Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
We R Builders, Inc. - 2026-04-21
RECEIVED BY: CITY CLERK RECEIPT COPY P h 111 ( e v n^ C G G Return DUPLICATE to �C ' `�` City Clerk's Office (Name) after signing/dating (Date)• in CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: 5) I /2p SUBJECT: Bond Acceptance I have received the bonds for (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's)Performance Bond No. 10` I '�rl 221/(j Payment Bond (Labor and Materials) Bond No. O1 Li Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved (Council Approval Date) CC No. I. -3 Agenda Item No. MSC No. City Clerk Vault No. Other No. SIRE System ID No. g:/forms/bond transmittal to treasurer oN11NGTo 2000 Main Street, oF� Huntington Beach,CA -x. City of Huntington Beach 92648 g APPROVED 7-0 \-*eouNTV • File #: 26-268 MEETING DATE: 4/21/2026 REQUEST FOR CITY COUNCIL ACTION SUBMITTED TO: Honorable Mayor and City Council Members SUBMITTED BY: Travis Hopkins, City Manager VIA: Chau Vu, Director of Public Works PREPARED BY: Joseph Pinel, Capital Projects Administrator Subject: Accept Lowest Responsive and Responsible Bid and Authorize to Execute Construction Contract with We R Builders, Inc. in the Amount of $729,770 for the Hartlund Water Main Replacement (CC-1735) Statement of Issue: On February 26, 2026, electronic bids were received for the Hartlund Water Main Replacement Project (CC-1735). City Council action is requested to award the construction contract to We R Builders, Inc., the lowest responsive and responsible bidder. Financial Impact: Based on the low bid received, the total estimated construction cost of this project is $873,271 as itemized below: Item Amount Bid submitted by We R Builders, Inc. $729,770.00 15% Contingency $109,465.50 Supplemental $34,035.50 Total Construction Cost: $873,271.00 Staff recommends awarding the construction contract to We R Builders, Inc. in the amount of $729,770. Funding is available in the current fiscal year budget within the Water Master Plan Fund, Account Nos. 50791033.69365 and 50791033.82100. Recommended Action: A) Accept the lowest responsive and responsible bid submitted by We R Builders, Inc. in the amount of $729,770; and, City of Huntington Beach Page 1 of 3 Printed on 4/15/2026 powered by LegistarT"' 357 File #: 26-268 MEETING DATE: 4/21/2026 B) Authorize the Director of Public Works to approve change orders up to the 15% contingency for potential construction-related changes; and, C) Authorize the Mayor and City Clerk to execute a construction contract with We R Builders, Inc. in a form approved by the City Attorney. Alternative Action(s): Reject all bids and provide staff with alternative action. Analysis: The Hartlund Water Main Replacement Project is part of the City's annual Water Main Replacement Program, designed to proactively upgrade aging components of the water distribution system. The project will replace existing asbestos cement pipe (ACP) with new 6-inch polyvinyl chloride (PVC) pipeline along Hartlund Lane, from Talbert Avenue to Le Conte Drive. Additional improvements include: • Replacement of 4-inch ACP water mains on Magic Circle and Rolf Circle • Replacement of the 6-inch ACP water main on Kiner Drive These upgrades will increase system reliability, enhance water service performance, and address pipelines that have reached the end of their useful life or have insufficient capacity. Bids were received electronically on February 26, 2026. The verified bid amounts are listed below: Bidder's Name Submitted and Verified Bid We R Builders, Inc. $729,770.00 Big Ben Inc $836,530.00 J.A. Salazar Construction & Supply Corp. $867,810.00 Q&E Pipeline Company $978,468.00 TORO ENTERPRISES, inc. $1,454,002.00 Creative Home/DBA: CHI Construction $1,485,742.50 Mike Bubalo Construction Co., Inc. $1,627,233.00 TTS Engineering Inc $1,674,317.66 T.E. Roberts, Inc. $1,794,955.00 Dominguez General Engineering, Inc. $1,809,200.00 CEM Construction $2,177,800.00 RE Chaffee Construction $2,283,460.00 MINAKO AMERICA CORPORATION $3,402,500.00 Staff recommends awarding a contract to We R Builders, Inc. in the amount of$729,770. Reference checks confirm that We R Builders, Inc., has successfully completed potable water main projects and City of Huntington Beach Page 2 of 3 Printed on 4/15/2026 powered by LegistarT"' 358 File #: 26-268 MEETING DATE: 4/21/2026 has demonstrated the capability to perform the work required for the city. The total project cost is estimated to be $873,271, which includes the construction contract, a 15% contingency, and supplemental expenses. Environmental Status: This action is not subject to the California Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not result in a direct or reasonably foreseeable indirect physical change in the environment) and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no potential for resulting in physical change to the environment, directly or indirectly. Strategic Plan Goal: Goal 6 - Infrastructure Investment, Strategy C - Conduct an assessment of all City facilities to determine priorities for upgrades and repairs, implementation and financial priority. Attachment(s): 1. RCA Contract Agreement Summary 2. Construction Contract 3. Vicinity Map 4. PowerPoint Presentation City of Huntington Beach Page 3 of 3 Printed on 4/15/2026 powered by LegistarT" 359 CITY OF HUNTINGTON BEACH 'i0i�� TINGT�roea �1 ff. II;;;;; RCA Contract , : 'v�� Agreement Summary _�F :. ....-���,� -..COUNT`t c,i'l GENERAL INFORMATION DATE PRESENTED REQUESTING DEPARTMENT April 21, 2026 PW- Engineering INSURANCE STATUS STAFF CONTACT[S] In Review (Risk Management) Joseph Pinel (x5291) - Capital Projects Administrator CONTRACT INFORMATION TOTAL COMPENSATION TERM OF CONTRACT/AGREEMENT $729,770 120 Working Days VENDOR NAME+TYPE OF SERVICE We R Builders (Construction Contract) - CC1735 Hartlund Water Main Replacement TYPE OF AGREEMENT(Professional Services,Service Agreement] Construction Contract PROCUREMENT Public Bid Opened February 26, 2026. We R Builders determined to be the lowest responsive and responsible bidder. SCOPE OF WORK Scope of work in relation to city's annual water main replacement program. Project to update oudated water main from asbestos cement pipe (ACP) to a new 6" polyvinyl choloride (PVC) along Hartlund Lane (RD 293). Project includes trenching, miscellaneous concrete, paving, & water service assembly. OTHER:Bonds.Special Contract Terms.Emergency Performance and Payment Bonds for construction activities recieved and filed with the City Clerk's office. BCITY OF HUNTINGTON BEACH 360 CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND WE R BUILDERS,INC. FOR HARTLUND LANE WATER MAIN REPLACEMENT CC1735 THIS AGREEMENT("Agreement")is made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and WE R BUILDERS,INC. , a corporation,hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project,hereinafter referred to as "PROJECT," more fully described as HARTLUND LANE WATER MAIN REPLACEMENT,CC1735 in the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged the parties covenant and agree as follows: 1. STATEMENT OF WORK;ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the 1 16-5195/City Funded Construction Contract.docx—revised 04/2016 prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK;PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms,conditions and obligations of this Agreement and the Contract Documents(as defined below in this Section), has inspected the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents"as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Department of Public Works of CITY, and any revisions,amendments or addenda thereto; 2 16-5195/City Funded Construction Contract.docx—revised 04/2016 D. The edition of Standard Specifications for Public Works Construction, published by Builders'News,Inc., 10801 National Boulevard,Los Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee as specified in the particular Plans, Specifications, Special Provisions and Addendum applicable to the Project; E. Bid documents including the Notice Inviting Bids,the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Director of Public Works of CITY or his or her written designee (hereinafter referred to as "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW,save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3 16-5195/City Funded Construction Contract.docx—revised 04/2016 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement,subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed SEVEN HUNDRED TWENTY-NINE THOUSAND, SEVEN HUNDRED SEVER Dollars �$ 729,770.00 ), as set forth in the Contract Documents, to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten(10)working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within ONE HUNDRED TWENTY L 120 )consecutive Working days from the day the Notice to Proceed is issued by DPW,excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, 4 16-5195/City Funded Construction Contract.docx—revised 04/2016 subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW,and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason,relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 5 I 6-5195/City Funded Construction Contractdocx—revised 04/2016 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent(100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work,and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of'the final contract price, including all change orders, to warrant such performance for a period of one (1)year after CITY's acceptance thereof within ten (10)days of filing of the Notice of Completion. 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR,within ten(10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is,and shall be,acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense,and be responsible for any and all payment of all taxes,social security, state disability insurance compensation, unemployment compensation and other payroll 6 16-5195/City Funded Construction Contract.docx—revised 04/2016 deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIOUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of ONE THOUSAND DOLLARS ($ 1,000.00 ) per each calendar day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes,unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay(unless DPW shall grant a further period of time),notify DPW in writing of the cause of the 7 I6-5195/City Funded Construction Contract.docx—revised 04/2016 delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed,but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen(15)days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DEMANDS FOR ADDITIONAL TIME OR MONEY. A. Definitions. (1) "Change Order"means a document signed by the CONTRACTOR and CITY which authorizes an addition, deletion or revision in the work, or an adjustment in the Compensation under Section 3, or the Completion Time specified at Section 4. (2) "Demand" means a written demand for a Change Order by the CONTRACTOR for any of the following: (a) A time extension; 8 16-5195/City Funded Construction Contract.docx—revised 04/2016 (b) Payment of money or damages arising from work done by,or on behalf of, the CONTRACTOR pursuant to this Agreement and payment of which is not expressly permitted pursuant to Section 3 of this Agreement; (c) Payment of an amount the CITY disputes; (d) Any disputes and other matters relating to the acceptability of the work performed or the interpretation of the Contract Documents; (e) A request for a time extension or additional payment based upon differing site conditions, such as subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents, or unknown physical conditions at the job site,of an unusual nature,differing materially from those ordinarily encountered and generally recognized as inherent to work of the PROJECT; or (f) A request for a time extension or additional payment based upon acts of neglect by CITY or due to fires,floods,labor disputes,epidemics,abnormal weather conditions or acts of God. B. A Demand for a time extension or payment of money or damages may only be granted by a Change Order. C. No Change Order may be granted except where the Contractor has submitted a Demand to the DPW(or his or her written designee). All Demands shall be submitted promptly,but in no event later than thirty(30)days after the occurrence of the event giving rise to the Demand. The Demand shall be in writing and include all documents necessary to substantiate the Demand. The DPW shalt act on the Demand within fifteen (15) days after receipt, including by requesting additional information from the CONTRACTOR to determine whether to approve the Change Order the Demand seeks. The DPW shall act on the Demand within fifteen(15) days 9 16-5195/City Funded Construction Contract.docx—revised 04/2016 after receipt of the additional information or within a period of time no greater than the time the CONTRACTOR took to produce the additional information requested,whichever is greater. D. Notwithstanding the thirty (30) days to submit a Demand under Subparagraph C, in the case of differing or unknown site conditions, immediately upon encountering the conditions, CONTRACTOR shall notify the DPW in writing of the conditions, so that the CITY may promptly investigate the conditions. E. If the CONTRACTOR disputes the DPW's written response on the Demand, or the CITY fails to respond within the time prescribed, the CONTRACTOR may so notify the City Engineer,in writing,either within fifteen(15)days of receipt of the City Engineer's response or within fifteen (15) days of the DPW's failure to respond within the time prescribed, respectively,and request an informal conference to meet and confer for settlement of the Demand. Upon the CONTRACTOR's request,the DPW shall schedule a meet and confer conference within thirty(30) days to seek to resolve. F. CITY and CONTRACTOR shall execute appropriate Change Orders covering changes to the time or price by executing the Change Order by mutual agreement. If the CITY and CONTRACTOR are unable to reach a mutual agreement, then the City Engineer shall issue a written decision on the claim within a reasonable time. G. Following the meet and confer conference, if the Demand remains in dispute,the CONTRACTOR may file a claim with the City as provided in Chapter 1 (commencing with Section 900)and Chapter 2(commencing with Section 910)of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the CONTRACTOR submits his 10 16-5195/City Funded Construction Contract.docx—revised 04/2016 or her Demand until the Demand is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. 13. VARIATIONS IN ESTIMATED OUANTII'IhS The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT,if the actual quantities used are either more than or less than the quantities listed in the bid schedule,the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion,DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, five percent(5%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work,will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent(50%)or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such 11 16-5195/City Funded Construction Contractdocx—revised 04/2016 sum as will bring the payments of each month up to one hundred percent(100%) of the value of the work completed since the commencement of the PROJECT,as determined in its sole discretion by DPW,less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR,if unencumbered,or any part thereof unencumbered,shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Provided,however,that in the event of a dispute between CITY and CONTRACTOR,CITY may withhold from the final payment an amount not to exceed 150 percent of the value of any disputed amount of work. Payments shall be made on demands drawn in the manner required by law,each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR,who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items,if any,to be set forth in CONTRACTOR's affidavit covering disputed claims, 12 16-5195/City Funded Construction Contract doex—revised 04/2016 or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25)for each calendar day or portion thereof for each worker paid(either by CONTRACTOR or any of its subcontractors)less than the prevailing wage rate established for that particular craft or type of work. 18. CALIFORNIA PREVAILING WAGE LAW A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by 13 16-5195/City Funded Construction Contract.docx—revised 04/2016 resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. hi accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 19. CALIFORNIA EIGHT-HOUR LAW A. California Labor Code,Sections 1 810 et seq,shall apply to the performance of this Agreement;thereunder,not more than eight(8)hours shall constitute one day's work and CONTRACTOR and each subcontractor employed by its hereunder,shall not require more than eight(8)hours of labor per day or forty(40)hours per week from any one person employed by it hereunder, except as stipulated in California Labor Code Section 1815. CONTRACTOR and each subcontractor employed by it hereunder shall, in accordance with California Labor Code Section 1812, keep an accurate record, open to inspection at all reasonable hours, showing the name and actual hours worked each calendar day and each calendar week by each worker employed in connection with the PROJECT. B. Pursuant to this Agreement and in accordance with California Labor Code Section 1813, CONTRACTOR shall, as a penalty to CITY, forfeit twenty-five dollars ($25) for each worker employed hereunder by CONTRACTOR or any subcontractor for each calendar day during which such worker is required or permitted to work more than eight(8) hours in any one 14 16-5195/City Funded Construction Contractdocx—revised 04/2016 (1)calendar day or forty(40)hours in any one(1)calendar week in violation of California Labor Code Section 1815. 20. PAYMENT OF TRAVEL AND SUBSISTENCE ALLOWANCE Section 1773.8 of the California Labor Code,regarding the payment of travel and subsistence allowance is applicable to this PROJECT. 21. EMPLOYMENT OF APPRENTICES Section 1777.5 of the California Labor Code, regarding the employment of apprentices is applicable to this PROJECT. 22. PAYROLL RECORDS CONTRACTOR agrees to keep accurate payroll record showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice or worker employed by it in connection with the PROJECT and agrees to require each of its subcontractors to do the same. CONTRACTOR further agrees that its payroll records and those of its subcontractors,if any, shall be available at all reasonable times to the CITY, and the employee or his representative,and the Division of Labor Standards Enforcement and the Division of Apprenticeship Standards, and to comply with all of the provisions of California Labor Code Section 1776, in general. 