Loading...
HomeMy WebLinkAboutPerformance Pipeline Technologies, Inc. - 2026-06-02 RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) °I , In CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: PO /7 I t' SUBJECT: Bond Acceptance I have received the bonds for !I (-C . (Company Name) CAPITAL PROJECTS (Includes CC's and MSC's) JJJ Performance Bond No. Payment Bond (Labor and Materials) Bond No. Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved " I? (Council Approval Date) CC No. Agenda Item No. Qt"1414 MSC No. City Clerk Vault No. l Other No. SIRE System ID No. `►��r�----- g:/forms/bond transmittal to treasurer a�N?�NGTp 2000 Main Street, Huntington Beach,CA ` ' 92648 City of Huntington Beach t � ` �_ APPROVED 6-0-1 v UNre (VAN DER MARK-ABSENT) comm File #: 26-407 MEETING DATE: 6/2/2026 REQUEST FOR CITY COUNCIL ACTION SUBMITTED TO: Honorable Mayor and City Council Members SUBMITTED BY: Travis Hopkins, City Manager VIA: Chau Vu, Director of Public Works PREPARED BY: Michael Aguas, Capital Projects Administrator Subject: Accept Lowest Responsive and Responsible Bid and Authorize Execution of a Construction Contract with Performance Pipeline Technologies, Inc., in the Amount of$1,970,231.60, for the FY 2025/26 Sewer Lining Project (CC-1845) Statement of Issue: On March 26, 2026, the City received electronic bids via PlanetBids for the FY 2025/26 Sewer Lining Project. City Council action is requested to award the construction contract in the amount of $1,970,231.60 to Performance Pipeline Technologies, Inc., the lowest responsive and responsible bidder. Financial Impact: The total construction cost for the project, including 15% contingency, inspection, and testing is $2,365,766.34. Item Amount Bid submitted by Performance Pipeline Technologies, Inc. $1,970,231.60 15% Contingency $295,534.74 Supplemental $100,000.00 Total Construction Cost: $2,365,766.34 Staff recommends awarding the construction contract to Performance Pipeline Technologies, Inc. in the amount of $1,970,231.60. Funding is available in the Fiscal Year 2025-26 budget in the Sewer Improvement Fund, Account No. 51189028.82600. Recommended Action: A) Accept the lowest responsive and responsible bid submitted by Performance Pipeline City of Huntington Beach Page 1 of 3 Printed on 5/27/2026 powered by LegistarT' 465 File #: 26-407 MEETING DATE: 6/2/2026 Technologies, Inc. in the amount of$1,970,231.60; and, B) Authorize the Director of Public Works to approve change orders up to 15% contingency in potential construction change orders; and, C) Authorize the Mayor and City Clerk to execute the construction contract in a form approved by the City Attorney. Alternative Action(s): 1. Reject all bids. 2. Direct staff to take alternative action. Analysis: The Engineering and Utilities Division identified the need for rehabilitation of existing sewer pipes based on maintenance history and video inspection. The scope of work for the project includes lining approximately 29,850 lineal feet of aged sewer main lines identified as a priority this year. The project locations would benefit from lining as the existing pipes contain calcium deposits resulting from groundwater seepage through minor cracks and joints, or have offset joints caused by tree root intrusion from adjacent mature trees located in parkways. These calcium deposits and roots inhibit sewage flow and will be removed prior to lining. The lining process is a trenchless rehabilitation method in which a cured-in-place pipe (CIPP) UV liner is inserted into the existing pipe to form a new structural pipe within the existing pipe. The project also includes rehabilitation of 66 manholes. Completion of this project will extend the service life of the sewer system by approximately 20 years, help prevent sanitary sewer overflows, reduce calcite buildup and groundwater inflow, and increase the structural integrity of the sewer infrastructure. Annual sewer lining projects preserve the life expectancy of critical citywide sewer utility infrastructure. Bids were opened on March 26, 2026, with the following results: Bidder's Name Bid Amount Performance Pipeline Technologies, Inc. $1,970,231.60 Vortex Services LLC, dba Sancon Technologies $2,355,989.00 Tunnelworks Services Inc. $2,377,552.00 lnliner Solutions, LLC $3,024,825.00 Staff reviewed Performance Pipline Technologies, Inc. bid and determined it to be the lowest responsive and responsible bidder. Staff recommends awarding the Construction Contract to Performance Pipeline Technologies, Inc. The total estimated project costs is $ $2,365,766.34, which includes the construction contract, 15% contingency, and supplemental costs for construction support services. City of Huntington Beach Page 2 of 3 Printed on 5/27/2026 powered by Legistarm 466 File #: 26-407 MEETING DATE: 6/2/2026 Environmental Status: This project is exempt from the California Environmental Quality Act (CEQA) pursuant to Section 15031c - Class 1 of the CEQA Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no potential to have a significant effect on the environment. Strategic Plan Goal: Non Applicable -Administrative Item For details, visit www.huntingtonbeachca.gov/strategicplan. Attachment(s): 1. RCA Contract Agreement Summary 2. Construction Contract 3. PowerPoint Presentation City of Huntington Beach Page 3 of 3 Printed on 5/27/2026 powered by LegistarTm 467 d#' TTI CITY OF HUNTINGT0N BEACH f F ~•RCA Contract ' ; �'�9" Agreement Summary N.V :F°��� �UNTV�i� GENERAL INFORMATION DATE PRESENTED REQUESTING DEPARTMENT 06/02/2026 Public Works, Utilities Division INSURANCE STATUS STAFF CONTACT[S) Pending Approval - RM / CAO Michael Aguas CONTRACT INFORMATION TOTAL COMPENSATION TERM OF CONTRACT/AGREEMENT $1,970,231.60 160 Working Day Construction Contract VENDOR NAME+TYPE OF SERVICE Performance Pipeline Technologies, Inc., Huntington Beach, California. Types of Services include but are not limited to CCTV Inspection, Pipe Cleaning, Mainline Sewer & Storm Drain Sealing, and Pipe Repairs - UV Cured Liners & CIPP (Cured-In-Place Pipe). TYPE OF AGREEMENT(Professional Services,Service Agreement) Construction Contract, Professional Service Agreement PROCUREMENT Design-Bid-Build Project. Project was open for Bids via PlanetBids to the Public Works On-Call Consultants, and recommend to award the Construction Contract to lowest responsive and responsible bidder. SCOPE OF WORK The scope of work includes lining existing sewer pipes based on maintenance history and video inspection. This project will use exclusively UV lining technologies. Total linear footage for UV lining is estimated at approximately 29,850 LF combined among 8", 10", 12", and 15" pipe diameters. OTHER:Bonds,Special Contract Terms.Emergency Contractor has provided Certificate of Insurance, Bonds, Contractor's Sworn Statement and City of Huntington Beach Business License and is pending approval from Rick Management and the City Attorney's Office. HUNTINGTON BEACH 468 CITY FUNDED CONSTRUCTION CONTRACT BETWEEN THE CITY OF HUNTINGTON BEACH AND PERFORMANCE PIPELINE TECHNOLOGIES, INC. FOR FY 2025-26 SEWER LINING PROJECT, CC1845 THIS AGREEMENT("Agreement") is made and entered into by and between the City of Huntington Beach, a municipal corporation of the State of California, hereinafter referred to as "CITY," and PERFORMANCE PIPELINE TECHNOLOGIES, INC. , a California corporation, hereinafter referred to as "CONTRACTOR." WHEREAS, CITY has solicited bids for a public works project, hereinafter referred to as "PROJECT," more fully described as FY 2025/26 SEWER LINING PROJECT, CC1845 in the City of Huntington Beach; and CONTRACTOR has been selected to perform said services, NOW, THEREFORE, in consideration of the promises and agreements hereinafter made and exchanged the parties covenant and agree as follows: 1. STATEMENT OF WORK; ACCEPTANCE OF RISK CONTRACTOR shall complete and construct the PROJECT pursuant to this Agreement and the Contract Documents (as hereinafter defined) and furnish, at its own cost and expense, all labor, plans, tools, equipment, supplies, transportation, utilities and all other items, services and facilities necessary to complete and construct the PROJECT in a good and workmanlike manner. CONTRACTOR agrees to fully assume the risk of all loss or damage arising out of the nature of the PROJECT, during its progress or prior to acceptance by CITY, from the action of the elements, from any unforeseen difficulties which may arise or be encountered in the 1 prosecution of work, and for all other risks of any description in connection with the work, including, but not limited to, all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as are herein expressly stipulated to be borne by CITY, and for well and faithfully completing the work within the stipulated time and in the manner shown and described in this Agreement, and in accordance with the requirements of CITY for the compensation set forth in the accepted bid proposal. 2. ACCEPTANCE OF CONDITIONS OF WORK; PLANS AND SPECIFICATIONS CONTRACTOR acknowledges that it is fully familiar with all the terms,conditions and obligations of this Agreement and the Contract Documents (as defined below in this Section), has inspected the location of the job site, and the conditions under which the work is to be performed, and that it enters into this Agreement based upon its thorough investigation of all such matters and is relying in no way upon any opinions or representations of CITY. It is agreed that the Contract Documents are incorporated into this Agreement by this reference, with the same force and effect as if the same were set forth at length herein, and that CONTRACTOR and its subcontractors, if any, shall be bound by the Contract Documents insofar as they relate in part or in any way, directly or indirectly, to the work covered by this Agreement. "Contract Documents" as defined herein mean and include: A. This Agreement; B. Bonds covering the work herein agreed upon; C. The CITY's standard Plans and Specifications and special contractual provisions, including those on file in the office of the Department of Public Works of CITY, and any revisions, amendments or addenda thereto; 2 D. The edition of Standard Specifications for Public Works Construction, published by Builders'News, Inc., 10801 National Boulevard, Los Angeles, CA 90064, and all amendments thereto, written and promulgated by the Southern California chapter of the American Public Works Association and the Southern California District Associated General Contractors of the California Joint Cooperative Committee as specified in the particular Plans, Specifications, Special Provisions and Addendum applicable to the Project; E. Bid documents including the Notice Inviting Bids, the Special Instructions to Bidders and the CONTRACTOR's proposal, (which is attached hereto as Exhibit "A" and incorporated herein by this reference); F. The particular Plans, Specifications, Special Provisions and Addenda applicable to the PROJECT. Anything mentioned in the Specifications and not indicated in the Plans or indicated in the Plans and not mentioned in the Specifications, shall be of like effect as if indicated and mentioned in both. In case of a discrepancy between any Plans, Specifications, Special provisions, or Addenda, the matter shall be immediately submitted by CONTRACTOR to the Director of Public Works of CITY or his or her written designee (hereinafter referred to as "DPW"), and CONTRACTOR shall not attempt to resolve or adjust the discrepancy without the decision of DPW, save only at its own risk and expense. Should there be any conflict between the terms of this Agreement and the bid or proposal of CONTRACTOR, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid or proposal which is in conflict herewith. 3 3. COMPENSATION CITY agrees to pay and CONTRACTOR agrees to accept as full compensation for the faithful performance of this Agreement, subject to any additions or deductions made under the provisions of this Agreement or the Contract Documents, a sum not to exceed One Million Nine Hundred Seventy Thousand Two Hundred Thirty One and 60/100 Dollars ( $1,970,231.60 ), as set forth in the Contract Documents,to be paid as provided in this Agreement. 4. COMMENCEMENT OF PROJECT CONTRACTOR agrees to commence the PROJECT within ten (10)working days after the Notice To Proceed is issued and diligently prosecute the PROJECT to completion within ONE HUNDRED SIXTY ( 160 ) consecutive Working days from the day the Notice to Proceed is issued by DPW, excluding delays provided for in this Agreement. 5. TIME OF THE ESSENCE The parties hereto recognize and agree that time is of the essence in the performance of this Agreement and each and every provision of the Contract Documents. CONTRACTOR shall prepare and obtain approval as required by the Contract Documents for all shop drawings, details and samples, and do all other things necessary and incidental to the prosecution of its work in conformance with the progress schedule set forth in the Contract Documents. CONTRACTOR shall coordinate its work with the work of all other contractors, subcontractors, and CITY forces working on the PROJECT in a manner that will facilitate the efficient completion of the PROJECT and in accordance with the terms and provisions of this Agreement. CITY shall have complete control of the premises on which the work is to be performed and shall have the right to decide the time and order in which the various portions of the work shall be performed and the priority of the work of other contractors, 4 subcontractors and CITY forces and, in general, all matters concerning the timely and orderly conduct of the work of CONTRACTOR on the premises. 6. CHANGES CONTRACTOR shall adhere strictly to the plans and specifications set forth in the Contract Documents unless a change therefrom is authorized in writing by DPW. CONTRACTOR agrees to make any and all changes, furnish materials and perform all work necessary within the scope of the PROJECT as DPW may require in writing. Under no condition shall CONTRACTOR make any changes without the prior written order or acceptance of DPW, and CITY shall not pay any extra charges made by CONTRACTOR that have not been agreed upon in writing by DPW. When directed to change the work, CONTRACTOR shall submit immediately to DPW a written cost proposal reflecting the effect of the change. Should DPW not agree to such cost proposal, the work shall be performed according to the changes ordered in writing by DPW and the proper cost thereof shall be negotiated by the parties upon cost and pricing data submitted by CONTRACTOR; thereupon, CITY will promptly issue an adjusted change order to CONTRACTOR and the contract price will be adjusted upward or downward accordingly. 