Loading...
HomeMy WebLinkAboutJamison Engineering Contractors, Inc. - 2020-02-24 Batch 7392520 Confirmation Page 1 of 1 i I PLEASE COMPLETE THIS INFORMATION RECORDING REQUESTED BY: Recorded in Official Records,Orange County Hugh Nguyen,Clerk-Recorder II I I II II I II I I I I I I I I I III I II NO FEE * $ R 0 0 1 1 9 9 1 2 7 8 $ WHEN RECORDED MAIL TO: 20200004558032 1:24 pm 09/01/20 9 503A M 2 1 CITY OF HUNTINGTON BEACH 0.00 0.00 0.00 0.00 0.00 0.00 0.000.000.00 0.00 j PUBLIC WORKS DEPARTMENT Attn:Lill Hernandez P.O.Box 190—2000 Main Street Huntington Beach,CA 92648 t THIS SPACE FOR RECORDER'S USE ONLY TITLE OF DOCUMENT NOTICE OF COMPLETION t NOTICE IS HEREBY GIVEN by the City of Huntington Beach,owner in fee,2000 Main Street,Huntington Beach,CA 92648,that the contract heretofore awarded to Jamison Engineering Contractors,Inc.,who was the company thereon for doing the following work to-wit: ;i Banning Bridge Bracket Pipe Support Emergency Repair Project,Project#CC 1611 That said work was completed 06/27/2020 by said company according to plans and specifications and to the satisfaction of the City Engineer of the City of Huntington Beach and that said work was accepted by the Director of Public Works on 06/27/2020,per City Council Resolution No.2003-70 adopted October 6,2003. That upon said contract Western Surety Company of South Dakota,was surety for the bond given by the said company as required This document is solely for the official business of the City of Huntington Beach,as contemplated under Government Code Section } 27383 and should be recorded free of charge. ,Dir or o s or City Engineer ate e City of Huntington Beach,California STATE OF CALIFORNIA) County of Orange )ss: City of Huntington Beach ) I,the undersigned,say:I am an Agent of the City of Huntington Beach,owner in fee,in the foregoing NOTICE OF COMPLETION. I have read said NOTICE OF COMPLETION and know the contents thereof;the same is true of my knowledge. I declare under penalty of perjury that the foregoing is true and correct,and that said NOTICE OF COMPLETION was duly and regularly ordered to be recorded in the Office of the County Recorder of Orange County. This document Is solely the official business o/ 2y�Z — the City of Huntington Beach,as contemplated under Government code section 27383 and Dir ea for ate blic Works or City Engineer should be recorded free of char4e. City of Huntington Beach,California THIS PAGE IS ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION (Additional recording fee applies) https://gs.secure-recording.com/Batch/Confirmation/7392520 9/1/2020 I CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND JAMISON ENGINEERING CONTRACTORS,INC. FOR BANNING BRIDGE BRACKET PIPE SUPPORT EMERGENCY REPAIR PROJECT THIS AGREEMENT("Agreement") is made and entered into by and between the City of Huntington Beach,a municipal corporation of the State of California,hereinafter referred to as "CITY,"and JAMISON ENGINEERING CONTRACTORS,INC. , a CALIFORNIA corporation,hereinafter referred to as "CONTRACTOR." WHEREAS,CITY has solicited bids for a public works project,hereinafter referred to as "PROJECT,"more fully described as BANNING BRIDGE BRACKET PIPE SUPPORT EMERGENCY REPAIR PROJECT in the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged the parties covenant and agree as follows: 1. STATEMENT OF WORK;ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the 1 16-5195/City Funded Construction Contract.docx—revised 04/2016 prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK;PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms,conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), has inspected the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents"as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions,including those on file in the office of the Department of Public Works of CITY, and any revisions, amendments or addenda thereto; 2 16-5195/City Funded Construction Contract.docx—revised 04/2016 D. The edition of Standard Specifications for Public Works Construction, published by Builders'News,Inc., 10801 National Boulevard,Los Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee as specified in the particular Plans, Specifications, Special Provisions and Addendum applicable to the Project; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Director of Public Works of CITY or his or her written designee (hereinafter referred to as "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3 16-5195/City Funded Construction Contract.docx—revised 04/2016 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed EIGHTY FIVE THOUSAND Dollars ($ 85,000.00 ), as set forth in the Contract Documents,to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten(10)working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within FORTY ( 40 ) consecutive Working days from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, 4 16-5195/City Funded Construction Contract.docx—revised 04/2016 subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason,relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 5 16-51951City Funded Construction Contract.docx—revised 04/2016 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final contract price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within ten (10) days of filing of the Notice of Completion. 