23. INDEMNIFICATION,DEFENSE,HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all claims, damages, losses, expenses,judgments, demands, defense costs, and consequential damage or liability of any kind or nature,however caused,including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, 15 16-5195/City Funded Construction Contract.docx—revised 04/2016 arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable,including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY, its officers, elected or appointed officials, employees, agents, and volunteers. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 24. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 16 16-5195/City Funded Construction Contract.docx—revised 04/2016 25. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend,hold harmless and indemnify CITY,CONTRACTOR shall obtain and furnish to CITY,a policy of general public liability insurance,including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit,the aggregate limit must be no less than One Million Dollars($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees,agents,and volunteers(the"Additionally Insured Parties")as Additional Insureds,and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary and non-contributory with any other valid and collectible insurance or self-insurance available to the Additionally Insured Parties. Any available insurance proceeds in excess of the minimum coverage amount specified herein shall be available to the Additionally Insured Parties. All coverage available to CONTRACTOR shall also be available to the Additionally Insured Parties. Under no circumstances shall said above-mentioned insurance contain a self-insured retention without the express written consent of CITY; however an insurance policy"deductible" of Five Thousand Dollars($5,000.00) is permitted. CONTRACTOR shall be responsible for causing all Subcontractors to maintain the same types and limits of insurance coverage as that required of CONTRACTOR by this Agreement. 17 16-5195/City Funded Construction Contract.docx—revised 04/2016 26. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. Provide the name and policy number of each carrier and policy; 2. State that the policy is currently in force; and 3. Promise to provide that such policies will not be canceled or modified without thirty (30)days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 27. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten(10)days of receipt of such claim or claims. 18 16-5195/City Funded Construction Contract.docx—revised 04/2016 28. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten(10)days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR,CITY may elect not to terminate this Agreement;in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 29 and any damages shall be assessed as set forth in Section 29. 29. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause,and whether or not PROJECT is fully complete upon seven(7)calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience,the CONTRACTOR shall be entitled to receive payment for work executed, and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's 19 16-5195/City Funded Construction Contract.docx—revised 04/2016 sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 30. DISPOSITION OF PLANS,ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 31. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement,or any part hereof,or any right or duty created herein,without the prior written consent of CITY and the surety. 32. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any fmancial interest in this Agreement in violation of the California Government Code. 33. STOP NOTICES;RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices,Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100)for every Stop Notice filed in excess of two(2),regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 20 16-5195/City Funded Construction Contract.docx—revised 04/2016 34. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant,or by enclosing the same in a sealed envelope,postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices,certificates or other communications will be sent by notifying the other party via personal delivery, reputable overnight carrier or U. S. certified mail-return receipt requested: TO CITY: TO CONTRACTOR: City of Huntington Beach WE R BUILDERS,INC. ATTN:JOSEPH PINEL , Public Works ATTN: NEZAR ALSMADI 2000 Main Street 1608 PALMYRITA AVENUE Huntington Beach, CA 92648 RIVERSIDE, CA 92507 35. SECTION HEADINGS The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions,and do not interpret,define,limit or describe,or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 21 16-5195/City Funded Construction Contract.docx—revised 04/2016 36. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 37. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 38. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non-prevailing party. 39. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the 22 16-5195/City Funded Construction Contract.docx—revised 04/2016 context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 40. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 41. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. 42. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 43. SURVIVAL Terms and conditions of this Agreement,which by their sense and context survive the expiration or termination of this Agreement shall so survive. 44. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 23 16-5195/City Funded Construction Contract.docx—revised 04/2016 45. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact,held by the signatory or is withdrawn. 46. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiation,and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements,promises, agreements or warranties,oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement, promise, agreement,warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof. 24 16-5195/City Funded Construction Contract.docx—revised 04/2016 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers on 2I ( , 2014, . CONTRAC OR: CITY OF HUNTINGTON BEACH,a municipal corporation of th tate of Calico 'a By: Nezar Alsmadi Ma or (print name) ITS: Chairman resident Vice-President City Clerk (circle one) INITIATED 72 By: Director of Public Works Nezar lsmadi (print name) REVIEWED AND APPROVED: ITS: ecre . / Chief Financial Officer / Asst. Secretary reasurer (circle one) City ager APPROVED AS TO FORM: f ../t/ F,- City Attorney COUNTERPART 25 16-5195/City Funded Construction Contract.docx—revised 04/2016 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by and through their authorized officers on �i ZJ` , 20 212 . CONTRACTOR: CITY OF HUNTINGTON BEACH,a municipal corporation of th State of California By: May (print name) ITS: Chairman/President/Vice-President City Clerk (circle one) INITIATED AN R AND By: Director of Public Works (print name) REVIEWED AND APPROVED: ITS: Secretary / Chief Financial Officer / Asst. Secretary/Treasurer C`" _ kla ei .- (circle one) City Manager APPROVED AS TO FORM: F,.. City Attorney COUNTERPART 25 16-5195/City Funded Construction Contract.docx—revised 04/2016 /Xth8iT 4 ' SECTION C PROPOSAL for the construction of HARTLUND LANE,WATER MAIN REPLACEMENT BETWEEN LE CONTE DR. AND TALBERT AVE. CC NO. 1735 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting ELECTRONIC Bids,the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor, material, equipment and incident insurance necessary therefor, in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the following prices. The undersigned agrees to complete the work within 120 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award,BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guarantee accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded,the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. c-i If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid,find Bidders Bond for 10% in the amount of which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting ELECTRONIC Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond for_% ", as the case may be) Any standard Surety Bid Bond form is acceptable. Bidder shall signify receipt of all Addenda here and submit the signed addendum, if any: Addenda No. Date Received Bidder's Signature N/A N/A N/A C-2 BID SCHEDULE Item Description Quantity Unit Unit Cost Total Cost No. (Extension) A Perform Mobilization, Set Up, and Demobilization including, contractor yard, field office, pre- construction activities including, submittals and shop drawings and clean-up during and after completion of construction 1 LS $30}000 s 30, aoo 2 Furnish and Maintain Project Traffic Control in accordance with City of Huntington Beach requirements, including warning signs,delineators, regulatory signs,project information signs, Traffic Control submittals and updates,daily inspections, and administrative coordination. 1 LS $IQ 00o S l0 000 3 Provide all necessary Pre- Construction Survey and Documentation, services required for preparation and submission of all required pre-construction documents (reports, videos, photographs), project site documentation video and drawings for documenting existing conditions per project specifications. 1 LS S B Soo $ 8,5OO 4 Furnish all labor, materials, and equipment required to provide Water Pollution Control and SWPPP, including preparation of Storm Water Pollution Prevention Plan, filing Notice of Intent, and implementing, inspecting, and maintaining BMPs. I LS S 4(29_ $14 Furnish all labor, materials, shop 5 drawings, and equipment required to provide Shoring and Bracing, for performing Excavation Safety I LS S51900 $ 51000 _ Item Description Quantity Unit Unit Cost Total Cost No. (Extension) Measures such as sheeting, shoring and bracing. 6 Furnish all labor, materials, and equipment necessary for Remove Valves, Boxes, and Abandon Existing Pipelines and Fittings and seal existing pipe. 1,990 LF S 1.OO S �� ql O 7 Furnish all labor, materials, and equipment necessary for Removal, Handling and Legal Disposal of Interfering AC Pipe including removal, handling and disposal per SCAQMD regulations, 1 LS S11 000 $ 1 00O 8 Furnish all labor, materials, tools, equipment necessary for, and performing the work necessary for installing 6-inch C-900, DR-18 PVC Water Main including pavement removal, trenching, thrust blocks, pipe and fittings, appurtenances, and backfilling 2,074 LF S 140 S 290 3(QO 9 Furnish and install Connection to Existing 8-inch Water Main in Talbert Ave, including pavement removal, trenching, tapping sleeve, thrust blocks, pipe and fittings, appurtenances, and backfilling 1 LS $30,000 $ 301000 10 Remove existing fire hydrant and Furnish and install new Fire Hydrant Assembly including pavement removal, trenching, salvage existing hydrant, new hydrant, thrust blocks, pipe and fittings, appurtenances, and backfilling. 3 EA S11;000 $ 331 OOO Item Description Quantity Unit Unit Cost Total Cost No. (Extension) 1 Remove existing and Furnish and install new Water Service Assembly including pavement removal, trenching, salvage existing meter, new meter, CMB, thrust blocks, pipe and fittings, appurtenances, and backfilling. 19 EA S Li 1OOO $ 3(Q,000 12 Furnish and install Temporary Water Service Pipeline including pipe and fittings, appurtenances, thrust blocks and restraints, street and driveway crossings, connections to services and hydrants, testing and disinfection, piping system removal and repair of damaged areas 1 LS $ 50 5OOOO S 50,OOO 13 Furnish and install Pressure Test, Disinfect, and Flush New Mains for the new water main in accordance with the City's Standards Section 02516, 02516.1, 02516.2, and 02517. 1 LS $ ►21000 S 12000 14 Furnish and install as needed for Reconstruct Sewer House Laterals is for existing interfering sewer laterals per Greenbook Standard Plan 223-2 and City Standard Plan 507& 508, 4 EA S 2OOO S a,OOO 15 Construct AC Pavement and Aggregate Base includes the placement AC paving and AB base material as identified in City Standard plan 109 10,000 SF $ 13.50 S 135,000 Item Description Quantity Unit Unit Cost Total Cost No. (Extension) 16 Miscellaneous Concrete Removal and Replacement includes the removal and installation of miscellaneous portland cement concrete, per City Standards 202, 207,& 209, as required for installation of the new water main or the abandonment of the existing pipe I LS $ $OO $ a,500 TOTAL BID ITEMS I TIIRU I6 FOR HARTLUND LANE, WATER MAIN REPLACEMENT BETWEEN LE CONTE DR. AM) TALBERT AVE. CC NO. 1735 $ O, OD Total Amount of Base Bid in Writing: S eVt✓N Hv rvD>t60 1 tAFeNry N IK16 -ii-FO US r4ND SEVEN li v NU p Note l: Refer to Section 7, Measure and Payment for additional information on bid items. LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater, and the portion of the work to be done by such subcontractor. Bid Name and Address of State class DIR PWC Dollar % of Item(s) Subcontractor License Registration # Amount Contract Number Name:HARDY HARPER ASPHALT A PAVING,INC. C-8& 1000000076 $48,024.00 7% Bid Item 15 Address:32 Rancho Circle,Lake Forest, 215952 C12 CA 92630 Name:Alliance Environmental B,C2, Group,LLC C20,C21, 1 /a Bid Item 7 Address:777 North Georgia Ave,Azusa, 716538 C22,C611 1000058821 $8,700.00 CA 91702 D64 By submission of this proposal, the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on 02/26/26 , at Riverside , Date City State Nezar Alsmadi , being first duly sworn, deposes and says that he or she is President, Secretary&Treasurer of We R Builders, Inc. the party making the foregoing bid that the bid is not made in the interest of,or on the behalf of,any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham;that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further,that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. We R Builders, Inc. Name of Bidder if/9 Si ature of Bidder 1608 Palmyrita Ave, Riverside, CA 92507 Address of Bidder C-4 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH, CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the Hartlund Lane Water Main Replacement, between Le Conte Dr. and Talbert Ave. (CC No. 1735), (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined,to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. We R Builders, Inc. Contractor !(� Nezar Alsmadi President, Secretary&Treasurer Title Date: 02/26/2026 C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162, the Bidder shall complete, under penalty of perjury,the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified, removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑ Yes El No If the answer is yes, explain the circumstances in the space provided. N/A Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code,each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. We R Builders, Inc. Contractor • Nezar Alsmadi President, Secretary&Treasurer Title Date: 02/26/2026 C-7 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: We R Builders, Inc. Bidder Name 1608 Palmyrita Ave Business Address Riverside, CA 92507 City, State Zip (714)423-3844 (Primary Contact-Direct); (714)874-5275(office) Estimates@WRBConstruction.com Telephone Number Email Address 1055746(Class A&B) State Contractor's License No. and Class 7/11/2019 Original Date Issued 07/31/2027 Expiration Date The work site was inspected by Nezar Alsmadi of our office on February 16 , 2026 . The following are persons, firms, and corporations having a principal interest in this proposal: We R Builders, Inc. (Corporation/Bidder) Nezar Alsmadi (President, Secretary&Treasurer) The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. We R Builders, Inc. Company Name S' nature of Bidder Nezar Alsmadi Printed or Typed Signature C-8 NOTARY CERTIFICATE Subscribed and sworn to before me this day of , 202_ . State of ) County of ) On before me, Month, Day, and Year Insert Name and Title of Notary personally appeared Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies),and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature See Attached Signature of Notary Public (PLACE NOTARY SEAL ABOVE) C-9 CALIFORNIA ACKNOWLEDGMENT CIVIL CODE §1189 ����;�dtK3�'•id?L�i6�ss§:3�+.�a.�a+`�ax:uc�'Ait�'�fitG:aa?s!��:�riY?hria'h.h��t�.�.�"e��kkr::�"�::`�Fu"�z'� "� 3�t8�°fs.8 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California County of Ck‘Jecs: � On `�o'CaGr'tZCo iZcl2it before me, wtr.._ (�cSe_S 1`11 k �(?-39`i c Dates Here Insert Name and Title of the Office personally appeared `v e— ' - A.SVMC. J. Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted,executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing �utets usM�d paragraph is true and correct. Notary Public-Callfarnta ' ` Los TTIS31Angelo'2046' WITNESS my hand and official seal. �T,+.;�• Commlulon 1246697 My Comm.Expires Oct 2!,2027 k Signature LcsAAA.e e—S Place Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): ❑ Corporate Officer—Title(s): ❑ Partner— 0 Limited ❑ General 0 Partner— ❑ Limited 0 General o Individual 0 Attorney in Fact ❑ Individual ❑ Attorney in Fact o Trustee 0 Guardian or Conservator ❑ Trustee ❑ Guardian or Conservator ❑ Other: o Other: Signer is Representing: Signer is Representing: tt ,, �as+is ©2019 National Notary Association Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work, specifically referencing the construction of potable water pipelines within public right-of-way in alley and/or street, alley and street paving projects within public right-of-way, and working within major arterials, alleys and streets and in close proximity to other underground utilities. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: 1. See attached Project Experience&References attachment. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: 2. See attached Project Experience&References attachment. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: 3. See attached Project Experience&References attachment. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: c-b We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I Operati ons@WRBConstruction.com CA License#1055746 I DIR#1000884610 PROJECT EXPERIENCE& REFERENCES About Our Experience We R Builders, Inc. is a California-licensed public works contractor specializing in underground wet utility infrastructure, including potable and recycled water pipelines, wastewater systems, storm drain improvements, and associated concrete, ADA, and civil restoration work for municipal agencies and water districts throughout Southern California. The firm's qualifications reflect a consolidated portfolio of public works experience consisting of projects performed directly by We R Builders, Inc., together with comparable underground utility and civil infrastructure projects previously delivered under the executive leadership of the firm's principal during prior ownership and leadership roles with other California-licensed contracting entities.The principal of We R Builders,Inc.no longer maintains any ownership interest or affiliation with those prior entities; however, the technical expertise, field leadership, and project delivery experience developed through those executive roles now reside within We R Builders, Inc. Through this combined experience, the firm's executive leadership has successfully overseen the delivery of water distribution and transmission mains, recycled water systems, sewer and storm drain improvements, treatment facility tie- ins,structural concrete work,ADA compliance programs,and multi-location on-call and task order contracts.All work has been executed in accordance with applicable public agency standards and specifications, including AWWA, ASTM, MUTCD,WATCH,Caltrans requirements where applicable,and governing municipal and water district criteria. The Project Experience Portfolio that follows presents representative projects demonstrating both firm-performed work and prior executive-led experience of similar scope,complexity,and regulatory rigor.References are available to confirm project delivery and executive-level responsibility for the listed projects,as applicable. Collectively,this experience demonstrates We R Builders, Inc.'s technical competence, compliance discipline, and organizational capacity to successfully execute complex public works utility and civil infrastructure projects. WE R BUILDERS,INC. WWW.WRBCONSTRUCTION.COM QUALIFICATION PACKAIii: We R Builders, Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I Operations@WRBConstruction.com CA License#1055746 I DIR#1000884610 PROJECT EXPERIENCE& REFERENCES Project's Portfolio Project: Public Water Improvement Plan—Tract 82836(Olson Group Development Project) Owner: Rowland Water District Address: 18616 Rorimer Street,La Puente, CA 91744 Contract Value: $430,000 Completion: 2023 Contact: John Poehler,Project Manager I (562) 522-5873 Scope of Work: • Installed a complete new potable water distribution system for a residential development • Installed multiple water mains ranging from 6-inch, 8-inch, 10-inch, and 12-inch diameter PVC and ductile iron pipe • Performed trench excavation, shoring, bedding, backfilling,and compaction • Installed fire hydrant assemblies, fire services, domestic water services, and water meters at each lot • Installed pipe fittings and appurtenances secured with thrust blocks where required • Conducted chlorination and pressure testing of the new water system • Completed tie-ins to the existing water distribution network • Performed surface restoration including Portland cement concrete,hot-mix asphalt,and landscape restoration • Coordinated all work in accordance with Rowland Water District standards and Los Angeles County Public Works requirements Project: Thompson Water Treatment Plant—Backwash Supply Pipeline Owner: Rubidoux Community Services District Engineer/CM: Krieger& Stewart,Inc. Contract Value: $675,039 Completion: December 2024 Contact Information: Brandon C. Valadez,Project Manager; K&S 1 (951)684-6900 Scope of Work: • Installed approximately 12-inch potable water pipeline • Performed trench excavation, shoring, bedding,and compaction • Installed mechanical appurtenances and completed treatment plant tie-ins • Constructed reinforced concrete foundations • Conducted pressure testing, chlorination,commissioning, and acceptance support • Completed full site and surface restoration • Coordinated closely with District operations staff Project: Esperanza Avenue Waterline Improvements—Phase I Owner: Cabazon Water District Engineer/CM: Krieger& Stewart, Inc. Contract Value: $283,095 Completion:August 2024 Contact Information: Travis R. Romeyn, District Consulting Engineer; K&S I (951)684-6900 Scope of Work: • Installed 8-inch AWWA C900 DR25 potable water main • Installed valves and services; performed trench excavation, shoring, and compaction testing • Coordinated utility work within County right-of-way • Completed pressure testing, flushing,and disinfection • Restored asphalt and concrete surfaces WE R BUILDERS,INC. W WW.WRBCONS'IRIICIION.COM We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I Operations(&,WRBConstruction.com CA License#1055746 I DIR#1000884610 PROJECT EXPERIENCE& REFERENCES Project's Portfolio Project: Market Street&24th Street Water Transmission Main Relocation Owner: Rubidoux Community Services District Engineer/CM: Krieger&Stewart,Inc. Contract Value: $330,756 Completion: February 2024 Contact Information: Sinisa Saric,Project Manager;K&S I(951)684-6900 Scope of Work: • Relocated and constructed 16-inch ductile iron transmission water main • Executed night work within an active arterial intersection • Installed restrained joint fittings,thrust blocks,valves,and appurtenances • Implemented WATCH-and MUTCD-compliant traffic control • Coordinated shutdowns and performed hydrostatic testing • Completed paving and surface restoration Project: On-Call Citywide ADA Curb Ramp Modifications and Sidewalk Replacement Program Owner:City of Palm Desert,Department of Public Works Contract Value: $600,000 Annually Term:August 2024—August 2027(Plus Two One-Year Extension Options) Contact: David Reyes I (760)862-6802 I dreyes@palmdesert.gov Scope of Work: • Performed ADA curb ramp modifications and sidewalk replacements citywide • Reconstructed curb ramps with truncated domes and retrofitted existing surfaces • Replaced sidewalks(4",6",and 8"),curb&gutter, cross gutters,and drive approaches • Performed ramping,patching,and grinding for grade correction and trip hazard removal • Maintained compliance with Cal/OSHA,CARB emissions,and water quality standards • Delivered rapid on-call response with minimal disruption to the community Project: Citywide Pedestrian Crossing Improvements Owner: City of Riverside,Department of Public Works Contract Value: $314,000 Completion: March 2024 Contact: David Hatch I(951)(951)288-3632 I dhatch@riversideca.gov Scope of Work: • Enhanced pedestrian safety at 14 citywide locations • Installed ADA-compliant curb ramps,flashing LED solar stop signs,and high-visibility crosswalks • Implemented WATCH-compliant traffic control and SWPPP/NPDES measures • Completed on time,within budget,with zero safety incidents Project: Citywide Sidewalk Rehabilitation Project(CIP-CS-24-02) Owner: City of Claremont,Community Services Department Contract Value: $230,000 Completion:June 2024 Contact: Cari Dillman I(909)399-5431 I cdillman@ci.claremont.ca.us Scope of Work: • Replaced approximately 10,000 SF of sidewalk, 1,000 LF of split-face rock curb,and 1,000 SF of driveway approaches • Installed decorative"Elephant Toe"curb per City standard • Managed pedestrian and vehicular traffic per WATCH manual requirements • Resolved tree-root conflicts and performed grading corrections • Coordinated closely with City inspectors to ensure ADA and design compliance • Delivered within budget and schedule in a constrained residential environment WE R BUILDERS,INC. WWW.WRBCONSTRUCTION.COM Qt \I 1('rAIIUN P \( \(,I We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.52751 Operations a'W RBConstruction.com CA License#1055746 I DIR#1000884610 PROJECT EXPERIENCE& REFERENCES Project's Portfolio Project: Public Works Concrete Maintenance Project(PW-24-133-SB) Owner: City of Fontana, Department of Public Works Contract Value: $250,000 Completion: December 2024 Contact: Rob Rigby 1 (909)350-76101 rrigby@fontanaca.gov Scope of Work: • Demolished and replaced over 22,600 SF of 4" PCC sidewalks, including selective 6"sections • Executed work in compliance with City standards and prevailing wage requirements • Implemented WATCH-compliant traffic control and SWPPP/NPDES measures • Tracked quantities and coordinated inspections with City staff • Delivered safely, within budget,and in full compliance Project: On-Call Emergency Asphalt and PCC Restorations Owner: City of Santa Ana, Department of Public Works Contract Value: $3,000,000(Work Order-Based Program) Term: 2023—Ongoing(Three-Year Extension) Contact: Michelle Cabanas 1 (714)(714)647-5031 I mcabanas@santa-ana.org Scope of Work: • Performed on-call PCC restorations including sidewalks,curbs, gutters,cross gutters, approaches,and ADA ramps • Provided rapid emergency mobilization citywide • Implemented WATCH-compliant traffic control and SWPPP/NPDES measures • Delivered ADA-compliant,durable repairs with minimal public disruption Project: On-Call Related Services—Task Order Contract Owner: Eastern Municipal Water District(EMWD) Contract Value: Work Order-Based Completion: 2025 Contact: Haely Hernandez I (951)928-3777 ext. 62311 hernanha@emwd.org Scope of Work: • Delivered concrete and structural repair services under a multi-year on-call contract • Scope included sidewalks,curb&gutter, foundations,CMU walls, and fencing repairs • Bundled multi-location tasks to improve efficiency and reduce costs • Maintained strict safety,quality,and compliance oversight • Delivered flexible solutions tailored to EMWD and local jurisdiction standards Project: Concrete,Masonry, and Drainage Repair/Maintenance Master Agreement Owner: Sierra Corporate Management, Inc. Contract Value: $1,000,000 Completion: December 2022 Contact: Edmund Nisbet 1(682)215-90491 edmundnisbet@gmail.com Scope of Work: • Performed maintenance and major concrete and masonry services across Southern California properties • Coordinated directly with homeowners and property managers • Renovated pool facilities to meet health and safety standards • Completed ADA upgrades to common areas • Designed and installed drainage improvements including pumps, piping, and catch basins WE R BUILDERS,INC. A\\i'\k.vv RBCo .,I RI ( flos'.C t \1 We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I Operations: WRBConstruction.com CA License#1055746 I DIR#1000884610 PROJECT EXPERIENCE& REFERENCES Project's Portfolio Project: Retaining Wall and Foundation System Replacement Owner: Hollydale Estates Contract Value: $350,000 Completion: December 2022 Contact: Edmund Nisbet I (682)(682)215-9049 I edmundnisbet@gmail.com Scope of Work: • Replaced over 500 LF of failing CMU retaining walls with new foundation systems • Maintained site safety and resident access throughout construction • Ensured compliance with structural and regulatory standards • Completed on schedule with zero safety incidents Project: Community Pool Renovations and ADA Accessibility Upgrades Owner: Solterra at Civic Center Contract Value: $300,000 Completion: December 2021 Contact:Alex Segal 1 (949)910-8031 I asegal@apex-rm.com Scope of Work: • Renovated multiple community pool facilities • Replaced decks,coping, and plaster • Installed drainage improvements and upgraded pumps, utilities,plumbing, electrical,and irrigation systems • Installed tiles,handrails, steps,and fencing to enhance safety and accessibility ADDITIONAL REFERENCES(AVAILABLE UPON REQUEST) Includes numerous residential and institutional communities throughout Southern California where services included concrete flatwork, drainage repairs,ADA upgrades, utility repairs, and emergency response work. WE R BUILDERS,INC. WW W.WRBCONS'1 RI IC I'ION.COM .)l \i I� !t +,: I t I y l' \t Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager, and Superintendent. For each of these critical positions, please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project. Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. Nezar Alsmadi (Resume attached) Name of proposed Project Manager Telephone No. of proposed Project Manager: (714)423-3844 Public Water Improvement Plan- F&I 6", 8", 10"& 12" PVC& DI Water Main, Tract 82836; $430K Water Services, Fire Hydrants&Laterals 08/2023 Project Name & Contract Amount Type of Work Date Completed Oasis Street Water Main F&I 12" DI Water Main, Water Services, Blow-off Replacement Project; $650K Assemblies, Waterline Tie-ins;Abandonments;etc. 12/2023 Project Name & Contract Amount Type of Work Date Completed Gateway Park Revitalization F&I 4" &6" PVC Water, Sewer& Project; $1.7M Storm Drain Mains&Laterals 11/2024 Project Name & Contract Amount Type of Work Date Completed 2. Alex Miramontes(Resume attached) Name of proposed Superintendent Telephone No. of proposed Superintendent: (714)900-8739 3 Miles of 6" PVC Transmission line ; TL673 Project; $30M Horizontal Directional Drill under Roadway. 5/2023 Project Name & Contract Amount Type of Work Date Completed Oasis Street Water Main F&I 12" DI Water Main, Water Services, Blow-off Replacement Project; $650K Assemblies, Waterline Tie-ins;Abandonments; etc. 12/2023 Project Name & Contract Amount Type of Work Date Completed Gateway Park Revitalization F&I 4" &6" PVC Water, Sewer& Project; $1.7M Storm Drain Mains&Laterals 11/2024 Project Name & Contract Amount Type of Work Date Completed C-11 We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I OperationsaWRBConstruction.com CA License#1055746 I DIR#1000884610 KEY PERSONAL NEZAR ALSMADI President& Chief Executive Officer I Project Manager Professional Summary Executive-led public works construction professional with over 15 years of experience delivering underground utility,civil, concrete,and ADA infrastructure projects for municipal agencies and water districts throughout Southern California.Serves as both executive decision-maker and hands-on Project Manager, providing direct oversight of contract compliance, schedule control, cost management, safety, quality assurance, and stakeholder coordination from preconstruction through final acceptance.Known for disciplined execution,transparent communication,and agency-focused delivery. Licenses& Certifications • California State License Board(CSLB) o Class A—General Engineering o Class B—General Building o License No. 1055746 • OSHA 30-Hour Construction Safety Education • Bachelor of Science,Civil Engineering Executive& Project Management Responsibilities • Provides executive oversight and project management leadership for all public works contracts • Serves as the primary point of contact for owners, engineers, inspectors,and utility agencies • Leads preconstruction planning,constructability reviews,sequencing,and mobilization strategies • Develops project schedules,monitors progress,and implements corrective action as needed • Oversees project budgets,cost controls, forecasting,and financial performance • Ensures compliance with contract documents,specifications,permits,and agency requirements • Manages risk identification,issue resolution,and dispute avoidance strategies • Leads change order evaluation,pricing strategy,negotiation support,and approval • Oversees submittals,RFIs,testing coordination,inspections,and closeout documentation • Directs safety planning, labor compliance coordination,and quality control enforcement • Retains final authority and accountability for schedule,cost,safety, and performance outcomes Representative Public Works Experience • Potable and recycled water distribution and transmission pipelines • Sewer and storm drain infrastructure improvements • Treatment plant tie-ins and shutdown coordination • Utility work in active rights-of-way under continuous inspection • ADA curb ramp,sidewalk,and access compliance programs • Multi-location and on-call public works contracts for municipal agencies WE R BUILDERS,INC. WWW.WRBCONSTRUCTION.COM QtALIFI('AIION P 1(`h1(11. We R Builders,Inc. 1608 Palmyrita Ave,Riverside,CA 92507 714.874.5275 I Operations(a,WRBConstruction.com CA License#1055746 I DIR#1000884610 KEY PERSONAL ALEXANDER MIRAMONTES Project Superintendent Professional Summary Experienced Project Superintendent with more than 10 years of field leadership in underground utility, civil, and public right-of-way construction. Responsible for daily field execution, crew supervision, safety enforcement, and coordination with inspectors and subcontractors. Brings strong hands-on knowledge of utility installation, traffic control, excavation safety,and restoration work,ensuring projects are delivered safely,efficiently,and in compliance with agency standards. Certifications&Training • OSHA Construction Safety Training • Trench&Excavation Competent Person • Traffic Control Certification(WATCH or equivalent) Field Leadership Responsibilities • Provides day-to-day supervision of field crews,subcontractors,and equipment • Coordinates site logistics,access, and work sequencing in active public environments • Oversees underground utility installation,testing,and surface restoration activities • Implements trenching,shoring,excavation,and site safety requirements • Sets up and maintains traffic control per agency requirements and WATCH standards • Interprets plans,specifications,and field directives for crews • Coordinates daily with inspectors,engineers,and utility representatives • Schedules and supports required inspections,testing,and corrective actions • Prepares Daily Work Reports(DWRs),photo documentation,and field records • Verifies completed quantities and conformance with plans and specifications • Supports punch-list completion and field closeout activities Relevant Experience • Water,sewer,and storm drain installations • Concrete sidewalk,curb&gutter,and ADA ramp construction • Work in live traffic corridors and occupied facilities • Multi-location and on-call public works programs WE R BUILDERS,INC. WWW.WRBC0NSTRUCTI0N.00M CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)), passed by the California State Senate on June 20,2014,established a new public works Contractor Registration Program,which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July 1 through June 30 state fiscal year) with the California Department of Industrial Relations(DIR).Currently the annual non-refundable registration fee for Contractors is $400. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT SHEET on SB 854 https://www.dir.ca.gov/public-works/PublicWorksSB854.html DIR's Contractor Registration Link—Call (844) 522-6734 https://www.dir.ca.gov/public-works/contractor-registration.html DIR's Contractor Registration searchable database: https://cadir.secure.force.com/ContractorSearch I am aware and will comply with the provisions of Labor Code Section 1771.1(a) which states: "A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded." I furthermore will comply by providing proof of registration with DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. We R Builders, Inc. Contractor • Nezar Alsmadi Estimates@WRBConstructioncom Email President, Secretary&Treasurer Title Date: 02/26/2026 PWC Registration #: 1000884610 C-12 Registration Date List Page 1 Report Title: Registration Date List Run Date and lime: 2025-06-29 20:24:07 Pacific Daylight Time Run by: Nezar Alsmadi Table name: x_cdoi2_csmportal_his_reg_dates Query Condition: Contractor=1000884610-We R Builders AND Registration Status!