7. NOTICE TO PROCEED No work, services, material, or equipment shall be performed or furnished under this Agreement unless and until a Notice to Proceed has been given to CONTRACTOR by CITY. CITY does not warrant that the work will be available on the date the Notice to Proceed is issued. In the event of a delay in commencement of the work due to unavailability of the job site, for any reason,relief to CONTRACTOR shall be limited to a time extension equal to the delay due to such unavailability. 5 8. BONDS Only bonds issued by California admitted sureties will be accepted. CONTRACTOR shall, prior to its performance of this Agreement, furnish the following two (2) bonds approved by the City Attorney: One in the amount of one hundred percent (100%) of the contract price to guarantee the CONTRACTOR's faithful performance of the work, and one in the amount of one hundred percent of the contract price to guarantee payment of all claims for labor and materials furnished. In addition, CONTRACTOR shall submit to CITY a bond in the amount of one hundred percent (100%) of the final contract price, including all change orders, to warrant such performance for a period of one (1) year after CITY's acceptance thereof within ten (10) days of filing of the Notice of Completion. 9. WARRANTIES CONTRACTOR unconditionally guarantees all work done under this Agreement including, but not limited to, any workmanship, installation, fabrication, material or structural facilities constructed. CONTRACTOR, within ten (10) days after notice by CITY of any defect in the work, shall have the option to make appropriate repairs or replace the defective item or items. Upon expiration of such ten (10) day period, CITY may then make appropriate repair or replacement at CONTRACTOR's risk and own cost and expense. 10. INDEPENDENT CONTRACTOR It is understood and agreed that CONTRACTOR is, and shall be, acting at all times hereunder as an independent contractor and not an employee of CITY. CONTRACTOR shall secure at its own cost and expense, and be responsible for any and all payment of all taxes, social security, state disability insurance compensation, unemployment compensation and other payroll 6 deductions for CONTRACTOR and its officers, agents and employees and all business licenses, if any, in connection with the PROJECT and/or the services performed hereunder. 11. LIQUIDATED DAMAGES/DELAYS It is agreed by the parties hereto that in case the total work called for hereunder is not in all parts and requirements finished or completed within the number of calendar days as set forth herein, damage will be sustained by CITY; and that it is, and would be, impractical and extremely difficult to ascertain and determine the actual damage which CITY would sustain in the event of and by reason of such delay. It is, therefore, agreed that CONTRACTOR will pay to CITY, as liquidated damages and not as a penalty, the sum of One Thousand and 00/100 ( $1,000 ) per each calendar day's delay in completing the work in excess of the number of working/calendar days set forth herein, which represents a reasonable endeavor by the parties hereto to estimate a fair compensation for the foreseeable damages CITY would sustain in the event of and by reason of such delay; and CONTRACTOR agrees to pay these damages herein provided, and further agrees that CITY may deduct the amount thereof from any monies due or that may become due to CONTRACTOR hereunder. CONTRACTOR will be granted an extension of time and will not be assessed damages for any portion of the delay in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God or of the public enemy, fire, floods, epidemics, quarantine restrictions, strikes, unsuitable weather, or delays of subcontractors due to such causes. CONTRACTOR shall, within fifteen (15) days from the beginning of any such delay(unless DPW shall grant a further period of time), notify DPW in writing of the cause of the 7 delay and CITY shall extend the time for completing the work if, in its judgment, the findings of fact thereon justify the delay; and the decision of DPW shall be conclusive on the parties hereto. Should CONTRACTOR be delayed in the prosecution or completion of the work by the act, neglect or default of CITY, or should CONTRACTOR be delayed by waiting for materials required by this Agreement to be furnished by CITY, or by damage caused by fire or other casualty at the job site for which CONTRACTOR is not responsible, or by the combined action of the workers, in no way caused by or resulting from default or collusion on the part of CONTRACTOR, or in the event of a lockout by CITY, then the time herein fixed for the completion of the work shall be extended by the number of days CONTRACTOR has thus been delayed,but no allowance or extension shall be made unless a claim therefor is presented in writing to CITY within fifteen (15) days of the commencement of such delay. No claims for additional compensation or damages for delays, irrespective of the cause thereof, and including without limitation the furnishing of materials by CITY or delays by other contractors or subcontractors will be allowed and an extension of time for completion shall be the sole remedy of CONTRACTOR. 12. DEMANDS FOR ADDITIONAL TIME OR MONEY. A. Definitions. (1) "Change Order" means a document signed by the CONTRACTOR and CITY which authorizes an addition, deletion or revision in the work, or an adjustment in the Compensation under Section 3, or the Completion Time specified at Section 4. (2) "Demand" means a written demand for a Change Order by the CONTRACTOR for any of the following: (a) A time extension; 8 (b) Payment of money or damages arising from work done by, or on behalf of, the CONTRACTOR pursuant to this Agreement and payment of which is not expressly permitted pursuant to Section 3 of this Agreement; (c) Payment of an amount the CITY disputes; (d) Any disputes and other matters relating to the acceptability of the work performed or the interpretation of the Contract Documents; (e) A request for a time extension or additional payment based upon differing site conditions, such as subsurface or latent physical conditions at the job site differing materially from those indicated in this Agreement or the Contract Documents, or unknown physical conditions at the job site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent to work of the PROJECT; or (f) A request for a time extension or additional payment based upon acts of neglect by CITY or due to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. B. A Demand for a time extension or payment of money or damages may only be granted by a Change Order. C. No Change Order may be granted except where the Contractor has submitted a Demand to the DPW (or his or her written designee). All Demands shall be submitted promptly, but in no event later than thirty(30) days after the occurrence of the event giving rise to the Demand. The Demand shall be in writing and include all documents necessary to substantiate the Demand. The DPW shall act on the Demand within fifteen (15) days after receipt, including by requesting additional information from the CONTRACTOR to determine whether to approve the Change Order the Demand seeks. The DPW shall act on the Demand within fifteen(15) days 9 after receipt of the additional information or within a period of time no greater than the time the CONTRACTOR took to produce the additional information requested, whichever is greater. D. Notwithstanding the thirty (30) days to submit a Demand under Subparagraph C, in the case of differing or unknown site conditions, immediately upon encountering the conditions, CONTRACTOR shall notify the DPW in writing of the conditions, so that the CITY may promptly investigate the conditions. E. If the CONTRACTOR disputes the DPW's written response on the Demand, or the CITY fails to respond within the time prescribed, the CONTRACTOR may so notify the City Engineer,in writing,either within fifteen(15)days of receipt of the City Engineer's response or within fifteen (15) days of the DPW's failure to respond within the time prescribed, respectively, and request an informal conference to meet and confer for settlement of the Demand. Upon the CONTRACTOR's request,the DPW shall schedule a meet and confer conference within thirty (30) days to seek to resolve. F. CITY and CONTRACTOR shall execute appropriate Change Orders covering changes to the time or price by executing the Change Order by mutual agreement. If the CITY and CONTRACTOR are unable to reach a mutual agreement, then the City Engineer shall issue a written decision on the claim within a reasonable time. G. Following the meet and confer conference, if the Demand remains in dispute,the CONTRACTOR may file a claim with the City as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the CONTRACTOR submits his 10 or her Demand until the Demand is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. 13. VARIATIONS IN ESTIMATED QUANTITIES The quantities listed in the bid schedule will not govern final payment. Payment to CONTRACTOR will be made only for the actual quantities of contract items used in construction of the PROJECT, in accordance with the plans and specifications. Upon completion of the PROJECT, if the actual quantities used are either more than or less than the quantities listed in the bid schedule, the bid price shall prevail subject to the provisions of this Section. DPW may, at its sole discretion, when warranted by the facts and circumstances, order an equitable adjustment, upwards or downwards, in payment to CONTRACTOR where the actual quantities used in construction of the PROJECT are in variation to the quantities listed in the bid schedule. No claim by CONTRACTOR for an equitable adjustment in price or time for completion shall be allowed if asserted after final payment under this Agreement. If the quantity variation is such as to cause an increase in the time necessary for completion, DPW shall ascertain the facts and circumstances and make such adjustment for extending the completion date as in its sole judgment the findings warrant. 14. PROGRESS PAYMENTS Each month DPW will make an estimate in writing of the work performed by CONTRACTOR and the value thereof. From each progress estimate, five percent (5%) will be deducted and retained by CITY and the remainder of the progress estimate, less the amount of all previous payments since commencement of the work, will be paid to CONTRACTOR. When CONTRACTOR has, in the judgment of DPW, faithfully executed fifty percent (50%) or more of the value of the work as determined from the bid schedule, and if DPW finds that satisfactory progress has been and is being made, CONTRACTOR may be paid such 11 sum as will bring the payments of each month up to one hundred percent (100%) of the value of the work completed since the commencement of the PROJECT,as determined in its sole discretion by DPW, less all previous payments and less all previous retained amounts. CITY's final payment to CONTRACTOR,if unencumbered, or any part thereof unencumbered, shall be made thirty-five (35) days after the acceptance of the work and the filing of a Notice of Completion by CITY. Provided, however, that in the event of a dispute between CITY and CONTRACTOR, CITY may withhold from the final payment an amount not to exceed 150 percent of the value of any disputed amount of work. Payments shall be made on demands drawn in the manner required by law, each payment to be accompanied by a certificate signed by DPW, affirming that the work for which payment is demanded has been performed in accordance with the terms of the Agreement and that the amount stated in the certificate is due under the terms of the Agreement. Partial payments on the contract price shall not be considered as an acceptance of any part of the work. 15. WITHHELD CONTRACT FUNDS, SUBSTITUTION OF SECURITIES At the request and at the sole cost and expense of CONTRACTOR,who shall retain beneficial ownership and receive interest, if any thereon, CITY shall permit the substitution and deposit therewith of securities equivalent to the amount of any monies withheld by CITY to ensure performance under the terms of this Agreement. 16. AFFIDAVITS OF SATISFACTION OF CLAIMS After the completion of the work contemplated by this Agreement, CONTRACTOR shall file with DPW its affidavit stating that all workers and persons employed, all firms supplying materials and all subcontractors working upon the PROJECT have been paid in full and that there are no claims outstanding against the PROJECT for either labor or material, except certain items,if any,to be set forth in CONTRACTOR's affidavit covering disputed claims, 12 or items in connection with Notices to Withhold, which have been filed under the provisions of the statutes of the State of California. 