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is,and shall be,acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll 6 16-5195/City Funded Construction Contract.docx—revised 04/2016 deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of FIVE HUNDRED ($ 500 ) per each calendar day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided,and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes,unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay(unless DPW shall grant a further period of time),notify DPW in writing of the cause of the 7 16-5195/City Funded Construction Contract.docx—revised 04/2016 delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed,but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen(15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DEMANDS FOR ADDITIONAL TIME OR MONEY. A. Definitions. (1) "Change Order"means a document signed by the CONTRACTOR and CITY which authorizes an addition, deletion or revision in the work, or an adjustment in the Compensation under Section 3,or the Completion Time specified at Section 4. (2) "Demand" means a written demand for a Change Order by the CONTRACTOR for any of the following: (a) A time extension; 8 16-5195/City Funded Construction Contract.docx—revised 04/2016 (b) Payment of money or damages arising from work done by,or on behalf of, the CONTRACTOR pursuant to this Agreement and payment of which is not expressly permitted pursuant to Section 3 of this Agreement; (c) Payment of an amount the CITY disputes; (d) Any disputes and other matters relating to the acceptability of the work performed or the interpretation of the Contract Documents; (e) A request for a time extension or additional payment based upon differing site conditions, such as subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents, or unknown physical conditions at the job site, of an unusual nature,differing materially from those ordinarily encountered and generally recognized as inherent to work of the PROJECT; or (f) A request for a time extension or additional payment based upon acts of neglect by CITY or due to fires,floods,labor disputes,epidemics,abnormal weather conditions or acts of God. B. A Demand for a time extension or payment of money or damages may only be granted by a Change Order. C. No Change Order may be granted except where the Contractor has submitted a Demand to the DPW(or his or her written designee). All Demands shall be submitted promptly,but in no event later than thirty(30)days after the occurrence of the event giving rise to the Demand. The Demand shall be in writing and include all documents necessary to substantiate the Demand. The DPW shall act on the Demand within fifteen (15) days after receipt, including by requesting additional information from the CONTRACTOR to determine whether to approve the Change Order the Demand seeks. The DPW shall act on the Demand within fifteen(15)days 9 16-51951City Funded Construction Contract.docx—revised 04/2016 after receipt of the additional information or within a period of time no greater than the time the CONTRACTOR took to produce the additional information requested,whichever is greater. D. Notwithstanding the thirty (30) days to submit a Demand under Subparagraph C, in the case of differing or unknown site conditions, immediately upon encountering the conditions, CONTRACTOR shall notify the DPW in writing of the conditions, so that the CITY may promptly investigate the conditions. E. If the CONTRACTOR disputes the DPW's written response on the Demand, or the CITY fails to respond within the time prescribed, the CONTRACTOR may so notify the City Engineer,in writing,either within fifteen(15)days of receipt of the City Engineer's response or within fifteen (15) days of the DPW's failure to respond within the time prescribed, respectively,and request an informal conference to meet and confer for settlement of the Demand. Upon the CONTRACTOR's request,the DPW shall schedule a meet and confer conference within thirty(30) days to seek to resolve. F. CITY and CONTRACTOR shall execute appropriate Change Orders covering changes to the time or price by executing the Change Order by mutual agreement. If the CITY and CONTRACTOR are unable to reach a mutual agreement,then the City Engineer shall issue a written decision on the claim within a reasonable time. G. Following the meet and confer conference, if the Demand remains in dispute,the CONTRACTOR may file a claim with the City as provided in Chapter 1 (commencing with Section 900)and Chapter 2 (commencing with Section 910)of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the CONTRACTOR submits his 10 16-5195/City Funded Construction Contract.docx—revised 04/2016 or her Demand until the Demand is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT,if the actual quantities used are either more than or less than the quantities listed in the bid schedule,the bid price shall prevail subject to the provisions of this Section. DPW may,at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion,DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, five percent (5%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work,will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent(50%)or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such 11 16-5195/City Funded Construction Contract.docx—revised 04/2016 sum as will bring the payments of each month up to one hundred percent(100%) of the value of the work completed since the commencement of the PROJECT,as determined in its sole discretion by DPW,less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR,if unencumbered,or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Provided,however,that in the event of a dispute between CITY and CONTRACTOR,CITY may withhold from the final payment an amount not to exceed 150 percent of the value of any disputed amount of work. Payments shall be made on demands drawn in the manner required by law,each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHBELD CONTRACT FUNDS SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR,who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items,if any,to be set forth in CONTRACTOR's affidavit covering disputed claims, 12 16-5195/City Funded Construction Contract.docx—revised 04/2016 or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid(either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 18. CALIFORNIA PREVAILING WAGE LAW A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by 13 16-5195/City Funded Construction Contract.docx—revised 04/2016 resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 19. CALIFORNIA EIGHT-HOUR LAW A. California Labor Code,Sections 1810 et seq,shall apply to