the Executive Director in accordance with section 17054, and there must be a final decision on any appeal that may be filed in accordance with section 17055 et seq. (a) Disallowance of any and/or all claim(s)to CalRecycle due to fraudulent claims or reporting;or (b) The filing of a civil action by the Attorney General for a violation of the False Claims Act,Government Code section 12650 et. seq;or (c) Default on a CalRecycle loan,as evidenced by written notice from CalRecycle staff provided to the borrower of the default;or (d) Foreclosure upon real property loan collateral or repossession of personal property loan collateral by CalRecycle;or (e) Filing voluntary or involuntary bankruptcy,where there is a finding based on substantial evidence,that the bankruptcy interfered with the CalRecycle contract,subcontract,grant or loan;or (f) Breach of the terms and conditions of a previous CalRecycle contract,any subcontract for a CalRecycle agreement, grant,or loan,resulting in termination of the CalRecycle contract,subcontract,grant or loan by the CalRecycle or prime contractor;or (g) Placement on the CalRecycle's chronic violator inventory established pursuant to Public Resources Code section 44104 for any owner or operator of a solid waste facility;or (h) The person,or any partner,member,officer,director,responsible managing officer,or responsible managing employee of an entity has been convicted by a court of competent jurisdiction of any charge of fraud,bribery,collusion, conspiracy,or any act in violation of any state or federal antitrust law in connection with the bidding upon,award of,or performance under any CalRecycle contract,subcontract,grant or loan;or (i) The person or entity is on the list of unreliable persons or entities,or similar list,of any other federal or California state agency;or Q) The person or entity has violated an Order issued in accordance with section 18304;or, (k) The person or entity has directed or transported to,has or accepted waste tires at,a site where the operator is required to have but does not have a waste tire facility permit;or, (1) The person or entity has transported waste tires without a waste tire hauler registration;or, (m) The person or entity has had a solid waste facility or waste tire permit or a waste tire hauler registration denied, suspended or revoked;or, (n) The person or entity has abandoned a site or taken a similar action which resulted in corrective action or the expenditure of funds by CalRecycle to remediate,clean,or abate a nuisance at the site;or (o) The following are additional grounds for a finding that,a person or entity described below should be placed on the Unreliable List: (1) The person or entity owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (2) The person held the position of officer director,manager,partner,trustee,or any other management position with significant control(Principal Manager)in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (3) The entity includes a Principal Manager who: 1. Was a Principal Manager in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (4) The entity has a person who owns 20%or more of the entity, if that person: I. Was a Principal Manager in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List. (5) The entity has another entity which owns 20%or more of the entity,if that other entity: I. Is on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List. (6) Subsection(o)is not intended to apply to a person or entity that purchases or otherwise obtains an entity on the Unreliable List subsequent to its placement on the Unreliable List. C-14 ODl Western Surety Company BID BOND (Percentage) Bond Number: N/A KNOW ALL PERSONS BY THESE PRESENTS, That we R.J. Noble Company of Orange, California hereinafter referred to as the Principal, and Western Surety Company as Surety, are held and firmly bound unto City of Huntington Beach hereinafter referred to as the Obligee, in the sum of h i 10 %) percent of the greatest amount bid, for the payment of which we bind ourselves, our legal representatives, successors and assigns,jointly and severally,firmly by these presents. WHEREAS, Principal has submitted or is about to submit a proposal to Obligee on a contract for Main Street,Talbert Avenue and Heil Avenue Rehabilitation, CC-1527 NOW, THEREFORE, if the said contract be awarded to Principal and Principal shall, within such time as may be specified, enter into the contract in writing and give such bond or bonds as may be specified in the bidding or contract documents with surety acceptable to Obligee; or if Principal shall fail to do so, pay to Obligee the damages which Obligee may suffer by reason of such failure not exceeding the penalty of this bond, then this obligation shall be void; otherwise to remain in full force and effect. SIGNED, SEALED AND DATED this 8 day of July 2016 R.J. Noble Company (Principal) By (Seal) ST E M DOZ , SECRETARY Western S afl S rety) By (Seal) Jam colt Saiandi Attorney-in-Fact Forth F5876 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness, accuracy,or validity of that document. State of California ) County of ORANGE ) On 07/11/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persons} whose names} is/are- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/hw/their authorized capacity(ie*, and that by his/her/their'signature(s}on the instrument the person(s); or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. J. DE IONGH - WITNESS my hand and offi se . Commission #2128504 Notary Public -California z Orange County D Signature My Comm. Expires Oct 28,2019 Signature qVNotary Public J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: []Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑Limited ❑ General ❑ Partner — ❑ Limited ❑General ❑Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02014 National Notary Association •www.NationaiNotary.org - 1-800-US NOTARY(1-800-876-6827) Item #5907 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange On July 8, 2016 before me, Lauren Emily Bierman, A Notary Public (insert name and title of the officer) personally appeared .lames Scott Salandi, Attorney-in-Fact who proved to me on the basis of satisfactory evidence to be the person(g)whose name(%) is/aR X subscribed to the within instrument and acknowledged to me that he/ Gt" executed the same in his/k;§W#mk authorized capacity(iesi), and that by his/higr tb(&signature( on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the i nstrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. �.�;or " LAUREN EMILY BIER MAN N �4 - COMM.#2097240 W .m ; NOTARY rUBLCtAUFORNIA : ORANGE COUNTY N MY COMM.EXF.JAN 16,2019 Signature 1 'u (Seal) Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents,That WESTERN SURETY COMPANY,a South Dakota corporation,is a duly organized and existing corporation having its principal office in the City of Sioux Falls,and State of South Dakota,and that it does by virtue of the signature and seal herein affixed hereby make,constitute and appoint James Scott Salandi, Leonard Ziminsky, David Jacobson, Individually of Irvine,CA,its true and lawful Attomey(s)-in-Fact with full power and authority hereby conferred to sign,seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney,pursuant to the authority hereby given,are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By-Law printed on the reverse hereof,duly adopted,as indicated,by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 16th day of June,2016. �,„Ma WESTERN SURETY COMPANY T.% Eryco _.1 1�•Di 1=s s*t�Sf aul T.Bruflat,Vice President State of South Dakota 1 JT ss County of Minnehaha On this 16th day of June,2016,before me personally came Paul T.Bruflat,to me known,who,being by me duly sworn,did depose and say: that he resides in the City of Sioux Falls,State of South Dakota;that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument;that he knows the seal of said corporation;that the seal affixed to the said instrument is such corporate seal;that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority,and acknowledges same to be the act and deed of said corporation. My commission expires 'i,46HR �NM S'a auauc� June 23,2021 � soumaixorn J.Mohr,Notary Public CERTIFICATE 1, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force,and further certify that the By-Law of the corporutton pri ted orr the reverse hereof is still in force. In testimony whereof I have hereunto subscribed m name and affixed the seal of the said co (`L ,y rp�ration this_ day of 4„M11Er WESTERN SURETY COMPANY a,�s\S fAbvYr` �yI,,TN pPKp "�wnw L.Nelson,Assistant Secretary Form F4280-7-2012 �s t LO OD {h Wy Q ,s U N s ZIT o � y O Z 6r r ry v Z N O "L W zW z z WK O Z WLO a� � s LO ra 9 , F J LU 2 °6 F- i � w 2 m U F- w m Z Z 00 Q 0 F- Z m z Q w a 1= Z w �0 E- w w Ln m Q Z Q o Q w o 0 1= m m - t ry � m 79/2/2016 E(MM/DD/YYYY) A`C" CERTIFICATE OF LIABILITY INSURANCE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACT PRODUCER Patriot Risk & insurance Services NAME, 100 Spectrum Center Drive, Suite#400 PHONE Ext: 949 486-7900 Fvc No: 949 486-7950 Irvine, CA 92618 E-MAIL ADDRESS: INSURER(S)AFFORDING COVERAGE NAIC# www.patrisk.com OK07568 INSURERA: Zurich American Insurance Company 16535 INSURED INSURER B: R. J. Noble Company, Inc. INsuRERc: 15505 Lincoln Avenue P.O. Box 620 INSURER D: Orange CA 92856-9020 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 31639308 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR IN POLICY NUMBER MM/DD/YYYY MM/DD/YYYY A ✓ COMMERCIAL GENERAL LIABILITY ✓ ✓ GLOO17436602 7/1/2016 7/1/2017 EACH OCCURRENCE $ 1,000,000 OCCUR DAMAGE TO RENTED CLAIMS-MADE ✓ PREMISES Ea occurrence $ 300,000 MED EXP(Any one person) $ 5,000 ✓ Contractual Liability PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY ✓� JEo LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY BAP017436702 7/1/2016 7/1/2017 COMBINED SINGLE LIMIT $ ✓ ✓ Ea accident 1,000,000 ✓ ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTYDAMAGE✓ $AUTOS ONLY ✓ AUTOS ONLY Per accident A UMBRELLA LIAB �/ OCCUR AUC017437202 7/1/2016 7/1/2017 EACH OCCURRENCE $ 10,000,000 ✓ EXCESS LIAB CLAIMS-MADE Policy Follows Form Over AGGREGATE $ 10,000,000 Underlying General Liab. DED RETENTION$ $ A WORKERS COMPENSATION ✓ WC017436302 7/1/2016 7/1/2017 STATUTE EORH AND EMPLOYERS'LIABILITY Y/N No Deductible for Workers ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBEREXCLUDED? N/A Compensation (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Re: RJN#91561 /Main Street Rehabilitation/Talbert Avenue Rehabilitation and Heil Avenue Rehabilitation City of Huntington Beach,its officers,elected or appointed officials,employees,agents and volunteers are named a nal Insure includes Primary&Non-contributory as respects to General Liability&Auto Liability per endorsemlamt� n contract. Waiver of subrogation applies to GL,Auto and Work and in favor of the additional insureds per attar ed en eme 30 days notice of cancellation, 10 days for non-payment of premium. MICHAEL E. GATES CERTIFICATE HOLDER CANCELLAfWM OF HUNTINGTON BEACH Cltyy of Huntington Beach SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 2000 Main Stret THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Huntington Beach CA 92648 AUTHORIZED REPRESENTATIVE Leonard E.Ziminsky ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD 31639308 1 16/17 - GL/AU/EXC/WC Annette Romero 1 9/2/2016 10:26:11 AM (PDT) I Page 1 of 6 Additional Insured — Owners, Lessees Or Contractors — ZURICH� Scheduled Person Or Organization Policy No. Eff. Date of Pol. I Exp. Date of Pol. I Eff.Date of End. Producer No. Add'I.Prem Return Prem. GLOO17436602 7/1/2016 7/1/2017 7/1/2016 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Named Insured:R.J. Noble Company,Inc. Address(including ZIP Code): 15505 Lincoln Avenue Orange CA 92856-9020 This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part SCHEDULE Name Of Additional Insured Person(s) Location And Description Of Covered Operations Or Organization(s) City of Huntington Beach,its officers,employees and agents and Volunteer e: RJN#91561 A. Section II — Who Is An Insured is amended to include as an insured the person or organization shown in the Schedule above, whom you are required to add as an additional insured on this policy under a written contract or written agreement. However, if you have entered into a construction contractor construction agreement with an additional insured person or organization shown in the Schedule of this endorsement, the insurance afforded to such additional insured only applies to the extent permitted by law. B. The insurance provided to the additional insured person or organization applies only to "bodily injury", "property damage" or"personal and advertising injury" covered under Section I — Coverage A— Bodily Injury And Property Damage Liability and Section I—Coverage B—Personal And Advertising Injury Liability, but only with respect to liability for"bodily injury", "property damage"or"personal and advertising injury"caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf, and resulting directly from your ongoing operations or"your work" as included in the "products-completed operations hazard", which is the subject of the written contract or written agreement at the Location designated and described in the Schedule above. C. However, regardless of the provisions of Paragraphs A. and B. above: 1. We will not extend any insurance coverage to any additional insured person or organization: U-GL-1177-E CW(04/12) Page 1 of 2 31639308 1 16/17 - cL/AU/EXC/WC I Anne[dncludes convridded material a insurartraServlcas Office.Inc..with its cermission. a. That is not provided to you in this policy; or b. That is any broader coverage than you are required to provide to the additional insured person or organization in the written contract or written agreement; and 2. We will not provide Limits of Insurance to any additional insured person or organization that exceed the lower of: a. The Limits of Insurance provided to you in this policy; or b. The Limits of Insurance you are required to provide in the written contract or written agreement. D. The insurance provided to the additional insured person or organization does not apply to: "Bodily injury", "property damage" or"personal and advertising injury" arising out of the rendering or failure to render any professional architectural, engineering or surveying services including: 1. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and 2. Supervisory, inspection, architectural or engineering activities. E. The following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV— Commercial General Liability Conditions: The additional insured must see to it that: 1. We are notified as soon as practicable of an"occurrence"or offense that may result in a claim; 2. We receive written notice of a claim or"suit"as soon as practicable; and 3. A request for defense and indemnity of the claim or "suit' will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured, if the written contract or written agreement requires that this coverage be primary and non-contributory. F. For the coverage provided by this endorsement: 1. The following paragraph is added to Paragraph 4.a.of the Other Insurance Condition of Section IV—Commercial General Liability Conditions: This insurance is primary insurance as respects our coverage to the additional insured person or organization, where the written contract or written agreement requires that this insurance be primary and non-contributory with respect to any other policy upon which the additional insured is a Named Insured. In that event, we will not seek contribution from any other such insurance policy available to the additional insured on which the additional insured person or organization is a Named Insured. 2. The following paragraph is added to Paragraph 4.b. of the Other Insurance Condition of Section IV—Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance, whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same"occurrence", offense, claim or"suit'. This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. All other terms and conditions of this policy remain unchanged. u-GL-»n-E Cw(04/12) Page 2 of 2 Includes copyrighted material of insurance Services Office,Inc.,with its permission. 31639308 1 16/17 - GL/AU/EXC/WC Annette Romero 1 9/2/2016 10:26:11 AM (PDT) I Page 3 of 6 R: J. Noble Company, Inc. POLICY NUMBER:GLO017436602 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: City of Huntington Beach,its officers,employees and agents and Volunteers Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV—Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products- completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 1 ❑ 31639308 16/17 - GL/AU/EXC/WC I Annette Romero 1 9/2/2016 10:26:11 AM (PDT) I Page 4 of 6 POLICY NUMBER:BAP017436702 COMMERCIAL AUTO CA20481013 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s) who are"insureds"for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured:R.J.Noble Company,Inc. Endorsement Effective Date:7/1/2016 SCHEDULE Name Of Person(s)Or Organization(s): City of Huntington Beach,its officers,employees and agents and Volunteers Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Each person or organization shown in the Schedule is an"insured"for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.I. of Section II — Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section 1 — Covered Autos Coverages of the Auto Dealers Coverage Form. CA 20 48 1013 0 Insurance Services Office, Inc., 2011 Page 1 of 1 Wolters Kluwer Financial Services I Uniform FormsTm 31639308 16/17 - GL/AU/EXC/WC I Annette Romero 1 9/2/2016 10:26:11 AM (PDT) I Page 5 of 6 WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 04 03 06 (Ed. 4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT- CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following"attaching clause"need be completed only when this endorsement is issued subsequent to preparation of the policy.) This endorsement, effective on 7i1i2016 at 12:01 A.M. standard time, forms a part of (DATE) Policy No. WC017436302 Endorsement No. Of the Zurich American Insurance Company (NAME OF INSURANCE COMPANY) issued to R.J. Noble Company, Inc. Premium (if any) $ �' r Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be % of the California workers' compensation pre- mium otherwise due on such remuneration. Schedule Person or Organization Job Description City of Huntington Beach,its officers,employees and agents and Volunteers Re:RJN#91561 WC 252(4-84) WC 04 03 06(Ed.4-84) Page 1 of 1 31639308 1 16/17 - GL/AU/EXC/WC I Annette Romero 1 9/2/2016 10:26:11 AM (PDT) I Page 6 of 6 UNCONDITIONAL WAIVER AND RELEASE ON PROGRESS PAYMENT (CALIFORNIA CIVIL CODE SECTION 8134, EFFECTIVE JULY 1, 2012) NOTICE TO CLAIMANT: THIS DOCUMENT WAIVES AND RELEASES LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL WAIVER AND RELEASE FORM. Identifying Information Name of Claimant: RJ NOBLE Name of Customer: MARK COMPANY Job Location: 261 CAMPUS DRIVE IRVINE CA 92612 li Owner: CAMPOS VERDES, LLC ! Through Date: 6/20/2016 l Unconditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the i claimant has for labor and service provided, and equipment and material delivered,to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, purusant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below.The claimant has received the following progress payment: 0.00 Exceptions This document does not affect any of the following: I (1)Retentions (2) Extras for which the claimant has not received payment. (3) Contract rights, including (A) a right based on rescission,abandonment,or breach of ; contract, and(B)the right to recover compensation for work not compensated by the payment. Signature Claimant's Signature: I Claimant's Title: ACCOUNTS RECEIVABLE ADMIN. Date of Signature: 9/6/2016 i i J iF f I JOB 8663 r RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) 0 , CITY OF HUNTINGTON BEACH • INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: A) 1 SUBJECT: Bond Acceptance I have received the bonds for (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) (y Performance Bond No. Payment Bond (Labor and Materials) Bond No. 73 (f-3 ,5-8 Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved (Council pproval Date) CC No. ��-�� Agenda Item No. < MSC No. City Clerk Vault No. Other No. SIRE System ID No. L !Z T g:/forms/bond transmittal to treasurer Bond No. 58738356 Executed in Duplicate PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS,City of Huntington Beach(hereafter referred to as"City")has, by written agreement dated entered into a contract with R.J.NOBLE COMPANY, 15505 E.LINCOLN AVENUE,ORANGE,CA 92865 (name and address of Contractor) (hereinafter referred to as"Principal"),for performance of the work described as follows: MAIN-TALBERT-HEIL STREET REHABILITATION PROJECT#CC-1527 (Project Title) WHEREAS, said contract, and all documents referenced therein (hereinafter collectively "Contract"), are incorporated herein by this reference made a part hereof as though set forth herein in full;and Said Principal is required under.lhe terms of the Contract to furnish a bond guaranteeing the prompt,full and faithful performance of said Contract, by a duly admitted surety insurer under the laws of the State of California(hereinafter referred to as"Surety");and Surety is certified and listed in the U.S. Department of the Treasury Circular 570,and has provided proof of sufficient bonding limitations as shown in said circular to provide bonds in the amount required by said Contract;and Surety has provided financial strength ratings from reputable companies,such as from A.M.Best,Moody's, or Standard&Poor's,to validate that Surety has positive ratings of being secure or Stable;and Surety is registered and listed with the California Department of Insurance, NOW,THEREFORE,we,the undersigned,as Principal,and Western Surety Company, 915_Wilshire Blvd.,Suite 1650,Los Angeles, CA 90017 (name and address of Surety) as Surety,are held and firmly bound unto City in the penal sum of two million three hundred eighty seven thousand one hundred thirty two&70/100 Dollars($ 2,387,132.70 ),this amount being not less than one hundred percent