17. WAIVER OF CLAIMS The acceptance by CONTRACTOR of the payment of the final certificate shall constitute a waiver of all claims against CITY under or arising out of this Agreement. A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 18. CALIFORNIA PREVAILING WAGE LAW A. The CITY has ascertained from the Director of Industrial Relations of the State of California the general prevailing rate of per diem wages and the general prevailing rate for legal holiday and overtime work in the locality in which the work is to be performed for each craft or type of work needed to execute this Agreement, and the same has been set forth by 13 resolution on file in the office of the City Clerk of CITY. CONTRACTOR and any subcontractor under it shall pay not less than said prevailing wage rates to all workers employed on this public works Agreement, as required by California Labor Code Sections 1771 and 1774. In accordance with the provisions of Section 3700 of the California Labor Code, CONTRACTOR agrees to secure payment of compensation to every employee. B. Pursuant to this Agreement and in accordance with Section 1774 and 1775 of the California Labor Code, CONTRACTOR shall, as penalty to CITY, forfeit twenty-five dollars ($25) for each calendar day or portion thereof for each worker paid (either by CONTRACTOR or any of its subcontractors) less than the prevailing wage rate established for that particular craft or type of work. 19. CALIFORNIA EIGHT-HOUR LAW A. California Labor Code, Sections 1810 et seq, shall apply to the performance of this Agreement; thereunder, not more than eight (8) hours shall constitute one day's work and CONTRACTOR and each subcontractor employed by its hereunder, shall not require more than eight (8)hours of labor per day or forty (40) hours per week from any one person employed by it hereunder, except as stipulated in California Labor Code Section 1815. CONTRACTOR and each subcontractor employed by it hereunder shall, in accordance with California Labor Code Section 1812, keep an accurate record, open to inspection at all reasonable hours, showing the name and actual hours worked each calendar day and each calendar week by each worker employed in connection with the PROJECT. B. Pursuant to this Agreement and in accordance with California Labor Code Section 1813, CONTRACTOR shall, as a penalty to CITY, forfeit twenty-five dollars ($25) for each worker employed hereunder by CONTRACTOR or any subcontractor for each calendar day during which such worker is required or permitted to work more than eight (8) hours in any one 14 (1) calendar day or forty (40)hours in any one (1) calendar week in violation of California Labor Code Section 1815. 20. PAYMENT OF TRAVEL AND SUBSISTENCE ALLOWANCE Section 1773.8 of the California Labor Code, regarding the payment of travel and subsistence allowance is applicable to this PROJECT. 21. EMPLOYMENT OF APPRENTICES Section 1777.5 of the California Labor Code, regarding the employment of apprentices is applicable to this PROJECT. 22. PAYROLL RECORDS CONTRACTOR agrees to keep accurate payroll record showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice or worker employed by it in connection with the PROJECT and agrees to require each of its subcontractors to do the same. CONTRACTOR further agrees that its payroll records and those of its subcontractors, if any, shall be available at all reasonable times to the CITY, and the employee or his representative, and the Division of Labor Standards Enforcement and the Division of Apprenticeship Standards, and to comply with all of the provisions of California Labor Code Section 1776, in general. 23. INDEMNIFICATION, DEFENSE, HOLD HARMLESS CONTRACTOR hereby agrees to protect, defend, indemnify and hold harmless CITY, its officers, elected or appointed officials, employees, agents, and volunteers from and against any and all claims, damages, losses, expenses, judgments, demands, defense costs, and consequential damage or liability of any kind or nature, however caused, including those resulting from death or injury to CONTRACTOR's employees and damage to CONTRACTOR's property, 15 arising directly or indirectly out of the obligations or operations herein undertaken by CONTRACTOR, caused in whole or in part by any negligent act or omission of the CONTRACTOR, any subcontractors, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, including but not limited to concurrent active or passive negligence, except where caused by the active negligence, sole negligence, or willful misconduct of the CITY, its officers, elected or appointed officials, employees, agents, and volunteers. CONTRACTOR will conduct all defense at its sole cost and expense and CITY shall approve selection of CONTRACTOR's counsel. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by CONTRACTOR. 24. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Pursuant to California Labor Code Section 1861, CONTRACTOR acknowledges awareness of Section 3700 et seq. of this Code, which requires every employer to be insured against liability for workers' compensation; CONTRACTOR covenants that it will comply with such provisions prior to commencing performance of the work hereunder. CONTRACTOR shall obtain and furnish to City workers' compensation and employer's liability insurance in an amount of not less than the State statutory limits. CONTRACTOR shall require all subcontractors to provide such workers' compensation and employer's liability insurance for all of the subcontractors' employees. CONTRACTOR shall furnish to CITY a certificate of waiver of subrogation under the terms of the workers' compensation and employer's liability insurance and CONTRACTOR shall similarly require all subcontractors to waive subrogation. 16 25. INSURANCE In addition to the workers' compensation and employer's liability insurance and CONTRACTOR's covenant to defend, hold harmless and indemnify CITY, CONTRACTOR shall obtain and furnish to CITY, a policy of general public liability insurance, including motor vehicle coverage covering the PROJECT. This policy shall indemnify CONTRACTOR, its officers, employees and agents while acting within the scope of their duties, against any and all claims arising out or in connection with the PROJECT, and shall provide coverage in not less than the following amount: combined single limit bodily injury and property damage, including products/completed operations liability and blanket contractual liability, of One Million Dollars ($1,000,000) per occurrence. If coverage is provided under a form which includes a designated general aggregate limit,the aggregate limit must be no less than One Million Dollars ($1,000,000) for this PROJECT. This policy shall name CITY, its officers, elected or appointed officials, employees, agents, and volunteers(the"Additionally Insured Parties") as Additional Insureds, and shall specifically provide that any other insurance coverage which may be applicable to the PROJECT shall be deemed excess coverage and that CONTRACTOR's insurance shall be primary and non-contributory with any other valid and collectible insurance or self-insurance available to the Additionally Insured Parties. Any available insurance proceeds in excess of the minimum coverage amount specified herein shall be available to the Additionally Insured Parties. All coverage available to CONTRACTOR shall also be available to the Additionally Insured Parties. Under no circumstances shall said above-mentioned insurance contain a self-insured retention without the express written consent of CITY; however an insurance policy "deductible" of Five Thousand Dollars ($5,000.00) is permitted. CONTRACTOR shall be responsible for causing all Subcontractors to maintain the same types and limits of insurance coverage as that required of CONTRACTOR by this Agreement. 17 26. CERTIFICATES OF INSURANCE; ADDITIONAL INSURED ENDORSEMENTS Prior to commencing performance of the work hereunder, CONTRACTOR shall furnish to CITY certificates of insurance subject to approval of the City Attorney evidencing the foregoing insurance coverages as required by this Agreement; the certificates shall: 1. Provide the name and policy number of each carrier and policy; 2. State that the policy is currently in force; and 3. Promise to provide that such policies will not be canceled or modified without thirty (30) days' prior written notice of CITY. CONTRACTOR shall maintain the foregoing insurance coverages in force until the work under this Agreement is fully completed and accepted by CITY. The requirement for carrying the foregoing insurance coverages shall not derogate from the CONTRACTOR's defense, hold harmless and indemnification obligations as set forth under this Agreement. CITY or its representative shall at all times have the right to demand the original or a copy of all the policies of insurance. CONTRACTOR shall pay, in a prompt and timely manner, the premiums on all insurance hereinabove required. CONTRACTOR shall provide a separate copy of the additional insured endorsement to each of CONTRACTOR's insurance policies, naming CITY, its officers, elected and appointed officials, employees, agents and volunteers as Additional Insureds, to the City Attorney for approval prior to any payment hereunder. 27. NOTICE OF THIRD PARTY CLAIM Pursuant to Public Contracts Code §9202, CITY shall provide notice to CONTRACTOR of receipt of any claim filed with CITY or a court of competent jurisdiction which arises out of performance of this agreement within ten(10)days of receipt of such claim or claims. 18 28. DEFAULT AND TERMINATION If CONTRACTOR fails or refuses to prosecute the work hereunder with diligence, or fails to complete the work within the time specified, or is adjudged bankrupt or makes an assignment for the benefit of creditors or becomes insolvent, or violates any provision of this Agreement or the Contract Documents, CITY may give CONTRACTOR notice in writing of its intention to terminate this Agreement. Unless the violation is cured within ten(10)days after such Notice of Intention has been served on CONTRACTOR, CITY may, without prejudice to any other remedy it may have, terminate this Agreement upon the expiration of that time. Upon such default by CONTRACTOR, CITY may elect not to terminate this Agreement; in such event CITY may make good the deficiency in which the default consists and deduct the resulting costs from the progress payments then or to become due to CONTRACTOR. If it is subsequently determined by a court of competent jurisdiction that CITY's termination of this Agreement under this Section was wrongful, such termination shall be converted to a termination for convenience under Section 29 and any damages shall be assessed as set forth in Section 29. 29. TERMINATION FOR CONVENIENCE CITY may terminate this Agreement for convenience at any time with or without cause, and whether or not PROJECT is fully complete upon seven(7) calendar days written notice to CONTRACTOR. In the event of termination, under this Section CITY shall pay CONTRACTOR for value of work in place on the PROJECT through the termination period less all such payments already made. In case of such termination for convenience,the CONTRACTOR shall be entitled to receive payment for work executed, and costs incurred by reason of such termination. In no event shall CONTRACTOR be entitled to recover overhead, profit or CONTRACTOR's fee on work not performed. Such payment by CITY shall be CONTRACTOR's 19 sole and exclusive remedy for termination by CITY for its convenience and CITY shall have no further obligation to CONTRACTOR. 30. DISPOSITION OF PLANS, ESTIMATES AND OTHER DOCUMENTS CONTRACTOR agrees that upon completion of the work to be performed hereunder, or upon expiration or earlier termination of this Agreement, all original plans, specifications, drawings, reports, calculations, maps and other documents pertaining to this Agreement shall be delivered to CITY and become its sole property at no further cost. 31. NONASSIGNABILITY CONTRACTOR shall not sell, assign, transfer, convey or encumber this Agreement,or any part hereof, or any right or duty created herein,without the prior written consent of CITY and the surety. 32. CITY EMPLOYEES AND OFFICIALS CONTRACTOR shall employ no CITY official nor any regular CITY employee in the work performed pursuant to this Agreement. No officer or employee of CITY shall have any financial interest in this Agreement in violation of the California Government Code. 33. STOP NOTICES., RECOVERY OF ADMINISTRATIVE COSTS CITY shall be entitled to all reasonable administrative costs and necessary disbursements arising out of the processing of Stop Notices, Notices to Withhold, or any similar legal document. This obligation shall be provided for in the labor and materials payment bond required of CONTRACTOR. CITY may charge an administrative fee of One Hundred Dollars ($100)for every Stop Notice filed in excess of two (2),regardless of whether or not CITY is named in an action to enforce such stop notices. CITY may set off any unreimbursed cost or expense so incurred against any sum or sums owed by CITY to CONTRACTOR under this Agreement. 20 34. NOTICES Any notices, certificates, or other communications hereunder shall be given either by personal delivery to CONTRACTOR's agent (as designated in Section 1 hereinabove) or to CITY as the situation shall warrant,or by enclosing the same in a sealed envelope,postage prepaid, and depositing the same in the United States Postal Service, to the addresses specified below; provided that CITY and CONTRACTOR may designate different addresses to which subsequent notices, certificates or other communications will be sent by notifying the other party via personal delivery, reputable overnight carrier or U. S. certified mail-return receipt requested: TO CITY: TO CONTRACTOR: City of Huntington Beach Performance Pipeline Technologies, Inc. ATTN: Michael Aguas ,Public Works ATTN: Gene Glassburner 2000 Main Street 5292 System Dr. Huntington Beach, CA 92649 Huntington Beach, CA 92648 35. SECTION HEADINGS The titles, captions, section, paragraph and subject headings, and descriptive phrases at the beginning of the various sections in this Agreement are merely descriptive and are included solely for convenience of reference only and are not representative of maters included or excluded from such provisions, and do not interpret,define, limit or describe, or construe the intent of the parties or affect the construction or interpretation of any provision of this Agreement. 21 36. IMMIGRATION CONTRACTOR shall be responsible for full compliance with the immigration and naturalization laws of the United States and shall, in particular, comply with the provisions of United States Code Section 1324a regarding employment verification. 37. LEGAL SERVICES SUBCONTRACTING PROHIBITED CONTRACTOR and CITY agree that CITY is not liable for payment of any subcontractor work involving legal services, and that such legal services are expressly outside the scope of services contemplated hereunder. CONTRACTOR understands that pursuant to Huntington Beach City Charter Section 309, the City Attorney is the exclusive legal counsel for CITY; and CITY shall not be liable for payment of any legal services expenses incurred by CONTRACTOR. 