=Cancelled Sort Order. None Value of property'gllde.pdf.max rows'must be less or equal than 5,000.Default max row number applied(1,000) 5 Registration Dates Contractor Registration Start Date Registration End Date Registration Status 1000884610-We R Builders 2024-07-01 2025-06-30 Active 1000884610-We R Builders 2023-07-01 2024-06-30 Expired 1000884610-We R Builders 2022-04-17 2022-06-30 Expired 1000884610-We R Builders 2025-07-01 2027-06-30 Future 1000884610-We R Builders 2022-09-22 2023-06-30 Expired Run By:Nezar Alsmadi 2025-06-29 20:24:07 Pacific Daylight Time CONTRACTOR PRE-QUALIFICATION QUESTIONNAIRE 1. How many times in the last five years has your firm been assessed and paid liquidated damages after completion of a project under a ©1 2 3 4 5+ construction contract with either a public or private owner? (Explain on a separate sheet.Identify all such projects by owner,owner's address,date of completion of the project,amount of liquidated damages assessed and all other information necessary to fully explain the assessment of liquidated damages.) 2. How many times in the last five years has your firm made any claim against a project owner concerning work on a project or payment for a 01 2 3 4 5+ contract and filed that claim in court or arbitration? (Explain on a separate sheet. Identify the claim(s)by providing the project name,date of the claim,name of the entity(or entities)against whom the claim was filed,a brief description of the nature of the claim,the court in which the case was filed and a brief description of the status of the claim[e.g."pending"or if resolved,a brief description of the resolutionl.l 3. How many times in the last five years has CalOSHA cited and assessed penalties against your firm for any "serious,""willful"or 01 2 3 4 5+ violation(s)or the federal Occupational Safety and Health Administration cited and assessed penalties against your firm for violation(s)of safety or health regulations? NOTE:If you have filed an appeal of a citation,and the Occupational Safety and Health Appeals Board has not yet ruled on your appeal,you need not include information about it. 4. How many times during the last five years,has your firm been required to pay back wages and/or penalties related to tate or federal prevailing wage O1 2 3 4 5+ laws for work performed by your firm? (Explain on a separate sheet.Identify the claim(s)by providing the project name,date of the claim,name of the claimant,a brief description of the nature of the claim,the court in which the case was filed and a brief description of the status of the claim[e.g. "pending"or,if resolved,a brief description of the resolution].) C-13 t��-ATA Document A310TM _ 2010 Bid BondBid Bond No: N/A CONTRACTOR: SURETY: ('game.legal status and address) (Nance, legal status and principal place We R Builders of business) 1608 Palmyrita Ave Merchants Bonding Company(Mutual) Riverside,CA 92507 P.O.Box 14498 This document has important legal consequences.Consultation with Des Moines.IA 50266 OWNER: an attorney is encouraged with respect to its completion or (Name.legal status and address) modification City of Huntington Beach 2000 Main Street, Huntington Beach,CA 92648 Any singular reference to Contractor Surety.Owner or BOND AMOUNT:Ten Percent of the Total Amount Bid(10%of Total Bid Amount) other party shall be considered plural where applicable PROJECT: ('fame, location or address, and Project number if any) Hartlund Water Main Replacement Project Number,if any: 1735 The Contractor and Surety are bound to the Owner in the amount set forth above,for the payment of which the Contractor and Surety bind themselves,their heirs,executors,administrators,successors and assigns,jointly and severally,as provided herein.The conditions of this Bond are such that if the Owner accepts the hid of the Contractor within the time specified in the hid documents,or within such time period as may be agreed to by the Owner and Contractor,and the Contractor either(I)enters into a contract with the Owner in accordance with the terms of such bid,and gives such bond or bonds as may be specified in the bidding or Contract Documents,with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner,for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof;or(2)pays to the Owner the difference,not to exceed the amount of this Bond,between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid,then this obligation shall be null and void,otherwise to remain in full force and effect.The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid.Waiver of notice by the Surety shall not apply to any extension exceeding sixty(60)days in the aggregate beyond the time for acceptance of bids specified in the bid documents,and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty(60)days. If this Bond is issued in connection with a subcontractor's bid to a Contractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. Signed and sealed this 20th day of February 2026 We R B litters (Prig ipal) (Seal) (Witness) — 1 (Title) /t5: (Seaaa' VIVOLSUUN Merck is Bonding Company(Mutual) (Sureo (Seal) 7' ecs) (Title)Thao Luu Attorney-in-Fact AIA Document A310'-2010.Copyright C 1963.1970 and 2010 by The American Institute of Architects.All rights reserved.WARNING:This Ale Irtit. Document is protected by U.S Copyright Law and International Treaties.Unauthorized reproduction or distribution of this AtA'Document,or any portion of it,may result in severe civil and criminal penalties,and will be prosecuted to the maximum extent poseibie under the law this document was created on 01/27/2012 07.23.12 under the terms of AIA Documents-on-DemandTM order no 2008397483 and is not for resale This document is licensed by the American Institute of Architects for one-time use only,and may not he reproduced nrio,to its cmmnletion nx„,, CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189 r3,c'i t3~3.t.z:.`E& "'3 Nt,;,19,3c-t.-g-4,,,,in '₹ =` �3,4N '�.5,4- ir =_'b. .'Ste..:*c•- biikw .i..1,..4s`. * A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ` l r County of � .� \�lc. �d2- 1 J} /� On rE \J'C��-1 g-t4 me, L—Cl" .c s R\Svwe&\/ Iv tAa�Cy Qul 3.c Date Here Insert Name and Title of the Officer J personally appeared N.zCAi- AsS1lMC Li. Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s)is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s)acted,executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing y?- LAMEES ALSMADI ��i. NotaryPublic-California paragraph is true and correct. ---.mss__ ,.S�A,_ Los Angeles County v.' %�r' commission 2168697 i WITNESS my hand and official seal. _tru-—_ My Comm.Expires Oct 28,2027 Signature \-+a �S Q..1 SkAdk Ploce Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑Corporate Officer—Title(s): O Corporate Officer—Title(s): ❑ Partner— 0 Limited ❑ General 0 Partner— 0 Limited 0 General ❑ Individual ❑ Attorney in Fact O Individual O Attorney in Fact ❑ Trustee O Guardian or Conservator O Trustee O Guardian or Conservator ❑ Other: ❑ Other: Signer is Representing: Signer is Representing: O2019 National Notary Association CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange On FEB 1E' 0 2026 before me, Irene Luong , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Thao Luu Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) IRENE LUONG acted, executed the instrument. Notary Public-California I certify under PENALTY OF PERJURY under the laws of orange county the S o of California that the foregoing is true I 'V. 9 9 �:+~1�' Commission M 2541818 — My Comm.Expires Dec 1 i,2029E and correct. ,f Witness my hand a doff ial sea. Signature Place Notary Seal Above Signature Notary Public uong OPTIONAL , Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: . Signer(s)Other Than Named Above: Capacity(ies)Claimed by Signer(s) Signer's Name: _____ Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title($): ❑ Corporate Officer —Title(S): ❑ Partner ❑Limited ❑General ❑ Partner ❑Limited❑General ❑ Attorney in Fact RIGHT THUP.1f3PRINT ❑ Attorney in Fact RIGHT THUMBPRINT ❑ Trustee OF SIGNER ❑ Trustee OF SIGNER ❑ Guardian or Conservator Top of thumb here ❑ Guardian or Conservator Top of thumb here ❑ Other. ❑ Other: Signer is Representing: Signer is Representing. MERCHANTS\ BONDING COMPANY,. POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa,d/b/a Merchants National Indemnity Company(in California only)(herein collectively called the "Companies")do hereby make,constitute and appoint,individually, Alexander R Holsheimer;Christine Woolford;Danielle Hanson;Emilie George;Irene Luong;James W Moilanen;P Austin Neff;Thao Luu;Yung T Mullidc their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attorney is granted and Is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding,Inc.,on October 16,2015. 'The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys-in-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof." 'The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,it is agreed that the power and authority hereby given to the Attorney-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this instrument to be signed and sealed this 2nd day of July ' 2024 • .•••�t10 NA •• 6 •••. MERCHANTS BONDING COMPANY(MUTUAL) • Q�� .004". MERCHANTS NATIONAL BONDING,INC. •••• ••OltPOR��G•: ;O•• sPO4 0). ' . d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY SCI 4j-•Z t • :c.) -. -o- Gtr: :� __� _o_ "31 : j`: 2003 ;,.A �y* 1933 ; By J • N.N• 7ce7/4, Q. v1 • 6�ly i'•.t\�.• President STATE OF IOWA .•••• ;., 'i:' ••••: ••••••••• COUNTY OF DALLAS ss. On this 2nd day of July 2024 , before me appeared Larry Taylor,to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies;and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. APVUAL , Penni Miller , z - Commission Number 787952 • .11—•-i • My Commission Expires IOWA January 20,2027 ,.Q(dotesy.9db (Expiration of notary's commission does not invalidate this instrument) I,William Warner,Jr.,Secretary of MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC.,do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which is still in full force and effect and has not been amended or revoked. In Witness Whereof,I have hereunto set my hand and affixed the seal of the Companies on this 20th day of February ,2026 . •••�P.i'0Ngl °•• :a.�1G o• •a 9•• •Z • 2003 '� •a 1933. ' ' Secretary • POA 0018(1/24) "" No. 2482-8 STATE OF CALIFORNIA DEPARTMENT OF INSURANCE SAN FRANCISCO Amended Certificate of Authority THIS IS TO CERTIFY that,pursuant to the Insurance Code of the State of California, Merchants Bonding Company(Mutual) of Iowa, organized under the laws of Iowa, subject to its Articles of Incorporation or other fundamental organizational documents,is hereby authorized to transact within this State,subject to all provisions ofthis Certificate, the following classes of insurance: Surety,Liability,and Miscellaneous as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all,and not in violation of any,of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable,and as such laws and requirements now are,or may hereafter be changed or amended. IN WITNESS WHEREOF, effective as of the 1"day of October, 2015,I have hereunto set my hand and caused my official seal to be affixed this 1"day of October, 2015 • ?:• 4t' . ., .,. Dave Jones Insurance Commissioner /3,v Valerie Sarfaty for Nettie Iloge Chief Deputy NOTICE: Qualification with the Secretary of State must be accomplished as required by the California Corporations Code promptly atter issuance of this Certificate of Authority. Failure to do so will be a violation of Insurance Code section 701 and will be grounds for revoking this Certificate of Authority pursuant to the covenants made in the application therefor and the conditions contained herein. Bond No. 101492266 Premium listed on Executed in Duplicate Performance Bond PAYMENT BOND (LABOR AND MATERIAL) KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, City of Huntington Beach (hereafter referred to as "City") has awarded to We R Builders 1608 PALMYRITA AVE RIVERSIDE, CA 92507 (Contractor's Name and Address) (hereafter referred to as"Principal"), a contract("Contract")for the work described as follows: Hartlund Lane Water Main Replacement, CC1735 (Project Title) WHEREAS, Principal is required under the terms of the Contract and the California Civil Code to furnish a bond to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law, by a duly admitted surety insurer under the laws of the State of California (hereinafter referred to as "Surety"); and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and has provided proof of sufficient bonding limitation, as shown in said circular to provide bonds in the amount required by said Contract; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's, or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety is registered and listed with the California Department of Insurance, NOW,THEREFORE, we, the undersigned, as Principal, and Merchants Bonding Company (Mutual) P.O. Box 14498 Des Moines, IA 50306-3498 (Surety's Name and Address) as Surety, are held and firmly bound unto City in the penal sum of Seven Hundred Twenty Nine Thousand Seven Hundred Seventy and 00/100 Dollars ($ 729,770.00 ), this amount being not less than one hundred percent (100%) of the total price set forth in the Contract, in lawful money of the United States of America, for the payment of which sum, well and truly to be made, we bind ourselves, and each of our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the Principal, his, her, or its heirs, executors, administrators, successors or assigns, or subcontractors shall fail to pay any of the persons named in Section 3181 of the California Civil Code("Claimants")for all labor, materials or services used or reasonably required for use in performance of the work described in the Contract, or any amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such Claimant, or prevailing wages due and penalties incurred pursuant to Sections 1774, 1775, 1813 or 1815 of the Labor Code, or any amounts required to be deducted,withheld and paid over to the Employment Development Department from the wages of employees of the Principal and Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to the work or labor performed under the Contract, Surety will pay for the same, in an amount not exceeding the penal sum specified in this bond; otherwise,this obligation shall be null and void. This bond shall inure to the benefit of any of the persons named in Section 3181 of the California Civil Code so as to give a right of action to such persons or their assigns. In case any action is brought upon this bond, Surety further agrees to pay all court costs and a reasonable attorney's fee in an amount fixed by the court. 15-4584/117357 Page 1 of 2 Surety stipulates and agrees, for value received, that no change, extension of time, alteration, addition or modification to the terms of the Contract,or any contract document or any work to be performed thereunder, whether made after notice or not, shall in any way affect, impair or release the obligations of Surety under this bond. Surety hereby waives notice of any such change, extension of time, alteration, addition, or modification to the terms of the Contract,the contract documents or the work thereunder. Surety also waives the provisions of California Civil Code§§2845 and 2849. IN WITNESS WHEREOF, each party represents and warrants that this instrument has been duly executed by Principal and Surety, on the date set forth below, that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond, waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: March 12, 2026 ATTEST We R Builders [Corporate Seal] (Principal Name) By: Name: 4 4L' Title: mss;ck41 .5,O c07 .-7-11(. (0, j ATTEST Merchants Bonding Company (Mutual) [Corporate Seal] (Surety Name) By: aLketitil Name: Thao Luu, Attorney-in-Fact (Signature of Attorney-in-Fact for Surety) 515-243-8171 (Attach Attorney-in-Fact Certificate) (Area Code&Telephone Number for Surety) APPROVED A1S TO FORM: 7 By: i �. . Michael J. Vigliotta, City Attorney Note: This bond must be executed in duplicate and dated, all signatures must be notarized, and evidence of the authority of any person signing as attorney-in-fact must be attached. 15-4584/117357 Page 2 of 2 PAYMENT BOND CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California \ 1 County of I.‘JZS� a� J} On V\ --tc.Se\V-b, PZUZL before me, \-SC-v•/R-2S k‘n/\CC\' / IV( AC c l\O\ C Date Here Insert Name and Title or the Officer personally appeared \-%L-2c,c--- `^���� Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing LAMEESALSMADI paragraph is true and correct. Notary Public-CelHonnla i �3, Los Angeles County _J J Commission l 2468697 [ WITNESS my hand and official seal. 1 My Comm.Expires Oct 28,20271 Signature 1._ -‘•^•^&.--e—S ‘'..\AC ---‘ Place Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document:r?a- Q 1' (--- oAr\A_ Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): 0 Corporate Officer—Title(s): ❑ Partner— 0 Limited ❑ General 0 Partner— ❑ Limited 0 General ❑ Individual ❑ Attorney in Fact ❑ Individual 0 Attorney in Fact ❑ Trustee ❑ Guardian or Conservator 0 Trustee 0 Guardian or Conservator O Other: 0 Other: Signer is Representing: Signer is Representing: ©2019 National Notary Association CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange MAR 12 2026 On before me, Irene Luong , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Thao Luu Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. jRENELuoNG I Notary Public California I certify under PENALTY OF PERJURY under the laws of orange County the State of California that the foregoing paragraph is true Commission#2541868 and correct. cy Comm.Expires Dec 16,2029 Witness my hand and .ffici:I seal Signature Place Notary Seal Above Signature of No .lic lr:1 e Luon• OPTIONAL Though the information below is not required by law it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies)Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): LI Corporate Officer —Title(s): ❑ Partner LI Limited ❑General ❑ Partner ❑Limited❑ General ❑ Attorney in Fact -IGHTTHUM:•-lNT ❑ Attorney in Fact RIGHT THUMBPRINT ❑ Trustee IF SIGNS' ❑ Trustee OF SIGNER ❑ Guardian or Conservator Top of thumb here ❑ Guardian or Conservator Top of thumb here ❑ Other: ❑ Other: Signer is Representing: Signer is Representing: MERCHAN117%\ BONDING COMPANY,. POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa,d/b/a Merchants National Indemnity Company(in California only)(herein collectively called the "Companies")do hereby make,constitute and appoint,individually, Alexander R Holsheimer;Christine Woolford;Danielle Hanson;Emilie George; Irene Luong;James W Moilanen;P Austin Neff;Thao Luu;Yung T Mullick their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attorney is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding, Inc.,on October 16,2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys-in-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,it is agreed that the power and authority hereby given to the Attorney-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this instrument to be signed and sealed this 2nd day of July , 2024 • .•`""""••. .••'-'•• MERCHANTS BONDING COMPANY(MUTUAL) •.•`P(,ON4 ••.• • •.��NG C04/,'.• MERCHANTS NATIONAL BONDING, INC. G0RP0/i▪ i O•�cokP0q'.'s' d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY :z:2 _O_ -.01 : : o r*.. � v': 2003 � ; •y• 1933 �' By . ." /"97/7 J�•:• • •• dl(i ' • \1 •' President STATE OF IOWA •. 