the performance of this Agreement; thereunder,not more than eight(8)hours shall constitute one days work and CONTRACTOR and each subcontractor employed by its hereunder, shall not require more than eight(8)hours of labor per day or forty(40)hours per week from any one person employed by it hereunder, except as stipulated in California Labor Code Section 1815. CONTRACTOR and each subcontractor employed by it hereunder shall, in accordance with California Labor Code Section 1812, keep an accurate record, open to inspection at all reasonable hours, showing the name and actual hours worked each calendar day and each calendar week by each worker employed in connection with the PROJECT. B. Pursuant to this Agreement and in accordance with California Labor Code Section 1813, CONTRACTOR shall, as a penalty to CITY, forfeit twenty-five dollars ($25) for each worker employed hereunder by CONTRACTOR or any subcontractor for each calendar day during which such worker is required or permitted to work more than eight(8)hours in any one 14 16-5195/City Funded Construction Contract.docx—revised 04/2016 (1)calendar day or forty(40)hours in any one(1)calendar week in violation of California Labor Code Section 1815. 20. PAYMENT OF TRAVEL AND SUBSISTENCE ALLOWANCE Section 1773.8 of the California Labor Code, regarding the payment of travel and subsistence allowance is applicable to this PROJECT. 21. EMPLOYMENT OF APPRENTICES Section 1777.5 of the California Labor Code, regarding the employment of apprentices is applicable to this PROJECT. 22. PAYROLL RECORDS CONTRACTOR agrees to keep accurate payroll record showing the name, address, social security number,work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman,apprentice or worker employed by it in connection with the PROJECT and agrees to require each of its subcontractors to do the same. CONTRACTOR further agrees that its payroll records and those of its subcontractors,if any, shall be available at all reasonable times to the CITY, and the employee or his representative, and the Division of Labor Standards Enforcement and the Division of Apprenticeship Standards, and to comply with all of the provisions of California Labor Code Section 1776, in general. 23. INDEMNIFICATION DEFENSE HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all claims, damages, losses, expenses,judgments, demands, defense costs, and consequential damage or liability of any kind or nature,however caused,including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, 15 16-5195/City Funded Construction Contract.docx—revised 04/2016 arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable,including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY, its officers, elected or appointed officials, employees, agents, and volunteers. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 24. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 16 16-5195/City Funded Construction Contract.docx—revised 04/2016 25. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend,hold harmless and indemnify CITY,CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance,including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit,the aggregate limit must be no less than One Million Dollars($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees,agents,and volunteers(the"Additionally Insured Parties")as Additional Insureds,and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary and non-contributory with any other valid and collectible insurance or self-insurance available to the Additionally Insured Parties. Any available insurance proceeds in excess of the minimum coverage amount specified herein shall be available to the Additionally Insured Parties. All coverage available to CONTRACTOR shall also be available to the Additionally Insured Parties. Under no circumstances shall said above-mentioned insurance contain a self-insured retention without the express written consent of CITY; however an insurance policy "deductible" of Five Thousand Dollars ($5,000.00) is permitted. CONTRACTOR shall be responsible for causing all Subcontractors to maintain the same types and limits of insurance coverage as that required of CONTRACTOR by this Agreement. 17 16-5195/City Funded Construction Contract.docx revised 04/2016 26. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. Provide the name and policy number of each carrier and policy; 2. State that the policy is currently in force; and 3. Promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner,the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 27. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten(10)days of receipt of such claim or claims. 18 16-5195/City Funded Construction Contract.docx—revised 04/2016 28. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten(10)days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have,terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR,CITY may elect not to terminate this Agreement;in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 29 and any damages shall be assessed as set forth in Section 29. 29. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause,and whether or not PROJECT is fully complete upon seven(7)calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience,the CONTRACTOR shall be entitled to receive payment for work executed, and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's 19 16-5195/City Funded Construction Contract.docx—revised 04/2016 sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 30. DISPOSITION OF PLANS ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 31. NONASSIGNABILTTY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement,or any part hereof,or any right or duty created herein,without the prior written consent of CITY and the surety. 32. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 33. STOP NOTICES;RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100)for every Stop Notice filed in excess of two(2),regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 20 16-5195/City Funded Construction Contract.docx—revised 04/2016 34. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant,or by enclosing the same in a sealed envelope,postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices,certificates or other communications will be sent by notifying the other party via personal delivery,reputable overnight carrier or U. S. certified mail-return receipt requested: TO CITY: TO CONTRACTOR: City of Huntington Beach JAMISON ENGINEERING CONTRACTORS ATTN:Lili A. Hernandez ,Public Works ATTN: Don Jamison 2000 Main Street 2525 S.Yale Street Huntington Beach, CA 92648 Santa Ana,CA 92704 35. SECTION HEADINGS The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions,and do not interpret,define,limit or describe,or construe the intent of the parries or affect the construction or interpretation of any provision of this Agreement. 21 16-5195/City Funded Construction Contract.docx—revised 04/2016 36. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 37. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services,and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 38. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non-prevailing party. 39. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the 22 16-5195/City Funded Construction Contract.docx—revised 04/2016 context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law,and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 40. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 41. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any parry who has signed it. 42. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 43. SURVIVAL Terms and conditions of this Agreement, which by their sense and context survive the expiration or termination of this Agreement shall so survive. 44. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 23 16-5195/City Funded Construction Contract.docx—revised 04/2016 45. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact,held by the signatory or is withdrawn. 46. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arms length negotiation,and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations,inducements,promises,agreements or warranties,oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement,promise, agreement,warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof. 24 16-5195/City Funded Construction Contract.docx—revised 04/2016 IN WITNESS WHEREOF,the parties hereto have caused this Agreement to be executed by and through their authorized officers on J y ,20ao_. CONTRACTOR: CITY OF HUNTINGTON BEACH,a municipal corporation of the State of California By: c ` - Mayor t name) ITS: Chairman/President/ ice-Presiden^t City Clerk J9 (circle one) INITIATED AND APPROVED: AND By: irec ub c Works - r v"k (print name) REVIEWED AND APPR VED: ITS: Secretary / Chief Financial Officer '/ Asst. Secretary/Treasurer (circle one) S City Manager APPRO D AS TO F City Attorr@y 25 16-5195/City Funded Construction Contract.docx—revised 04/2016 �Xtf1glT A ' Jamison EngineeringContractors, Inc. 2525 S.Yale Street,Santa Ana,CA 92704 (714)434-9196 Fax:(714)434-3762 Quote#02779(Revised) February 20, 2020 TO: City of Huntington Beach ATTENTION: Lili Hernandez REFERENCE: Banning Bridge Brackets Dear Lili, We propose to do the following for the price of Eighty Five Thousand Dollars and 00/100($85,000.00), including all applicable taxes:This quote is Time and materials not to exceed$85,000.00 without written consent. (This price includes engineering drawings from RMS engineering.)All Materials, Rentals, Outside Services, Fuel, Permits, Licenses and Bonds will be Cost+15%. Jamison will provide labor, materials, and equipment Jamison Eng. Contractors propose to do an Emergency design build project to Design,fabricate and install 7 new pipe supports on the north side of Banning Bridge over Talbert marsh channel as follows: A.) Produce design drawings from a structural engineer for approval B.) Fabricate new supports using: 316 stainless steel C.) Design and install a working platform along pipe alignment. No anchors will be used for the platform D.) Install new approved supports E.) Remove existing pipe supports and repair the concrete where the existing anchors were F.) Remove temporary walkway The fence along the bridge will be removed and replaced after construction is completed. A temporary fence will be installed during Non-working hours. There will be no impact to the street and very little impact to the sidewalk. Jamison will perform the work using cranes and trucks parked on the East and West sides of the channel.Attached is a quote from our structural engineer and a T&M estimate for the proposed work, also a copy of our July 2019-June 2020 rate sheets. We appreciate the opportunity of presenting this quote. It will remain firm for the next 30 days. If you have any questions, please call me at 714-620-5048. Respectfully, Don Jamison Jamison Eng. Contractors 714-620-5048 ABC®IR® JAMIENG-01 _ KMAL00 AD CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDmvY) 19, THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.HIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER License#0757776 coluracr Gail Schrenk HUB International Insurance Services Inc. NAME_ — PHONE 4695 MacArthur Court,Suite 600 (A/c,NoExt):(877)825-2681 _ T(FA6c,No):(951)231-2572 Newport Beach,CA 92660 �E-M L cal. — — f APPRE�:_ Cp hubinternationaLcom — I ----_INSURERL)AFFORDING COVERAGE NAIC p --_ itsuRERA.