38. ATTORNEY'S FEES In the event suit is brought by either party to construe, interpret and/or enforce the terms and/or provisions of this Agreement or to secure the performance hereof, each party shall bear its own attorney's fees, such that the prevailing party shall not be entitled to recover its attorney's fees from the non-prevailing party. 39. INTERPRETATION OF THIS AGREEMENT The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any of the parties. If any provision of this Agreement is held by an arbitrator or court of competent jurisdiction to be unenforceable, void, illegal or invalid, such holding shall not invalidate or affect the remaining covenants and provisions of this Agreement. No covenant or provision shall be deemed dependent upon any other unless so expressly provided here. As used in this Agreement, the masculine or neuter gender and singular or plural number shall be deemed to include the other whenever the 22 context so indicates or requires. Nothing contained herein shall be construed so as to require the commission of any act contrary to law, and wherever there is any conflict between any provision contained herein and any present or future statute, law, ordinance or regulation contrary to which the parties have no right to contract, then the latter shall prevail, and the provision of this Agreement which is hereby affected shall be curtailed and limited only to the extent necessary to bring it within the requirements of the law. 40. GOVERNING LAW This Agreement shall be governed and construed in accordance with the laws of the State of California. 41. DUPLICATE ORIGINAL The original of this Agreement and one or more copies hereto have been prepared and signed in counterparts as duplicate originals, each of which so executed shall, irrespective of the date of its execution and delivery, be deemed an original. Each duplicate original shall be deemed an original instrument as against any party who has signed it. 42. CONSENT Where CITY's consent/approval is required under this Agreement, its consent/approval for one transaction or event shall not be deemed to be consent/approval to any subsequent occurrence of the same or any other transaction or event. 43. SURVIVAL Terms and conditions of this Agreement, which by their sense and context survive the expiration or termination of this Agreement shall so survive. 44. MODIFICATION No waiver or modification of any language in this Agreement shall be valid unless in writing and duly executed by both parties. 23 45. SIGNATORIES Each undersigned represents and warrants that its signature hereinbelow has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify CITY fully for any injuries or damages to CITY in the event that such authority or power is not, in fact, held by the signatory or is withdrawn. 46. ENTIRETY The parties acknowledge and agree that they are entering into this Agreement freely and voluntarily following extensive arm's length negotiation,and that each has had the opportunity to consult with legal counsel prior to executing this Agreement. The parties also acknowledge and agree that no representations, inducements, promises, agreements or warranties, oral or otherwise, have been made by that party or anyone acting on that party's behalf, which are not embodied in this Agreement, and that that party has not executed this Agreement in reliance on any representation, inducement, promise, agreement, warranty, fact or circumstance not expressly set forth in this Agreement. This Agreement, and the attached Exhibit "A", contain the entire agreement between the parties respecting the subject matter of this Agreement, and supersede all prior understandings and agreements whether oral or in writing between the parties respecting the subject matter hereof. 24 IN WITNESS WHEREOF,the parties hereto have caused this Agreement to be executed by and through their authorized officers on JIM\I2J , 20,2i, . CONTRACTOR: CITY OF HUNTINGTON BEACH,a municipal corporation of the State of California By: �' Ma r (print name) ITS: Chairman/President/Vice-President City Clerk (circle one) INITIATED APPROVED: ANI) By: Dire for Public Works (, c c, LAS S bvv ✓ 4' (print name) REVIEWED AND APPROVED: ITS: Secretary / Chief Financial Officer / Asst. Secretary/Treasurer (circle one) City M ager APPROVED AS TO FORM: FA, 1>C/1./N/' ti—City Attorney 25 �X/1/,8f1 4 SECTION C PROPOSAL for the construction of FY 2025/26 SEWER LINING PROJECT CC No. 1845 in the CITY OF HUNTINGTON BEACH TO THE HONORABLE MAYOR AND MEMBERS OF THE COUNCIL OF HUNTINGTON BEACH: In compliance with the Notice Inviting Electronic Bids, the undersigned hereby proposes and agrees to perform all the work therein described, and to furnish all labor,material, equipment and incident insurance necessary therefor,in accordance with the plans and specifications on file in the office of the City Engineer of the City of Huntington Beach. The undersigned agrees to perform the work therein to the satisfaction of and under the supervision of the City Engineer of the City of Huntington Beach, and to enter into a contract at the bid prices provided in the electronic bid form included in Planet Bids. The official bid schedule is provided electronically through the City's PlanetBids system. All bidders shall submit pricing exclusively using the PlanetBids bid form. The PlanetBids bid from is hereby incorporated by reference into these bid documents and shall control for the purposes of bid evaluation and award. Failure to fully complete the PlanetBids bid form shall render the bid non-responsive. The undersigned agrees to complete the work within 160 working days, starting from the date of the Notice to Proceed. BIDDER declares that this proposal is based upon careful examination of the work site, plans, specifications, Instructions to Bidders and all other contract documents. If this proposal is accepted for award,BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the guaranty accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE AGENCY RESERVES THE RIGHT TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all appurtenant expenses, taxes, royalties, fees, etc., and will be guaranteed for a period of sixty days from the bid opening date. If at such time the contract is not awarded, the AGENCY will reject all bids and will readvertise the project. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. c-i If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER, the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option, be considered null and void. Accompanying this proposal of bid,find- 19;11 bon J in the amount of I 0 Y. which said amount is not less than 10% of the aggregate of the total bid price, as required by the Notice Inviting Electronic Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check", or "Bidder's Bond for_% ", as the case may be) Any standard Surety Bid Bond form is acceptable. C-2 If awarded the Contract, the undersigned agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within 10 working days after the date of the AGENCY'S notice of award of contract to the BIDDER,the proceeds of the security accompanying this bid shall become the property of the AGENCY and this bid and the acceptance hereof may, at the AGENCY'S option,be considered null and void. Accompanying this proposal of bid,find bidder's bond for 10% in the amount of $200,000 which said amount is not less than 10%of the aggregate of the total bid price,as required by the Notice Inviting Electronic Bids, payable to the AGENCY. (Please insert the words "Cash", "Certified Check",or"Bidder's Bond for_% ",as the case may be) Any standard Surety Bid Bond form is acceptable. C-2 LIST OF SUBCONTRACTORS In accordance with Government Code Section 4104, the Bidder shall set forth the name and business address of each subcontractor who will perform work or render service to the bidder on said contract in an amount in excess of one-half of one percent of the total bid or $10,000, whichever is greater,and the portion of the work to be done by such subcontractor. Bid Name and Address of State Class DIR PWC Dollar %of Item(s) Subcontractor License Registration# Amount Contract Number Zebron Contracting,Inc. 8»17() C33 1000004993 $171,600 9% 12 PO Box 2874 Newport Beach By submission of this proposal,the Bidder certifies: 1. That he is able to and will perform the balance of all work which is not covered in the above subcontractors listing. 2. That the AGENCY will be furnished copies of all subcontracts entered into and bonds furnished by subcontractor for this project. C-3 NONCOLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on 3/18/26,at_Huntington Beach ,CA Date City State Gene Glassburner , being first duly sworn, deposes and says that he or she is General Manager ofPerformance Pipeline Technologies,Inc the party making the foregoing bid that the bid is not made in the interest of,or on the behalf of,any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham;that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price, or that of any other bidder,or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract;that all statements contained in the bid are true;and,further,that the bidder has not,directly or indirectly,submitted his or her bid price or any breakdown thereof,or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay fee to any corporation,partnership,company association,organization,bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Performance Pipeline Technologies,Inc. Name of Bidder (-"2"446---"" Signature of Bidder 5292 System Drive,Huntington Beach,CA 92649 Address of Bidder • C-4 UTILITY AGREEMENT HONORABLE MAYOR AND CITY COUNCIL CITY OF HUNTINGTON BEACH,CALIFORNIA Gentlemen: The undersigned hereby promises and agrees that in the performance of the work specified in the contract, known as the CC-1845 FY 2025/26 SEWER LINING PROJECT, (I)(we)(it) will employ and utilize only qualified persons, as hereinafter defined, to work in proximity to any electrical secondary or transmission facilities. The term "Qualified Person" is defined in Title 8, California Administrative Code, Section 2700, as follows: "Qualified Person: A person who, by reason of experience or instruction, is familiar with the operation to be performed and the hazards involved." The undersigned also promised and agrees that all such work shall be performed in accordance with all applicable electrical utility company's requirements, Public Utility Commission orders, and State of California Cal-OSHA requirements. The undersigned further promises and agrees that the provisions herein shall be and are binding upon any subcontractor or subcontractors that may be retained or employed by the undersigned, and that the undersigned shall take steps as are necessary to assure compliance by any said subcontractor or subcontractors with the requirements contained herein. Performance Pipeline Technologies, Inc. Contractor ---- - By Gene Glassburner,General Manager Title Date: 3/18/26 • C-5 DISQUALIFICATION QUESTIONNAIRE In accordance with Government Code Section 10162,the Bidder shall complete,under penalty of perjury,the following questionnaire. QUESTIONNAIRE Has the Bidder, any officer of the Bidder or any employee of the Bidder who has a proprietary interest in the Bidder ever been disqualified,removed or otherwise prevented from bidding on or completing a Federal, State or local government project because of a violation of law or a safety regulation? ❑Yes No If the answer is yes,explain the circumstances in the space provided. Note: This questionnaire constitutes a part of the Proposal, and a signature portion of the Proposal shall constitute signature of this questionnaire. C-6 COMPENSATION INSURANCE CERTIFICATE Pursuant to Section 1861 of the State Labor Code,each contractor to whom a public works contract has been awarded shall sign the following certificate. I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract. Performance Pipeline Technologies,Inc. Contractor By Gene Glassburner,General Manager Title Date: 3/18/26 C-7 BIDDER'S INFORMATION BIDDER certifies that the following information is true and correct: Performance Pipeline Technologies,Inc. Bidder Name 5292 System Drive Business Address Huntington Beach CA 92649 City, State Zip (714 )536-7386 GGlassburnerna,Azuria.com Telephone Number Email Address 825824 C-42 State Contractor's License No. and Class 10/9/2003 Original Date Issued 6/30/26 Expiration Date The work site and video CCTV footage of existing sewer lines were inspected by our office in 2022/2023. The following are persons, firms, and corporations having a principal interest in this proposal: The undersigned is prepared to satisfy the Council of the City of Huntington Beach of its ability, financially or otherwise, to perform the contract for the proposed work and improvements in accordance with the plans and specifications set forth. Performance Pipeline Technologies,Inc. Company Name Signature of Bidder Gene Glassburner Printed or Typed Signature C-8 NOTARY CERTIFICATE Subscribed and sworn to before me this (�day of Ch ,202 6 . A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document, to which this certificate is attached, and not the truthfulness,accuracy,or validity of that document. State of CU 1 ) County of c'CW`9 C ) On tv\°•r(AN 011J � before me, A i•i►tr, S ;e-kron(f No 1 ?Vb1' L. Month, Day,and Year Insert Name and Title of Notary personally appeared G J\ to 1\ Yc Ci v1/25 b e c od- Name(s)of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies),and that by his/her/their signature(s)on the instrument the person(s),or the entity upon behalf of which the person(s)acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. _ AtDEN JAMES liWIWER WITNESS my hand and official seal. Commanion12b47694 ,. Notary Public-Ce6lanm ORANGE County My Comm.E�uea FEti 13,2030 Signature Signature of Notary Public (PLACE NOTARY SEAL ABOVE) C-9 Bidder's Project History For the purposes of this project, the bidder shall provide project history of similar work showing at least five (5) years of experience specifically referencing the construction of sanitary sewer lining installation using UV technologies of at least 10,000 linear feet of 8-inch or greater in public right-of-way, calcium cleaning and root removal from sanitary sewer systems, and manhole lining and rehabilitation within public right-of-way. Bidders are encouraged to submit supplemental relevant project history in addition to the projects listed herein. Listed below are the names, address and telephone numbers for three public agencies for which the bidder has performed similar work within the past five years: 1. Please see attached project list for UV CIPP projects,including heavy cleaning,CCTV,grouting. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: 2. Please see attached project list for UV CIPP projects,including heavy cleaning,CCTV,grouting. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: 3. Please see attached project list for UV CIPP projects,including heavy cleaning,CCTV,grouting. Name and Address of Public Agency Name and Telephone No. of Project Manager: Contract Amount Type of Work Date Completed Provide additional project description to show similar work: c-lo Performance Pipeline Technologies 5292 System Drive Huntington Beach,CA.92649 UV References Installing Impreg GL16 Owner: City of Huntington Beach Project Name: Emergency sewer lining Contact: Wastewater Division Supervisor: Mark Birchfield 714 329-2885 Scope: 8"sewer main CIPP-approximately 1,300 L.F under on call services agreement and demonstrations Install Date: 5/22/2018 to present Contract Amount: $70,000 Owner: East Orange County Water District Project Name: Emergency Sewer lining Contact: Wastewater Supervisor,Justin Davis 714 497-8073 Scope: Approximately 1,450 L.F.of 8"sewer main's under emergency contract and demonstrations Install Date: 7/18/2018 to 2020 Contract Amount: $82,400 Owner: City of Anaheim Project Name: La Palma&East St Sewer Rehabilitation Resident Engineer: Kevin Miako 714 765-5100 x 5807 General Contractor: Vasilj,John Gavigan 626 476-6839 Install Date: 10/18/2018 Scope: 15"x 300'CIPP Contract Amount: $45,000 Owner: City of Los Angeles Project Name: Sewers 6(Sewer Rehabilitation) General Contractor: Tomovich Contact: Tom Andrejich 626 688-2544 Scope: 545'of 6"UV Liner Install Date January 2019 Contract Amount: $68,000 Owner: Laguna Sanitary District: Project Name(s): North Trunk Phases 1,2,3,4 Resident Engineer: Kevin Thompson 805 803-8756 Scope of Work: Phase I,21"x 480'Diameter sewer main Phase II,5800'of 21"Diameter sewer main Phase III, 4675 L.F.of 21" Phase IV,4700'L.F. of 21"&24" Install Date(s): Phase I,6/18/2020 Phase II,7-6-21 to 7-23-21 Phase III,3-22 to 4-22 Phase IV, 11-2022 to 11-22-22 Contract Amounts: Phase I,$60,000.00 Phase II,$977,234.41 Phase III,$1,163,420.00 Phase IV,$1,793,779.53 Owner: Cal Trans: Route Project Name: 74 Mile marker 58.10 Resident Engineer: Naan Nguyen 909 821-8164 General Contractor: Ames Construction, Lon Rose 951 666-0613 Scope: 36"x 325'Diameter Storm drain Pipe Install Date: 3/1/2021 Contract Amount: $65,000 Owner: Monterey County Project Name: Monterey County Route 1 Storm Drain Rehab General Contractor: Taylor Jane Construction Contact: John Souza 805 723-5129 Scope of Work: approximately 150'of 24"storm drain pipe Installation Date: Installed 10-26-22 Contract Amount: $25,000 Owner: Orange County Sanitation District Project Name: Orange Western Sub Trunk Scope: Installing 2,280 L.F.21"CIPP Resident Engineer: Dickie Fernandez 714-593-7523 Installation Date: March 2023 Contract Amount: $5,013,918 Owner: City of Los Angeles: Project Name: North Outfall Sewer Unit 30 General Contractor: Mladen Buntich Scope: Install two 42"Double Barrel siphons approx.500 LF Install Date: November 2023 Contract Amount: $651,891 Owner: City of Encinitas Project Name: Moonlight Beach Barrels and Storm Water Repairs Resident Engineer: Greg Gomez 858-223-8468 General Contractor: Beador Construction Company Scope: Install three 72"Storm drain barrels approx.900 LF Install Date: December 2023 Contract Amount: $563,433.70 Owner: Laguna County Sanitary District Project Name: Solomon Creek Rehabilitation Resident Engineer: Kevin Thompson 805-803-8756 Scope: Install approx. 15,000 LF of 8", 10", 12", 15" Install Date: Completed December 2025 Contract Amount: $1,154,388.80 Owner: City of Ontario Project Name: Prologis Grove Wet Utilities,Job 239 Resident Engineer: Daniel Fernandez, Scope: 2,614 LF of 20" Install Date: February—March 2026 Contract Amount: $504,502.00 Bidder's Critical Staff Listed below are the names of the bidders proposed Construction Project Manager,and Superintendent. For each of these critical positions,please list at least three projects for which the critical staff has performed similar work within the last five years. These projects do not have to be under the employment of the bidder of this project.Bidders are encouraged submit supplemental relevant project history in addition to the projects listed herein. 1, Gene Glassburner-please see attached resume Name of proposed Project Manager Telephone No. of proposed Project Manager: 714-350-2131 City of Ontario Prologis Grove Wet Utilities $535,000.00 20"UV CIPP,3,000 LF March 2026 Project Name&Contract Amount Type of Work Date Completed Laguna County Sanitary District Solomon Creek Rehabilitation 8"to 15"UV CIPP, $1.3m chemical grout,heavy cleaning. December 2025 Project Name&Contract Amount Type of Work Date Completed City of Encinitas Moonlight Beach Barrels and Storm Drain Repairs $800,000 72"UV CIPP,900LF,grouting,heavy cleaning December 2023 Project Name&Contract Amount Type of Work Date Completed 2. Jason Gomez-please see attached resume Name of proposed Superintendent Telephone No. of proposed Superintendent: 714-454-4586 City of Ontario Prologis Grove Wet Utilities $535,000.00 20"UV CIPP,3,000 LF March 2026 Project Name&Contract Amount Type of Work Date Completed Laguna County Sanitary District Solomon Creek Rehabilitation 8"to 15"UV CIPP, December 2025 $1.3m chemical grout,heavy cleaning. Project Name&Contract Amount Type of Work Date Completed City of Encinitas Moonlight Beach Barrels and Storm Drain Repairs $800,000 72"UV CIPP,900LF,grouting.heavy cleaning December 2023 Project Name&Contract Amount Type of Work Date Completed C-1 t • ;III _! Appendix Resumes GENE R. GLASSBURNER JR . General Manager 15292 System Drive I Huntington Beach,CA 1714-536-7386 I GGlassburner@azuria.com BACKGROUND I have used my 34 years of experience in the sanitation industry to build and operate a successful trenchless rehabilitation company,striving to exceed customer expectations. At Performance Pipeline Technologies,we have dedication to utilizing the industry's most advanced technology to solve our customers'problems,while maintaining the highest level of product quality and safety standards. SIGNIFICANT EXPERIENCE Performance Pipeline Technologies,Inc I Huntington Beach,CA 2002—Present General Manager&Owner Responsible for managing all phases of the company,including but not limited to project acquisition,estimating, scheduling,procurement,equipment acquisition,employee training and performance. Critically involved in the coordination with clients,subcontractors,owners,vendors,and consultants.Direct management and supervision of Clean&CCTV crews and CIPP field installation crews;providing oversight and project support for safety, production,quality and project management standards. Sancon Technologies,Inc I Huntington Beach,CA 1987—2011 Project Manager&Superintendent Supervised and managed 36 employees. Worked directly with the Foreman on multiple projects to ensure the execution met contract requirements and Owner expectations. Ensured our product quality and safety exceeded industry standards. Responsible for implementation of training of crews. Orange County Sanitation District,Inc I Fountain Valley,CA 1985—1987 Line and Pump Station Maintenance Worker—Level 2 Responsible for cleaning sewer lines ranging from 48"to 108"in diameter. Operated high velocity flush trucks and balling machines. Repaired and replaced sewage pumps. Cleaned wet wells of debris LICENSES & CERTIFICATIONS NAASCO Certificate#U304-1120 CA Contractor's License C-42#825824/HIC Certificate Confined Space Entry Certificate Commercial Driver's License CPR Training Certificate Supervisory Training(DOT CFR)Substance Abuse/Alcohol Misuse Certificate First Aid Training and Certificate Performance Pipeline Technologies Inc. 5292 System Drive,Huntington Beach CA 92649 State Contractor's License:825824 C-42 DIR Registration Number. 1000561121 JASON GOMEZ Operations Manager 15292 System Drive I Huntington Beach,CA 1714-454-4586 I JGomez@azuria.com BACKGROUND With 30+years of trenchless rehabilitation experience,I have helped build Performance Pipeline into a safe and successful trenchless rehabilitation company,specializing in CIPP,Cleaning,CCTV. SIGNIFICANT EXPERIENCE Performance Pipeline Technologies,Inc I Huntington Beach,CA 2006—Present Operations Manager&Superintendent Specialized in CIPP Lining systems,Cleaning,and CCTV Implement Training for all employees Manage 25+Field Employees. Worked directly with City Inspectors in completing projects successfully. AST I Glendale,CA 2004-2006 Superintendent Supervised 16 employees Worked directly with foreman in the completion of projects Implemented training course for new employees Sancon Technologies,Inc I Huntington Beach,CA 2000-2004 Superintendent Lead workers directly with supervisors in completing projects. In charge of a 5 man crew's daily installations and activities Worked directly with City Inspectors in completing projects Hydro Chem I Dallas,TX 1990-2000 Foreman • Managed Daily Operations for 3-man Clean&CCTV crew LICENSES 8c CERTIFICATIONS 1. NAASCO Certified#U 805-2424(MACP,LACP,PACP,CIPP) 2. Confined Space Entry 3. Commercial Driver's License 4. CPR Training Certificate 5. First Aid Certificate SKILLS CIPP Specialist,Strong Leadership,Excellent Communication,Safety-Oriented,Problem-Solver,Strong Attention to Details,Goal-Drive. Performance Pipeline Technologies Inc. 5292 System Drive,Huntington Beach CA 92649 State Contractor's License:825824 C-42 DIR Registration Number.1000561121 CONTRACTOR REGISTRATION WITH CALIFORNIA DEPARTMENT OF INDUSTRIAL RELATIONS (DIR) CERTIFICATE Pursuant to SB 854 (citing Labor Code Section 1771.1(a)),passed by the California State Senate on June 20,2014,established a new public works Contractor Registration Program,which requires all contractors and subcontractors bidding and performing work on Public Works Projects to register on an annual basis (each July 1 through June 30 state fiscal year) with the California Department of Industrial Relations(DIR).Currently the annual non-refundable registration fee for Contractors is $300. Each contractor to whom a public works contract has been awarded shall sign the following certificate. DIR FACT SHEET on SB 854 http://www.dir.ca.gov/DLSE/PublicWorks/SB854FactSheet 6.30.14.pdf DIR's Contractor Registration Link—Call(844)522-6734 https://efiling.dir.ca.gov/PWCR/ActionServlet?action=displayPWCRegistrationForm DIR's Contractor Registration searchable database: https://efiling.dir.ca.gov/PWCR/Search.action I am aware and will comply with the provisions of Labor Code Section 1771.1(a)which states: "A contractor or subcontractor shall not be qualified to bid on,be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded." I furthermore will comply by providing proof of registration with DIR as the primary contractor, as well as for ALL subcontractors at the time of submitting the bid. Performance Pipeline Technologies.Inc. Contractor By GGlassburner@Azuria.com Email Gene Glassburner.General Manager Title Date: 3/18/26 PWC Registration#: 1000561121 C-12 CONTRACTOR'S SWORN STATEMENT AND WARRANTY REGARDING CONTINUING INSURANCE OBLIGATIONS FROM: ? hi&M lit -Jc PROJECT: rS 7.0Lc (Contractor Name) S-c'..it✓ L�� .. Nc C C �`t5 .SZ9t SyStTM -0/, J (Street Address) --�l7, CA. ''Z('` 9 (City, State, Zip Code) TO: CITY OF HUNTINGTON BEACH DECLARATION Attached hereto is a true and correct copy of the current Certificate of Insurance and Additional Insured Endorsement CG 2010 1185, which Certificate complies with the insurance requirements of the Contract by and between the City of Huntington Beach ("City") and the above-named Contractor ("Contractor")for the above-described project("Project"). I declare under penalty of perjury under the laws of the State of California that the above statement is true and correct. Signed on Sf- 2O , 20 24 , at 'PI LA _ ' 2-G / (Date) (City, State) (Signature of Individual Who is Making Declaration) WARRANTY Contractor hereby warrants and agrees to maintain Products and Complete Operations Insurance in compliance with the insurance requirements of the Contract for the Project. Said insurance shall be maintained through and until the expiration of all Warranties provided by the Contractor. Said insurance shall contain Additional Insured Endorsement CG 2010 1185, naming the City as an additional insured. Contractor shall supply to the City, on at least an annual basis, a Certificate of Insurance and the aforementioned Endorsement evidencing continued coverage which meets the Contract requirements. c c Signed on " 20 , 202 , at /dig CA• (Date) (City, State) CONTRACTOR: 11 Name: ?�VfArivw1 : z ?,Ct �JL "VW TJJL . By: C�- Name: CIC_ CPA SS b(..:✓-r-c.