17 • •• COUNTY OF DALLAS ss. ............. On this 2nd day of July 2024 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. ?JAC Penni Miller ., v Commission Number 787952 • :,MSS • My Commission Expires IOWA January 20,2027 �Nota bl (Expiration of notary's commission does not invalidate this instrument) I,William Warner,Jr.,Secretary of MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC.,do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which is still in full force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 12th day of March ,2026 . .••••Pt10•NA<•••. .••O\N.... 0, ••. d€‘7-40•2-6/7.0.000a. :%'• 2003 Q. 1933 c Secretary O)•. •*" .s". 'v. 10).• • •• POA 0018 (1/24) ••••"' "''•• Bond premium is subject to change based on the final contract amount Bond No. 101492266 Executed in Duplicate Premium: $18,244.00 PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, City of Huntington Beach (hereafter referred to as"City") has, by written agreement dated , 2026 , entered into a contract with We R Builders 1608 PALMYRITA AVE RIVERSIDE, CA 92507 (Contractor's Name and Address) (hereafter referred to as"Principal")for performance of the work described as follows: Hartlund Lane Water Main Replacement, CC1735 (Project Title) WHEREAS, said contract, and all documents referenced therein (hereinafter collectively "Contract"), are incorporated herein by this reference made a part hereof as though set forth herein in full; and Said Principal is required under the terms of the Contract to furnish a bond guaranteeing the prompt, full and faithful performance of said Contract, by a duly admitted surety insurer under the laws of the State of California (hereinafter referred to as "Surety"); and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and has provided proof of sufficient bonding limitations as shown in said circular to provide bonds in the amount required by said Contract; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's, or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety is registered and listed with the California Department of Insurance, NOW,THEREFORE, we, the undersigned, as Principal, and Merchants Bonding Company (Mutual) P.O. Box 14498 Des Moines, IA 50306-3498 (Surety's Name and Address) as Surety, are held and firmly bound unto City in the penal sum of Seven Hundred Twenty Nine Thousand Seven Hundred Seventy and 00/100 Dollars ($ 729,770.00 ), this amount being not less than one hundred percent of the price set forth in the Contract, in lawful money of the United States, for the payment of which sum,well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors,jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the Principal shall promptly, fully and faithfully perform each and all of the covenants, obligations and things to be done and performed by the Principal in strict accordance with the terms of the Contract as said contract may be altered, amended or modified from time to time; and if the Principal shall indemnify and save harmless City and all of City's officers, agents and employees (hereinafter collectively referred to as "Obligees") from any and all losses, liability and damages, claims, judgments, stop notices, fees and costs of every description, whether imposed by law or in equity, which may be incurred by the Obligees by reason of the failure or default on the part of the Principal in the performance of any or all of the terms or the obligations of the Contract, including all alterations, amendments and modifications thereto, and any warranties or guarantees required thereunder, then this obligation shall be void; otherwise, it shall be and shall remain in full force and effect. Surety stipulates and agrees, for value received, that no adjustment of the time or price in the Contract or any alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, shall in any way affect, limit, restrict, impair or release the obligations of the Surety under this Bond. Surety waives notice of any adjustment of contract or contract price, and any other alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, and agrees to automatically adjust the penal sum of this Bond to reflect such adjustments, alterations, changes, deletions, additions or other modifications. Surety agrees to provide written confirmation of such adjustments in the penal sum to City on not less than a quarterly basis. Surety also waives the provisions of Civil Code§§2845 and 2849. 15-4584/117174 Page 1 of 2 Bond No. 101492266 The obligations of this Bond shall survive the completion of the work described in the Contract as to all obligations and liabilities of the Principal which survive completion of the work. IN WITNESS WHEREOF, each party represents and warrants that this instrument has been duly executed by Principal and Surety, on the date set forth below, that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond, waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: March 12, 2026 ATTEST We R Builders [Corporate Seal] (Principal Name) By: Name: 4&vvc,,,{; Title: ' .c t4 Se c 4"11 ATTEST Merchants Bonding Company (Mutual) [Corporate Seal] (Surety Name) By: Name: Thao Luu, Attorney-in-Fact (Signature of Attorney-in-Fact for Surety) 515-243-8171 (Attach Attorney-in-Fact Certificate) (Area Code&Telephone Number for Surety) APPROVED PAS TO FORM BY Michael J.Vigliotta, City Attorney NOTES:This bond must be executed in duplicate and dated, all signatures must be notarized,and evidence of the authority of any person signing as attorney-in-fact must be attached. 15-4584/117174 Page 2 of 2 PERFORMANCE BOND CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California 1 County of `Kv 5k �e-- J} On •rCv\\3 t 2OZS- before me,\.--C-hl�--2S N SNA\C- - /NtID • ?-►.\?Vc Date Here Insert Name and Title of the Officer personally appeared \-- e--2.G•C ��S`^^C�1/4. Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing LAMEESALSMADI paragraph is true and correct. Notary Public-Calttontla Los Angeles County WITNESS my hand and official seal. 7 Commission#2468697 1 My Comm.Expires Oct 28,1027 Signature 1--CN^I\-'e—e% '-•-\•5\1•11/4-9-- ---‘: Place Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Docume lran Title or Type of Document: c'r—oCV\/&C-�S-Si...... c:—\ u`tiA_ \�' C3 Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): 0 Corporate Officer —Title(s): ❑ Partner— 0 Limited 0 General 0 Partner— ❑ Limited 0 General ❑ Individual ❑ Attorney in Fact 0 Individual 0 Attorney in Fact O Trustee ❑ Guardian or Conservator 0 Trustee ❑ Guardian or Conservator ❑ Other: ❑ Other: Signer is Representing: Signer is Representing: ©2019 National Notary Association CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange On MAR 1 2 2026 before me, Irene Luong , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Thao Luu Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) �o. IRENE LUONG acted, executed the instrument. : n. Notary Public-California Orange County 0I certify under PENALTY OF PERJURY under the laws of Commission#2541868 the State of California that the foregoing paragraph is true <-,,Fo*+ My Comm.Expires Dec 16,2029 and correct. Witness my hand a d offi al seal Signature Place Notary Seal Above Signature of otary Public I raI e Luong OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies)Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): ❑ Corporate Officer —Title(s): ❑ Partner ❑Limited ❑General ❑ Partner ❑Limited❑General ❑ Attorney in Fact RIGHT THUMBPRINT ❑ Attorney in Fact RIGHT THUMBPRINT ❑ Trustee OF SIGNER ❑ Trustee OF SIGNER ❑ Guardian or Conservator Top of thumb here ❑ Guardian or Conservator Top of thumb here ❑ Other: ❑ Other: Signer is Representing: Signer is Representing: MERCHANTS BONDING COMPANYTU POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa,d/b/a Merchants National Indemnity Company(in California only)(herein collectively called the "Companies")do hereby make,constitute and appoint,individually, Alexander R Holsheimer;Christine Woolford; Danielle Hanson;Emilie George;Irene Luong;James W Moilanen;P Austin Neff;Thao Luu;Yung T Mullick their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attorney is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding,Inc.,on October 16,2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys-in-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,it is agreed that the power and authority hereby given to the Attorney-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this instrument to be signed and sealed this 2nd day of July , 2024 • ................... .• - •• ��\.. Coo, MERCHANTS NATIONAL BONDING,INC. :CO•VOSPOR'4.'• • Q?*.Coi1P0,94.4y� d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY j 2003 4) •l• 1933• c By • • 6 \ . . �.•�' •.......•.;��. . .��••�•'K\ . Presidenrel‘fPt STATE OF IOWA .. w •. •. •. COUNTY OF DALLAS ss. On this 2nd day of July 2024 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies;and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. `pRiA�r Penni Miller ~ , o v Commission Number 787952z r- ` • Ira; • My Commission Expires lOWP January 20,2027 ! Nota bl (Expiration of notary's commission does not invalidate this instrument) I,William Warner,Jr.,Secretary of MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC.,do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which is still in full force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 12th day of March ,2026 :2 _ _ -o- rt" €/t0/010"-e'" • 2003 ;4) •6•• 1933 ;• Secretary • r •••.4•••• POA 0018 (1/24) CONTRACTOR'S SWORN STATEMENT AND WARRANTY REGARDING CONTINUING INSURANCE OBLIGATIONS FROM: We R Builders, Inc. PROJECT: Hartlund Lane Water Main (Contractor Name) Replacement, CC1735 1608 Palmyrita Avenue (Street Address) Riverside, CA 92507 (City, State, Zip Code) TO: CITY OF HUNTINGTON BEACH DECLARATION Attached hereto is a true and correct copy of the current Certificate of Insurance and Additional Insured Endorsement CG 2010 1185, which Certificate complies with the insurance requirements of the Contract by and between the City of Huntington Beach ("City") and the above-named Contractor ("Contractor")for the above-described project ("Project"). I declare under penalty of perjury under the laws of the State of California that the above statement is true and correct. Signed on March 13 , 20 26 , at Riverside, CA (Date) (City, State) (Signature f Individual Who is Making Declaration) WARRANTY Contractor hereby warrants and agrees to maintain Products and Complete Operations Insurance in compliance with the insurance requirements of the Contract for the Project. Said insurance shall be maintained through and until the expiration of all Warranties provided by the Contractor. Said insurance shall contain Additional Insured Endorsement CG 2010 1185, naming the City as an additional insured. Contractor shall supply to the City, on at least an annual basis, a Certificate of Insurance and the aforementioned Endorsement evidencing continued coverage which meets the Contract requirements. Signed on March 13 , 20 26 , at Riverside, CA (Date) (City, State) CONTRACTOR: Name: We R Builders, Inc. By: Name: Nezar madi Title: Presid nt, Secretary& Treasurer A ® CERTIFICATE OF LIABILITY INSURANCE DATE(Mkt TOD(YYYY) 4/13/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the pollcy(les)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsernent(s). PRODUCER CONTACT Michael Benoit NAME: Pacific United Insurance Services P/ No Eat); (619)274-8144 I P No): (6191274-8143 7851 Mission Center Court EMAIL Michael(Ipacificunitedins.com ADDRESS: Suite 322 INSURER(S)AFFORDING COVERAGE NAIC/ San Diego CA 92108 INSURER A:CUmis Specialty Insurance Company 12758 INSURED INSURER B:Infinity Select Insurance Company 20260 WE B. BUILDERS INsuRERc:Kinsale Insurance Company 38920 1608 Palmyrita Ave. INSURER D:State Compensation Insurance Fund 35076 INSURER E:Navigators Insurance Company 42307 Riverside CA 92507 INSURERF:Mt. Hawley Insurance Company 37974 COVERAGES CERTIFICATE NUMBER:25-26 All Lines Master REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWTHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TOALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUER POLICY EFF POLICY EXP LIMITS LTR INSR MD POLICY NUMBER (t.IM/DDIYYYY) (MM/DD/YYYY) X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED 100,000 A CLAIMS-MADE X OCCUR PREMISES(Ea nr•nerence) $ X Y (/150001390 11/10/2025 11/10/2026 MEO EXP(Any one person) S 5,000 PERSONAL dADV INJURY $ 1,000,000 GENL AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE S 2,000,000 X POUCY PRO- JECT LOC PRODUCTS-COMP/OPAGG $ 2,000,000 OTHER S AUTOMOBILE LIADILITY COMBINED SINGLE LIMIT S 1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) 5 B ALL ONNED —^SCHEDULED AUTOS AUTOS 50015171101 02/23/2026 08/23/2026 BODILY INJURY(Per accident) S NON-OARED PROPERTY DAMAGE $ HIRED AUTOS _ AUTOS (Per accident) S x UMBRELLALIAB X OCCUR EACH OCCURRENCE S 2,000,000 EXCESSUAB c CLAIMS MADE AGGREGATE S 2,000,000 DED I I RETENTION$ 0100410694-0 11/10/2025 11/10/2026 $ WORKERS COMPENSATION X I STA UTE I I 0RH AND EMPLOYERS'LIABILITY Y I N ANY PROPRIETOR/PARTNERiEXECUTNE NIA F L.EACH ACCIDENT S 1,000,000 OFFICER/MEMBER EXCLUDED? (Y D (Mandatory In NH) y 9348101-25 10/23/2025 10/23/2026 E L.DISEASE-EA EMPLOYEE S 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E L.DISEASE-POLICY LIMIT S 1,000,000 E Inland Marine 04-I(4059249 8/20/2025 8/20/2026 Schell Equ'ymen(-LI9htio Med um $70,000 F Pollution Liability EGIA013656 10/23/2025 10/23/2026 EacI,Po'uton lacrdenUAoqregaIe $1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more spaco Is required) City of Huntington Beach, its officers, elected or appointed officials, employees, agents and volunt rs is named as additional insured as required per the attached endorsement. APPROVED AS TO FOR By: MICHAEL J.VIGLIOTTA CITY ATTORNEY CERTIFICATE HOLDER CANCELLATION `- `IUD I I INC 71 UN I EACH SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Huntington Beach THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 2000 Main Street Huntington Beach, CA 92648 AUTHORIZED REPRESENTATIVE Michael Benoit/PHOEBE AC.(.ccbn\Y I ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD INS025(201401) ADDITIONAL COVERAGES Ref# Description Coverage Code Form No. Edition Date Business Auto Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 [Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium OFADTLCV Copyright 2001,AMS Services,Inc. POLICY NUMBER: WIS0001390 COMMERCIAL GENERAL LIABILITY CG 20 10 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s)Of Covered Operations City of Huntington Beach, its officers, elected or Project name: Hartlund Lane Water Main appointed officials, employees, agents, and volunteers Replacement, CC1735 2000 Main Street Huntington Beach, CA 92648 Information required to complete this Schedule, if not shown above,will be shown in the Declarations. A. Section II -Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following additional organization(s) shown in the Schedule, but only exclusions apply: with respect to liability for"bodily injury", "property This insurance does not apply to "bodily injury" or damage" or "personal and advertising injury" "property damage"occurring after: caused, in whole or in part, by: 1.Your acts or omissions; or 1.All work, including materials, parts or equipment furnished in connection with such 2. The acts or omissions of those acting on your work, on the project(other than service, behalf; maintenance or repairs)to be performed by or in the performance of your ongoing operations for on behalf of the additional insured(s) at the the additional insured(s) at the location(s) location of the covered operations has been designated above. completed;or However: 2. That portion of"your work" out of which the injury or damage arises has been put to its 1.The insurance afforded to such additional intended use by any person or organization insured only applies to the extent permitted by other than another contractor or subcontractor law;and engaged in performing operations for a 2. If coverage provided to the additional insured is principal as a part of the same project. required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 10 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 2 C.With respect to the insurance afforded to these 2. Available under the applicable limits of additional insureds, the following is added to insurance; Section III-Limits Of Insurance: whichever is less. If coverage provided to the additional insured is This endorsement shall not increase the required by a contract or agreement, the most we applicable limits of insurance. will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or Page 2 of 2 ©Insurance Services Office, Inc.,2018 CG 20 10 12 19 POLICY NUMBER: W1S0001390 COMMERCIAL GENERAL LIABILITY CG 20 37 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location And Description Of Completed Operations City of Huntington Beach, its officers, elected or Project name: Hartlund Lane Water Main Replacement, appointed officials, employees, agents, and volunteers CC1735 2000 Main Street Huntington Beach, CA 92648 Information required to complete this Schedule, if not shown above,will be shown in the Declarations. A. Section II -Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following is added to organization(s) shown in the Schedule, but only Section III -Limits Of Insurance: with respect to liability for "bodily injury" or If coverage provided to the additional insured is "property damage" caused, in whole or in part, by required by a contract or agreement, the most we "your work" at the location designated and will pay on behalf of the additional insured is the described in the Schedule of this endorsement amount of insurance: performed for that additional insured and included in the"products-completed operations hazard". 