-Landmark American Insurance Company_._ 33138 INSURED INSURER B_West American Insurance CO _ _ _ 44393 Jamison Engineering Contractors,Inc. INSURERC:RSUI Indemni _Com an _ 22314 _ Sant S.Yale A I INSURER D:State Compensation Insurance Fund of California Santa Ana,CA 92704 ---- p --- _ 35076 INSURER E: I INSURER F: — COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CL IMS. A INSR I TYPE OF INSURANCE IADDLISUBRI POLICY OF POLICY EXP I --- — POLICY NUMBER LIMITS A I X I COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE Ig 1,000,000 __I_ CLAIMS-MADE �XJ OCCUR X I LHA14O469 DAMAGE TO RENTED 3/21/2019 3l21/2020 REM E�{Ea occurrence $ 50,0,X I BI/PD Ded:$2,500 I _ — _—'-- --- I MED EXP�n�ne perso i_ 5,000 _PERSONAL&ADV INJURY _I$ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: I j IE� I I I I II I GENERAL AGGREGATE 2,000,000I POLICY i X J G $ 2,000,000PROTS-COMP/O _ P OTHER: [t:571�AU�TOMOBILE LIABILITY IGLE LIMIT $ 1,000,(Eaaccidentf I$ANYAUTO X BAW56573285 13/21/2019 3/21/2020 I OWNED SCHEDULED I BODILY INJURYAPer person�$AUTOS ONLY AUTOS E NN pp BODILY INJURY(Per accide�I$ HIRED ONLY X I AUTOS ONLB PERTY DAMAGEX Comp&Coll Ded$1,000 �Nor accident Is I$C I I UMBRELLA LIAR I X I OCCUR I I I — i I I 1 I 5,000,000rXEXCESS LAB NHA246849 EACH OCCURRENCE $ - I 3/21/2020 _— —S00I DEXR ETENTION$ O AGGREGATE '000 D I WORKERS COMPENSATION $ AND EMPLOYERS'LIABILITY I I LX�-$TAT�ITE ERH I_____ __IANYPROPRIETOR/PARTNER/FEXECUTIVE Y/N 90374962020 1/1/2020 I 1/1/2021 pFFICER/MEMBEREXCLUDED? IN/A E.LEACHACCIDENT — $ 1,000,000(Mandatory In NH) If yes,describe under I I I 1,000,000 DESCRIPTION OF OPERATIONS below I E.L.DISEASE-EA EMPLOYEE$ _ E.L.DISEASE-POLICY LIMIT I$ 1,000,000 AP O D AS 10 FORM DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,maybe attached if more space is required) B Excess Liability Policy following underlying policies:GL,Auto,WC Only 12CH EL E.GATES The City of Huntington Beach,its Officers,elected or appointed officials,employees,agents and volunteers are Addii�,gq�l bFtPRM ATTORNEY nerai Liability policy per attached endorsement form Manuscript,Primary/Non-Contributory is Included. Waiver of Subrogation in regards to theGeneral L bility when required by written contract per the attached endorsement RSG14048 10108.Additional Insured in regards to the Auto Liability policy when required by written contract per the attached endorsement CA8810 01/13. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Huntington Beach THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 2000 Main Street ACCORDANCE WITH THE POLICY PROVISIONS. Huntington Beach,CA 92648 EI AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD LANDMARK AMERICAN INSURANCE COMPANY This Endorsement Changes The Policy. Please Read It Carefully. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE FORM SCHEDULE Name of Person or Organization: Any Person or Organization As Required By Written Contract The following is added to SECTION IV— CONDITIONS, 8. TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US: We waive any right of recovery we may have against the person or organization shown in the SCHEDULE above because of payment we make for injury or damage arising out of your ongoing operations, "your product" or"your work" done under a written contract with that person or organization and included in the "product-completed operations hazard". This waiver applies only to the person or organization shown in the SCHEDULE above. This endorsement effective 3/21/2019 forms part of Policy Number LHA140469 issued to JAMISON ENGINEERING CONTRACTORS, INC. by Landmark American Insurance Company RSG 14048 1008 Includes copyrighted material of Insurance Services Office, Inc. 1992 with its permission. COMMERCIAL AUTO CA 88 10 01 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BUSINESS AUTO COVERAGE ENHANCEMENT ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM With respect to coverage afforded by this endorsement, the provisions of the policy apply unless modified by the endorsement. COVERAGEINDEX SUBJECT PROVISION NUMBER ADDITIONAL INSURED BY CONTRACT, AGREEMENT OR PERMIT 3 ACCIDENTAL AIRBAG DEPLOYMENT 12 AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS 19 AMENDED FELLOW EMPLOYEE EXCLUSION 5 AUDIO, VISUAL AND DATA ELECTRONIC EQUIPMENT COVERAGE 13 BROAD FORM INSURED BODILY INJURY REDEFINED 1 EMPLOYEES AS INSUREDS (including employee hired auto) 22 EXTENDED CANCELLATION CONDITION 2 EXTRA EXPENSE- BROADENED COVERAGE 23 GLASS REPAIR- WAIVER OF DEDUCTIBLE 10 1 HIRED AUTO PHYSICAL DAMAGE (including employee hired auto and loss of use) 6 HIRED AUTO COVERAGE TERRITORY 20 LOAN /LEASE GAP 14 PARKED AUTO COLLISION COVERAGE(WAIVER OF DEDUCTIBLE) 16 PERSONAL EFFECTS COVERAGE 11 PHYSICAL DAMAGE -ADDITIONAL TRANSPORTATION EXPENSE COVERAGE 8 RENTAL REIMBURSEMENT SUPPLEMENTARY PAYMENTS 9 TOWING AND LABOR 4 TWO OR MORE DEDUCTIBLES 7 UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS 17 WAIVER OF TRANSFER OF RIGHTS OF RECOVERYAGAINST OTHERS TO US 18 20 SECTION II - LIABILITY COVERAGE is amended as follows: 1. BROAD FORM INSURED ° SECTION II - LIABILITY COVERAGE, paragraph A.I. - WHO IS AN INSURED is amended to include the following as an insured: d. Any legally incorporated entity of which you own more than 50 percent of the voting stock during the policy period. However, "insured" does not include any organization that: (1) Is a partnership or joint venture; or (2) Is an insured under any other automobile policy; or (3) Has exhausted its Limit of Insurance under any other automobile policy. Paragraph d. (2) of this provision does not apply to a policy written to apply specifically in excess of this policy. e. Any organization you newly acquire or form, other than a partnership or joint venture, of which you own more than 50 percent of the voting stock. This automatic coverage is afforded only for 180 days from the date of acquisition or formation. However, coverage under this provision does not apply: (1) If there is similar insurance or a self-insured retention plan available to that organization; © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 1 of 7 (2) If the Limits of Insurance of any other insurance policy have been exhausted; or (3) To "bodily injury" or "property damage" that occurred before you acquired or formed the organization. 