✓' Title: C.DtvLi1` J✓1"wAc, Ceit/ Je-K ,- l ® DATE(MM/DD/YYYY) ACc RO CERTIFICATE OF LIABILITY INSURANCE 7/1/2026 5/6/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. IF SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Locklon Companies,LI.C NAMEACT 013A Lockton Insurance Brokers,LLC in CA PHONE FAX CA license kOF15767 (NC.No.Ext) (NC,No): E-MAIL Three City Place Dr.,Ste.900 ADDRESS: St.Louis MO 63 14 1-708 1 INSURER(S)AFFORDING COVERAGE NAIC II (314)432.0500 midwestcertifrcales@lockton.com _ INSURER A:XL Insurance America,Inc. 24554 INSURED perfommncc Pipeline Technologies,Inc. INSURER B:ACE American Insurance Company 22667 1347989 5292 System Dr INSURER C:ACE Fire Underwriters Insurance Company 20702 Huntington Beach CA 92649 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 21262577 REVISION NUMBER: XXXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR UE TYPE OF INSURANCE ADDL SR _-- POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER (MM/DD/YYYY) IMM/DDIYYYY) A X COMMERCIAL GENERAL LIABILITY Y N CGD300084910 7/1/2025 7/1/2026 EACH OCCURRENCE $ 2,000,000 CW 1,1S-A1ADE X OCCUR PD/CONTRACTUAL TO RENTED A BROAD FORM PD/CONTRACTUAL PREMISES] pmrence) ,$ 1,000,000 X Independt Contractor MED EXP(Any one person)_ S 10,000 X XCU PERSONAL&ADV INJU_R_Y S 2,000,000 GENL AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE _ S 4,000,000 POLICY[X JEC X LOC PRODUCTS-COMP/OP AGG s 4,000,000 OTHER 0 $ B AUTOMOBILE LIABILITY Y N ISAH11428551 7/1/2025 7/1/2026 COMBINED SINGLE LIMIT $ (Ea accident) 5,000,000 X ANY AUTO BODILY INJURY(Per person) $ XXXXXXX__ OWNED ^SCHEDULED BODILY INJURY(Per accdent) $ AUTOS ONLY _ AUTOS XXXXXXX HIRED NON-OWNED PROPERTY DAMAGE $ XXXXXXX AUTOS ONLY ^ AUTOS ONLY (Per accident) $ XXXXXXX UMBRELLA LIAB OCCUR NOT APPLICABLE EACH OCCURRENCE S XXXXXXX EXCESS LIAR CLAIMS-MADE AGGREGATE S XXXXXXX DED I I RETENTIONS S XXXXXXX WORKERS COMPENSATION N \VLRC7309740A(AOS) 7/1/2025 7/1/2026 X I STATUTE I I ERH B AND EMPLOYERS'LIABILITY C ANY PROPRIETORJPARTNERIEXECUTIVE YIN SCFC73097447(\rl) 7/1/2025 7/1/2026 E.L.EACH ACCIDENT $ 1,000,000 C OFFICERf,IEMBER EXCLUDED? n N IA (EXCLUDING MONOPOLISTIC (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE 5 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT S 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached II more space Is required) THIS CERTIFICATE SUPERSEDES ALL PREVIOUSLY ISSUED CERTIFICATES FOR THIS HOLDER,APPLICABLE TO THE CARRIERS LISTED AND THE POLICY TERM(S)REFERENCED. The City of Huntington Beach,its officers,elected or appointed officials,employees,agents and volunteers arc additional insurOp.0�gr, �) ty pnd Autom 'le Liability on a primary and non-contributory basis where required by written contract executed prior to loss,but only with respect to h alItliO{ eo (TritdR d Is ed's operations. BBL—__ MICHAEL J. VIGLIOTTA CITY ATTORNEY CITY OF HUNTINGTON BEACH CERTIFICATE HOLDER CANCELLATION See Attachments SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 21262577 THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of I I)tlitington Beach 2000 Main Street Huntington Beach CA 92648 AUTHORIZED REPRESENTAT - I ©1988- CORD CORPORAT N. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD Attachment Code: D680367 Certificate ID:21262577 POLICY NUMBER: CGD300084910 COMMERCIAL GENERAL LIABILITY CG 20 10 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations CITY OF HUNTINGTON BEACH ITS OFFICERS, VARIOUS AS REQUIRED PER THE WRITTEN ELECTED OR APPOINTED OFFICIALS, EMPLOYEES, CONTRACT AGENTS AND VOLUNTEERS Information required to complete this Schedule. if not shown above,will be shown in the A. Section II—Who Is An Insured is amended to B.With respect to the insurance afforded to these include as an additional insured the person(s)or additional insureds, the following additional organization(s)shown in the Schedule, but only exclusions apply: with respect to liability for"bodily injury", "property This insurance does not apply to"bodily injury"or damage"or"personal and advertising injury" "property damage"occurring after: caused, in whole or in part, by: 1. Your acts or omissions; or 1.All work, including materials, parts or equipment furnished in connection with such 2. The acts or omissions of those acting on your work, on the project(other than service, behalf; maintenance or repairs)to be performed by or in the performance of your ongoing operations for on behalf of the additional insured(s)at the the additional insured(s) at the location(s) location of the covered operations has been designated above. completed; or However: 2. That portion of"your work"out of which the injury 1. The insurance afforded to such additional or damage arises has been put to its intended insured only applies to the extent permitted by use by any person or organization other than law; and another contractor or subcontractor engaged in performing operations for a principal as a part of 2. If coverage provided to the additional insured is the same project. required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 10 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 2 Attachment Code: D680367 Certificate ID:21262577 C. With respect to the insurance afforded to these 2. Available under the applicable limits of additional insureds, the following is added to insurance; Section III—Limits Of Insurance: whichever is less. If coverage provided to the additional insured is This endorsement shall not increase the applicable required by a contract or agreement, the most we limits of insurance. will pay on behalf of the additional insured is the amount of insurance: '1. Required by the contract or agreement; or Page 2 of 2 ©Insurance Services Office, Inc., 2018 CG 20 10 12 19 Attachment Code: D680367 Certificate ID: 21262577 POLICY NUMBER: CGD300084910 COMMERCIAL GENERAL LIABILITY CG 20 37 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organizations) Location And Description Of Completed Operations CITY OF HUNTINGTON BEACH ITS OFFICERS, VARIOUS AS REQUIRED PER THE WRITTEN ELECTED OR APPOINTED OFFICIALS, EMPLOYEES CONTRACT AGENTS AND VOLUNTEERS Information required to complete this Schedule, if not shown above,will be shown in the A. Section II—Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s)or additional insureds, the following is added to organization(s) shown in the Schedule, but only Section III—Limits Of Insurance: with If coverage provided to the additional insured is respect to liability for'"bodily injury' or'"property required by a contract or agreement, the most we damage"caused, in whole or in part, by"your work" will pay on behalf of the additional insured is the at the location designated and described in the amount of insurance: Schedule of this endorsement performed for that additional insured and included in the"products- 1. Required by the contract or agreement; or completed operations hazard". 2.Available under the applicable limits of However: insurance; 1. The insurance afforded to such additional whichever is less. insured only applies to the extent permitted by This endorsement shall not increase the applicable law; and limits of insurance. required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 37 12 19 ©Insurance Services Office, Inc., 2018 Page 1 of 1 Attachment Code: D544796 Certificate ID:21262577 ENDORSEMENT# This endorsement, effective 12:01 a.m., 7/1/2025, forms a part of Policy No. CGD300084910 issued to AZURIA WATER SOLUTIONS, INC. By XL Insurance America, Inc. THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY INSURANCE CLAUSE ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS COVERAGE PART It is agreed that to the extent that insurance is afforded to any Additional Insured under this policy, this insurance shall apply as primary and not contributing with any insurance carried by such Additional Insured, as required by written contract. All other terms and conditions of this policy remain unchanged. XIL 424 0605 ©, 2005, XL America, Inc. Attachment Code: D680367 Certificate ID: 21262577 ENDORSEMENT#153 This endorsement, effective 12:01 a.m., November 5, 2025, forms a part of Policy No. CGD300084910 Issued to AZURIA WATER SOLUTIONS, INC. by XL Insurance America, Inc. THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CANCELLATION NOTIFICATION TO OTHERS ENDORSEMENT In the event coverage is cancelled for any statutorily permitted reason, other than nonpayment of premium, advanced written notice will be mailed or delivered to person(s)or entity(ies)according to the notification Number of Days Name of Person(s)or Entity(ies) Mailing Address: Advanced Notice of Cancellation: CITY OF HUNTINGTON BEACH ITS 30 DAYS OFFICERS, ELECTED OR APPOINTED OFFICIALS, EMPLOYEES,AGENTS AND VOLUNTEERS All other terms and conditions of the Policy remain unchanged. IXI 405 0910 ©2010 X.L. America, Inc. All Rights Reserved. PERFORMANCE BOND Bond #30249305 KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, City of Huntington Beach (hereafter referred to as "City") has, by written agreement dated ( - 21-k b -2.. , 20 2-5--2O entered into a contract with Performance Pipeline Technologies, Inc., 5292 System Dr., Huntington Beach, CA 92649 (Contractor's Name and Address) (hereafter referred to as "Principal")for performance of the work described as follows: FY 2025/2026 Sewer Lining Project/Project Consists of 29,850 LF of 8", 10", 12", and 15" Diameters CIPP and Manhole Rehabilitation (Project Title) WHEREAS, said contract, and all documents referenced therein (hereinafter collectively "Contract"), are incorporated herein by this reference made a part hereof as though set forth herein in full; and Said Principal is required under the terms of the Contract to furnish a bond guaranteeing the prompt, full and faithful performance of said Contract, by a duly admitted surety insurer under the laws of the State of California (hereinafter referred to as "Surety"); and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and has provided proof of sufficient bonding limitations as shown in said circular to provide bonds in the amount required by said Contract; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's, or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety is registered and listed with the California Department of Insurance, NOW, THEREFORE, we, the undersigned, as Principal, and Western Surety Company, 151 N. Franklin St., Chicago, IL 60606 (Surety's Name and Address) as Surety, are held and firmly bound unto City in the penal sum of One Million Nine Hundred Seventy Thousand Two Hundred Thirty One &60/100 Dollars ($ 1,970,231.60 ), this amount being not less than one hundred percent of the price set forth in the Contract, in lawful money of the United States, for the payment of which sum, well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors,jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the Principal shall promptly, fully and faithfully perform each and all of the covenants, obligations and things to be done and performed by the Principal in strict accordance with the terms of the Contract as said contract may be altered, amended or modified from time to time; and if the Principal shall indemnify and save harmless City and all of City's officers, agents and employees (hereinafter collectively referred to as "Obligees") from any and all losses, liability and damages, claims, judgments, stop notices, fees and costs of every description, whether imposed by law or in equity, which may be incurred by the Obligees by reason of the failure or default on the part of the Principal in the performance of any or all of the terms or the obligations of the Contract, including all alterations, amendments and modifications thereto, and any warranties or guarantees required thereunder, then this obligation shall be void; otherwise, it shall be and shall remain in full force and effect. Surety stipulates and agrees, for value received, that no adjustment of the time or price in the Contract or any alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, shall in any way affect, limit, restrict, impair or release the obligations of the Surety under this Bond. Surety waives notice of any adjustment of contract or contract price, and any other alteration, change, deletion, addition or other modification to the Contract, or the work to be performed thereunder, and agrees to automatically adjust the penal sum of this Bond to reflect such adjustments, alterations, changes, deletions, additions or other modifications. Surety agrees to provide written confirmation of such adjustments in the penal sum to City on not less than a quarterly basis. Surety also waives the provisions of Civil Code §§ 2845 and 2849. 15-4584/117174 Page 1 of 2 Bond No. 30249305 The obligations of this Bond shall survive the completion of the work described in the Contract as to all obligations and liabilities of the Principal which survive completion of the work. IN WITNESS WHEREOF, each party represents and warrants that this instrument has been duly executed by Principal and Surety, on the date set forth below, that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond, waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: 2L ATTEST [Corporate Seal] Performance Pipeline Technologies, Inc. (Principal Name) By: Name: Gene Glassburner Title: General Manager ATTEST [Corporate Seal] Western Surety Company (Surety Name) By: Name: Andrew P. Thome, Attorney-in-Fact (Signature of Attorney-in-Fact for Surety) (312) 822-5000 (Attach Attorney-in-Fact Certificate) (Area Code&Telephone Number for Surety) APPROVED S TO FORM; ' By I r • - • - Michael J. Vigliotta, City Attorney NOTES:This bond must be executed in duplicate and dated,all signatures must be notarized, and evidence of the authority of any person signing as attorney-in-fact must be attached. 