of the price set forth in the Contract,in lawful money of the United States,for the payment of which sum,well and truly to be made, we bind ourselves,our heirs,executors, administrators and successors,jointly and severally,firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the Principal shall promptly,fully and faithfully perform each and all of the covenants,obligations and things to be done and performed by the Principal in strict accordance with the terms of the Contract as said contract may be altered, amended or modified from time to time;and if the Principal shall indemnify and save harmless City and all of City's officers,agents and employees(hereinafter collectively referred to as"Obligees")fromany and all losses, liability and damages, claims,judgments,stop notices,fees and costs of every description,whether imposed by law or in equity, which may be incurred by the Obligees by reason of the failure or default on the part of the Principal in the performance of any or all of the terms or the obligations of the Contract,including all alterations,amendments and modifications thereto,and any warranties or guarantees required thereunder,then this obligation shall be void;otherwise,it shall be and shall remain in full force and effect. Surety stipulates and agrees,for value received,that no adjustment of the time or price in the Contract or any alteration,change,deletion,addition or other modification to the Contract, or the work to be performed thereunder,shall in any way affect,limit,restrict,impair or release the obligations of the Surety under this Bond. Surety waives notice of any adjustment of contract or contract price,and any other alteration,change, deletion,addition or other modification to the Contract, or the work to be performed thereunder,and agrees 1 5-4 5 94/1 1 71 74 Bored No. 58738356 Executed in Duplicate to automatically adjust the penal sum of this Bond to reflect such adjustments,alterations,changes, deletions,additions or other modifications. Surety agrees to provide written confirmation of such adjustments in the penal sum to City on not less than a quarterly basis. Surety also waives the provisions of Civil Code§§2845 and 2849. The obligations of this Bond shall survive the completion of the work described in the Contract as to all obligations and liabilities of the Principal which survive completion of the work. IN WITNESS WHEREOF,each party represents and warrants that this instrument has been duly executed by Principal and Surety,on the date set forth below,that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond,waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: September 1,2016 ATTEST R.J.NOBLE COMPANY (Corporate Seal) (Prind al Name) By:X Name: STEV ENDWA Title: SECRETARY ATTEST Western Surety Company (Corporate Seal) ur a BY: N es (Signature of Attorney-In-Fact for Surety) (Attach Atton,ey-ln-Fact Certificate) 866-404-7926 (Area Code&Telephone Number for Surety) APPROVED AS TO FORM: By: Michael E,Gates,City Attorney Ate' `' 3(^sF�. Note: This bond must be executed in duplicate and dated,al/signatures must be notarized,and evidence of the authority of any person signing as attorney-in-fact must be attached. PERFORMANCE BOND Page 2 of 2 15-q584/117174 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of ORANGE ) On 09/06/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the persons} whose name(sy is/-are- subscribed to the within instrument and acknowledged to me that he/she/they-executed the same in his/her/their authorized capacityoeo,and that by his/her/their•signature(oon the instrument the person(s); or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws J. DE IONGN of the State of California that the foregoing paragraph Commission#2128504 is true and correct. Z .-® Notary Public-California D WITNESS my hand and official se . Orange County My Comm. Expires Oct 28,2019 Signature Signat_urd f Notary Public J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages:. Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑General ❑ Partner — ❑ Limited ❑General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney In Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑ Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02014 National Notary Association -www.NationalNotary.org • 1-800-US NOTARY(1-800-876-6827) Item #5907 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange On September 1, 2016 before me, Lauren Emily Bierman, A Notary Public (insert name and title of the officer) personally appeared .lames Scott Salandi, Attorney-in-Fact who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/ape( subscribed to the within instrument and acknowledged to me that he/ lx" executed the same in his/k?§W& k authorized capacity(i*, and that by his/hotrAkek signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the i nstrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. �6�;°"NF, LAUREN EMILY BIERMAN N Z• ''� COMM.4 2097240 e NOTARY rU9LIC�CAIlFORNIA tY ORANGE COUNTY N Cann °4IF MY COMM,EXPJANfS,2019 Signature I l (Seal) Bond No.58738356 Executed in Duplicate PAYMENT SOLID (LABOR AND MATERIALS) KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, City of Huntington Beach(hereafter referred to as"City")has awarded to R.J.NOBLE COMPANY, 15505 E.LINCOLN AVENUE,ORANGE,CA 92865 (name and address of Contractor) (hereinafter referred to as"Principal'),a contract("Contract")for the work described as follows: MAIN-TALBERT-HEIL STREET REHABILITATION PROJECT#CC-1527 (Project Title) WHEREAS, Principal is required under the terms of the Contract and the California Civil Code to furnish a bond to secure the payment of claims of laborers,mechanics,materialmen,and other persons as provided by law, by a duly admitted surety insurer under the laws of the State of California (hereinafter referred to as "Surety"); and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and has provided proof of sufficient bonding limitation, as shown in said circular to provide bunds in the amount required by said Contract;and Surety has provided financial strength ratings from reputable companies,such as from A.M.Best,Moody's or Standard&Poor's,to validate that Surety has positive ratings of being secure or stable,and Surety is registered and listed with the California Department of Insurance. NOW THEREFORE,we,the undersigned Principal,and _ Western Surety Company,915 Wilshire Blvd.,Suite 1650, Los Angeles, CA 90017 (name and address of Surety) as Surely,are held and firmly bound unto City in the penal sum of two million three hundred eighty seven thousand one hundred thirty two&70/100 dollars($ 2,387,132.70 ),this amount being not less than one hundred percent(100%)of the total price set forth in the Contract,in lawful money of the United States of America,for the payment of which sum,well and truly to be made,we bind ourselves,and each of our heirs, executors,administrators,successors,and assigns,jointly and severally,firmly by these Presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT,if the Principal,his,her,or its heirs,executors, administrators,successors or assigns,or subcontractors shall fail to pay any of the persons named in Section 3181 of the California Civil Code("Claimants")for all labor,materials or services used or reasonably required for use in performance of the work described in the Contract,or any amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such Claimant,or prevailing wages due and penalties incurred pursuant to Sections 1774, 1775,1813 or 1815 of the Labor Code,or any amounts required to be deducted,withheld and paid over to the Employment Development Department from the wages of employees of the Principal and Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to the work or labor performed under the Contract, Surety will pay for the same: in an amount not exceeding the penal sum specified in this bond;otherwise,this obligation shall be null and void. This bond shall inure to the benefit of any of the persons named in Section 3181 of the California Civil Code so as to give a right of action to such persons or their assigns. In case any action is brought upon this bond, Surety further agrees to pay all court costs and a reasonable attorney's fee in an amount fixed by the court. PAYMENT BOND Page 1 of 2 154584/117357 Surety stipulates and agrees,for value received, that no change,extension of time,alteration, addition or modification to the terms of the Contract,or any contract document or any work to be performed thereunder,whether made after notice or not,shall in any way affect, impair or release the obligations of Surety under this bond. Surety hereby waives notice of any such change, extension of time,alteration;addition,or modification to the terms of the Contract,the contract documents or the work thereunder. Surety also waives the provisions of California Civil Code§§ 2845 and 2849. IN WITNESS WHEREOF,each party represents and warrants that this instrument has been duly executed by Principal and Surety,on the date set forth below,that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety,by execution of this bond,waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: September 1, 2016 ATTEST R.J.NOBLE COMPANY (Corporate Seal) (Principal Name) By:X Name: STEV ENDoAA Title:S ECRETARY ATTEST Western Suretv Com an (Corporate Seal) ( alma) By: mes Scott Salandi (Signature of Attorney-in-Fact for Surety) (Attach Attorney-in-Fact Certificate) 866-404-7926 (Area Code&Telephone Number for Surety) APPROVED AS TO FORM: By: Michael E.Gates,,City Attorney Note: This bond must be executed in duplicate and dated,all signatures must be notarized,and evidence of the authority of any person signing as attorney-in-fact must be attached. PAYMENT BOND Page 2 of 2 154584/117351 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness, accuracy,or validity of that document. State of California ) County of ORANGE ) On 09/06/2016 before me, J. DE IONGH, NOTARY PUBLIC Date Here Insert Name and Title of the Officer personally appeared STEVE MENDOZA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persons} whose name(s}is/are- subscribed to the within instrument and acknowledged to me that hefshefthey-executed the same in his/her/their authorized capacity(ies}, and that by his/her/their signature(s}on the instrument the person(s); or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. J. DE IONGH WITNESS my hand and official s a Commission #2128504 Notary Pubiic California v Orange county Signature My Comm.Expires Oct 28.2019 Signature otary Public J. DE IONGH Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signers) Other Than Named Above: Capacity(lies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑Corporate Officer — Title(s): ❑Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: 02014 National Notary Association •www.NationalNotary.org - 1-800-US NOTARY(1-800-876-6827) Item #5907 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange On September 1, 2016 before me, Lauren Emily Bierman, A Notary Public (insert name and title of the officer) personally appeared .lames Scott Salandi, Attorney-in-Fact who proved to me on the basis of satisfactory evidence to be the per whose name(s) is/aNx subscribed to the within instrument and acknowledged to me that he/ thy executed the same in his1N6W&6 t authorized capacity(isei), and that by his/hi§r Ni§Jt signature(s) on the instrument the person(x), or the entity upon behalf of which the person(s) acted, executed the i nstrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. F ���r LAURENEYILYBIERNAN COMM.9 2097240 X e: NOTARY NLfC- 0RNIA;0 1 ORANGE COUNTY N ^ r MY COMM.EXP.JAN 15,2019 Signature 1 ��/`� (Seal) Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents,That WESTERN SURETY COMPANY,a South Dakota corporation,is a duly organized and existing corporation having its principal office in the City of Sioux Falls,and State of South Dakota,and that it does by virtue of the signature and seal herein affixed hereby make,constitute and appoint James Scott Salandi, Leonard Ziminsky, David Jacobson, Individually of Irvine,CA,its true and lawful Attomey(s)-in-Fact with full power and authority hereby conferred to sign,seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney,pursuant to the authority hereby given,are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By-Law printed on the reverse hereof,duly adopted,as indicated,by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 16th day of June,2016. ,�asuaer> WESTERN SURETY COMPANY a............ p's �a?4ap0Aq��ty'� 4``rf A`!1p �rN DPµO APPaul T.Bruflat,Vice President State of South Dakota ss County of Minnehaha On this 16th day of June,2016,before me personally came Paul T. Bruflat,to me known,who,being by me duly swom,did depose and say: that he resides in the City of Sioux Falls,State of South Dakota;that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument;that he knows the seal of said corporation;that the seal affixed to the said instrument is such corporate seal;that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority,and acknowledges same to be the act and deed of said corporation. My commission expires J.MOHR NOTARYPUBUC� June 23,2021 SOUTH OWTA s J.Mohr,Notary Public CERTIFICATE I, L. Nelson,Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force,and further certify that the By-Law of the corporation printed on the reverse,lrereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this _day of )C42 e `n V)C Q. "arra. .......... WESTERN WESTERN SURETY COMPANY 'Ni4C� 'S)t1D': L.Nelson,Assistant Secretary Form F4280-7-2012 9/19/2016 Company Profile COMPANY PROFILE Company Profile Company Search Company Information Company Search Results WESTERN SURETY COMPANY Company 333 S. WABASH AVEMIE Information CHICAGO, IL 60604 Old Company Names Agent for Service Old Company Names Effective Date Reference Information Agent For Service NAIC Group List Vivian Imperial Lines of Business 818 WEST SEVENTH STREET Workers' SUITE 930 Compensation LOS ANGELES CA 90017 Complaint and Request for Action/Appeals Reference Information Contact Information Financial Statements NAIC #: 13188 PD F's Annual Statements California Company ID #: 0761-7 Quarterly Date Authorized in California: 07/29/1930 Statements Company Complaint License Status: UNLIMITED-NORMAL Company Company Type: Property &Casualty Performance & Comparison Data State of Domicile: SOUTH DAKOTA Company Enforcement Action Composite back to top Complaints Studies Additional Info NAIC Group List Find A Company Representative In Your Area NAIC Group #: 0218 CNA INS GRP View Financial Disclaimer Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary. LIABILITY SURETY back to top © 2008 California Department of Insurance https://i nteractive.web.i nsurance.ca.gov/com panyprofi letcom panyprofi le?event=com panyProfi le&doF uncti on=getCom panyProfi le&ei d=2977 1/1 CONTRACTOR'S SWORN STATEMENT AND WARRANTY REGARDING CONTINUING INSURANCE OBLIGATIONS FROM: R.J.NOBLE COMPANY PROJECT: MAIN-TALBERT-HEIL STREET REHABILITATION (Contractor Name) PROJECT CC-1527 15505 E.LINCOLN AVENUE (Street Address) ORANGE,CA 92865 (City,State and Zip) TO: CITY OF HUNTINGTON BENCH DECLARATION Attached hereto is a true and correct copy of the current Certificate of Insurance and Additional Insured Endorsement CG 2010 1185, which Certificate complies with the insurance requirements of the Contract by and between the City of Huntington Beach( City' and the above-named Contractor("Contractor's for the above-described project("Project'. I declare under penalty of perjury under the laws of the State of California that the above statement is true and correct. Signed on 09/06/2016 20_at 15505 E.LINCOLN AVENUE,ORANGE,CA 92865 (Date) (City,State) x (Signa re of n idual Who is Making Declaration) STEVE MENDO A,SECR ARY WARRANTY Contractor hereby warrants and agrees to maintain Products and Completed Operations Insurance in compliance with the insurance requirements of the Contract for the Project, Said insurance shall be maintained through and until the expiration of all Warranties provided by Contractor, Said insurance shall contain Additional Insured Endorsement CG 2010 1185, naming City as an additional insured. Contractor shall supply to City, on at least an annual basis, a Certificate of Insurance and the aforementioned Endorsement evidencing continued coverage which meets the Contract requirements. Signed on 09/06/2016 20_at 15505 E.LINCOLN AVENUE,ORANGE,CA 92865 (Date) (City, State) CONTPACTOR: Fume: R.J.NOBLE COMPANY By X Name: STEVE M DOZA Title;S Z77621.2 $ � C%j U f / \ \ Vk co ■ a $ 2 g D o a © z > & C k CL E � � At � � � ■ , � � IL � § z0 J$I§ § §�0� ■ ®§§2 immw /CLLƒ z z §/Z§ 2 \ o / 2LL m o tv 0 §m§$ 2 \ � � a w -\U)w $ 0 ° m z z c / k 0 n LLJglaz � / \a\� ��/R CITY OF HUNTINGTON BEACH PROJECT NAME: MAIN-TALBERT-HEIL -ST. REHABILITATION CC#: CC-1527 BID OPENING DATE: 7/26/2016 TIME & LOCATION: 2:00 PM @ COUNCIL CHAMBERS ENGINEER'S ESTIMATE: $2,670,000.00 BIDS SUBMITTED (AS READ AT OPENING) BIDDER'S NAME FINAL APPARENT BID RANK AMOUNT All American Asphalt Corona / 2 7,5"` 9„2 Excel Paving- Long Beach Hardy&Harper, Inc.-'Santa Ana / v Minco Construction-Gardena R.J. Noble Co-Orange ' , �g7 7?2 Ruiz Concrete And Paving Inc.- Long Beach YAKAR- Covina tti W / t PTS_07282015_Version_15_CC1527 City of Huntington Beach _ 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov "FF-T-- Office of the City Clerk Robin Estanislau, City Clerk September 29, 2016 RJ Noble Co - Orange Attn: Kori Porter 15505 E. Lincoln Avenue Orange CA 992856 Re: CC-1527 — MAIN/TALBERT/HEIL STREET REHABILITATION Enclosed for your records is a fully executed copy of the "City Funded Construction Contract between the City of Huntington Beach and R. J. Noble Company for Main Street, Talbert Avenue, Heil Avenue Rehabilitation Project— CC 1527" approved by the Huntington Beach City Council on August 15, 2016. Sincerely, Robin Estanislau, CIVIC City Clerk RE:pe Enclosure Sister Cities: Anjo, Japan ♦ Waitakere, New Zealand Dept. ID PW 16-050 Page 1 of Meeting Date: 8/15/2016 CITY OF HUNTINGTON BEACH , ,- REQUEST FOR. CITY COUNCIL ACTION MEETING DATE: 8/15/2016 SUBMITTED TO: Honorable Mayor and City Council Members SUBMITTED BY: Fred A. Wilson, City Manager PREPARED BY: Travis K. Hopkins, PE, Director of Public Works SUBJECT: Accept the lowest responsive and responsible bid and authorize execution of a construction contract with the R.J. Noble Company in the amount of $2,387,132.70 for the Main Street Rehabilitation, Talbert Avenue Rehabilitation, and Heil Avenue Rehabilitation Project, CC-1527 Statement of Issue: On July 26, 2016, bids were publicly opened for the Main Street Rehabilitation, Talbert Avenue Rehabilitation, and Heil Avenue Rehabilitation Project. City Council action is requested to award the construction contract to the R.J. Noble Company, the lowest responsive and responsible bidder. Financial Impact: Funds in the amount of $2,750,000 are budgeted in the General Fund Account No. 10040314.82800 ($1,000,000) and Measure "M" Account No. 21390025.82300 ($1,750,000). Reimbursement from the Cal Recycle Rubberized Asphalt Concrete (RAC) grant in the amount of $36,000 is anticipated. Recommended Action: A) Accept the lowest responsive and responsible base bid submitted by the R.J. Noble Company in the amount of $2,387,132.70; and, B) Authorize the Mayor and City Clerk to execute a construction contract in a form approved by the City Attorney. Alternative Action(s): Reject all bids, or provide staff with alternative action. Analysis: The project will rehabilitate Main Street (Garfield Avenue to Delaware Street), Talbert Avenue (Gothard Street to Newland Street), and Heil Avenue (Edwards Street to Goldenwest Street). The project segments were last rehabilitated in the 1990's. Rehabilitation methods include grinding out and replacing failed asphalt concrete with fiber reinforced asphalt concrete. Sewer and storm water manholes and water meter boxes and valves will be adjusted to grade. Areas of settled or raised curb, gutter, and sidewalk will be replaced as necessary. The project will utilize rubberized asphalt concrete (RAC) which contains crumb rubber derived from 100% California waste tire rubber. A two-inch layer of RAC uses over 2,000 waste tires per lane- HB -531- Item 4. - I Dept. ID PW 16-050 Page 2 of 2 Meeting Date: 8/15/2016 mile. The project will divert more than 12,000 waste tires that would otherwise end up in a landfill. Including this project, the use of RAC in the rehabilitation of the City's arterial streets has resulted in the diversion of over 283,000 waste tires. For this project, the City would obtain reimbursement through a Cal Recycle grant to offset some of the cost of RAC pavement. BIDDER'S NAME BID AMOUNT CORRECTED BID VERIFIED TOTAL (Amount Read at Bid CONTRACT AMOUNT Opening and Basis of Award) R.J. Noble Company $2,387,132.70 No Correction $2,387,132.70 All American Asphalt $2,675,692.00 No Correction $2,675,692.00 Excel Paving $2,672,633.00 +$36,000 $2,708,633.00 Hardy & Harper, Inc. $2,828,000.00 No Correction $2,828,000.00 The engineer's estimate for the project is $2,670,000. Staff recommends awarding a contract to the R.J. Noble Company in the amount of$2,387,132.70. The R.J. Noble Company has provided acceptable street rehabilitation construction in the past including the current Gothard Street rehabilitation project from Edinger Avenue to McFadden Avenue. The total project cost is estimated to $2,750,000, which includes the construction contract, project management, construction contingency, and supplementals (soils and materials testing, construction support, inspection services and additional engineering support by outside firms). Public Works Commission Action: The Public Works Commission reviewed and approved the project on June 15, 2016, with a vote of 6-0-1 (Lake-absent). Environmental Status: The project is categorically exempt pursuant to Class 1, section 15031 c of the California Environmental Quality Act. Strategic Plan Goal: Enhance and maintain infrastructure Attachment(s): 1. Project Location Map Item 4. - 2 HB -54- �o 'R� � �� � BOLSA AVE4n--- 3 NTS a v U Mc FADDEN AV U z c~n clan EDING-R, ? o OHEILm Q o AVE.cy- tr o w > cn Q WARNER � Q m AVE. N �SLATER o AVE. 05 O 1 CD TALBERT AVE. PACIFIC o 9 EL AVE. P� GARFI ELD� AVE. o � cf) cf) cf) cf) 4, YORKTOWN AVE. ~ cn ADAMS AVE. INDIANAPO IS AVE. PROJECT LOCATION qL o F-- F = � cn ro w TLA A AVE.