2. EMPLOYEES AS INSUREDS SECTION II - LIABILITY COVERAGE, paragraph A.1. - WHO IS AN INSURED is amended to include the following as an insured: f. Any "employee" of yours while using a covered "auto" you do not own, hire or borrow, but only for acts within the scope of their employment by you. Insurance provided by this endorse- ment is excess over any other insurance available to any "employee". g. An "employee" of yours while operating an "auto" hired or borrowed under a written contract ® or agreement in that "employee's" name, with your permission, while performing duties re- lated to the conduct of your business and within the scope of their employment. Insurance ® provided by this endorsement is excess over any other insurance available to the "employee". 3. ADDITIONAL INSURED BY CONTRACT, AGREEMENT OR PERMIT ® SECTION II - LIABILITY COVERAGE, paragraph A.1. - WHO IS AN INSURED is amended to include ® the following as an insured: _® h. Any person or organization with respect to the operation, maintenance or use of a covered o "auto", provided that you and such person or organization have agreed in a written contract, agreement, or permit issued to you by governmental or public authority, to add such person, or organization, or governmental or public authority to this policy as an "insured". However, such person or organization is an "insured": (1) Only with respect to the operation, maintenance or use of a covered "auto"; (2) Only for "bodily injury" or "property damage" caused by an "accident" which takes place after you executed the written contract or agreement, or the permit has been issued to you; and (3) Only for the duration of that contract, agreement or permit 4. SUPPLEMENTARY PAYMENTS SECTION II - LIABILITY COVERAGE, Coverage Extensions, 2.a. Supplementary Payments, para- graphs (2) and (4) are replaced by the following: (2) Up to $3,000 for cost of bail bonds (including bonds for related traffic violations ) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the insured at our request, including actual loss of earn- ings up to $500 a day because of time off from work. 5. AMENDED FELLOW EMPLOYEE EXCLUSION In those jurisdictions where, by law, fellow employees are not entitled to the protection afforded to the employer by the workers compensation exclusivity rule, or similar protection, the following provision is added: SECTION II - LIABILITY, exclusion B.5. FELLOW EMPLOYEE does not apply if the "bodily injury" results from the use of a covered "auto" you own or hire. SECTION III -PHYSICAL DAMAGE COVERAGE is amended as follows: 6. HIRED AUTO PHYSICAL DAMAGE Paragraph A.4. Coverage Extensions of SECTION III - PHYSICAL DAMAGE COVERAGE, is amended by adding the following: If hired "autos" are covered "autos" for Liability Coverage, and if Comprehensive, Specified Causes of Loss or Collision coverage are provided under the Business Auto Coverage Form for any "auto" you own, then the Physical Damage coverages provided are extended to "autos": a. You hire, rent or borrow; or © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 2 of 7 b. Your "employee" hires or rents under a written contract or agreement in that "employee's" name, but only if the damage occurs while the vehicle is being used in the conduct of your business, subject to the following limit and deductible: A. The most we will pay for "loss" in any one "accident" or "loss" is the smallest of: (1) $50,000; or (2) The actual cash value of the damaged or stolen property as of the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property with other property of like kind and quality, minus a deductible. B. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. C. Subject to the limit, deductible and excess provisions described in this provision, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. D. Subject to a maximum of $1,000 per "accident", we will also cover the actual loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss. E. This coverage extension does not apply to: (1) Any "auto" that is hired, rented or borrowed with a driver; or (2) Any "auto" that is hired, rented or borrowed from your "employee". For the purposes of this provision, SECTION V-DEFINITIONS is amended by adding the following: 'Total loss" means a "loss" in which the cost of repairs plus the salvage value exceeds the actual cash value. 7. TOWING AND LABOR SECTION III - PHYSICAL DAMAGE COVERAGE, paragraph A.2. Towing, is amended by the addition of the following: We will pay towing and labor costs incurred, up to the limits shown below, each time a covered "auto" classified and rated as a private passenger type, "light truck" or "medium truck" is dis- abled: a. For private passenger type vehicles, we will pay up to $50 per disablement. b. For "light trucks", we will pay up to $50 per disablement. "Light trucks" are trucks that have a gross vehicle weight (GVVV) of 10,000 pounds or less. c. For "medium trucks" , we will pay up to $150 per disablement. "Medium trucks" are trucks that have a gross vehicle weight (GVW) of 10,001 -20,000 pounds. However, the labor must be performed at the place of disablement. 8. PHYSICAL DAMAGE -ADDITIONAL TRANSPORTATION EXPENSE COVERAGE Paragraph A.4.a., Coverage Extension of SECTION III - PHYSICAL DAMAGE COVERAGE, is amend- ed to provide a limit of$50 per day and a maximum limit of $1,500 0 © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 3 of 7 9. RENTAL REIMBURSEMENT SECTION III -PHYSICAL DAMAGE COVERAGE,A. COVERAGE, is amended by adding the following: a. We will pay up to $75 per day for rental reimbursement expenses incurred by you for the rental of an "auto" because of "accident" or "loss", to an "auto" for which we also pay a "loss" under Comprehensive, Specified Causes of Loss or Collision Coverages. We will pay only for those expenses incurred after the first 24 hours following the "accident" or "loss" to the covered "auto." b. Rental Reimbursement will be based on the rental of a comparable vehicle, which in many cases may be substantially less than $75 per day, and will only be allowed for the period of time it should take to repair or replace the vehicle with reasonable speed and similar quality, up to a maximum of 30 days. c. We will also pay up to $500 for reasonable and necessary expenses incurred by you to remove and replace your tools and equipment from the covered "auto". M d. This coverage does not apply unless you have a business necessity that other "autos" avail- able for your use and operation cannot fill. e. If "loss" results from the total theft of a covered "auto" of the private passenger type, we will pay under this coverage only that amount of your rental reimbursement expenses which is not already provided under Paragraph 4. Coverage Extension. f. No deductible applies to this coverage. For the purposes of this endorsement provision, materials and equipment do not include "personal effects" as defined in provision 11. 