15-4584/117174 Page 2 of 2 PERFORMANCE BOND CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California County of Orange n Vivi Goenawan, Notary Public On u vvt 2 3. before me, U Date Here Insert Name and Title of the Officer personally appeared GoAe Glass-u-rvuzir Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the fore oin ragraph is true and correct. WITNESS my hand and official se I. VIVI GODOAN Commission#2408442- Signature c : +�:. Notary ORNPublic County Signature of Notary Public ���j ORANGE County My Comm.E*es JULY 15,"2026 Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Doc M Document _ Title or Type of Document: R-ar�a "cil^ C.e 1 n�v`-c,1 # 3 o L U z 0 5 Document Date: G 1 2`�l '7�2 6 Number of Pages: z Signer(s) Other Than Named Above: f� PAYMENT BOND (LABOR AND MATERIAL) Bond# 30249305 KNOW ALL PERSONS BY THESE PRESENTS: WHEREAS, City of Huntington Beach (hereafter referred to as"City") has awarded to Performance Pipeline Technologies, Inc. 5292 System Dr., Huntington Beach, CA 92649 (Contractor's Name and Address) (hereafter referred to as "Principal"), a contract("Contract") for the work described as follows: FY 2025/2026 Sewer Lining Project/Project Consists of 29,850 LF of 8", 10", 12", and 15" Diameters CIPP and Manhole Rehabilitation (Project Title) WHEREAS, Principal is required under the terms of the Contract and the California Civil Code to furnish a bond to secure the payment of claims of laborers, mechanics, materialmen, and other persons as provided by law, by a duly admitted surety insurer under the laws of the State of California (hereinafter referred to as "Surety"), and Surety is certified and listed in the U.S. Department of the Treasury Circular 570, and has provided proof of sufficient bonding limitation, as shown in said circular to provide bonds in the amount required by said Contract; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety has provided financial strength ratings from reputable companies, such as from A.M. Best, Moody's, or Standard & Poor's, to validate that Surety has positive ratings of being secure or stable; and Surety is registered and listed with the California Department of Insurance, NOW, THEREFORE, we, the undersigned, as Principal, and Western Surety Company, 151 N. Franklin St., Chicago, IL 60606 (Surety's Name and Address) as Surety, are held and firmly bound unto City in the penal sum of One Million Nine Hundred Seventy _ Thousand Two Hundred Thirty One &60/100 Dollars ($ 1,970,231.60 ), this amount being not less than one hundred percent (100%) of the total price set forth in the Contract, in lawful money of the United States of America,for the payment of which sum, well and truly to be made, we bind ourselves, and each of our heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT, if the Principal, his, her, or its heirs, executors, administrators, successors or assigns, or subcontractors shall fail to pay any of the persons named in Section 3181 of the California Civil Code("Claimants")for all labor, materials or services used or reasonably required for use in performance of the work described in the Contract, or any amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such Claimant, or prevailing wages due and penalties incurred pursuant to Sections 1774, 1775, 1813 or 1815 of the Labor Code, or any amounts required to be deducted,withheld and paid over to the Employment Development Department from the wages of employees of the Principal and Subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to the work or labor performed under the Contract, Surety will pay for the same, in an amount not exceeding the penal sum specified in this bond; otherwise, this obligation shall be null and void. This bond shall inure to the benefit of any of the persons named in Section 3181 of the California Civil Code so as to give a right of action to such persons or their assigns. In case any action is brought upon this bond, Surety further agrees to pay all court costs and a reasonable attorney's fee in an amount fixed by the court. 15-4584/117357 Page 1 of 2 Surety stipulates and agrees, for value received, that no change, extension of time, alteration, addition or modification to the terms of the Contract,or any contract document or any work to be performed thereunder, whether made after notice or not, shall in any way affect, impair or release the obligations of Surety under this bond. Surety hereby waives notice of any such change, extension of time, alteration, addition, or modification to the terms of the Contract,the contract documents or the work thereunder. Surety also waives the provisions of California Civil Code§§2845 and 2849. IN WITNESS WHEREOF, each party represents and warrants that this instrument has been duly executed by Principal and Surety, on the date set forth below, that the name of each corporate party being affixed hereto is such party's proper legal name and that the individuals signing this instrument have been duly authorized pursuant to the authority of its governing body. Surety, by execution of this bond, waives any defense which Surety has or may have by reason of any failure of the Principal to execute or properly execute this bond. Dated: (.9 1L1 EC. ATTEST [Corporate Seal] Performance Pipeline Technologies, Inc. (Principal Name) By: - r� -- Name: Gene Glassburner Title: General Manager ATTEST [Corporate Seal] Western Surety Company (Surety Name) By: (�Name: Andrew P. Thome,Attorney-in-Fact (Signature of Attorney-in-Fact for Surety) (312) 822-5000 (Attach Attorney-in-Fact Certificate) (Area Code&Telephone Number for Surety) APPROVED S TO FORM: By: \ . Michael J.Vigliotta, City Attorney Note: This bond must be executed in duplicate and dated, all signatures must be notarized, and evidence of the authority of any person signing as attorney-in-fact must be attached. 15-4584/117357 Page 2 of 2 PAYMENT BOND CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy, or validity of that document. State of California ) • County of Orange On al.)-v•-(2_ 2`f% 2"62-‘ before me, Vivi Goenawan, Notary Public Date Here Insert Name and Title of the Officer personally appeared ci�2 GkRS S`puc i&or • Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies),and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the fo going aragraph is true and correct. 0Vivi GO�NAWAN WITNESS my hand and official s al. �. Commission N 2408442 _4 1� Notary Public-California '� ORANGE County My Comm.Expires JULY 15,202 Signature ` "^"" Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Docum t -� "" Title or Type of Document: V Motif r 1�,���v`-d` 302- 4 Of Document Date: C, J 2-q/ ?-0 2 6 Number of Pages: Signer(s) Other Than Named Above: 95 • • State of Missouri County of St. Louis On 06/18/2026, before me, a Notary Public in and for said County and State, residing therein, duly commissioned and sworn, personally appeared Andrew P. Thome known to me to be Attorney-in-Fact of WESTERN SURETY COMPANY the corporation described in and that executed the within and foregoing instrument, and known to me to be the person who executed the said instrument in behalf of said corporation, and he duly acknowledged to me that such corporation executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal, the day and year stated in this certificate above. coftivatii Christina A. Culotta, Notary Public CHRISTINA A.CULOTTA Notary Public- Notary Seal STATE OF MISSOURI St. Louis County My Commission Expires:Aug.5,2027 Commission# 18313442 My Commission Expires: ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. Missouri State of&alifernis- County of St. Louis On June 18, 2026 before me, Dana A. Johnessee, Notary Public (insert name and title of the officer) personally appeared Andrew P. Thome, Attorney-in-Fact who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. DANA A JOHNESSEE WITNESS my hand and official seal. NotaryPublic-NotarySeal STATE OF MISSOURI St,Louis County My Commission Expires:Sep.2O,2029 n ` Commission N 13516439 Signature f/�; T 4Vf 11 / (Seal) ana A. Johnessee, Notary Public Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents,That WESTERN SURETY COMPANY,a South Dakota corporation,is a duly organized and existing corporation having its principal office in the City of Sioux Falls,and State of South Dakota,and that it does by virtue of the signature and seal herein affixed hereby make,constitute and appoint Dana A Johnessee, Andrew P Thome, Michael D Wiedemeier, Amanda Williams, Andrea McCarthy, Donna Robson, Ashley Miller,Christina A Culotta,Blake Messer,Ivy Lowery,Individually of Chesterfield,MO, its true and lawful Attorney(s)-in-Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature -In Unlimited Amounts— and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given,are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the Authorizing By-Laws and Resolutions printed at the bottom of this page,duly adopted,as indicated,by the shareholders of the corporation. In Witness Whereof,WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 29th day of September,2025. .1Ylll. IVEPP44, WESTERN SURETY COMPANY .2-3-71,9 orrgrF y W:4_ ZE aC Larry Kasten,Vice President State of South Dakota f ss County of Minnehaha On this 29th day of September,2025,before me personally came Larry Kasten,to me known,who,being by me duly sworn,did depose and say: that he resides in the City of Sioux Falls,State of South Dakota;that he is a Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation;that the seal affixed to the said instrument is such corporate seal;that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority,and acknowledges same to be the act and deed of said corporation. My commission expires S M.BENT 'A w 5E�L NOTARY PUBLIC March 2,2026 SOUTH DAKOTAdi2"1*-11-- M.Bent,Notary Public CERTIFICATE I,Paula Kolsrud,Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force,and further certify that the By-Laws and Resolutions of the corporation printed below this certificate are still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this day of , YYY WII h �• �gErrc`+ WESTERN SURETY COMPANY _fir'. o,k tifc? oRgr y ° i Gt_JAP),. Oat fr'k�TH"pP�1�.� Paula Kolsrud,Assistant Secretary �41nMYY" Authorizing By-Laws and Resolutions ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By-Law duly adopted by the shareholders of the Company. Section 7. All bonds,policies,undertakings,Powers of Attorney,or other obligations of the corporation shall be executed in the corporate name of the Company by the President,Secretary,and Assistant Secretary,Treasurer,or any Vice President,or by such other officers as the Board of Directors may authorize. The President,any Vice President, Secretary, any Assistant Secretary,or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. This Power of Attorney is signed by Larry Kasten,Vice President,who has been authorized pursuant to the above Bylaw to execute power of attorneys on behalf of Western Surety Company. This Power of Attorney may be signed by digital signature and sealed by a digital or otherwise electronic-formatted corporate seal under and by the authority of the following Resolution adopted by the Board of Directors of the Company by unanimous written consent dated the 27'"day of April,2022: "RESOLVED:That it is in the best interest of the Company to periodically ratify and confirm any corporate documents signed by digital signatures and to ratify and confirm the use of a digital or otherwise electronic-formatted corporate seal,each to be considered the act and deed of the Company." Go to www.cnasuretv.com>Owner/Obligee Services>Validate Bond Coverage,if you want to verify bond authenticity. Form F4250-62023 / , �0NTI.... CITY OF 3 __, HUNTINGTON BEACH - -r•=�Q couNT(O f" Lisa Lane Barnes City Clerk July 10, 2026 Performance Pipeline Technologies, Inc. Attn: Gene Glassburner 5292 System Drive Huntington Beach, CA 92649 Re: FY 2025-26 Sewer Lining Project, CC1845 The City Council awarded the bid to your company for the above referenced project. Enclosed is a copy of the executed contract with the City of Huntington Beach. A Certification of Compliance with Title VII of the Civil Rights Act, Certification of Compliance with Prevailing Wage Laws and Contractor's Certificate form must be returned to this office after the project is completed but prior to the release of retention funds. In addition, the following item must also be on file, with this office before the City can release any retention funds: A warranty bond guaranteeing the final amount of work and materials for one year. If your performance bond does not include specific wording for a one-year warranty, then a rider or separate bond must be submitted. Should you have any questions or concerns regarding the enclosures or items that must be on file in this office prior to release of retention funds, please call the Public Works Department at 714-536-5517. Sincerely, Donna Switzer Senior Deputy City Clerk Enclosures Office: (714) 536—5405 I 2000 Main Street, Huntington Beach, CA 92648 I vwvw.huntingtonbeachca.gov Switzer, Donna From: Gene Glassburner <gglassburner@azuria.com> Sent: Friday, July 10, 2026 10:23 AM To: Aguas, Michael Cc: Adrian Padilla; Dustin Zeier; Bannon, Patrick; Fait, David; Mark Lewis; Switzer, Donna Subject: RE: Executed Construction Contract - CC1845 FY 2025-26 Sewer Lining Received,Thanks Michael. We look forward to starting this project with you. Thank you, Gene Glassburner General Manager Performance Pipeline Technologies Inc 5292 System Drive Huntington Beach CA 92649 Office: 714-536-7386 111 l From:Aguas, Michael<Michael.Aguas@surfcity-hb.org> Sent: Friday,July 10, 2026 10:02 AM To: Gene Glassburner<gglassburner@azuria.com> Cc:Adrian Padilla <apadilla@azuria.com>; Dustin Zeier<dzeier@azuria.com>; Bannon, Patrick <Patrick.Bannon@surfcity-hb.org>; Fait, David <David.Fait@surfcity-hb.org>; Mark Lewis<mlewis@ardurra.com>; Switzer, Donna <Donna.Switzer@surfcity-hb.org> Subject: [EXTERNAL] Executed Construction Contract-CC1845 FY 2025-26 Sewer Lining Good morning Gene, Please find attached the fully executed construction contract for the FY 2025-26 Sewer Lining Project. The City looks forward to getting this project started and partnering with Performance Pipeline Technologies. Please confirm receipt of the contract for the City Clerk Records Gene. Respectfully, 1 Michael Aguas ,jilIPPRV_, Capital Projects Administrator Public Works Engineering—Utilities -• . , Phone: (714)375-5011 Cell: (657)531-9761 Michael.Aquas onsurfcity-hb.orq EB © © 0 2000 Main Street,Huntington Beach,CA 92648 Azuria Disclaimer This email and any files transmitted with it are confidential and intended solely for the use of the individual or entity to whom they are addressed. If you are not the named addressee you should not disseminate,distribute, retain,or copy this e-mail or any attachments. If you have received this email in error, please delete and notify the sender. At Azuria,we care about your privacy and have taken appropriate measures to ensure that the data you have provided to us is secure.To learn more about how we comply with privacy laws and,as a result,care for the security and privacy of personal data we collect from you,visit this page to view our privacy policies and notices. Azuria.com 2 RECEIVED BY: CITY CLERK RECEIPT COPY Return DUPLICATE to City Clerk's Office (Name) after signing/dating (Date) CITY OF HUNTINGTON BEACH INTERDEPARTMENTAL COMMUNICATION TO: City Treasurer FROM: City Clerk DATE: J 12.