= 0 Main St (Garfield Ave to Delaware St) m J m Y Q2 Talbert Ave (Gothard St to Newland St) HAM ILTON Oz AVE. 0 CDm 0 Heil Ave (Edwards St to Goldenwest St) BANNING OCEAN AVE. LEGEND ARTERIAL STREET LOCATIONS 06/06/16 FY 15/16 ARTERIAL REHABILITATION, CC- 1527 PROJECT LOCATION MAP CITY OF HUNTINGTON BEACH DEPARTMENT OF PUBLIC WORKS 1 of 1 HB -55- Item 4. - 3 CITY OF HUNTINGTON BEACH PROJECT NAME: MAIN-TALBERT-HEIL -ST. REHABILITATION CC#: CC-1527 BID OPENING DATE: 7/26/2016 TIME & LOCATION: 2:00 PM @ COUNCIL CHAMBERS ENGINEER'S ESTIMATE: $2,670,000.00 BIDS SUBMITTED (AS READ AT OPENING) BIDDER'S NAME FINAL APPARENT BID RANK AMOUNT oa ✓ All American Asphalt-Corona 37- Excel Paving- Long Beach 672. 33 ------------------------------ Hardy& Harper, Inc.- Santa Ana o Ada Minco Construction- Gardena R.J. Noble Co-Orange ' �o Ruiz Concrete And Paving Inca Long Beach YAKAR-Covina low PT5 07282015 Version 15 CC1527 2016 C, C73 C\-f (2 -7 2V NOTICE INVITING SEALED BIDS for the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites sealed bids for the above stated projects and will receive such bids in the office of the City Clerk, Second Floor, 2000 Main Street, Huntington Beach, California 92648, up to the hour of 2:00 PM on JULY 26, 2016. Bids will be publicly opened in the Council Chambers unless otherwise posted. On July 11, 2016, copies of the Plans, Specifications, and contract documents will be available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648, upon payment of a $28.00 nonrefundable fee if picked up, or payment of a $48.00 nonrefundable fee if sent by UPS ground delivery (bidder shall pay additional costs for special delivery). On July 11, 2016, Plans, Specifications, and contract documents can be downloaded free on AGENCY website. http://www.huntingtonbeachca.Qov/government/departments/public works/Bids/ Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are on file at the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648. The AGENCY will deduct 5% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the Public Contract Code, Section 10263. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. -1 The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders as determined by the AGENCY. The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State Contractor's License Class A at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. All extension of unit prices will be subject to verification by the AGENCY. In case of a variation between the unit price and the extension, the unit price will govern. Project Description: The project consists primarily of grinding the existing pavement, removal of failed roadway sections, asphalt concrete paving of failed areas, overlaying the streets with fiber reinforced asphalt concrete, and limited removal and installation of concrete curb and gutter, concrete sidewalk, cross-gutter, and curb access ramps. Sewer and storm drain manholes will be adjusted to grade and water meter boxes and valves will be replaced and adjusted to grade as necessary. The project includes installing traffic loops, signage, and striping. • The contract shall allow the Contractor 80 working days to complete the contract. • Talbert Avenue project shall be finished first before November 21, 2016. The AGENCY reserves the right to reject any or all bids, to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH, CALIFORNIA, the 8th day of September 2015, by Resolution No. 2015-47. Attest: /s/ Robin Estanislau CITY CLERK OF THE CITY OF HUNTINGTON BEACH -2 CITY OF HUNTINGTON BEACH PUBLIC WORKS DEPARTMENT 2000 Main Street P . O Box 1 90 Huntington Beach , CA 92648 LETTER OF TRANSMITTAL Fax (714) 374-1573 Attention: Robin Estanislau Date: June 29, 2016 To: City Clerk's Office Project/C.C. No.: CC No. 1527 2000 Main Street Regarding: MAIN STREET, TALBERT AVENUE AND Huntington Beach, CA 92648 HEIL AVENUE REHABILITATION ® We are sending you: ❑ By Mail ❑ By Fax Mail(Number of pages including this sheet:) ❑ We are hand delivering: ❑ Attached ❑ Under a separate cover via the following items: ❑ Shop drawings ❑ Prints ❑ Plans ❑ Samples ❑ Specifications ❑ Copy of letter ❑ Change Order ❑ Other: Item# Copies Pages Description 1 1 2 Notice Inviting Sealed Bids for CC No. 1527 MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION These are transmitted as checked below: ❑ For approval ❑ Approved as submitted ❑ Resubmit copies for approval ® For your action ❑ Approved as noted ❑ Submit copies for distribution ❑ As requested ❑ Returned for corrections ❑ Return corrected prints ❑ For reviewicomment ❑ Other: Remarks: Per Resolution 2015-47 (adopted on 9/8/15), the City Council authorized the advertisement of the above listed arterial rehabilitation project. Please find the attached Notice Inviting Sealed Bids for advertisement on 7/7/16, 7/14/16, and 7/21/16, The bid opening is scheduled for 7/26/16 at 2:00 PM in the City Council Chambers. If you have any questions regarding the enclosed attachment, feel free to contact me at jwagner surfcity-hb.org or(714) 536-5467, cc: file aJ James Wagner,PE,8en711vil Engineer HA Cut&Paste\NISB Transmital To Clerk.docx Esparza, Patty From: David Ward [DWard@ocregister.com] Sent: Wednesday, June 29, 2016 4:53 PM To: Esparza, Patty Subject: RE: Legal ad for the HB Wave- CC-1527 Glad to help! Your proof is below. Have a wonderful evening. Ad#10178435 Run Dates 7/7, 7/14, 7/21 Cost$675.00 PROOF 1 NOTICE INVITING SEALED BIDS far the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Nowland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO.1527 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEA92V OFVZN that the CITY OF HUNTINGTON BEACH,as AGENCY,invites sealed bids for the above slated projects and will receive such bids in the otf^.a of the City Clerk, Second Floor, 2000 f0ait Street, Hun:irigto:s Beach, Caldr-mia 92648. up to the hour of 2a00 Pfri on JULY 26, 201B. Biµs will :�e pua,Ilyly opened in the Council Charnbers unless otherwise posted. On July 11, 2016, copies of the Flans, SpecifcaGans• and adnt: wf documents will be available from the Office ci the Director of Public Works, 20-0�3 [.chin Street, Huntington Beach.CA 92648,upon payment of a$22LOO nonrefundzi.ble fee it picked up, or payment of a$4&00 ninnxalunda ire tea if seat by UPS ground delivery (bidder shall pay addltiornal costs for special deliveM. Or, July 11, 2MB, Plans. SC+ecificatio as, 9,7d contract docu- ments can be downloaded ire-3 on AGENCY wabsite_ f1t1p:;,'�s,+rv_Flu.rttingtCnbe3chC2,C�ov,�r�veLrimen�;deparimcritsrpublic worlsfds; Any contract entered into pursuant to 1.11is notice will incorporate the provisions of the State Labor Cade. Pursuant to the provisions of fine Labor Code al the State of California, the minimum prevailing rate of per dvi ,,wages tar each craft, classification or type of tivorkmar nee-ded iL execute the contract shall be those de?lermined by the Ditecttr of InCuVuial Se- latfons of the State of California, which arL an file at the OMi]ce of the Director of Pr-brie Works.2000 Main Street, Huntincton Beach, CA 92648, Tt;e AGENCY wl.l deduct 5% retention from nd pr'ogr2,s pa',merrtS. The Car-tractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the Public Contract Code. Sec41'on i(?;6?. Tne Contractor shall be bene,icial awraer of ire surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be ai:ord- ed full opportunity to subrnit birds in response to this nct:ce and will not be discriminated against on the basis of rate,color, national origin., ancestry, sex, or religjon in any consid- eration leading to the award of comraci. No bid shalt be considered unless ii is prepared an the aroroyed Proposal forms in con- formance.vita tho lnstrictions to Bidders as determined by the AGENCY. The bid must be accbm;.anled by a cenified c.t:eck• .cashiea'3 cttecik,or biddea's bond made parable to the AGc&,GY for an arnourt Tio, less Shan 1f7 of the arnount t)id. The successful biddier shall be Incensed m aci:cnrdance with aiovi4ons of the Business arid Professtins Code and shall possess a Stale Gontractor's License Class A at One irme of the bid openinq. The success- ful Contractor and his sutpertaactors oiil be requfred to possess business licenses from the AGENCY.All exta lion of unit prices will be subject to verdi cation lay the AGENCY_ In case of a varation betweij�:-the 4init price and the extension,the unit price will govern. Project Description: The prr:ject cons;sls primarily of grindinq the exisigriq pavernef:t. removal of failed roadway sectiains, asphalt concrete pa:nrq of lai=ed areas,oyerlayinq the streets milli %er reinforced asphalt corrcu,etE. and limitej removal and instal�atiDn of can- cfete curb and gutter, concrete sidewalk, amiss-qu,ter- and curb access ramps. Sewer ,�uid storm drain manholes will be a•dGjsted to grade and water meter boxes and va'Nes veil be replaced air-1 adjusted to grade as rece5sarv, The project includes insiallinq Iraffic loops,sit;na,qe,and striping_ e The contract shall allo.l the Contractor 80 workin!q cay's to complete;he Contras_ a Talbert Avenue project steali be finished trst before November 21.2016. Ine AGENCY reserves ta,e right to reject any or a.l bids_ to waive any irregularity and to take all bids urder advisement for a naaximurn period of 6o days. BY ORDEFI of the CITY CCIUNCIL cf the CITY OF i-WNTINGTON BEACH, CA.!tFCRNIA,ine Bth day of September 2015,by Resolution No.2015-47. Attest; .,is,;Robin Estanislau CITY CLERK OF THE CITY OF HUNTINGTON BEACH Published_The Huntington Beach Wave July 7,14,2%2016/0178435 2 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C- REVISED BID SCHEDULE (1 Sheet) Replace one page entitled "Project Bid Schedule—Heil (Edwards—Goldenwest) C- 2.14"with "Revised Project Bid Schedule— Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22" to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Number One, dated July 19, 2016. Company Name By Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at(714) 536-5467 within 24 hours of posting. REVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note. Description Quantity Unit Price.- j Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ $ GRADE FROM WALK TO EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/RESIDENTIAL DRIVEWAY ("W"AND TYPE 12 14 SHOWN ON PLAN) PER STD 1,040 SF $ $ PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC SIGNALS AND LIGHTING 13 15 SYSTEMS, 2005 EDITION. 22 EA $ $ SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP AND ROOTS TO 24" BELOW TOP 14 16 OF SIDEWALK/GRADE WITHIN 14 EA $ $ PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 AFFIDAVIT OF PUBLICATION Proof of Publication STATE OF CALIFORNIA, - " NOTICE INVITING SEALED BIDS ss. - - - for the construction of MAIN STREET REHABILITATION COUriIy Of Orange from Garfield Avenue to-Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to�Newland Street AND HEIL AVENUE REHABILITATION I am a citizen of the United States and a resident from Edwards Street to Goldenwest Street __CC;,NO..1527 of the Count aforesaid; I am over the age of in the' " Y g CITYIOF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY'G1VEN that the CITY OF HUNTINGTON BEACH,as eighteen years, and not a party t0 Or interested in AGENCY,invites sealed bids for the above stated projects and will receive such bids in the office of the City,Clerk, Second Floor,'2000 Main Street, Huntington Beach, California 92648,up to the hour of 2:00 PM,on JULY 26,2016. Bids will be publicly opened in the above entitled matter. I am the principal clerk the Council Chambers unless'otherwise posted: On July 11,2016,copies of the'Plans,Specifications,and contract documents will be of the Huntington Beach Wave, a newspaper available from the Office of the Director of Public Works, 2000 Main Street, Huntington Beach,CA 92648,upon payment of a$28.60_nonrefundable fee if picked up,or payment that has been adjudged to be a newspaper of of a$48.00 nonrefundable fee if-sent by UPS ground delivery(bidder"shall pay additional costs for sppecial delivery).On July 11,'2016,Plans,'Specifications,and contract docu- ments can be downloaded free on AGENCY website. - general circulation by the Superior Court of the hftp://www.huntingtonbeach6a.gov/governmenVdeparlments/pyblic_works/Bids/ Any contract entered into pursuant to this notice will incorporate the provisions of the State County of Orange, State Of California, On July 1> Labor Code. Pursuant to the provisions'of the Labor,Code of the State of California,the minimum prevailing rate of per diem wages for each craft,classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Re- 1998, Case No. A-185906 in and for the Cit Of lations of the State of California,which are on file at the Office of the Director of Public }� Works,'2000 Main Street,Huntington Beach,CA 92648:, llUntin ton Beach, Count of O e State Of The AGENCY will deduct 5%retention from all progress payments.'The Contractor may g y ran g substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the Public Contract Code;Section 10263. The Contractor shall be beneficial California; that the notice, Of which the annexed owner of the surety and shall receive any igterest thereon. The AGENCY hereby affirmative) ensures that minority business enterprises will be afford. is a true printed copy,has been published in each ed full opportunity to submit bids in�response,to this notice and will not be discriminated against on the basis of race,color,national origin,ancestry,sex,.or religion in any consid- eration leading to the award of"contract. regular and entire issue of said newspaper and iNo bid shall be considered"unless it is'prepared'on the-approved Proposal forms in con- formance with the Instructions to Bidders as determined by the AGENCY.The bid must be not in an SU lement thereof On the f011OWln accompanied by a certified check;cashier's check,or bidder's bond made payable to the y pp g ,AGENCY for an amount no less than 10%of.the-amount bid. The successful bidder shall Abe licensed in accordance with provisions of the Business and Professions Code and shall dates,t0 Wit: possess a State Contractor's License Class A at the time of the bid opening. The success- ful Contractor and his subcontractors will be required to possess,business licenses from the AGENCY.All extension of unit prices willbe subject to verification by the AGENCY. In case of a variation between the unit price and the extension,the unit price will govern. Project Description: The project consists primarily of grinding the existing pavement, July 7, 14,21,2016 removal of failed roadway sections,asphalt concrete paving of failed areas,overlaying the streets with fiber reinforced asphalt concrete,and limited removal and installation of con- crete curb and gutter, concrete sidewalk, cross-gutter, and curb access ramps. Sewer and storm drain manholes will*be adjusted to grade and water meter boxes and valves will be replaced and adjusted to grade,as necessary.The project includes installing traffic loops,signage,and striping. "I certify (Or declare) Under the penalty Of •The contract shall allow the Contractor 80 working days to complete the contract. o Talbert Avenue project shall be.finished first before November 21,2016. perjury under the laws Of the State of California The AGENCY reserves the right to reject"any or all bids,to waive any irregularity and to take all bids under advisement fora maximum period of 60 days. that the foregoing is true and correct": BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH,CALIFORNIA,the 8th day of September 2015,by Resolution No.2015.47. Executed at Santa Ana, Orange County, attest: " /s/Robin Estanislau California, On CITY CLERK OF THE CITY.OF HUNTINGTON BEACH July 21,2016 'ublished:The Huntington Beach Wave July 7,14,21,201610178435 - _ Signature Huntington Beach Wave 625 N.Grand Ave. Santa Ana,CA 92701 (714)796-2209 AFFIDAVIT OF PUBLICATION Proof of Publication STATE OF CALIFORNIA, ) SS. NOTICE INVITING SEALED BIDS' . for the construction of MAIN STREET REHABILITATION County Of Orange ) from Garfield Avenue to Delaware Street' TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street I am a citizen Of the United States and a resident HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street of the County aforesaid; I am over the age of _ CC NO.1527 '• in the, CITY OF HUNTINGTON BEACH eighteen years, and not a party to Or interested in PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH,as office AGENCY,invites sealed bids for the.above stated projects and will receive such bids H the oorthe above entitled matter. I am the principal clerk 92648,oup to the yhourrof 2e00 PMlon JULY 6 2000 ,2016et Bids Will benpublicly penednin the Council Chambers unless otherwise posted. of the Huntington Beach Wave, a newspaper On July 11,2016,copies of the Plans, Specifications,and contract documents will be available from the Office of the Director of Public Works,2000 Main Street, Huntington Beach,CA 92648,upon payment of a$28.00 nonrefundable fee if picked'up,or payment that has been adjudged to be a newspaper Of of a$48.00 nonrefundable fee if sent by UPS ground delivery(bidder shall pay additional costs for special delivery).On.July 11,201,6,-Plans, Specifications;and contract docul ments can be downloaded free on AGENCY website. general circulation by the Superior Court Of the http://www.hun.tingtonbeachca.gov/governmenUdepartments/public works/Bids/ Any contract entered into pursuant to�ihis•notice will incorporate the provisions of the State County of Orange, State Of California, on July 1, Labor Code. Pursuant'to the provisions of the Labor Code of the State of California,the minimum prevailing rate of per diem wages for each craft,classification or type of workman needed tO-execute the'contract shall be those determined by the Director of Industrial Re- 1998, Case No. A-185906 in and for the City Of lations of the State Of-California,which are on file at the Office of the Director of Public Works,2000 Main Street,Huntington Beach,CA 92648. Huntington Beach, Count of Orange, State of g y g The AGENCY will deduct holder retention from all progress payments. The Contractor may substitute an escrow holder Burety of equal value to the retention in accordance with the California; that the notice of Which the annexed provisions of the Public Contract Code;Section 10263. The Contractor shall owner of the surety and shall receive any interest,thereon. be beneficial is a true printed copy,has been published in each The AGENCY hereby affirmatively ensures that minority business enterprises will be afford- ed full opportunity to submit bids in response to this notice and will not be discriminated against on.the basis of rate,color,national origin,ancestry,sex,or religion in any ci a e regular and entire issue of said newspaper and eration leading to the award of contract. p No d shall'be'considered unless,it is . osal forms in con- o maince with the Instructions to Bidders as determined by approved AGENCY.The bid must be not in any Supplement thereof On the following accomppanied by a certified check;cashier's check,or bidder's bond made pa able to the AGENCY for an amount no.less than 10%of the amount bid. The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall dates,t0 wit: possess a State Contractor's License Class A"at the time of the bid opening. The and shall Contractor and his subcontractors Wilk be,required to possess business licenses from the AGENCY.All extension of unit prices will be subject to verification in the AGENCY. m case of a variation between the unit price and the extension,the unit price will govern. 'In July 7 14 21 2016 Project DescrlPtlon: The project-consists primarily of grinding the existing pavement, > > > removal of failed roadway sections,asphalt concrete paving of failed areas,overlaying the streets with fiber reinforced asphalt concrete„and limited removal and installation overlaying the curb and gutter, concrete sidewalk, removal and curb access ramps. of Sewer and storm drain manholes will be adjusted to grade'and water meter boxes and valves will bePepla9ed9and.adjusted to grade to The.project includes installing traffic loops,si na e,and striping. "I certify (Or declare) under the penalty Of e The contract shall allow the Contractor 80 working days to complete the contract. •Talbert Avenue project shall be finished:firat before November 21,2016.:, perjury under the laws Of the State Of California The AGENCY reserves the right to'reject any or all bids,to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. that the foregoing 1S true and correct": BY ORDER of the CITY COUNCIL of the CITY OF HUNTINGTON BEACH,CA 8th day of September 2015,by Resolution No.2015 LIFORNIA,the .47. Executed at Santa Ana, Orange County, Attest: California,On /s/Robin Estanislau CITY July 21,2016 Published:The Huntington Beach WaveOJuly 7 1CITY 1 21,2018 0178430N BEACH Signature Huntington Beach Wave 625 N.Grand Ave. Santa Ana,CA 92701 (714)796-2209 Wagner, James From: Wagner, James Sent: Tuesday, July 19, 2016 2:19 PM To: Esparza, Patty Cc: Whitely, Paul, Broussard, Todd Subject: MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION, Attachments: CC-1527 ADDENDUM 1 (07-19-16).pdf Good Afternoon Patty- Addendum 1 for CC-1527 was issued today 7-19-16. 1 will hand carry the addendum to you this afternoon. The bid closed 2 PM on Tuesday July 26, 2016. Thanks James Wagner, PE Public Works Dept., First Floor 2000 Main Street Huntington Beach, CA 92648 Direct 714-536-5467 1 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For MAIN STREET,TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C- REVISED BID SCHEDULE (1 Sheet) Replace one page entitled "Project Bid Schedule— Heil (Edwards —Goldenwest)C- 2.14"with "Revised Project Bid Schedule— Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22" to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Number One, dated July 19, 2016. Company Name By Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at(714) 536-5467 within 24 hours of posting. REVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED _ OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ $ GRADE FROM WALK TO EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/ RESIDENTIAL DRIVEWAY ("W"AND TYPE 12 14 SHOWN ON PLAN) PER STD 1,040 SF $ $ PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC SIGNALS AND LIGHTING 13 15 SYSTEMS, 2005 EDITION. 