10. EXTRA EXPENSE-BROADENED COVERAGE Under SECTION III - PHYSICAL DAMAGE COVERAGE,A. COVERAGE,we will pay for the expense of returning a stolen covered "auto" to you. The maximum amount we will pay is $1,000. 11. PERSONAL EFFECTS COVERAGE A. SECTION III - PHYSICAL DAMAGE COVERAGE, A. COVERAGE, is amended by adding the following: If you have purchased Comprehensive Coverage on this policy for an "auto" you own and that "auto" is stolen, we will pay, without application of a deductible, up to $600 for "personal effects" stolen with the "auto." The insurance provided under this provision is excess over any other collectible insurance. B. SECTION V-DEFINITIONS is amended by adding the following: For the purposes of this provision, "personal effects" mean tangible property that is worn or carried by an insured." "Personal effects" does not include tools, equipment, jewelry, money or securities. 12. ACCIDENTAL AIRBAG DEPLOYMENT SECTION III - PHYSICAL DAMAGE COVERAGE, B. EXCLUSIONS is amended by adding the follow- ing: If you have purchased Comprehensive or Collision Coverage under this policy, the exclusion for "loss" relating to mechanical breakdown does not apply to the accidental discharge of an airbag. Any insurance we provide shall be excess over any other collectible insurance or reimbursement by manufacturer's warranty. However, we agree to pay any deductible applicable to the other cov- erage or warranty. 13. AUDIO, VISUAL AND DATA ELECTRONIC EQUIPMENT COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE, B. EXCLUSIONS, exception paragraph a. to exclu- sions 4.c. and 4.d. is deleted and replaced with the following: © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 4 of 7 Exclusion 4.c. and 4.d. do not apply to: a. Electronic equipment that receives or transmits audio, visual or data signals, whether or not designed solely for the reproduction of sound, if the equipment is permanently installed in the covered "auto" at the time of the "loss" and such equipment is designed to be solely operated by use of the power from the "auto's" electrical system, in or upon the covered "auto" and physical damage coverages are provided for the covered "auto"; or If the "loss" occurs solely to audio, visual or data electronic equipment or accessories used with this equipment, then our obligation to pay for, repair, return or replace damaged or stolen property will be reduced by a$100 deductible. 14. LOAN /LEASE GAP COVERAGE A. Paragraph C., LIMIT OF INSURANCE of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by adding the following: The most we will pay for a "total loss" to a covered "auto" owned by or leased to you in any one "accident" is the greater of the.- 1. Balance due under the terms of the loan or lease to which the damaged covered "auto" is subject at the time of the "loss" less the amount of: a. Overdue payments and financial penalties associated with those payments as of the date of the "loss", b. Financial penalties imposed under a lease due to high mileage, excessive use or ab- normal wear and tear, c. Costs for extended warranties, Credit Life Insurance, Health, Accident or Disability Insurance purchased with the loan or lease, d. Transfer or rollover balances from previous loans or leases, e. Final payment due under a"Balloon Loan", f. The dollar amount of any unrepaired damage which occurred prior to the "total loss" of a covered "auto", g. Security deposits not refunded by a lessor, h. All refunds payable or paid to you as a result of the early termination of a lease agreement or as a result of the early termination of any warranty or extended service agreement on a covered "auto", L Any amount representing taxes, j. Loan or lease termination fees; or 2. The actual cash value of the damage or stolen property as of the time of the "loss". An adjustment for depreciation and physical condition will be made in determining the actual cash value at the time of the "loss". This adjustment is not applicable in Texas. B. ADDITIONAL CONDITIONS This coverage applies only to the original loan for which the covered "auto" that incurred the loss serves as collateral, or lease written on the covered "auto" that incurred the loss. C. SECTION V-DEFINTIONS is changed by adding the following: As used in this endorsement provision, the following definitions apply: "Total loss" means a "loss" in which the cost of repairs plus the salvage value exceeds the actual cash value. A "balloon loan" is one with periodic payments that are insufficient to repay the balance over the term of the loan, thereby requiring a large final payment. © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 5 of 7 15. GLASS REPAIR-WAIVER OF DEDUCTIBLE Paragraph D. Deductible of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by the addition of the following: No deductible applies to glass damage if the glass is repaired rather than replaced. 