1. Required by the contract or agreement; or However: 2. Available under the applicable limits of insurance; 1. The insurance afforded to such additional insured only applies to the extent permitted by whichever is less. law; and This endorsement shall not increase the 2. If coverage provided to the additional insured is applicable limits of insurance. required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 37 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 1 POLICY NUMBER:WI50001390 COMMERCIAL GENERAL LIABILITY CG 20 01 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NONCONTRIBUTORY - OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance (2) You have agreed in writing in a contract or Condition and supersedes any provision to the agreement that this insurance would be contrary: primary and would not seek contribution Primary And Noncontributory Insurance from any other insurance available to the additional insured. This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and CG 20 01 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 1 POLICY NUMBER: WIS0001390 COMMERCIAL GENERAL LIABILITY G0270 12 23 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CHANGES - CANCELLATION AND NONRENEWAL This endorsement modifies insurance provided under the following: All Coverage Parts included in this policy are subject to the following conditions. A. Cancellation B. Nonrenewal 1. The first Named Insured shown in the 1. If we decide not to renew this Policy,we will Declarations may cancel this policy by mail or deliver to the first Named Insured mailing or delivering to us advance written shown in the Declarations written notice of notice of cancellation. the nonrenewal not less than 30 days before 2. We may cancel this policy by mailing or the expiration date. delivering to the first Named Insured written 2. If notice is mailed, proof of mailing will be notice of cancellation at least: sufficient proof of notice. a. 10 days before the effective date of cancellation if we cancel for nonpayment of premium;or b. 30 days before the effective date of cancellation if we cancel for any other reason. 3. We will mail or deliver our notice to the first Named Insured's last mailing address known to us. 4. Notice of cancellation will state the effective date of cancellation. The policy period will end on that date. 5. If this policy is cancelled,we will send the first Named Insured any premium refund due. If we cancel, the refund will be pro rata. If the first Named Insured cancels,the refund may be less than pro rata. However, in no event shall we retain less than the Minimum Earned Premium at Inception. The cancellation will be effective even if we have not made or offered a refund. 6. If notice is mailed, proof of mailing will be sufficient proof of notice. ALL OTHER TERMS AND CONDITIONS OF THIS POLICY REMAIN UNCHANGED. ©2023 WESTCAP G0270 12 23 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. Page 1 of 1 POLICY NUMBER: W1S0001390 COMMERCIAL GENERAL LIABILITY CG 25 03 05 09 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Project(s): Each Project of the insured as required by an"insured contract" Designated Construction Project General Aggregate Limit: $ 2,000,000 The combined maximum we will pay for all projects covered by Designated Construction Project Aggregate Limit is $ 5,000,000 Information required to complete this Schedule, if not shown above,will be shown in the Declarations. A. For all sums which the insured becomes legally 3. Any payments made under Coverage A for obligated to pay as damages caused by "occur- damages or under Coverage C for medical rences" under Section I - Coverage A, and for all expenses shall reduce the Designated Con- medical expenses caused by accidents under struction Project General Aggregate Limit for Section I - Coverage C, which can be attributed that designated construction project. Such only to ongoing operations at a single designated payments shall not reduce the General Ag- construction project shown in the Schedule gregate Limit shown in the Declarations nor above: shall they reduce any other Designated Con- 1.A separate Designated Construction Project struction Project General Aggregate Limit for General Aggregate Limit applies to each des- any other designated construction project ignated construction project, and that limit is shown in the Schedule above. equal to the amount of the General Aggregate 4. The limits shown in the Declarations for Each Limit shown in the Declarations. Occurrence, Damage To Premises Rented To 2.The Designated Construction Project General You and Medical Expense continue to apply. Aggregate Limit is the most we will pay for the However, instead of being subject to the sum of all damages under Coverage A, ex- General Aggregate Limit shown in the Decla- cept damages because of"bodily injury"or rations, such limits will be subject to the appli "property damage" included in the"products- cable Designated Construction Project Gen- completed operations hazard", and for medi- eral Aggregate Limit. cal expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or"suits"brought; or c.Persons or organizations making claims or bringing"suits". CG 25 03 05 09 ©Insurance Services Office, Inc., 2008 Page 1 of 2 B. For all sums which the insured becomes legally C. When coverage for liability arising out of the obligated to pay as damages caused by "occur- "products-completed operations hazard" is pro- rences" under Section I - Coverage A, and for all vided, any payments for damages because of medical expenses caused by accidents under "bodily injury"or"property damage" included in Section I - Coverage C, which cannot be at- the "products-completed operations hazard" will tributed only to ongoing operations at a single reduce the Products-completed Operations Ag- designated construction project shown in the gregate Limit, and not reduce the General Ag- Schedule above: gregate Limit nor the Designated Construction 1.Any payments made under Coverage A for Project General Aggregate Limit. damages or under Coverage C for medical D. If the applicable designated construction project expenses shall reduce the amount available has been abandoned, delayed, or abandoned under the General Aggregate Limit or the and then restarted, or if the authorized contract- Products-completed Operations Aggregate ing parties deviate from plans, blueprints,de- Limit,whichever is applicable; and signs, specifications or timetables, the project will 2. Such payments shall not reduce any Desig- still be deemed to be the same construction pro- nated Construction Project General Aggre- ject. gate Limit. E. The provisions of Section III- Limits Of Insur- ance not otherwise modified by this endorsement shall continue to apply as stipulated. Page 2 of 2 ©Insurance Services Office, Inc.,2008 CG 25 03 05 09 COMMERCIAL GENERAL LIABILITY CG 20 33 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN A WRITTEN CONSTRUCTION AGREEMENT WITH YOU This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART A. Section II -- Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured any person or additional insureds, the following additional organization for whom you are performing exclusions apply: operations when you and such person or This insurance does not apply to: organization have agreed in writing in a contract or agreement that such person or organization be 1. "Bodily injury", "property damage" or"personal added as an additional insured on your policy. and advertising injury" arising out of the Such person or organization is an additional rendering of, or the failure to render, any insured only with respect to liability for "bodily professional architectural, engineering or injury", "property damage" or "personal and surveying services, including: advertising injury"caused, in whole or in part, by: a. The preparing, approving, or failing to 1. Your acts or omissions; or prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, 2. The acts or omissions of those acting on your change orders or drawings and behalf; specifications; or in the performance of your ongoing operations for b. Supervisory, inspection, architectural or the additional insured. engineering activities. However, the insurance afforded to such This exclusion applies even if the claims additional insured: against any insured allege negligence or other 1. Only applies to the extent permitted by law; wrongdoing in the supervision, hiring, and employment,training or monitoring of others by 2. Will not be broader than that which you are that insured, if the "occurrence" which caused required by the contract or agreement to the "bodily injury" or"property damage", or the provide for such additional insured. offense which caused the "personal and advertising injury", involved the rendering of or A person's or organization's status as an the failure to render any professional additional insured under this endorsement ends architectural, engineering or surveying when your operations for that additional insured services. are completed. CG 20 33 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 2 2. "Bodily injury" or "property damage" occurring C. With respect to the insurance afforded to these after: additional insureds, the following is added to a. All work, including materials, parts or Section Ill—Limits Of Insurance: equipment furnished in connection with The most we will pay on behalf of the additional such work, on the project (other than insured is the amount of insurance: service, maintenance or repairs) to be 1. Required by the contract or agreement you performed by or on behalf of the additional have entered into with the additional insured; insured(s) at the location of the covered or operations has been completed; or 2. Available under the applicable limits of b. That portion of"your work" out of which the injury or damage arises has been put to its insurance; intended use by any person or organization whichever is less. other than another contractor or This endorsement shall not increase the subcontractor engaged in performing applicable limits of insurance. operations for a principal as a part of the same project. Page 2 of 2 ©Insurance Services Office, Inc., 2018 CG 20 33 12 19 COMMERCIAL GENERAL LIABILITY CG 20 39 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN WRITTEN CONSTRUCTION AGREEMENT WITH YOU (COMPLETED OPERATIONS) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART A. Section II — Who Is An Insured is amended to 2. Supervisory, inspection, architectural or include as an additional insured any person or engineering activities. organization for whom you have performed This exclusion applies even if the claims against operations when you and such person or any insured allege negligence or other wrongdoing organization have agreed in writing in a contract or in the supervision, hiring, employment, training or agreement that such person or organization be monitoring of others by that insured, if the added as an additional insured on your policy. "occurrence" which caused the "bodily injury" or Such person or organization is an additional "property damage"involved the rendering of or the insured only with respect to liability for "bodily failure to render any professional architectural, injury"or"property damage"caused, in whole or in engineering or surveying services. part, by "your work" performed for that additional insured and included in the "products-completed C. With respect to the insurance afforded to these operations hazard". additional insureds, the following is added to Section III—Limits Of Insurance: However, the insurance afforded to such additional insured: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Only applies to the extent permitted by law; and 1. Required by the contract or agreement you 2. Will not be broader than that which you are have entered into with the additional insured; or required by the contract or agreement to provide for such additional insured. 2. Available under the applicable limits of insurance; B. With respect to the insurance afforded to these additional insureds, the following additional whichever is less. exclusion applies: This endorsement shall not increase the This insurance does not apply to: applicable limits of insurance. "Bodily injury" or"property damage" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or CG 20 39 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 1 POLICY NUMBER: W1S0001390 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: City of Huntington Beach,its officers,elected or appointed officials,employees,agents,and volunteers 2000 Main Street Huntington Beach,CA 92648 Protect name:Haglund Lane Water Main Replacement.CC1735 Information required to complete this Schedule, if not shown above,will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV-Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products- completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 ©Insurance Services Office, Inc.,2008 Page 1 of 1 POLICY NUMBER: WIS0001390 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: Blanket as required by an"insured contract" Information required to complete this Schedule, if not shown above,will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV-Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products- completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 ©Insurance Services Office, Inc., 2008 Page 1 of 1 • STATE Endorsement Agreement COMP[NSATtON I N � A A:,C:F Waiver of Subrogation FUND Blanket Basis 9348101-2025 Home Office Renewal San Francisco SD All Effective Dates are 9-45-82-45 at 12:01 AM Pacific Page 1 of 1 Standard Time or the Time Indicated at Effective October 23, 2025 at 12:01 AM Pacific Standard Time and Expiring October 23, 2026 at 12:01 AM WE R BUILDERS 3746 FOOTHILL BLVD#304 GLENDALE,CA 91214 We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the schedule. This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us. The additional premium for this endorsement shall be 2.00%of the total policy premium. Schedule Person or Organization Job Description Any person or organization for whom the Blanket Waiver of Subrogation named Insured has agreed by written contract to furnish this waiver Nothing in this endorsement shall be held to vary,alter,waive or extend any of the terms,conditions, agreements,or limitations of this policy other than as above stated.Nothing elsewhere in this policy shall be held to vary,alter,waive or limit the terms,conditions,agreements or limitations in this endorsement. Countersigned and Issued at San Francisco October 23,2025 2572 Authorized Representative President and CEO SF—END Rev.2/2025 OLD DP 217 SCHEDULE OF UNDERLYING INSURANCE Attached To and Forming Part of Policy Effective Date of Endorsement Named Insured 0100410694-0 11/10/2025 12:01AM at the Named We R Builders Insured address shown on the Declarations Additional Premium: Return Premium: $0 $0 PRIMARY INSURANCE: Policy Type:General Liability Issuing Company: CUMIS Specialty Insurance Limits of Insurance: Company Inc Policy Number: TBD Each Occurrence/Claim: $1,000,000 Policy Dates: 11/10/2025-11/10/2026 General Aggregate: $2,000,000 Coverage Form: Occurrence Products/Completed $2,000,000 Operations Aggregate: Retroactive Date: N/A Personal and Advertising Injury $1,000,000 Limit: (claims made policy only) PRIMARY INSURANCE: Policy Type:Automobile Liability Issuing Company: Infinity Select Insurance Limits of Insurance: Company Policy Number: 50015171101 Each Accident: $1,000,000 Policy Dates: 08/11/2025-02/11/2026 CAX1001 0224 Page 1 of 1 Policy Number: EGL0013658 Mt. Hawley Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL COVERAGE SCHEDULE OF ENDORSEMENTS The following is a listing of endorsements by Form Number and Title that form a part of the policy at issue: D-2FORM(01/20) State of California Non-Admitted Disclosure Notice CPL 101 03 23 Contractors Pollution Liability Coverage Form EGL 102E 09 24 Contractors Conditions Of Coverage IL-0017(11/98) Common Policy Conditions CPL 361 CM 05 23 Claims Made And Reported Asbestos And Lead Based Paint Coverage Endorsement EGL 313 06 09 Designated Contracting Services EIL 300 02 23 Crisis And Reputation Management CPL 346 03 23 Blanket Non-Owned Disposal Site Coverage Endorsement CPL 360 12 22 Enhanced Designated Contracting Services Endorsement CPL 365 08 20 Mold, Mildew And Fungus Coverage CPL 508 03 10 EIFS Exclusion EGL 360 03 20 Communicable Disease Exclusion EGL 364 12 23 Excl-Access Or Disclosure Of Confidential Or Personal And Data-Related Liab EIL 301 04 23 Exclusion -Perfluoroalkyl And Polyfluoroalkyl Substances (PFAS) RIL-099ENV(06/21) Service Of Suit And Conditions Endorsement RIL-2138A 01 21 Limited Terrorism Exclusion (Other Than Certified Acts) RIL-2145(01/15) Exclusion Of Terrorism Involving NBCR Terrorism ILF-0001(04/22) Signature Page ALL OTHER TERMS AND CONDITIONS OF THIS POLICY REMAIN UNCHANGED. RIL 100 (06/98) Page 1 of 1 Insured (1) A defect, deficiency, inadequacy, or dangerous condition in Your Product or Your Work;or (2) A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms. h. Discrimination Any Claim, Suit, or Damages, arising out of the actual or alleged discrimination by any insured on the basis of age, color, race, sex, creed, national origin, marital status, disability, or sexual orientation. Electronic Data Any Claim, Suit, Damages, Bodily Injury, Property Damage, or Corrective Action Costs arising out of the loss of, loss of use of, damage to, corruption of, inability to access,or inability to manipulate Electronic Data. As used in this exclusion, Electronic Data means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software, including systems and applications software, hard or floppy disks, CD-R0MS, tapes, drives, cells, data processing devices, or any other media which are used with electronically controlled equipment. J. Employer's Liability Any Claim, Suit, or Damages arising out of any Bodily Injury to: (1) An Employee of any Insured or any subcontractor arising out of and in the course of: (a) Employment by the insured; or (b) Performing duties related to the conduct of the insured's business; or (2) The spouse, child, parent, brother, sister, or domestic partner of that Employee as a consequence of Paragraph (1)above. This exclusion applies whether the insured may be liable as an employer or in any other capacity and to any obligation to share Damages with or repay someone else who must pay Damages because of the injury. This exclusion does not apply to liability assumed by the insured under an Insured Contract. k. Warranties Or Guarantees Any Claim, Suit, or Damages based upon or arising out of warranties or guarantees. I. Failure To Perform The return of fees or charges for services rendered, including but not limited to the contract price, costs, or expenses incurred to perform or correct the Contracting Services that were to be performed by any insured, or expenses incurred by any insured for redesign, changes, additions, or remedies necessitated by a Claim, including the time and expense incurred by any insured in assisting in resolving the Claim. m. Fines, Penalties And Assessments Any fines, penalties, or assessments or any punitive, exemplary, or multiplied Damages arising out of or related to in the performance of Contracting Services by the insured. We shall have no duty to defend any criminal proceedings. However, where permitted by law, this exclusion does not apply to any civil fines, penalties, or assessments or any punitive, exemplary,or multiplied Damages. CPL 101 03 23 Contains copyrighted material of Insurance Services Office, Inc. Page 4 of 20 Insured Document A310TM - 2010 Bid Bond No: N/A Bid Bond CONTRACTOR: SURETY: (Name.legal status and address) (Name,legal.status and principal place We R Builders of business) 1608 Palmyrita Ave Merchants Bonding Company(Mutual) Riverside,CA 92507 P.O.Box 14498 This document has important legal consequences.Consultation with Des Moines,IA 50266 OWNER: an attorney is encouraged with (Name,legal