22 EA $ $ SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP AND ROOTS TO 24" BELOW TOP 14 16 OF SIDEWALK/GRADE WITHIN 14 EA $ $ PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 Unsuccessful Bids CC- 1527 Main St., Talbert Ave., Heil Ave. Rehabilitation City of Huntington Beach u-t 2000 Main Street ♦ Huntington Beach, CA 92648 - (714) 536-5227 ♦ www.huntingtonbeachca.gov M4. Office of the City Clerk � 1909 Robin Estanislau, City Clerk October 26, 2016 All American Asphalt P. O. Box 2229 Corona, CA 92878-2229 RE: Main St., Talbert Ave., Heil Ave. Rehabilitation —CC-1527 Enclosed please find your original bid bond for CC-1527. Sincerely, Robin Estanislau, CIVIC City Clerk RE:pe Enclosure Sister Cities: Anjo, Japan e Waitakere, New Zealand Uli CL C-D C) -1Z LU Cf) LU �773- Lu Ul> jf LU st -'r- 6L City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice 'To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C- REVISED BID SCHEDULE (1 Sheet) Replace one page entitled "Project Bid Schedule— Heil (Edwards —Goldenwest) C- 2.14" with "Revised Project Bid Schedule—Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22"to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Number One, dated July 19, 2016. n 11 PimeY i Cmn Company Name By E warC( J Cs+rl5on, iCn eSIC�R�If Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at (714) 536-5467 within 24 hours of posting. SECTION C PROPOSAL for the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all Tabor, material, equipment and incident insurance necessary therefor. in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the wort: therein to the satisfaction of and under the supervision of the City Engineer of" the City of I-luntin-ton Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 80 working days, starting fi•orn the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award. BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the g m guaranty accompanying this this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set Forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall ,,overn over extended amounts, and words shall govern over figures. C-t If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and vold. Accompanvin- this proposal of�bid, find Nd�r'S VAIN � 10 I. in the amount of, 1n ok�kk17�1Ct which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond for_% ", as the case may be) Any standard Surety Bid Bond form is acceptable. Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature C-2 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 PROJECT BASE BID: 13asis oPAward Main Street Rehabilitation from Garfield Avenue to Delaware Street, Talbert Avenue Rehabilitation from Gothard Street to Newland Street, and Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street. . . . . . . . . C-2.2 to C-2.15 I. MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street 2.TALBE1ZT AVENUE REHABILITATION from Gothard Street to Newland Street $ l ' ©5 , O�'� . oo 3. HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street i& , �o 00 13ASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: (TOTAL FOR ITEMS 1, 2, & 3) $ . G�'?S w d 0 r: BASIS OF AWARD C-2.1 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 MAIN STREET FROM GARFIELD AVENUE TO DELAWARE STREET CC NO. 1527 C-2.2 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 1 1 (INCLUDES ALL 2 EA APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16) WET PROCESS vim, , 2 3 OVERLAY PER TYPICAL 2,200 TN $ CJ�7 $ l (Sly, 01 SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 4 EA $�•� r $ �r GRADE. REPLACE WATER VALVE BOX 4 5 ASSEMBLY AND ADJUST TO 19 EA $ GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 5 6 PAVEMENT TO A DEPTH OF 171,300 SF $ 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 6 6 A.C. BASE COURSE OVER 95% 2 200 TN COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. C-2.3 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC r� 8 SIGNALS AND LIGHTING 52 EA $�ivZ5 - $ �� / 00 SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE AND RECONSTRUCT MEDIAN CURB PER HB STD PLAN 201 (CF=8"). (INCLUDES ic• 8 9 SLOT PAVEMENT, AGGREGATE 50 LF BASE, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). / 9 10 (INCLUDES SLOT PAVEMENT, 30 LF $ l �C $ 0 AGGREGATE BASE, LOT DRAINS,AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DRIVEWAY CURB SECTION AS 10 11 50 SF $ MODIFIED PER DETAIL ON $ �+ SHEET 3. RAISE SURVEY WELL MONUMENT TO GRADE AND 11 12 PREPARE CORNER RECORD 1 EA $ ��—� $ �� (PRE-AND/OR POST- CONSTRUCTION). INSTALL TRUNCATED DOMES 12 13 TO EXISTING CURB ACCESS 8 EA $ 6750 $ 7a 00 RAMP PER CALTRANS STD. PLAN RSP A88A OR RSP A88B. C-2.4 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 13 14 EXISTING SLOPE, RELOCATING 600 SF $ ' IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 96 ' y I 14 15 STAMPED CONCRETE PER HB 50 LF $ $ `� STD PLAN 711. 15 MOBILIZATION 1 LS $ 5000— $ 16 TRAFFIC CONTROL PLAN 1 LS $ $ /G'U 17 FURNISH PROJECT TRAFFIC 1 LS $, `� ov� $ �� CONTROL 18 FURNISH AND INSTALL SIGNING 1 LS $l$; fie' $ /5' AND STRIPING 19 PROJECT SPECIFIC SWPPP 1 LS $ 1 'zoo $l 00 FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY ry 20 APPROVED EQUAL COATING 2 LS $ oC $5�zoy ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ "5-0Qi JS3 ©> Total Amount Bid in Words: r(V+✓- hutow'e L� T�-(p �cD /�cn��ct ���,�E'c ......... ....... ......... ...... C-2.5, SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 TALBERT AVENUE REHABILITATION FROM GOTHARD STREET TO NEWLAND STREET CC NO. 1527 C-2.6 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). (INCLUDES ALL O (�0c) 1 1 APPURTENANCES, CURB 16 EA CJ GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT pp 2 3 RUBBER HOT MIX (ARHM GG- 5,700 TN $ e2 $ �, ;kC U C1/2"PG 64-16) WET PROCESS OVERLAY. vac, ,/ 3 4 ADJUST SEWER MANHOLE TO 21 EA $fJ 7 $�`7 GRADE. 4 5 ADJUST STORM DRAIN 9 EA MANHOLE TO GRADE. REPLACE WATER VALVE BOX _ 5 6 ASSEMBLY AND ADJUST TO 60 EA $ 5y ` $���G��l� GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C.6 8 PAVEMENT TO A DEPTH OF 440,020 SF $ $ 004 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 7 8 A.C. BASE COURSE OVER 95% 5,700 TN $ $����r1 00() COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. INSTALL TRUNCATED DOMES TO EXISTING CURB ACCESS 8 10 RAMP AS REQUIRED PER 2 EA $(v50 ✓ $ (�Gi, CALTRANS STD. PLAN RSP A88A. C-2.7 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 9 11 (INCLUDES SLOT PAVEMENT, 245 LF $ $ r�i (�i AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 10 12 EXISTING SLOPE, RELOCATING 6,300 SF IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DEEPENED CURB AND GUTTER PER HB STD. PLAN 202(B) 11 13 (CF=8"). (ITEM INCLUDES 60 LF $ REBAR, CLASS 560-C-3250 CONCRETE, SLOT PAVEMENT, AGGREGATE BASE, AND LOT DRAIN IF PRESENT.) REMOVE AND RECONSTRUCT 12 14 DRIVEWAY CURB SECTION AS 45 LF $ MODIFIED PER DETAIL ON SHEET 5. REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP ✓� 13 15 AND ROOTS TO 24" BELOW TOP 7 EA $ / / $3�' 1�7 OF SIDEWALK/GRADE. PULL OUT ALL ROOTS WITHIN PROPOSEDIMPROVEMENTS. C-2.8 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 14 16 SIGNALS AND LIGHTING 61 EA $ $l � SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE EXISTING RETAINING WALL WITHIN CITY RIGHT-OF- WAY AND CONSTRUCT NEW RETAINING WALL (OPTION 2) BEHIND CITY RIGHT-OF-WAY PER HB COMMUNITY DEVELOPMENT BUILDING DIVISION STD PLAN NO. 3 AND G 15 17 DETAIL ON SHEET 5. (ITEM 1 LS INCLUDES EXCAVATION AND/ OR BACKFILL, RE-GRADING, RELOCATING EXISTING IRRIGATION, RETURNING LANDSCAPE BEHIND WALL TO PRE-CONSTRUCTION CONDITIONS AND ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE.) REMOVE AND RECONSTRUCT LOCAL DEPRESSION PER HB STD PLAN 302. (INCLUDES SLOT 16 18 PAVEMENT, AGGREGATE BASE, 180 SF $ � ' $�3��D AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 17 19 205. (ITEM INCLUDES SLOT 4,380 SF $; PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.9 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount 18 MOBILIZATION 1 LS $u0000 19 TRAFFIC CONTROL PLAN 1 LS $ $ 20 FURNISH PROJECT TRAFFIC 1 LS $56.lot, $ 5b,�It� CONTROL 21 FURNISH AND INSTALL SIGNING 1 LS $1 $ lv �� AND STRIPING 22 PROJECT SPECIFIC SWPPP 1 LS $.5100 - $�� Total Amount Bid in Figures: $ /, y05j 0651, C)CD Total Amount Bid in Words: 0 m� l�ivn "ft�uQ �un�fr �I h�� ���� ......... .......... . . .......... i✓� C-2.10 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 HEIL AVENUE REHABILITATION FROM EDWARDS STREET TO GOLDENWEST STREET CC NO. 1527 C-2.11 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). (INCLUDES ALL g EA $ )L� 0 1 1 APPURTENANCES, CURB $� GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16) WET PROCESS 2 3 OVERLAY PER TYPICAL 1,970 TN $ ���/ �v SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 1 EA $ GRADE. ADJUST OCSD MANHOLE TO GRADE PER OCSD STD. PLAN S- �/ _ 4 5 053, S-054 AND S-055. 5 EA $ �� ` $ CONTRACTOR TO COORDINATE WITH MIKE BOLSTER AT (714) 593-7645. 5 6 ADJUST STORM DRAIN 1 EA $ MANHOLE TO GRADE. REPLACE WATER VALVE BOX 6 7 ASSEMBLY AND ADJUST TO 10 EA $ ��7� $ GRADE PER HB STD PLAN 612. C-2.12 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount COLD MILL EXISTING A.C. 7 8 PAVEMENT TO A DEPTH OF 153,310 SF $ �'� $� O �i 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 8 8 A.C. BASE COURSE OVER 95% 1,970 TN $ $ �i COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 9 10 205. (ITEM INCLUDES SLOT 1,730 SF $ PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 10 11 (INCLUDES SLOT PAVEMENT, 1,100 LF $ AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO _ 11 12 EXISTING SLOPE, RELOCATING 10,100 SF $ '' $ �i IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.13 REVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price j Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL / 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ GRADE FROM WALK TO EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/ RESIDENTIAL DRIVEWAY ("W"AND TYPE ,J 12 14 SHOWN ON PLAN) PER STD 1,040 SF $ � $ 15�� i PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC s� 13 15 SIGNALS AND LIGHTING 22 EA $ $ SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP 14 16 AND ROOTS TO 24" BELOW TOP 14 EA $�� / $ 7 � OF SIDEWALK/GRADE WITHIN PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount SAWCUT AND REMOVE EXISTING SIDEWALK AT EXISTING AND CONSTRUCT TREE WELL WITH SIDEWALK PER DETAIL ON SHEET 3. (ITEM 15 17 INCLUDES REMOVAL OF 4 EA $ vo- $ SIDEWALK, 6LF OF NEW SIDEWALK, NON-CHEMICAL WEED CONTROL BARRIER TO BE DUPONT LANDSCAPE MAX OR AGENCY APPROVED EQUAL AND MULCH.) ��jj 16 MOBILIZATION 1 LS $ 8600 - 17 TRAFFIC CONTROL PLAN 1 LS $ ����� $ IOU 18 FURNISH PROJECT TRAFFIC CONTROL 1 LS $ fI bo $3 i 19 FURNISH AND INSTALL SIGNING 1 LS $ /�SyD $�6'50 V AND STRIPING . 20 PROJECT SPECIFIC SWPPP 1 LS $ `U l $���'� r FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY / 21 APPROVED EQUAL COATING 4 LS $ ,(�U� $ ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ 7 50: 00 Total Amount Bid in Words s Uc'r> ,,.,hlCr��lt '� BSc„ n,lr; -i'1^c„ct Y n. 5 i h U'v)'-f ezd d o c l qx S 0-pid �Q D Caw fs C-2.15 L[ST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, wh ichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class DIR Dollar "% of Item(.) Subcontractor License Number Amount Contract Number lG 3. 1 !(.+'�^zar,.I Sc.(�'t=:�r(✓�v PIS✓eMlnT �, t r7t?vct�;y7(, �-rAQ6 �+3iL GyF� �s sr .1�� � C a� f3v�l r_ °�v 1,4--kr./_'� qAq, C?/I6--be, � r; 7�i 3`3U I /� r vc�r;� v �,4,�f 3�_ � L l tv f 3 rt6r f 4/-�tL� C `fir 1 rl 13 -TAr-_R TEC r✓ 51-" r THu r-{'q,�,r r— 1.5�5_1 !U.. r'Y:r Ll.6��-- r � fitthm CAA BV submission ofthis proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of per jury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on 1 25 l > at CoYoro 0q- Dale City Seale Edu�ar CGr�SvVi being first duly sworn, deposes and says that he or she is �l`C _PY-eS)��rI of P1I 9 rj r/_ ha ( the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding: that the bidder has not in any manner, directly or indirectly, sought by a�(lreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof; or the contents thereof; or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. �}II Amfv roan Pwhia� Name of Bidder Signature of Bidder Ede► J; N(son, ilk 61den-1 P.O. gOX 222q, (oroh014 (,4 I-za_lg Address of Bidder C-4 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness.accuracv.or validitv of that document. State of California County of Riverside On 07/25/2016 before me, Rebecca Angela Parra, Notary Public Date Here Insert name and Title of the Officer personally appeared Edward J. Carlson Name(s)of Signer(s) 7 who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she4hey executed the same in his/her/ authorized capacity(ies), and that by his/her/th& REBECCA ANGELA PARRA signature(s) on the instrument the person(s), or the entity upon behalf Commission # 2024944 of which the person(s)acted, executed the instrument. i :� i Notary Public - California z Z Riverside County ' I certify under PENALTY OF PERJURY under the laws of the State of My Comm.Expires May 17,2017 California that the forgoing paragraph is true and correct. WITNESS my harp an official seal. C Signature �L y Place Notary Seal Above Signature of otary Public OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document Non Collusion Affidavit Document Date: 07/25/2016 Number of Pages: One (1) Signer(s)Other Than Named Above: None Capacity(ies)Claimed by Signer(s) Signer's Name: Edward J. Carlson Signer's Name: ❑ Individual ❑ Individual X Corporate Officer—Title(s): Vice President ❑ Corporate Officer—Title(s): ❑ Partner❑ ❑ Limited❑ General ❑ Partner❑ ❑ Limited ❑ General RIGHTTHUMBPRINT RIGHT THUMBPRINT ❑Attorney in Fact OF SIGNER ❑Attorney in Fact OF SIGNER ❑Trustee Top of thumb here ❑Trustee Top of thumb here ❑ Other: ❑Other: Signer is Representing: Signer is Representing: All American Asphalt UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract. known as the MAIN STREET REHABILITATION, TALBERT AVENUE REHABILITATION AND HEIL AVENUE REHABILITATION, PROJECT CC-1527, (1)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person ii,ho, try reason of experience or instruction, is familiar rnilh the operation to he performed and the hazards inmlved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. "hhe undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. All Pmeaicen Rsphal � Contractor By Cd`A a rd -d� ��f I sorrt Ur ce Rea r� Title Date: -7lz�l G5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety reUIulation? l ❑ Yes No Ifthe answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. 11/( PWOW7 PS 0ha If Contractor By tc ward r (rlwi, Vice -Pv-es'idetz�- Title J Date: 71 261u C-7 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: All 6weriCali ;}s&a if Bidder Name APO C-g(l cf)( Lh Business Address COYO1/76f 7&1 City, State Zip ( l -[ ) 1;69 ►l�o� Telephone Number 200� 3, State Contractor's License No. and Class Original Date Issued �� -;I I26 )0 Expiration Date The wort: site was inspected by �IYVIHC pQftj of our office on �U� 95 201k. The followim, are persons, firms, and corporations having a principal interest in this proposal: Cg Nyoornkn MAYY- Lo v"VINRY)k tm g dward -\_ CQvOw ,; \�'�� vYQs�d�r* C-8 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. () 8W11660 1�1sDti�0� Company Name Signature of Bidder Edward -►' Carlsor), lJice Tysi('eH- Printed or Typed Signature Subscribed and sworn to before me this_ day of 201_ A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of County of ) On before me, Month. Day, and Year Insert Name and Title of Notary personally appeared Name(s) ofSigner(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Si(Inature Signature of Notary Public (PLACE NOTARY SEAL ABOVE) C-9 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness.accuracv.or validitv of that document. State of California County of Riverside On 07/25/2016 before me, Rebecca Angela Parra Notary Public Date Here Insert name and Title of the Officer personally appeared Edward J. Carlson Name(s)of Signer(s) f who proved to me on the basis of satisfactory evidence to be the persons) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/sheFthey: executed the same in his/4e4the4 authorized capacity(ies), and that by his/he4their signature(s) on the instrument the persorl or the entity upon behalf REBECCA ANGELA PARRA of which the persons)acted, executed the instrument. Commission # 2024944 a s`: Notary Public - California Z I certify under PENALTY OF PERJURY under the laws of the State of Z t��t Riverside County California that the forgoing paragraph is true and correct. My Comm.Expires May 17,2017 WITNESS my hand a d official s al. Signature Place Notary Seal Above Signatu of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document Bidder's Information Document Date: 07/25/2016 Number of Pages: Two (2) Signer(s) Other Than Named Above: None Capacity(ies)Claimed by Signer(s) Signer's Name: Edward J. Carlson Signer's Name: o Individual o Individual X Corporate Officer—Title(s): Vice President o Corporate Officer—Title(s): o Partner 11 o Limited o General RIGHT o Partner ❑ o Limited o General 1 RIGHT THUMBPRINT o Attorney in Fact OF SIGNER o Attorney in Fact OF SIGNER o Trustee Top of thumb here o Trustee Top of thumb here o Other: o Other: Signer is Representing: Signer is Representing: All American Asphalt Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work, specifically referencing the construction of{Describe specific work and experience necessary for project. For example, "Sanitary sewer line installation of at least of 1,000 of 8-inch and Greater in public right-of-way. Sanitary sewer lift stations of similar size, project work within public streets, an area containing high ground water and pipeline construction in hi(_,h ground water regions with trench depths of 8-feet to the invert."}. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: I . \2QSe S0 0NR(W 0(_ Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: 3. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: C-10 "2015" PAST WORK REFERENCES City of Hawthorne Hawthrone Blvd Reconstruction 4455 W. 162nd Street Contract Amount: $12,579,000.00 Hawthorne, CA 90250 Start: 4/2014 Contact: Heecheol Kwon, (310) 349-2980 Completed: 5/2015 City of Inglewood Florence Ave One Manchester Blvd, 3" Floor Contract Amount: $2,639,000.00 Inglewood, CA 90301 Start: 4/2015 Contact: Hunter Nguyen, (310) 412-4252 Completed: 10/2015 County of Ventura Pavement Resurfacing, Phase II 800 S. Victoria Ave Contract Amount: $2,401,970.00 Ventura, CA 93009 Start: 4/2015 Contact: Jeewoong Kim, (805) 654-3987 Completed: 10/2015 City of Montclair Northeast Montclair Street Rehabilitation 5111 Benito Street Contract Amount: $514,150.00 Montclair, CA 91763 Start: 4/2015 Contact: Steve Stanton, (909) 625-9444 Completed: 7/2015 Riverside County Transportation Commission Route 74 Widening 4080 Lemon Street, 3"'Floor Contract: $1,970,004.00 Riverside, CA 92501 Start: 4/2014 Contact: Bill Seitz, (949) 300-9132 Completed: 7/2015 City of Riverside 2014/15 Arterial Streets 3900 Main Street Contract Amount: $1,683,076.00 Riverside, CA 92501 Start: 4/2015 Contact: Steve Howard, (951) 826-5708 Completed: 9/2015 Long Beach Unified School District Garfield Elementary School Pavement 2201 E. Market Street Contract Amount: $1,976,508.00 Long Beach, CA 92805 Start: 6/2015 Contact: Nancy Chinchilla, (562) 997-7513 Completed: 11/2015 "2014" PAST WORK REFERENCES City of Fullerton Yorba Linda Blvd Reconstruction 303 W. Commonwealth Ave Contract Amount: $1,346,000.00 Fullerton, CA 92832 Start: 7/2014 Contact: Kevin Kwak, (714) 738-6865 Completed: 11/2014 Port of Long Beach 2013 Roadway Maintenance and Slurry 4801 Airport Plaza Drive Contract Amount: $992,000.00 Long Beach, CA 90815 Start: 6/2014 Contact: Lincoln Lo, (562) 283-7000 Completed: 10/2014 City of Beverly Hills 2012-2013 Street Resurfacing 455 N. Rexford Drive Contract Amount: $2,970,000 Beverly Hills, CA 90210 Start: 7/2013 Contact: Mark Cueno, (310) 285-2557 Completed: 5/2014 City of Jurupa Valley 2012-13 Pavement Rehabilitation 12363 Limonite Ave Contract Amount: $970,000 Riverside, CA 92507 Start: 5/2013 Contact: Michael Myers, (951) 332-6464 Completed: 12/2013 City of Santa Ana Bristol Street Rehabilitation 20 Civic Center Contract Amount: $6,951,475 Santa Ana, CA 92701 Start: 3/2013 Contact: Kurt Weimann, (714) 647-5639 Completed: 12/2014 "2013" PAST WORK REFERENCES Department of Transportation Route 74, Contract No. 12-OL6404 3521 '/4 University Dr Contract Amount: $1,134,057 Irvine CA 92612 Start: 7/2012 Contract: Dat Pham, (949) 279-8586 Completed: 5/2013 City of Santa Clarita 2011/12 Overlay & Slurry Seal Program 23920 Valencia Blvd Contract Amount: $5,995,000 Santa Clarita CA 91355 Start: 8/2012 Contact: Bill Whitlatch, (661) 259-2489 Completed: 5/2013 LACDPW Seventh Avenue 900 S Fremont Ave Contract Amount: $2,077,000 Alhambra, CA 91803 Start: 9/2012 Contact: Hector Hernandez, (626) 458-2191 Completed: 12/2013 Department of Transportation Route 74, Contract No. 08-OP9504 2023 Chicago Ave., B-6 Contract Amount: $3,450,622 Riverside, CA 92507 Start: 6/2012 Contact: Michael Chen, (951) 830-6017 Completed: 9/2013 City of Laguna Hills Citywide Pavement Rehabilitation 24035 El Toro Rd Contract Amount: $1,778,169 Laguna Hills, CA 92653 Start: 8/2012 Contact: Kenneth Rosenfield, (949) 707-2650 Completed: 9/2013 County of Riverside Transportation Gilman Springs Road 3525 14" St Contract Amount: $1,695,108 Riverside, CA 92501 Start: 7/2013 Contact: Trai Nguyen, (951) 961-5363 Completed: 9/2013 City of Azusa Pavement Management Improvements 213 E Foothill Blvd Contract Amount: $980,000 Azusa, CA 91702 Start: 5/17/12 Christina Curiel, (626) 812-5254 Completed: 1/18/13 WATER DISTRICT PAST WORK REFERENCES Rialto Water Services Remove& Replace 9 Locations 437 N Riverside Ave Contract Amount: $36,695.35 Rialto, CA 92376 Completed: 1/14/16-4/30/16 Contact: Stephanee Stafford, (909) 820-0400 x 53301 Moulton Niguel Water District 2A Yard Parking improvements 27500 La Paz Rd Contract Amount: $70,050.00 Laguna Niguel, CA 92677 Completed: 10/l/15 —3/31/16 Contact: Jim Sampson, (949) 795-6880 Rialto Water Services Remove&Replace 12 Locations 437 N Riverside Ave Contract Amount: $29,032.14 Rialto, CA 92376 Completed: 9/1/15 —9/30/15 Contact: Stephanee Stafford, (909) 820-0400 x 53301 Rialto Water Services 110 Locations Citywide 437 N Riverside Ave Contract Amount: $108,790.00 Rialto, CA 92376 Completed: 2/1/15 —6/30/15 Contact: Stephanee Stafford, (909) 820-0400 x 53301 Yucaipa Valley Water District Crow Street Road Replacement 35477 Oak Glen Rd Contract Amount: $415,779 Yucaipa, CA 92399 Completed: 8/27/13 — 10/31/13 Contact: Linda Kilday, (909) 797-51 18 Pico Water District Manning inter-Tie Project 4843 Church Street Contract Amount: $155,555.00 Pico Rivera, CA 90660 Completed: 8/1/11 — 12/30/11 Contact: Mark Grajeda, (562) 692-3756 Santa Margarita Water District Portola Dam Upstream Slope 26111 Antonio Parkway Contract Amount: $181,000.00 Rancho Santa Margarita, CA 92688 Completed: 12/1/10— 1/31/1 1 Contact: Dia Bader, (949) 459-6576 Moulton Niguel Water District Cabot&Crown Valley Parkway 27500 La Paz Rd Contract Amount: $64,500.00 Laguna Niguel, CA 92677 Completed: 5/1/09—5/31/09 Contact: Jim Sampson, (949) 795-6880 Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager, and Superintendent For each of these critical positions, please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project. Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. I. 1\m A bey. Name oaf proposed Project Manager Telephone No. of proposed Project Manager: Zb1 12ols PrA Y gal SAOS U&AIU- 7NO 3 UMbO can OO UIS Project Name & Contract Amount Type of Work Date Completed SY`shl %0 Rehab. 'k(05�,4-1)- `:NRA MA'h M Iar-jolt Project Name & Contract Amount Type of Work Date Completed Project Name & Contract Amount Type of Work Date Completed Name of proposed Superintendent Telephone No. of proposed Superintendent: ?JaW �AUN O(\\\(YNA ; V !3KIM - N m W1(fPY1�Y1 il�20�`� Project Name & Contract Amount Type of Work Date Completed illWTY) Project Name & Contract Amount Type of Work Date Completed 1�s�8en al %ZQA O Ou?(W' cti�2o►� Project Name & Contract Amount Type of Work Date Completed C-ll CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)), passed by the California State Senate Oil June 20, 2014, established a new public works Contractor Registration Program which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July I through June 30 state fiscal year) with the California Department of Industrial Relations (DIR). Currently the annual non-refundable registration fee for Contractors is $300. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT SHEET on SB 854 http://www.dir.ca.gov/DI-SE/Public Works/SB854FactSheet_6.30.14.pdf DIR's Contractor Registration Link—Call (844) 522-6734 https://eliling.dir.ca.(,ov/PWCR/ActioiiServlet?action=displayPWCRegistratioiiForm DIR's Contractor Registration searchable database: https://efiling.dir.ca.gov/PWCR/Searcli.action I am aware and will comply with the provisions of Labor Code Section 1771.1(a) which states: "A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 Of the Public Contract Code, provided the contractor is registered to perform public wort: Pursuant to Section 1725.5 at the time the contract is awarded." I furthermore will comply by providing proof of registration with DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. W A WIR Y I CG P Contractor By FAK'drd a Cason; Jive pr�s����� Title Date: 15�2p (P DIIZ \Obbt'Lb\os\ C-12 o Fidelity and Deposit Company of Maryland Home Office: P.O.Box 1227.Baltimore.MD 21203-1227 BID BOND KNOW ALL MEN BY THESE PRESENTS: That we, ALL AMERICAN ASPHALT BOND NO. 085 97 423 as Principal,(hereinafter called the "Principal"), and FIDELITY AND DEPOSIT COMPANY OF MARYLAND P.O. Box 1227, Baltimore, Maryland 21203, a corporation duly organized under the laws of the State of Maryland, as Surety,(hereinafter called the"Surety"),are held and firmly bound unto City of Huntington Beach as Obligee,(hereinafter called the"Obligee"), in the sum of TEN PERCENT OF THE TOTAL BID PRICE IN-------- Dollars($ 10%OF TOTAL BID PRICE ),for the payment of which sum well and truly to be made,the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns,jointly and severally, firmly by these presents. WHEREAS,the Principal has submitted a bid for Main Street Rehabilitation from Garfield Avenue to Delaware Street,Talbert Avenue Rehabilitation from Gothard Street to Newland Street,And Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street-CC No. 1527 Bid Date: July 26,2016 NOW,THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or contract documents with good and sufficient surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter into such contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 19th day of July 2016 A.D., ALL AMERICAN ASPHALT (SEAL) p„ 'd",Z Princip l uW4tness �--- Edw(ird T C1 w h Title UI CQ QSI`d2i'7 FIDELITY AND DEPOSIT COMPANY OF MARYLAND Surety Byri��Q r now $�� (SEAL) Rebecca Haas-Bates Attorney-in-Fact Printed in cooperation with the American Institute of Architects(AIA)by Fidelity and Deposit Company of Maryland. Fidelity and Deposit Company of Maryland vouches that the language in the document conforms exactly to the language used in AIA Document A-310,February 1970 Edition. BID70000ZZ0701f CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of Orange ) On 07/19/2016 before me, R. Paramo,Notary Public Date Here Insert Name and Title of the Officer personally appeared Rebecca Haas-Bates NameKof SignerN who proved to me on the basis of satisfactory evidence to be the persons} whose name(4 is/at;e subscribed to the within instrument and acknowledged to me that he/she/they executed the same in hislher/t wir authorized capacity, and that by his/her/Ytiair signature�qon the instrument the person(,, or the entity upon behalf of which the person(s).acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws R. PARAMO of the State of California that the foregoing paragraph :. Commission #2035890 ittrue iNotary Public -California iz Orange County and office I al. M Comm.Ex ires Au 5, 2017 Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Bid Bond Document Date:07/19/2016 Number of Pages: One 1 Signer(s) Other Than Named Above: All American Asphalt Capacity(ies) Claimed by Signer(s) Signer's Name: Rebecca Haas-Bates Signer's Name: O Corporate Officer — Title(s): O Corporate Officer — Title(s): O Partner — O Limited O General O Partner — O Limited O General O Individual W Attorney in Fact O Individual O Attorney in Fact O Trustee O Guardian or Conservator O Trustee O Guardian or Conservator O Other: O Other: Signer Is Representing: Signer Is Representing: Fidelity and Deposit Company of Maryland ©2014 National Notary Association -www.Nationa]Notary.org• 1-800-US NOTARY(1-800-876-6827) Item #5907 EXTRACT FROM BY-LAWS OF THE COMPANIES "Article V,Section 8,Attomeys-in-Fact. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate; and I do further certify that Article V, Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the loth day of May, 1990. o RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN 1T,�E,'STIM NY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this I C �,aay of v 201G. a ovof .,'''++irisp7ti �Ncy I . a •4"a° tee'`.m s r O t `' SEAL rea _�`• teas � .r. b♦, .... . ✓RI i Michael Bond, Vice President CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVIL CODE g 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness.accuracv.or validitv of that document. State of California County of Riverside On 07/25/2016 before me, Rebecca Angela Parra,Notary Public Date Here Insert name and Title of the Officer personally appeared Edward J. Carlson Name(s)of Signer(s) f who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/a-re subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/4e.4heif authorized capacity(ies), and that by his/her4heif REBECCA ANGELA PARRA signature(s) on the instrument the person(s), or the entity upon behalf Commission # 2024944 of which the person(s) acted, executed the instrument. Notary Public - California D Z'.?'. — I certify under PENALTY OF PERJURY under the laws of the State of r. Riverside County My Comm.Expires May 17.2017J California that the forgoing paragraph is true and correct. ,z t: WITNESS my h a d official seal. �� Signature Place Notary Seal Above Signatul of Notary Public OPTIONAL Though the information below is not required b law, it may rove valuable to person relying on the document " 6` 9 9 Y Y P P Y 9 and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document } Title or Type of Document Bid Bondrt ld�4S dif tia Document Date: 07/19/2016 Number of Pages: One (1) Signer(&) Other Than Named Above: Fidelity and Deposit Company of Maryland Capacity(ies)Claimed by Signer(s) Signer's Name: Edward J. Carlson Signers Name: 'sF, rs 9 ❑ Individual •yx`�:i ❑ Individual ts-� ���• X Corporate Officer—Titles : Vice President 1���y� { p O ❑ Corporate Officer—Title(s): ❑ Partner❑ ❑ Limited ❑ Generals n°r « ❑ Partner ❑ ❑ Limited❑ GeneralRIGHT THUMBPRINT RIGHT TH UMBPRINT , #y ❑Attorney in Fact OF SIGNER ❑Attorney in Fact sr � Top of thumb here Top of thumb here , '" ❑Trustee 1, # ❑Trustee ❑Other: ❑Other: fi 'Sk Signer is Representing: Signer is Representing: , € "a All American Asphalt OF s t t, r< CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness. accuracv.or validitv of that document. State of California County of Riverside On 07/25/2016 before me, Rebecca Angela Parra Notary Public Date Here Insert name and Title of the Officer personally appeared Edward J. Carlson Name(s)of Signer(s) f who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she" executed the same in his/h r4he r authorized capacity(ies), and that by his/hem„hhei� t =—v REBECCA ANGELA PARRA signature(s) on the instrument the person(s), or the entity upon behalf Commission # 2024944 Z of which the person(s) acted, executed the instrument. c"C Notary Public - California zz z:�_,... Z z,. Riverside County I certify under PENALTY OF PERJURY under the laws of the State of My Comm.Expires May 17,2017J California that the forgoing paragraph is true and correct. WITNESS my hagd a d official seal. r Signature Place Notary Seal Above Signatu�of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document Bid Bond Document Date: 07/19/2016 Number of Pages: One (1) Signer(s)Other Than Named Above: Fidelity and Deposit Company of Maryland Capacity(ies)Claimed by Signer(s) Signer's Name: Edward J. Carlson Signer's Name: ❑ Individual ❑ Individual X Corporate Officer—Title(s): Vice President ❑Corporate Officer—Title(s): ❑ Partner❑ ❑ Limited ❑ General RIGHT THUMBPRINT ❑ Partner❑ ❑ Limited ❑ General RIGHT THUMBPRINT ❑Attorney in Fact OF SI I GNER ❑Attorney in Fact OF SIGNER ❑Trustee Top of thumb here ❑Trustee Top of thumb here ❑ Other: ❑ Other: Signer is Representing: Signer is Representing: All American Asphalt City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachea.gov Fy``B. n'ieoetiP°°W. Office of the City Clerk Robin Estanislau, City Clerk October 26, 2016 Excel Paving Company 2230 Lemon Ave. Long Beach, CA 92806 RE: Main St., Talbert Ave., Heil Ave. Rehabilitation — CC-1527 Enclosed please find your original bid bond for CC-1527. Sincerely, 4q440.� �&4W4� Robin Estanislau, CIVIC City Clerk RE:pe Enclosure Sister Cities: Anjo, Japan ♦ Waitakere, New Zealand -3 S Y �.S I City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE, For MAIN STREET,TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C-REVISED BID SCHEDULE(1 Sheet) Replace one page entitled "Project Bid Schedule—Heil (Edwards—Goldenwest) C- 2.14"with "Revised Project Bid Schedule—Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22"to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Number One, dated July 19, 2016. Company Name By C.P. IIfN illi ii11� PRESIX-IT All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at(714) 536-5467 within 24 hours of posting. SECTION C PROPOSAL for the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 80 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid, find in the amount of which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond forte% ", as the case may be) Any standard Surety Bid Bond form is acceptable. Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received Bidder's Signature C.P. MOWN C-2 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 PROJECT BASE BID: Basis of Award Main Street Rehabilitation from Garfield Avenue to Delaware Street, Talbert Avenue Rehabilitation from Gothard Street to Newland Street, and Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street. . . . . . . . . C-2.2 to C-2.15 1. MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street 2.TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street $ I , q �T, olj-� 3. HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: (TOTAL FOR ITEMS 1, 2, & 3) $ Z� Co-72, � 33 BASIS OF AWARD 7�-Z G C-2.1 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 MAIN STREET FROM GARFIELD AVENUE TO DELAWARE STREET CC NO. 1527 C-2.2 PROJECT BID SCHEDULE r MAIN (GARFIELD-BEACH) Bid Contract aJnit Extended'` No. Note Description Quan"tity Unit Price Amounf. REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 1 1 (INCLUDES ALL 2 EA $ lsw d — $ 100�lI ' APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT,AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT OAT FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16)WET PROCESS 2 3 OVERLAY PER TYPICAL 2,200 TN $_ $ 1 S 7 W SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 4 EA $ DO _ $ wo— GRADE. REPLACE WATER VALVE BOX 4 5 ASSEMBLY AND ADJUST TO 19 EA $ $ 7Gi OIJ-- GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. l 5 6 PAVEMENT TO A DEPTH OF 171,300 SF $ o '1 $ 3e63'Z 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 6 6 A.C. BASE COURSE OVER 95% 2,200 TN $ $ MOO— COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. C-2.3 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Const Bid Contract Unit Extended No Note I' Description Quantity Unit . Price. Amount. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 7 8 SIGNALS AND LIGHTING 52 EA $ SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE AND RECONSTRUCT MEDIAN CURB PER HB STD PLAN 201 (CF=8"). (INCLUDES 8 9 SLOT PAVEMENT, AGGREGATE 50 LF $ BASE, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 9 10 (INCLUDES SLOT PAVEMENT, 30 LF $ �S' $ "- AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 10 11 DRIVEWAY CURB SECTION AS 50 SF $ $ MODIFIED PER DETAIL ON SHEET 3. RAISE SURVEY WELL MONUMENT TO GRADE AND �D 11 12 PREPARE CORNER RECORD 1 EA $ $ (PRE-AND/OR POST- CONSTRUCTION). INSTALL TRUNCATED DOMES 12 13 TO EXISTING CURB ACCESS 8 EA $ $ y�Qo RAMP PER CALTRANS STD. PLAN RSP A88A OR RSP A88B. C-2.4 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) const. Bid Contract. Unit Extended;: No. Note Description Quantity Unit Price Amount; REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO G 13 14 EXISTING SLOPE, RELOCATING 600 SF $ $ 100p IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 14 15 STAMPED CONCRETE PER HB 50 LF $ 1 $ STD PLAN 711. 15 MOBILIZATION 1 LS $ 7D P ` $ 7 So b 16 TRAFFIC CONTROL PLAN 1 LS $ ZSOd $ D Q 17 FURNISH PROJECT TRAFFIC 1 LS $ 1fp0b _ $ �Sd C1 CONTROL 18 FURNISH AND INSTALL SIGNING 1 LS $ 2,900— $ 2�d AND STRIPING 19 PROJECT SPECIFIC SWPPP 1 LS $ $fda FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY 20 APPROVED EQUAL COATING 2 LS $ govo — $ V aoa " ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ jg qo Total Amount Bid in Words: ............................ ......_..........................................._......._........,..._................_...... ......_.................... ... ......................,..... ...... ..... _....._..._............_ .r. e__......... C-2.5 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 TALBERT AVENUE REHABILITATION FROM GOTHARD STREET TO NEWLAND STREET CC NO. 1527 C-2.6 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Co;nst. Bird Contract , Unit Extended No. Note Descnptio'n Quantity . Unit. Price Amount'' 'I REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). (INCLUDES ALL 900 - 1 1 APPURTENANCES, CURB 16 EA $ $ GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.1 T FIBER REINFORCED ASPHALT 2 3 RUBBER HOT MIX(ARHM GG- 5,700 TN $_ $ C1/2"PG 64-16)WET PROCESS OVERLAY. 3 4 ADJUST SEWER MANHOLE TO 21 EA $ ADD $ GRADE. 4 5 ADJUST STORM DRAIN 9 EA $ (DAD ' $ 7MO MANHOLE TO GRADE. REPLACE WATER VALVE BOX 5 6 ASSEMBLY AND ADJUST TO 60 EA $ 00'' $ 2,gOO4 GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 6 8 PAVEMENT TO A DEPTH OF 440,020 SF $ b 2� $ l D 00 r 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 7 8 A.C. BASE COURSE OVER 95% 5,700 TN $ go- $ COMPACTED SUBGRADE PRIOR TO 0.1 T ARHM OVERLAY, PER PLANS. INSTALL TRUNCATED DOMES TO EXISTING CURB ACCESS p 8 10 RAMP AS REQUIRED PER 2 EA $ 700 $ (LAD CALTRANS STD. PLAN RSP A88A. C-2.7 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Const '' Bid Contract Unit Extended No. Note. Description. Quantity Unit, Price Amounf REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8").9 11 (INCLUDES SLOT PAVEMENT, 245 LF $ `l/fijr AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO ` 10 12 EXISTING SLOPE, RELOCATING 6,300 SF $ IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DEEPENED CURB AND GUTTER PER HB STD. PLAN 202(B) 11 13 (CF=8"). (ITEM INCLUDES 60 LF $ �^ $ 2 6 — REBAR, CLASS 560-C-3250 CONCRETE, SLOT PAVEMENT, AGGREGATE BASE, AND LOT DRAIN IF PRESENT.) REMOVE AND RECONSTRUCT 12 14 DRIVEWAY CURB SECTION AS 45 LF $_qj- $ 2O2f" MODIFIED PER DETAIL ON SHEET 5. REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP 13 15 AND ROOTS TO 24" BELOW TOP 7 EA $ /000 — $ -7000 OF SIDEWALK/GRADE. PULL OUT ALL ROOTS WITHIN PROPOSEDIMPROVEMENTS. C-2.8 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract Unit Extended No. Note Description Quantity Unit , ;; Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC �� ��� 14 16 SIGNALS AND LIGHTING 61 EA $ 2 $ 't SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN aff PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE EXISTING RETAINING WALL WITHIN CITY RIGHT-OF- WAY AND CONSTRUCT NEW RETAINING WALL (OPTION 2) BEHIND CITY RIGHT-OF-WAY PER HB COMMUNITY DEVELOPMENT BUILDING DIVISION STD PLAN NO. 3 AND 15 17 DETAIL ON SHEET 5. (ITEM 1 LS $ 10690— $ l ova— INCLUDES EXCAVATION AND/ OR BACKFILL, RE-GRADING, RELOCATING EXISTING IRRIGATION, RETURNING LANDSCAPE BEHIND WALL TO PRE-CONSTRUCTION CONDITIONS AND ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE.) REMOVE AND RECONSTRUCT LOCAL DEPRESSION PER HB STD PLAN 302. (INCLUDES SLOT /- 16 18 PAVEMENT, AGGREGATE BASE, 180 SF AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 17 19 205. (ITEM INCLUDES SLOT 4,380 SF $ t o — $ K z zoo 0 PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.9 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Const. Bid Contract Unit Extended NN ,Note Description Quantity Unit Price Amount 18 MOBILIZATION 1 LS $ 7i $ 2��D 19 TRAFFIC CONTROL PLAN 1 LS 20 FURNISH PROJECT TRAFFIC 1 LS $ $ CONTROL 21 FURNISH AND INSTALL SIGNING 1 LS $ (o0 ado— $ (oD�OlJ AND STRIPING 22 PROJECT SPECIFIC SWPPP 1 LS $ $ydl Total Amount Bid in Figures: $ 11 q 22 6 IS-- Total Amount Bid in Words: tlb 1 yr r _..._._._............_........................_........-...__.................._................._........................_......._..O►Le.............. ..... _._.��................._.. ._...._.r..........�._...... ...� L--Lf^hz -kv C-2.10 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 HEIL AVENUE REHABILITATION FROM EDWARDS STREET TO GOLDENWEST STREET CC NO. 1527 C-2.11 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No Note Description Quantity Unit Price, Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 1 1 (INCLUDES ALL 9 EA $ $ qszI)D APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16) WET PROCESS 2 3 OVERLAY PER TYPICAL 1,970 TN $ �s_ $ SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 1 EA GRADE. ADJUST OCSD MANHOLE TO GRADE PER OCSD STD. PLAN S- // 4 5 053, S-054 AND S-055. 5 EA $ 7/�U $ CONTRACTOR TO COORDINATE WITH MIKE BOLSTER AT(714) 593-7645. 5 6 ADJUST STORM DRAIN 1 EA $ y UU $ MANHOLE TO GRADE. REPLACE WATER VALVE BOX 6 7 ASSEMBLY AND ADJUST TO 10 EA $ `I 0 $ �D GRADE PER HB STD PLAN 612. C-2.12 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Const. Bid Contract Unit Extended No. Note Description Quantity Unit Price,: Amount COLD MILL EXISTING A.C. 7 8 PAVEMENT TO A DEPTH OF 153,310 SF $ b' q b $ &I�?lq 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 8 8 A.C. BASE COURSE OVER 95% 1,970 TN $ U� $ 'S—V 6a COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 9 10 205. (ITEM INCLUDES SLOT 11730 SF PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). / r 10 11 (INCLUDES SLOT PAVEMENT, 17100 LF $ AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO C� 11 12 EXISTING SLOPE, RELOCATING 10,100 SF IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.13 DEVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Const. Bid Contract ;r ' Unit Extended: No. Note _ .,: Descri tion Quantity °Unit �Price. _Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ GRADE FROM WALK TO EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/RESIDENTIAL DRIVEWAY("W"AND TYPE / 12 14 SHOWN ON PLAN) PER STD 1,040 SF $�^ $ PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC �}, 13 15 SIGNALS AND LIGHTING 22 EA $ z U — $ SS�b SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE"D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP 14 16 AND ROOTS TO 24" BELOW TOP 14 EA $ '� U $ 11 U U OF SIDEWALK/GRADE WITHIN PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Const. Bid Contract Unit Extended No., Note Description Quanfity Unit Pnce; Amount SAWCUT AND REMOVE EXISTING SIDEWALK AT EXISTING AND CONSTRUCT TREE WELL WITH SIDEWALK PER DETAIL ON SHEET 3. (ITEM INCLUDES REMOVAL OF (J �Qp— 15 17 SIDEWALK, 6LF OF NEW 4 EA $ $ SIDEWALK, NON-CHEMICAL WEED CONTROL BARRIER TO BE DUPONT LANDSCAPE MAX OR AGENCY APPROVED EQUAL AND MULCH. 