16. PARKED AUTO COLLISION COVERAGE (WAIVER OF DEDUCTIBLE) Paragraph D. Deductible of SECTION III - PHYSICAL DAMAGE COVERAGE is amended by the addition of the following: The deductible does not apply to "loss" caused by collision to such covered "auto" of the private ® passenger type or light weight truck with a gross vehicle weight of 10,000 lbs. or less as defined by ® the manufacturer as maximum loaded weight the "auto" is designed to carry while it is: a. In the charge of an "insured"; " b. Legally parked; and c. Unoccupied. " The 'loss" must be reported to the police authorities within 24 hours of known damage. The total amount of the damage to the covered "auto" must exceed the deductible shown in the ® Declarations. ® This provision does not apply to any 'loss" if the covered "auto" is in the charge of any person or organization engaged in the automobile business. 17. TWO OR MORE DEDUCTIBLES Under SECTION III PHYSICAL DAMAGE COVERAGE, if two or more company policies or coverage forms apply to the same accident, the following applies to paragraph D. Deductible: a. If the applicable Business Auto deductible is the smaller (or smallest) deductible it will be waived; or b. If the applicable Business Auto deductible is not the smaller (or smallest) deductible it will be reduced by the amount of the smaller (or smallest) deductible; or c. If the loss involves two or more Business Auto coverage forms or policies the smaller (or smallest) deductible will be waived. For the purpose of this endorsement company means any company that is part of the Liberty Mutual Group. SECTION IV -BUSINESS AUTO CONDITIONS is amended as follows: 18. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS SECTION IV- BUSINESS AUTO CONDITIONS, Paragraph B.2. is amended by adding the following: If you unintentionally fail to disclose any hazards, exposures or material facts existing as of the inception date or renewal date of the Business Auto Coverage Form, the coverage afforded by this Policy will not be prejudiced. However, you must report the undisclosed hazard of exposure as soon as practicable after its discovery, and we have the right to collect additional premium for any such hazard or exposure. 19. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT, OR LOSS SECTION IV - BUSINESS AUTO CONDITIONS, paragraph A.2.a. is replaced in its entirety by the following: a. In the event of "accident', claim, "suit" or 'loss", you must promptly notify us when it is known to: I. You, if you are an individual; 2. A partner, if you are a partnership; 3. Member, if you are a limited liability company; 4. An executive officer or the "employee" designated by the Named Insured to give such notice, if you are a corporation. © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 6 of 7 To the extent possible, notice to us should include: (1) How, when and where the "accident" or "loss" took place; (2) The "insureds" name and address; and (3) The names and addresses of any injured persons and witnesses. 20. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US SECTION IV - BUSINESS AUTO CONDITIONS, paragraph A.5., Transfer of Rights of Recovery Against Others to Us, is amended by the addition of the following: If the person or organization has waived those rights before an "accident" or "loss", our rights are waived also. 21. HIRED AUTO COVERAGE TERRITORY SECTION IV - BUSINESS AUTO CONDITIONS, paragraph 13.7., Policy Period, Coverage Territory, is amended by the addition of the following: f. For "autos" hired 30 days or less, the coverage territory is anywhere in the world, provided that the insured's responsibility to pay for damages is determined in a "suit", on the merits, in the United States, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to. This extension of coverage does not apply to an "auto" hired, leased, rented or borrowed with a driver. SECTION V -DEFINITIONS is amended as follows: 22. BODILY INJURY REDEFINED Under SECTION V-DEFINTIONS, definition C. is replaced by the following: "Bodily injury" means physical injury, sickness or disease sustained by a person, including mental anguish, mental injury, shock, fright or death resulting from any of these at any time. COMMMON POLICY CONDITIONS 23. EXTENDED CANCELLATION CONDITION COMMON POLICY CONDITIONS, paragraph A. - CANCELLATION condition applies except as fol- lows: If we cancel for any reason other than nonpayment of premium, we will mail to the first Named Insured written notice of cancellation at least 60 days before the effective date of cancellation. This provision does not apply in those states which require more than 60 days prior notice of cancella- tion. © 2013 Liberty Mutual Insurance CA 88 10 01 13 Includes copyrighted material of Insurance Services Office,Inc.,with its permission. Page 7 of 7 . . , LANDMARK AMERICAN INSURANCE COMPANY , This Endorsement Changes The Policy. Please Read It Carefully. ADDITIONAL 8NS80������ ~~ K���H8�U�K�'� J����� ����K8�� 0�y����&���-_ PRIMARY~ . ~ . ,~~~~ YOUR mm��ovm This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE FORM SCHEDULE f0mnmemf Person orOrman�mt��n' HundngbonBeecb �o--------�obad ---'-----------'--- ~ . �... =� = �u � noon/cano. e| oroppoinb:do�cia|u |�mpoy�eo. ogantoandvo/unbsona ' . . , Risk Management Department � 2UOO Main Street _ HunUngbznBeach.CA S2G4D � (if nn entry appears above, information required to complete U on b� this be - th - ---� - amapp�ab|oho this ondoemant.) the Declarations A. SECTION U - WHO IS AN INSURED in amended to include as an additional insured the person(s) or organization(s) shown in the SCHEOULE, but only with naabmct to liability for "bodily injury", "propertyoamage"or'pexoono| ondadve�ioingin/ury^oauoad. invvho|eorinpo�. by: 1' Your acts or omissions; or 3. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations; and/or "your work" defined for the additional insured(s) designated above included in the"prod unto'oomp|ebad operations hozond^ B. If you are required by a written contract or by issuance or existence of written permit, to provide primaryinsurance, this policy shall be primary and SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS, 4. Other Insurance does not apply, but only with respect to coverage provided by this policy. , This endorsement effective 3/21/2010 forms part of Policy Number LHA140489 issued to JAK8|GON ENGINEERING CONTRACTORS .INC by Landmark American Insurance��ompany ' � -----------'-