status and address) respect to its completion or modification. City of Huntington Beach 2000 Main Street, Huntington Beach,CA 92648 Any singular reference to Contractor,Surety,Owner or BOND AMOUNT:Ten Percent of the Total Amount Bid(10%of Total Bid Amount) other party shall be considered plural where applicable, PROJECT: (?Jame, location or address,and Project number, if any) Hartlund Water Main Replacement Project Number,if any: 1735 The Contractor and Surety are bound to the Owner in the amount set forth above,for the payment of which the Contractor and Surety bind themselves,their heirs,executors,administrators,successors and assigns,jointly and severally,as provided herein.The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the time specified in the bid documents,or within such time period as may be agreed to by the Owner and Contractor,and the Contractor either(1)enters into a contract with the Owner in accordance with the terms of such bid,and gives such bond or bonds as may be specified in the bidding or Contract Documents,with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner,for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof;or(2)pays to the Owner the difference,not to exceed the amount of this Bond,between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid,then this obligation shall be null and void,otherwise to remain in full force and effect The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid. Waiver of notice by the Surety shall not apply to any extension exceeding sixty(60)days in the aggregate beyond the time for acceptance of bids specified in the bid documents,and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty(60)days. If this Bond is issued in connection with a subcontractor's bid to a Contractor,the term Contractor in this Bond shall • be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond" Signed and sealed this 20th day of February 2026 We R B ilders (Prin ipal) (Seal) (Witness) (Title) It5:dt.o'I'ISCacJary tecisu4h Merch is Bonding Company(Mutual) • (Surety) (Seal) '" ess) • (Title)Thao Luu Attorney-in-Fact AlA Document A310"—2010.Copyright C 1963,1970 and 2010 by The American Institute of Architects.All rights reserved.WARNING:This Ale Init. Document is protected by U.S.Copyright Law and International Treaties"Unauthorized reproduction or distribution of this Ale Document,or any portion of it,may result in severe civil and criminal penalties,and will be prosecuted to the maximum extent possible under the law.This document was created on 01/27/2012 07:23:12 under the terms of AIA Documents-on-DemandTM order no. 2008397483,and is not for resale.This document is licensed by The American Institute of Architects for one-time use only,end may not be reproduced prior to its romnletion.ne++tn CALIFORNIA ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California County of IRA t On Ve 'J � `C-Lkocf, a-g1Z02 before me, \_aw cs 1"� SVv &I 1 N c,,TC,cr`�e��v c Date Here Insert Name and Title of the Officer personally appeared N A'\Svv\c&( Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing LAMEES ALSMADI C .= Notary Public-California paragraph is true and correct. -i.;"-!..4-7 Los Angeles County ,isy,+!° Commission#2468697 WITNESS my hand and official seal. •"' My Comm.Expires Oct 28,2027 \ Signature \ 1 S . Place Notary Seal and/or Stamp Above Signature of Notary Public OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Corporate Officer—Title(s): ❑ Corporate Officer—Title(s): ❑ Partner— ❑ Limited ❑ General ❑ Partner— ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Individual O Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Trustee O Guardian or Conservator ❑ Other: O Other: Signer is Representing: Signer is Representing: stgativattraugriii ©2019 National Notary Association CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange On F E B 2 0 2026 before me, Irene Luong , Notary Public, Date Insert Name of Notary exactly as it appears on the official seal personally appeared Thao Luu Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) •••. IRENE LUONG acted, executed the instrument. Notary Public•California:' ft?" Orange County I certify under PENALTY OF PERJURY under the laws of -�r�=� �° Commission N 25418�a the State of California that the foregoing paragraph is true +..°•0 My Comm.Expires Dec 16,2029 and correct. Witness my hand a d off ial sea. Signature •� ��% Place Notary Seal Above Signature!'Notary Public Ir- - Luong OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies)Claimed by Signer(s) Signer's Name: Signer's Name: ❑ Individual ❑ Individual ❑ Corporate Officer—Title(s): ❑ Corporate Officer —Title(s): ❑ Partner ❑Limited ❑General ❑ Partner ❑Limited❑General LI Attorney in Fact 'IGHTTHUM:•'INT ❑ Attorney in Fact RIGHT THUMBPRINT ❑ Trustee •F SIGNS' ❑ Trustee OF SIGNER El Guardian or Conservator Top of thumb here ❑ Guardian or Conservator Top of thumb here El Other: ❑ Other: Signer is Representing: Signer is Representing: MERCHANT`? BONDING COMPANYTU POWER OF ATTORNEY Know All Persons By These Presents,that MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa,d/b/a Merchants National Indemnity Company(in California only)(herein collectively called the "Companies")do hereby make,constitute and appoint,individually, Alexander R Holsheimer;Christine Woolford;Danielle Hanson;Emilie George; Irene Luong;James W Moilanen;P Austin Neff;Thao Luu;Yung T Mullick their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. This Power-of-Attorney is granted and is signed and sealed by facsimile under and by authority of the following By-Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding,Inc.,on October 16,2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys-in-Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings,recognizances,contracts of indemnity and other writings obligatory in the nature thereof." "The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company,and such signature and seal when so used shall have the same force and effect as though manually fixed." In connection with obligations in favor of the Florida Department of Transportation only,it is agreed that the power and aut hority hereby given to the Attorney-in-Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations in favor of the Kentucky Department of Highways only,it is agreed that the power and authority hereby given to the Attorney-in-Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner- Department of Highways of the Commonwealth of Kentucky at least thirty(30)days prior to the modification or revocation. In Witness Whereof,the Companies have caused this instrument to be signed and sealed this 2nd day of July , 2024 • ♦••""""••. .•••- ••• MERCHANTS BONDING COMPANY(MUTUAL) ••♦�P�'P0 Ac.... •--‘0 ••: :p�-`N PD O� • MERCHANTS NATIONAL BONDING,INC. h�•T. IP4�� • (l g4.1 • d/b/a MERCHANTS NATIONAL INDEMNITY COMPANY v' 2003 o; •y 1933 :'c: By • ••••.� '. ..•:rJ�.`• �6`�'l•y l.�d•• President STATE OF IOWA •...�.......•••♦ ▪•......•• COUNTY OF DALLAS ss. On this 2nd day of July 2024 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies;and that the said instrument was signed and sealed in behalf of the Companies by authority of their respective Boards of Directors. co Penni Miller • • ° v Commission Number 787952 Z �� G r- • •,•r•,. • My Commission Expires - IONIA January 20,2027 Nota bl (Expiration of notary's commission does not invalidate this instrument) I,William Warner,Jr.,Secretary of MERCHANTS BONDING COMPANY(MUTUAL)and MERCHANTS NATIONAL BONDING,INC.,do hereby certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies,which is still in full force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 20th day of February ,2026 . 4tyc.., €,/ j' 2003 i,I %' 1933 . Secretary .ti .� POA 0018 (1/24) •�"""" No. 2482-8 STATE OF CALIFORNIA DEPARTMENT OF INSURANCE SAN FRANCISCO Amended Certificate of Authority THIS IS TO CERTIFY that,pursuant to the Insurance Code of the State of California, Merchants Bonding Company(Mutual) of Iowa, organized under the laws of Iowa, subject to its Articles of Incorporation or other fundamental organizational documents,is hereby authorized to transact within this State,subject to all provisions of this Certificate, the following classes of insurance: Surety,Liability,and Miscellaneous as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all,and not in violation of any, of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable, and as such laws and requirements now are, or may hereafter be changed or amended. IN WITNESS WHEREOF, effective as of the Is` day of October, 2015,I have hereunto set my hand and caused my official seal to be e;tr. affixed this 1"day of October, 2015. 1- Dave Jones Cw = 4'� Insurance Commissioner ^7CT�R By Valerie Sarfaty for Nettie Hoge Chief Deputy NOTICE: Qualification with the Secretary of State must be accomplished as required by the California Corporations Code promptly after issuance of this Certificate of Authority. Failure to do so will be a violation of insurance Code section 701 and will be grounds for revoking this Certificate of Authority pursuant to the covenants made in the application therefor and the conditions contained herein. OFFICIAL BID SECURITY- DO NOT OPEN Project Name: Hartlund Lane Water Main Replacement Project Manager: Eduardo Okamoto-Cerda CC #: 1735 Bid Opening Date: February 26, 2026, at 10:00 am Pnbbc nrk nr{c b�C�c 2-35/¢inrxnad { O L/\ a4 jorir j/s1'�`0.IGio CITY OF ;jai° . � ``t HUNTINGTON BEACH :ie�w•�- -..ewe Q//1 Lisa Lane Barnes I City Clerk May 1, 2026 We R Builders Attn: Nezar Alsmadi 1608 Palmyrita Avenue Riverside, CA 92507 Re: Hartlund Lane Water Main Replacement, CC-1735 The City Council awarded the bid to your company for the above referenced project. Enclosed is a copy of the executed contract with the City of Huntington Beach. A Certification of Compliance with Title VII of the Civil Rights Act, Certification of Compliance with Prevailing Wage Laws and Contractor's Certificate form must be returned to this office after the project is completed but prior to the release of retention funds. In addition, the following item must also be on file, with this office before the City can release any retention funds: A warranty bond guaranteeing the final amount of work and materials for one year. If your performance bond does not include specific wording for a one-year warranty, then a rider or separate bond must be submitted. Should you have any questions or concerns regarding the enclosures or items that must be on file in this office prior to release of retention funds, please call the Public Works Department at 714-536-5517. cerely, Lisa Lane Barnes City Clerk LLB:ds Enclosure Office: (714) 536—5405 I 2000 Main Street, Huntington Beach, CA 92648 I www.huntingtonbeachca.gov RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: 51 x 124 SUBJECT: Bond Acceptance I have received the bonds for \I\J& R I� Pith (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) Performance Bond No. \ol 4 12Z&Q(p Payment Bond (Labor and Materials) Bond No. 1O1141 2—Z_L t, Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved 4/2, /2(.v (Council Approval Date) CC No. Agenda Item No. (2O- 2Di) MSC No. City Clerk Vault No. LO 7O. 5O Other No. SIRE System ID No. g:/forms/bond transmittal to treasurer ..ldIl1I = 1)1 . CC1735 Hartlund Talbe �-}� `rpLane Water Main T.. _.�. ._._._. 1 E Aye . . Replacement (=J U Project Location Gladys Tradewind Cir. Dr. o Magic .;Santana Cir. c Cir. _RI _ Sterling Dr. t Sprting 2 J a v °v .� Ralf= yo�\� hu�t Dr. Cir. va G c°Shamrock Cir. ca Kiner Dr. eetwater idlewild C7 ` 0 Cir. Cir. Taylor Dr. = f e - — Sunbeam ' _ v) ca L •- J Cir. O o Dancy E C>% J Cir. o, O C.9 c 2 Cir Forelle Dr. � �.. C� Pad rino ga1'e Dr. o c Ma',/).- Cir. s) Q p La Palma C��,�°s�, ">0 Q Dr. O Delfino fiat Cir. Basin 2 Cir,-�. F! lis Ave . ,-- L 411 U o G T Hartlund \-\\ -\- I N• Po 0 a I n � �• `,�p R Rq T�� ••i <P,, --- - -� • - Replacement co, _ -�" „„! „pi,: dnI ,f, �i ' \ ' It ( \ '',1 . ' ' Project ________ _______ _ ___ _ _ ii w C C _ 1 735 , ' / , . fir "�'`►► ..__ r::k,. . � o 7 • • 6. 17, 19 3 ,C°O i;,•• •sue• April 21 , 2026 City Council Meeting 412 Project a 1M .bar _ ... " d§ 3 - .�.yytt {{� ....................... .ce..m''_ «A q pw�w... w«.rw�♦ Ek t �T#a' 3' ii Tam«ia^ w Project Area • +'M'+^!" f S c P lu class:.. H *M _ ,.eat t'�...,.. -..,..,. et4',,,t,,i7OL.L..:„.., ',.•tiir';t5t:!:•:,::01. ..-ir,Wil-i' - - "i •$�.-• t _ 4. yyc.'. rk P over' • S.41 0n -r, ophts- y 4 s a t,. +"rr a0sin Y € Ei aXa €�r yz pii,. •k g w'Z"-.... '.WB{i77a((,11111 5T1 Y iAilli4gu"I g¢ .4 '.1 `, . . .. 'a te +yjr 'l r tei �; y, i ;i e, - , H Cane ° "y a: ,r 1111 Fj r % :;t1.0.',:71":4,-..,"..• lonrx}caeof . ! , 1x • 1.0-� t c of �,iix „§# !....1k.. a !tqj�r ₹ A :.. --;,-.4,44„,4,N "t Asa < '•`rte :➢ ,;i i iti ..Ali / I-rEM b 6. t4 Imo, 4. 1 :•� ,-p t''� A .. .:, :.. �. >.f i 413 ar un n a er Main i Year Built: 1 973 6 Water main meets Annual Water . , .,: Main Replacement Criteria 0 , li , Update water mains that have Irage �"`` reached their "end-of-service- § 17 �::w - �, p life. w �--u � Convert system from asbestos ` � -= �`` (ACP) to PVC water main - ice o O,,, ,NGpRPORA4.O.•y V ..9 • t.ie••.; 17 ,5t% I''' • k c°LINTY , '' 414 Scope of or Abandon existing Asbestos Jattt = UlCement Pipe (ACP) water mains CC1735 Hartlund __ — Talbert Ave. Lane Water Main �-----�- ---�� -- i n residential tract Replacement � �� U Project Location Tradewind Cir. �t Gladys Trench and install new 6 Dr. � o �SantanaCir. m Polyvinyl Chloride Pipe (PVC) J magic � a) Sterling Dr. o Cir.' spring `° t Rolf' �Q°<<hul tDr. along Hartlund Lane and Kiner c Gr. a c fa °Shamrock Cir. D r. �, Kiner Dr. t(fl eetwater Idlewild LdCQf . TaylorDr. e Install new 4" PVC water mains —'Sunbeam J. e,',; m Danc a) on Magic and Rolf Circle Cr Cir.y'n o. . x= . A��, ° Localized concrete and -4. Cir; C Forelle Dr. n �gy .- U /1 N -' .� v'Padrino gale Dr, repair if �UN......G r�/Ij e o _. Man Cir. ss/ ,� ��•••.-N�oaPoegrfo•.•. V a La Palma i 04...es, , °?o�� II _ •,Fp t\ • a. 0 711 Dr. o o Delfino ca co Y. c�; ! _ Cir- - — c B sin 2 f rill Ave. C:3 :-...-_-,-3.-- --,r ��� Irk (ix, •.. i7,t9a9 ..- �oUNTY °s\',/�t� .0i 415 Funding • We R Builders Bid : $ 729, 770 O 1 5% Contingency: $ 109,465 • Supplemental Costs : $ 34,036 $ 873 , 271 Current Funding <53 • Water Improvements : $ 839 , 235 `= =_ •�sfi O Other Prof. Services : $ 34,036cj, $ 873 , 271 ''•`fe Pa.•,4O cF���NTY �\ 416 Questions ? r'rrifns .:."s^ :R_ �. ti • '.• .. ti '1_ 1 417 N '�'` City of Huntington Beach i�j --;` City Treasurer P.O. Box 190 %y 7'..;7 (714) 536-5267 FAX(714) 536-5934 Huntington Beach, CA 92648-2702 SCF ' , Jason Schmitt City Treasurer WE R BUILDERS 1608 PALMYRITA AVE RIVERSIDE, CA 92507 Dear Business Owner: Thank you for your payment. Attached is your City of Huntington Beach Business License certificate. Please note that approximately one month prior to the license expiration date, you will be mailed a renewal notice for the upcoming year. If for any reason your renewal notice does not arrive,you are still responsible for renewing and paying your business license prior to the expiration date. Penalties will be incurred if the payment is not received by the expiration date. Please post the business license in public view. If you do not transact business from a fixed location within the City,you must carry this license with you at all times. If a vehicle license plate number is displayed on the Business License certificate below,you must carry a copy of the certificate in that vehicle. Please contact the Business License office if there are any changes to:ownership, address, business name, business vehicle,or type of business conducted.Additionally, please notify our office if you discontinue your business. The Gender Tax Repeal Act of 1995(Act)prohibits a business from discriminating based on a person's gender for prices of similar or like-kind goods and services. However,the Act does not prohibit price differences based on the amount of time,difficulty,or cost of providing the services. In addition to prohibiting discrimination based on a person's gender,the Act requires certain businesses to clearly and conspicuously disclose to customers in writing the pricing for each standard service provided.The posting requirement applies to barbers and hair salons,tailors or businesses providing aftermarket clothing alterations, dry cleaners,and laundries providing services to individuals.To access the Department of Consumer Affairs publication,please use the following webpage: https://www.barbercosmo.ca.gov/consumers/genderpolicy.pdf. To access the publication in Korean, Spanish,Vietnamese, Traditional Chinese, Simplified Chinese,or Tagalog,please use the following webpage: https://www.dca.ca.gov/publications/index.shtml There are many resources available to our business owners. Listed below are a few that might be of interest and assistance to you. Office of Business Development -(714) 536-5582 Service Corps of Retired Executives-(714)550-7369 Huntington Beach Chamber of Commerce-(714)536-8888 Fictitious Business Name Information-(714)834-2889 CA Department of Tax and Fee Administration-(949)440-3473 Community Development-(714)536-5271 If you have any questions, please call a Business License representative at (714) 536-5267. City of Huntington Beach City Treasurer License Number Business Name/Service Address POST IN PUBLIC VIEW A314269 WE R BUILDERS Effective Date �' 4•�����tiT N 6Tp'L 03/01/2026 Owner/Corporation 1"y ‘ r t-: ` Expiration Date WE R BUILDERS z % 02/28/2027 License Type Z.