16 MOBILIZATION 1 LS $ 7i $ 17 TRAFFIC CONTROL PLAN 1 LS $ $ 18 FURNISH PROJECT TRAFFIC 1 LS $ 2,7" � $ 7V CONTROL 19 FURNISH AND INSTALL SIGNING 1 LS $ 740el) AND STRIPING 20 PROJECT SPECIFIC SWPPP 1 LS $ $ S-pDa FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY 77 21 APPROVED EQUAL COATING 4 LS $ J OD6 ✓ $ ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ 1 �J Total Amount Bid in Words: �ve�J ✓�, __.._..................................................................._............__.....__......._................ ............._...._._......._..._................ ...................._........ .._......._... . ... ......_.... ...... C-2.15 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class DIR Dollar % of Item(s) Subcontractor License Number Amount Contract �I Number W By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class. bD? Dollar %of' Items) Subcontractor License: Number, Amount Contract ..Number, , By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid. Name and Address of State Class DIP Dollar %of Item(s) Subcontractor License,' Number Amount Contract Number By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed o o;'at LQI 13ACH ,;,LlK)aM Date City State C.P. beingptjftlworn, deposes and says that he or she is P? SI of e , pnam4w the party making the foregoing bid that the bid is not made in t e interest o, or on'r ye behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Clrl KING C dNY Name of Bidder Signature of Bidder C.P: 9P11) Pf ,, °R(1-:31QENT LEMON Vi4iUE — Address of Bidder '- WE'D,Cr,, CA K C U^6 C-4 CAUPO1111111IIA ALL-PURPOSE A ENT CML CODE§1189 A notary putt or offw often com;edng this catiticate verifies only the identity of the Individual who signed the document to*ft this certificate Is attached,and not the truthfulness,accuracy,or validity of that document. State of CaNfomia ) County of Los Angeles ) on JUL ? 0) 016 before rne, C. Phillips, Notary Public- Date Here Insert Name and rare of the Officer personally appeared C. P. Brown Name(s)of Siggtw(s) who proved to me on the basis of satisfactory evidence-to be the pwson(s) whose names) subscribed to the within instrument and aolmowiedged to me that he/aboftay executed the same in hiss authorized capacity(m),and that by hl&4 signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. "!`rips WITNESS my hand and official seal. : yComni.Expiies0d-29 LOS ANGELES COUNTY,20161( Signature. Signatu Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Desc iption of Attached Document Idle or Type of Document: Document Date: Number of Pages: -.Signer(s) Other Than Named Above: Capacity(ies)Claimed by Signers) Signer's Name: Signer's Name: ❑Corporate Officer-Titie(s): 0 Corporate Officer rdws): ❑Partner — ❑Limited ❑General ❑Partner— ❑Limited ❑General ❑Individual ❑Attorney in Fact ❑Individual ❑Attomey in Fact ❑Trustee ❑Guardian or Conservator ❑Truster ❑Guardian or Conservator n Other: ❑ Other- Signer Is Representing:— Signer Is Representing: 02014 National Notary Association•www.NeWWNah".org• 1-800-US NOTARY(1-0-876-M2 Item#5907 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the MAIN STREET REHABILITATION, TALBERT AVENUE REHABILITATION AND HEIL AVENUE REHABILITATION, PROJECT CC-1527, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. A£.,: s L , DBA FXCEL Contractor � � I By Title Date: C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162, the Bidder shall complete, under penalty of perjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? -/ ❑ Yes 63 No If the answer is yes, explain the circumstances in the space provided. II Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. s kl WM Contractor By L*eP 3H,0 VML P 1ES1Q EN III Title ! Date: U C-7 i BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Bidder Name Business Address 0°S� gFAC ?, C:I.908p3 City, State Zip �562j 599-5841 Telephone Number STATE U0, 60,8659 'A' State Contractor's License No. and Class Original Da e sued 6;5 b%► IA Expiration Date The work site was inspected by % of our office on , 201�. The following are persons, firms, and corporations having a principal interest in this proposal: Curtis P.Brown President and Chief Fxecutcj,a nri,,.,,. Curtis P.Brown III Vice President and Chief Operating Officer Bruce E.Flatt Vice President and Chief Financial nffic r — MarciaS.Miller Secretary Michele E.Orakulich Assistant Secretary K'°ALP tN 46& ?9XnZi O B6 V M C—O The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. PAW. 11C .a Company Name E. COMIPAAjy Signature of Bidder Printed or Typed Signature Subscribed and sworn to before me this day of I(Ii 2 �01ti , 201_ . A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of C,�Lir--ORAQM ) County of LOS NGELES ) On -� 'I'' before me, C. Phillips f 1rifnr,,D.J,B.. Month, Day, and Year Insert Name and Title of Notary personally appeared C.P„ BROWN Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. k` C.PHILLIPS { COMM.#1996177 n Notary P-,bk-California V) LOS ANG LES COUNTY IL Signature My Comm.ixPires Oct.29,20:t9j" t Signature otary Public (PLACE NOTARY SEAL ABOVE) C-9 Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work, specifically referencing the construction of{Describe specific work and experience necessary for project. For example, "Sanitary sewer line installation of at least of 1,000 of 8-inch and greater in public right-of-way. Sanitary sewer lift stations of similar size, proiect work within public streets, an area containing high ground water and pipeline construction in high ground water regions with trench depths of 8-feet to the invert."}. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: l t36YDADAJAtq Name and Address of Public Agency Name and Telephone No. of Project Manager: Ire Contract Amount Type of Work Date Completed Provide additio al project description to show similar work: 1�'"a I 4.�r 2. OSWA Ckn ! AAAR U Giv►C- IA Name and Address of Public Agency Name and Telephone No. of Project Manager: IMYUYq Cie r4x. 1 N, (QLti Z--4 r 3 ►�g os�— Gv&tA A--c- (� CA)A 1, Contract Amount Type of Work Date Completed Provide a rtionaI project description to show similar work: ST en 3. "14 e4o �60 f--� 110(060 p,�,l,�Ntrfw- 81U) Name and Address of Public Agency Name and Telephone No. of Project Manager: P-4441 60q [qlq Contract Amount Type of Work Date Completed Pro de adds onal project description to show similar work: C-10 Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager, and Superintendent. For each of these critical positions,please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project. Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. 1. to Ol('t1U1Z Name of proposed Project Manager Telephone No. of proposed Project Manager: 02)5-4 5 41. '&�I & I I W 6qI Fr- ", 1 / 1(, Project Name & Contract Amount Type of Work Date Completed (�VmoA-C Project Name & Contract Amount Type of Work Date Comp el ted Project Na e & Contract Amount Type of Work Date Completed 2. Name of proposed Superintendent Telephone No. of proposed Superintendent: (562) 19-5841 � wAit*� Aj6 bmy OqS qzol Project NAne & Contract Amount Type of Work Date Completed L-AMAID Ale 3, M DSO smile ® Zo t Project Name & Contract Amount Type of Work Date Completed �T qn wuz� P ject Name & Contract Amount Type of Work Date 6ompleted C-11 CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)), passed by the California State Senate on June 20, 2014, established a new public works Contractor Registration Program, which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July 1 through June 30 state fiscal year) with the California Department of Industrial Relations (DIR). Currently the annual non-refundable registration fee for Contractors is $300. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT SHEET on SB 854 http://www.dir.ca.gov/DLSE/PublicWorks/SB854FactSheet_6.30.14.pdf DIR's Contractor Registration Link—Call (844) 522-6734 https://efiling.dir.ca.gov/P WCR/ActionServlet?action=displayPWCRegistrationForm DIR's Contractor Registration searchable database: https://efiling.dir.ca.gov/PWCR/Search.action I am aware and will comply with the provisions of Labor Code Section 1771.l(a) which states: "A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded." I furthermore will comply by providing proof of registration with DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. raw WC. "A -0,PAIW6 Contractor By Title Date: DIR#: C-12 STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycle) RELIABLE CONTRACTOR DECLARATION CalRecycle 168(Revised 7/13) This form must be completed and submitted to the Department of Resources Recycling and Recovery(CalRecycle) prior to authorizing a contractor(s) to commence work. Failure to provide this documentation in a timely manner may result in nonpayment of funds to the contractor(s). This form is intended to help the CalRecycle's Grantees comply with the Unreliable List requirement of their Terms and Conditions. The Unreliable List provision requires the following: Prior to authorizing a contractor(s) to commence work under the Grant, the Grantee shall submit to CalRecycle a declaration signed under penalty of perjury by the contractor(s) stating that within the preceding three (3) years, none of the events listed in Section 17050 of Title 14, California Code of Regulations,Natural Resources, Division 7,has occurred with respect to the contractor(s). Please see the reverse of this page,or refer to www.calre sg com If any of the events listed in Section 17050 have occurred, disclosure is required but will not necessarily result in CalRecycle refusing to approve the contractor. A signed statement explaining the facts and circumstances of the events must be attached to and submitted with this form. Contractor: Complete the form and send original to the Grantee. Grantee: Scan the form and upload it to the grant in CalRecycle's Grant Management System (GMS). For further instruction about logging into GMS and uploading this form, reference the Procedures and Requirements. Retain the original form in your grant file. .� _,a ,� r F.e- s3 .. .r°' -i.,: SS`✓ �; 4 ^. .. --� a'�._,E.n. 4.k,>„t u* t trro``-s -r`�t' x q 5 v.. GRANTEE NAME: GRANT NUMBER: City of Huntington Beach TRPS,Grant ID 17197 PRIMARY CONTACT NAME: Thomas Herbel,City Engineer, 714-375-5077 J CONTRACTOR NAME: , M EL PAVING COMPANY AUTHORIZED CONTRACTOR REPRESENTATIVE NAME: pinto O'[JU•UV' MAILING ADDRESS: Ba4} LalClid AVENUE nr As the authorized representative of the above identified contractor, I declare under penalty of perjury under the laws of the State of California that within the preceding three (3)years, none of the events listed in Section 17050 of Title 14, California Code of Regulations, Natural Resources, Division 7, has occurred with respect to the above identified contractor. Alternatively, as the authorized representative of the above identified contractor, I declare under penalty of perjury under the laws of the State of California that within the preceding three (3)years, if any of the events listed in Section 17050 of Title 14, California Code of Regulations, Natural Resources, Division 7, has occurred with respect to the above identified contractor, I have disclosed all such occurrences in an attached signed statement that explains the facts and circumstances of the listed events. f Signature C- 1,ti,�—� Date C-13 STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycle) RELIABLE CONTRACTOR DECLARATION CalRecycle 168(Revised 7/13) Title 14 CCR,Division 7,Chapter 1 Article 5.Unreliable Contractors,Subcontractors,Borrowers and Grantees Section 17050. Grounds for Placement on Unreliable List The following are grounds for a finding that a contractor, any subcontractor that provides services for a CalRecycle agreement, grantee or borrower is unreliable and should be placed on the CalRecycle Unreliable Contractor, Subcontractor, Grantee or Borrower List ("Unreliable List"). The presence of one of these grounds shall not automatically result in placement on the Unreliable List. A finding must be made by the Executive Director in accordance with section 17054,and there must be a final decision on any appeal that may be filed in accordance with section 17055 et seq. (a) Disallowance of any and/or all claim(s)to CalRecycle due to fraudulent claims or reporting;or (b) The filing of a civil action by the Attorney General for a violation of the False Claims Act,Government Code section 12650 et.seq;or (c) Default on a CalRecycle loan,as evidenced by written notice from CalRecycle staff provided to the borrower of the default;or (d) Foreclosure upon real property loan collateral or repossession of personal property loan collateral by CalRecycle;or (e) Filing voluntary or involuntary bankruptcy,where there is a finding based on substantial evidence,that the bankruptcy interfered with the CalRecycle contract,subcontract,grant or loan;or (f) Breach of the terms and conditions of a previous CalRecycle contract,any subcontract for a CalRecycle agreement, grant,or loan,resulting in termination of the CalRecycle contract,subcontract,grant or loan by the CalRecycle or prime contractor;or (g) Placement on the CalRecycle's chronic violator inventory established pursuant to Public Resources Code section 44104 for any owner or operator of a solid waste facility;or (h) The person,or any partner,member,officer,director,responsible managing officer,or responsible managing employee of an entity has been convicted by a court of competent jurisdiction of any charge of fraud,bribery,collusion, conspiracy,or any act in violation of any state or federal antitrust law in connection with the bidding upon,award of,or performance under any CalRecycle contract,subcontract,grant or loan;or (i) The person or entity is on the list of unreliable persons or entities,or similar list,of any other federal or California state agency;or (j) The person or entity has violated an Order issued in accordance with section 18304;or, (k) The person or entity has directed or transported to,has or accepted waste tires at,a site where the operator is required to have but does not have a waste tire facility permit;or, (1) The person or entity has transported waste tires without a waste tire hauler registration;or, (m) The person or entity has had a solid waste facility or waste tire permit or a waste tire hauler registration denied, suspended or revoked;or, (n) The person or entity has abandoned a site or taken a similar action which resulted in corrective action or the expenditure of funds by CalRecycle to remediate,clean,or abate a nuisance at the site;or (o) The following are additional grounds for a finding that,a person or entity described below should be placed on the Unreliable List: (1) The person or entity owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (2) The person held the position of officer director,manager,partner,trustee,or any other management position with significant control(Principal Manager)in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (3) The entity includes a Principal Manager who: 1. Was a Principal Manager in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List; (4) The entity has a person who owns 20%or more of the entity,if that person: 1. Was a Principal Manager in an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List. (5) The entity has another entity which owns 20%or more of the entity,if that other entity: 1. Is on the Unreliable List;or, 2. Owned 20%or more of an entity on the Unreliable List at the time of the activity that resulted in its placement on the Unreliable List. (6) Subsection(o)is not intended to apply to a person or entity that purchases or otherwise obtains an entity on the Unreliable List subsequent to its placement on the Unreliable List. C-14 Bond No. Bid Bond BID BOND The American Institute of Architects, AIA Document No.A310(February, 1970 Edition) KNOW ALL MEN BY THESE PRESENTS,that we PALP Inc.dba Excel Paving Company as Principal hereinafter called the Principal,and Federal Insurance Company a corporation duly organized under the laws of the state of Indiana as Surety, hereinafter called the Surety, are held and firmly bound unto City of Huntington Beach as Obligee,hereinafter called the Obligee,in the sum of Ten percent of the total amount of the bid Dollars (S 10% ), for the payment of which sum well and truly to be made,the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators,successors and assigns,jointly and severally, firmly by these presents. WHEREAS,the Principal has submitted a bid for Main Street,Talbert,Heil Avenue Rehabilitation(CC1527) NOW,Tf MR.EFORE,if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material fiunished in the prosecution thereof; or in the event of the failure of the Principal to enter such Contract and give such bond or bonds,if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid,then this obligation shall be null and void,otherwise to remain in full force and effect. Signed and sealed this 12th day of July 2016 PALP Inc.dba Excel Paving Company Witness Principal (Seal) i By: a OR4.1°,'r"�, P�KSIDEsl7 Name/ritle Federal Insurance Company Surety (Seal) 4JO Witness ' Douglas U app Attomey-in-Fact ORSC 21328(5/97) ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange On JULY 12, 2016 before me, Debra Swanson, Notary Public (insert name and title of the officer) personally appeared Douglas A. Rapp who proved to me on the basis of satisfactory evidence to be the person() whose name() is/afe subscribed to the within instrument and acknowledged to me that he/44e4l;H� executed the same in his/4e4 re i authorized capacity{i ), and that by hiss;; signature( on the instrument the person(*, or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. a 'LOFT WITNESS my hand and official seal. 'S�. N60 DE MM.# 99711 0)�N COMMA.# 1997119 7J ® NOTARY PUBLIC-CALIFORNIA;7 ' ORANGE COUNTY N (� MY COMM,EXR NOV 10,2016 Signature (Seal) Chubb POWER Federal Insurance Company Attn: Surety Department OF Vigilant Insurance Company 15 Mountain View Road Surety ATTORNEY Pacific Indemnity Company Warren, NJ 07059 oHulae Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana corporation, VIGILANT INSURANCE COMPANY, a New York corporation, and PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Douglas A. Rapp and Timothy D. Rapp of Aliso Viejo,California----------------—-----—----------------------------- each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise, bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations. In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY have each executed and attested these presents and affixed their corporate seals on this 16th day of December,2011. Kenneth C.Wendel,Assistant Secretary .N�Vic-eent STATE OF NEW JERSEY ss. County of Somerset On this 16th day Of December, 2011 before me,a Notary Public of New Jersey,personally came Kenneth C.Wendel,to me known to be Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY, the companies which executed the foregoing Power of Attorney, and the said Kenneth C. Wendel, being by me duly sworn, did depose and say that he is Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY and knows the corporate seals thereof, that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by authority of the By-Laws of said Companies;and that he signed said Power of Attorney as Assistant Secretary of said Companies by like authority;and that he is acquainted with David B.Norris,Jr.,and knows him to be Vice President of said Companies;and that the signature of David B. Norris,Jr.,subscribed to said Power of Attorney is in the genuine handwriting of David B.Norris,Jr.,and was thereto subscribed by authority of said By- Laws and in deponent's presence. Notarial Seal AD, KATHERINE J.ADELAAR NOTARY PUBUC OF NEW JEkSF) No.2316685 " P 6L�G Commiition es ExpirJUly IA,2014 a� Notary Public CERTIFICATION Extract from the By-Laws of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY: "All powers of attorney for and on behalf of the Company may and shall be executed in the name and on behalf of the Company,either by the Chairman or the President or a Vice President or an Assistant Vice President,jointly with the Secretary or an Assistant Secretary, under their respective designations. The signature of such officers may be engraved,printed or lithographed.The signature of each of the following officers:Chairman,President,any Vice President,any Assistant Vice President,any Secretary, any Assistant Secretary and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof,and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached! I,Kenneth C.Wendel,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY (the"Companies?do hereby certify that (i) the foregoing extract of the By-Laws of the Companies is true and correct, (ii) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are authorized by the U.S.Treasury Department;further,Federal and Vigilant are licensed in Puerto Rico and the U.S.Virgin Islands,and Federal is licensed in American Samoa,Guam,and each of the Provinces of Canada except Prince Edward Island;and (iii) the foregoing Power of Attorney is true,correct and in full force and effect. Given under my hand and seals of said Companies at Warren,NJ this 12TH day of JULY,2016 W � a _* • S r 7 �t'i]IANP as *•�� aEw Kenneth C.We el,Assistant Secretary IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM,VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER,PLEASE CONTACT US AT ADDRESS LISTED ABOVE,OR BY Telephone(908)903-3493 Fax(908)903-3656 e-mail: surety@chubb.com Form 15-10-02256-U (Ed.5-03) CONSENT C/WFORNIA ALL-PURPOSE ACKNOWLEDGMENT CML CODE§1189 A notary public or other officer completing#a certificaite verifies only the identity of the WAdual who signed the doaxnent to which this certiflca to is MacW,and not the truthWhess,accuracy,or validity of that document State of California ) County of Los Angeles ) On before me, C. Phillips, Notary Public" Date Here Insert Name and Tide of the Officer personally appeamd C. P. Brown Narne(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be t person(*he perso whose names) isMw subscribed to the within instrument and acknowledged to me that he/ y executed the same in hiss authorized capacity(ies),and that by his/! c signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of Califomia that the foregoing paragraph is true and correct. WITNESS my hand and official seal. ^rotary raObllc-California w LOS ANGFLES COUNTY LL My Comm.Expires Oct.29,2016 t Signature. ilnat of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signers) Other Than Named Above: Capacity(ies)Claimed by Signer(s)" Signer's Name: Signer's"Name: ❑Corporate Officer-Title(s): O Corporate Officer- Title(s): ❑Partner — ❑Limited ❑General ❑Partner— ❑Limited �General ❑Individual O Attomey in Fact O Individual O Attorney,in Fact ❑Trustee O Guardian or Conservator O Trustee O Guardian or Conservator fl Other. O Other. Signer Is Representing~ Signer Is Representing:- @2014 National Notary Association•www.NationalNotary.org• 1-800-US NOTARY(1-800-876-6827) Item#5907 City of Huntington Beach 2000 Main Street ♦ Huntington Beach, CA 92648 (714) 536-5227 ♦ www.huntingtonbeachca.gov J) 1O�S Office of the City Clerk FB. 09 P � Robin Estanislau, City Clerk October 26, 2016 Hardy & Harper, Inc. 1312 E. Warner Ave. Santa Ana, CA 92705 RE: Main St., Talbert Ave., Heil Ave. Rehabilitation — CC-1527 Enclosed please find your original bid bond for CC-1527. Sincerely, 44� 94hWdj4tU) Robin Estanislau, CIVIC City Clerk RE:pe Enclosure Sister Cities: Anjo, Japan ♦ Waitakere, New Zealand t.