(.40 SUBJECT: Bond Acceptance I have received the bonds for Ve+IfYleitflAPIj Q1 i IMin7Ir A) I . (C3mpany Name) O CAPITAL PROJECTS (Includes CC's and MSC's) 2 Performance Bond No. 3o X305 Payment Bond (Labor and Materials) Bond No. 302-(1°)30 _ Warranty or Maintenance Bond No. TRACT AND DEVELOPMENT Faithful Performance Bond No. Labor and Material Bond No. Guarantee and Warranty Bond No. Monument Bond No. Franchise Bond No. Letter of Credit Bond No. Other Re: Tract No. Approved 10/2 2V (Council App fffffoval ate) CC No. D 5 Agenda Item No. 21 MSC No. City Clerk Vault No. t!l 08, e.9) Other No. SIRE System ID No. A-- g:/forms/bond transmittal to treasurer *AIAI Document A310TM - 2010 Bid Bond SURETY: This document has CONTRACTOR: (Name,legal atoms and principal place o/hueinecc) important legal (Name,legal stands and address) Travelers Casualty and Surety Company of America consequences. a Performance Pipeline Technologies,Inc. One Tower Square Consultation with an 5292 System Drive Hartford,CT 06183 attorney Is encouraged Huntington Beach,CA 92649 with respect to its completion or OWNER: Mail Notices To: modification. (Name,legal status and address) Travelers Any singular reference to CAttn:Surety Claim Dept. Contractor,Surety, 2000 0 of Main Beach One Tower Square 2S1 A Owner,or other party Main Street shell be considered plural Huntington Beach,CA 92648 Hartford.CT 06183 where applicable. BOND AMOUNT:Ten Percent(10%)of Amount Bid PROJECT: CC No.1845/FY 2025/2026 Sewer lining Project (Name,location or address,and Project number,If any) The Contractor and Surety are bound to the Owner in the amount set forth above,for the payment of which the Contractor and Surety bind themselves,their heirs,executors,administrators,successors and assigns,jointly and severally,as provided herein.The conditions of this Bond arc such that if the Owner accepts the bid of the Contractor within the time specified in the hid documents,or within such time period as may he agreed to by the Owner and Contractor,and the Contractor either(I)enters into a contract with the Owner in accordance with the terms of such bid,and gives such bond or bonds as may be specified in the bidding or Contract Documents,with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner,for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof;or(2)pays to the Owner the difference,not to exceed the amount of this Bond,between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid,then this obligation shall be null and void,otherwise to remain in full force and effect.The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid.Waives of notice by the Surety shall not apply to any extension exceeding sixty(60)days in the aggregate beyond the time for acceptance of bids specified in the bid documents,and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty(60)days. If this Bond is issued in connection with a subcontractor's bid to a Contractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall he deemed to be Crntractur. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project,any provision in this Bored conflicting with said statutory or legal requirement shall he deemed deleted het-claim and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished,the intent is that this Bond shall be construed an a statutory brad and nut as a common law bond. Signed and scaled this 19th day of March,2026 Performance Pipeline Technologies,Inc. (Principal) (Seal) �e1��J�' tr' � ' � (Witness) � (stria) Gene Glassburner,General Manager (6:).).All:tiz Tray: = asu I r Su ety Company of America (Wit . ) Danielle Lowery, itness f43i SEAL sc,' vY ( )A ,. :w P Thorne,Attorney-in-Fact ,,u .._ .'a: Ink AIA Document A310,n- 2010.Copyright 1N191,1,1970 and 2010 by The American Institute of Architects.All rights reserved.WARNING:in., ,1111 Purchasers are permitted to reproduce ten(10)copies of this document when completed.To report cow/fight violations of MA Contract Documents,email The American Institute of Architects'legal counsel,Sspr^9hl'Sass cog. cane CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT �:: -,., <+ •. -;rcrc,"4-c'(:<-.rcccxx-x'.c:crccX-.crc.c-4c;•:,c rc.ccr,:cc:r;r,-..-4:04:!' ,c:C,crcx-A cxr.c ;t C. 4.rctx.<--,.-r,;K^. A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of Orange ) On Moct,h, t'-t ,2o'L4 before me, Aiden James Swaner, Notary Public , Date Here Insert Name and Title of the Officer personally appeared '0\e- 9.0,0.1A I c b to' b f ner Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies),and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. AVENJAMESSWANER WITNESS my hand and official seal.4iiiiwCommiaabn K 2547694 ^may:' Notary Pubbc-California I Y^, ', ORANGECounry Signature My Comm.EWpiree FEB 13,2030 :41:_-41.4.:_ ________________� Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness, accuracy, or validity of that document. Missouri State of California County of St.Louis _ ) On March 19th.2026 _ before me, -Ivy Danielle Lowery,Notary Public (insert name and title of the officer) personally appeared Andrew P.Thome,Attorney-In-Fact who proved to me on the basis of satisfactory evidence to be the person(s)whose name(s)is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s)on the instrument the person(s), or the entity upon behalf of which the person(s)acted,executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. IVY DANIELLE L0WMERY Public-Notify Sal WITNESS my hand and official seal. $ TE OF St LOtal County RI My��ion*ku ,2029 OC • C Seal) 1 Ivy Dani I Lowery,Notary Public Travelers Casualty and Surety Company of America ,�►•. Travelers Casualty and Surety Company TRAVELERS J st. Paul Fire and Marine Insurance Company POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS' That Travelers Casualty and Surety Company of America, Travelers Casualty and Surety Company, and St. Paul Firo and Marino Insurance Company are corporations duly organized under the laws of the State of Connecticut (herein collectively called the"Companies").and that the Companies do hereby make,constitute and appoint ANDREW P THOME of CHESTERFIELD , Missouri , their true and lawful Attomey(s)-in-Fact to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF,the Companies have caused this instrument to be signed,and their corporate seals to be hereto affixed,this 21st day of April, 2021. Oevo .. Niiir f8 *W01 State of Connecticut By __._. City of Hartford ss. Robert L.Rene , enior Vice President On this the 21st day of April, 2021, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of each of the Companies, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of said Companies by himself as a duly authorized officer. IN WITNESS WHEREOF,I hereunto set my hand and official seal. \l // n�' CO:ANY ` /'/�/y �///' My Commission expires the 30th day of June,2026 1 °guebf""" ---- Anna P.Nowik,Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of each of the Companies,which resolutions are now in full force and effect,reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President,any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds,recognizances,contracts of indemnity,and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee end revoke the power given him or her,and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is In writing and a copy thereof is filed in the office of the Secretary;and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory In the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required) by one or more Attorneys-In-Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority;and It is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President,any Assistant Vice President,any Secretary,any Assistant Secretary,and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in- Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof,and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I. Kevin E. Hughes, the undersigned, Assistant Secretary of each of the Companies, do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies,which remains in full force and effect. Dated this 19th day of March 2026 n+mronn A rwfram. 6\41.4 it emir a w _ � corm reS ° -+s r* Kevin E.Hughes,Assi tant Secretary To verity the authenticity of this Power of Attorney,please call us at 1-800-,421-3880. Please refer to the above-named Attonrey(s)-in-Fact and the details of the bond to which this Power of Attorney Is attached. No, 5546 STATE OF CALIFORNIA DEPARTMENT OF INSURANCE sAN FRANCISCO Amended Certificate of Authority • THIS IS TO CERTIFY,That,/,ww u:i to the Insurance Crxle of the Stare of C'all/yrnia, Trmialers Casualty and Surety Company of America ofHurffortl Conneoiic'tu.organ&ed under the laws of Connecticut,subject wits Xrride tlf InemportItion ar other fundanienhil organisational do tmtants,Is hereby authorised to transact within fhle'Stare,srdJeat:to all provtsdoes.of thth.Certlficata,the followLtg cicsses of insurance: Fire Mariner Surety,Disability,Rlate.CInts,LtahtRty,Woriter a'Compensation, Common c riletUtibtlliy,Boiler and Maciaiuery,Butgtary,Crcdit,spiirtkier, 'I"ettm and Vehicle,.Automobile,;Aire raft,.ani•Mlseellaueons as strch.classes arc rroiaor nuttr•hti!regfdttr•be dtifinuel in the lnsurance.ltnes of thelttue of.California.al(forrria., *(IS.CERTIFICATE is iprasSly conilitio,wij upon that holder hereof now arid herettfter bc1,, irr jr!! compliance Wilt all,anti not.irt.violation of ally,of thegppllrrtble'laitts and lawf rl.requtretnent Indite Jostler rtathurily-if the laws oftheSrareofCrhfornivas long itsswthlrtws'orregttirenretrtsnrcb.i 7teiandaprlkah/c, and as xuch laws and requirements tioru.ars,or may hereafler•beehmtged hit amanita IN WITNESS WI•iBREQtr, effective as of the 1st drily of,J'rtly, 199?, 1 have hereunto.set.any hand and caused iiiy official seal to.be affixed this 16Th alai,afAmu,.NY94 Fee $92.00 Chunk Quackenbush • Insrdnau.Convuirsioaat not-NO. • Filed $/2$197 By i'ittaria S.Sidharr' Deputy Certification I, the undersigned Insurance Commissioner.of the State of California,'do hereby cert0.tltru 1 have compared the above comp of Certificate ofAuthotity with the rltrpliCote of original nor.on file in my office,and that the same is a frill, tree, and correct•tr'trnstnipt there'll,and of the suhele of said duplicate, and said • Certificate of Authority is now iu fail farts rnut a racy. LN WITNESS WI3ERE.UF,t Immireraunro set any hand and caused airy official skid to le aff xeci this 31st day of December.3067. Sterw f vtzrrer hwtaanro Cwvb,ttzrwter Pauline U•.4nrlratr { ♦ pCd ✓w~` {lr. - :,,Yn f Y Sir� j�ry4 t� -.�+y�+�„„:,;q4,.' yy,,� i �ii� , ���,,,.� iS • ?� � � •S r � ....r'.-.t .. ' ti4'L�G,7. SGAi:u id* • 3s:�: :+did+sia,.E'ft'e�i-+14+4::+.9,N.. .�.3.`i,� ,.. ......_ .. ._..._. ..,.... ..c `. r�:. `. 5292 System Drive Huntington Beach,CA.92649 Phone(714)536-7386 PERFORMANCE PIPELINE TECHNOLOGIES OFFICIAL BID SECURITY-DO NOT OPEN PROJECT MANAGER—Michael Aguas Project Name: FY 2025/26 Sewer Lining Project CC#: 1845 Bid Opening Date: March 19, 2026 at 10:00 AM MAR 18 2l?6 ;rformance Pipeline Technologies R#1000561121 (((� �r7IIr•nm \'0•TING7a � ••••��pp R P O Rq TF0••i• o> .•• -- - •i FY 2025/26 Sewer �,f,,,�,--„ :r,.. . � LiningProject � � Construction Contract -= - - , '�''/ -... OO1845 „ski. 44:61. e • 17, 190` , ••' QL 61°UNTIN June 2 , 2026 Council City Meeting 495 Background The City's Utility Division implements an annual sewer lining program to rehabilitate ageing sewer mains identified through CCCTV inspections and maintenance history. This project includes lining approximately 29,850 linear feet of sewer main using UV CIPP technology across multiple pipe diameters (8"-15"). Work also includes rehabilitation of 66 manholes and restoration of service laterals. Project locations are shown in the accompanying maps. The Sewer Lining Project is essential to public health and safety, in addition to , 0, 01.ING �� preserving the life of the City's existing sewer infrastructure. This project helps � o�a•��osvoRgrfo••y prevent sewer overflows, tree root intrusion, groundwater seepage, and calcium eit, �s.��`` build-up. \ -- - __ s 'c4; •.,rte ,� - 1;-, ifs - A Vied;•••: .::'411 �� � =�0UNTY cii' +iii►/�' 496 Projects FY 2025/26 Sewer Lining Project CC1845 L• SewerManholestoRehablli(ate=0 --Lateralsa2 I • New UV Sewer Lining Cure-in-Place Pipe =Sewer Llnes to ReMa6llitate=12'•271 ft Sewer Facilities �� On.4/hol Nark (CIPP) Technology E • Estimated 29,850 linear feet of existing - sewer main to be lined ., t� �, . • Long Term Sewer Main Infrastructure lawPA,„.% Protection from groundwater seepage through minor cracks and from tree root intrusion. -- —_--- • Total of 66 manhole's to be rehabilitated ..... �T I G � I o- M' •r .\a�pRPOR \ a 117 11 41 . _ --.. R Fp�\ I. 127 128 1 c�; S t., , _' 137 138 139 1 \ «. Reporting District 1?H 1k17"lam '••fig O eve '7 1404 ..�\≤:c AO UNTY it IF 497 Projects FY 2025/26 Sewer Lining Project CC1845 , Sewer Manholes to Rehabllltate=38 °— Laterals=404 City Sewer Mainline Zones {�Sewer Lines to Rehabilitate=8"-16450ft,10"-457ft 12"-457 ft,15"•269ft �. n _ - . SewerFac,littes to receive New UV Lined • CIPP & Manhole Rehabilitation :• = € � l �: District 146 .. District 128 v ' District 199 , r: District 424 ° 71 e District 426 i 0.. . 07 't - O- a � �.a•n OI ���ee,`, a4POR �Oe.�e1411 -136- 137 f y - ('` N. _ ; �. . 3 a146� 147 � c a � a R o er o , \ S z - • t 155 156 1571 �\{',� . . 9.;j Q Reporting District 146Ilk a ,. i _-, g P� ���i�1 f epuNT`( c' irri +..sir, 498 Fundingand S Current Funding: • The FY 2025-26 Sewer Lining Project is fully funded through the Sewer Improvement Fund, Account No. 51189028.82600 • No additional appropriations will be required r, fSchedule: • Design Phase completed 24/25 ,�<.���'��.. o <3 • Construction to begin early summer 2026F�,`� __ c0ONTY 1i/I 499 Bid / Recommendation Lowest Responsive & Responsible Bid : • Performance Pipeline Technologies, Inc. Huntington Beach, California • Bid amount: $1 ,970,231 .60 • 15% Contingency: $295,534.74 • Supplemental: $100,000.00 6 Total Construction Cost: $2,365,766.34 _ ��1TIN671 r/// Staff recommends awarding the Construction _ S•.; � Contract to Performance Pipeline Technologies, Inc. ��, ;.Y ,_ r� ` ,4-8 7„, <col n NN•.N °11 Y C, 500 , Questions ? r, " „ , ,. E , , , I _ , ,,„,,j,,,,,, / 1 ( ix, ,„, , ,,,,,_,, ..._._ _ ...7 t,,,,,,...77, ::...%:...tr,....;;;;,.,..,.=,,i vett y qg.x iii kt-: ' `may y „ y Sl y>. -____& £ ^f f ,,, i t r i a --7. 501