•'•�.. • CONTRACTOR `b, 6' ,,\\, Amount Paid -,.y�il�i $111.86 THIS LICENSE IS ONLY FOR THE BUSINESS AND TYPE SHOWN. IT IS FOR THE PERSON TO WHOM ISSUED AND IS NON-TRANSFERABLE. RENEWAL IS DUE ON OR BEFORE THE EXPIRATION DATE. CITY OF HUNTINGTON BEACH .0/1r / BUSINESS LICENSE ; P.O.Box 190 1 - Huntington Beach,CA 92648-2702 (714)536-5267 a ^,� ) JUN 26 2025 Robert Torrez By Interim Chief Financial Officer HNY0623A 4000000091 87/1 mml Ilnl�lniI.uli��lllllnl�l�ll�h���l�l���l�n'�11�'Illl��hy�l imam .;•`;ikf. HARDY&HARPER INC 32 RANCHO CIR ;'' •'1 LAKE FOREST CA 92630-8325 Dear Business Owner: Thank you for your payment. Attached is your City of Huntington Beach Business License certificate. Please note that approximately one month prior to the license expiration date,you will be mailed a renewal notice for the upcoming year. If for any reason your renewal notice does not arrive,you are still responsible for renewing and paying your business license prior to the expiration date. Penalties will be incurred if the payment is not received by the expiration date. Please post the business license in public view. If you do not transact business from a fixed location within the City,you must carry this license with you at all times. If a vehicle license plate number is displayed on the Business License certificate below,you must carry a copy of the certificate in that vehicle. Please contact the Business License office if there are any changes to:ownership, address, business name,business vehicle,or type of business conducted.Additionally,please notify our office if you discontinue your business. The Gender Tax Repeal Act of 1995(Act)prohibits a business from discriminating based on a person's gender for prices of similar or like-kind goods and services. However,the Act does not prohibit price differences based on the amount of time,difficulty,or cost of providing the services. In addition to prohibiting discrimination based on a person's gender,the Act requires certain businesses to clearly and conspicuously disclose to customers in writing the pricing for each standard service provided.The posting requirement applies to barbers and hair salons,tailors or businesses providing aftermarket clothing alterations,dry cleaners,and laundries providing services to individuals.To access the Department of Consumer Affairs publication, please use the following webpage: https://www.barbercosmo.ca.gov/consumers/gender_policy.pdf. To access the publication in Korean,Spanish,Vietnamese, Traditional Chinese, Simplified Chinese,or Tagalog, please use the following webpage: https://www.dca.ca.gov/publications/index.shtml There are many resources available to our business owners. Listed below are a few that might be of interest and assistance to you. Office of Business Development -(714)536-5582 Service Corps of Retired Executives-(714)550-7369 Huntington Beach Chamber of Commerce-(714)536-8888 Fictitious Business Name Information-(714)834-2889 CA Department of Tax and Fee Administration-(949)440-3473 Community Development-(714)536-5271 If you have any questions, please call a Business License representative at(714)536-5267. City of Huntington Beach Business License License Number Business Name/Service Address POST IN PUBLIC VIEW A011016 HARDY& HARPER INC ����N�! Effective Date # �,� ..... ...jQ1e 7/1/2025 Owner/Corporation t ; 9 Expiration Date FRED T MAAS JR Z 6/30/2026 otw� . cry License Type �a�;,. oQ/t {� Amount Paid CONTRACTOR �DUNTv�F�i $110.80 4' mid THIS LICENSE IS ONLY FOR THE BUSINESS AND TYPE SHOWN. IT IS FOR THE PERSON TO WHOM ISSUED AND IS NON-TRANSFERABLE. RENEWAL IS DUE ON OR BEFORE THE EXPIRATION DATE. -f1/1]. •� CITY OF HUNTINGTON BEACH BUSINESS LICENSE ; P.O. Box 190 Huntington Beach,CA 92648-2702 sir!" ,r (714)536-5267 • " `" David Cain Interim Chief Financial Officer HNY0318A 4000000072 69/1 Ill�lllll�l�ll�ll�llll����llll�lll�l�ll�lllllllll�llllllll�lll�ll ti ALLIANCE ENVIRONMENTAL GROUP LLC • • . 777 N GEORGIA AVE * AZUSA CA 91702-2207 Dear Business Owner: Thank you for your payment. Attached is your City of Huntington Beach Business License certificate. Please note that approximately one month prior to the license expiration date,you will be mailed a renewal notice for the upcoming year. If for any reason your reiiewal notice dues nut aiIlye, you die still IespunsIble fur reiiewhrg and pdyliig yuui t,usliress lIcerrse pilot to lire expliatluri date. Penalties will be incurred if the payment is not received by the expiration date. Please post the business license in public view. If you do not transact business from a fixed location within the City,you must carry this license with you at all times. If a vehicle license plate number is displayed on the Business License certificate below, you must c any a of the reitifirale in dial veliirle Please tor dad the Bu5ine55 t Welly-office if there are piny c'Iiaiige5 to crwnerchip, address, husiness name, business vehicle, or type of business conducted Additionally, please notify our office if you discontinue your business. The Gender Tax Repeal Act of 1995(Act)prohibits a business from discriminating based on a person's gender for prices of similar or like-kind goods and services. However, the Act does not prohibit price differences based on the amount of time,difficulty, or cost of providing the services. In addition to prohibiting discrimination based on a person's gender,the Act requires certain businesses to clearly and conspicuously disclose to customers in writing the pricing for each standard service provided.The posting requirement applies to barbers and hair salons, tailors or businesses providing aftermarket clothing alterations, dry cleaners,and laundries providing services to individuals. To access the Department of Consumer Affairs publication, please use the following webpage: https://www.barbercosmo.ca.gov/consumers/gender_policy.pdf. To access the publication in Korean. Spanish,Vietnamese, Traditional Chinese, Simplified Chinese, or Tagalog, please use the following webpage: https://www.dca.ca.gov/publications/index.shtml There are many resources available to our business owners. Listed below are a few that might be of interest and assistance to you. Office of Business Development -(714)536-5582 Service Corps of Retired Executives-(714)550-7369 Huntington Beach Chamber of Commerce-(714)536-8888 Fictitious Business Name Information-(714)834-2889 CA Department of Tax and Fee Administration -(949)440-3473 Community Development-(714)536-5271 If you have any questions, please call a Business License representative at(714) 536-5267. City of Huntington Beach Business License License Number Business Name/ Service Address POST IN PUBLIC VIEW A270230 ALLIANCE ENVIRONMENTAL GROUP LLC • VINGTDy Effective Date 4/1/2025 Owner/Corporation F9 i ALLIANCE ENVIRONMENTAL GROUP LLC • c, `; y Expiration Date 9 "�J Q 3/31/2026 License Type .� FQ= Amount Paid CONTRACTOR �`'0u TI tP" $110.80 THIS LICENSE IS ONLY FOR THE BUSINESS AND TYPE SHOWN. IT IS FOR THE PERSON TO WHOM ISSUED AND IS NON-TRANSFERABLE. RENEWAL IS DUE ON OR BEFORE THE EXPIRATION DATE. 00Ite 15121, SECTION A l`"u. b „,//Z/20, a//124 NOTICEINVITINGELECTRONIC BIDS for the construction of HARTLUND LN, BETWEEN LE CONTE DR AND TALBERT AVE. WATER MAIN REPLACEMENT PROJECT CC No. 1735 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites electronic bids for the above stated project and will receive such bids prior to 10:00 am on Thursday, February 26, 2026, on the City's PlanetBids System Vendor Portal, at which time or thereafter bids will be opened and made available online. Bids received after this time will be considered non-responsive. Prospective bidders must first register as a vendor and then bid on this project via the City's PlanetBids System Vendor Portal website at: https://www.planetbids.com/portal/portal.cfm?CompanyID=15340 Copies of the bid documents, including instructions to bidders, bidder proposal form, and specifications may be downloaded free at: https://www.planetbids.com/portal/portal.cfm?CompanyID=15340. Bidders must first register as a vendor on the City of Huntington Beach PlanetBids system to view and download the Contract Documents,to be added to the prospective bidders list, and to receive addendum notifications when issued. Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft, classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California, which are available online at www.dir.ca.gov/DLSR and also on file at the Office of the Director of Public Works, 2000 Main Street, Huntington Beach, CA 92648. The AGENCY will deduct 5% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the Public Contract Code,Section 10263. The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. No bid shall be considered unless it is prepared on the approved Proposal forms in conformance with the Instructions to Bidders as determined by the AGENCY. The bid must be accompanied by a certified check, cashier's check, or bidder's bond made payable to the AGENCY for an amount no less than 10% of the amount bid. For electronic submittal of bids, the bid security must be A-1 received at the City of Huntington Beach Public Works Office, 2000 Main Street, no later than the bid opening date and time. The bid security must be submitted in a sealed envelope bearing the name and address of the bidder, and the outside of the envelope must read as follows: OFFICIAL BID SECURITY - DO NOT OPEN Project Name: Hartlund Lane Water Main Replacement Project Manager: Eduardo Okamoto-Cerda CC #: 1735 Bid Opening Date: February 26, 2026, at 10:00 am The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State Contractor's License Class A, at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY. All extension of unit prices will be subject to verification by the AGENCY. In case of a variation between the unit price and the extension, the unit price will govern. Project Description: The project consists of the installation of approximately 2,100 linear feet of 6-inch diameter PVC AWWA C900(DR 18)water pipeline,with appurtenances, in Hartlund Ln., Kiner Dr., Rolf Cir, Magic Cir., and Gladys Dr. Scope includes replacement of fire hydrants, modifications to existing water services, relocating sewer laterals,and abandonment of the existing water piping. The contract shall allow the Contractor 120 working days to complete the contract. The engineer's estimate of probable construction cost for the work included in the basis of award is $2,200,000. All questions related to this bid solicitation must be submitted through the City's PlanetBids System Vendor Portal per the information provided in the Instructions to Bidders. Any other contact to City staff regarding this bid solicitation will be referred back to the PlanetBids system. The AGENCY reserves the right to reject any or all bids, to waive any irregularity and to take all bids under advisement for a maximum period of 60 days. A-2 Column INTERIM AD DRAFT This is the proof of your ad scheduled to run in Huntington Beach Wave on the dates indicated below. If changes are needed, please contact us prior to deadline at (714) 796-2209. Notice ID:jMZUDvLTEOUkWxjoyOHJ I Proof Updated: Feb.05,2026 at 01:23pm PST Notice Name: NIEB-CC No. 1735 See Proof on Next Page This is not an invoice.Below is an estimated price,and it is subject to change.You will receive an invoice with the final price upon invoice creation by the publisher. FILER FILING FOR Donna Switzer Huntington Beach Wave donna.switzer@surfcity-hb.org (714)374-1649 Columns Wide: 5 Ad Class: Legals Total Column Inches: 46.18 Number of Lines: 95 02/12/2026:City Notices 701.21 02/19/2026:City Notices 701.21 Subtotal $1402.42 Tax $0.00 Processing Fee $0.00 Total $1402.42 NIEB -CC No. 1735 - Page 1 of 3 SECTION A NOTICE INVITING ELECTRONIC BIDS for the construction of HARTLUND LN,BETWEEN LE CONTE DR AND TALBERT AVE. WATER MAIN REPLACEMENT PROJECT CC No.1735 In the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH, as AGENCY, invites electronic bids for the above stated protect and will receive such bids prior to 10:00 am on Thursday, February 26,2026, on the City's Planet Bids System Vendor Portal, at which time or thereafter bids will be opened and made available online. Bids received after this time will be considered non-responsive. Prospective bidders must first register as a vendor and then bid on this protect via the City's PlanetBlds System Vendor Portal website at: https://www.planetbids.com/portal/ portal.cfm?Companyl D=15340 Copies of the bid documents, including instructions to bidders,bidder proposal form, and specifications may be downloaded free at: https://www.pianetbids.com/portal/ portal.cfm?Companyl D=15340. Bidders must first register as a vendor on the City of Huntington Beach PlanetBlds system to view and download the Contract Documents, to be added to the prospective bidders list,and to receive addendum notifications when Issued. Any contract entered Into pursuant to this notice will incorporate the provisions of the State Labor Code.Pursuant to the provisions of the Labor Code of the State of California, the minimum prevailing rate of per diem wages for each craft,classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California,which are available online at www.dir. ca.gov/DLSR and also on file at the Office of the Director of Public Works,2000 Main Street,Huntington Beach,CA 92648. The AGENCY will deduct 5% retention from all progress payments. The Contractor may substitute an escrow holder surety of equal value to the retention in accordance with the provisions of the Public Contract Code,Section 10263.The Contractor shall be beneficial owner of the surety and shall receive any interest thereon. The AGENCY hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion In any consideration leading to the award of contract. No bid shall be considered unless It is prepared on the approved Proposal forms in conformance with the Instructions to Bidders as determined by the AGENCY. The bid must be accompanied by a certified check, cashiers check, or bidders bond made payable to the AGENCY for an amount no less than 10%of the amount bid. For electronic submittal of bids,the bid security must be received at the City of Huntington Beach Public Works Office, 2000 Main Street, no later than the bid opening date and time. The bid security must be submitted In a sealed envelope bearing the name and address of the bidder, and the outside of the envelope must read as follows: OFFICIAL BID SECURITY-DO NOT OPEN Project Name: Hartlund Lane Water Main Replacement Project Manager: Eduardo Okamoto- Cerda CC#:1735 Bid Opening Date:February 26,2026,at 10:00 am The successful bidder shall be licensed in accordance with provisions of the Business and Professions Code and shall possess a State Contractors License Class A,at the time of the bid opening. The successful Contractor and his subcontractors will be required to possess business licenses from the AGENCY.All extension of unit prices will be sublect to verification by the AGENCY. In case of a variation between the unit price and the extension,the unit price will govern. Project Description: The protect consists of the installation of approximately 2,100 linear feet of 6-inch diameter PVC AWWA C900 (DR 18) water pipeline,with appurtenances, in Hartlund Ln., Kiner Dr., Rolf Cir,Magic Cir.,and Gladys Dr.Scope includes replacement of fire hydrants, modifications to existing water services, relocating sewer laterals, and abandonment of the existing water piping. The contract shall allow the Contractor 120 working days to complete the contract. The engineer's estimate of probable construction cost for the work included in the basis of award is$2,200,000. All questions related to this bid solicitation must be submitted through the City's PlanetBlds System Vendor Portal per the information provided in the instructions to Bidders.Any other contact to City staff regarding this bid solicitation will be referred back to the PlanetBlds system. NIEB - CC No. 1735 - Page 2 of 3 The AGENCY reserves the right to relect any or all bids,to waive any Irregularity and to take all bids under advisement for a maximum period of 60 days. Huntington Beach Wave Published:2/12,2/19/26 NIEB -CC No. 1735 - Page 3 of 3 iNeuuoesrNE 1VilaL,_ FOUNTAIN VALLEY VIEW casmundson@scng.com Invoice number 2C7C23BA-0108 Date created Feb 5,2026 ealmeidaPscng.com Payment method Invoiced Outside Column Notice Id jMZUDvLTEOUkWxjoyOHJ Publisher Huntington Beach Wave Bill to City of Huntington Beach- City Clerk's Office $1402.42 due March 5, 2026 __=Notes =__ Notice Name:NIEB- CC No. 1735 Order Number: T HIS IS NOT A BILL AS A BILLABLE CUST OMER FOR SOUT HERN CALIFORNIA NEWS GROUP YOU WILL BE INVOICED DIRECTLY BY T HEM AND PAY T HEM ON YOUR NORMAL BILLING CYCLE. Description Qty Unit price Amount 02/12/2026:City Notices Notice 1 701.21 701.21 02/19/2026:City Notices Notice 1 701.21 701.21 Subtotal $1402.42 Tax 0.00 Amount Due $1402.42 Questions? Visit help.column.us - Page 1 of 1 INCLUDES THE FOUNTAIN VALLEY VIEW 1920 Main St. Suite 225, Irvine Irvine, California 92614 (714) 796-2209 legals@inlandnewspapers.com City of Huntington Beach-City Clerk's Office 2000 Main Street Huntington Beach, California 92648 Account Number: 5272431 Ad Order Number: 0011777925 Customer's Reference/PO Number: Publication: Huntington Beach Wave Publication Dates: 02/12/2026 and 02/19/2026 Total Amount: $1402.42 Payment Amount: $0.00 Amount Due: $1402.42 Notice ID: jMZUDvLTEOUkWxjoyOHJ Invoice Text: SECTIONANOTICEINVITINGELECTRONICBIDSforthe construction of HARTLUND LN, BETWEEN LE CONTE DR AND TALBERT AVE. WATER MAIN REPLACEMENT PROJECT CC No. 1735 in the CITY OF HUNTINGTON BEACH PUBLIC NOTICE IS HEREBY GIVEN that the CITY OF HUNTINGTON BEACH,as AGENCY, invites electronic bids for the above stated project and will receive such bids prior to 10:00 am on Thursday, February 26, 2026, on the City's PlanetBids System Vendor Portal,at which time or thereafter bids will be opened and made available online. Bids received after this time will be considered non-responsive. Prospective bidders must first register as a vendor and then bid on this project via the City's PlanetBids System Vendor Portal website at: https://www.planetbids.com/portal/portal.cfm?CompanylD=15340 Copies of the bid documents, including instructions to bidders, bidder proposal form,and specifications may be downloaded free at: https://www.planetbids.com/portal/portal.cfm? CompanylD=15340. Bidders must first register as a vendor on the City of Huntington Beach PlanetBids system to view and download the Contract Documents,to be added to the prospective bidders list,and to receive addendum notifications when issued.Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Pursuant to the provisions of the Labor Code of the State of California,the minimum prevailing rate of per diem wages for each craft,classification or type of workman needed to execute the contract shall be those determined by the Director of Industrial Relations of the State of California,which are available online at www.dir.ca.gov/DLSR and also on file at the Office of the Director of Public Works, NIEB- CC No. 1735- Page 1 of 3 See Proof on Next Page INCLUDES THE FOUNTA N 0, VALLEY VIEW.1VillikiHuntington Beach Wave 1920 Main St.Suite 225,Irvine Irvine,California 92614 (714)796-2209 2000 Main Street Huntington Beach,California 92648 AFFIDAVIT OF PUBLICATION STATE OF CALIFORNIA County of Orange County I am a citizen of the United States and a resident of the County aforesaid; I am over the age of eighteen years,and not a party to or interested in the above-entitled matter. I am the principal clerk of the Huntington Beach Wave, a newspaper that has been adjudged to be a newspaper of general circulation by the Superior Court of the County of Orange County, State of California, on July 1, 1998, Case No. A- 185906 in and for the City of Irvine, County of Orange County, State of California; that the notice, of which the annexed is a true printed copy, has been published in each regular and entire issue of said newspaper and not in any supplement thereof on the following dates,to wit: 0211212026,02119/2026 I certify (or declare) under the penalty of perjury under the laws of the State of California that the foregoing is true and correct: Executed at Anaheim,Orange County, California,on Date: Feb 19, 2026. Cante9k. S ure NIEB- CC No. 1735 - Page 1 of 3