} +4 J and+,r r' #' a° d 5 P' wFr+ 5; as# ,e, J }..r '�"} - ,� tVs .,P ;4r'# x M« #S4r J`t J.ir u n xs P�w air § a a' x J t r r•'.'' ,�s ,.�/+� .S ^ yar'd i` 't `P t` N„ ',m �k a `' at rt. f r o-r > ,,r } g y, � 5 i,R �r r< } ' � `'�``! _', y,. + r• -ca+,a� .F£ttt 2 ,j x `&'* {a t' r'�a tt`dll-� 01 .ram`. t.r •+' !-�»,ka- ;asy '7 ,- c:_ } Wz L a x''x o-P-'" .� '� r t g2{.4 r 7`1 wa'rA ✓ IV, ,.. m��=:._4,¢���SYk.7a�i§ ry'��'�•v��t�#`.t 3�P �R �?�+o'�"�}�'��"#4S�S�' ��" ,rsa,#t'ty'L+3��,xa. j $ �..�t d_ Y 17. i }; \^� 'J"��,*�i'�,z,}�ri ����}'lr �t y,�#fir• �fi',�,'vv� i'�*t£q��w�St��A a#��',-�"����#` ,�fr-�F�-2gt e�!�,:.'.n r �� aC# ++th I rll F r ir't� ° #�r1"4 "rW f sas X; :r';��Fadt •G7- .�, °.` } ,�a�xr9 •-� ry xfi �q .�' �:���:��. ..��- 4s'�:-� `7`a # t�#d�,r t � .a � t,Ft �. , sP;;"#'S'y `ta�kx4 "`y5``v+P��;�.%K�xx k'�;�rp�':t3 ;PSQ<�E `'ak a4�✓; �'`��� �ti,,, a' c�3?FE.rz �#P'^ e��2""+3t'''�,� JNt��a,Nk�lr#v9"�u�y t,t;v#4ry„J,.,+ r4{�( $r»wp�J,##t k'a'"xh`S.I',` t r" a�r'" �drl i la,�.3 S� r�#tr3 <T. �.�b rarY,�� '.a ��^�*y�:�Tv'3$SY $M�"n r�x,�'t} t�.�%r, a_.s1��ti�,�.rs�i'F d ar a^yfr :Ky t,�cc L �'h fiktir $'.,,'e k FM� :y"�."k F^{•�'`a 7c'�< 1: X i-yt :��. X 3��r�F•� g$§�`.+j �dOTua� �^ rrv# rr5 �� tt�ry :� �"aNs,:�MX3n 11#'�� ��'� � a.,3 yr :ra•�, i'.d3rJJ`-°�'1� 3 n �'4•�'.���i*wth#`tea 9-�r,�,t� a�, }'F.i ti�#t T 75+4t'��t.�F��.a� ,�.y ,,.'�.� ,kr 3 � a k! x h t SD m' '� t'-� -.,%+jr-: 21 _ # r '� t e.t-"0 sk tvr'� L7 r• 1'� �' st`o_.r s.'n,r+�z�'�w�` Fr y'' vN' Acc= U ' x„ �,t e *ri`'rz' iFi "tt.0 '�• 4 ! '�yy' "_'Mi#Eye ua^t•r' ' v O Ca - r'C �� Q � � N ,� � � � ��t�.t,. }>x T r f� e�'1K>., �z' ?£rs+�¢�'sC� ",,r ii'�+• r Q U CD ON � ,attSxlrt fa '"� C� r ¢ >< r, t a 5 d! 9 : 6+ ; F'i j�y�elf. rz�,t a LLl CD j 3 rq�t i tr }Ri N U 6ttrr s #x# + t�tlt rt #ts > �F{ �: s t'r�', t m r e sf r.. a y ar- r-+ ,«v'- t o ",7r f 7 I rm pax q $4 .N � }s.�F� airy a � F`?. •41t-..�� + Qa x a t U sc IY t+3 -t-`'z' rt,'.^ 'fixr< fatt a 3P cwEi.%r1.i }a 21rt;a,�Tt,Jr3}'k4#� 's=fiv`' s'' r 'ry aM-� .rrkt t t�E( .€a$ 32 x5 iJ tv"NaF— te �— ��;r�,�'u i r a k w�� 1 NA" �` r 'rtr fir#�-.t§ N d�26s �, ��"x%;k�^,B �`§f �` 4�r• 9t � � t R+ -,ttS r3 +x r �"§ti ����` �,. a�'� �y t a""'M1s�,lis,;�`��p�f Jl k�:! "�F�?,#"zk���z�u-gl a ��+a+$i 3't�,Oat�:.t� �� � �. ^z �t 3•- 5.y`�t a '� �7 #xt a�u `0", �aara }�; ��'„ .L � � y�I ,"ui."yj +m � .r� C " Fi ,yeYi t"4'# M,. #a h t a '# t ,3 -%>•. .-�... wr Pr % ,p ,t id t`ix t�t N- r- t p a 7. �Riv 'J �•z ss t' tii �zb�i P a fit' C^++ !z r x�s i) ry'" x - ' i, '.�,, #�' z�a,?r, sa, '+f. �, e a} $ a' '•v ��tka�w w �,�* �,ht'v.�'��-' r r .� r G- F j33 CL -.� �'•t's � to $� - � �'t �� Yr�xt {t.r�y1<�X A�.a.= a,.sr ,2 i % � > . �` 1 ri y s{ titc�g' }tx a{� rFla s "AI rc ,:,� tea..����- 9. #��n .N �.�"fitM�� � a✓'�'�' rx<' � nt�� � � � v �'�3 i "�E4 t t c r. .,8 +•Y?^y +5� .. _ & s "*"' k=c-- `3' rr'x b s 'j r a`E{+. ;' a as SECTION C PROPOSAL for the construction of MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Sealed Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of;and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 80 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications.. Instructions to Bidders and all other contract documents. if this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forf-eiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes. royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertisc the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. C-1 el If awarded the Contract. the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option; be considered null and void. Accompanying this proposal of bid, find Bidder's Bond in the amount of lo%of Amount which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Sealed Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond forio% as the case may be) Any standard Surety Bid Bond form is acceptable. Bidder shall signify receipt of all Addenda here, if any: Addenda No. Date Received � ldergnature #! C-2 0 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 PROJECT BASE BID: Basis of Award Main Street Rehabilitation from Garfield Avenue to Delaware Street, Talbert Avenue Rehabilitation from Gothard Street to Newland Street, and Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street. . . . . . . . . C-2.2 to C-2.1.5 1. MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street $ 5� � � 000 I 2.TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street i i $ 1 , 4000 noo 3. HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street $ BASE BID TOTAL AMOUNT LUMP SUM BID IN FIGURES: (TOTAL FOR ITEMS 1. 2. & 3) i i BASIS OF AWARD C-2.1 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 MAIN STREET FROM GARFIELD AVENUE TO DELAWARE STREET CC NO. 1527 C-2.2 — PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Const. Bid Contract Unit Extended No. Note Description Quantity j Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). e 1 1 (INCLUDES ALL 2 EA $ ���jp4 $ APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT OAT FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16) WET PROCESS 2 3 OVERLAY PER TYPICAL 2,200 TN $ ��•`1�2 $ 42,2ol( SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 4 EA $ bmo GRADE. f $ REPLACE WATER VALVE BOX 4 5 ASSEMBLY AND ADJUST TO 19 EA $ 50•oo $ �y 2S0 GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 22 5 6 PAVEMENT TO A DEPTH OF 171,300 SF $ . 7o $ �Jr7 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 6 6 A.C. BASE COURSE OVER 95% 2,200 TN $76. 76 $ ltiin COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. C-2.3 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 7 8 SIGNALS AND LIGHTING 52 EA $ Z�� °� $ poi o SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE AND RECONSTRUCT MEDIAN CURB PER HB STD PLAN 201 (CF=8"). (INCLUDES 8 9 SLOT PAVEMENT, AGGREGATE 50 LF $ *'oo $ Z, /oa BASE, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8").9 10 (INCLUDES SLOT PAVEMENT, 30 LF $ S° eo $ 11500 AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 10 11 DRIVEWAY CURB SECTION AS 50 SF $ 4 /S $ y09, 00 MODIFIED PER DETAIL ON SHEET 3. RAISE SURVEY WELL MONUMENT TO GRADE AND 11 12 PREPARE CORNER RECORD 1 EA $ 2,o_T 1) $ 2 a2 (PRE-AND/OR POST- CONSTRUCTION). INSTALL TRUNCATED DOMES 12 13 TO EXISTING CURB ACCESS 8 EA $ 511,00 $ 6�b RAMP PER CALTRANS STD. PLAN RSP A88A OR RSP A88B. C-2.4 PROJECT BID SCHEDULE MAIN (GARFIELD-BEACH) Const. Bid Contract Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 13 14 EXISTING SLOPE, RELOCATING 600 SF $ Sy $ �j,12 y IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT 14 15 STAMPED CONCRETE PER HB 50 LF $ $_-7 5'pa STD PLAN 711. -15 MOBILIZATION 1 LS $ �jo�aoo $ 30�aoa 16 TRAFFIC CONTROL PLAN 1 LS $ Sooa $ J/ aoo FURNISH PROJECT TRAFFIC 17 CONTROL 1 LS $ Zi4� o00 $ 2✓��000 18 FURNISH AND INSTALL SIGNING 1 LS $ Z 9/s $ ZO,9/S AND STRIPING 19 PROJECT SPECIFIC SWPPP 1 LS $ ;Lwo $ Zoo 0 FURNISH AND INSTALL ZEBRON OR SANCON OR AGENCY 20 APPROVED EQUAL COATING ooa 2 LS s I,Sao $ ON NEW CONCRETE ON INSIDE OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ 7 6 000 Total Amount Bid in Words: 1, ............5..,.: ..-...oAIt _T sU ................ .._.. ...... .......................... C-2.5 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HELL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 TALBERT AVENUE REHABILITATION FROM GOTHARD STREET TO NEWLAND STREET CC NO. 1527 C-2.6 - PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract' Unit Extended No. Note Description Quantity Unit Price Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 22 C 1 1 (INCLUDES ALL 16 EA $ J,%ov $ ,$00 APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT 2 3 RUBBER HOT MIX (ARHM GG- 5,700 TN $ �2, a 2 $ 72 071/ C1/2"PG 64-16) WET PROCESS OVERLAY. 3 4 ADJUST SEWER MANHOLE TO 21 EA $ GRADE. oo v $ 2/ ono 4 5 ADJUST STORM DRAIN 9 EA $ 1 000 $ moo MANHOLE TO GRADE. � REPLACE WATER VALVE BOX 5 6 ASSEMBLY AND ADJUST TO 60 EA $ 7s°, oo $ /S�000 GRADE PER HB STD PLAN 612. COLD MILL EXISTING A.C. 6 8 PAVEMENT TO A DEPTH OF 440,020 SF $ , 30 $132 oo 6 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED (� 7 8 A.C. BASE COURSE OVER 95% 5,700 TN s76,16 $ /3 7i 53 2- COMPACTED SUBGRADE PRIOR TO 0.17'ARHM OVERLAY, PER PLANS. INSTALL TRUNCATED DOMES TO EXISTING CURB ACCESS RAMP AS REQUIRED PER 8 10 CALTRANS STD. PLAN RSP 2 EA $ �� °° $ A88A. C-2.7 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Bid Const. Contract' Unit Extended No: Note Description Quantity Unit Price I Amount REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). S 9 11 (INCLUDES SLOT PAVEMENT, 245 LF $ ✓° aO $ AGGREGATE BASE, LOT —� DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 10 12 EXISTING SLOPE, RELOCATING 6,300 SF $ zoz IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT DEEPENED CURB AND GUTTER PER HB STD. PLAN 202(B) 11 13 (CF=8"). (ITEM INCLUDES 60 LF $ ��• oo $ 3, o o a REBAR, CLASS 560-C-3250 CONCRETE, SLOT PAVEMENT, AGGREGATE BASE, AND LOT DRAIN IF PRESENT.) REMOVE AND RECONSTRUCT 12 14 DRIVEWAY CURB SECTION AS 45 LF $ 00 $ 2 1 6 0 MODIFIED PER DETAIL ON —f - SHEET 5. REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP 13 15 AND ROOTS TO 24" BELOW TOP 7 EA $ 00e $ 7, o D OF SIDEWALK/GRADE. PULL OUT ALL ROOTS WITHIN PROPOSEDIMPROVEMENTS. C-2.8 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) i Bid Const. Contract', Unit Extended No. Note Description Quantity. Unit Price Amount INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 14 16 SIGNALS AND LIGHTING 61 EA 00 $ SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE EXISTING RETAINING WALL WITHIN CITY RIGHT-OF- WAY AND CONSTRUCT NEW RETAINING WALL (OPTION 2) BEHIND CITY RIGHT-OF-WAY PER HB COMMUNITY DEVELOPMENT BUILDING DIVISION STD PLAN NO. 3 AND q 15 17 DETAIL ON SHEET 5. (ITEM 1 LS INCLUDES EXCAVATION AND/ OR BACKFILL, RE-GRADING, RELOCATING EXISTING IRRIGATION, RETURNING LANDSCAPE BEHIND WALL TO PRE-CONSTRUCTION CONDITIONS AND ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE.) REMOVE AND RECONSTRUCT LOCAL DEPRESSION PER HB STD PLAN 302. (INCLUDES SLOT 16 18 PAVEMENT, AGGREGATE BASE, 180 SF $ �� �g $ 3, Z�Z •`� AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 17 19 205. (ITEM INCLUDES SLOT 4,380 SF $ lid •�g $7g PAVEMENT, AGGREGATE BASE AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.9 PROJECT BID SCHEDULE TALBERT (GOTHARD-NEWLAND) Const. Bid Contract Unit Extended No. Note Description Quantity, Unit Price Amount 18 MOBILIZATION 1 LS $ o o ao $ 30� o00 19 TRAFFIC CONTROL PLAN 1 LS $ oaa $ Sand 20 FURNISH PROJECT TRAFFIC 1 LS $ Sq CONTROL ova $ 34lyoo � 21 FURNISH AND INSTALL SIGNING 1 LS $ Sk 161.20 $ i5 Ill. Zc AND STRIPING 22 PROJECT SPECIFIC SWPPP 1 LS $ Z�000 $ Zj coo Total Amount Bid in Figures: $ I 4 q o 0o o TotaL..Amoun..Bid in Words p��. 1'1.�.�fi�n. _ . . .wed �l . !tee / . .h°u . ... ... ... C-z.10 SECTION C PROJECT BID SCHEDULE MAIN STREET REHABILITATION from Garfield Avenue to Delaware Street TALBERT AVENUE REHABILITATION from Gothard Street to Newland Street AND HEIL AVENUE REHABILITATION from Edwards Street to Goldenwest Street CC NO. 1527 HEIL AVENUE REHABILITATION FROM EDWARDS STREET TO GOLDENWEST STREET CC NO. 1527 -- C-2.1.1 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity I Unit Price I Amount REMOVE AND RECONSTRUCT CURB ACCESS RAMP, DEPRESSED CURB, AND GUTTER PER CALTRANS STD PLAN RSP A88A FROM BCR TO ECR. (CASE SHOWN ON PLAN). 2 1 1 (INCLUDES ALL 9 EA $ J 3 000a $ 2,q Too APPURTENANCES, CURB GUTTER, DEPRESSED CURB, SIDEWALK, DOMES, RETAINING CURB, SLOT PAVEMENT, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) CONSTRUCT 0.17' FIBER REINFORCED ASPHALT RUBBER HOT MIX (ARHM GG- C1/2"PG 64-16) WET PROCESS 2 3 OVERLAY PER TYPICAL 1,970 TN $ $ 163�1sf. y° SECTION ON SHEET 3. (INCLUDES ALL ITEMS NECESSARY TO COMPLETE WORK IN PLACE. 3 4 ADJUST SEWER MANHOLE TO 1 EA $ 1 0�0 $ GRADE. —t ADJUST OCSD MANHOLE TO GRADE PER OCSD STD. PLAN S 4 5 053, S-054 AND S-055. 5 EA $ 31000 $ �S� 000 CONTRACTOR TO COORDINATE WITH MIKE BOLSTER AT(714) 593-7645. ADJUST STORM DRAIN 5 6 MANHOLE TO GRADE. 1 EA $ �,� 60 $ (1o�o REPLACE WATER VALVE BOX 6 7 ASSEMBLY AND ADJUST TO 10 EA $1 50.oo $ 7�5-oo GRADE PER HB STD PLAN 612. C-2.12 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount COLD MILL EXISTING A.C. 7 8 PAVEMENT TO A DEPTH OF 153,310 SF $ - �✓ a $ y �a-5 0.34' FROM NEW FINISHED SURFACE PER PLANS. CONSTRUCT NEW 0.17' B-PG-70 10-RAP FIBER REINFORCED 8 8 A.C. BASE COURSE OVER 95% 1,970 TN $ W, 7 6 $ COMPACTED SUBGRADE PRIOR T TO 0.17'ARHM OVERLAY, PER PLANS. REMOVE AND RECONSTRUCT CONCRETE CURB AND CROSS GUTTER PER HB STD. PLAN 9 10 205. (ITEM INCLUDES SLOT 1,730 SF $ I $ �j� y5'I,L(o PAVEMENT, AGGREGATE BASE —� AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT CURB AND GUTTER PER HB STD PLAN 202 (CF=8"). 10 11 (INCLUDES SLOT PAVEMENT, 1,100 LF $ 50. oa AGGREGATE BASE, LOT DRAINS, AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT SIDEWALK PER HB STD. PLAN 207 AND AS MODIFIED ON PLANS. (INCLUDES OVER EXCAVATION OR FILL FOR CHANGES IN GRADE, RE- GRADE FROM WALK TO 11 12 EXISTING SLOPE, RELOCATING 10,100 SF IRRIGATION TO BACK OF NEW WALK, RETURNING LANDSCAPING TO PRE- CONSTRUCTION CONDITION AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) C-2.i 3 REVISED PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount INSTALL COLORED PERVIOUS CONCRETE, COLOR AND SCORING PATTERN CALLED OUT ON PLAN. (INCLUDES OVER EXCAVATION OR FILL lr 22 13 FOR CHANGES IN GRADE, RE- 1,980 SF $ t .00 $ /� go GRADE FROM WALK TO i EXISTING SLOPE, RELOCATING IRRIGATION TO BACK OF NEW WALK AND ALL ITEMS NECESSARY TO COMPLETE THE WORK IN PLACE.) REMOVE AND RECONSTRUCT COMMERCIAL/ RESIDENTIAL DRIVEWAY ("W"AND TYPE q 12 14 SHOWN ON PLAN) PER STD 1,040 SF PLAN 209 OR 211. MATCH EXISTING IMPROVEMENTS TO GRADE. INSTALL NEW DETECTOR LOOPS PER CITY STANDARD SPECIAL PROVISIONS FOR THE CONSTRUCTION OF TRAFFIC 13 15 SIGNALS AND LIGHTING 22 EA $ p, O 0 $ lj, 20 SYSTEMS, 2005 EDITION. SPLICE LOOPS TO DLC IN PULLBOX. BIKE LANE LOOPS AND ALL LOOPS AT LIMIT LINE SHALL BE TYPE "D". REMOVE EXISTING TREE AND ROOTS; GRIND TREE STUMP AND ROOTS TO 24" BELOW TOP 14 16 OF SIDEWALK/ GRADE WITHIN 14 EA $ rT $ ova PROPOSEDIMPROVEMENT AREA. Revised C-2.14 Addendum 1, CC-1527 PROJECT BID SCHEDULE HEIL (EDWARDS - GOLDENWEST) Bid Const. Contract Unit Extended No. Note Description Quantity Unit Price Amount SAWCUT AND REMOVE EXISTING SIDEWALK AT EXISTING AND CONSTRUCT TREE WELL WITH SIDEWALK PER DETAIL ON SHEET 3. (ITEM 15 17 INCLUDES REMOVAL OF 4 EA $ ✓) $ z/oa0 SIDEWALK, 6LF OF NEW SIDEWALK, NON-CHEMICAL WEED CONTROL BARRIER TO BE DUPONT LANDSCAPE MAX OR AGENCY APPROVED EQUAL AND MULCH. 16 MOBILIZATION 1 LS $ aoo $ 301 ono 17 TRAFFIC CONTROL PLAN 1 LS 18 FURNISH PROJECT TRAFFIC 1 LS $ o�y $ CONTROL 19 FURNISH AND INSTALL SIGNING 1 LS $ Z� 1 M o $Z` AND STRIPING 20 PROJECT SPECIFIC SWPPP 1 LS $_ �rIc 5M k- FURNISH AND INSTALL ZEBRON SM� OR SANCON OR AGENCY S r APPROVED EQUAL COATING �a 21 ON NEW CONCRETE ON INSIDE 4 LS $ $ / OF AGENCY SEWER MANHOLE RING. Total Amount Bid in Figures: $ 000 Total Amount Bid in Words. n.............. ......._ ..,........................ .. ..... �- ev ......., !.. !s..... c .... �n.................... .. . ......... ...,.,.. C-z.1 s LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class DIR w Dollar % of Item(s) Subcontractor License Numhei• Amount_. ;Contract- fNumber ✓� 1,1�� t✓I l� I I ��� G"l'17 100000 I(7�YOO,,0 AJ� I ben (7Car�Qi GP K 2� �1 i Tr.ec 162- oo C-Z� (c�ooaolis�i$ g, yso 1551 P, M 16-4 Avti,- cA b L1 Iq 7tip+.r,er f0,%Am:e✓+ r&A 95 1 '76-0& 10"DoIy G /96q o �yi I z c°I(ref) 13� y �t�i5 I�Z1q� n �000004286 465.00 C i By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on 7/25/16, at Santa Ana CA Dote Cit1; State Steve Kirschner being first duly sworn, deposes and says that he or she is Vice President of Hardy&Harper,Inc the party making the foregoing bid that the bid is not made in the interest of, or on the behalf of, any undisclosed person, partnership, company, association, organization; or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Hardy&Harper,Inc Name of Bidder Signature of Bidder Steve Kirschner- Vice President 1312 E.Warner Ave.,Santa Ana, CA 92705 Address of Bidder C-d UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the MAIN STREET REHABILITATION, TALBERT AVENUE REHABILITATION AND HEIL AVENUE REHABILITATION, PROJECT CC-1527, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person ivho, by reason ofexperience or instruction, is familiar with the operation to be performedl and the ha_ardv involve(l." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements; Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor- or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Hard),&Harper,Inc Contract By Steve Kirschner-Vice President Title Date: 7/25/I6 G5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162, the Bidder shall complete, under penalty ofperjury, the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes ® No 1f the answer is yes, explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code, each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Hardy&Harper,Inc Contractor By Steve Kirschner-Vice President Title Date: 7/25/16 C-7 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Hardy&Harper,Inc Bidder Name 1312 East Warner Ave. Business Address Santa Ana CA 92703 City, State Zip 714 ) 444-1851 Telephone Number 215952;A,C-8,C12 State Contractor's License No. and Class 3/13/63 Original Date Issued 12/31/17 Expiration Date The work site was inspected by Corey Kirschner of our office on July 14th _ , 2016 . The following are persons, firms, and corporations having a principal interest in this proposal: Fred T.Maas,Jr-President,Treasurer Dan T.Maas-CEO Steve Kirschner-Vice President Kristen S.Paulino-Secretary C-8 The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability. financially or otherwise; to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Hardy&Harper,Inc Compat ame a�. Signature of Bidder Steve Kirschner-Vice President Printed or Typed Signature Subscribed and sward to before me this day of . 201 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of ) County of ) On before me, Month, Day; and Year Insert Name and Title of Notary personally appeared Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s). or the entity upon behalf of which the person(s) acted. executed the instrument. I certify under PENALTY 017 PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. swynature Signature of Notary Public (PLACE NOTARY SEAL ABOVE) C-9 CALIFORNIA JURAT WITH AFFIANT STATEMENT GOVERNMENT CODE§8202 ❑See Attached Document (Notary to cross out lines 1-6 below) ❑See Statement Below (Lines 1-6 to be completed only by document signer[s], not Notary) Signature of Document Signer No. 1 Signature of Document Signer No. 2 (if any) A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California Subscribed and sworn to (or affirmed) before me County of _ Orange on this 25 day of July , 20 16 by Date Month Year (1) st�v� �orsch� NA PHAM H (and (2) COMM.#2149384 M fn ! k W `;V Notary Public California Name(g)of Signer 0 ?- ORANGE COUNTY a My Comm.Expires Apr 17,2020 proved to me on the basis of satisfactory evidence to be the person(a) who appeared before me. Signature Signature of Notary Public Seal Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Bidder's Information Document Date: July 25, 2016 Number of Pages: __2_—Signer(s)Other Than Named Above: None zzve cx zee e c cc�� � vc�> zez �ce�c��uz �c <e<xccv, ©2014 National Notary Association • www.NationalNotary.org • 1-800-US NOTARY(1-800-876-6827) Item#5910 Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work, specifically referencing the construction of {Describe specific work and experience necessary for project. For example, "Sanitary sewer line installation of at least of 1,000 of 8-inch and greater in public right-of-way. Sanitary sewer lift stations of similar size, project work within public streets, an area containing hiah around water and pipeline construction in hiah around water regions vvith trench depths of 8-feet to the invert."}. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: I. Please see attachment"A" Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount 'hype of Work Date Completed Provide additional project description to show similar work: 2. Name and Address of Publie Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: Name and Address of Public Agency Name and Telephone No_ of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: C-10 PUBLIC WORKS REFERENCES Attachment A 2015/2016 Owner/Agency Contact Project (Amount & Completion Date) City of Hesperia Dwaine Latimer, P.E. Street Improvements and 9700 Seventh Avenue (760) 947-1434 Main Street Bridge Rehab Hesperia, CA 92345 dlatimeraa)cityofhesperia.us $1,184,570.00 01/15 City of Covina Natalie Avila Resurfacing of Streets at 125 E. College Street (626) 384-5400 Hollenbeck Ave, Cypress St. Covina, CA 91723-2199 RAvila covinaca.gov $624,297.95 8/15 City of Pasadena Richard Yee Preventitive Maintenance 100 N Garfield Ave (626) 744-4643 Street FEDERAL ID NO. Pasadena, CA 92570 STPL-5064(081) $1,518,231 .24 8/15 City of Eastvale Ruben Castaneda SCHLEISMAN ROAD 12363 Limonite Ave., Suite 910 (951) 703-4472 Overlay STPL-5486(002) Eastvale, CA 91752 rcastanedaCa�eastvaleca.gov $333,333.00 8/15 City of Cathedral City Bill Simmons Date Palm Drive Street 68700 Avenida Lalo Guerrero (760) 770-0340 Improvement, 1-10 to Vander Cathedral City, CA 92234 bsimmons@cathedralcity.gov Rd Bid # 1315-02E Proj # 8668 $406,064.90 8/15 City of Laguna Niguel Frank Borges St. Christopher Neighborhoods 30111 Crown Valley Parkway (949) 362-4325 & Via Vetti Pavement Rehab Laguna Niguel, CA 92677 FBorges(a�cityoflagunaniquel.org Improvement No. 15-02 $1 ,226,861 .00 9/15 City of Norco Bill Thomas FY 2015-16 Annual Minor 2870 Clark Ave (951) 735-3900 Street Rehabilitation Phase I Norco, CA 92860 $777,000.00 10/15 City of Norco Bill Thomas FY 2015-16 Annual Minor 2870 Clark Ave (951) 735-3900 Street Rehabilitation Phase 11 Norco, CA 92860 $547,000.00 11/15 PUBLIC WORKS REFERENCES Attachment 2015/2016 City of Walnut Natalie Avila, P.E Area 1 & 2 Street 21201 La Puente Rd. (909) 594-9702, Ext. 315 Resurfacing Project Walnut, CA 91789 navilaCa)rkagroup.com $1,077,000.00 11/15 City of Rancho Cucamonga Romeo David Foothill Blvd Pavement 10500 Civic Center Drive (909)477-2740 Rehabilitation Rancho Cucamonga, CA 91730 Romeo.DavidCcDcityofrc.us $1 ,076,200.00 11/15 City of Simi Valley Fuad Shamout, P.E FY 2015-16 Annual Minor 2929 Tapo Canyon Road (805) 583-6788 Street Rehabilitation Simi Valley, CA 93063 FShamoutCcDsimivalley.org $1 ,213,960.50 11/15 City of Redondo Beach Lauren Sablan, P.E Aviation Blvd Resurfacing 415 Diamond Street (310) 318-0661 Project Redondo Beach, CA 90277 Lauren.Sablan(a)redondo.org $367,293.00 12/15 City of Palm Desert Bo Chen, P.E Portola Ave STP Rehabilitation 73-510 Fred Waring Drive (310) 370-5099 Project Palm Desert, CA 92260 bochen ancityofpalmdesert.org $639,204.74 2/16 City of Pasadena Sean Singletary Preventitive Maintenance of 100 N. Garfield Ave (626) 744-4273 Streets 2015 Pasadena, CA91109 ssingletaryCo)cityofpasadena.net $1 ,182,829.46 4/6/16 City of Lake Elsinore Ken Rukavina FY 15-16 Citywide Pavement 130 South Main Street (951) 674-3124 Rehab Phase 5 Lake Elsinore, CA 92530 krukavina(cDlake-elsinore.org $560,736.74 2/16 City of Lake Elsinore Ken Rukavina FY 15-16 Citywide Pavement 130 South Main Street (951) 674-3124 Rehab Phase 4 Lake Elsinore, CA 92530 krukavina oNake-elsinore.org $895,665.91 3/16 City of Colton Jess Sotto FY 15-16 Asphalt Paving 650 N. La Cadena Drive (909) 370-5099 Project Colton, CA 92324 JSotto coltonca.gov $1,569,242.84 4/16 City of Westminster Tuan Pham Citywide Street Improvement 8200 Westminster Blvd (714) 898-3311 For Various Residential Streets Westminster, CA 92683 tpham westminster-ca.qov $679,108.61 5/16 Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager, and Superintendent. For each of these critical positions, please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project. _Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. 1. Mike Amundson Name of proposed Project Manager Telephone No. ofproposed Project Manager: (-i10 444 185I Schleisman Rd Overlay$333,333.00 Road Overlay work _ _ _ 8/15 Project Name & Contract Amount Type of Work Date Completed Minor Street Maintenance Phase 1 $1,543,000.00 Street Maintenance 4/14 Project Name & Contract Amount Type of Work Date Completed Phase 3 Street Rehab$1,075,484.00 Street Rehabilitation 6/14 Project Name & Contract Amount IIype of Work Date Completed 2. Dennis Be le Name of proposed Superintendent Telephone No. of proposed Superintendent: 44,1 Street Improvement&Main Street Bridge Rehabilitation $1 181 570 00 Street Improvement 1/15 Project Name & Contract Amount Type of Work Date Completed Foothill Blvd Pavement Rehabilitation $1,076,200.00 Pavement Rehabilitation 11/15 Project Name & Contract Amount Type of Work Date Completed Street Resurfacing Project $1,187,987.00 Resurfacing Project 12/14 Project Name & Contract Amount Type of Work Date Completed C-t I. CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRI.AL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)), passed by the California State Senate on June 20. 2014, established a new public works Contractor Registration Program, which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July I through June 30 state fiscal year) with the California Department of Industrial Relations (DIR). Currently the annual non-refundable registration fee for Contractors is $300. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT- SHEET on SB 854 littp.//www.dir.ca.gov/DLSE/PublicWorks/SB854FactSheet_6.30.14.pdf DIR's Contractor Registration Link—Call (844) 522-6734 https://efiling.dir.ca.,)ov/PWCR/ActionServlet?action=displayPWCRegistratioiiForm D1R's Contractor Registration searchable database: https://eFllii-.dir.c,i.gov/PWCP/Search.action am aware and «ill comply with the provisions of Labor Code Section 1771.1(a) which states: "A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded." I furthennore will comply by providing proof of registration vvith DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. Hardy&Harper,Inc Contract By Steve Kirschner-Vice President Title Date: 7/25/16 DIR 4: 1000000076 C-12 STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycie) RELIABLE CONTRACTOR DECLARATION CalRecycie 168(Revised 7/13) This form must be completed and submitted to the Department of Resources Recycling and Recovery(CalRecycle) prior to authorizing a contractor(s) to commence work. Failure to provide this documentation in a timely manner may result in nonpayment of funds to the contractor(s). This form is intended to help the CalRecycle's Grantees comply with the Unreliable List requirement of their Terms and Conditions. The Unreliable List provision requires the following: Prior to authorizing a contractor(s) to commence work under the Gant, the Grantee shall submit to CalRecycle a declaration signed under penalty of perjury by the contractor(s) stating that within the preceding three (3) years, none of the events listed in Section 17050 of Title 14, California Code of Regulations,Natural Resources, Division 7,has occurred with respect to the contractor(s). Please see the reverse of this page,or refer to w-,vxv.cah-e-s.com If any of the events listed in Section 17050 have occurred, disclosure is required but will not necessarily result in CalRecycle refusing to approve the contractor. A signed statement explaining the facts and circumstances of the events must be attached to and submitted with this form. Contractor: Complete the Form and send original to the Grantee. Grantee: Scan the form and upload it to the grant in CalRecycle's Grant Management System (GMS). For further inslruclion ahow logging into GMS and uploading lhis fibrin, reference the Procedures and Requiremew.v. Retain the original fonn in your grant Bile. GRANTEE INFORMATION ' � 4 � .., GRANTEE NAME: i GRANT NUMBER: City of Huntington Reach TRPS Grant 1D 17197 ............... PRIMARY CONTACT NAME: � E Thomas Herbel,City Engineer, 714-375-5077 � CONTRACTOR INFORMAT ION CONTRACTOR NAME: i .. Har per, .......... ... _. __ _. _. ____ __._ __- ____.. . ............... .......... _.. AUTHORIZED CONTRACTOR REPRESENTATIVE NAME: Steve Kirschner ............... .. . ...................................... MAILING ADDRESS. 1312 E.Warner Ave.,Santa Ana,CA 92705 .... __..... ... . _.................. ...._ _ _ _..._.. .. ..._- .................._...... ........ _.... . . As the authorized representalive of the above identified contractor. I declare ludo penalty of peijw-v uncler the laws of the State o/Cali%nrnia that within the preceding three (3)years, none of the events listed in Section 17050 of Title 14, California Code of Regulations. Natural Resources, Division 7, has occurred with respect to the above identified C01711a(10r. E I Alternatively, as the authorized rel)resenlalive of the above identified contractor, I declare unaler penalty of perjury under the lcnvs of the State o/California that ivithin the preceding three (3)years, if any of the events listed in Section /7050 of Title 14, California Cade of Regulations, Natural Resources, Division 7, has occurred with respect to the above identified contractor, I have disclosed all such occurrences in an attached signed statement that explains the facts and ( circumstances of the listed events. i � [ i , Signature Pule 7/25/16 Steve irschner ice Presiden C-13 STATE OF CALIFORNIA DEPARTMENT OF RESOURCES RECYCLING AND RECOVERY(CalRecycle) RELIABLE CONTRACTOR DECLARATION CalRecycle 168(Revised 7/13) Title 14 CCR, Division 7,Chapter I Article i. Unreliable Contractors,Subcontractors,Borrowers and Grantees Section 17050. Grounds for Placement on Unreliable list The following are grounds for a finding that a contractor,any subcontractor that provides services for a C-alRecvcle agreement. Grantee or borrower is unreliable and should be placed on the CalRecycle Unreliable Contractor, Subcontractor, Grantee or Borrower List ("Unreliable List"). The presence of one of these grounds shall not automatically result in placement on the Unreliable List. A finding must be made by the EXeeUtive Director in accordance with section 17054, and there must be a final decision on any appeal that may be filed in accordance with section 17055 et seq. (a) Disallowance ofany and/or all claina(s)to CalRecycle due to fraudulent claims or reporting;or (b) The filing of a civil action by the Attorney General for a violation ofthe False Claims Act,Government Code section 12650 et.seq;or (c) Default on a CalRecycle loan,as evidenced by m-itten notice from CalRecycle staff provided to the borrower of the default:or (d) Foreclosure upon real property loan collateral or repossession of personal property loan collateral by CalRecycle:or (e) Filing voluntary or involuntary bankruptcy.where there is a finding based on substantial evidence,that the bankruptcy interfered with the CalRecycle contract.subcontract.grant or loan:or (1) Breach of the tcmrs and conditions of a previous CalRecycle contract.any subcontract for a CalRecycle agreement, grant,or loan_resulting in termination of the CalRec;�cle contract.subcontract,grant or to by the CalRecycle or prime contractor;or (g) Placement on the CalRecycle's chronic violator inventory established pursuant to Public Resources Code section 44104 for any owner or operator of a solid waste facility:or (h) The person,or any partner,member,officer,director,responsible managing officer,or responsible managing employee ofan entity has been convicted by a Court ofcompGent jurisdiction ofany charge of fraud,bribery,collusion, conspiracy,or any act in violation ofany state or fedcral antitrust law ha connection with the bidding upon_award ot;or performance under any CalRecycle contract;subcontract.grant or loan:or 0) 1'hc person or entity is on the list of unreliable persons or entities,or similar list,ofany other federal or California state agency;or (I) I-he person or entity has violated an Order issued in accordance with section 18304:or, (k) The person or entity has directed or transported to,has or accepted waste tires at,a site\,\,here the operator is required to have but does not have a waste tire facility permit;or, (I) The person or entity has transported waste tires without a waste tire hauler registration;or, (ill) The person or entity has had a solid waste facility or waste tire permit or a waste tire hauler registration denied, suspended or revoked;or- (n) The person or entity has abandoned a site or taken a similar action which resulted in corrective action or the expenditure of funds by CalRecycle to remediate,clean,or abate a nuisance at the site;or (o) The trot lowing are additional grounds Ibr a finding that,a person or entity described below should be placed on the Unreliable List: (1) The person or entity owned 2011`1'�or more ofan entity on the Unreliable List at the time ofthe activity that resulted in its placement on the Unreliable List; (2) The person held the position of officer director,manager,partner,trustee;or any other management position with signilieant control(Principal Manager)in an entity on the Unreliable List at the time ofthe activity that resulted in its placement on the Unreliable list; (3) The entity includes a Principal fvlanager ovho: 1 Was a Principal Manager in an entity on the Unreliable List at the time ofthe activity that resulted in its placement oil the Unreliable List:or, 2. Owwned 20%or more ofan entity on the Unreliable List at the time ofthe activity that resulted in its placement on the Unreliable List; (4) The entity has a person who owns 20%or more ofthe entity, ifthat person: 1. Was a Principal Manager in an entity on the Unreliable List at the time ofthe activity that resulted in its placement oil the Unreliable List;or, 2. Owned 20`,%or more ofan entity on the Unreliable List at the time ofthe activity that resulted ill its placement on the Unreliable List. (5) The entity has another entity which owns 20%or more ofthe entity, if that other entity: 1. Is on the Unreliable List:or. 2. Owned 20%or more ofan entity on the Unreliable List at the time ofthe activity that resulted in its placement on the Unreliable List. (6) Subsection(o)is not intended to apply to a person or entity that purchases or otherwise obtains an entity on the Unreliable List subsequent to its placement on the Unreliable List. C-14 City of Huntington Beach Public Works Department 2000 Main Street Tel. (714) 536-5431, Fax (714) 374-1573 ADDENDUM NUMBER ONE For MAIN STREET, TALBERT AVENUE AND HEIL AVENUE REHABILITATION CC NO. 1527 in the CITY OF HUNTINGTON BEACH July 19, 2016 Notice To All Bidders: Please note the following clarification to the Project Plans, Specifications, and Special Provisions: 1) SEE SECTION C- REVISED BID SCHEDULE (1 Sheet) Replace one page entitled "Project Bid Schedule—Heil (Edwards—Goldenwest) C- 2.14" with "Revised Project Bid Schedule—Heil (Edwards—Goldenwest) Revised C- 2.14" Added bid number"22" to Install Colored Pervious Concrete item that was unnumbered in original. This item is to be included in the total bid. This is to acknowledge receipt and review of Addendum Nu be ne, dated Jul 19 2016. — fiQr per Company Name By Qtt\1,C, -kjrsthnCr- VICe frt5�&jdCrq :T1251,C, Date All bidders must acknowledge and include the receipt of this Addendum with your bid proposal. Should you have any questions regarding this Addendum, please call James Wagner at (714) 536-5467 within 24 hours of posting. Bid Bond Bid Bond Number:CSBA-2731 CONTRACTOR: SURETY: (Name,legal status and address) (Name,legal status and principal place of business) 1;ardy&Harper,Inc. Fidelity and Deposit Company of Maryland 1312 E.Warner Avenue 777 South Figueroa Street,Suite 3900 Santa Ana,CA 92705 Los Angeles,CA 90017 OWNER: This document has important legal (Name, legal status and address) consequences. Consultation with City of Huntington Beach An attorney is encouraged with respect 2000 Main Street its completion or modification. Huntington Beach,CA 92648 Any singular reference to Contractor,Surety,Owner or other party shad be considered Plural where applicable. BOND AMOUNT: Ten Percent(10%)of Amount Bid PROJECT:Main Street Rehabilitation from Garfield Avenue to Delaware Street,Talbert Avenue Rehabilitation from Gothard Street to Newland Street,and Heil Avenue Rehabilitation from Edwards Street to Goldenwest Street CC No. 1527 Project Number,if any. The Contractor and Surety are bound to the Owner in the amount set forth above,for the payment of which the Contractor and Surety bind themselves,their heirs,executors,administrators,successors and assigns,jointly and severally,as provided herein.The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the time specified in the bid documents,or within such time period as may be agreed to by the Owner and Contractor,and the Contractor either(1) enters into a contract with the Owner in accordance with the terms of such bid,and gives such bond or bonds as may be specified in the bidding or Contract Documents,with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner,for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof,or(2)pays to the Owner the difference,not to exceed the amount of this Bond,between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid,then this obligation shall be null and void,otherwise to remain in full force and effect.The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid.Waiver of notice by the Surety shall not apply to any extension exceeding sixty(60) days in the aggregate beyond the time for acceptance of bids specified in the bid documents,and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty(60) days. If this Bond is issued in connection with a subcontractor's bid to a Contractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted here from and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. Signed and sealed this 25th day of July,2016 Hardy&Harper,Inc. (Princi al) (Seal) (Witness) (Title) Fidelity and Deposit Company of Maryland � i (Surety) (Seal) (Witness) (Title)Dwight Reilly,Attorney-in-Fact By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP)(www.nasbp.orR) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business. NASBP vouches that t the original text of this document conforms exactly to the text in AIA Document A310-2010, Bid Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion, execution or acceptance. CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 �(`�:c�`.ctQrC',s-<^,c=2%,n��.-=r,rR.-=�,c�`,i-f'.cYM,cA�,i'K,cvo�,cR:ct.cam.ct:c�.ct^.cti:c�^n^^.cam%��t,c�,ct�n;ct•cam^,i-���v^'c�c�n ct.i A notary public or other officer completing this certificate"verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness,accuracy, or validity of that document. State of California ) County of Orange ) On July 25 2016 before me, Tina Pham, Notary Public Date Here Insert Name and Title of the Officer personally appeared Steve Kirschner NameX of Signery who proved to me on the basis of satisfactory evidence to be the person(g) whose name(8) is/ale subscribed to the within instrument and acknowledged to me that he/state/they executed the same in his/her/their authorized capacity(i(�5), and that by his/h)Rr/their signature(15)on the instrument the person(s), or the entity upon behalf of which the person(x) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. TINA PHAM comm.#2149384 WITNESS my hand and official seal. _. ; Notary Public-California ORANGE COUNTY it My Comm.Expires Apr17,2020 Signature Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Bid Bond Document Date: July 25, 2016 Number of Pages: 1 Signer(s) Other Than Named Above: Dwight Reilly Capacity(ies) Claimed by Signer(s) Signer's Name: Steve Kirschner Signer's Name: �— ❑✓ Corporate Officer — Title(s): y cP Prasiriant ❑Corporate Officer — Title(s): ❑Partner — ❑ Limited ❑ General ❑Partner — ❑ Limited ❑ General ❑Individual ❑Attorney in Fact ❑ Individual ❑Attorney in Fact ❑Trustee ❑ Guardian or Conservator ❑Trustee ❑ Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing: Signer Is Representing: Hardy&.Harper, Inc 02014 National Notary Association •www.NationalNotary.org• 1-800-US NOTARY (1-800-876-6827) Item #5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness, accuracy,or validity of that document. State of California County of Orange On 07/25/2016 before me, Susan Pugh Notary Public personally appeared Dwight Reilly who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s),or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the state of California that the foregoing paragraph is true and correct. SUSAN PUGH Comm.#2105405 M Notary Public-California X WITNESS my hand and official seal. LL ORANGE COUNTY r My Comm.Expires Apr 29,2019 Signature of Notary OPTIONAL Though the data below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent reattachment of this form. CAPACITY CLAIMED BY SIGNER DESCRIPTION OF ATTACHED DOCUMENT ❑ INDIVIDUAL Bid Bond ❑ CORPORATE OFFICER Title or Type of Document One ❑ PARTNER(S) Number of Pages ❑ MEMBER of LLC ® ATTORNEY-IN-FACT ❑ TRUSTEE(S) 07/25/2016 ❑ GUARDIAN/CONSERVATOR Date of Document OTHER: SIGNER IS REPRESENTING: Signer(s) other than named above NAME OF PERSON(S) OR ENTITY(IES) ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY,a corporation of the State of New York,the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Maryland, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"), by MICHAEL BOND, Vice President, in pursuance of authority granted by Article V, Section 8, of the By-Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint Daniel HUCKABAY,Dwight REILLY,Andrew WATERBURY,Arturo AYALA,Shaunna BURCHFIEL and . Michael CASTANEDA, all of Orange, California, EACH its true and lawful agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills,Maryland.,and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland.,in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8,of the By-Laws of said Companies,and is now in force. IN WITNESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this 9th day of May,A.D.2016. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND vuyy v r�ocros •a G-µairrsp`.'•• �w BSAL moo ?'6•. % (1 Secretary Vice President Eric D.Barnes Michael Bond State of Maryland County of Baltimore On this 9th day of May,A.D. 2016,before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, MICHAEL BOND,Vice President,and ERIC D.BARNES,Secretary, of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument,and acknowledged the execution of same, and being by me duly sworn,deposeth and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and year fast above written. Constance A.Dunn,Notary Public My Commission Expires:July 9,2019 POA-F 012-0079B